EX-99 2 contract2005.htm EXHIBIT 99.1, CONTRACT FOR ADDITION TO MAIN OFFICE Contract for Addition

 

Exhibit 99.1

 

 

1997 EDITION

 

 

 

AlA DOCUMENT

A1O1-1997

 

 

Standard Form of Agreement Between Owner and Contractor

 

where the basis of payment is a STIPULATED SUM

 

 

This document has impor-

AGREEMENT made as of the 24th day of January in the year two thousand and five.

tant legal consequences.

(In words, indicate day, month and year)

Consultation with an

 

attorney is encouraged

BETWEEN the Owner:

with respect to its

(Name, address and other information)

completion or modification.

 

 

Community National Bank

 

4811 US Route 5

AIA Document A201-1997,

Derby, VT  05829

General Conditions of the

 

Contract for Construction, is

and the Contractor:

adopted in this document by

(Name, address and other information)

reference. Do not use with

 

other general conditions

Kingdom Construction Inc.

unless this document is

PO Box 219

modified.

Newport, VT  05855

 

 

 

 

This document has been

 

approved and endorsed by

The Project is:

The Associated General

(Name and location)

Contractors of America.

 

 

Addition & Renovation to

 

Community National Bank

 

4811 US Route 5

 

Derby, Vermont  05829

 

 

 

The Architect is:

 

(Name, address and other information)

 

 

©1997 AIA ®

Black River Design Architects PLC

AIA Document A101-1997

73 Main Street

OWNER-CONTRACTOR

Montpelier, VT  05602

AGREEMENT

 

 

The Owner and Contractor agree as follows.

The American Institute

 

of Architects

 

1735 New York Avenue, N.W.

 

Washington, D.C. 20006-5292

Copyright 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, © 1997 by The American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution.

1

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

ARTICLE 1  THE CONTRACT DOCUMENTS

 

The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement and Modifications issued after execution of this Agreement; these form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 8.

 


ARTICLE 2  THE WORK OF THIS CONTRACT

 

The Contractor shall fully execute the Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others.

 


ARTICLE 3  DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION

 

3.1  The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner.
(Insert the date of commencement if it differs from the date of this Agreement or, if applicable, state that the date will be fixed in a notice to proceed.)

 

Commencement date: January 10, 2005

 

If, prior to the commencement of the Work, the Owner requires time to file mortgages, mechanic's liens and other security interests, the Owner's time requirement shall be as follows:

 

 

 

3.2  The Contract Time shall he measured from the date of commencement.

 

3.3  The Contractor shall achieve Substantial Completion of the entire Work not later than            days from the date of commencement, or as follows:

 

(Insert number of calendar days. Alternatively, a calendar date may be used when coordinated with the date of commencement. Unless stated elsewhere in the Contract Documents, insert any requirements for earlier Substantial Completion of certain portions of the Work.)

 


Substantial Completion by November 15, 2005

 

 

 

, subject to adjustments of this Contract Time as provided in the Contract Documents.

 

(Insert provisions, if any, for liquidated damages relating to failure to complete on time or for bonus payments, for early completion of the Work.)

 

 

©1997 AIA ®

 

AIA Document A101-1997

 

OWNER-CONTRACTOR

 

AGREEMENT

 

 

 

The American Institute

 

of Architects

 

1735 New York Avenue, N.W.

 

Washington, D.C. 20006-5292

 

2

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

 

ARTICLE 4  CONTRACT SUM

 

4.1  The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance of the Contract. The Contract Sum shall be Three Million, Three Hundred Seventy Thousand, Eight Hundred Twenty-five and 85/100 Dollars ($3,370,825.85)
subject to additions and deductions as provided in the Contract Documents.

 


4.2  The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner:

 

(State the numbers or other identifications of accepted alternates. If decisions on other alternates are to be made by the Owner subsequent to the execution of this Agreement, attach a schedule of such other alternates showing the amount for each and the date when that amount expires.)

 

See attached 'Exhibit A'

 

Contractor to itemize all costs for self performed work on each requisition.

 

4.3  Unit prices, if any, are as follows:

 

 

 

 

 

ARTICLE 5  PAYMENTS

 

5.1  PROGRESS PAYMENTS

 

5.1.1  Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.

 


5.1.2  The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows:

 

 

 

5.1.3  Provided that an Application for Payment is received by the Architect not later than the first day of a month, the Owner shall make payment to the Contractor not later than the seventh day of the same month. If an Application for Payment is received by the Architect after the application date fixed above, payment shall be made by the Owner not later than thirty days after the Architect receives the Application for Payment.

  © 1997 AIA®
  AIA DOCUMENT A101-1997
  OWNER-CONTRACTOR
  AGREEMENT


5.1.4  Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. The schedule of values shall be prepared in such form and supported by such data to substantiate its accuracy as the Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis for reviewing the Contractor's Applications for Payment.

  The American Institute
  of Architects
  1735 New York Avenue, N.W.
  Washington, D.C. 20006-5292

 

 

 

3

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

 

5.1.5  Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment.

 


5.1.6  Subject to other provisions of the Contract Documents, the amount of each progress pay-rent shall be computed as follows:

 

.1

Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of ten percent (10%). Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute shall be included as provided in Subparagraph 7.3.8 of AIA Document A201-1997;

 

.2

.Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage of ten percent (10%);

 

.3

Subtract the aggregate of previous payments made by the Owner; and

 

.4

Subtract amounts, if any, for which the Architect has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of AIA Document A201-1997.

 

5.1.7  The progress payment amount determined in accordance with Subparagraph 5.1.6 shall be further modified under the following circumstances:

 

.1

Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to the full amount of the Contract Sum, less such amounts as the Architect shall determine for incomplete Work, retainage applicable to such work and unsettled claims; and (Subparagraph .9.8.5 of .AIA Document A201-1997 requires re/ease of' applicable retainage upon Substantial Completion of Work with consent of surety ,if any)

 

.2

Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance with Subparagraph 9.10.3 of AIA Document A201-1997.

 

5.1.8  Reduction or limitation of retainage, if any, shall be as follows:

 

(If it is intended, prior to Substantial Completion of the entire Work, to reduce or limit the retainage resulting from the percentages inserted in Clauses 5.1.6.1 and 5.1.6.2 above, and this is not explained elsewhere in the Contract Documents, insert here provisions for such reduction or limitation.)

 

At 50% of contract completion, and if all parties are in agreement, eliminate withholding further retainage.

 


5.1.9  Except with the Owner's prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site.

 


5.2  FINAL PAYMENT

  © 1997 AIA ®
  AIA DOCUMENT A101-1997


5.2.1  Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when:

  OWNER-CONTRACTOR
  AGREEMENT

.1

the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as provided in Subparagraph 12.2.2 of AIA Document A201-1997, and to satisfy other requirements, if any, which extend beyond final payment; and

  The American Institute
  of Architects
  1735 New York Avenue, N.W.
  Washington, D.C. 20006-5292

.2

a final Certificate for Payment has been issued by the Architect.

 

 

 

 

4

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

52.2  The Owner's final payment to the Contractor -shall be made no later than 30 days after the issuance of the Architect's final Certificate for Payment, or as follows:

 

 

 

ARTICLE 6  TERMINATION OR SUSPENSION

 

6.1  The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201-1997.

 

6.2  The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201-1997.

 

ARTICLE 7  MISCELLANEOUS PROVISIONS

 

7.1  Where reference is made in this Agreement to a provision of AIA Document A201-1997 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents.

 

 

 

7.2  Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located.

 

(Insert rate of interest agreed upon, if any)

 

 

 

(Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Contractor's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.)

 

 

 

7.3  The Owner's representative is:
(Name, address and other information)

 

 

 

Steve Marsh
Louise Bonvechio

 

7.4  The Contractor's representative is:
(Name, address and other information)

 

Karl Chaffee
Luc Quirion

© 1997 AIA ®
AIA DOCUMENT A101-1997

7.5  Neither the Owner's nor the Contractor's representative shall be changed without ten days' written notice to the other party.

OWNER-CONTRACTOR
AGREEMENT

7.6  Other provisions:

The American Institute
of Architects
1735 New York Avenue, N.W.
Washington, D.C. 20006-5292

 

 

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

5

 

 

ARTICLE 8  ENUMERATION OF CONTRACT DOCUMENTS

 

8.1  The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows:

 

8.1.1  The Agreement is this executed 1997 edition of the Standard Form of Agreement Between Owner and Contractor, AIA Document A101-1997.

 

 

 

8.1.2  The General Conditions are the 1997 edition of the General Conditions of the Contract for Construction, AIA Document A201-1997.

 

 

 

8.1.3  The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated November 8, 2004, and are as follows:

 


 

Document

Title

Pages

See Exhibit 'B'

 

 

 

 

 

8.1.4  The Specifications are those contained in the Project Manual dated as in Subparagraph 8.1.3, and are as follows:
(Either list the Specifications here or refer to an exhibit attached to this Agreement.)

 

Section

Title

Pages

 

 

 

See Exhibit 'C'

 

 

 

 

 

 

8.1.5  The Drawings are as follows, and are dated November 8, 2004 unless a different date is shown below:
(Either list the Drawings here or refer to an exhibit attached to this Agreement.)

 

Number

Title

Date

See Exhibit 'D'

 

 

 

 

 

 

 

 

©1997 AIA ®

 

AIA Document A101-1997

 

OWNER-CONTRACTOR

 

AGREEMENT

 

 

 

The American Institute

 

of Architects

 

1735 New York Avenue, N.W.

 

Washington, D.C. 20006-5292

 

 

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

6

 

8.1.6  The Addenda, if any, are as follows:

Number

Date

Pages

 

 

 

   1

November 15, 2004

1 (plus attachments)

   2

November 19, 2004

52 (plus attachments)

   3

November 24, 2004

3 (plus attachments)

 

Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 8.

 

8.1.7  Other documents, if any, forming part of the Contract Documents are as follows:

(List here any additional documents that are intended to form part of the Contract Documents. AIA Document A201-1997 provides that bidding requirements such as advertisement or invitation to bid, Instructions to Bidders, sample forms and the Contractor's bid are not part of the Contract Documents unless enumerated in this Agreement. They should be listed here only if intended to be part of the Contract Documents.)

 

See Exhibit 'E'

 

This Agreement is entered into as of the day and year first written above and is executed in at least three original copies, of which one is to be delivered to the Contractor, one to the Architect for use in the administration of the Contract, and the remainder to the Owner.

/s/ Stephen P. Marsh

/s/Karl Chaffee

OW N E R (Signature)

CONTRACTOR, (Signature)

Stephen P. Marsh, President & COO

Karl Chaffee, Owner

(Printed name and title)

(Printed name and title)

 

 

CAUTION:  You should sign an original AIA document or a licensed reproduction. Originals contain the AIA logo printed in red; licensed reproductions are those produced in accordance with the Instructions to this document.

 

 

©1997 AIA ®

 

AIA Document A101-1997

 

OWNER-CONTRACTOR

 

AGREEMENT

 

 

 

The American Institute

 

of Architects

 

1735 New York Avenue, N.W.

 

Washington, D.C. 20006-5292

 

7

WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

EXHIBIT 'A'

Bid Tabulation

Actual

Project:

Phase 2/3 Cost:

$3,172,290.62

Community National Bank, Ph.2/3

Sales Tax:

($1,453.56)

Date:

Phase 1 Cost:

$240,852.83

November 24, 2004

Building Cost:

$3,411,689.89

Estimator:

C.M. 6% Fee:

$204,701.39

Karl Chaffee

A&E 10% Fee:

$361,639.13

rev. 1/19/05

Contingency:

$86,257.17

Total:

$4,064,287.59

Phase 2/3

Contract Amount:

$3,361,087.29

($24,225.92)

$174,231.75

$2,869,162.79

$3,172,290.62

Description

Contractor

Material

Labor

Subs

Total

General Conditions

Kingdom

$21,580.00

$99,417.34

$83,550.00

$204,547.34

Demolition

Kingdom

$3,468.56

$12,569.04

$13,860.00

$29,897.60

Building Relocation

Deleted

$0.00

Garage Construction

Kingdom

$7,489.08

$8,619.52

$3,290.28

$19,398.88

Sitework

Gosselin's

$368,235.00

$368,235.00

Paving

Grays

$51,109.00

$51,109.00

Linestriping

Franks Linestriping

$800.00

$800.00

Allenblock

Kingdom

$2,520.00

$2,520.00

Dumpster Enclosure

Roundhill Fence

$3,279.51

$3,279.51

Building Concrete

Gosselins

$249,100.00

$249,100.00

Site Concrete

Above

$0.00

$0.00

Masonry

Royce Guyer

$56,400.00

$56,400.00

Cold Formed Metal Framing

P. Brodeur, below

$0.00

$0.00

Structural Steel

Reliance

$292,000.00

$292,000.00

Steel Joists and Deck

Reliance, above

$0.00

$0.00

Steel Erection

Reliance, above

$0.00

$0.00

Rough Carpentry

Kingdom

$9,386.71

$11,020.05

$20,406.76

Interior Finish Carpentry

Kingdom

$17,563.33

$18,454.29

$36,017.62

Exterior Finish Carpentry

Kingdom

$1,347.73

$1,179.81

$2,527.54

Architectural Woodwork

See Allowances

$0.00

Fluid Applied Waterproofing

NICOM

$11,578.00

$11,578.00

Vapor and Air Barriers

Kingdom

$1,176.52

$564.47

$1,740.99

Rigid Insulation

Kingdom

$2,337.12

$1,024.83

$3,361.95

Spray Foam Insulation

NEFC/Kingdom

$2,000.00

$2,104.80

$9,092.00

$13,196.80

Firestopping

Kingdom

$500.00

$841.92

$1,341.92

Manufactured Wall Panels

Kingdom

$10,904.95

$5,913.39

$16,818.34

Single Ply Membrane Roof

Magog

$86,829.00

$86,829.00

Shingle Roofing

Above

$0.00

Flashing and Sheetmetal

Magog, above

$0.00

Skylights

Deleted

$0.00

Joint Sealants

Kingdom

$1,000.00

$1,400.00

$2,400.00

Doors and Frames

HCI Craftsman

$48,866.00

$6,018.41

$54,884.41

Finish Hardware

HCI, above

$6,303.88

$6,303.88

Overhead Doors

Troy Overhead Door

$3,994.00

$3,994.00

Aluminum Entrys/Storefronts

Mayo's

$138,348.00

$138,348.00

Aluminum Windows

Mayo's, above

$0.00

Glass and Glazing

Mayo's, above

$0.00

Aluminum Curtainwalls

Mayo's, above

$0.00

Wood Windows

Oakes Brothers

$1,276.08

$200.00

$1,476.08

LGMF, Drywall

P. Brodeur

$188,800.00

$188,800.00

Flourocarbon Coatings

See other division

$0.00

$0.00

Metal Coatings

See other division

$0.00

$0.00

Painting

Cluba/Hinman

$55,000.00

$55,000.00

Acoustical Ceilings

AJ Interiors

$46,805.00

$46,805.00

Flooring

Allowance

$106,000.00

$106,000.00

Signage

See allowance

$0.00

$0.00

Fire Extinguishers

Under separate contract

$0.00

$0.00

Bath Accessories

Under separate contract

$0.00

$0.00

Projection Screens

Under separate contract

$0.00

$0.00

Residential Appliances

Under separate contract

$0.00

$0.00

Roller Shades

Under separate contract

$0.00

$0.00

Foot Grilles

Under separate contract

$0.00

$0.00

Sprinkler

MV Sprinkler

$45,000.00

$45,000.00

Mechanical

Mechanical

$669,990.00

$669,990.00

Electrical

Ames

$338,744.00

$338,744.00

Route 5: 2 - 24" culverts

Deleted

$0.00

$0.00

Landscaping

Reduced allowance

$10,000.00

$10,000.00

Pavers and planters at front entry

Deleted

$0.00

$0.00

Canopies @ plaza - $8,000/each

Deleted

$0.00

$0.00

Site signage

Under separate contract

$0.00

$0.00

Teller Work Stations

Under separate contract

$0.00

$0.00

Receptionists Desk

Under separate contract

$0.00

$0.00

Library/Conference

Under separate contract

$0.00

$0.00

Kitchen Cabinets

Under separate contract

$0.00

$0.00

Structural Work @ Waiting Area

Reduced allowance

$10,000.00

$10,000.00

Ornamental Stairs

Reduced allowance

$20,000.00

$20,000.00

Chimney Enclosure

Allowance

$3,000.00

$3,000.00

Sunshades

Deleted

$0.00

$0.00

Miscellaneous Metals

Reduced allowance

$10,000.00

$10,000.00

Guardrails

Deleted

$0.00

$0.00

Blower Door Test

By Owner

$0.00

$0.00

Fireplaces

Under separate contract

$0.00

$0.00

Door Access System

Deleted

$0.00

$0.00

Power Company Charges

Allowance

$15,000.00

$15,000.00

Upgrades per L&I permit letter

Allowance

$2,000.00

$2,000.00

Entrance/Planter Allowance

Allowance

$50,000.00

$50,000.00

Additional Adjustments

See attachment

($76,561.00)

($76,561.00)

Additional Adjustments per Last Line Item on Bid Tab

Actual/

Description

Value

Allowance

Change interior drywall finish in gargare to painted OSB. Delete 1 x 3 ceiling furring.

($945.00)

Actual

Reuse existing windows in garage.

($1,275.00)

Actual

Eliminate ten interior borrowed lites.

($2,500.00)

Allowance

Modify ceilings to 2 x 4 tegular in non-public areas

($2,000.00)

Allowance

Modify mechanical controls (5% reduction)

($4,608.00)

Allowance

Modify mechanical systems (5% reduction)

($28,887.00)

Allowance

Waterproof only between existing entrances

($8,000.00)

Allowance

Patch floors only in rooms 002-006

($2,000.00)

Allowance

Leave Library/Conference as-is

($5,000.00)

Allowance

Change ceramic tile and ceramic base to VCT and 4" rubber base in all bathrooms

($7,897.00)

Allowance

Eliminate Builders Risk Insurance (purchased by CNB)

($13,440.00)

Actual

Total:

($76,561.00)

EXHIBIT 'B'

PROJECT MANUAL TABLE OF CONTENTS

ADDITION AND RENOVATIONS TO

COMMUNITY NATIONAL BANK

Derby, Vermont

PROJECT MANUAL COVER SHEET

PROJECT MANUAL TABLE OF CONTENTS

INVITATION TO BID

BID FORM

INDEX OF DRAWINGS

INDEX TO SPECIFICATIONS

TECHNICAL SPECIFICATIONS

 

 

 

 

PROJECT MANUAL TABLE OF CONTENTS - 1

 

 

INDEX TO SPECIFICATIONS                                                         EXHIBIT 'C'

DIVISION 1 - GENERAL REQUIREMENTS

01010

SUMMARY OF WORK

01020

ALLOWANCES

01026

UNIT PRICES

01027

APPLICATIONS FOR PAYMENT

01030

ALTERNATES

01035

MODIFICATION PROCEDURES

01040

PROJECT COORDINATION

01050

FIELD ENGINEERING

01045

CUTTING AND PATCHING

01095

REFERENCE STANDARDS AND DEFINITIONS

01200

PROJECT MEETINGS

01300

SUBMITTALS

01400

QUALITY CONTROL SERVICES

01500

TEMPORARY FACILITIES

01600

MATERIALS AND EQUIPMENT

01631

PRODUCT SUBSTITUTIONS

01700

PROJECT CLOSE-OUT

01740

WARRANTIES AND BONDS

 

 

DIVISION 2 - SITE WORK.

02000

EXISTING UTILITIES AND UNDERGROUND STRUCTURES

02030

CLEARING, GRUBBING, AND STRIPPING

02060

BUILDING DEMOLITION

02070

SELECTIVE BUILDING DEMOLITION

02200

EROSION CONTROL

02210

DEWATERING

02331

EXCAVATING, TRENCHING, AND BACKFILLING-VT

02340

ROCK REMOVAL

02350

SOIL COMPACTION

02360

STONE FILL AND RIP RAP

02500

WATER MAINS AND APPURTENANCES

02515

UNIT PAVERS

02526

SANITARY SEWERS, MANHOLES, AND APPURTENANCES-VT

02550

STORM DRAINAGE SYSTEMS

02710

BITUMINOUS CONCRETE PAVING

02711

FOUNDATION DRAINAGE SYSTEM

02900

LOAMING, SEEDING, AND FERTILIZING

02910

RESTORATION OF SURFACES

DIVISION 3 - CONCRETE

03102

CONCRETE FORMWORK

03202

CONCRETE REINFORCEMENT

03300

CAST IN PLACE CONCRETE

DIVISION 4 - MASONRY

04200

UNIT MASONRY

04720

CAST STONE

DIVISION 5 - METALS

05100

STRUCTURAL STEEL

05200

STEEL JOISTS

05310

STEEL FLOOR DECK

05400

COLD-FORMED METAL FRAMING

05500

METAL FABRICATIONS

DIVISION 6 - WOOD AND PLASTICS

06100

ROUGH CARPENTRY

DIVISION 7 - THERMAL AND MOISTURE PROTECTION

07120

FLUID-APPLIED WATERPROOFING

07190

VAPOR AND AIR INFILTRATION RETARDERS

07210

BUILDING INSULATION

07270

FIRESTOPPING

07410

MANUFACTURED WALL PANELS

07530

SINGLE-PLY MEMBRANE ROOFING

07600

FLASHING AND SHEET METAL

07810

PLASTIC UNIT SKYLIGHTS

07901

JOINT SEALANTS

DIVISION 8 - DOORS AND WINDOWS

08111

STANDARD STEEL DOORS AND FRAMES

08211

FLUSH WOOD DOORS

08360

SECTIONAL OVERHEAD DOORS

08410

ALUMINUM ENTRANCES AND STOREFRONTS

08520

ALUMINUM WINDOWS

08710

DOOR HARDWARE

08800

GLAZING

08920

GLAZED ALUMINUM CURTAIN WALLS

DIVISION 9 - FINISHES

09255

GYPSUM BOARD ASSEMBLIES

09850

FLUOROCARBON COATINGS

09860

GALVANIZING AND METAL COATINGS

09900

PAINTING

DIVISION 10 - SPECIALTIES

10100

VISUAL DISPLAY BOARDS

10425

SIGNS

10522

FIRE EXTINGUISHERS, CABINETS, AND ACCESSORIES

10800

TOILET AND BATH ACCESSORIES

DIVISION 11 - EQUIPMENT

11132

PROJECTION SCREENS

11452

RESIDENTIAL APPLIANCES

DIVISION 12 - FURNISHINGS

12494

ROLLER SHADES

12680

FOOT GRILLES

DIVISION 13 - SPECIAL CONSTRUCTION  N/A

DIVISION 14 - CONVEYING SYSTEMS  N/A

DIVISION 15 - MECHANICAL  N/A

DIVISION 16 - ELECTRICAL  N/A

 

 

 

INDEX OF DRAWINGS                                                         EXHIBIT 'D'

C1

EXISTING CONDITIONS SITE PLAN

C2

GRADING SITE PLAN

C3

MISCELLANEOUS DETAILS

C4

MISCELLANEOUS DETAILS

C5

EROSION CONTROL DETAILS

 

 

L1

LANDSCAPE AND ORIENTATION PLAN

L2

ENLARGED PLAZA PLAN AND CANOPY DETAILS

L3

ENLARGED PLAZA STAIRS AND EQUIPMENT BAY

 

 

D1

PARTIAL DEMOLITION PLANS

 

 

A1

LOWER LEVEL FLOOR PLAN

A2

FIRST FLOOR PLAN

A3

SECOND FLOOR PLAN

A4

ROOF PLAN

A5

BUILDING ELEVATIONS

A6

BUILDING SECTIONS

A7

WALL SECTIONS

A8

WALL SECTIONS AND DETAILS

A9

DETAILS

A10

DETAILS

A11

STAIR PLANS AND DETAILS

A12

ENLARGED PLANS AND INTERIOR ELEVATIONS

A13

LOWER LEVEL REFLECTED CEILING PLAN

A14

FIRST FLOOR REFLECTED CEILING PLAN

A15

SECOND FLOOR REFLECTED CEILING PLAN

A16

NOT USED (PHASE ONE)

A17

MAINTENANCE GARAGE PLANS

A18

DOOR SCHEDULE

A19

DOOR SCHEDULE

A20

WINDOW SCHEDULE

A21

FINISH SCHEDULE

A22

FINISH SCHEDULE

 

 

S1

FOUNDATION PLAN

S2

FIRST FLOOR FRAMING PLAN

S3

SECOND FLOOR FRAMING PLAN

S4

ROOF FRAMING PLAN

S5

STRUCTURAL SECTIONS

S6

STRUCTURAL SECTIONS

S7

TYPICAL PIER AND BASEPLATE DETAILS

S8

TYPICAL STRUCTURAL DETAILS

S9

STRUCTURAL NOTES

 

 

H1.0

LOWER LEVEL HVAC PLAN

H1.1

FIRST FLOOR HVAC PLAN

 

INDEX OF DRAWINGS - 1

H1.2

SECOND FLOOR HVAC PLAN

H4.0

HVAC SCHEDULES & DETAILS

M0.0

PH 1A MECHANICAL PIPING PLAN

M1.0

LOWER LEVEL MECHANICAL PIPING PLAN

M1.1

FIRST FLOOR MECHANICAL PIPING PLAN

M1.2

SECOND FLOOR MECHANICAL PIPING PLAN

M1.3

SNOWMELT PIPING PLAN

M2.0

HOT WATER FLOW DIAGRAM

M2.1

CHILLED WATER FLOW DIAGRAM

M3.0

MECHANICAL PIPING DETAILS PLAN

M3.1

MECHANICAL PIPING DETAILS PLAN

M4.0

MECHANICAL SCHEDULES AND NOTES PLAN

P1.0

LOWER LEVEL PLUMBING PLAN

P1.1

FIRST FLOOR PLUMBING PLAN

P1.2

SECOND FLOOR PLUMBING PLAN

P4.0

PLUMBING SCHEDULES AND NOTES PLAN

 

 

ESITE-1

SITE LIGHTING PLAN

EL-1

LOWER LEVEL LIGHTING PLAN

EL-2

FIRST FLOOR LIGHTING PLAN

EL-3

SECOND FLOOR LIGHT PLAN

EP-1

LOWER LEVEL POWER PLAN

EP-2

FIRST FLOOR POWER PLAN

EP-3

SECOND FLOOR POWER PLAN

 

 

 

 

 

 

 

 

 

INDEX OF DRAWINGS - 2

 

Exhibit "E"

8.1.7

     Under Vermont Statue, for the Arbitration portion of this contract to be enforceable, this
"Acknowledgment of Arbitration" must be contained in this agreement.

 

Acknowledgment of Arbitration

 

We understand that this agreement contains an agreement to arbitrate. After signing this document, we understand that we will not be able to bring lawsuit concerning any dispute that may arise which is covered by the arbitration agreement, unless it involves a question of constitutional or civil rights. Instead, we agree to submit any such dispute to an impartial arbitrator.

 

 

 

/s/ Stephen P. Marsh

 

/s/ Karl Chaffee

Owner (signature)

 

Contractor

 

 

 

 

 

 

Stephen P. Marsh, President & COO

 

Karl Chaffee, Owner

(Printed name and title)

 

(Printed name and title)