Commitments And Contingencies

12 Months Ended

Dec. 31, 2019

Commitments and Contingencies Disclosure [Abstract]

Commitments And Contingencies

Note 23. Commitments and Contingencies

As a result of issues generated in the ordinary course of business, the Companies are involved in legal proceedings before various courts and are periodically subject to governmental examinations (including by regulatory authorities), inquiries and investigations. Certain legal proceedings and governmental examinations involve demands for unspecified amounts of damages, are in an initial procedural phase, involve uncertainty as to the outcome of pending appeals or motions, or involve significant factual issues that need to be resolved, such that it is not possible for the Companies to estimate a range of possible loss. For such matters that the Companies cannot estimate, a statement to this effect is made in the description of the matter. Other matters may have progressed sufficiently through the litigation or investigative processes such that the Companies are able to estimate a range of possible loss. For legal proceedings and governmental examinations that the Companies are able to reasonably estimate a range of possible losses, an estimated range of possible loss is provided, in excess of the accrued liability (if any) for such matters. Any accrued liability is recorded on a gross basis with a receivable also recorded for any probable insurance recoveries. Estimated ranges of loss are inclusive of legal fees and net of any anticipated insurance recoveries. Any estimated range is based on currently available information and involves elements of judgment and significant uncertainties. Any estimated range of possible loss may not represent the Companies’ maximum possible loss exposure. The circumstances of such legal proceedings and governmental examinations will change from time to time and actual results may vary significantly from the current estimate. For current proceedings not specifically reported below, management does not anticipate that the liabilities, if any, arising from such proceedings would have a material effect on the Companies’ financial position, liquidity or results of operations.

Environmental Matters

The Companies are subject to costs resulting from a number of federal, state and local laws and regulations designed to protect human health and the environment. These laws and regulations affect future planning and existing operations. They can result in increased capital, operating and other costs as a result of compliance, remediation, containment and monitoring obligations.

Air

CAA

The CAA, as amended, is a comprehensive program utilizing a broad range of regulatory tools to protect and preserve the nation’s air quality. At a minimum, states are required to establish regulatory programs to address all requirements of the CAA. However, states may choose to develop regulatory programs that are more restrictive. Many of the Companies’ facilities are subject to the CAA’s permitting and other requirements.

MATS

In February 2019, the EPA published a proposed rule to reverse its previous finding that it is appropriate and necessary to regulate toxic emissions from power plants. However, the emissions standards and other requirements of the MATS rule would remain in place as the EPA is not proposing to remove coal and oil-fired power plants from the list of sources that are regulated under MATS. Although litigation of the MATS rule and the outcome of the EPA’s rulemaking are still pending, the regulation remains in effect and Dominion Energy and Virginia Power are complying with the applicable requirements of the rule and do not expect any adverse impacts to their operations at this time.

Ozone Standards

The EPA published final non-attainment designations for the October 2015 ozone standard in June 2018. States have until August 2021 to develop plans to address the new standard. Until the states have developed implementation plans for the standard, the Companies are unable to predict whether or to what extent the new rules will ultimately require additional controls. The expenditures required to implement additional controls could have a material impact on the Companies’ results of operations and cash flows.

Oil and Gas NSPS

In August 2012, the EPA issued an NSPS impacting new and modified facilities in the natural gas production and gathering sectors and made revisions to the NSPS for natural gas processing and transmission facilities. These rules establish equipment performance specifications and emissions standards for control of VOC emissions for natural gas production wells, tanks, pneumatic controllers, and compressors in the upstream sector. In June 2016, the EPA issued another NSPS regulation, for the oil and natural gas sector, to regulate methane and VOC emissions from new and modified facilities in transmission and storage, gathering and boosting, production and processing facilities. All projects which commenced construction after September 2015 are required to comply with this regulation. In October 2018, the EPA published a proposed rule reconsidering and amending portions of the 2016 rule, including but not limited to, the fugitive emissions requirements at well sites and compressor stations. The amended portions of the 2016 rule were effective immediately upon publication. Until the proposed rule regarding reconsideration is final, Dominion Energy and Dominion Energy Gas are implementing the 2016 regulation. Dominion Energy and Dominion Energy Gas are still evaluating whether potential impacts on results of operations, financial condition and/or cash flows related to this matter will be material.

ACE Rule

In July 2019, the EPA published the final rule informally referred to as the ACE Rule, as a replacement for the Clean Power Plan. ACE Rule applies to existing coal-fired power plants. The final rule includes unit-specific performance standards based on the degree of emission reduction levels achievable from unit efficiency improvements to be determined by the permitting agency. The ACE Rule requires states to develop plans by July 2022, to implement these performance standards. These state plans must be approved by the EPA by January 2024. While the impacts of

this rule could be material to Dominion Energy and Virginia Power’s results of operations, financial condition and/or cash flows, the existing regulatory frameworks in South Carolina and Virginia provide rate recovery mechanisms that could substantially mitigate any such impacts for the regulated electric utilities.

Carbon Regulations

In August 2016, the EPA issued a draft rule proposing to reaffirm that a source’s obligation to obtain a PSD or Title V permit for GHGs is triggered only if such permitting requirements are first triggered by non-GHG, or conventional, pollutants that are regulated by the New Source Review program, and to set a significant emissions rate at 75,000 tons per year of CO2 equivalent emissions under which a source would not be required to apply BACT for its GHG emissions. Until the EPA ultimately takes final action on this rulemaking, the Companies cannot predict the impact to their results of operations, financial condition and/or cash flows.

In December 2018, the EPA proposed revised Standards of Performance for Greenhouse Gas Emissions from New, Modified, and Reconstructed Stationary Sources. The proposed rule would amend the previous determination that the best system of emission reduction for newly constructed coal-fired steam generating units is no longer partial carbon capture and storage. Instead, the proposed revised best system of emission reduction for this source category is the most efficient demonstrated steam cycle (e.g., supercritical steam conditions for large units and subcritical steam conditions for small units) in combination with the best operating practices.

State Regulations

In May 2019, VDEQ issued a final rule establishing a state carbon regulation program with a 28.0 million ton initial state-wide carbon cap in 2020. The cap is reduced by approximately three percent per year through 2030, resulting in an ultimate cap of 19.6 million tons. The final rule includes a provision for VDEQ to delay implementation of the rule and possible adjustments to the baseline cap pending authorization from the General Assembly and Governor of Virginia. Once VDEQ is authorized to begin implementation of the rule, the impacts of this program could be material to Dominion Energy and Virginia Power’s results of operations, financial condition and/or cash flows; however, the existing regulatory framework in Virginia provides rate recovery mechanisms that could substantially mitigate any such impact.

Water

The CWA, as amended, is a comprehensive program requiring a broad range of regulatory tools including a permit program to authorize and regulate discharges to surface waters with strong enforcement mechanisms. The Companies must comply with applicable aspects of the CWA programs at their operating facilities.

Regulation 316(b)

In October 2014, the final regulations under Section 316(b) of the CWA that govern existing facilities and new units at existing facilities that employ a cooling water intake structure and that have flow levels exceeding a minimum threshold became effective.

The rule establishes a national standard for impingement based on seven compliance options, but forgoes the creation of a single technology standard for entrainment. Instead, the EPA has delegated entrainment technology decisions to state regulators. State regulators are to make case-by-case entrainment technology determinations after an examination of five mandatory facility-specific factors, including a social cost-benefit test, and six optional facility-specific factors. The rule governs all electric generating stations with water withdrawals above two MGD, with a heightened entrainment analysis for those facilities over 125 MGD. Dominion Energy and Virginia Power currently have 13 and seven facilities, respectively, that are subject to the final regulations. Dominion Energy anticipates that it may have to install impingement control technologies at certain of these stations that have once-through cooling systems. Dominion Energy and Virginia Power are currently evaluating the need or potential for entrainment controls under the final rule as these decisions will be made on a case-by-case basis after a thorough review of detailed biological, technology, cost and benefit studies. DESC is conducting studies and implementing plans as required by the rule to determine appropriate intake structure modifications at certain facilities to ensure compliance with this rule. While the impacts of this rule could be material to Dominion Energy and Virginia Power’s results of operations, financial condition and/or cash flows, the existing regulatory frameworks in South Carolina and Virginia provide rate recovery mechanisms that could substantially mitigate any such impacts for the regulated electric utilities.

Effluent Limitations Guidelines

In September 2015, the EPA released a final rule to revise the Effluent Limitations Guidelines for the Steam Electric Power Generating Category. The final rule establishes updated standards for wastewater discharges that apply primarily at coal and oil steam generating stations. Affected facilities are required to convert from wet to dry or closed cycle coal ash management, improve existing wastewater treatment systems and/or install new wastewater treatment technologies in order to meet the new discharge limits. In April 2017, the EPA granted two separate petitions for reconsideration of the Effluent Limitations Guidelines final rule and stayed future compliance dates in the rule. Also in April 2017, the U.S. Court of Appeals for the Fifth Circuit granted the EPA’s request for a stay of the pending consolidated litigation challenging the rule while the EPA addresses the petitions for reconsideration. In September 2017, the EPA signed a rule to postpone the earliest compliance dates for certain waste streams regulations in the Effluent Limitations Guidelines final rule from November 2018 to November 2020; however, the latest date for compliance for these regulations remains December 2023. While the impacts of this rule could be material to Dominion Energy and Virginia Power’s results of operations, financial condition and/or cash flows, the existing regulatory frameworks in South Carolina and Virginia provide rate recovery mechanisms that could substantially mitigate any such impacts for the regulated electric utilities.

Waste Management and Remediation

The operations of the Companies are subject to a variety of state and federal laws and regulations governing the management and

disposal of solid and hazardous waste, and release of hazardous substances associated with current and/or historical operations. The CERCLA, as amended, and similar state laws, may impose joint, several and strict liability for cleanup on potentially responsible parties who owned, operated or arranged for disposal at facilities affected by a release of hazardous substances. In addition, many states have created programs to incentivize voluntary remediation of sites where historical releases of hazardous substances are identified and property owners or responsible parties decide to initiate cleanups.

From time to time, Dominion Energy, Virginia Power or Dominion Energy Gas may be identified as a potentially responsible party in connection with the alleged release of hazardous substances or wastes at a site. Under applicable federal and state laws, the Companies could be responsible for costs associated with the investigation or remediation of impacted sites, or subject to contribution claims by other responsible parties for their costs incurred at such sites. The Companies also may identify, evaluate and remediate other potentially impacted sites under voluntary state programs. Remediation costs may be subject to reimbursement under the Companies’ insurance policies, rate recovery mechanisms, or both. Except as described below, the Companies do not believe these matters will have a material effect on results of operations, financial condition and/or cash flows.

Dominion Energy has determined that it is associated with former manufactured gas plant sites, including certain sites associated with Virginia Power. At 11 sites associated with Dominion Energy, including certain sites acquired in the SCANA Combination, remediation work has been substantially completed under federal or state oversight. Where required, the sites are following state-approved groundwater monitoring programs. Dominion Energy has proposed or expects to propose remediation plans associated with three sites, including one at Virginia Power, and expects to conduct remediation activities primarily in 2020. As of December 31, 2019, Dominion Energy and Virginia Power have $34 million and $16 million, respectively, of reserves recorded, including a charge of $16 million ($12 million after-tax) that Virginia Power recorded in 2018, in other operations and maintenance expense in the Consolidated Statements of Income. In addition, for one site associated with Dominion Energy, an updated work plan submitted to SCDHEC in September 2018,

would increase costs by approximately $8 million if approved. Dominion Energy is associated with 13 additional sites, including two associated with Virginia Power, which are not under investigation by any state or federal environmental agency nor the subject of any current or proposed plans to perform remediation activities. Due to the uncertainty surrounding such sites, Dominion Energy and Virginia Power are unable to make an estimate of the potential financial statement impacts.

Ash Pond and Landfill Closure Costs

In April 2015, the EPA enacted a final rule regulating CCR landfills, existing ash ponds that still receive and manage CCRs, and inactive ash ponds that do not receive, but still store, CCRs. Dominion Energy currently operates inactive ash ponds, existing ash ponds and CCR landfills subject to the final rule at 11 different facilities, eight of which are at Virginia Power. This rule created a legal obligation for Dominion Energy and Virginia Power to retrofit or close all of its inactive and existing ash ponds over a

certain period of time, as well as perform required monitoring, corrective action, and post-closure care activities as necessary.

In December 2016, legislation was enacted that creates a framework for EPA- approved state CCR permit programs. In August 2017, the EPA issued interim guidance outlining the framework for state CCR program approval. The EPA has enforcement authority until state programs are approved. The EPA and states with approved programs both will have authority to enforce CCR requirements under their respective rules and programs. In September 2017, the EPA agreed to reconsider portions of the CCR rule in response to two petitions for reconsideration. In March 2018, the EPA proposed certain changes to the CCR rule related to issues remanded as part of the pending litigation and other issues the EPA is reconsidering. Several of the proposed changes would allow states with approved CCR permit programs additional flexibilities in implementing their programs. In July 2018, the EPA promulgated the first phase of changes to the CCR rule. Until all phases of the CCR rule are promulgated, Dominion Energy and Virginia Power cannot forecast potential incremental impacts or costs related to existing coal ash sites in connection with future implementation of the 2016 CCR legislation and reconsideration of the CCR rule. In August 2018, the U.S. Court of Appeals for the D.C. Circuit issued its decision in the pending challenges of the CCR rule, vacating and remanding to the EPA three provisions of the rule. Dominion Energy and Virginia Power do not expect the scope of the U.S. Court of Appeals for the D.C. Circuit’s decision to impact their closure plans, but cannot forecast incremental impacts associated with any future changes to the CCR rule in connection with the court’s remand.

In April 2017, the Governor of Virginia signed legislation into law that placed a moratorium on the VDEQ issuing solid waste permits for closure of ash ponds at Virginia Power’s Bremo, Chesapeake, Chesterfield and Possum Point power stations until May 2018. The law also required Virginia Power to conduct an assessment of closure alternatives for the ash ponds at these four stations, to include an evaluation of excavation for recycling or off-site disposal, surface and groundwater conditions and safety. Virginia Power completed the assessments and provided the report on December 1, 2017. In April 2018, the Governor of Virginia signed legislation into law extending the existing permit moratorium until July 2019. The legislation also required Virginia Power to solicit and compile by November 2018, information from third parties on the suitability, cost and market demand for beneficiation or recycling of coal ash from these units. The coal ash recycling business plan was submitted to the legislature in November 2018. The extended moratorium does not apply to a permit required for an impoundment where CCRs have already been removed and placed in another impoundment on-site, are being removed from an impoundment, or are being processed in connection with a recycling or beneficial use project. In connection with this legislation, in the second quarter of 2018, Virginia Power recorded an increase to its ARO and a related environmental liability related to future ash pond and landfill closure costs of $131 million, which resulted in an $81 million ($60 million after-tax) charge recorded in other operations and maintenance expense in its Consolidated Statement of Income, a $46 million increase in property, plant and equipment associated with asset retirement costs and a $4 million increase in regulatory assets.

In March 2019, the Governor of Virginia signed into law legislation which requires any CCR unit located at Virginia Power’s Bremo, Chesapeake, Chesterfield or Possum Point power stations that stop accepting CCR prior to July 2019 be closed by removing the CCR to an approved landfill or through recycling for beneficial reuse. The legislation further requires that at least 6.8 million cubic yards of CCR be beneficially reused. Costs associated with the closure of these CCR units are recoverable through a rate adjustment clause approved by the Virginia Commission with a revenue requirement that cannot exceed $225 million in any 12-month period. Associated costs that are allocated to customers outside of Virginia, and not actually recovered from such customers, are recoverable through the Virginia rate adjustment clause. In connection with this legislation, Virginia Power recorded a $2.4 billion ARO related to the cost of landfills and beneficial reuse, with an offsetting increase to property, plant and equipment of $1.3 billion for the Chesterfield power station and an increase primarily to regulatory assets for the remaining portion related to the Bremo, Chesapeake and Possum Point power stations during the first quarter of 2019. In addition, Virginia Power revised its estimated cash flows for the existing ARO related to future ash pond and landfill closure costs, which resulted in a decrease of $202 million and a corresponding $113 million ($84 million after-tax) benefit in other operations and maintenance expense in the Consolidated Statement of Income in the first quarter of 2019.

Other Legal Matters

The Companies are defendants in a number of lawsuits and claims involving unrelated incidents of property damage and personal injury. Due to the uncertainty surrounding these matters, the Companies are unable to make an estimate of the potential financial statement impacts; however, they could have a material impact on results of operations, financial condition and/or cash flows.

SCANA Legal Proceedings

The following describes certain legal proceedings involving Dominion Energy, SCANA or DESC relating to events occurring before closing of the SCANA Combination. Dominion Energy intends to vigorously contest the lawsuits, claims and assessments which have been filed or initiated against SCANA and DESC. No reference to, or disclosure of, any proceeding, item or matter described below shall be construed as an admission or indication that such proceeding, item or matter is material. For certain of these matters, and unless otherwise noted therein, Dominion Energy is unable to estimate a reasonable range of possible loss and the related financial statement impacts, but for any such matter there could be a material impact to its results of operations, financial condition and/or cash flows. For the matters for which Dominion Energy is able to reasonably estimate a probable loss, Dominion Energy’s Consolidated Balance Sheets include reserves of $696 million and insurance receivables of $111 million, included within other receivables at December 31, 2019. Dominion Energy’s Consolidated Statements of Income for the year ended December 31, 2019 includes charges of $641 million ($480 million after-tax), included within impairment of assets and other charges, included within the Corporate and Other segment.

Ratepayer Class Actions

In May 2018, a consolidated complaint against DESC, SCANA and the State of South Carolina was filed in the State Court of Common Pleas in Hampton County, South Carolina (the DESC Ratepayer Case). In September 2018, the court certified this case as a class action. The plaintiffs allege, among other things, that DESC was negligent and unjustly enriched, breached alleged fiduciary and contractual duties and committed fraud and misrepresentation in failing to properly manage the NND Project, and that DESC committed unfair trade practices and violated state anti-trust laws. The plaintiffs sought a declaratory judgment that DESC may not charge its customers for any past or continuing costs of the NND Project, sought to have SCANA and DESC’s assets frozen and all monies recovered from Toshiba Corporation and other sources be placed in a constructive trust for the benefit of ratepayers and sought specific performance of the alleged implied contract to construct the NND Project.

In December 2018, the State Court of Common Pleas in Hampton County entered an order granting preliminary approval of a class action settlement and a stay of pre-trial proceedings in the DESC Ratepayer Case. The settlement agreement, contingent upon the closing of the SCANA Combination, provided that SCANA and DESC would establish an escrow account and proceeds from the escrow account would be distributed to the class members, after payment of certain taxes, attorneys’ fees and other expenses and administrative costs. The escrow account would include (1) up to $2.0 billion, net of a credit of up to $2.0 billion in future electric bill relief, which would inure to the benefit of the escrow account in favor of class members over a period of time established by the South Carolina Commission in its order related to matters before the South Carolina Commission related to the NND Project, (2) a cash payment of $115 million and (3) the transfer of certain DESC-owned real estate or sales proceeds from the sale of such properties, which counsel for the DESC Ratepayer Class estimate to have an aggregate value between $60 million and $85 million. At the closing of the SCANA Combination, SCANA and DESC funded the cash payment portion of the escrow account. The court held a fairness hearing on the settlement in May 2019. In June 2019, the court entered an order granting final approval of the settlement, which order became effective July 2019. In July 2019, DESC transferred $117 million representing the cash payment, plus accrued interest, to the plaintiffs. In addition, property, plant and equipment with a net recorded value of $54 million is in the process of being transferred to the plaintiffs in coordination with the court-appointed real estate trustee to satisfy the settlement agreement.

In September 2017, a purported class action was filed by Santee Cooper ratepayers against Santee Cooper, DESC, Palmetto Electric Cooperative, Inc. and Central Electric Power Cooperative, Inc. in the State Court of Common Pleas in Hampton County, South Carolina (the Santee Cooper Ratepayer Case). The allegations are substantially similar to those in the DESC Ratepayer Case. The plaintiffs seek a declaratory judgment that the defendants may not charge the purported class for reimbursement for past or future costs of the NND Project. In March 2018, the plaintiffs filed an amended complaint including as additional named defendants, including certain then current and former directors of Santee Cooper and SCANA. In June 2018, Santee Cooper filed a Notice of Petition for Original Jurisdiction with the Supreme Court of

South Carolina. In December 2018, Santee Cooper filed its answer to the plaintiffs’ fourth amended complaint and filed cross claims against DESC, which was denied. In October 2019, Santee Cooper voluntarily consented to stay its cross claims against DESC pending the outcome of the trial of the underlying case. In November 2019, DESC removed the case to the U.S. District Court for the District of South Carolina. In December 2019, the plaintiffs and Santee Cooper filed a motion to remand the case to state court. In January 2020, the case was remanded to state court. In February 2020, the parties executed a preliminary settlement term sheet relating to this matter as well as the Luquire Case and the Glibowski Case described below. The proposed settlement is expected to be $520 million, of which Dominion Energy’s portion is $320 million. The parties are currently negotiating a settlement agreement based on the preliminary settlement term sheet that will be presented to the court for preliminary approval. This case is pending.

In July 2019, a similar purported class action was filed by certain Santee Cooper ratepayers against DESC, SCANA, Dominion Energy and former directors and officers of SCANA in the State Court of Common Pleas in Orangeburg, South Carolina (the Luquire Case). In August 2019, DESC, SCANA and Dominion Energy were voluntarily dismissed from the case. The claims are similar to the Santee Cooper Ratepayer Case. In February 2020, the parties executed a preliminary settlement term sheet as described above relating to this matter as well as the Santee Cooper Ratepayer Case and the Glibowski Case. This case is pending.

RICO Class Action

In January 2018, a purported class action was filed, and subsequently amended, against SCANA, DESC and certain former executive officers in the U.S. District Court for the District of South Carolina (the Glibowski Case). The plaintiff alleges, among other things, that SCANA, DESC and the individual defendants participated in an unlawful racketeering enterprise in violation of RICO and conspired to violate RICO by fraudulently inflating utility bills to generate unlawful proceeds. The DESC Ratepayer Class Action settlement described previously contemplates dismissal of claims by DESC ratepayers in this case against DESC, SCANA and their officers. In August 2019, the individual defendants filed motions to dismiss. In February 2020, the parties executed a preliminary settlement term sheet as described above relating to this matter as well as the Santee Cooper Ratepayer Case and the Luquire Case. This case is pending.

SCANA Shareholder Litigation

In September 2017, a purported class action was filed against SCANA and certain former executive officers and directors in the U.S. District Court for the District of South Carolina. Subsequent additional purported class actions were separately filed against all or nearly all of these defendants. In January 2018, the U.S. District Court for the District of South Carolina consolidated these suits, and the plaintiffs filed a consolidated amended complaint in March 2018. The plaintiffs allege, among other things, that the defendants violated §10(b) of the Securities Exchange Act of 1934, as amended, and Rule 10b-5 promulgated thereunder, and that the individually named defendants are liable under §20(a) of the same act. In June 2018, the defendants filed motions to dismiss. In March 2019, the U.S. District Court for the District of South Carolina granted in part and denied in part

the defendants’ motions to dismiss. In December 2019, the parties executed a settlement agreement pursuant to which SCANA will pay $192.5 million, up to $32.5 million of which can be satisfied through the issuance of shares of Dominion Energy common stock, subject to approval by the U.S. District Court for the District of South Carolina. In February 2020, the U.S. District Court for the District of South Carolina granted preliminary approval of the settlement agreement, pending a fairness hearing.

In September 2017, a shareholder derivative action was filed against certain former executive officers and directors of SCANA in the State Court of Common Pleas in Richland County, South Carolina. In September 2018, this action was consolidated with another action in the Business Court Pilot Program in Richland County. The plaintiffs allege, among other things, that the defendants breached their fiduciary duties to shareholders by their gross mismanagement of the NND Project, and that the defendants were unjustly enriched by bonuses they were paid in connection with the project. The defendants have filed a motion to dismiss the consolidated action. In February 2019, one action was voluntarily dismissed. This case is pending.

In January 2018, a purported class action was filed against SCANA, Dominion Energy and certain former executive officers and directors of SCANA in the State Court of Common Pleas in Lexington County, South Carolina (the City of Warren Lawsuit). The plaintiff alleges, among other things, that defendants violated their fiduciary duties to shareholders by executing a merger agreement that would unfairly deprive plaintiffs of the true value of their SCANA stock, and that Dominion Energy aided and abetted these actions. Among other remedies, the plaintiff seeks to enjoin and/or rescind the merger. In February 2018, Dominion Energy removed the case to the U.S. District Court for the District of South Carolina, and filed a Motion to Dismiss in March 2018. In June 2018, the case was remanded back to the State Court of Common Pleas in Lexington County. Dominion Energy appealed the decision to remand to the U.S. Court of Appeals for the Fourth Circuit, where the appeal was consolidated with a similar appeal in the Metzler Lawsuit discussed below. In June 2019, the U.S. Court of Appeals for the Fourth Circuit reversed the order remanding the case to state court. The case is pending in the U.S. District Court for the District of South Carolina.

In February 2018, a purported class action was filed against Dominion Energy and certain former directors of SCANA and DESC in the State Court of Common Pleas in Richland County, South Carolina (the Metzler Lawsuit). The allegations made and the relief sought by the plaintiffs are substantially similar to that described for the City of Warren Lawsuit. In February 2018, Dominion Energy removed the case to the U.S. District Court for the District of South Carolina, and filed a Motion to Dismiss in March 2018. In August 2018, the case was remanded back to the State Court of Common Pleas in Richland County. Dominion Energy appealed the decision to remand to the U.S. Court of Appeals for the Fourth Circuit, where the appeal was consolidated with the City of Warren Lawsuit. In June 2019, the U.S. Court of Appeals for the Fourth Circuit reversed the order remanding the case to state court. The case is pending in the U.S. District Court for the District of South Carolina.

In September 2019, the U.S. District Court for the District of South Carolina granted the plaintiffs’ motion to consolidate the City of Warren Lawsuit and the Metzler Lawsuit. In October 2019, the plaintiffs filed an amended complaint against certain former directors and executive officers of SCANA and DESC,

which stated substantially similar allegations to those in the City of Warren Lawsuit and the Metzler Lawsuit. In November 2019, the defendants filed a motion to dismiss. This case is pending.

In May 2019, a case was filed against certain former executive officers and directors of SCANA in the State Court of Common Pleas in Richland County, South Carolina. The plaintiffs allege, among other things, that the defendants breached their fiduciary duties to shareholders by their gross mismanagement of the NND Project, were unjustly enriched by the bonuses they were paid in connection with the project and breached their fiduciary duties to secure and obtain the best price for the sale of SCANA. Also in May 2019, the case was removed to the U.S. District Court of South Carolina by the non-South Carolina defendants. In June 2019, the plaintiffs filed a motion to remand the case to state court. In January 2020, the case was remanded to state court. This case is pending.

Employment Class Actions and Indemnification

In August 2017, a case was filed in the U.S. District Court for the District of South Carolina on behalf of persons who were formerly employed at the NND Project. In July 2018, the court certified this case as a class action. In February 2019, certain of these plaintiffs filed an additional case, which case has been dismissed and the plaintiffs have joined the case filed August 2017. The plaintiffs allege, among other things, that SCANA, DESC, Fluor Corporation and Fluor Enterprises, Inc. violated the Worker Adjustment and Retraining Notification Act in connection with the decision to stop construction at the NND Project. The plaintiffs allege that the defendants failed to provide adequate advance written notice of their terminations of employment and are seeking damages, which could be as much as $100 million for 100% of the NND Project.

In September 2018, a case was filed in the State Court of Common Pleas in Fairfield County, South Carolina by Fluor Enterprises, Inc. and Fluor Daniel Maintenance Services, Inc. against DESC and Santee Cooper. The plaintiffs make claims for indemnification, breach of contract and promissory estoppel arising from, among other things, the defendants’ alleged failure and refusal to defend and indemnify the Fluor defendants in the aforementioned case. These cases are pending.

FILOT Litigation and Related Matters

In November 2017, Fairfield County filed a complaint and a motion for temporary injunction against DESC in the State Court of Common Pleas in Fairfield County, South Carolina, making allegations of breach of contract, fraud, negligent misrepresentation, breach of fiduciary duty, breach of implied duty of good faith and fair dealing and unfair trade practices related to DESC’s termination of the FILOT agreement between DESC and Fairfield County related to the NND Project. The plaintiff sought a temporary and permanent injunction to prevent DESC from terminating the FILOT agreement. The plaintiff withdrew the motion for temporary injunction in December 2017. This case is pending.

Governmental Proceedings and Investigations

In June 2018, DESC received a notice of proposed assessment of approximately $410 million, excluding interest, from the SCDOR following its audit of DESC’s sales and use tax returns for the periods September 1, 2008 through December 31, 2017. The proposed assessment, which includes 100% of the NND Project, is based on the SCDOR’s position that DESC’s sales and

use tax exemption for the NND Project does not apply because the facility will not become operational. DESC has protested the proposed assessment, which remains pending. 

In September and October 2017, SCANA was served with subpoenas issued by the U.S. Attorney’s Office for the District of South Carolina and the Staff of the SEC’s Division of Enforcement seeking documents related to the NND Project. In February 2020, the SEC filed a complaint against SCANA, two of its former executive officers and DESC in the U.S. District Court for the District of South Carolina alleging that the defendants violated federal securities laws by making false and misleading statements about the NND Project. In addition, the South Carolina Law Enforcement Division is conducting a criminal investigation into the handling of the NND Project by SCANA and DESC. These matters are pending. SCANA and DESC are cooperating fully with the investigations, including responding to additional subpoenas and document requests; however, Dominion Energy cannot currently predict whether or to what extent SCANA or DESC may incur a material liability.

Other Litigation

In December 2018, arbitration proceedings commenced between DESC and Cameco Corporation related to a supply agreement signed in May 2008. This agreement provides the terms and conditions under which DESC agreed to purchase uranium hexafluoride from Cameco Corporation over a period from 2010 to 2020. Cameco Corporation alleges that DESC violated this agreement by failing to purchase the stated quantities of uranium hexafluoride for the 2017 and 2018 delivery years. DESC denies that it is in breach of the agreement and believes that it has reduced its purchase quantity within the terms of the agreement. This matter is pending.

Abandoned NND Project

DESC, for itself and as agent for Santee Cooper, entered into an engineering, construction and procurement contract with Westinghouse and WECTEC in 2008 for the design and construction of the NND Project, of which DESC’s ownership share is 55%. Various difficulties were encountered in connection with the project. The ability of Westinghouse and WECTEC to adhere to established budgets and construction schedules was affected by many variables, including unanticipated difficulties encountered in connection with project engineering and the construction of project components, constrained financial resources of the contractors, regulatory, legal, training and construction processes associated with securing approvals, permits and licenses and necessary amendments to them within projected time frames, the availability of labor and materials at estimated costs and the efficiency of project labor. There were also contractor and supplier performance issues, difficulties in timely meeting critical regulatory requirements, contract disputes, and changes in key contractors or subcontractors. These matters preceded the filing for bankruptcy protection by Westinghouse and WECTEC in March 2017, and were the subject of comprehensive analyses performed by SCANA and Santee Cooper.

Based on the results of SCANA’s analysis, and in light of Santee Cooper’s decision to suspend construction on the NND Project, in July 2017, SCANA determined to stop the construction of the units and to pursue recovery of costs incurred in connection with the construction under the abandonment provisions of the Base Load

Review Act or through other means. This decision by SCANA became the focus of numerous legislative, regulatory and legal proceedings. Some of these proceedings remain unresolved and are described above.

In September 2017, DESC, for itself and as agent for Santee Cooper, filed with the U.S. Bankruptcy Court for the Southern District of New York Proofs of Claim for unliquidated damages against each of Westinghouse and WECTEC. These Proofs of Claim were based upon the anticipatory repudiation and material breach by Westinghouse and WECTEC of the contract, and assert against Westinghouse and WECTEC any and all claims that are based thereon or that may be related thereto.

Westinghouse’s reorganization plan was confirmed by the U.S. Bankruptcy Court for the Southern District of New York and became effective in August 2018. In connection with the effectiveness of the reorganization plan, the contract associated with the NND Project was deemed rejected. DESC is contesting approximately $285 million of filed liens in Fairfield County, South Carolina. Most of these asserted liens are claims that relate to work performed by Westinghouse subcontractors before the Westinghouse bankruptcy, although some of them are claims arising from work performed after the Westinghouse bankruptcy.

Westinghouse has indicated that some unsecured creditors have sought or may seek amounts beyond what Westinghouse allocated when it submitted its reorganization plan to the U.S. Bankruptcy Court for the Southern District of New York. If any unsecured creditor is successful in its attempt to include its claim as part of the class of general unsecured creditors beyond the amounts in the bankruptcy reorganization plan allocated by Westinghouse, it is possible that the reorganization plan will not provide for payment in full or nearly in full to its pre-petition trade creditors. The shortfall could be significant.

DESC and Santee Cooper were responsible for amounts owed to Westinghouse for valid work performed by Westinghouse subcontractors on the NND Project after the Westinghouse bankruptcy filing until termination of the interim assessment agreement. In December 2019, DESC and Santee Cooper entered into a confidential settlement agreement with W Wind Down Co LLC resolving claims relating to the interim assessment agreement.

Further, some Westinghouse subcontractors who have made claims against Westinghouse in the bankruptcy proceeding also filed against DESC and Santee Cooper in South Carolina state court for damages. Many of these claimants have also asserted construction liens against the NND Project site. DESC also intends to oppose these claims and liens. With respect to claims of Westinghouse subcontractors, DESC believes there were sufficient amounts previously funded during the interim assessment agreement period to pay such validly asserted claims. With respect to the Westinghouse subcontractor claims which relate to other periods, DESC understands that such claims will be paid pursuant to Westinghouse’s confirmed bankruptcy reorganization plan. DESC further understands that the amounts paid under the plan may satisfy such claims in full. Therefore, DESC believes that the Westinghouse subcontractors may be paid substantially (and potentially in full) by Westinghouse. While Dominion Energy cannot be assured that it will not have any exposure on account of unpaid Westinghouse subcontractor claims, which DESC is presently disputing, Dominion Energy believes it is unlikely that it will be required to make payments on account of such claims.

Appalachian Gateway

Gas Producers Litigation

In connection with the Appalachian Gateway project, Dominion Energy Field Services, Inc. entered into contracts for firm purchase rights with a group of small gas producers. In June 2016, the gas producers filed a complaint in the Circuit Court of Marshall County, West Virginia against Dominion Energy, DETI and Dominion Energy Field Services, Inc., among other defendants, claiming that the contracts are unenforceable and seeking compensatory and punitive damages. During the third quarter of 2016, Dominion Energy, DETI and Dominion Energy Field Services, Inc. were served with the complaint. Also in the third quarter of 2016, Dominion Energy and DETI, with the consent of the other defendants, removed the case to the U.S. District Court for the Northern District of West Virginia. In October 2016, the defendants filed a motion to dismiss and the plaintiffs filed a motion to remand. In February 2017, the U.S. District Court entered an order remanding the matter to the Circuit Court of Marshall County, West Virginia. In March 2017, Dominion Energy was voluntarily dismissed from the case; however, DETI and Dominion Energy Field Services, Inc. remained parties to the matter. In April 2017, the case was transferred to the Business Court Division of West Virginia. In January 2018, the court granted the motion to dismiss filed by the defendants on two counts. In 2019, all claims were settled between Dominion Energy Field Services, Inc. and the gas producers, and all claims against DETI and Dominion Energy Field Services, Inc. were dismissed with no material impact to Dominion Energy or Dominion Energy Gas’ results of operations, financial condition or cash flows.

FERC

FERC staff in the Office of Enforcement, Division of Investigations, conducted a non-public investigation of Virginia Power’s offers of combustion turbines generators into the PJM day-ahead markets from April 2010 through September 2014. FERC staff notified Virginia Power of its preliminary findings relating to Virginia Power’s alleged violation of FERC’s rules in connection with these activities. Virginia Power provided its response to FERC staff’s preliminary findings letter explaining why Virginia Power’s conduct was lawful and refuting any allegation of wrongdoing. In May 2019, FERC issued an order approving an agreement between Virginia Power and FERC staff that settled any and all potential claims relating to the types of activities that were the subject of the investigation, under which Virginia Power neither admits nor denies the alleged violations and paid $7 million in disgorgement to PJM and a $7 million penalty to the U.S. Department of the Treasury.

Nuclear Matters

In March 2011, a magnitude 9.0 earthquake and subsequent tsunami caused significant damage at the Fukushima Daiichi nuclear power station in northeast Japan. These events resulted in significant nuclear safety reviews by the NRC and industry groups such as the Institute of Nuclear Power Operations. Like other U.S. nuclear operators, Dominion Energy has gathered supporting data and participated in industry initiatives focused on the ability to respond to and mitigate the consequences of, design-basis and beyond-design-basis events at its stations.

In July 2011, an NRC task force provided initial recommendations based on its review of the Fukushima Daiichi accident and in October 2011 the NRC staff prioritized these recommendations into Tiers 1, 2 and 3. Tier 1 recommendations consisted of actions which the NRC staff determined should be started without unnecessary delay. Tier 2 and 3 items consisted of items which could not be initiated in the near term because of resource restraints, the need for further technical assessment, or were dependent on activities related to the higher priority Tier 1 issues. In December 2011, the NRC Commissioners approved the agency staff’s prioritization and recommendations, and that same month an appropriations act directed the NRC to require reevaluation of external hazards (not limited to seismic and flooding hazards) as soon as possible.

Based on the prioritized recommendations, in March 2012, the NRC issued orders and information requests requiring specific reviews and actions to all operating reactor licensees, construction permit holders and combined license holders based on the lessons learned from the Fukushima Daiichi event. The orders applicable to Dominion Energy requiring implementation of safety enhancements related to mitigation strategies for responding to extreme natural events resulting in the loss of power at plants, and enhancing spent fuel pool instrumentation have been implemented. The information requests issued by the NRC requested each reactor licensee to reevaluate the seismic and external flooding hazards at their facility using present-day methods and information, conduct walkdowns of their facility to ensure protection against these hazards in their current design basis, and to reevaluate their emergency communications systems and staffing levels. The walkdowns of each unit have been completed, audited by the NRC and found to be adequate. Reevaluation of the emergency communications systems and staffing levels was completed as part of the effort to comply with the orders. Reevaluation of the seismic hazards is complete and final with NRC acceptance received for all Dominion Energy facilities. Reevaluation of the external flooding hazards is complete for all Dominion Energy facilities. However, NRC acceptance of the external flooding hazards reevaluations for Millstone and Surry have not yet been received. NRC is expected to accept these external flooding hazards analyses in 2020. Dominion Energy and Virginia Power do not currently expect that compliance with the NRC’s information requests will materially impact their financial position, results of operations or cash flows during the implementation period. The NRC staff has resolved the Tier 2 and Tier 3 recommendations and no additional future actions on the part of Dominion Energy are anticipated with respect to these recommendations. Therefore, Dominion Energy and Virginia Power do not expect material financial impacts related to compliance with Tier 2 and Tier 3 recommendations.

Nuclear Operations

Nuclear Decommissioning—Minimum Financial Assurance

The NRC requires nuclear power plant owners to annually update minimum financial assurance amounts for the future decommissioning of their nuclear facilities. Decommissioning involves the decontamination and removal of radioactive contaminants from a nuclear power station once operations have ceased, in accordance with standards established by the NRC.

The 2019 calculation for the NRC minimum financial assurance amount, aggregated for Dominion Energy and Virginia Power’s nuclear units, excluding joint owners’ assurance amounts and Millstone Unit 1 and Kewaunee, as those units are in a decommissioning state, was $2.8 billion and $1.8 billion, respectively, and has been satisfied by a combination of the funds being collected and deposited in the nuclear decommissioning trusts and the real annual rate of return growth of the funds allowed by the NRC. The 2019 NRC minimum financial assurance amounts above were calculated using preliminary December 31, 2019 U.S. Bureau of Labor Statistics indices. Dominion Energy believes that the amounts currently available in its decommissioning trusts and their expected earnings will be sufficient to cover expected decommissioning costs for the Millstone and Kewaunee units. Virginia Power also believes that the decommissioning funds and their expected earnings for the Surry and North Anna units will be sufficient to cover decommissioning costs, particularly when combined with future ratepayer collections and contributions to these decommissioning trusts, if such future collections and contributions are required. This reflects a positive long-term outlook for trust fund investment returns as the decommissioning of the units will not be complete for decades. Dominion Energy and Virginia Power will continue to monitor these trusts to ensure they meet the NRC minimum financial assurance requirement, which may include, if needed, the use of parent company guarantees, surety bonding or other financial instruments recognized by the NRC. See Note 9 for additional information on nuclear decommissioning trust investments.

Nuclear Insurance

The Price-Anderson Amendments Act of 1988 provides the public up to $14.1 billion of liability protection on a per site, per nuclear incident basis, via obligations required of owners of nuclear power plants, and allows for an inflationary provision adjustment every five years. During the second quarter of 2019, the total liability protection per nuclear incident available to all participants in the Secondary Financial Protection Program decreased from $14.1 billion to $13.9 billion. This decrease does not impact Dominion Energy’s responsibility per active unit under the Price-Anderson Amendments Act of 1988. Dominion Energy and Virginia Power have purchased $450 million of coverage from commercial insurance pools for Millstone, Surry and North Anna with the remainder provided through the mandatory industry retrospective rating plan. In the event of a nuclear incident at any licensed nuclear reactor in the U.S., Dominion Energy and Virginia Power could be assessed up to $138 million for each of their licensed reactors not to exceed $21 million per year per reactor. There is no limit to the number of incidents for which this retrospective premium can be assessed. The NRC granted an exemption in March 2015 to remove Kewaunee from the Secondary Financial Protection program. This same exemption permitted Dominion Energy to reduce Kewaunee’s required level of liability coverage to $100 million. This reduction was implemented in January 2018, following the removal and storage of the spent nuclear fuel from the spent fuel pool. The current levels of nuclear property insurance coverage for Dominion Energy and Virginia Power’s nuclear units are as follows:

	Coverage
(billions)
Dominion Energy
Millstone	$	1.70
Kewaunee		0.05
Summer		2.75
Virginia Power(1)
Surry	$	1.70
North Anna		1.70

(1) Surry and North Anna share a blanket property limit of $200 million.

Dominion Energy and Virginia Power’s nuclear property insurance coverage for Millstone, Surry and North Anna exceeds the NRC minimum requirement for nuclear power plant licensees of $1.06 billion per reactor site. In March 2015, the NRC granted an exemption which allowed Kewaunee to reduce its property insurance limit to $50 million. This reduction was implemented in January 2018, following the removal and storage of the spent nuclear fuel from the spent fuel pool. This includes coverage for premature decommissioning and functional total loss. The NRC requires that the proceeds from this insurance be used first, to return the reactor to and maintain it in a safe and stable condition and second, to decontaminate the reactor and station site in accordance with a plan approved by the NRC. Nuclear property insurance is provided by NEIL, a mutual insurance company, and is subject to retrospective premium assessments in any policy year in which losses exceed the funds available to the insurance company. Dominion Energy and Virginia Power’s maximum retrospective premium assessment for the current policy period is $81 million and $50 million, respectively. Based on the severity of the incident, the Board of Directors of the nuclear insurer has the discretion to lower or eliminate the maximum retrospective premium assessment. Dominion Energy and Virginia Power have the financial responsibility for any losses that exceed the limits or for which insurance proceeds are not available because they must first be used for stabilization and decontamination.

Millstone and Virginia Power also purchase accidental outage insurance from NEIL to mitigate certain expenses, including replacement power costs, associated with the prolonged outage of a nuclear unit due to direct physical damage. Under this program, Dominion Energy and Virginia Power are subject to a retrospective premium assessment for any policy year in which losses exceed funds available to NEIL. Dominion Energy and Virginia Power’s maximum retrospective premium assessment for the current policy period is $31 million and $10 million, respectively.

ODEC, a part owner of North Anna, and Massachusetts Municipal and Green Mountain, part owners of Millstone’s Unit 3, are responsible to Dominion Energy and Virginia Power for their share of the nuclear decommissioning obligation and insurance premiums on applicable units, including any retrospective premium assessments and any losses not covered by insurance.

Under Price-Anderson, DESC (for itself and on behalf of Santee-Cooper) maintains agreements of indemnity with the NRC that, together with private insurance, cover third-party liability arising from any nuclear incident occurring at Summer. Price-Anderson provides funds up to $14.0 billion for public liability claims that could arise from a single nuclear incident. Each nuclear plant is insured against this liability to a maximum of $450 million by American Nuclear Insurers with the remaining coverage provided by a mandatory program of

deferred premiums that could be assessed, after a nuclear incident, against all owners of commercial nuclear reactors. Each reactor licensee is liable for up to $138 million per reactor owned for each nuclear incident occurring at any reactor in the U.S., provided that not more than $21 million of the liability per reactor would be assessed per year. DESC’s maximum assessment, based on its two-thirds ownership of Summer, would be $92 million per incident, but not more than $14 million per year. Both the maximum assessment per reactor and the maximum yearly assessment are adjusted for inflation at least every five years.

DESC currently maintains insurance policies (for itself and on behalf of Santee Cooper) with NEIL. The policies provide coverage to Summer for property damage and outage costs up to $2.75 billion resulting from an event of nuclear origin and up to $2.33 billion resulting from an event of a non-nuclear origin. The NEIL policies in aggregate, are subject to a maximum loss of $2.75 billion for any single loss occurrence. The NEIL policies permit retrospective assessments under certain conditions to cover insurer’s losses. Based on the current annual premium, DESC’s portion of the retrospective premium assessment would not exceed $24 million. DESC currently maintains an excess property insurance policy (for itself and on behalf of Santee Cooper) with the European Mutual Association for Nuclear Insurance. The policy provides coverage to Summer for property damage and outage costs up to $415 million resulting from an event of a non-nuclear origin. The European Mutual Association for Nuclear Insurance policy permits retrospective assessments under certain conditions to cover insurer’s losses. Based on the current annual premium, DESC’s portion of the retrospective premium assessment would not exceed $2 million.

To the extent that insurable claims for property damage, decontamination, repair and replacement and other costs and expenses arising from an incident at Summer exceed the policy limits of insurance, or to the extent such insurance becomes unavailable in the future, and to the extent that DESC’s rates would not recover the cost of any purchased replacement power, DESC will retain the risk of loss as a self-insurer. DESC has no reason to anticipate a serious nuclear or other incident. However, if such an incident were to occur, it likely would have a material impact on DESC’s results of operations, cash flows and financial position.

Spent Nuclear Fuel

Dominion Energy and Virginia Power entered into contracts with the DOE for the disposal of spent nuclear fuel under provisions of the Nuclear Waste Policy Act of 1982. The DOE failed to begin accepting the spent fuel on January 31, 1998, the date provided by the Nuclear Waste Policy Act and by Dominion Energy and Virginia Power’s contracts with the DOE. Dominion Energy and Virginia Power have previously received damages award payments and settlement payments related to these contracts.

By mutual agreement of the parties, the settlement agreements are extendable to provide for resolution of damages incurred after 2013. The settlement agreements for the Surry, North Anna and Millstone nuclear power stations have been extended to provide for periodic payments for damages incurred through December 31, 2019, and additional extensions are contemplated by the settlement agreements. A similar agreement for Summer extends until the DOE has accepted the same amount of spent fuel from the

facility as if it has fully performed its contractual obligations. In June 2018, a lawsuit for Kewaunee was filed in the U.S. Court of Federal Claims for recovery of spent nuclear fuel storage costs incurred for the period January 1, 2014 through December 31, 2017. In March 2019, Dominion Energy amended its filing for recovery of spent nuclear fuel storage to include costs incurred for the year ended December 31, 2018. This matter is pending.

In 2019, Virginia Power received payments of $15 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2017 through December 31, 2017 and $11 million for resolution of claims incurred at Millstone for the period of July 1, 2017 through June 30, 2018. In 2019, Dominion Energy received payment of $3 million for resolution of its share of claims incurred at Summer for the period of January 1, 2018 through December 31, 2018.

In 2018, Virginia Power and Dominion Energy received payments of $16 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2016 through December 31, 2016, and $13 million for resolution of claims incurred at Millstone for the period of July 1, 2016 through June 30, 2017.

In 2017, Virginia Power and Dominion Energy received payments of $22 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2015 through December 31, 2015, and $14 million for resolution of claims incurred at Millstone for the period of July 1, 2015 through June 30, 2016.

Dominion Energy and Virginia Power continue to recognize receivables for certain spent nuclear fuel-related costs that they believe are probable of recovery from the DOE. Dominion Energy’s receivables for spent nuclear fuel-related costs totaled $52 million and $49 million at December 31, 2019 and 2018, respectively. Virginia Power’s receivables for spent nuclear fuel-related costs totaled $35 million and $30 million at December 31, 2019 and 2018, respectively.

Dominion Energy and Virginia Power will continue to manage their spent fuel until it is accepted by the DOE.

Long-Term Purchase Agreements

At December 31, 2019, Dominion Energy had the following long-term commitments that are noncancelable or are cancelable only under certain conditions, and that a third party has used to secure financing for the facility that will provide the contracted goods or services:

	2020		2021		2022		2023		2024		Thereafter		Total
(millions)
Purchased electric capacity(1)		$45		$44		$44		$44		$44		$494		$715

(1) Commitments represent estimated amounts payable for energy under power purchase contracts with qualifying facilities which expire at various dates through 2046. Energy payments are generally based on fixed dollar amounts per month and totaled $29 million for the year ended December 31, 2019.

Guarantees, Surety Bonds and Letters of Credit

In October 2017, Dominion Energy entered into a guarantee agreement to support a portion of Atlantic Coast Pipeline’s obligation under a $3.4 billion revolving credit facility with a

stated maturity date of October 2021. Dominion Energy’s maximum potential loss exposure under the terms of the guarantee is limited to 48% of the outstanding borrowings under the revolving credit facility, an equal percentage to Dominion Energy’s ownership in Atlantic Coast Pipeline. As of December 31, 2019, Atlantic Coast Pipeline has borrowed $1.8 billion against the revolving credit facility and borrowed an additional $27 million in January and February 2020. Dominion Energy’s Consolidated Balance Sheet includes a liability of $14 million and $21 million associated with this guarantee agreement at December 31, 2019 and 2018, respectively.

In addition, at December 31, 2019, Dominion Energy had issued an additional $27 million of guarantees, primarily to support other equity method investees. No amounts related to the other guarantees have been recorded.

Dominion Energy also enters into guarantee arrangements on behalf of its consolidated subsidiaries, primarily to facilitate their commercial transactions with third parties. If any of these subsidiaries fail to perform or pay under the contracts and the counterparties seek performance or payment, Dominion Energy would be obligated to satisfy such obligation. To the extent that a liability subject to a guarantee has been incurred by one of Dominion Energy’s consolidated subsidiaries, that liability is included in the Consolidated Financial Statements. Dominion Energy is not required to recognize liabilities for guarantees issued on behalf of its subsidiaries unless it becomes probable that it will have to perform under the guarantees. Terms of the guarantees typically end once obligations have been paid. Dominion Energy currently believes it is unlikely that it would be required to perform or otherwise incur any losses associated with guarantees of its subsidiaries’ obligations.

At December 31, 2019, Dominion Energy had issued the following subsidiary guarantees:

	Maximum Exposure
(millions)
Commodity transactions(1)	$	2,215
Nuclear obligations(2)		182
Cove Point(3)		1,900
Solar(4)		477
Other(5)		377
Total(6)	$	5,151

(1) Guarantees related to commodity commitments of certain subsidiaries. These guarantees were provided to counterparties in order to facilitate physical and financial transaction related commodities and services.

(2) Guarantees primarily related to certain DGI subsidiaries’ regarding all aspects of running a nuclear facility.

(3) Guarantees related to Cove Point, in support of terminal services, transportation and construction. Cove Point has two guarantees that have no maximum limit and, therefore, are not included in this amount.

(4) Includes guarantees to facilitate the development of solar projects. Also includes guarantees entered into by DGI on behalf of certain subsidiaries to facilitate the acquisition and development of solar projects.

(5) Guarantees related to other miscellaneous contractual obligations such as leases, environmental obligations, construction projects and insurance programs. Due to the uncertainty of worker’s compensation claims, the parental guarantee has no stated limit.

(6) Excludes Dominion Energy’s guarantees for the new corporate office properties discussed further within Note 15.

Additionally, at December 31, 2019, Dominion Energy had purchased $163 million of surety bonds, including $77 million at Virginia Power and $26 million at Dominion Energy Gas, and

authorized the issuance of letters of credit by financial institutions of $89 million to facilitate commercial transactions by its subsidiaries with third parties. Under the terms of surety bonds, the Companies are obligated to indemnify the respective surety bond company for any amounts paid.

Indemnifications

As part of commercial contract negotiations in the normal course of business, the Companies may sometimes agree to make payments to compensate or indemnify other parties for possible future unfavorable financial consequences resulting from specified events. The specified events may involve an adverse judgment in a lawsuit or the imposition of additional taxes due to a change in tax law or interpretation of the tax law. The Companies are unable to develop an estimate of the maximum potential amount of any other future payments under these contracts because events that would obligate them have not yet occurred or, if any such event has occurred, they have not been notified of its occurrence. However, at December 31, 2019, the Companies believe any other future payments, if any, that could ultimately become payable under these contract provisions, would not have a material impact on their results of operations, cash flows or financial position.