XML 52 R16.htm IDEA: XBRL DOCUMENT v3.19.3.a.u2
CONTINGENCIES, COMMITMENTS, AND GUARANTEES
12 Months Ended
Dec. 31, 2019
Commitments and Contingencies Disclosure [Abstract]  
CONTINGENCIES, COMMITMENTS, AND GUARANTEES CONTINGENCIES, COMMITMENTS, AND GUARANTEES
General Litigation Matters
The Registrants are involved in various other matters being litigated and regulatory matters. The ultimate outcome of such pending or potential litigation or regulatory matters against each Registrant and any subsidiaries cannot be determined at this time; however, for current proceedings not specifically reported herein, management does not anticipate that the ultimate liabilities, if any, arising from such current proceedings would have a material effect on such Registrant's financial statements.
The Registrants believe the pending legal challenges discussed below have no merit; however, the ultimate outcome of these matters cannot be determined at this time.
Southern Company
In January 2017, a securities class action complaint was filed against Southern Company, certain of its officers, and certain former Mississippi Power officers in the U.S. District Court for the Northern District of Georgia by Monroe County Employees' Retirement System on behalf of all persons who purchased shares of Southern Company's common stock between April 25, 2012 and October 29, 2013. The complaint alleges that Southern Company, certain of its officers, and certain former Mississippi Power officers made materially false and misleading statements regarding the Kemper County energy facility in violation of certain provisions under the Securities Exchange Act of 1934, as amended. The complaint seeks, among other things, compensatory damages and litigation costs and attorneys' fees. In 2017, the plaintiffs filed an amended complaint that provided additional detail about their claims, increased the purported class period by one day, and added certain other former Mississippi Power officers as defendants. Also in 2017, the defendants filed a motion to dismiss the plaintiffs' amended complaint with prejudice, to which the plaintiffs filed an opposition. In March 2018, the court issued an order granting, in part, the defendants' motion to dismiss. The court dismissed certain claims against certain officers of Southern Company and Mississippi Power and dismissed the allegations related to a number of the statements that plaintiffs challenged as being false or misleading. In April 2018, the defendants filed a motion for reconsideration of the court's order, seeking dismissal of the remaining claims in the lawsuit. In August 2018, the court denied the motion for reconsideration and denied a motion to certify the issue for interlocutory appeal. On August 22, 2019, the court certified the plaintiffs' proposed class. On September 5, 2019, the defendants filed a petition for interlocutory appeal of the class certification order with the U.S. Court of Appeals for the Eleventh Circuit. On December 19, 2019, the U.S. District Court for the Northern District of Georgia entered an order staying all deadlines in the case pending mediation. The stay automatically expires on March 31, 2020.
In February 2017, Jean Vineyard and Judy Mesirov each filed a shareholder derivative lawsuit in the U.S. District Court for the Northern District of Georgia. Each of these lawsuits names as defendants Southern Company, certain of its directors, certain of its officers, and certain former Mississippi Power officers. In 2017, these two shareholder derivative lawsuits were consolidated in the U.S. District Court for the Northern District of Georgia. The complaints allege that the defendants caused Southern Company to make false or misleading statements regarding the Kemper County energy facility cost and schedule. Further, the complaints allege that the defendants were unjustly enriched and caused the waste of corporate assets and also allege that the individual defendants violated their fiduciary duties. Each plaintiff seeks to recover, on behalf of Southern Company, unspecified actual damages and, on each plaintiff's own behalf, attorneys' fees and costs in bringing the lawsuit. Each plaintiff also seeks certain changes to Southern Company's corporate governance and internal processes. In April 2018, the court entered an order staying this lawsuit until 30 days after the resolution of any dispositive motions or any settlement, whichever is earlier, in the securities class action.
In May 2017, Helen E. Piper Survivor's Trust filed a shareholder derivative lawsuit in the Superior Court of Gwinnett County, Georgia that names as defendants Southern Company, certain of its directors, certain of its officers, and certain former Mississippi Power officers. The complaint alleges that the individual defendants, among other things, breached their fiduciary duties in connection with schedule delays and cost overruns associated with the construction of the Kemper County energy facility. The complaint further alleges that the individual defendants authorized or failed to correct false and misleading statements regarding the Kemper County energy facility schedule and cost and failed to implement necessary internal controls to prevent harm to Southern Company. The plaintiff seeks to recover, on behalf of Southern Company, unspecified actual damages and disgorgement of profits and, on its behalf, attorneys' fees and costs in bringing the lawsuit. The plaintiff also seeks certain unspecified changes to Southern Company's corporate governance and internal processes. In May 2018, the court entered an order staying this lawsuit until 30 days after the resolution of any dispositive motions or any settlement, whichever is earlier, in the securities class action. On August 5, 2019, the court granted a motion filed by the plaintiff on July 17, 2019 to substitute a new named plaintiff, Martin J. Kobuck, in place of Helen E. Piper Survivor's Trust.
Georgia Power
In 2011, plaintiffs filed a putative class action against Georgia Power in the Superior Court of Fulton County, Georgia alleging that Georgia Power's collection in rates of amounts for municipal franchise fees (which fees are paid to municipalities) exceeded the amounts allowed in orders of the Georgia PSC and alleging certain state tort law claims. In 2016, the Georgia Court of Appeals reversed the trial court's previous dismissal of the case and remanded the case to the trial court. Georgia Power filed a petition for writ of certiorari with the Georgia Supreme Court, which was granted in 2017. In June 2018, the Georgia Supreme Court affirmed the judgment of the Georgia Court of Appeals and remanded the case to the trial court for further proceedings. Following a motion by Georgia Power, on February 13, 2019, the Superior Court of Fulton County ordered the parties to submit petitions to the Georgia PSC for a declaratory ruling to address certain terms the court previously held were ambiguous as used in the Georgia PSC's orders. The order entered by the Superior Court of Fulton County also conditionally certified the proposed class. In March 2019, Georgia Power and the plaintiffs filed petitions with the Georgia PSC seeking confirmation of the proper application of the municipal franchise fee schedule pursuant to the Georgia PSC's orders. On October 23, 2019, the Georgia PSC issued an order that found and concluded that Georgia Power has appropriately implemented the municipal franchise fee schedule. On March 6, 2019, Georgia Power filed a notice of appeal with the Georgia Court of Appeals regarding the Superior Court of Fulton County's February 2019 order. The amount of any possible losses cannot be calculated at this time because, among other factors, it is unknown whether conditional class certification will be upheld and the ultimate composition of any class and whether any losses would be subject to recovery from any municipalities.
Mississippi Power
In May 2018, Southern Company and Mississippi Power received a notice of dispute and arbitration demand filed by Martin Product Sales, LLC (Martin) based on two agreements, both related to Kemper IGCC byproducts for which Mississippi Power provided termination notices in 2017. Martin alleges breach of contract, breach of good faith and fair dealing, fraud and misrepresentation, and civil conspiracy and makes a claim for damages in the amount of approximately $143 million, as well as additional unspecified damages, attorney's fees, costs, and interest. A portion of the claim for damages was on behalf of Martin Transport, Inc. (Martin Transport), an affiliate of Martin. In the first quarter 2019, Mississippi Power and Southern Company filed motions to dismiss, which were denied by the arbitration panel on May 10, 2019. On September 27, 2019, Martin Transport filed a separate complaint against Mississippi Power in the Circuit Court of Kemper County, Mississippi alleging claims of fraud, negligent misrepresentation, promissory estoppel, and equitable estoppel, each arising out of the same alleged facts and circumstances that underlie Martin's arbitration demand. Martin Transport seeks compensatory damages of $5 million and punitive damages of $50 million. In November 2019, Martin Transport's claim was combined with the Martin arbitration case and the separate court case was dismissed. On December 16, 2019, Southern Company and Mississippi Power each filed motions for summary judgment on all claims. On February 17, 2020, the arbitration panel granted Southern Company's motion and dismissed Southern Company from the arbitration. An adverse outcome in this proceeding could have a material impact on Southern Company's and Mississippi Power's financial statements.
In November 2018, Ray C. Turnage and 10 other individual plaintiffs filed a putative class action complaint against Mississippi Power and three members of the Mississippi PSC in the U.S. District Court for the Southern District of Mississippi. Mississippi Power received Mississippi PSC approval in 2013 to charge a mirror CWIP rate premised upon including in its rate base pre-construction and construction costs for the Kemper IGCC prior to placing the Kemper IGCC into service. The Mississippi Supreme Court reversed that approval and ordered Mississippi Power to refund the amounts paid by customers under the previously-approved mirror CWIP rate. The plaintiffs allege that the initial approval process, and the amount approved, were improper. They also allege that Mississippi Power underpaid customers by up to $23.5 million in the refund process by applying an incorrect interest rate. The plaintiffs seek to recover, on behalf of themselves and their putative class, actual damages, punitive
damages, pre-judgment interest, post-judgment interest, attorney's fees, and costs. In response to Mississippi Power and the Mississippi PSC each filing a motion to dismiss, the plaintiffs filed an amended complaint on March 14, 2019. The amended complaint included four additional plaintiffs and additional claims for gross negligence, reckless conduct, and intentional wrongdoing. Mississippi Power and the Mississippi PSC have each filed a motion to dismiss the amended complaint. An adverse outcome in this proceeding could have a material impact on Mississippi Power's financial statements.
See Note 2 under "Kemper County Energy Facility" for additional information.
Southern Power
Southern Power indirectly owns a 51% membership interest in RE Roserock LLC (Roserock), the owner of the Roserock facility in Pecos County, Texas. Prior to the facility being placed in service in 2016, certain solar panels were damaged during installation by the construction contractor, McCarthy Building Companies, Inc. (McCarthy), and certain solar panels were damaged by a hail event that also occurred during construction. In connection therewith, Southern Power withheld payment of approximately $26 million to the construction contractor, which placed a lien on the Roserock facility for the same amount. In 2017, Roserock filed a lawsuit in the state district court in Pecos County, Texas against XL Insurance America, Inc. and North American Elite Insurance Company seeking recovery from an insurance policy for damages resulting from the hail event and McCarthy's installation practices. In June 2018, the court granted Roserock's motion for partial summary judgment, finding that the insurers were in breach of contract and in violation of the Texas Insurance Code for failing to pay any monies owed for the hail claim. Separate lawsuits were filed between Roserock and McCarthy, as well as other parties, and that litigation was consolidated in the U.S. District Court for the Western District of Texas. On April 18, 2019, Roserock and the parties to the state and federal lawsuits executed a settlement agreement and mutual release that resolved both lawsuits. Following execution of the agreement, the lawsuits were dismissed, Southern Power paid McCarthy the amounts previously withheld, and McCarthy released its lien. As part of the settlement, Roserock received funds that covered all related legal costs, damages, and the replacement costs of certain solar panels. Funds received by Southern Power in excess of the initial replacement costs were recognized as a gain and included in other income (expense), net, with a portion allocated to noncontrolling interests. As a result, Southern Power recognized a $12 million after-tax gain in the second quarter 2019.
Environmental Remediation
The Southern Company system must comply with environmental laws and regulations governing the handling and disposal of waste and releases of hazardous substances. Under these various laws and regulations, the Southern Company system could incur substantial costs to clean up affected sites. The traditional electric operating companies and the natural gas distribution utilities conduct studies to determine the extent of any required cleanup and have recognized the estimated costs to clean up known impacted sites in the financial statements. A liability for environmental remediation costs is recognized only when a loss is determined to be probable and reasonably estimable. The traditional electric operating companies and the natural gas distribution utilities in Illinois and Georgia have each received authority from their respective state PSCs or other applicable state regulatory agencies to recover approved environmental compliance costs through regulatory mechanisms. These regulatory mechanisms are adjusted annually or as necessary within limits approved by the state PSCs or other applicable state regulatory agencies. At December 31, 2019 and 2018, the environmental remediation liabilities of Alabama Power and Mississippi Power were immaterial.
Georgia Power has been designated or identified as a potentially responsible party at sites governed by the Georgia Hazardous Site Response Act and/or by the federal Comprehensive Environmental Response, Compensation, and Liability Act, and assessment and potential cleanup of such sites is expected. For all years presented, Georgia Power recovered approximately $2 million annually through the ECCR tariff. Effective January 1, 2020, Georgia Power is recovering approximately $12 million annually through the ECCR tariff under the 2019 ARP. Georgia Power recognizes a liability for environmental remediation costs only when it determines a loss is probable and reasonably estimable and reduces the reserve as expenditures are incurred. Any difference between the liabilities accrued and costs recovered through rates is deferred as a regulatory asset or liability. The annual recovery amount is expected to be adjusted in future regulatory proceedings.
On December 23, 2019, Mississippi Power entered into an agreement with the Mississippi Commission on Environmental Quality related to groundwater conditions arising from the closed ash pond at Plant Watson. Mississippi Power paid a civil penalty of $200,000 and will complete an assessment and remediation consistent with the requirements of the agreement and the CCR Rule. It is anticipated that corrective action will be needed; however, an estimate of remedial costs will not be available until further site assessment is completed. Mississippi Power expects to recover the retail portion of remedial costs through the ECO Plan and the wholesale portion through MRA rates.
Southern Company Gas is subject to environmental remediation liabilities associated with 40 former MGP sites in four different states. Southern Company Gas' accrued environmental remediation liability at December 31, 2019 and 2018 was based on the
estimated cost of environmental investigation and remediation associated with known current and former MGP operating sites. These environmental remediation expenditures are generally recoverable from customers through rate mechanisms approved by the applicable state regulatory agencies of the natural gas distribution utilities.
At December 31, 2019 and 2018, the environmental remediation liability and the balance of under recovered environmental remediation costs were reflected in the balance sheets as follows:
 
Southern Company
Georgia
Power
Southern Company Gas
 
(in millions)
December 31, 2019:
 
 
 
Environmental remediation liability:
 
 
 
Other current liabilities
$
51

$
15

$
36

Accrued environmental remediation
234


233

Under recovered environmental remediation costs:
 
 
 
Other regulatory assets, current
$
49

$
12

$
37

Other regulatory assets, deferred
300

40

260

 
 
 
 
December 31, 2018:
 
 
 
Environmental remediation liability:
 
 
 
Other current liabilities
$
49

$
23

$
26

Accrued environmental remediation
268


268

Under recovered environmental remediation costs:
 
 
 
Other regulatory assets, current
$
21

$
2

$
19

Other regulatory assets, deferred
345

53

292


The ultimate outcome of these matters cannot be determined at this time; however, as a result of the regulatory treatment for environmental remediation expenses described above, the final disposition of these matters is not expected to have a material impact on the financial statements of the applicable Registrants.
Nuclear Fuel Disposal Costs
Acting through the DOE and pursuant to the Nuclear Waste Policy Act of 1982, the U.S. government entered into contracts with Alabama Power and Georgia Power that require the DOE to dispose of spent nuclear fuel and high level radioactive waste generated at Plants Farley, Hatch, and Vogtle Units 1 and 2 beginning no later than January 31, 1998. The DOE has yet to commence the performance of its contractual and statutory obligation to dispose of spent nuclear fuel. Consequently, Alabama Power and Georgia Power pursued and continue to pursue legal remedies against the U.S. government for its partial breach of contract.
In 2014, Alabama Power and Georgia Power filed lawsuits against the U.S. government for the costs of continuing to store spent nuclear fuel at Plants Farley, Hatch, and Vogtle Units 1 and 2 for the period from January 1, 2011 through December 31, 2013. The damage period was subsequently extended to December 31, 2014. On June 12, 2019, the Court of Federal Claims granted Alabama Power's and Georgia Power's motion for summary judgment on damages not disputed by the U.S. government, awarding those undisputed damages to Alabama Power and Georgia Power. However, those undisputed damages are not collectible and no amounts will be recognized in the financial statements until the court enters final judgment on the remaining damages.
In 2017, Alabama Power and Georgia Power filed additional lawsuits against the U.S. government in the Court of Federal Claims for the costs of continuing to store spent nuclear fuel at Plants Farley, Hatch, and Vogtle Units 1 and 2 for the period from January 1, 2015 through December 31, 2017. Damages will continue to accumulate until the issue is resolved, the U.S. government disposes of Alabama Power's and Georgia Power's spent nuclear fuel pursuant to its contractual obligations, or alternative storage is otherwise provided. No amounts have been recognized in the financial statements as of December 31, 2019 for any potential recoveries from the pending lawsuits.
The final outcome of these matters cannot be determined at this time. However, Alabama Power and Georgia Power expect to credit any recoveries for the benefit of customers in accordance with direction from their respective PSC; therefore, no material impact on Southern Company's, Alabama Power's, or Georgia Power's net income is expected.
On-site dry spent fuel storage facilities are operational at all three plants and can be expanded to accommodate spent fuel through the expected life of each plant.
Nuclear Insurance
Under the Price-Anderson Amendments Act (Act), Alabama Power and Georgia Power maintain agreements of indemnity with the NRC that, together with private insurance, cover third-party liability arising from any nuclear incident occurring at the companies' nuclear power plants. The Act provides funds up to $13.9 billion for public liability claims that could arise from a single nuclear incident. Each nuclear plant is insured against this liability to a maximum of $450 million by American Nuclear Insurers (ANI), with the remaining coverage provided by a mandatory program of deferred premiums that could be assessed, after a nuclear incident, against all owners of commercial nuclear reactors. A company could be assessed up to $138 million per incident for each licensed reactor it operates but not more than an aggregate of $20 million per incident to be paid in a calendar year for each reactor. Such maximum assessment, excluding any applicable state premium taxes, for Alabama Power and Georgia Power, based on its ownership and buyback interests in all licensed reactors, is $275 million and $267 million, respectively, per incident, but not more than an aggregate of $41 million and $40 million, respectively, to be paid for each incident in any one year. Both the maximum assessment per reactor and the maximum yearly assessment are adjusted for inflation at least every five years. The next scheduled adjustment is due no later than November 1, 2023. See Note 5 under "Joint Ownership Agreements" for additional information on joint ownership agreements.
Alabama Power and Georgia Power are members of Nuclear Electric Insurance Limited (NEIL), a mutual insurer established to provide property damage insurance in an amount up to $1.5 billion for members' operating nuclear generating facilities. Additionally, both companies have NEIL policies that currently provide decontamination, excess property insurance, and premature decommissioning coverage up to $1.25 billion for nuclear losses and policies providing coverage up to $750 million for non-nuclear losses in excess of the $1.5 billion primary coverage.
NEIL also covers the additional costs that would be incurred in obtaining replacement power during a prolonged accidental outage at a member's nuclear plant. Members can purchase this coverage, subject to a deductible waiting period of up to 26 weeks, with a maximum per occurrence per unit limit of $490 million. After the deductible period, weekly indemnity payments would be received until either the unit is operational or until the limit is exhausted. Alabama Power and Georgia Power each purchase limits based on the projected full cost of replacement power, subject to ownership limitations, and have each elected a 12-week deductible waiting period for each nuclear plant.
A builders' risk property insurance policy has been purchased from NEIL for the construction of Plant Vogtle Units 3 and 4. This policy provides the Vogtle Owners up to $2.75 billion for accidental property damage occurring during construction.
Under each of the NEIL policies, members are subject to assessments each year if losses exceed the accumulated funds available to the insurer. The maximum annual assessments for Alabama Power and Georgia Power as of December 31, 2019 under the NEIL policies would be $58 million and $85 million, respectively.
Claims resulting from terrorist acts are covered under both the ANI and NEIL policies (subject to normal policy limits). The aggregate that NEIL will pay for all claims resulting from terrorist acts in any 12-month period is $3.2 billion plus such additional amounts NEIL can recover through reinsurance, indemnity, or other sources.
For all on-site property damage insurance policies for commercial nuclear power plants, the NRC requires that the proceeds of such policies shall be dedicated first for the sole purpose of placing the reactor in a safe and stable condition after an accident. Any remaining proceeds are to be applied next toward the costs of decontamination and debris removal operations ordered by the NRC, and any further remaining proceeds are to be paid either to the applicable company or to its debt trustees as may be appropriate under the policies and applicable trust indentures. In the event of a loss, the amount of insurance available might not be adequate to cover property damage and other expenses incurred. Uninsured losses and other expenses, to the extent not recovered from customers, would be borne by Alabama Power or Georgia Power, as applicable, and could have a material effect on Southern Company's, Alabama Power's, and Georgia Power's financial condition and results of operations.
All retrospective assessments, whether generated for liability, property, or replacement power, may be subject to applicable state premium taxes.
Other Matters
Southern Company
As discussed in Note 1 under "Leveraged Leases," a subsidiary of Southern Holdings has several leveraged lease agreements. The ability of the lessees to make required payments to the Southern Holdings subsidiary is dependent on the operational performance of the assets. In 2017, the financial and operational performance of one of the lessees and the associated generation assets raised significant concerns about the short-term ability of the generation assets to produce cash flows sufficient to support ongoing operations and the lessee's contractual obligations and its ability to make the remaining semi-annual lease payments through the end of the lease term in 2047. In addition, following the expiration of the existing power offtake agreement in 2032, the lessee also is exposed to remarketing risk, which encompasses the price and availability of alternative sources of generation. While all lease payments through December 31, 2019 have been paid in full due to recent operational improvements, operational and remarketing risks and the resulting cash liquidity challenges persist, and significant concerns continue regarding the lessee's ability to make the remaining semi-annual lease payments. These challenges may also impact the expected residual value of the generation assets. Southern Company has evaluated the recoverability of the lease receivable and the expected residual value of the generation assets under various scenarios. Based on current forecasts of energy prices in the years following the expiration of the existing PPA, Southern Company concluded that it is no longer probable that all of the associated rental payments will be received over the term of the lease. As a result, during the fourth quarter 2019, Southern Company revised the estimate of cash flows to be received under the leveraged lease, which resulted in an impairment charge of $17 million ($13 million after tax). If any future lease payment is not paid in full, the Southern Holdings subsidiary may be unable to make its corresponding payment to the holders of the underlying non-recourse debt related to the generation assets. Failure to make the required payment to the debtholders could represent an event of default that would give the debtholders the right to foreclose on, and take ownership of, the generation assets from the Southern Holdings subsidiary, in effect terminating the lease and resulting in the write-off of the related lease receivable, which totaled approximately $76 million at December 31, 2019. Southern Company will continue to monitor the operational performance of the underlying assets and evaluate the ability of the lessee to continue to make the required lease payments. The ultimate outcome of this matter cannot be determined at this time.
Alabama Power
On October 16, 2019, Alabama Power agreed to a consent order regarding a fish kill investigation. The consent order required Alabama Power to pay approximately $50,000 to the Alabama Department of Environmental Management in civil penalties and approximately $172,000 to the Alabama Department of Conservation and Natural Resources in fish restocking costs. Alabama Power paid the penalties and restocking costs during the fourth quarter 2019.
Mississippi Power
In 2013, Mississippi Power submitted a lost revenue claim under the Deepwater Horizon Economic and Property Damages Settlement Agreement associated with the oil spill that occurred in the Gulf of Mexico in 2010. In May 2018, Mississippi Power's claim was settled. The settlement proceeds of $18 million, net of expenses and income tax, were included in Mississippi Power's earnings for 2018. Mississippi Power received half of the settlement proceeds in 2018 and half in 2019.
In conjunction with Southern Company's sale of Gulf Power, NextEra Energy held back $75 million of the purchase price pending Mississippi Power and Gulf Power negotiating a mutually acceptable revised operating agreement for Plant Daniel. In addition, Mississippi Power and Gulf Power committed to seek a restructuring of their 50% undivided ownership interests in Plant Daniel such that each of them would, after the restructuring, own 100% of a generating unit. On January 15, 2019, Gulf Power provided notice to Mississippi Power that Gulf Power will retire its share of the generating capacity of Plant Daniel on January 15, 2024. Mississippi Power has the option to purchase Gulf Power's ownership interest for $1 on January 15, 2024, provided that Mississippi Power exercises the option no later than 120 days prior to that date. Mississippi Power is assessing the potential operational and economic effects of Gulf Power's notice. The ultimate outcome of these matters remains subject to completion of Mississippi Power's evaluations and applicable regulatory approvals, including by the FERC and the Mississippi PSC, and cannot be determined at this time. See Note 15 under "Southern Company" for information regarding the sale of Gulf Power.
Southern Company Gas
Gas Pipeline Projects
At December 31, 2019, Southern Company Gas was involved in two gas pipeline construction projects, the Atlantic Coast Pipeline project and the PennEast Pipeline project.
The Atlantic Coast Pipeline has experienced challenges to its permits since construction began in 2018. During the third and fourth quarters 2018, a FERC stop work order, together with delays in obtaining permits necessary for construction and construction delays due to judicial actions, impacted the cost and schedule for the project. Project cost estimates are approximately $8.0 billion ($400 million for Southern Company Gas), excluding financing costs. On October 4, 2019, the U.S. Supreme Court agreed to hear Atlantic Coast Pipeline's appeal of a lower court ruling that overturned a key permit for the project. On January 7, 2020, the U.S. Court of Appeals for the Fourth Circuit vacated another key permit. The operator of the joint venture has indicated that it currently expects to complete construction by the end of 2021 and place the project in service shortly thereafter.
On February 7, 2020, Southern Company Gas entered into an agreement with Dominion Atlantic Coast Pipeline, LLC for the sale of its interest in Atlantic Coast Pipeline. The transaction is expected to be completed in the first half of 2020; however, the ultimate outcome cannot be determined at this time. See Note 15 under "Southern Company Gas – Proposed Sale of Pivotal LNG and Atlantic Coast Pipeline" for additional information.
Expected project costs related to the PennEast Pipeline for Southern Company Gas total approximately $300 million, excluding financing costs. In January 2018, the PennEast Pipeline received initial FERC approval. Work continues with state and federal agencies to obtain the required permits to begin construction on the PennEast Pipeline. On September 10, 2019, an appellate court ruled that the PennEast Pipeline does not have federal eminent domain authority over lands in which a state has property rights interests. On February 18, 2020, PennEast Pipeline filed a petition for a writ of certiorari to seek U.S. Supreme Court review of the appellate court decision. On December 30, 2019, PennEast Pipeline filed a two-year extension request with the FERC to complete the project by January 19, 2022.
Additionally, on January 30, 2020, PennEast Pipeline filed an amendment with the FERC to construct the pipeline project in two phases. The first phase would consist of 68 miles of pipe, constructed entirely within Pennsylvania, which is expected to be completed by November 2021. The second phase would include the remaining route in Pennsylvania and New Jersey and is targeted for completion in 2023. FERC approval of the amended plan is required prior to beginning the first phase.
The ultimate outcome of these matters cannot be determined at this time; however, any work delays, whether caused by judicial or regulatory action, abnormal weather, or other conditions, may result in additional cost or schedule modifications or, ultimately, in project cancellation, any of which could result in an impairment of one or both of Southern Company Gas' investments and could have a material impact on Southern Company's and Southern Company Gas' financial statements. Southern Company Gas evaluated its investments and determined there was no impairment as of December 31, 2019.
See Note 3 under "Guarantees" and Note 7 under "Southern Company Gas" for additional information.
Natural Gas Storage Facilities
A wholly-owned subsidiary of Southern Company Gas owns and operates a natural gas storage facility consisting of two salt dome caverns in Louisiana. Periodic integrity tests are required in accordance with rules of the Louisiana Department of Natural Resources (DNR). In 2017, in connection with an ongoing integrity project, updated seismic mapping indicated the proximity of one of the caverns to the edge of the salt dome may be less than the required minimum and could result in Southern Company Gas retiring the cavern early.
In the third quarter 2019, management determined that it no longer planned to obtain the core samples during 2020 that are necessary to determine the composition of the sheath surrounding the edge of the salt dome. Core sampling is a requirement of the Louisiana DNR to put the cavern back in service; as a result, the cavern will not return to service by 2021. This change in plan, which affects the future operation of the entire storage facility, resulted in a pre-tax impairment charge of $91 million ($69 million after-tax) recorded by Southern Company Gas in 2019. Southern Company Gas continues to monitor the pressure and overall structural integrity of the entire facility pending any future decisions regarding decommissioning.
Southern Company Gas has two other natural gas storage facilities located in California and Texas, which could be impacted by ongoing changes in the U.S. natural gas storage market. Recent sales of natural gas storage facilities have resulted in losses for the sellers and may imply an impact on future rates and/or asset values. Sustained diminished natural gas storage values could trigger impairment of either or both of these natural gas storage facilities, which have a combined net book value of $326 million at December 31, 2019.
The ultimate outcome of these matters cannot be determined at this time, but could have a material impact on the financial statements of Southern Company and Southern Company Gas.
Commitments
To supply a portion of the fuel requirements of the Southern Company system's electric generating plants, the Southern Company system has entered into various long-term commitments not recognized on the balance sheets for the procurement and delivery of fossil fuel and, for Alabama Power and Georgia Power, nuclear fuel. The majority of the Registrants' fuel expense for the periods presented was purchased under long-term commitments. Each Registrant expects that a substantial amount of its future fuel needs will continue to be purchased under long-term commitments.
Georgia Power has commitments, in the form of capacity purchases, regarding a portion of a 5% interest in the original cost of Plant Vogtle Units 1 and 2 owned by MEAG Power that are in effect until the later of the retirement of the plant or the latest stated maturity date of MEAG Power's bonds issued to finance such ownership interest. The payments for capacity are required whether or not any capacity is available. Portions of the capacity payments made to MEAG Power for its Plant Vogtle Units 1 and 2 investment relate to costs in excess of Georgia Power's allowed investment for ratemaking purposes. The present value of these portions at the time of the disallowance was written off. Generally, the cost of such capacity is included in purchased power in Southern Company's statements of income and in purchased power, non-affiliates in Georgia Power's statements of income. Georgia Power's capacity payments related to this commitment totaled $6 million, $8 million, and $9 million in 2019, 2018, and 2017, respectively. At December 31, 2019, Georgia Power's estimated long-term obligations related to this commitment totaled $56 million, consisting of $5 million for 2020, $5 million for 2021, $4 million for 2022, $3 million for 2023, $4 million for 2024, and $35 million for 2025 and thereafter.
See Note 9 for information regarding PPAs accounted for as leases.
Southern Company Gas has commitments for pipeline charges, storage capacity, and gas supply, including charges recoverable through natural gas cost recovery mechanisms or, alternatively, billed to marketers selling retail natural gas, as well as demand charges associated with Southern Company Gas' wholesale gas services. Gas supply commitments include amounts for gas commodity purchases associated with Southern Company Gas' gas marketing services of 45 million mmBtu at floating gas prices calculated using forward natural gas prices at December 31, 2019 and valued at $84 million. Southern Company Gas provides guarantees to certain gas suppliers for certain of its subsidiaries in support of payment obligations. Southern Company Gas' expected future contractual obligations for pipeline charges, storage capacity, and gas supply that are not recognized on the balance sheets at December 31, 2019 were as follows:
 
Pipeline Charges, Storage Capacity, and Gas Supply
 
(in millions)
2020
$
725

2021
559

2022
526

2023
454

2024
330

2025 and thereafter
1,677

Total
$
4,271


Guarantees
SCS may enter into various types of wholesale energy and natural gas contracts acting as an agent for the traditional electric operating companies and Southern Power. Under these agreements, each of the traditional electric operating companies and Southern Power may be jointly and severally liable. Accordingly, Southern Company has entered into keep-well agreements with each of the traditional electric operating companies to ensure they will not subsidize or be responsible for any costs, losses, liabilities, or damages resulting from the inclusion of Southern Power as a contracting party under these agreements.
Alabama Power has guaranteed a $100 million principal amount long-term bank loan entered into by SEGCO in November 2018. Georgia Power has agreed to reimburse Alabama Power for the portion of such obligation corresponding to Georgia Power's proportionate ownership of SEGCO's stock if Alabama Power is called upon to make such payment under its guarantee. At December 31, 2019, the capitalization of SEGCO consisted of $87 million of equity and $100 million of long-term debt, on which the annual interest requirement is derived from a variable rate index. In addition, SEGCO had short-term debt outstanding of $26 million. See Note 7 under "SEGCO" for additional information.
In 2017, Atlantic Coast Pipeline executed a $3.4 billion revolving credit facility with a stated maturity date of October 2021. Southern Company Gas entered into a guarantee agreement to support its share of the revolving credit facility. Southern Company Gas' maximum exposure to loss under the terms of the guarantee is limited to 5% of the outstanding borrowings under the credit facility, and totaled $88 million as of December 31, 2019. See "Other MattersSouthern Company GasGas Pipeline Projects" herein and Note 7 under "Southern Company Gas" for additional information regarding the Atlantic Coast Pipeline.
As discussed in Note 9, Alabama Power and Georgia Power have entered into certain residual value guarantees related to railcar leases.