F-1/A 1 ff12023a7_chikoholdings.htm REGISTRATION STATEMENT

As filed with the Securities and Exchange Commission on October 25, 2023.

Registration Statement No. 333-270591

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549

____________________________

AMENDMENT NO. 7 TO
FORM F-1
REGISTRATION STATEMENT
UNDER
THE SECURITIES ACT OF 1933

__________________________________________

Chi Ko Holdings Limited

(Exact name of registrant as specified in its charter)

__________________________________________

Cayman Islands

 

1540

 

Not Applicable

(State or other jurisdiction of
incorporation or organization)

 

(Primary Standard Industrial
Classification Code Number)

 

(IRS Employer
Identification Number)

Room 2620, 26/F., New Tech Plaza
34 Tai Yau Street
San Po Kong
Kowloon, Hong Kong
+852 2155 9690
(Address, including zip code, and telephone number, including area code, of registrant’s principal executive offices)

__________________________________________

c/o Cogency Global Inc.
122 East 42
nd Street, 18th Floor
New York, NY 10168
+212 947-7200
(Name, address, including zip code, and telephone number, including area code, of agent for service)

__________________________________________

Copies to:

Virginia Tam
K&L Gates
44/F, Edinburgh Tower, The Landmark
15 Queen’s Road Central, Hong Kong

+852 2230 3535

 

Mark E. Crone, Esq.
The Crone Law Group P.C.
500 Fifth Avenue, Suite 938
New York, NY 10110
+646 861 7891

__________________________________________

Approximate date of commencement of proposed sale to public: As soon as practicable after this registration statement becomes effective.

If any of the securities being registered on this form are to be offered on a delayed or continuous basis pursuant to Rule 415 under the Securities Act, check the following box. 

If this Form is filed to register additional securities for an offering pursuant to Rule 462(b) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. 

If this Form is a post-effective amendment filed pursuant to Rule 462(c) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. 

If this Form is a post-effective amendment filed pursuant to Rule 462(d) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. 

Indicate by check mark whether the registrant is an emerging growth company as defined in Rule 405 of the Securities Act: Emerging growth company

If an emerging growth company that prepares its financial statements in accordance with accounting principles generally accepted in the United States (“U.S. GAAP”), indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 7(a)(2)(B) of the Securities Act. 

____________

        The term “new or revised financial accounting standard” refers to any update issued by the Financial Accounting Standards Board to its Accounting Standards Codification after April 5, 2012.

The registrant hereby amends this registration statement on such date or dates as may be necessary to delay its effective date until the registrant shall file a further amendment that specifically states that this registration statement shall thereafter become effective in accordance with Section 8(a) of the Securities Act or until the registration statement shall become effective on such date as the Commission, acting pursuant to such Section 8(a), may determine.

 

Table of Contents

The information in this prospectus is not complete and may be changed. We may not sell these securities until the registration statement filed with the Securities and Exchange Commission is effective. This prospectus is not an offer to sell these securities and it is not soliciting an offer to buy these securities in any jurisdiction where the offer or sale is not permitted.

PRELIMINARY PROSPECTUS

 

SUBJECT TO COMPLETION, DATED OCTOBER 25, 2023

1,740,000 Ordinary Shares

Chi Ko Holdings Limited

This is the IPO of the ordinary shares, par value US$0.0001 per share (“Ordinary Shares” or “Shares”), of Chi Ko Holdings Limited (“CKHL”). We are offering 1,740,000 Ordinary Shares of CKHL, representing 13.4% of the Ordinary Shares following completion of the offering of CKHL. Following the offering, 1,740,000 of the Ordinary Shares will be held by shareholders for general trading, assuming the underwriters do not exercise the over-allotment option.

Prior to this offering, there has been no public market for our Ordinary Shares. The offering price of our Ordinary Shares in this offering is expected to be between $4.00 and $5.00 per share. We intend to apply to list our Ordinary Shares on the Nasdaq Capital Market under the symbol “CKHL.” Listing of our Ordinary Shares on Nasdaq is a condition to the offering. There is no assurance that such application will be approved, and if our application is not approved, this offering may not be completed.

Investors are cautioned that you are buying shares of a Cayman Islands holding company with operations in Hong Kong by its Operating Subsidiary.

CKHL is a holding company incorporated in the Cayman Islands with no material operations of its own, and we conduct our operations primarily in Hong Kong through our key Operating Subsidiary Chiu & Lee Partners. References to the “Company,” “we,” “us,” and “our” in the prospectus are to CKHL, the Cayman Islands entity that will issue the Ordinary Shares being offered. References to “Chiu & Lee Partners” are to the entity operating the business. References to “Operating Subsidiary” refer to Chiu & Lee Partners. This is an offering of the Ordinary Shares of CKHL, the holding company in the Cayman Islands, instead of the shares of the Operating Subsidiary. Investors in this offering may never directly hold any equity interests in the Operating Subsidiary.

Investing in our Ordinary Shares is highly speculative and involves a high degree of risk. Before buying any shares, you should carefully read the discussion of material risks of investing in our Ordinary Shares in “Risk Factors” beginning on page 22 of this prospectus.

Our operations are primarily located in Hong Kong, a Special Administrative Region of the People’s Republic of China (“China” or the “PRC”), with its own governmental and legal system that is independent from mainland China and has its own distinct rules and regulations. As of the date of this prospectus, we are not subject to the PRC government’s direct influence or discretion over the manner in which we conduct our business activities outside of the PRC. However, due to long-arm provisions under the current PRC laws and regulations, there remains regulatory uncertainty with respect to the implementation and interpretation of laws in China. We are subject to the risks of uncertainty about any future actions of the PRC government or authorities in Hong Kong in this regard. We may also be subject to unique risks due to the uncertainty of the interpretation and application of PRC laws and regulations.

Should the PRC government choose to exercise significant oversight and discretion over the conduct of our business, they may intervene in or influence our operations. Such governmental actions:

        could result in a material change in our operations and/or the value of our securities;

        could significantly limit or completely hinder our ability to continue our operations;

        could significantly limit or completely hinder our ability to offer or continue to offer our securities to investors; and

        may cause the value of our securities to significantly decline or be worthless.

We are aware that recently the PRC government has initiated a series of regulatory actions and new policies to regulate business operations in certain areas in China with little advance notice, including cracking down on illegal activities in the securities market, enhancing supervision over China-based companies listed overseas using a variable interest entity (“VIE”) structure, adopting new measures to extend the scope of cybersecurity reviews, and expanding the efforts in anti-monopoly enforcement. Since these statements and regulatory actions are new, it is highly uncertain how soon the legislative or administrative regulation making bodies will respond and what existing or new laws or regulations or detailed implementations and interpretations will be modified or promulgated, if any. It is also highly uncertain what the potential impact such modified or new laws and regulations will have on Chiu & Lee Partners’ daily business operation, its ability to accept foreign investments and the listing of our Ordinary Shares on U.S. or other foreign exchanges.

The PRC government may intervene or influence our operations at any time and may exert more control over offerings conducted overseas and foreign investment in Hong Kong-based issuers. The PRC government may also intervene or impose restrictions on our ability to move out of Hong Kong to distribute earnings and pay dividends or to reinvest in our business outside of Hong Kong. Furthermore, PRC regulatory authorities may in the future promulgate laws, regulations or

 

Table of Contents

implementing rules that require our company or any of our subsidiaries to obtain regulatory approval from PRC authorities before this offering. These actions could result in a material change in our operations and could significantly limit or completely hinder our ability to complete this offering or cause the value of our Ordinary Shares to significantly decline or become worthless. See “Prospectus Summary — Recent Regulatory Developments in the PRC” beginning on page 13.

As of the date of this prospectus, our operations in Hong Kong and our registered public offering in the United States are not subject to the review nor prior approval of the Cyberspace Administration of China (the “CAC”) nor the China Securities Regulatory Commission (the “CSRC”). Uncertainties still exist, however, due to the possibility that laws, regulations, or policies in the PRC could change rapidly in the future. In the event that (i) the PRC government expanded the categories of industries and companies whose foreign securities offerings are subject to review by the CSRC or the CAC and that we are required to obtain such permissions or approvals, or (ii) we inadvertently concluded that relevant permissions or approvals were not required or that we did not receive or maintain relevant permissions or approvals required, any action taken by the PRC government could significantly limit or completely hinder our operations in Hong Kong and our ability to offer or continue to offer our Ordinary Shares to investors and could cause the value of such securities to significantly decline or be worthless.

Furthermore, as more stringent criteria, including the Holding Foreign Companies Accountable Act (the “HFCA Act”), have been imposed by the SEC and the Public Company Accounting Oversight Board (“PCAOB”), recently, our Ordinary Shares may be prohibited from trading if our auditor cannot be fully inspected. Our auditor, ZH CPA, LLC, the independent registered public accounting firm that issues the audit report included in this prospectus, as an auditor of companies that are traded publicly in the United States and a firm registered with the PCAOB, is subject to laws in the United States pursuant to which the PCAOB conducts regular inspections to assess ZH CPA, LLC’s compliance with applicable professional standards. ZH CPA, LLC is headquartered in Denver, Colorado, and can be inspected by the PCAOB. As of the date of this prospectus, our auditor is not subject to the determinations announced by the PCAOB on December 16, 2021, relating to the PCAOB’s inability to inspect or investigate completely registered public accounting firms headquartered in mainland China or Hong Kong because of a position taken by one or more authorities in the PRC or Hong Kong. On August 26, 2022, CSRC, the Ministry of Finance of the PRC (the “MOF”), and the PCAOB signed a Statement of Protocol (the “Protocol”), governing inspections and investigations of audit firms based in China and Hong Kong. The Protocol remains unpublished and is subject to further explanation and implementation. Pursuant to the fact sheet with respect to the Protocol disclosed by the SEC, the PCAOB shall have independent discretion to select any issuer audits for inspection or investigation and has the unfettered ability to transfer information to the SEC. On December 15, 2022, the PCAOB Board determined that the PCAOB was able to secure complete access to inspect and investigate registered public accounting firms headquartered in mainland China and Hong Kong and voted to vacate its previous determinations to the contrary. However, should PRC authorities obstruct or otherwise fail to facilitate the PCAOB’s access in the future, the PCAOB Board will consider the need to issue a new determination. See “Risk Factors — Risks Relating to Our Ordinary Shares — Although the audit report included in this prospectus is prepared by U.S. auditors who are currently inspected by the PCAOB, there is no guarantee that future audit reports will be prepared by auditors inspected by the PCAOB and, as such, in the future investors may be deprived of the benefits of such inspection. Furthermore, trading in our securities may be prohibited under the HFCA Act if the SEC subsequently determines our audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely, and as a result, U.S. national securities exchanges, such as the Nasdaq, may determine to delist our securities. Furthermore, on December 29, 2022 the Accelerating Holding Foreign Companies Accountable Act was enacted, which amended the HFCA Act by requiring the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three, and thus, reduced the time before the securities may be prohibited from trading or delisted” on page 27. We cannot assure you whether Nasdaq or other regulatory authorities will apply additional or more stringent criteria to us. Such uncertainty could cause the market price of our Ordinary Shares to be materially and adversely affected.

Our management monitors the cash position of our Operating Subsidiary regularly and prepares budgets on a monthly basis to ensure it has the necessary funds to fulfill its obligations for the foreseeable future and to ensure adequate liquidity. In the event that there is a need for cash or a potential liquidity issue, it will be reported to our chief financial officer and subject to approval by our board of directors.

For CKHL to transfer cash to its subsidiaries, CKHL is permitted under the laws of the Cayman Islands and its memorandum and articles of association (as amended from time to time) to provide funding to our subsidiaries incorporated in the BVI and Hong Kong through loans or capital contributions. CKHL’s subsidiary formed under the laws of the BVI is permitted under the laws of the BVI to provide funding to our Hong Kong Operating Subsidiary Chiu & Lee Partners subject to certain restrictions laid down in the BVI Business Companies Act 2004 (as amended) and memorandum and articles of association of the relevant CKHL’s subsidiary incorporated under the laws of the BVI. As a holding company, CKHL may rely on dividends and other distributions on equity paid by its subsidiaries for its cash and financing requirements. According to the BVI Business Companies Act 2004 (as amended), a BVI company may make dividends distribution to the extent that immediately after the distribution, the value of the company’s assets exceeds its liabilities and that such company is able to pay its debts as they fall due. According to the Companies Ordinance of Hong Kong, a Hong Kong company may only make a distribution out of profits available for distribution. If any of CKHL’s subsidiaries incur debt on its own behalf in the future, the instruments governing such debt may restrict their ability to pay dividends to CKHL. 

 

Table of Contents

During the year ended March 31, 2023, Chiu & Lee Partners declared cash dividends in the amount of HK$26,607,539 (approximately US$3,411,223) to its sole shareholder Orange Space Limited, and having received the dividend income, Orange Space Limited declared the same amount of dividend to its shareholder, CKHL and CKHL also declared the same amount of dividend to its shareholders. For the cash dividend declared for the year ended March 31, 2023, HK$10,387,048 (approximately US$1,331,673) was offset by the amount due from Mr. Keung Yun Yuen in March 3023 and the remaining HK$13,612,952 (approximately US$1,745,250) has been settled in April 2023.

During the year ended March 31, 2022, Chiu & Lee Partners declared cash dividends in the amount of HK$12,000,000 (approximately US$1,538,462) to the then direct shareholder, Mr. Keung Yun Yuen. For the cash dividend declared for the year ended March 31, 2022, HK$10,704,314 (approximately US$,1372,348) was offset by the amount due from Mr. Keung Yun Yuen in February 2022 and HK$1,295,681 (approximately US$166,113) was offset from Mr. Keung Yun Yuen in May 2022.

Save as disclosed above, during the years ended March 31, 2023 and 2022 and as of the date of this prospectus, CKHL did not declare or pay any dividends and there were no transfer of assets among CKHL and its subsidiaries.

We do not have any current intentions to distribute further earnings. If we determine to pay dividends on any of our Ordinary Shares in the future, as a holding company, we will be dependent on receipt of funds from our Hong Kong Operating Subsidiary Chiu & Lee Partners by way of dividend payments. See “Dividend Policy,” and “Consolidated Statements of Change in Shareholders’ Equity in the Report of Independent Registered Public Accounting Firm” for further details.

We are an “emerging growth company” and a “foreign private issuer” as defined under the federal securities laws and, as such, will be subject to reduced public company reporting requirements. See “Prospectus Summary — Implications of Being an Emerging Growth Company and a Foreign Private Issuer” for additional information.

Upon the completion of this offering, the outstanding shares of CKHL will consist of 12,990,000 Ordinary Shares, assuming the underwriters do not exercise their over-allotment option to purchase additional Ordinary Shares, or 13,251,000 Ordinary Shares, assuming the over-allotment option is exercised in full. CKHL will be a “controlled company” as defined under the Nasdaq Stock Market Rules because, immediately after the completion of this offering, our Controlling Shareholder of CKHL will own 78.1% of the total issued and outstanding Ordinary Shares, representing 78.1% of the total voting power, assuming that the underwriters do not exercise their over-allotment option, or 76.6% of the total issued and outstanding Ordinary Shares, representing 76.6% of the total voting power, assuming that the over-allotment option is exercised in full.

 

Per Share

 

Total(3)

IPO price(1)

 

$

4.00

 

$

6,960,000

Underwriting discounts(2) and commissions

 

$

0.32

 

$

556,800

Proceeds, before expenses, to us

 

$

3.68

 

$

6,403,200

____________

(1)    Based on an assumed public offering price of US$4.00 per Ordinary Share.

(2)    Represents underwriting discounts equal to 8% per Ordinary Share.

(3)    Assumes that the underwriters do not exercise any portion of their over-allotment option.

We expect our total cash expenses for this offering (including cash expenses payable to our underwriters for their out-of-pocket expenses) to be approximately US$1,900,641 exclusive of the above discounts. In addition, we will pay additional items of value in connection with this offering that are viewed by the Financial Industry Regulatory Authority (“FINRA”), as underwriting compensation. These payments will further reduce proceeds available to us before expenses. See “Underwriting.”

Neither the Securities and Exchange Commission nor any state securities commission nor any other regulatory body has approved or disapproved of these securities or determined if this prospectus is truthful or complete. Any representation to the contrary is a criminal offense.

This offering is being conducted on a firm commitment basis. The underwriters are obligated to take and pay for all of the shares if any such shares are taken. We have granted the underwriters an option for a period of forty-five (45) days after the closing of this offering to purchase up to 261,000 additional Ordinary Shares from us at the IPO price, less underwriting discounts to cover over-allotments, if any. If the underwriters exercise the option in full, assuming the public offering price per Ordinary Share is US$4.00, the total underwriting discounts payable will be US$640,320 and the total proceeds to us, before expenses, will be US$7,363,680.

We expect our total cash expenses for this offering to be approximately US$1,900,641, including cash expenses payable to the underwriters for their reasonable out-of-pocket expenses, exclusive of the above discounts.

If we complete this offering, net proceeds will be delivered to us on the closing date.

The underwriters expect to deliver the Ordinary Shares against payment as set forth under “Underwriting” on or about            , 2023.

EF Hutton

division of Benchmark Investments, LLC

The date of this prospectus is            , 2023.

 

Table of Contents

TABLE OF CONTENTS

 

Page

Prospectus Summary

 

1

Risk Factors

 

22

Special Note Regarding Forward-Looking Statements

 

52

Industry and Market Data

 

53

Use of Proceeds

 

57

Dividend Policy

 

58

Capitalization

 

59

Dilution

 

60

Exchange Rate Information

 

62

Corporate History and Structure

 

63

Management’s Discussion and Analysis of Financial Condition and Results of Operations

 

65

Business

 

76

Regulations

 

93

Management

 

101

Related Party Transactions

 

107

Principal Shareholders

 

108

Description of Share Capital

 

109

Shares Eligible for Future Sale

 

119

Material Income Tax Considerations

 

122

Underwriting

 

127

Expenses Related to this Offering

 

132

Legal Matters

 

133

Experts

 

133

Enforceability of Civil Liabilities

 

134

Where You Can Find Additional Information

 

136

Index to Consolidated Financial Statements

 

F-1

We are responsible for the information contained in this prospectus and any free writing prospectus we prepare or authorize. We have not, and the underwriters have not, authorized anyone to provide you with different information, and we and the underwriters take no responsibility for any other information others may give you. We are not, and the underwriters are not, making an offer to sell our Ordinary Shares in any jurisdiction where the offer or sale is not permitted. You should not assume that the information contained in this prospectus is accurate as of any date other than the date on the front cover of this prospectus, regardless of the time of delivery of this prospectus or the sale of any Ordinary Shares.

For investors outside the United States: Neither we nor the underwriters have done anything that would permit this offering or possession or distribution of this prospectus in any jurisdiction, other than the United States, where action for that purpose is required. Persons outside the United States who come into possession of this prospectus must inform themselves about, and observe any restrictions relating to, the offering of the Ordinary Shares and the distribution of this prospectus outside the United States.

CKHL is incorporated under the laws of the Cayman Islands as an exempted company with limited liability and a majority of our outstanding securities are owned by non-U.S. residents. Under the rules of the SEC we currently qualify for treatment as a “foreign private issuer.” As a foreign private issuer, we will not be required to file periodic reports and financial statements with the SEC as frequently or as promptly as domestic registrants whose securities are registered under the Exchange Act.

Until and including            , 2023 (25 days after the date of this prospectus), all dealers that buy, sell or trade our Ordinary Shares, whether or not participating in this offering, may be required to deliver a prospectus. This delivery requirement is in addition to the obligation of dealers to deliver a prospectus when acting as underwriters and with respect to their unsold allotments or subscriptions.

i

Table of Contents

CONVENTIONS THAT APPLY TO THIS PROSPECTUS

Unless otherwise indicated or the context otherwise requires, all references in this prospectus to:

        ‘‘Articles’’ or ‘‘Articles of Association’’ refers to the amended and restated articles of association of our Company (as amended from time to time) adopted on [•] and as amended, supplemented and/or otherwise modified from time to time;

        “BVI” refers to the British Virgin Islands;

        “Chiu & Lee Partners” refers to Chiu & Lee Partners Construction Co., Limited, a company incorporated in Hong Kong with limited liability, an indirect wholly owned subsidiary of CKHL and our key Operating Subsidiary in Hong Kong;

        “Companies Act” refers to the Companies Act (as revised) of the Cayman Islands, as amended, supplemented or otherwise modified from time to time;

        “Company,” “we,” “us,” and “CKHL” refers to Chi Ko Holdings Limited, an exempted Company incorporated in the Cayman Islands with limited liability on March 29, 2022, that will issue the Ordinary Shares being offered;

        “Controlling Shareholder” refers to the ultimate beneficial owner of the Company, who is Mr. Keung Yun Yuen. See “Management” and “Principal Shareholders” for more information;

        “COVID-19” refers to the Coronavirus Disease 2019;

        “Exchange Act” refers to the U.S. Securities Exchange Act of 1934, as amended;

        “HKD” or “HK$” refers to Hong Kong dollar(s), the lawful currency of Hong Kong;

        “Hong Kong” refers to Hong Kong Special Administrative Region of the People’s Republic of China;

        “Independent Third Party” refers to a person or company who or which is independent of and is not a 5% owner of, does not control and is not controlled by or under common control with any 5% owner and is not the spouse or descendant (by birth or adoption) of any 5% owner of the Company;

        “IPO” refers to an initial public offering of securities;

        “mainland China” refers to the PRC (excluding Hong Kong, Macau and Taiwan);

        ‘‘Memorandum’’ or ‘‘Memorandum of Association’’ refers to the amended and restated memorandum of association of our Company (as amended from time to time) adopted on [•] and as amended, supplemented and/or otherwise modified from time to time;

        “Nasdaq” refers to Nasdaq Stock Market LLC;

        “Orange Space” refers to ORANGE SPACE LIMITED, a BVI business company limited by shares incorporated in the BVI, a direct wholly owned subsidiary of CKHL;

        “Ordinary Shares” or “Shares” refer to our ordinary shares, par value $0.0001 per ordinary share;

        “PCAOB” refers to Public Company Accounting Oversight Board;

        “PRC” or “China” refers to the People’s Republic of China;

        “PRC government” or “PRC authorities”, or variations of such words or similar expressions, refer to the central, provincial, and local governments of all levels in mainland China, including regulatory and administrative authorities, agencies and commissions, or any court, tribunal or any other judicial or arbitral body in mainland China;

        “PRC laws” refers to all applicable laws, statutes, rules, regulations, ordinances and other pronouncements having the binding effect of law in mainland China;

ii

Table of Contents

        “SEC” or “Securities and Exchange Commission” means the United States Securities and Exchange Commission;

        “Securities Act” refers to the U.S. Securities Act of 1933, as amended; and

        “U.S. dollars” or “$” or “USD” or “dollars” refers to United States dollar(s), the lawful currency of the United States.

We have made rounding adjustments to some of the figures included in this prospectus. Accordingly, numerical figures shown as totals in some tables may not be an arithmetic aggregation of the figures that preceded them.

Unless the context indicates otherwise, all information in this prospectus assumes no exercise by the underwriters of their over-allotment option.

CKHL is a holding company with operations conducted in Hong Kong through its key Operating Subsidiary in Hong Kong, Chiu & Lee Partners. Chiu & Lee Partners’ reporting currency is Hong Kong dollars. This prospectus contains translations of Hong Kong dollars into U.S. dollars solely for the convenience of the reader. Unless otherwise noted, all translations from Hong Kong dollars to U.S. dollars and from U.S. dollars to Hong Kong dollars in this prospectus were calculated at the rate of US$1 = HK$7.8, representing the noon buying rate in The City of New York for cable transfers of HK$ as certified for customs purposes by the Federal Reserve Bank of New York on the last trading day of March 31, 2022. No representation is made that the HK$ amount represents or could have been, or could be converted, realized or settled into US$ at that rate, or at any other rate.

iii

Table of Contents

PROSPECTUS SUMMARY

The following summary highlights information contained elsewhere in this prospectus and does not contain all of the information you should consider before investing in our Ordinary Shares. You should read the entire prospectus carefully, including “Risk Factors,” “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” and our consolidated financial statements and the related notes thereto, in each case included in this prospectus. You should carefully consider, among other things, the matters discussed in the section of this prospectus titled “Business” before making an investment decision. Unless the context otherwise requires, all references to “CKHL,” “we,” “us,” “our,” the “Company,” and similar designations refer to Chi Ko Holdings Limited, an exempted Cayman Islands company and its wholly owned subsidiaries.

Overview

We are a holding company incorporated in the Cayman Islands with operations conducted by our Hong Kong subsidiary, Chiu & Lee Partners.

We are a one-stop shop construction service provider and established construction contractor in Hong Kong with over 40 years of experience in the construction industry, principally providing (i) foundation and site formation work, which mainly include piling work, excavation and lateral support work and pile cap construction, work; (ii) general building work and associated services, which mainly include development of superstructures, alteration, and addition work; and (iii) other construction work, which mainly includes demolition work. We are able to undertake construction work as either a main contractor or a subcontractor.

Competitive Strengths

We believe the following competitive strengths differentiate us from our competitors:

        Established market presence in the construction industry with over 40 years of operating history;

        Possess a range of qualifications to undertake a range of construction projects;

        Strong and stable network of subcontractors and suppliers;

        Stable relationships with our customers; and

        Experienced and professional management team.

Our Strategies

We intend to pursue the following strategies to further expand our business:

        Adhere to our one-stop shop strategy and prudent financial management;

        Compete for sizeable and profitable construction projects;

        Grow through selected strategic acquisition for machinery and robotics;

        Enhance our participation in undertaking construction works from both the private sector and the public sector; and

        Further enhance our project management capability.

Corporate History and Structure

We are a company principally engaged in construction work in Hong Kong. We have obtained the relevant registration for our business operations via our key Operating Subsidiary, Chiu & Lee Partners, as a general building contractor from the Buildings Department of Hong Kong since 1999 and as a specialist contractor in the demolition work category, foundation work category, and site formation work category from the Buildings Department of Hong Kong since 2006. As of the date of this prospectus, our Controlling Shareholder owns 90.2% of our issued share capital.

In February 2022, Orange Space Limited was incorporated under the laws of the British Virgin Islands, as an intermediate holding company.

1

Table of Contents

In March 2022, CKHL was incorporated under the laws of the Cayman Islands as an exempted company with limited liability, as the holding company of our BVI and Hong Kong subsidiaries.

In April 2022, as part of the reorganization, CKHL acquired, through Orange Space, all the shares of Chiu & Lee Partners from the Controlling Shareholder and became the ultimate holding company of Orange Space and Chiu & Lee Partners. On May 4, 2022, CKHL issued 11,249,999 Ordinary Shares to the Controlling Shareholder. On May 4, 2022, the Controlling Shareholder sold 551,250 Ordinary Shares each to Mr. Ling Chi Fai and Mr. Wong Chi Wai, respectively. Mr. Ling Chi Fai and Mr. Wong Chi Wai are individuals that have no affiliation with CKHL and its subsidiaries.

The chart below illustrates our corporate structure and subsidiaries as of the date of this prospectus and upon completion of this offering (assuming the underwriters do not exercise the over-allotment option):

We are offering 1,740,000 Ordinary Shares, representing 13.4% of the Ordinary Shares following completion of the offering of CKHL, assuming the underwriters do not exercise the over-allotment option.

We will be a “controlled company” as defined under the Nasdaq Stock Market Rules because, immediately after the completion of this offering, our Controlling Shareholder will own 78.1% of our total issued and outstanding Shares, representing 78.1% of the total voting power, assuming that the underwriters do not exercise their over-allotment option.

Holding Company Structure

CKHL is a holding company incorporated in the Cayman Islands with no material operations of its own, and we conduct our operations primarily in Hong Kong through our key Operating Subsidiary Chiu & Lee Partners. This is an offering of the Ordinary Shares of CKHL, the holding company in the Cayman Islands, instead of the shares of the Operating Subsidiary. Investors in this offering will not directly hold any equity interests in the Operating Subsidiary.

As a result of our corporate structure, CKHL’s ability to pay dividends may depend upon dividends paid by our Operating Subsidiary. If our existing Operating Subsidiary or any newly formed ones incur debt on their own behalf in the future, the instruments governing their debt may restrict their ability to pay dividends to us.

2

Table of Contents

Transfers of Cash To and From Our Subsidiaries

Our management monitors the cash position of our Operating Subsidiary regularly and prepares budgets on a monthly basis to ensure it has the necessary funds to fulfill its obligations for the foreseeable future and to ensure adequate liquidity. In the event that there is a need for cash or a potential liquidity issue, it will be reported to our Chief Financial Officer and subject to approval by our board of directors.

No regulatory approval is required for CKHL to transfer cash to its subsidiaries is subject to the following: CKHL is permitted under the laws of the Cayman Islands and its memorandum and articles of association (as amended from time to time) to provide funding to our subsidiaries incorporated in the BVI and Hong Kong through loans or capital contributions. CKHL’s subsidiary formed under the laws of the BVI is permitted under the laws of the BVI to provide funding to our Hong Kong Operating Subsidiary Chiu & Lee Partners subject to certain restrictions laid down in the BVI Business Companies Act 2004 (as amended) and memorandum and articles of association of the relevant CKHL’s subsidiary incorporated under the laws of the BVI.

The ability of Orange Space, the direct subsidiary of CKHL, to transfer cash to CKHL is subject to the following: according to the BVI Business Companies Act 2004 (as amended), Orange Space may make dividends distribution to the extent that immediately after the distribution, the value of the company’s assets exceeds its liabilities and that such company is able to pay its debts as they fall due.

The ability of Chiu & Lee Partners to transfer cash to Orange Space is subject to the following: according to the Companies Ordinance of Hong Kong, Chiu & Lee Partners may only make a distribution out of profits available for distribution. Other than the above, we did not adopt or maintain any cash management policies and procedures as of the date of this prospectus.

During the year ended March 31, 2023, Chiu & Lee Partners declared cash dividends in the amount of HK$26,607,539 (approximately US$3,411,223) to its sole shareholder Orange Space Limited, and having received the dividend income, Orange Space Limited declared the same amount of dividend to its shareholder, CKHL and CKHL also declared the same amount of dividend to its shareholders.

For the cash dividend declared for the year ended March 31, 2023 to the shareholders of CKHL, Mr. Wong Chi Wai and Ling Chi Fai amounting to HK$1,303,769.5 (approximately US$167,145) was waived by Mr. Wong Chi Wai and Ling Chi Fai respectively. For the cash dividend declared for the year ended March 31, 2023 to the shareholder of CKHL, Fly Cloud Limited, which is wholly owned by Mr. Keung Yun Yuen and amounting to HK$24,000,000 (approximately US$3,076,923), HK$10,387,048 (approximately US$1,331,673) was offset by the amount due from Mr. Keung Yun Yuen in March 2023 and the remaining HK$13,612,952 (approximately US$1,745,250) has been settled in April 2023.

During the year ended March 31, 2022, Chiu & Lee Partners declared cash dividends in the amount of HK$12,000,000 (approximately US$1,538,462) to the then direct shareholder, Mr. Keung Yun Yuen. For the cash dividend declared for the year ended March 31, 2022, HK$10,704,314 (approximately US$,1372,348) was offset by the amount due from Mr. Keung Yun Yuen in February 2022 and HK$1,295,681 (approximately US$166,113) was offset from Mr. Keung Yun Yuen in May 2022.

Save as disclosed above, during the years ended March 31, 2023 and 2022, CKHL did not declare or pay any dividends and there was no transfer of assets among CKHL and its subsidiaries.

If we determine to pay dividends on any of our Ordinary Shares in the future, as a holding company, we will be dependent on receipt of funds from our subsidiaries by way of dividend payments. CKHL is permitted under the laws of Cayman Islands and its memorandum and articles of association (as amended from time to time) to provide funding to its subsidiaries through loans or capital contributions. Chiu & Lee Partners is permitted under the laws of Hong Kong to provide funding to CKHL through dividend distributions without restrictions on the amount of the funds distributed.

We currently intend to retain all available funds and future earnings, if any, for the operation and expansion of our business and do not anticipate declaring or paying any dividends in the foreseeable future. Any future determination related to our dividend policy will be made at the discretion of our board of directors after considering our financial condition, results of operations, capital requirements, contractual requirements, business prospects and other factors the board of directors deems relevant, and subject to the restrictions contained in any future financing instruments.

3

Table of Contents

There are no statutory prohibitions in the Cayman Islands on the granting of financial assistance by a company to another person for the purchase of, or subscription for, its own, its holding company’s or a subsidiary’s shares. Therefore, a company may provide financial assistance provided the directors of the company, when proposing to grant such financial assistance, discharge their duties of care and act in good faith, for a proper purpose and in the interests of the company. Such assistance should be on an arm’s-length basis. Subject to the Companies Act and our Memorandum and Articles of Association, our Company in general meeting may declare dividends in any currency to be paid to the members but no dividend shall be declared in excess of the amount recommended by our board of directors. Subject to a solvency test, as prescribed in the Companies Act, and the provisions, if any, of the company’s memorandum and articles of association, a company may pay dividends and distributions out of its share premium account. In addition, based upon English case law that is likely to be persuasive in the Cayman Islands, dividends may be paid out of profits. The Cayman Islands does not impose a withholding tax on payments of dividends to shareholders in the Cayman Islands.

Under Hong Kong law, dividends could only be paid out of distributable profits (that is, accumulated realized profits less accumulated realized losses) or other distributable reserves, as permitted under Hong Kong law. Dividends cannot be paid out of share capital. There are no restrictions or limitation under the laws of Hong Kong imposed on the conversion of HK dollar into foreign currencies and the remittance of currencies out of Hong Kong, nor there is any restriction on foreign exchange to transfer cash between CKHL and its subsidiaries, across borders and to U.S. investors, nor there is any restrictions and limitations to distribute earnings from our business and subsidiaries, to CKHL and U.S. investors and amounts owed. Under the current practice of the Inland Revenue Department of Hong Kong, no tax is payable in Hong Kong in respect to dividends paid by us.

See “Dividend Policy” and “Risk Factors — We rely on dividends and other distributions on equity paid by our subsidiaries to fund any cash and financing requirements we may have, and any limitation on the ability of our subsidiaries to make payments to us could have a material adverse effect on our ability to conduct our business,” and Consolidated Statements of Change in Shareholders’ Equity in the audited financial statements contained in this prospectus for more information.

Enforceability of Civil Liabilities

We are incorporated under the laws of the Cayman Islands as an exempted company with limited liability. Substantially all of our assets are located outside the United States. In addition, all of our directors and officers are nationals or residents of jurisdictions other than the United States and all or a substantial portion of their assets are located outside the United States. As a result, it may be difficult for investors to effect service of process within the United States upon us or these persons or to enforce judgments obtained in U.S. courts against us or them, including judgments predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States. It may also be difficult for you to enforce judgments obtained in U.S. courts based on the civil liability provisions of the U.S. federal securities laws against us and our officers and directors.

We have appointed Cogency Global Inc. as our agent upon whom process may be served in any action brought against us under the securities laws of the United States.

Appleby, our counsel as to the laws of the Cayman Islands has advised us that there is uncertainty as to whether the courts of the Cayman Islands would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in the Cayman Islands against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States.

Appleby has informed us that any final and conclusive judgment for a definite sum (not being a sum payable in respect of taxes or other charges of a like nature nor a fine or other penalty) and/or certain non-monetary judgments rendered in any action or proceedings brought against our Company in a foreign court (other than certain judgments of a superior court of certain states of the Commonwealth of Australia) will be recognized as a valid judgment by the courts of the Cayman Islands without re-examination of the merits of the case. On general principles, we would expect such proceedings to be successful provided that the court which gave the judgment was competent to hear the action in accordance with private international law principles as applied in the Cayman Islands and the judgment is not contrary to public policy in the Cayman Islands, has not been obtained by fraud or in proceedings contrary to natural justice.

4

Table of Contents

Substantially all of our assets are located outside the United States. In addition, a majority of our directors and officers are nationals or residents of jurisdictions other than the United States and all or a substantial portion of their assets are located outside the United States. As a result, it may be difficult for investors to effect service of process within the United States upon us or these persons.

Name

 

Position

 

Nationality

 

Residence

Mr. Keung Yun Yuen

 

Chairman of the board

 

Chinese

 

Hong Kong

Mr. Chan Lee Chuen

 

Director and Chief Executive Officer

 

Chinese

 

Hong Kong

Ms. Choi Hiu Ying

 

Chief Financial Officer

 

Chinese

 

Hong Kong

Mr. Thirupathi Nachiappan

 

Independent Director Appointee

 

Indian

 

Hong Kong

Mr. Wong Heung Ming

 

Independent Director Appointee

 

Chinese

 

Hong Kong

Dr. Liu Yuk Shing

 

Independent Director Appointee

 

Chinese

 

Hong Kong

Mr. Ng Wai Leung

 

Quality Surveyor Manager

 

Chinese

 

Hong Kong

CFN Lawyers, our counsel as to the laws of Hong Kong, has advised us that there is uncertainty as to whether the courts of Hong Kong would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in Hong Kong against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States.

A judgment of a court in the United States predicated upon U.S. federal or state securities laws may be enforced in Hong Kong at common law by bringing an action in a Hong Kong court on that judgment for the amount due thereunder, and then seeking summary judgment on the strength of the foreign judgment, provided that the foreign judgment, among other things, is (1) for a debt or a definite sum of money (not being taxes or similar charges to a foreign government taxing authority or a fine or other penalty), and (2) final and conclusive on the merits of the claim, but not otherwise. Such a judgment may not, in any event, be so enforced in Hong Kong if (a) it was obtained by fraud, (b) the proceedings in which the judgment was obtained were opposed to natural justice, (c) its enforcement or recognition would be contrary to the public policy of Hong Kong, (d) the court of the United States was not jurisdictionally competent, or (e) the judgment was in conflict with a prior Hong Kong judgment.

Hong Kong has no arrangement for the reciprocal enforcement of judgments with the United States. As a result, there is uncertainty as to the enforceability in Hong Kong, in original actions or in actions for enforcement, of judgments of U.S. courts of civil liabilities predicated solely upon the federal securities laws of the United States or the securities laws of any state or territory within the United States.

Summary of Key Risks

Our business is subject to a number of risks, including risks that may prevent us from achieving our business objectives or may materially and adversely affect our business, financial condition, results of operations, cash flows, and prospects that you should consider before making a decision to invest in our Ordinary Shares. These risks are discussed more fully in “Risk Factors.”

Risks Relating to Doing Business in Hong Kong

        Our key operations are in Hong Kong, a Special Administrative Region of the PRC. According to the long-arm provisions under the current PRC laws and regulations, the PRC government may exercise significant oversight and discretion over the conduct of our business and may intervene in or influence our operations at any time, which could result in a material change in our operations and/or the value of our Ordinary Shares. The PRC government may intervene or impose restrictions on our ability to move money out of Hong Kong to distribute earnings and pay dividends or to reinvest in our business outside of Hong Kong. Changes in the policies, regulations, rules, and the enforcement of laws of the PRC government may also be quick with little advance notice and our assertions and beliefs of the risk imposed by the PRC legal and regulatory system cannot be certain. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — Our key operations are in Hong Kong, a Special Administrative Region of the PRC. According to the long-arm provisions under the current PRC laws and regulations, the PRC government may exercise significant oversight and discretion over the conduct of our business and may intervene in or influence our operations at any time, which could result in a material change in our operations and/or the value of

5

Table of Contents

our Ordinary Shares. Changes in the policies, regulations, rules, and the enforcement of laws of the PRC government may also be quick with little advance notice and our assertions and beliefs of the risk imposed by the PRC legal and regulatory system cannot be certain” on page 22 of this prospectus.

        There are uncertainties regarding the interpretation and enforcement of PRC and Hong Kong laws, rules, and regulations. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — There are uncertainties regarding the interpretation and enforcement of PRC and Hong Kong laws, rules, and regulations” on page 23 of this prospectus.

        If the PRC government chooses to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers, such action may significantly limit or completely hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — If the PRC government chooses to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers, such action may significantly limit or completely hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless on page 23 of this prospectus.

        Adverse regulatory developments in China may subject us to additional regulatory review, and additional disclosure requirements and regulatory scrutiny to be adopted by the SEC in response to risks related to recent regulatory developments in China may impose additional compliance requirements for companies like us with Hong Kong-based operations, all of which could increase our compliance costs and subject us to additional disclosure requirements. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — Adverse regulatory developments in China may subject us to additional regulatory review, and additional disclosure requirements and regulatory scrutiny to be adopted by the SEC in response to risks related to recent regulatory developments in China may impose additional compliance requirements for companies like us with Hong Kong-based operations, all of which could increase our compliance costs and subject us to additional disclosure requirements” on page 25 of this prospectus.

        We may become subject to a variety of PRC laws and other obligations regarding data security offerings that are conducted overseas and/or foreign investment in China-based issuers, and any failure to comply with applicable laws and obligations could have a material and adverse effect on our business, financial condition and results of operations and may hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — We may become subject to a variety of PRC laws and other obligations regarding data security offerings that are conducted overseas and/or foreign investment in China-based issuers, and any failure to comply with applicable laws and obligations could have a material and adverse effect on our business, financial condition and results of operations and may hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless” on page 25 of this prospectus.

        Although the audit report included in this prospectus is prepared by U.S. auditors who are currently inspected by the PCAOB, there is no guarantee that future audit reports will be issued by auditors inspected by the PCAOB, and, as such, in the future, investors may be deprived of the benefits of such inspection. Furthermore, trading in our Ordinary Shares may be prohibited under the HFCA Act if the SEC subsequently determines our audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely, and as a result, U.S. national securities exchanges, such as the Nasdaq, may determine to delist our securities. Furthermore, on December 29, 2022 the Accelerating Holding Foreign Companies Accountable Act was enacted, which amended the HFCA Act by requiring the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three, and thus, reduced the time before our Ordinary Shares may be prohibited from trading or delisted. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — Although the audit report included in this prospectus is prepared by U.S. auditors who are currently inspected by the PCAOB, there is no guarantee that future audit reports will be issued by auditors inspected by the PCAOB, and, as such, in the future, investors may be deprived of the benefits of such inspection. Furthermore, trading in our Ordinary Shares may be prohibited under the HFCA Act if the SEC subsequently determines our audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely, and as a result, U.S. national securities exchanges, such as the Nasdaq, may determine to delist our securities. Furthermore, on December 29, 2022 the Accelerating Holding Foreign Companies Accountable Act was

6

Table of Contents

enacted, which amended the HFCA Act by requiring the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three, and thus, reduced the time before our Ordinary Shares may be prohibited from trading or delisted” on page 27 of this prospectus.

        The recent joint statement by the SEC, proposed rule changes submitted by Nasdaq, and an act passed by the U.S. Senate and the U.S. House of Representatives all call for additional and more stringent criteria to be applied to emerging market companies. These developments could add uncertainties to our offering, business operations, share price, and reputation. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — The recent joint statement by the SEC, proposed rule changes submitted by Nasdaq, and an act passed by the U.S. Senate and the U.S. House of Representatives all call for additional and more stringent criteria to be applied to emerging market companies. These developments could add uncertainties to our offering, business operations, share price, and reputation” on page 29 of this prospectus.

        The enactment of Law of the PRC on Safeguarding National Security in the Hong Kong Special Administrative Region could impact our Hong Kong subsidiary. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — The enactment of Law of the PRC on Safeguarding National Security in the Hong Kong Special Administrative Region could impact our Hong Kong subsidiary” on page 30 of this prospectus.

        If we become subject to the recent scrutiny, criticism, and negative publicity involving U.S.-listed China-based companies, we may have to expend significant resources to investigate and/or defend the matter, which could harm our business operations, this offering, and our reputation and could result in a loss of your investment in our Ordinary Shares, in particular if such matter cannot be addressed and resolved favorably. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — If we become subject to the recent scrutiny, criticism, and negative publicity involving U.S.-listed China-based companies, we may have to expend significant resources to investigate and/or defend the matter, which could harm our business operations, this offering, and our reputation and could result in a loss of your investment in our Ordinary Shares, in particular if such matter cannot be addressed and resolved favorably” on page 30 of this prospectus.

        A downturn in Hong Kong, mainland China, or global economy, or a change in economic and political policies of China, could materially and adversely affect our business and financial condition. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — A downturn in the Hong Kong, China, or global economy, or a change in economic and political policies of China, could materially and adversely affect our business and financial condition” on page 31 of this prospectus.

        Because our business is conducted in Hong Kong dollars and the price of our Ordinary Shares is quoted in U.S. dollars, changes in currency conversion rates may affect the value of your investments. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — Because our business is conducted in Hong Kong dollars and the price of our Ordinary Shares is quoted in U.S. dollars, changes in currency conversion rates may affect the value of your investments” on page 31 of this prospectus.

        There are political risks associated with conducting business in Hong Kong. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — There are political risks associated with conducting business in Hong Kong” on page 31 of this prospectus.

        The Hong Kong legal system embodies uncertainties that could limit the availability of legal protections. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — The Hong Kong legal system embodies uncertainties that could limit the availability of legal protections” on page 32 of this prospectus.

        You may experience difficulties in effecting service of legal process, enforcing foreign judgments or bringing actions in Hong Kong against us or our management named in this prospectus based on Hong Kong laws. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — You may experience difficulties in effecting service of legal process, enforcing foreign judgments or bringing actions in Hong Kong against us or our management named in this prospectus based on Hong Kong laws” on page 32 of this prospectus.

        Changes in international trade policies, trade disputes, barriers to trade, or the emergence of a trade war may dampen growth in Hong Kong, where the majority of our clients reside. See “Risk Factors — Risks Relating to Doing Business in Hong Kong — Changes in international trade policies, trade disputes, barriers to trade, or the emergence of a trade war may dampen growth in Hong Kong, where the majority of our clients reside” on page 33 of this prospectus.

7

Table of Contents

Risks Related to Our Business and Industry

        If we are unable to accurately estimate the overall risks, revenues, or costs on our projects, we may incur contract losses or achieve lower than anticipated profits. See “Risk Factors — Risks Related to Our Business and Industry — If we are unable to accurately estimate the overall risks, revenues, or costs on our projects, we may incur contract losses or achieve lower than anticipated profits” on page 33 of this prospectus.

        We may be unable to obtain or maintain sufficient bonding capacity, which could materially adversely affect our business. See “Risk Factors — Risks Related to Our Business and Industry — We may be unable to obtain or maintain sufficient bonding capacity, which could materially adversely affect our business” on page 34 of this prospectus.

        Design-build contracts subject us to the risk of design errors and omissions. See “Risk Factors — Risks Related to Our Business and Industry — Design-build contracts subject us to the risk of design errors and omissions” on page 34 of this prospectus.

        We depend on third parties for equipment and supplies essential to operate our business. See “Risk Factors — Risks Related to Our Business and Industry — We depend on third parties for equipment and supplies essential to operate our business” on page 34 of this prospectus.

        The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability. See “Risk Factors — Risks Related to Our Business and Industry — The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability” on page 34 of this prospectus.

        Failure to maintain safe work sites could result in significant losses, which could materially affect our business and reputation. See “Risk Factors — Risks Related to Our Business and Industry — Failure to maintain safe work sites could result in significant losses, which could materially affect our business and reputation” on page 34 of this prospectus.

        Our revenue mainly relies on successful tenders or acceptance of our quotations for construction projects which are non-recurring in nature and any failure in securing projects from our existing customers and/or new customers in the future would affect our business operation and financial results. See “Risk Factors — Risks Related to Our Business and Industry — Our revenue mainly relies on successful tenders or acceptance of our quotations for construction projects which are non-recurring in nature and any failure in securing projects from our existing customers and/or new customers in the future would affect our business operation and financial results” on page 35 of this prospectus.

        A significant portion of our revenue was generated from contracts awarded by a limited number of customers and any significant decrease in the number of projects with our major customers and any significant decrease in the number of projects with our major customers may materially and adversely affect our financial condition and operating results. See “Risk Factors — Risks Related to Our Business and Industry — A significant portion of our revenue was generated from contracts awarded by a limited number of customers and any significant decrease in the number of projects with our major customers and any significant decrease in the number of projects with our major customers may materially and adversely affect our financial condition and operating results” on page 35 of this prospectus.

        We may not be able to bill and receive the full amount of gross amounts due from customers for contract work and our revenue may fluctuate due to variation orders. See “Risk Factors — Risks Related to Our Business and Industry — We may not be able to bill and receive the full amount of gross amounts due from customers for contract work and our revenue may fluctuate due to variation orders” on page 35 of this prospectus.

        We rely on our subcontractors to help complete our projects and to supply the machinery required. See “Risk Factors — Risks Related to Our Business and Industry — We rely on our subcontractors to help complete our projects and to supply the machinery required” on page 35 of this prospectus.

8

Table of Contents

        As we from time to time engage subcontractors in our work, we may bear responsibilities for any non-performance, delayed performance, sub-standard performance, or non-compliance of our subcontractors. See “Risk Factors — Risks Related to Our Business and Industry — As we from time to time engage subcontractors in our work, we may bear responsibilities for any non-performance, delayed performance, sub-standard performance, or non-compliance of our subcontractors” on page 36 of this prospectus.

        There is no guarantee that safety measures and procedures implemented at our construction sites could prevent the occurrence of industrial accidents of all kinds, which in turn might lead to claims in respect to employees’ compensation, personal injuries, fatal accidents, and/or property damages against us. See “Risk Factors — Risks Related to Our Business and Industry — There is no guarantee that safety measures and procedures implemented at our construction sites could prevent the occurrence of industrial accidents of all kinds, which in turn might lead to claims in respect to employees’ compensation, personal injuries, fatal accidents, and/or property damages against us” on page 36 of this prospectus.

        We determine the price of our quotation or tender based on the estimated time and costs to be involved in a project and the actual time and costs incurred may deviate from our estimate due to unexpected circumstances, thereby leading to cost overruns and adversely affecting our operations and financial results. See “Risk Factors — Risks Related to Our Business and Industry — We determine the price of our quotation or tender based on the estimated time and costs to be involved in a project and the actual time and costs incurred may deviate from our estimate due to unexpected circumstances, thereby leading to cost overruns and adversely affecting our operations and financial results” on page 37 of this prospectus.

        The geological conditions of construction sites are difficult to anticipate and may result in higher project expenses. See “Risk Factors — Risks Related to Our Business and Industry — The geological conditions of construction sites are difficult to anticipate and may result in higher project expenses” on page 37 of this prospectus.

        There is no assurance that we can maintain the qualifications, licenses, and registrations for the operation of our construction business. See “Risk Factors — Risks Related to Our Business and Industry — There is no assurance that we can maintain the qualifications, licenses, and registrations for the operation of our construction business” on page 37 of this prospectus.

        We rely on the service of our authorized signatory(ies) (“Authorized Signatory”) and Technical Director for our registrations maintained with the Buildings Department of Hong Kong. See “Risk Factors — Risks Related to Our Business and Industry — We rely on the service of our authorized signatory(ies) (“Authorized Signatory”) and Technical Director for our registrations maintained with the Buildings Department of Hong Kong” on page 37 of this prospectus.

        Cash inflows and outflows in connection with construction projects may be irregular thus may affect our net cash flow position. See “Risk Factors — Risks Related to Our Business and Industry — Cash inflows and outflows in connection with construction projects may be irregular thus may affect our net cash flow position” on page 38 of this prospectus.

        We may be liable for damage caused to underground service utilities and infrastructures and/or foundation of aged building adjacent to the construction sites where we carry out our construction projects. See “Risk Factors — Risks Related to Our Business and Industry — We may be liable for damage caused to underground service utilities and infrastructures and/or foundation of aged building adjacent to the construction sites where we carry out our construction projects” on page 38 of this prospectus.

        Claims in connection with employees’ compensation or personal injuries may arise and affect our reputation and operations. See “Risk Factors — Risks Related to Our Business and Industry — Claims in connection with employees’ compensation or personal injuries may arise and affect our reputation and operations” on page 38 of this prospectus.

        We face keen competition from other players in the market. See “Risk Factors — Risks Related to Our Business and Industry — We face keen competition from other players in the market” on page 39 of this prospectus.

9

Table of Contents

        Any deterioration in the prevailing market conditions in the construction industry may adversely affect our performance and financial condition. See “Risk Factors — Risks Related to Our Business and Industry — Any deterioration in the prevailing market conditions in the construction industry may adversely affect our performance and financial condition” on page 39 of this prospectus.

        We are dependent on our key executives, management team and professional staff. See “Risk Factors — Risks Related to Our Business and Industry — We are dependent on our key executives, management team and professional staff” on page 39 of this prospectus.

        We may be unable to obtain sufficient funding on terms acceptable to us, or at all. See “Risk Factors — Risks Related to Our Business and Industry — We may be unable to obtain sufficient funding on terms acceptable to us, or at all” on page 39 of this prospectus.

        Our insurance coverage may be inadequate to protect us from potential losses. See “Risk Factors — Risks Related to Our Business and Industry — Our insurance coverage may be inadequate to protect us from potential losses” on page 39 of this prospectus.

        We may be subject to litigation, arbitration, or other legal proceeding risk. See “Risk Factors — Risks Related to Our Business and Industry — We may be subject to litigation, arbitration, or other legal proceeding risk” on page 40 of this prospectus.

        We rely on our customer and subcontractor for the provision of machinery and equipment at construction sites. See “Risk Factors — Risks Related to Our Business and Industry — We rely on our customer and subcontractor for the provision of machinery and equipment at construction sites” on page 40 of this prospectus.

        We rely on a stable workforce to carry out our construction projects. If we or our subcontractors experience any shortage of labor, industrial actions, strikes, or material increase in labor costs, our operations and financial results would be adversely affected. See “Risk Factors — Risks Related to Our Business and Industry — We rely on a stable workforce to carry out our construction projects. If we or our subcontractors experience any shortage of labor, industrial actions, strikes, or material increase in labor costs, our operations and financial results would be adversely affected” on page 40 of this prospectus.

        We may be unable to successfully implement our future business plans and objectives. See “Risk Factors — Risks Related to Our Business and Industry — We may be unable to successfully implement our future business plans and objectives” on page 40 of this prospectus.

        A sustained outbreak of the COVID-19 pandemic could have a material adverse impact on our business, operating results, and financial condition. See “Risk Factors — Risks Related to Our Business and Industry — A sustained outbreak of the COVID-19 pandemic could have a material adverse impact on our business, operating results, and financial condition” on page 41 of this prospectus.

        A severe or prolonged downturn in the global economy could materially and adversely affect our business and results of operations. See “Risk Factors — Risks Related to Our Business and Industry — A severe or prolonged downturn in the global economy could materially and adversely affect our business and results of operations” on page 41 of this prospectus.

Risks Related to Our Ordinary Shares

        There has been no public market for our Ordinary Shares prior to this offering; if an active trading market does not develop you may not be able to resell our Shares at any reasonable price. See “Risk Factors — Risks Related to Our Ordinary Shares — There has been no public market for our Ordinary Shares prior to this offering; if an active trading market does not develop you may not be able to resell our Shares at any reasonable price” on page 42 of this prospectus.

        The trading price of our Ordinary Shares may be volatile, which could result in substantial losses to you. See “Risk Factors — Risks Related to Our Ordinary Shares — The trading price of our Ordinary Shares may be volatile, which could result in substantial losses to you” on page 42 of this prospectus.

10

Table of Contents

        We rely on dividends and other distributions on equity paid by our subsidiaries to fund our cash and financing requirements we may have, and any limitation on the ability of our subsidiaries to make payments to us could have a material adverse effect on our ability to conduct our business. See “Risk Factors — Risks Related to Our Ordinary Shares — We rely on dividends and other distributions on equity paid by our subsidiaries to fund our cash and financing requirements we may have, and any limitation on the ability of our subsidiaries to make payments to us could have a material adverse effect on our ability to conduct our business” on page 43 of this prospectus.

        Our lack of effective internal controls over financial reporting may affect our ability to accurately report our financial results or prevent fraud, which may affect the market for and the price of our Ordinary Shares. See “Risk Factors — Risks Related to Our Ordinary Shares — Our lack of effective internal controls over financial reporting may affect our ability to accurately report our financial results or prevent fraud, which may affect the market for and the price of our Ordinary Shares” on page 44 of this prospectus.

        Our Ordinary Shares are expected to initially trade under $5.00 per share and thus would be known as a “penny stock.” Trading in penny stocks has certain restrictions and these restrictions could negatively affect the price and liquidity of our Ordinary Shares. See “Risk Factors — Risks Related to Our Ordinary Shares — Our Ordinary Shares are expected to initially trade under $5.00 per share and thus would be known as a “penny stock.” Trading in penny stocks has certain restrictions and these restrictions could negatively affect the price and liquidity of our Ordinary Shares” on page 44 of this prospectus.

        If we fail to meet applicable listing requirements, Nasdaq may delist our Ordinary Shares from trading, in which case the liquidity and market price of our Ordinary Shares could decline. See “Risk Factors — Risks Related to Our Ordinary Shares — If we fail to meet applicable listing requirements, Nasdaq may delist our Ordinary Shares from trading, in which case the liquidity and market price of our Ordinary Shares could decline” on page 44 of this prospectus.

        If you purchase our Ordinary Shares in this offering, you will incur immediate and substantial dilution in the book value of your Shares. See “Risk Factors — Risks Related to Our Ordinary Shares — If you purchase our Ordinary Shares in this offering, you will incur immediate and substantial dilution in the book value of your Shares” on page 45 of this prospectus.

        If a limited number of participants in this offering purchase a significant percentage of the offering, the effective public float may be smaller than anticipated and the price of our Ordinary Shares may be more volatile than it otherwise would be. See “Risk Factors — Risks Related to Our Ordinary Shares — If a limited number of participants in this offering purchase a significant percentage of the offering, the effective public float may be smaller than anticipated and the price of our Ordinary Shares may be more volatile than it otherwise would be” on page 45 of this prospectus.

        Our directors, officers, and principal shareholders have significant voting power and may take actions that may not be in the best interests of our other shareholders. See “Risk Factors — Risks Related to Our Ordinary Shares — Our directors, officers, and principal shareholders have significant voting power and may take actions that may not be in the best interests of our other shareholders” on page 45 of this prospectus.

        Our board of directors may decline to register the transfer of Ordinary Shares in certain circumstances. See “Risk Factors — Risks Related to Our Ordinary Shares — Our board of directors may decline to register the transfer of Ordinary Shares in certain circumstances” on page 46 of this prospectus.

11

Table of Contents

        Because the amount, timing, and whether or not we distribute dividends at all is entirely at the discretion of our board of directors, you must rely on price appreciation of our Ordinary Shares for return on your investment. See “Risk Factors — Risks Related to Our Ordinary Shares — Because the amount, timing, and whether or not we distribute dividends at all is entirely at the discretion of our board of directors, you must rely on price appreciation of our Ordinary Shares for return on your investment” on page 46 of this prospectus.

        Our management has broad discretion to determine how to use the funds raised in the offering and may use them in ways that may not enhance our results of operations or the price of our Ordinary Shares. See “Risk Factors — Risks Related to Our Ordinary Shares — Our management has broad discretion to determine how to use the funds raised in the offering and may use them in ways that may not enhance our results of operations or the price of our Ordinary Shares” on page 47 of this prospectus.

        Our disclosure controls and procedures may not prevent or detect all errors or acts of fraud. See “Risk Factors — Risks Related to Our Ordinary Shares — Our disclosure controls and procedures may not prevent or detect all errors or acts of fraud” on page 47 of this prospectus.

        We do not intend to pay dividends for the foreseeable future. See “Risk Factors — Risks Related to Our Ordinary Shares — We do not intend to pay dividends for the foreseeable future” on page 47 of this prospectus.

        Securities analysts may not publish favorable research or reports about our business or may publish no information at all, which could cause our Ordinary Share price or trading volume to decline. See “Risk Factors — Risks Related to Our Ordinary Shares — Securities analysts may not publish favorable research or reports about our business or may publish no information at all, which could cause our Ordinary Share price or trading volume to decline” on page 47 of this prospectus.

        Certain judgments obtained against us by our shareholders may not be enforceable. See “Risk Factors — Risks Related to Our Ordinary Shares — Certain judgments obtained against us by our shareholders may not be enforceable” on page 47 of this prospectus.

        You may have more difficulties protecting your interests than you would as a shareholder of a U.S. corporation. See “Risk Factors — Risks Related to Our Ordinary Shares — You may have more difficulties protecting your interests than you would as a shareholder of a U.S. corporation” on page 48 of this prospectus.

        Cayman Islands economic substance requirements may have an effect on our business and operations. See “Risk Factors — Risks Related to Our Ordinary Shares — Cayman Islands economic substance requirements may have an effect on our business and operations” on page 49 of this prospectus.

        We are a foreign private issuer within the meaning of the rules under the Exchange Act, and, as such, we are exempt from certain provisions applicable to U.S. domestic public companies. See “Risk Factors — Risks Related to Our Ordinary Shares — We are a foreign private issuer within the meaning of the rules under the Exchange Act, and, as such, we are exempt from certain provisions applicable to U.S. domestic public companies” on page 49 of this prospectus.

        As a foreign private issuer, we are permitted to adopt certain home country practices in relation to corporate governance matters that differ significantly from Nasdaq corporate governance listing standards. These practices may afford less protection to shareholders than they would enjoy if we complied fully with Nasdaq corporate governance listing standards. See “Risk Factors — Risks Related to Our Ordinary Shares — As a foreign private issuer, we are permitted to adopt certain home country practices in relation to corporate governance matters that differ significantly from Nasdaq corporate governance listing standards. These practices may afford less protection to shareholders than they would enjoy if we complied fully with Nasdaq corporate governance listing standards” on page 49 of this prospectus.

12

Table of Contents

        We may lose our foreign private issuer status in the future, which could result in significant additional costs and expenses. See “Risk Factors — Risks Related to Our Ordinary Shares — We may lose our foreign private issuer status in the future, which could result in significant additional costs and expenses” on page 49 of this prospectus.

        There can be no assurance that we will not be a passive foreign investment company (“PFIC”), for U.S. federal income tax purposes for any taxable year, which could result in adverse U.S. federal income tax consequences to U.S. holders of our Ordinary Shares. See “Risk Factors — Risks Related to Our Ordinary Shares — There can be no assurance that we will not be a passive foreign investment company (“PFIC”), for U.S. federal income tax purposes for any taxable year, which could result in adverse U.S. federal income tax consequences to U.S. holders of our Ordinary Shares” on page 50 of this prospectus.

        We are an emerging growth company within the meaning of the Securities Act and may take advantage of certain reduced reporting requirements. See “Risk Factors — Risks Related to Our Ordinary Shares — We are an emerging growth company within the meaning of the Securities Act and may take advantage of certain reduced reporting requirements” on page 50 of this prospectus.

        We will incur increased costs as a result of being a public company, particularly after we cease to qualify as an “emerging growth company.” See “Risk Factors — Risks Related to Our Ordinary Shares — We will incur increased costs as a result of being a public company, particularly after we cease to qualify as an “emerging growth company” on page 50 of this prospectus.

        As a “controlled company” under the rules of the Nasdaq Capital Market, we may choose to exempt our Company from certain corporate governance requirements that could have an adverse effect on our public shareholders. See “Risk Factors — Risks Related to Our Ordinary Shares — As a “controlled company” under the rules of the Nasdaq Capital Market, we may choose to exempt our Company from certain corporate governance requirements that could have an adverse effect on our public shareholders” on page 51 of this prospectus.

Recent Regulatory Developments in the PRC

We are aware that, recently, the PRC government initiated a series of regulatory actions and statements to regulate business operations in certain areas in China with little advance notice, including cracking down on illegal activities in the securities market, enhancing supervision over China-based companies listed overseas using variable interest entity (“VIE”) structure, adopting new measures to extend the scope of cybersecurity reviews, and expanding the efforts in anti-monopoly enforcement. For example, on July 6, 2021, the General Office of the Communist Party of China Central Committee and the General Office of the State Council jointly issued a document to crack down on illegal activities in the securities market and promote the high-quality development of the capital market, which, among other things, requires the relevant governmental authorities to strengthen cross-border oversight of law enforcement and judicial cooperation, to enhance supervision over China-based companies listed overseas, and to establish and improve the system of extraterritorial application of the PRC securities laws. Also, on July 10, 2021, the Cyberspace Administration of China (the “CAC”) issued a revised draft of the Measures for Cybersecurity Review for public comments (the “Revised Draft”), which required that, in addition to “operators of critical information infrastructure,” any “data processor” controlling personal information of no less than one million users that seeks to list in a foreign stock exchange should also be subject to cybersecurity review, and it further elaborated the factors to be considered when assessing the national security risks of the relevant activities.

On December 24, 2021, the CSRC released the Administrative Provisions of the State Council Regarding the Overseas Issuance and Listing of Securities by Domestic Enterprises (Draft for Comments) (the “Draft Administrative Provisions”) and the Measures for the Overseas Issuance of Securities and Listing Record-Filings by Domestic Enterprises (Draft for Comments) (together with the Draft Administrative Provisions, the “Draft Rules Regarding Overseas Listing”). The Draft Rules Regarding Overseas Listing lays out the filing regulation arrangement for both direct and indirect overseas listing and clarifies the determination criteria for indirect overseas listing in overseas markets. Among other things, if a domestic enterprise intends to indirectly offer and list securities in an overseas market, the record-filing obligation is with a major operating entity incorporated in the PRC, and such filing obligation shall be completed within three working days after the overseas listing application is submitted. The required filing materials for an IPO and listing

13

Table of Contents

shall include, but not be limited to: regulatory opinions, record filing, approval, and other documents issued by competent regulatory authorities of relevant industries (if applicable), and security assessment opinions issued by relevant regulatory authorities (if applicable).

On December 27, 2021, the National Development and Reform Commission (“NDRC”) and the Ministry of Commerce jointly issued the Special Administrative Measures for Entry of Foreign Investment (Negative List) (2021 Version) (“Negative List”), which became effective and replaced the previous version. Pursuant to the Negative List, if a PRC company, which engages in any business where foreign investment is prohibited under the Negative List, or prohibited businesses seeks an overseas offering or listing, it must obtain the approval from competent governmental authorities. Based on a set of Q&A published on the NDRC’s official website, a NDRC official indicated that after a PRC company submits its application for overseas listing to the CSRC and where matters relating to prohibited businesses under the Negative List are implicated, the CSRC will consult the regulatory authorities having jurisdiction over the relevant industries and fields. Because the Draft Rules Regarding Overseas Listing are currently in draft form and given the novelty of the Negative List, there remain substantial uncertainties as to whether and what requirements, including filing requirements, will be imposed on a PRC company with respect to its listing and offerings overseas as well as with the interpretation and implementation of existing and future regulations in this regard.

On February 17, 2023, the CSRC issued the Trial Administrative Measures of Overseas Securities Offering and Listing by Domestic Enterprises, or the Trial Measures, which became effective on March 31, 2023. On the same date of the issuance of the Trial Measures, the CSRC circulated No.1 to No.5 Supporting Guidance Rules, the Notes on the Trial Measures, the Notice on Administration Arrangements for the Filing of Overseas Listings by Domestic Enterprises and the relevant CSRC Answers to Reporter Questions on the official website of the CSRC, or collectively, the Guidance Rules and Notice. The Trial Measures, together with the Guidance Rules and Notice, reiterate the basic supervision principles as reflected in the Draft Rules Regarding Overseas Listing by providing substantially the same requirements for filings of overseas offering and listing by domestic companies, yet made the following updates compared to the Draft Rules Regarding Overseas Listing: (a) further clarification of the circumstances prohibiting overseas issuance and listing; (b) further clarification of the standard of indirect overseas listing under the principle of substance over form, and (c) adding more details of filing procedures and requirements by setting different filing requirements for different types of overseas offering and listing. Under the Trial Measures and the Guidance Rules and Notice, domestic companies conducting overseas securities offering and listing activities, either in direct or indirect form, shall complete filing procedures with the CSRC pursuant to the requirements of the Trial Measures within three working days following its submission of initial public offerings or listing application. The companies that have already been listed on overseas stock exchanges or have obtained the approval from overseas supervision administrations or stock exchanges for its offering and listing and will complete their overseas offering and listing prior to September 30, 2023 are not required to make immediate filings for its listing yet need to make filings for subsequent offerings in accordance with the Trial Measures. The companies that have already submitted an application for an initial public offering to overseas supervision administrations prior to the effective date of the Trial Measures but have not yet obtained the approval from overseas supervision administrations or stock exchanges for the offering and listing may arrange for the filing within a reasonable time period and should complete the filing procedure before such companies’ overseas issuance and listing.

On January 4, 2022, the CAC, the NDRC, and several other administrations jointly adopted and published the revised Cybersecurity Review Measures (“CRM”), which took effect on February 15, 2022, and replaced the Revised Draft issued on July 10, 2021. Pursuant to the revised CRM, if a network platform operator holding personal information of over one million users seeks for “foreign” listing, it must apply for the cybersecurity review. In addition, operators of critical information infrastructure purchasing network products and services are also obligated to apply for the cybersecurity review for such purchasing activities. Although the CRM provides no further explanation on the extent of “network platform operator” and “foreign” listing, we do not believe we are obligated to apply for a cybersecurity review pursuant to the revised CRM, considering that (i) we are not in possession of or otherwise holding personal information of over one million users, and it is also very unlikely that we will reach such threshold in the near future; and (ii) as of the date of this prospectus, we have not received any notice or determination from applicable PRC governmental authorities identifying it as a critical information infrastructure operator.

On February 24, 2023, the CSRC, together with Ministry of Finance of the PRC, National Administration of State Secrets Protection and National Archives Administration of China, revised the Provisions on Strengthening Confidentiality and Archives Administration for Overseas Securities Offering and Listing, which were issued by the CSRC, National Administration of State Secrets Protection and National Archives Administration of China in 2009, or

14

Table of Contents

the Provisions. The revised Provisions were issued under the title the “Provisions on Strengthening Confidentiality and Archives Administration of Overseas Securities Offering and Listing by Domestic Companies” and came into effect on March 31, 2023 together with the Trial Measures. One of the major revisions to the revised Provisions is expanding their application to cover indirect overseas offering and listing, as is consistent with the Trial Measures. The revised Provisions require that, including, but not limited to, (a) a domestic company that plans to, either directly or indirectly through its overseas listed entity, publicly disclose or provide to relevant individuals or entities including securities companies, securities service providers and overseas regulators, any documents and materials that contain state secrets or working secrets of government agencies, shall first obtain approval from competent authorities according to law, and file with the secrecy administrative department at the same level; and (b) domestic company that plans to, either directly or indirectly through its overseas listed entity, publicly disclose or provide to relevant individuals and entities including securities companies, securities service providers and overseas regulators, any other documents and materials that, if leaked, will be detrimental to national security or public interest, shall strictly fulfil relevant procedures stipulated by applicable national regulations.

Our Operating Subsidiary may collect and store certain data from our clients in Hong Kong, in connection with our business and operations. Given that (1) our Operating Subsidiary is incorporated and located in Hong Kong; (2) we have no subsidiary, VIE structure, nor any direct operations in mainland China; and (3) pursuant to the Basic Law, which is a national law of the PRC and the constitutional document for Hong Kong, national laws of the PRC shall not be applied in Hong Kong except for those listed in Annex III of the Basic Law (which is confined to laws relating to defense and foreign affairs, as well as other matters outside the autonomy of Hong Kong), and we do not currently expect the Measures for Cybersecurity Review (2021), the PRC Personal Information Protection Law, the Trial Measures and the revised Provisions to have an impact on our business, operations, or this offering, as we do not believe that our Operating Subsidiary is deemed to be an “Operator” that is required to file for cybersecurity review before listing in the United States because (i) our Operating Subsidiary is incorporated in Hong Kong and operates in Hong Kong without any subsidiary or VIE structure in mainland China, and each of the Measures for Cybersecurity Review (2021), the PRC Personal Information Protection Law, the Trial Measures and the revised Provisions remain unclear whether it shall be applied to a company based in Hong Kong; (ii) as of date of this prospectus, our Operating Subsidiary has neither collected nor stored any personal information of PRC individuals; (iii) all of the data our Operating Subsidiary has collected is stored in servers located in Hong Kong; and (iv) as of the date of this prospectus, our Operating Subsidiary has not been informed by any PRC governmental authority of any requirement that it file for a cybersecurity review or a CSRC review.

Since these statements and regulatory actions are new, it is highly uncertain how soon the legislative or administrative regulation making bodies will respond or what existing or new laws or regulations or detailed implementations and interpretations will be modified or promulgated, if any. It is also highly uncertain what the potential impact such modified or new laws and regulations will have on CKHL’s daily business operations, its ability to accept foreign investments, and the listing of our Ordinary Shares on a U.S. or other foreign exchange. There remains significant uncertainty in the interpretation and enforcement of relevant PRC cybersecurity laws and regulations. If the Trial Measures are adopted into law in the future and become applicable to our Operating Subsidiary, if our Operating Subsidiary is deemed to be an “Operator,” or if the Measures for Cybersecurity Review (2021) or the PRC Personal Information Protection Law becomes applicable to our Operating Subsidiary, the business operation of our Operating Subsidiary and the listing of our Ordinary Shares in the United States could be subject to the CAC’s cybersecurity review or CSRC Overseas Issuance and Listing review in the future. If the applicable laws, regulations, or interpretations change and our Operating Subsidiary becomes subject to the CAC or CSRC review, we cannot assure you that our Operating Subsidiary will be able to comply with the regulatory requirements in all respects, and our current practice of collecting and processing personal information may be ordered to be rectified or terminated by regulatory authorities. If our Operating Subsidiary fails to receive or maintain such permissions or if the required approvals are denied, our Operating Subsidiary may become subject to fines and other penalties that may have a material adverse effect on our business, operations, and financial condition and may hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless.

Additionally, due to long-arm provisions under the current PRC laws and regulations, there remains regulatory uncertainty with respect to the implementation and interpretation of laws in China. We are also subject to the risks of uncertainty about any future actions the PRC government or authorities in Hong Kong may take in this regard.

15

Table of Contents

Should the PRC government choose to exercise significant oversight and discretion over the conduct of our business, they may intervene in or influence our operations.

Such governmental actions:

        could result in a material change in our operations;

        could hinder our ability to continue to offer securities to investors; and

        may cause the value of our Ordinary Shares to significantly decline or be worthless.

Permission Required from Hong Kong and PRC Authorities

Due to the registration requirements of the Buildings Department of Hong Kong, Chiu & Lee Partners is required to apply for the relevant registrations to conduct its operation in Hong Kong and has been a registered specialist contractor in the categories of foundation, site formation, and demolition work since 2006 and registered general building contractor since 1999. As of the date of this prospectus, Chiu & Lee Partners has received all requisite permissions and approvals for the operation of our business in Hong Kong and no permission has been denied. See “Business — Major Qualifications, Licenses and Certifications” on page 89. Chiu & Lee Partners’ business operation and personnel are also subject to the relevant laws and regulations. See “Regulations — Regulations Related to Our Business Operations in Hong Kong” on page 93. As of the date of this prospectus, Chiu & Lee Partners is not required to obtain any permission or approval from Hong Kong authorities to issue our Ordinary Shares to foreign investors. We are also not required to obtain permissions or approvals from any PRC authorities before listing in the United States and to issue our Ordinary Shares to foreign investors or operate our business as currently conducted, including the CSRC, the CAC, or any other governmental agency that is required to approve our operations.

Hong Kong is a Special Administrative Region of the PRC and the basic policies of the PRC regarding Hong Kong are reflected in the Basic Law, which serves as Hong Kong’s constitution. The Basic Law provides Hong Kong with a high degree of autonomy and executive, legislative and independent judicial powers, including that of final adjudication under the principle of “one country, two systems”. The PRC laws and regulations do not currently have any material impact on our business, financial condition or results of operations. However, there is no assurance that there will not be any changes in the economic, political and legal environment in Hong Kong in the future. In the event that (i) the PRC government expanded the categories of industries and companies whose foreign securities offerings are subject to review by the CSRC or the CAC and that we are required to obtain such permissions or approvals, (ii) we inadvertently concluded that relevant permissions or approvals were not required or that we did not receive or maintain relevant permissions or approvals required, or (iii) applicable laws, regulations, or interpretations change and require us to obtain such permissions or approvals in the future, we may face similar regulatory risks as those operated in mainland China, including the ability to offer securities to investors, list their securities on a U.S. or other foreign exchanges, conduct their business or accept foreign investment or sanctions by the CSRC, the CAC, or other PRC regulatory agencies.

Recent PCAOB Developments

On May 20, 2020, the U.S. Senate passed the HFCA Act, which includes requirements for the SEC to identify issuers whose audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely because of a restriction imposed by a non-U.S. authority in the auditor’s local jurisdiction. The U.S. House of Representatives passed the HFCA Act on December 2, 2020, and the HFCA Act was signed into law on December 18, 2020. Pursuant to the HFCA act, our securities may be prohibited from trading on the Nasdaq or other U.S. stock exchanges if our auditor cannot be inspected by the PCAOB for three consecutive years, and this ultimately could result in our Ordinary Shares being delisted.

On March 24, 2021, the SEC adopted interim final rules relating to the implementation of certain disclosure and documentation requirements of the HFCA Act. A company will be required to comply with these rules if the SEC identifies it as having a “non-inspection” year under a process to be subsequently established by the SEC. The SEC is assessing how to implement other requirements of the HFCA Act, including the listing and trading prohibition requirements described above.

On June 22, 2021, the U.S. Senate passed the Accelerating Holding Foreign Company Act, which was signed into law on December 29, 2022, reduced the number of consecutive non-inspection years required for triggering the prohibitions under the HFCA Act from three years to two years.

16

Table of Contents

On December 2, 2021, the SEC issued amendments to finalize rules implementing the submission and disclosure requirements in the HFCA Act, which took effect on January 10, 2022. The rules apply to registrants that the SEC identifies as having filed an annual report with an audit report issued by a registered public accounting firm that is located in a foreign jurisdiction and that PCAOB is unable to inspect or investigate completely because of a position taken by an authority in foreign jurisdictions.

On December 16, 2021, PCAOB issued a Determination Report, which found that the PCAOB is unable to inspect or investigate completely registered public accounting firms headquartered in mainland China of the PRC or Hong Kong, a Special Administrative Region and dependency of the PRC, because of a position taken by one or more authorities in the PRC or Hong Kong.

Our auditor, ZH CPA, LLC, the independent registered public accounting firm that issues the audit report included elsewhere in this prospectus, as an auditor of companies that are traded publicly in the United States and a firm registered with the PCAOB, is subject to laws in the United States pursuant to which the PCAOB conducts regular inspections to assess our auditor’s compliance with the applicable professional standards. ZH CPA, LLC is headquartered in Denver, Colorado, and can be inspected by the PCAOB. As of the date of this prospectus, our auditor is not subject to the determinations announced by the PCAOB on December 16, 2021 in mainland China or Hong Kong because of a position taken by one or more authorities in the PRC or Hong Kong.

On August 26, 2022, CSRC, the MOF, and the PCAOB signed the Protocol, governing inspections and investigations of audit firms based in China and Hong Kong. The Protocol remains unpublished and is subject to further explanation and implementation. Pursuant to the fact sheet with respect to the Protocol disclosed by the SEC, the PCAOB shall have independent discretion to select any issuer audits for inspection or investigation and has the an exemption from the rule that a majority of our board of directors must be independent directors; unfettered ability to transfer information to the SEC.

On December 15, 2022, the PCAOB Board determined that the PCAOB was able to secure complete access to inspect and investigate registered public accounting firms headquartered in mainland China and Hong Kong and voted to vacate its previous determinations to the contrary. However, should PRC authorities obstruct or otherwise fail to facilitate the PCAOB’s access in the future, the PCAOB Board will consider the need to issue a new determination.

See “Risk Factors — Risks Relating to Our Ordinary Shares — Although the audit report included in this prospectus is prepared by U.S. auditors who are currently inspected by the PCAOB, there is no guarantee that future audit reports will be prepared by auditors inspected by the PCAOB and, as such, in the future investors may be deprived of the benefits of such inspection. Furthermore, trading in our securities may be prohibited under the HFCA Act if the SEC subsequently determines our audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely, and as a result, U.S. national securities exchanges, such as the Nasdaq, may determine to delist our securities. Furthermore, on December 29, 2022 the Accelerating Holding Foreign Companies Accountable Act was enacted, which amended the HFCA Act by requiring the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three, and thus, reduced the time before the securities may be prohibited from trading or delisted.” on page 27.

Implication of Being a Controlled Company

We are and will continue, following this offering, to be a “controlled company” within the meaning of the Nasdaq Stock Market Rules and, as a result, may rely on exemptions from certain corporate governance requirements that provide protection to shareholders of other companies.

For so long as we are a controlled company under that definition, we are permitted to elect to rely, and may rely, on certain exemptions from corporate governance rules, including:

        an exemption from the rule that a majority of our board of directors must be independent directors;

        an exemption from the rule that the compensation of our chief executive officer must be determined or recommended solely by independent directors; and

        An exemption from the rule that our director nominees must be selected or recommended solely by independent directors.

17

Table of Contents

As a result, you will not have the same protection afforded to shareholders of companies that are subject to these corporate governance requirements. Although we do not intend to rely on the “controlled company” exemption under the Nasdaq listing rules, we could elect to rely on this exemption after we complete this offering. If we elected to rely on the “controlled company” exemption, a majority of the members of our board of directors might not be independent directors and our nominating and corporate governance and compensation committees might not consist entirely of independent directors after we complete this offering. See “Risk Factors — Risks Related to Our Ordinary Shares and This Offering — As a “controlled company” under the rules of the Nasdaq Capital Market, we may choose to exempt our Company from certain corporate governance requirements that could have an adverse effect on our public shareholders.”

Implications of Being an Emerging Growth Company and a Foreign Private Issuer

As a company with less than $1.235 billion in revenue during our last fiscal year, we qualify as an “emerging growth company” as defined in the Jumpstart Our Business Startups Act (the “JOBS Act”), enacted in April 2012, and may take advantage of reduced reporting requirements that are otherwise applicable to public companies. These provisions include, but are not limited to:

        being permitted to present only two years of audited financial statements and only two years of related Management’s Discussion and Analysis of Financial Condition and Results of Operations in our filings with the SEC;

        not being required to comply with the auditor attestation requirements in the assessment of our internal control over financial reporting;

        reduced disclosure obligations regarding executive compensation in periodic reports, proxy statements, and registration statements; and

        exemptions from the requirements of holding a nonbinding advisory vote on executive compensation and shareholder approval of any golden parachute payments not previously approved.

We may take advantage of these provisions until the last day of our fiscal year following the fifth anniversary of the date of the first sale of our Ordinary Shares pursuant to this offering. However, if certain events occur before the end of such five-year period, including if we become a “large accelerated filer,” our annual gross revenues exceed US$1.235 billion, or we issue more than US$1 billion of non-convertible debt in any three-year period, we will cease to be an emerging growth company before the end of such five-year period.

In addition, Section 107 of the JOBS Act provides that an “emerging growth company” can take advantage of the extended transition period provided in Section 7(a)(2)(B) of the Securities Act for complying with new or revised accounting standards. We have elected to take advantage of the extended transition period for complying with new or revised accounting standards and acknowledge such election is irrevocable pursuant to Section 107 of the JOBS Act.

We are a foreign private issuer as defined by the SEC. As a result, in accordance with the rules and regulations of The Nasdaq Stock Market LLC, we may comply with home country governance requirements and certain exemptions thereunder rather than complying with Nasdaq corporate governance standards. We may choose to take advantage of the following exemptions afforded to foreign private issuers:

        Exemption from filing quarterly reports on Form 10-Q or provide current reports on Form 8-K disclosing significant events within four days of their occurrence.

        Exemption from Section 16 rules regarding sales of Ordinary Shares by insiders, which will provide less data in this regard than shareholders of U.S. companies that are subject to the Exchange Act.

        Exemption from the Nasdaq rules applicable to domestic issuers requiring disclosure within four business days of any determination to grant a waiver of the code of business conduct and ethics to directors and officers. Although we will require board approval of any such waiver, we may choose not to disclose the waiver in the manner set forth in the Nasdaq rules, as permitted by the foreign private issuer exemption.

Furthermore, Nasdaq Rule 5615(a)(3) provides that a foreign private issuer, such as us, may rely on our home country corporate governance practices in lieu of certain of the rules in the Nasdaq Rule 5600 Series and Rule 5250(d), provided that we nevertheless comply with Nasdaq’s Notification of Noncompliance requirement (Rule 5625), the

18

Table of Contents

Voting Rights requirement (Rule 5640) and that we have an audit committee that satisfies Rule 5605(c)(3), consisting of committee members that meet the independence requirements of Rule 5605(c)(2)(A)(ii). If we rely on our home country corporate governance practices in lieu of certain of the rules of Nasdaq, our shareholders may not have the same protections afforded to shareholders of companies that are subject to all of the corporate governance requirements of Nasdaq. If we choose to do so, we may utilize these exemptions for as long as we continue to qualify as a foreign private issuer.

Corporate Information

Our principal executive office is located at Room 2620, 26/F., New Tech Plaza, 34 Tai Yau Street, San Po Kong, Kowloon, Hong Kong. Our telephone number is (+852) 2155 9690. Our registered office in the Cayman Islands is located at the office of Appleby Global Services (Cayman) Limited, 71 Fort Street, PO Box 500, George Town, Grand Cayman, KY1–1106, Cayman Islands.

Our agent for service of process in the United States is Cogency Global Inc., located at 122 East 42nd Street, 18th Floor New York, NY 10168. Information contained on, or that can be accessed through, our website is not a part of, and shall not be incorporated by reference into, this prospectus.

Impact of COVID-19

Since late December 2019, the outbreak of COVID-19 spread rapidly throughout China and later to the rest of the world. On January 30, 2020, the International Health Regulations Emergency Committee of the World Health Organization declared the outbreak a “Public Health Emergency of International Concern” (“PHEIC”), and later on March 11, 2020, a global pandemic. The COVID-19 outbreak has led governments across the globe to impose a series of measures intended to contain its spread, including border closures, travel bans, quarantine measures, social distancing, and restrictions on business operations and large gatherings. From 2020 to the middle of 2021, COVID-19 vaccination programs had been greatly promoted around the globe, however several types of COVID-19 variants emerged in different parts of the world.

Supply chain disruptions have become a major challenge for the global economy since the start of the COVID-19 pandemic. These shortages and supply-chain disruptions are significant and widespread. Lockdowns in several countries across the world, labor shortages, robust demand for tradable goods, disruptions to logistics networks, and capacity constraints have resulted in increases in freight costs and delivery times. Companies that are reliant on the movement of goods and materials, such as our Company, which relies on construction materials, may suffer from plant closures and supply shortages across the extended supply network.

In addition, multiple infected cases within a construction site may result in shortage of labor and in more serious cases may cause a temporary halt in the site’s construction operation for a few days. Hence, our productivity and progress may also be negatively affected.

Furthermore, while we, our customers, subcontractors, and suppliers have not experienced any material suspensions or cancellations of our projects due to the COVID-19 outbreak during the years ended March 31, 2022 and 2021, our business may be adversely affected if concerns relating to COVID-19 continue to restrict travel, or result in the Company’s personnel, vendors, and services providers being unavailable to pursue their business objectives free of COVID-19 related restrictions. The extent to which COVID-19 impacts our business in the future will depend on future developments, which are highly uncertain and cannot be predicted, including new information that may emerge concerning the severity of COVID-19 and the actions to contain COVID-19 or treat its impact, among others. If the disruptions posed by COVID-19 or other matters of global concerns continue for an extended period of time, our ability to pursue our business objectives may be materially adversely affected. In addition, our ability to raise equity and debt financing, which may be adversely impacted by COVID-19 and other events, including as a result of increased market volatility, decreased market liquidity and third-party financing became unavailable on terms acceptable to us or at all.

Any future impact on our results of operations will depend on, to a large extent, future developments and new information that may emerge regarding the duration and severity of the COVID-19 pandemic and the actions taken by government authorities and other entities to contain the spread or treat its impact, almost all of which are beyond our control. As such, we cannot assure you that we will be able to maintain the growth rate we have experienced or projected. We will continue to closely monitor the situation throughout 2023 and beyond.

19

Table of Contents

The Offering

Securities being offered:

 

1,740,000 Ordinary Shares.

IPO price:

 

We estimate the IPO price will be between US$4.00 and US$5.00 per Ordinary Share.

Number of Ordinary Shares outstanding before this offering:

 


11,250,000 Ordinary Shares.

Number of Ordinary Shares outstanding after this offering:

 


12,990,000 Ordinary Shares.

Over-allotment option:

 

We have granted the underwriter the right to purchase up to 261,000 additional Ordinary Shares from us at the public offering price less the underwriting discount within 45 days from the date of the closing of this offering to cover over-allotments.

Use of proceeds:

 

Based upon an IPO price of US$4.00 per Share, we estimate that we will receive net proceeds from this offering, after deducting the estimated underwriting discounts and the estimated offering expenses payable by us, of approximately US$4,352,559 if the underwriters do not exercise their over-allotment option, and US$5,313,039 if the underwriters exercise their over-allotment option in full, after deducting the underwriting discounts and commissions, non-accountable expense allowance and estimated offering expenses payable by us.

   

We plan to use the net proceeds of this offering as follows:

   

   Approximately 40% for purchasing machinery and robotics equipment;

   

   Approximately 20% for employing additional staff; and

   

   The balance to fund working capital and for other general corporate purposes.

   

For more information on the use of proceeds, see “Use of Proceeds” on page 57.

Lock-up:

 

We and all of our directors, officers, and principal shareholders (defined as owners of 5% or more of our Ordinary Shares) have agreed with the underwriters, subject to certain exceptions, not to offer, issue, sell, transfer, contract to sell, encumber, grant any option for the sale of, or otherwise dispose of, directly or indirectly, any of our Ordinary Shares or securities convertible into or exercisable or exchangeable for our Ordinary Shares for a period of 180 days after the effective date of the registration statement, which forms a part of this prospectus. See “Shares Eligible for Future Sale” and “Underwriting” for more information.

Proposed Nasdaq symbol:

 

We have applied to have our Ordinary Shares listed on the Nasdaq Capital Market under the symbol “CKHL.” We do not intend to apply to list the representative’s warrants on any security exchange.

20

Table of Contents

Transfer agent and registrar:

 

VStock Transfer, LLC

Risk factors:

 

Investing in our Ordinary Shares is highly speculative and involves a high degree of risk. As an investor you should be able to bear a complete loss of your investment. You should carefully consider the information set forth in the “Risk Factors” section beginning on page 22.

Unless otherwise indicated, all information contained in this prospectus assumes no exercise of the underwriters’ over-allotment option and is based on 11,250,000 Ordinary Shares outstanding as of the date of this prospectus.

21

Table of Contents

RISK FACTORS

An investment in our Ordinary Shares involves a high degree of risk. You should carefully consider the following information about these risks, together with the other information appearing elsewhere in this prospectus, before deciding to invest in our Ordinary Shares. The occurrence of any of the following risks could have a material adverse effect on our business, financial condition, results of operations, and future growth prospects. In these circumstances, the market price of our Ordinary Shares could decline, and you may lose all or part of your investment.

Risks Related to Doing Business in Hong Kong

Our key operations are in Hong Kong, a Special Administrative Region of the PRC. According to the long-arm provisions under the current PRC laws and regulations, the PRC government may exercise significant oversight and discretion over the conduct of our business and may intervene in or influence our operations at any time, which could result in a material change in our operations and/or the value of our Ordinary Shares. The PRC government may intervene or impose restrictions on our ability to move money out of Hong Kong to distribute earnings and pay dividends or to reinvest in our business outside of Hong Kong. Changes in the policies, regulations, rules, and the enforcement of laws of the PRC government may also be quick with little advance notice and our assertions and beliefs of the risk imposed by the PRC legal and regulatory system cannot be certain.

CKHL is a holding company and we conduct our operations in Hong Kong through our Operating Subsidiary Chiu & Lee Partners. Hong Kong is a Special Administrative Region of the PRC. As at the date of this prospectus, we are not materially affected by recent statements by the PRC government indicating an intention to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China-based issuers. However, due to certain long-arm provisions in the current PRC laws and regulations, there remains regulatory uncertainty with respect to the implementation and interpretation of laws in China as they may affect Hong Kong. The PRC government may choose to exercise additional oversight and discretion over Hong Kong, and the policies, regulations, rules, and the enforcement of laws of the PRC government to which we are subject may change rapidly and with little advance notice to us or our shareholders. As a result, the application, interpretation, and enforcement of new and existing laws and regulations in the PRC and our assertions and beliefs of the risk imposed by the PRC legal and regulatory system are by their very nature uncertain.

In addition, these PRC laws and regulations may be interpreted and applied inconsistently by different agencies or authorities, which may result in inconsistency with our current policies and practices. New laws, regulations, and other government directives in the PRC may also be costly to comply with, and such compliance, any associated inquiries or investigations, or any other government actions may:

        delay or impede our development;

        result in negative publicity or increase our operating costs;

        require significant management time and attention; and

        subject us to remedies, administrative penalties, and even criminal liabilities that may harm our business, including fines assessed for our current or historical operations, or demands or orders that we modify or even cease our business practices.

We are aware that recently the PRC government initiated a series of regulatory actions and statements to regulate business operations in certain areas in China with little advance notice, including cracking down on illegal activities in the securities market, enhancing supervision over China-based companies listed overseas using a VIE structure, adopting new measures to extend the scope of cybersecurity reviews, and expanding the efforts in anti-monopoly enforcement. Since these statements and regulatory actions are new, it is highly uncertain how soon the PRC legislative or administrative regulation making bodies will respond or what existing or new laws or regulations or detailed implementations and interpretations will be modified or promulgated, if any, or what the potential impact that any such modified or new laws and regulations would have on our daily business operation, the ability to accept foreign investments and list on a U.S. or other foreign exchange.

The PRC government may intervene or influence our operations at any time and may exert more control over offerings conducted overseas and foreign investment in Hong Kong-based issuers, which may result in a material change in our operations and/or the value of our Ordinary Shares. For example, there is currently no restriction or

22

Table of Contents

limitation under the laws of Hong Kong on the conversion of HK dollar into foreign currencies and the transfer of currencies out of Hong Kong and the laws and regulations of the PRC on currency conversion control do not currently have any material impact on the transfer of cash between the ultimate holding company and the Operating Subsidiary in Hong Kong. However, the PRC government may, in the future, impose restrictions or limitations on our ability to move money out of Hong Kong to distribute earnings and pay dividends to and from the other entities within our organization or to reinvest in our business outside of Hong Kong. Such restrictions and limitations, if imposed in the future, may delay or hinder the expansion of our business to outside of Hong Kong and may affect our ability to receive funds from our Operating Subsidiary in Hong Kong. The promulgation of new laws or regulations, or the new interpretation of existing laws and regulations, in each case, that restrict or otherwise unfavorably impact our ability to conduct our business could require us to change certain aspects of our business to ensure compliance; decrease demand for our services; reduce revenues; increase costs; require us to obtain more licenses, permits, approvals, or certificates; or subject us to additional liabilities. To the extent any new or more stringent measures are implemented, our business, financial condition, and results of operations could be adversely affected and the value of our Ordinary Shares could decrease or become worthless.

There are uncertainties regarding the interpretation and enforcement of PRC and Hong Kong laws, rules, and regulations.

A substantial majority of our operations are conducted in Hong Kong, a Special Administrative Region of China with its own governmental and legal system that is independent from mainland China and has its own distinct rules and regulations. However, our Hong Kong Operating Subsidiary Chiu and Lee Partners may become subject to laws, rules, and regulations applicable to foreign investment in mainland China. The PRC legal system is a civil law system based on written statutes. Prior court decisions may be cited for reference but have limited precedential value, unlike the common law system applicable in Hong Kong. These laws and regulations are sometimes vague and may be subject to future changes, and their official interpretation and enforcement could be unpredictable with little advance notice, which could result in a material change in our operations and/or the value of our Ordinary Shares.

In 1979, the PRC government began to promulgate a comprehensive system of laws, rules, and regulations governing economic matters in general. The overall effect of legislation over the past three decades has significantly enhanced the protections afforded to various forms of foreign investment in China. However, China has not developed a fully integrated legal system, and recently enacted laws, rules, and regulations may not sufficiently cover all aspects of economic activities in China or may be subject to significant degrees of interpretation by PRC regulatory agencies. In particular, because these laws, rules, and regulations are relatively new, and because of the limited number of published decisions and the non-binding nature of such decisions, and because the laws, rules, and regulations often give the relevant regulator significant discretion in how to enforce them, the interpretation and enforcement of these laws, rules, and regulations involve uncertainties and can be inconsistent and unpredictable. In addition, the PRC legal system is based in part on government policies and internal rules, some of which are not published on a timely basis or at all, and which may have a retroactive effect. As a result, we may not be aware of our violation of these policies and rules until after the occurrence of the violation.

Any administrative and court proceedings in China may be protracted, resulting in substantial costs and diversion of resources and management attention. Since PRC administrative and court authorities have significant discretion in interpreting and implementing statutory and contractual terms, it may be more difficult to evaluate the outcome of administrative and court proceedings and the level of legal protection we enjoy than in more developed legal systems.

If the PRC government chooses to exert more oversight and control over offerings that are conducted overseas and/or foreign investment in China based issuers, such action may significantly limit or completely hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless.

Recent statements by the PRC government have indicated an intent to exert more exert oversight and control over offerings that are conducted overseas and/or foreign investments in China based issuers. On July 10, 2021, the CAC issued the Measures for Cybersecurity Review for public comments (the “Revised Draft”), which required that, among others, in addition to “operator of critical information infrastructure” any “data processor” controlling personal information of no less than one million users which seeks to list in a foreign stock exchange should also be subject to cybersecurity review. Pursuant to Article 6 of the Revised Draft, companies holding data or more than one million users must apply for cybersecurity approval when seeking overseas listings because of the risk that such data and personal information

23

Table of Contents

could be “affected, controlled, and maliciously exploited by foreign governments.” On December 28, 2021, the CAC published the revised Cybersecurity Review Measures (“CRM”), which further restates and expands the applicable scope of the cybersecurity review. The revised CRM took effect on February 15, 2022, and replaced the Revised Draft issued on July 10, 2021. Pursuant to the revised CRM, if a network platform operator holding personal information of over one million users seeks for “foreign” listing, it must apply for the cybersecurity review. Our business belongs to the construction industry, which does not involve the collection of user data, implicate cybersecurity, or involve any other type of restricted industry. As a result, the likelihood of us being subject to the review of the CAC is remote.

On December 24, 2021, the CSRC, together with other relevant PRC authorities issued the Provisions of the State Council on the Administration of Overseas Securities Offering and Listing by Domestic Companies (Draft for Comments), and the Measures for the Filing of Overseas Securities Offering and Listing by Domestic Companies (Draft for Comments) (“Draft Rules Regarding Overseas Listing”). The Draft Rules Regarding Overseas Listing require that a PRC domestic enterprise seeking to issue and list its shares overseas shall complete the filing procedures of and submit the relevant information to CSRC, including direct and indirect issuance and listing. Where an enterprise whose principal business activities are conducted in PRC seeks to issue and list its shares in the name of an overseas enterprise on the basis of the equity, assets, income or other similar rights and interests of the relevant PRC domestic enterprise, such activities shall be deemed an indirect overseas issuance and listing under the Draft Rules Regarding Overseas Listing.

On February 17, 2023, the CSRC issued the Trial Administrative Measures of Overseas Securities Offering and Listing by Domestic Enterprises, or the Trial Measures, which became effective on March 31, 2023. On the same date of the issuance of the Trial Measures, the CSRC circulated No.1 to No.5 Supporting Guidance Rules, the Notes on the Trial Measures, the Notice on Administration Arrangements for the Filing of Overseas Listings by Domestic Enterprises and the relevant CSRC Answers to Reporter Questions on the official website of the CSRC, or collectively, the Guidance Rules and Notice. The Trial Measures, together with the Guidance Rules and Notice, reiterate the basic supervision principles as reflected in the Draft Rules Regarding Overseas Listing by providing substantially the same requirements for filings of overseas offering and listing by domestic companies, yet made the following updates compared to the Draft Rules Regarding Overseas Listing: (a) further clarification of the circumstances prohibiting overseas issuance and listing; (b) further clarification of the standard of indirect overseas listing under the principle of substance over form, and (c) adding more details of filing procedures and requirements by setting different filing requirements for different types of overseas offering and listing. Under the Trial Measures and the Guidance Rules and Notice, domestic companies conducting overseas securities offering and listing activities, either in direct or indirect form, shall complete filing procedures with the CSRC pursuant to the requirements of the Trial Measures within three working days following its submission of initial public offerings or listing application. The companies that have already been listed on overseas stock exchanges or have obtained the approval from overseas supervision administrations or stock exchanges for its offering and listing and will complete their overseas offering and listing prior to September 30, 2023 are not required to make immediate filings for its listing yet need to make filings for subsequent offerings in accordance with the Trial Measures. The companies that have already submitted an application for an initial public offering to overseas supervision administrations prior to the effective date of the Trial Measures but have not yet obtained the approval from overseas supervision administrations or stock exchanges for the offering and listing may arrange for the filing within a reasonable time period and should complete the filing procedure before such companies’ overseas issuance and listing.

On February 24, 2023, the CSRC, together with Ministry of Finance of the PRC, National Administration of State Secrets Protection and National Archives Administration of China, revised the Provisions on Strengthening Confidentiality and Archives Administration for Overseas Securities Offering and Listing, which were issued by the CSRC, National Administration of State Secrets Protection and National Archives Administration of China in 2009, or the Provisions. The revised Provisions were issued under the title the “Provisions on Strengthening Confidentiality and Archives Administration of Overseas Securities Offering and Listing by Domestic Companies” and came into effect on March 31, 2023 together with the Trial Measures. One of the major revisions to the revised Provisions is expanding their application to cover indirect overseas offering and listing, as is consistent with the Trial Measures. The revised Provisions require that, including, but not limited to, (a) a domestic company that plans to, either directly or indirectly through its overseas listed entity, publicly disclose or provide to relevant individuals or entities including securities companies, securities service providers and overseas regulators, any documents and materials that contain state secrets or working secrets of government agencies, shall first obtain approval from competent authorities according to law, and file with the secrecy administrative department at the same level; and (b) a domestic company that plans to, either directly or indirectly through its overseas listed entity, publicly disclose or provide to relevant individuals and

24

Table of Contents

entities including securities companies, securities service providers and overseas regulators, any other documents and materials that, if leaked, will be detrimental to national security or public interest, shall strictly fulfil relevant procedures stipulated by applicable national regulations.

As of the date of this prospectus, our registered public offering in the United States is not subject to the review or prior approval of the CAC nor the CSRC. Uncertainties still exist, however, due to the possibility that laws, regulations, or policies in the PRC could change rapidly in the future. It is uncertain whether the PRC government will adopt additional requirements or extend the existing requirements to apply to our Operating Subsidiary located in Hong Kong. Any future action by the PRC government expanding the categories of industries and companies whose foreign securities offerings are subject to review by the CSRC or the CAC could significantly limit or completely hinder our ability to offer or continue to offer securities to investors and could cause the value of such securities to significantly decline or be worthless.

In the event that (i) the PRC government expands the categories of industries and companies whose foreign securities offerings are subject to review by the CSRC or the CAC such that we are required to obtain such permissions or approvals; or (ii) we inadvertently concluded that relevant permissions or approvals were not required or that we did not receive or maintain relevant permissions or approvals required, any action taken by the PRC government could significantly limit or completely hinder our operations, significantly limit or completely hinder our ability to offer our Ordinary Shares to investors, and cause the value of such Shares to significantly decline or become worthless.

Adverse regulatory developments in China may subject us to additional regulatory review, and additional disclosure requirements and regulatory scrutiny to be adopted by the SEC in response to risks related to recent regulatory developments in China may impose additional compliance requirements for companies like us with Hong Kong-based operations, all of which could increase our compliance costs and subject us to additional disclosure requirements.

Currently, Hong Kong has a separate legal system from mainland China, and it has its legislative framework and judiciary independent of that of the PRC government. Nonetheless, the recent regulatory developments in China, in particular with respect to restrictions on China-based companies raising capital offshore, may lead to additional regulatory review in China over our financing and capital raising activities in the United States. In addition, we may be subject to industry-wide regulations that may be adopted by the relevant PRC authorities, which may have the effect of limiting our service offerings, restricting the scope of our operations in Hong Kong, or causing the suspension or termination of our business operations in Hong Kong entirely. We may have to adjust, modify, or completely change our business operations in response to adverse regulatory changes or policy developments, and we cannot assure you that any remedial action adopted by us can be completed in a timely, cost efficient, or liability-free manner or at all.

On July 30, 2021, in response to the recent regulatory developments in China and actions adopted by the PRC government, the Chairman of the SEC issued a statement asking the SEC staff to seek additional disclosures from offshore issuers associated with China-based operating companies (including Hong Kong) before their registration statements will be declared effective. On August 1, 2021, the CSRC issued a statement saying that it had taken note of the new disclosure requirements announced by the SEC regarding the listings of Chinese companies and the recent regulatory development in China, and that both countries should strengthen communications on regulating China-related issuers. Since we operate in Hong Kong, we cannot guarantee that we will not be subject to tightened regulatory review and we could be exposed to government interference from China.

We may become subject to a variety of PRC laws and other obligations regarding data security offerings that are conducted overseas and/or foreign investment in China-based issuers, and any failure to comply with applicable laws and obligations could have a material and adverse effect on our business, financial condition, and results of operations and may hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless.

On June 10, 2021, the Standing Committee of the National People’s Congress enacted the PRC Data Security Law, which took effect on September 1, 2021. The law requires data collection to be conducted in a legitimate and proper manner, and stipulates that, for the purpose of data protection, data processing activities must be conducted based on data classification and hierarchical protection system for data security.

25

Table of Contents

On July 6, 2021, the General Office of the Communist Party of China Central Committee and the General Office of the State Council jointly issued a document to crack down on illegal activities in the securities market and promote the high-quality development of the capital market, which, among other things, requires the relevant governmental authorities to strengthen cross-border oversight of law-enforcement and judicial cooperation, to enhance supervision over China-based companies listed overseas, and to establish and improve the system of extraterritorial application of the PRC securities laws.

On August 20, 2021, the 30th meeting of the Standing Committee of the 13th National People’s Congress voted and passed the “Personal Information Protection Law of the People’s Republic of China” (“PRC Personal Information Protection Law”), which became effective on November 1, 2021. The PRC Personal Information Protection Law applies to the processing of personal information of natural persons within the territory of China that is carried out outside of China where (1) such processing is for the purpose of providing products or services for natural persons within China, (2) such processing is to analyze or evaluate the behavior of natural persons within China, or (3) there are any other circumstances stipulated by related laws and administrative regulations.

On December 24, 2021, the CSRC, together with other relevant government authorities in China issued the Draft Rules Regarding Overseas Listing. The Draft Rules Regarding Overseas Listing require that a PRC domestic enterprise seeking to issue and list its shares overseas (“Overseas Issuance and Listing”) shall complete the filing procedures of and submit the relevant information to CSRC. The Overseas Issuance and Listing includes direct and indirect issuance and listing. Where an enterprise whose principal business activities are conducted in PRC seeks to issue and list its shares in the name of an overseas enterprise on the basis of the equity, assets, income, or other similar rights and interests of the relevant PRC domestic enterprise, such activities shall be deemed an indirect overseas issuance and listing under the Draft Rules Regarding Overseas Listing.

On February 17, 2023, the CSRC issued the Trial Administrative Measures of Overseas Securities Offering and Listing by Domestic Enterprises, or the Trial Measures, which became effective on March 31, 2023. On the same date of the issuance of the Trial Measures, the CSRC circulated No.1 to No.5 Supporting Guidance Rules, the Notes on the Trial Measures, the Notice on Administration Arrangements for the Filing of Overseas Listings by Domestic Enterprises and the relevant CSRC Answers to Reporter Questions on the official website of the CSRC, or collectively, the Guidance Rules and Notice. The Trial Measures, together with the Guidance Rules and Notice, reiterate the basic supervision principles as reflected in the Draft Rules Regarding Overseas Listing by providing substantially the same requirements for filings of overseas offering and listing by domestic companies, yet made the following updates compared to the Draft Rules Regarding Overseas Listing: (a) further clarification of the circumstances prohibiting overseas issuance and listing; (b) further clarification of the standard of indirect overseas listing under the principle of substance over form, and (c) adding more details of filing procedures and requirements by setting different filing requirements for different types of overseas offering and listing. Under the Trial Measures and the Guidance Rules and Notice, domestic companies conducting overseas securities offering and listing activities, either in direct or indirect form, shall complete filing procedures with the CSRC pursuant to the requirements of the Trial Measures within three working days following its submission of initial public offerings or listing application. The companies that have already been listed on overseas stock exchanges or have obtained the approval from overseas supervision administrations or stock exchanges for its offering and listing and will complete their overseas offering and listing prior to September 30, 2023 are not required to make immediate filings for its listing yet need to make filings for subsequent offerings in accordance with the Trial Measures. The companies that have already submitted an application for an initial public offering to overseas supervision administrations prior to the effective date of the Trial Measures but have not yet obtained the approval from overseas supervision administrations or stock exchanges for the offering and listing may arrange for the filing within a reasonable time period and should complete the filing procedure before such companies’ overseas issuance and listing.

On December 28, 2021, the CAC jointly with the relevant authorities formally published Measures for Cybersecurity Review (2021) which took effect on February 15, 2022, and replaced the former Measures for Cybersecurity Review (2020) issued on July 10, 2021. Measures for Cybersecurity Review (2021) stipulates that operators of critical information infrastructure purchasing network products and services, and online platform operators (together with the operators of critical information infrastructure, the “Operators”) carrying out data processing activities that affect or may affect national security, shall conduct a cybersecurity review, and any online platform operator who controls more than one million users’ personal information must go through a cybersecurity review by the cybersecurity review office if it seeks to be listed in a foreign country.

26

Table of Contents

Given that (1) our operating subsidiary is incorporated and located in Hong Kong; (2) we have no subsidiary, VIE structure, nor any direct operations in mainland China; and (3) pursuant to the Basic Law, which is a national law of the PRC and the constitutional document for Hong Kong, national laws of the PRC shall not be applied in Hong Kong except for those listed in Annex III of the Basic Law (which is confined to laws relating to defense and foreign affairs, as well as other matters outside the autonomy of Hong Kong), we do not currently expect the Measures for Cybersecurity Review (2021), the PRC Personal Information Protection Law, and the Draft Rules Regarding Overseas Listing to have an impact on our business, operations, or this offering. Our belief is grounded on the following: (1) we do not believe that our Operating Subsidiary falls within the definition of an “Operator” that is required to file for cybersecurity review before listing in the United States, because (2) our operating Subsidiary is incorporated in Hong Kong and operates in Hong Kong without any subsidiary or VIE structure in mainland China and each of the Measures for Cybersecurity Review (2021), the PRC Personal Information Protection Law, and the Draft Rules Regarding Overseas Listing remains unclear whether it shall be applied to a company based in Hong Kong; (3) as of the date of this prospectus, our Operating Subsidiary has neither collected nor stored personal information of any PRC individuals; (4) all of the data our operating subsidiary has collected is stored in servers located in Hong Kong; and (5) as of the date of this prospectus, our Operating Subsidiary has not been informed by any PRC governmental authority of any requirement that it file for a cybersecurity review or a CSRC review.

However, since these statements and regulatory actions are new, it is highly uncertain how soon the legislative or administrative regulation-making bodies will respond and what existing or new laws or regulations or detailed implementations and interpretations will be modified or promulgated, if any. It is also highly uncertain what the potential impact such modified or new laws and regulations will have on the daily business operations of our Operating Subsidiary, their respective abilities to accept foreign investments and the listing of our Ordinary Shares on a U.S. or other foreign exchanges. There remains significant uncertainty in the interpretation and enforcement of relevant PRC cybersecurity laws and regulations. If the Draft Rules Regarding Overseas Listing are adopted into law in the future and becomes applicable to our Operating Subsidiary, if our Operating Subsidiary is deemed to be an “Operator” that is required to file for cybersecurity review before listing in the United States, or if the Measures for Cybersecurity Review (2021) or the PRC Personal Information Protection Law becomes applicable to our Operating Subsidiary, the business operation of our operating subsidiary and the listing of our Ordinary Shares in the United States could be subject to the CAC’s cybersecurity review or CSRC Overseas Issuance and Listing review in the future. If our Operating Subsidiary becomes subject to the CAC or CSRC review, we cannot assure you that our operating subsidiary will be able to comply with the regulatory requirements in all respects, and the current practice of collecting and processing personal information may be ordered to be rectified or terminated by regulatory authorities. In the event of a failure to comply, our operating subsidiary may become subject to fines and other penalties that may have a material adverse effect on our business, operations, and financial condition and may hinder our ability to offer or continue to offer Ordinary Shares to investors and cause the value of our Ordinary Shares to significantly decline or be worthless.

Although the audit report included in this prospectus is prepared by U.S. auditors who are currently inspected by the PCAOB, there is no guarantee that future audit reports will be issued by auditors inspected by the PCAOB and, as such, in the future investors may be deprived of the benefits of such inspection. Furthermore, trading in our securities may be prohibited under the HFCA Act if the SEC subsequently determines our audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely, and as a result, U.S. national securities exchanges, such as the Nasdaq, may determine to delist our securities. Furthermore, on December 29, 2022 the Accelerating Holding Foreign Companies Accountable Act was enacted, which amended the HFCA Act by requiring the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three, and thus, reduced the time before the securities may be prohibited from trading or delisted.

The audit report included in this prospectus was issued by ZH CPA, LLC, a U.S.-based accounting firm that is registered with the PCAOB and can be inspected by the PCAOB. We have no intention of dismissing ZH CPA, LLC in the future or of engaging any auditor not based in the U.S. and not subject to regular inspection by the PCAOB. There is no guarantee, however, that any future auditor engaged by the Company would remain subject to full PCAOB inspection during the entire term of our engagement. The PCAOB is currently unable to conduct inspections in mainland China and Hong Kong without the approval of the PRC authorities. Currently, our U.S. auditor’s audit work for us can be inspected by the PCAOB, and we have no operations in mainland China. However, if there is significant change to current political arrangements between mainland China and Hong Kong, companies operated in Hong Kong like us may face similar regulatory risks as those operated in the PRC, and we cannot assure you that our auditor’s audit

27

Table of Contents

work for us will continue to be able to be inspected by the PCAOB. If it is later determined that the PCAOB is unable to inspect or investigate our auditor completely, investors may be deprived of the benefits of such inspection. Any audit reports not issued by auditors that are completely inspected by the PCAOB could result in a lack of assurance that our financial statements and disclosures are adequate and accurate.

Inspections of other auditors conducted by the PCAOB outside mainland China have at times identified deficiencies in those auditors’ audit procedures and quality control procedures, which may be addressed as part of the inspection process to improve future audit quality. The lack of PCAOB inspections of audit work undertaken in mainland China prevents the PCAOB from regularly evaluating auditors’ audits and their quality control procedures. As a result, if any component of our auditor’s work papers become located in mainland China in the future, such work papers will not be subject to inspection by the PCAOB. As a result, investors would be deprived of such PCAOB inspections, which could result in limitations or restrictions to our access of the U.S. capital markets.

As part of a continued regulatory focus in the United States on access to audit and other information currently protected by national law, in particular mainland China’s, in June 2019, a bipartisan group of lawmakers introduced bills in both houses of the U.S. Congress that, if passed, would require the SEC to maintain a list of issuers for which PCAOB is not able to inspect or investigate the audit work performed by a foreign public accounting firm for such issuers completely. The proposed Ensuring Quality Information and Transparency for Abroad-Based Listings on our Exchanges Act prescribes increased disclosure requirements for these issuers and, beginning in 2025, the delisting from U.S. national securities exchanges such as the Nasdaq of issuers included on the SEC’s list for three consecutive years. It is unclear if this proposed legislation will be enacted. Furthermore, there have been recent deliberations within the U.S. government regarding potentially limiting or restricting China-based companies from accessing U.S. capital markets.

On May 20, 2020, the U.S. Senate passed the HFCA Act, which includes requirements for the SEC to identify issuers whose audit work is performed by auditors that the PCAOB is unable to inspect or investigate completely because of a restriction imposed by a non-U.S. authority in the auditor’s local jurisdiction. The U.S. House of Representatives passed the HFCA Act on December 2, 2020, and the HFCA Act was signed into law on December 18, 2020. Additionally, in July 2020, the U.S. President’s Working Group on Financial Markets issued recommendations for actions that can be taken by the executive branch, the SEC, the PCAOB or other federal agencies and department with respect to Chinese companies listed on U.S. stock exchanges and their audit firms, in an effort to protect investors in the United States. In response, on November 23, 2020, the SEC issued guidance highlighting certain risks (and their implications to U.S. investors) associated with investments in China-based issuers and summarizing enhanced disclosures the SEC recommends China-based issuers make regarding such risks.

On March 24, 2021, the SEC adopted interim final rules relating to the implementation of certain disclosure and documentation requirements in the HFCA Act. On December 2, 2021, the SEC adopted amendments to finalize rules implementing the submission and disclosure requirements in the HFCA Act. The rules apply to public companies whose stock is registered with the SEC and are identified by the SEC as having filed an annual report with an audit report issued by a registered public accounting firm that is located in a foreign jurisdiction and whose audit work that PCAOB is unable to inspect or investigate. We will be required to comply with these rules if the SEC identifies us as having a “non-inspection” year under a process to be subsequently established by the SEC. The final amendments require any identified registrant to submit documentation to the SEC establishing that the registrant is not owned or controlled by a government entity in the public accounting firm’s foreign jurisdiction, and they also require, among other things, disclosure in the registrant’s annual report regarding the audit arrangements of, and government influence on, such registrants. Pursuant to the HFCA act, our securities may be prohibited from trading on the Nasdaq or other U.S. stock exchanges if our auditor cannot be inspected by the PCAOB for three consecutive years, and this ultimately could result in our Ordinary Shares being delisted.

On June 22, 2021, the U.S. Senate passed the Accelerating Holding Foreign Companies Accountable Act, which was signed into law on December 29, 2022, amended the HFCA Act and require the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its audit work cannot be inspected when its auditor is subject to PCAOB inspections for two consecutive years instead of three and, thus, reduced the time before our Ordinary Shares may be prohibited from trading or delisted.

28

Table of Contents

On September 22, 2021, the PCAOB adopted a final rule implementing the HFCA Act, which provides a framework for the PCAOB to use when determining, as contemplated under the HFCA Act, whether the PCAOB is unable to inspect or investigate completely registered public accounting firms located in a foreign jurisdiction in connection with their audit works because of a position taken by one or more authorities in that jurisdiction.

On November 5, 2021, the SEC approved the PCAOB’s Rule 6100, Board Determinations Under the HFCA Act. Rule 6100 provides a framework for the PCAOB to use when determining, as contemplated under the HFCA Act, whether it is unable to inspect or investigate completely registered public accounting firms located in a foreign jurisdiction because of a position taken by one or more authorities in that jurisdiction.

On December 16, 2021, the PCAOB issued a report on its determinations that it was unable to inspect or investigate completely PCAOB-registered public accounting firms headquartered in mainland China and in Hong Kong, because of positions taken by PRC authorities in those jurisdictions. In addition, the PCAOB’s report identified the specific registered public accounting firms which are subject to these determinations. Our registered public accounting firm, ZH CPA, LLC is not headquartered in mainland China or Hong Kong and was not identified in this report as a firm subject to the PCAOB’s determination.

The SEC is assessing how to implement other requirements of the HFCA Act, including the listing and trading prohibition requirements described above. Future developments in respect to increasing U.S. regulatory access to audit information are uncertain, as the legislative developments are subject to the legislative process and the regulatory developments are subject to the rule-making process and other administrative procedures.

On August 26, 2022, CSRC, the MOF, and the PCAOB signed the Protocol, governing inspections and investigations of audit firms based in China and Hong Kong. The Protocol remains unpublished and is subject to further explanation and implementation. Pursuant to the fact sheet with respect to the Protocol disclosed by the SEC, the PCAOB shall have independent discretion to select any issuer audits for inspection or investigation and has the unfettered ability to transfer information to the SEC. There can be no assurance that we will be able to comply with requirements imposed by U.S. regulators if there is significant change to current political arrangements between mainland China and Hong Kong or if any component of our auditor’s work papers become located in mainland China in the future. Delisting of our Ordinary Shares would force holders of our Ordinary Shares to sell their Ordinary Shares. The market price of our Ordinary Shares could be adversely affected as a result of anticipated negative impacts of these executive or legislative actions, regardless of whether these executive or legislative actions are implemented and regardless of our actual operating performance. On December 15, 2022, the PCAOB Board determined that the PCAOB was able to secure complete access to inspect and investigate registered public accounting firms headquartered in mainland China and Hong Kong and voted to vacate its previous determinations to the contrary. However, should PRC authorities obstruct or otherwise fail to facilitate the PCAOB’s access in the future, the PCAOB Board will consider the need to issue a new determination.

The SEC is assessing how to implement other requirements of the HFCA Act, including the listing and trading prohibition requirements described above. Future developments in respect of increasing U.S. regulatory access to audit information are uncertain, as the legislative developments are subject to the legislative process and the regulatory developments are subject to the rule-making process and other administrative procedures.

The recent joint statement by the SEC, proposed rule changes submitted by Nasdaq, and an act passed by the U.S. Senate and the U.S. House of Representatives all call for additional and more stringent criteria to be applied to emerging market companies. These developments could add uncertainties to our offering, business operations, share price, and reputation.

U.S. public companies with substantially all of their operations in China (including in Hong Kong) have been the subject of intense scrutiny, criticism, and negative publicity by investors, financial commentators, and regulatory agencies, such as the SEC. Much of the scrutiny, criticism, and negative publicity has centered on financial and accounting irregularities and mistakes, a lack of effective internal controls over financial accounting, inadequate corporate governance policies, or a lack of adherence thereto and, in many cases, allegations of fraud.

On December 7, 2018, the SEC and the PCAOB issued a joint statement highlighting continued challenges faced by the U.S. regulators in their oversight of financial statement audits of U.S.-listed companies with significant operations in China. On April 21, 2020, SEC Chairman Jay Clayton and PCAOB Chairman William D. Duhnke III, along with other senior SEC staff, released a joint statement highlighting the risks associated with investing in companies based in or have substantial operations in emerging markets including China, reiterating past SEC and PCAOB statements on

29

Table of Contents

matters including the difficulty associated with inspecting accounting firms and audit work papers in China and higher risks of fraud in emerging markets and the difficulty of bringing and enforcing SEC, Department of Justice and other U.S. regulatory actions, including in instances of fraud, in emerging markets generally.

On May 20, 2020, the U.S. Senate passed the HFCA Act requiring a foreign company to certify it is not owned or controlled by a foreign government if the PCAOB is unable to audit specified reports because the company uses a foreign auditor not subject to PCAOB inspection. If the PCAOB is unable to inspect the company’s auditors for three consecutive years, the issuer’s securities are prohibited to trade on a national exchange. On December 2, 2020, the U.S. House of Representatives approved the HFCA Act.

On May 21, 2021, Nasdaq filed three proposals with the SEC to (i) apply minimum offering size requirement for companies primarily operating in a “Restrictive Market”; (ii) prohibit Restrictive Market companies from directly listing on Nasdaq Capital Market, and only permit them to list on Nasdaq Global Select or Nasdaq Global Market in connection with a direct listing; and (iii) apply additional and more stringent criteria to an applicant or listed company based on the qualifications of the company’s auditors.

As a result of this scrutiny, criticism, and negative publicity, the traded stock of many U.S.-listed Chinese companies sharply decreased in value and, in some cases, has become virtually worthless. Many of these companies are now subject to shareholder lawsuits and SEC enforcement actions and are conducting internal and external investigations into the allegations. It is not clear what effect this sector-wide scrutiny, criticism, and negative publicity will have on us, our offerings, business, and our share price. If we become the subject of any unfavorable allegations, whether such allegations are proven to be true or untrue, we will have to expend significant resources to investigate such allegations and/or defend our company. This situation will be costly and time consuming and distract our management from developing our growth. If such allegations are not proven to be groundless, we and our business operations will be severely affected and you could sustain a significant decline in the value of our shares.

The enactment of Law of the PRC on Safeguarding National Security in the Hong Kong Special Administrative Region could impact our Hong Kong Operating Subsidiary.

On June 30, 2020, the Standing Committee of the PRC National People’s Congress adopted the Law of the People’s Republic of China on Safeguarding National Security in the Hong Kong Special Administrative Region (the “Hong Kong National Security Law”). This law defines the duties and government bodies of the Hong Kong National Security Law for safeguarding national security and four categories of offenses — secession, subversion, terrorist activities, and collusion with a foreign country or external elements to endanger national security — and their corresponding penalties. On July 14, 2020, former U.S. President Donald Trump signed the Hong Kong Autonomy Act (“HKAA”) into law, authorizing the U.S. administration to impose blocking sanctions against individuals and entities who are determined to have materially contributed to the erosion of Hong Kong’s autonomy. On August 7, 2020, the U.S. government imposed HKAA-authorized sanctions on 11 individuals, including then-HKSAR chief executive Carrie Lam and John Lee, who later replaced Carrie Lam as chief executive on July 1, 2022.

In July 2021, President Joe Biden warned investors about the risks of doing business in Hong Kong, issuing an advisory saying China’s push to exert more control over Hong Kong threatens the rule of law and endangers employees and data. The HKAA further authorizes secondary sanctions, including the imposition of blocking sanctions, against foreign financial institutions that knowingly conduct a significant transaction with foreign persons sanctioned under this authority. The imposition of sanctions may directly affect the foreign financial institutions as well as any third parties or customers dealing with any foreign financial institution that are targeted. It is difficult to predict the full impact of the Hong Kong National Security Law and HKAA on Hong Kong and companies located in Hong Kong. If our subsidiaries are determined to be in violation of the Hong Kong National Security Law or the HKAA by competent authorities, our business operations could be materially and adversely affected.

If we become subject to the recent scrutiny, criticism, and negative publicity involving U.S.-listed China-based companies, we may have to expend significant resources to investigate and/or defend the matter, which could harm our business operations, this offering, and our reputation and could result in a loss of your investment in our Ordinary Shares, in particular if such matter cannot be addressed and resolved favorably.

During the last several years, U.S.-listed companies that have substantially all of their operations in China have been the subject of intense scrutiny by investors, financial commentators, and regulatory agencies. Much of the scrutiny has centered on financial and accounting irregularities and mistakes, lack of effective internal controls over financial reporting, and, in many cases, allegations of fraud. As a result of the scrutiny, the publicly traded stock

30

Table of Contents

of many U.S.-listed Chinese companies that have been the subject of such scrutiny has sharply decreased in value. Many of these companies are now subject to shareholder lawsuits and/or SEC enforcement actions that are conducting internal and/or external investigations into the allegations.

If we become the subject of any such scrutiny, whether any allegations are true or not, we may have to expend significant resources to investigate such allegations and/or defend the Company. Such investigations or allegations would be costly and time consuming and likely would distract our management from our normal business and could result in our reputation being harmed. Our stock price could decline because of such allegations, even if the allegations are false.

A downturn in Hong Kong, mainland China, or the global economy, or a change in economic and political policies of China, could materially and adversely affect our business and financial condition.

Our business may be influenced to a significant degree by political, economic, and social conditions in Hong Kong and China generally. The Chinese economy differs from the economies of most developed countries in many respects, including the amount of government involvement, level of development, growth rate, control of foreign exchange, and allocation of resources. While the Chinese economy has experienced significant growth over the past decades, growth has been uneven, both geographically and among various sectors of the economy. The PRC government has implemented various measures to encourage economic growth and guide the allocation of resources. Some of these measures may benefit the overall Chinese economy, but they may have a negative effect on us.

Economic conditions in Hong Kong and China are sensitive to global economic conditions. Any prolonged slowdown in the global or Chinese economy may affect potential clients’ confidence in financial market as a whole and have a negative impact on our business, results of operations, and financial condition. Additionally, continued turbulence in the international markets may adversely affect our ability to access the capital markets to meet liquidity needs. Rising tension between the U.S. and China may an adverse effect on global economic conditions. On August 9, 2023, an executive order was issued by President Biden to direct the Department of Treasury to issue regulations to restrict outbound investment in key technology sectors by U.S. persons to China, with a view to bolster U.S. national security and to curtail investment in sectors that may advance China’s military, intelligence, surveillance or cyber-enabled capabilities.

Because our business is conducted in Hong Kong dollars and the price of our Ordinary Shares is quoted in U.S. dollars, changes in currency conversion rates may affect the value of your investments.

Our business is conducted in Hong Kong; our books and records are reported in Hong Kong dollars, which is the currency of Hong Kong; and the financial statements that we file with the SEC and provide to our shareholders are presented in U.S. dollars. Changes in the exchange rate between the Hong Kong dollar and U.S. dollar affect the value of our assets and the results of our operations in U.S. dollars. The value of the Hong Kong dollar against the U.S. dollar and other currencies may fluctuate and is affected by, among other things, changes in the Hong Kong’s political and economic conditions and perceived changes in the economy of Hong Kong and the United States. Any significant revaluation of the Hong Kong dollar may materially and adversely affect our cash flows, revenue, and financial condition. Further, our Ordinary Shares offered by this prospectus are denominated in U.S. dollars, and we will need to convert the net proceeds we receive into Hong Kong dollar in order to use the funds for our business. Changes in the conversion rate between the U.S. dollar and the Hong Kong dollar will affect that amount of proceeds we will have available for our business.

Since 1983, Hong Kong dollars have been pegged to the U.S. dollars at the rate of approximately HK$7.80 to US$1.00. We cannot assure you that this policy will not be changed in the future. If the pegging system collapses and Hong Kong dollars suffer devaluation, the Hong Kong dollar cost of our expenditures denominated in foreign currency may increase. This would in turn adversely affect the operations and profitability of our business.

There are political risks associated with conducting business in Hong Kong.

Any adverse economic, social, and/or political conditions, material social unrest, strike, riot, civil disturbance, or disobedience, as well as significant natural disasters, may affect the market may adversely affect the business operations of the Company. Hong Kong is a Special Administrative Region of the PRC and the basic policies of the PRC regarding Hong Kong are reflected in the Basic Law, namely, Hong Kong’s constitutional document, which provides Hong Kong with a high degree of autonomy and executive, legislative, and independent judicial powers, including that of final adjudication under the principle of “one country, two systems.” However, there is no assurance that there will not be any changes in the economic, political, and legal environment in Hong Kong in the future. Since our operation is based in Hong Kong, any change of such political arrangements may pose immediate threat to the stability of the economy in Hong Kong, thereby directly and adversely affecting our results of operations and financial positions.

31

Table of Contents

Under the Basic Law, Hong Kong is exclusively in charge of its internal affairs and external relations, while the government of the PRC is responsible for its foreign affairs and defense. As a separate customs territory, Hong Kong maintains and develops relations with foreign states and regions. Based on certain recent development, including the Hong Kong National Security Law issued by the Standing Committee of the PRC National People’s Congress in June 2020, the U.S. State Department has indicated that the United States no longer considers Hong Kong to have significant autonomy from China and, at the time, then-President Donald Trump signed an executive order and HKAA to remove Hong Kong’s preferential trade status and to authorize the U.S. administration to impose blocking sanctions against individuals and entities who are determined to have materially contributed to the erosion of Hong Kong’s autonomy. The United States may impose the same tariffs and other trade restrictions on exports from Hong Kong that it places on goods from mainland China. These and other recent actions may represent an escalation in political and trade tensions involving the United States, China, and Hong Kong, which could potentially harm our business.

Given the relatively small geographical size of Hong Kong, any of such incidents may have a widespread effect on our business operations, which could in turn adversely and materially affect our business, results of operations, and financial condition. It is difficult to predict the full impact of the HKAA on Hong Kong and companies with operations in Hong Kong like us. Furthermore, legislative or administrative actions in respect to China-U.S. relations could cause investor uncertainty for affected issuers, including us, and the market price of our Ordinary Shares could be adversely affected.

The Hong Kong legal system embodies uncertainties that could limit the availability of legal protections.

Hong Kong is a Special Administrative Region of the PRC. Following British colonial rule from 1842 to 1997, China assumed sovereignty under the “one country, two systems” principle. The Hong Kong Special Administrative Region’s constitutional document, the Basic Law, ensures that the current political situation will remain in effect for 50 years. The laws previously in force in Hong Kong, that is, the common law, rules of equity, ordinances, subordinate legislation and customary law are maintained. Hong Kong has enjoyed the freedom to function with a high degree of autonomy for its affairs, including currencies, immigration and customs operations, and its independent judiciary system and parliamentary system. The Special Administrative Region of Hong Kong is responsible for its own domestic affairs including, but not limited to, the judiciary and courts of last resort, immigration and customs, public finance, currencies and extradition. Hong Kong continues using the English common law system.

On July 14, 2020, the United States signed an executive order to end the special status enjoyed by Hong Kong post-1997. As the autonomy currently enjoyed may be compromised, it could potentially impact Hong Kong’s common law legal system and may, in turn, bring about uncertainty in, for example, the enforcement of our contractual rights. This could, in turn, materially and adversely affect our business and operations. Additionally, intellectual property rights and confidentiality protections in Hong Kong may not be as effective as in the United States or other countries. Accordingly, we cannot predict the effect of future developments in the Hong Kong legal system, including the promulgation of new laws, changes to existing laws or the interpretation or enforcement thereof, or the pre-emption of local regulations by national laws. These uncertainties could limit the legal protections available to us, including our ability to enforce our agreements with our customers.

You may experience difficulties in effecting service of legal process, enforcing foreign judgments or bringing actions in Hong Kong against us or our management named in this prospectus based on Hong Kong laws.

Currently, all of our operations are conducted in Hong Kong outside the United States, and all of our assets are located outside the United States. All of our directors and officers are Hong Kong nationals or residents and a substantial portion of their assets are located in Hong Kong outside the United States. You may experience difficulties in effecting service of legal process, enforcing foreign judgments or bringing actions in Hong Kong against us or our management named in the prospectus, as judgments entered in the United States can be enforced in Hong Kong only at common law. If you want to enforce a judgment of the United States in Hong Kong, it must be a final judgment conclusive upon the merits of the claim, for a liquidated amount in a civil matter and not in respect of taxes, fines, penalties, or similar charges, the proceedings in which the judgment was obtained were not contrary to natural justice, and the enforcement of the judgment is not contrary to public policy of Hong Kong. Such a judgment must be for a fixed sum and must also come from a “competent” court as determined by the private international law rules applied by the Hong Kong courts. In addition, the PRC does not have treaties providing for the reciprocal recognition and enforcement of judgments of courts with the Cayman Islands and many other countries and regions. Therefore, recognition and enforcement in the PRC of judgments of a court in any of these non-PRC jurisdictions in relation to any matter not subject to a binding arbitration provision may be difficult or impossible. For more information regarding the relevant laws of the Cayman Islands and Hong Kong, see “Enforceability of Civil Liabilities.”

32

Table of Contents

Changes in international trade policies, trade disputes, barriers to trade, or the emergence of a trade war may dampen growth in Hong Kong, where the majority of our customers reside.

Political events, international trade disputes, and other business interruptions could harm or disrupt international commerce and the global economy, and they could have a material adverse effect on us and our customers, our service providers, and our other partners. International trade disputes could result in tariffs and other protectionist measures that may materially and adversely affect our business.

Tariffs could increase the cost of the services and products, which could affect customers’ investment decisions. In addition, political uncertainty surrounding international trade disputes and the potential of their escalation to trade war and global recession could have a negative effect on customer confidence, which could materially and adversely affect our business. We also may have access to fewer business opportunities, and our operations may be negatively impacted as a result. In addition, the current and future actions or escalations by either the United States or China that affect trade relations may cause global economic turmoil and potentially have a negative impact on our markets, our business, or our results of operations, as well as the financial condition of our clients, and we cannot provide any assurances as to whether such actions will occur or the form that they may take.

Risks Related to Our Business and Industry

If we are unable to accurately estimate the overall risks, revenues, or costs on our projects, we may incur contract losses or achieve lower than anticipated profits.

Pricing on a fixed unit price contract is based on approved quantities irrespective of our actual costs, and contracts with a fixed total price require that the work be performed for a single price irrespective of our actual costs. We only generate profits on fixed unit price and fixed total price contracts when our revenues exceed our actual costs, which requires us to accurately estimate our costs, to control actual costs, and to avoid cost overruns. If our cost estimates are too low or if we do not perform the contract within our cost estimates, then cost overruns may cause us to incur a loss or cause the contract not to be as profitable as we expected. The costs incurred and profit realized, if any, on our contracts can vary, sometimes substantially, from our original projections due to a variety of factors, including, but not limited to:

        the failure to include materials or work in a bid or the failure to estimate properly the quantities or costs needed to complete a fixed total price contract;

        delays caused by weather conditions or otherwise failing to meet scheduled acceptance dates;

        contract or project modifications or conditions creating unanticipated costs that are not covered by change orders;

        changes in the availability, proximity, and costs of materials, including liquid asphalt cement, aggregates, and other construction materials, as well as fuel and lubricants for our equipment;

        to the extent not covered by contractual cost escalators, variability, and inability to predict the costs of purchasing diesel, liquid asphalt, and cement;

        the availability and skill level of workers;

        the failure by our suppliers, subcontractors, designers, engineers, or customers to perform their obligations;

        fraud, theft, or other improper activities by our suppliers, subcontractors, designers, engineers, customers, or our own personnel;

        mechanical problems with machinery or equipment;

        difficulties in obtaining required government permits or approvals;

        changes in applicable laws and regulations;

        uninsured claims or demands from third parties for alleged damages arising from the design, construction, or use and operation of a project of which our work is part; and

        public infrastructure customers seeking to impose contractual risk-shifting provisions that result in our facing increased risks.

33

Table of Contents

These factors, as well as others, may cause us to incur losses, which could have a material adverse effect on our financial condition, results of operations, or liquidity.

We may be unable to obtain or maintain sufficient bonding capacity, which could materially adversely affect our business.

A significant number of our contracts require performance and payment bonds. Our ability to obtain performance and payment bonds primarily depends upon our capitalization, working capital, past performance, management expertise, reputation, and certain external factors, including the overall capacity of the surety market. If we are unable to renew or obtain a sufficient level of bonding capacity in the future, we may be precluded from being able to bid for certain projects or successfully contract with certain customers. In addition, even if we are able to successfully renew or obtain performance or payment bonds, we may be required to post letters of credit in connection with such bonds, which could negatively affect our liquidity and results of operations.

It is standard for sureties to issue or continue bonds on a project-by-project basis, and they can decline to do so at any time or require the posting of additional collateral as a condition thereto. Events that adversely affect the insurance and bonding markets generally may result in bonding becoming more difficult to or costly to obtain in the future. If we were to experience an interruption or reduction in the availability of our bonding capacity as a result of these or any other reasons, or if bonding costs were to increase, we may be unable to compete for certain projects that require bonding.

Design-build contracts subject us to the risk of design errors and omissions.

Design-build contracts are used as a method of project delivery that provides the owner with a single point of responsibility for both design and construction. We generally subcontract design responsibility to architectural and engineering firms. However, in the event of a design error or omission that causes damages, there is a risk that the subcontractor and/or its errors and omissions insurance would not be able to absorb the full amount of the liability incurred. In this case, we may be responsible for the liability, resulting in a potentially material adverse effect on our financial position, results of operations, cash flows, and liquidity.

We depend on third parties for equipment and supplies essential to operate our business.

We rely on third parties to sell or lease properties, machineries, and equipment to us and to provide us with supplies, including concrete, reinforced steel bars, and other construction materials (such as stone, gravel, and sand) necessary for our operations. We cannot assure you that our favorable working relationships with our suppliers will continue in the future. In addition, there have historically been periods of supply shortages in our industry. The inability to purchase or lease the properties, machineries, or equipment that are necessary for our operations could severely impact our business. If we lose our supply contracts and receive insufficient supplies from third parties to meet our customers’ needs, or if our suppliers experience price increases or disruptions to their business, such as labor disputes, supply shortages, or distribution problems, our business could be materially and adversely affected.

The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability.

In some instances, including in the case of many of our fixed unit price contracts, we guarantee that we will complete a project by a certain date. Any failure to meet contractual schedule or completion requirements set forth in our contracts could subject us to responsibility for costs resulting from the delay, generally in the form of contractually agreed-upon liquidated damages, liability for our customer’s actual costs arising out of our delay, reduced profits or a loss on that project, damage to our reputation, and a material adverse impact to our financial position.

Failure to maintain safe work sites could result in significant losses, which could materially affect our business and reputation.

Because our employees and others are often in close proximity with mechanized equipment, moving vehicles, chemical substances, and dangerous manufacturing processes, our construction and maintenance sites are potentially dangerous workplaces. Therefore, safety is a primary focus of our business and is critical to our reputation and performance. Many of our clients require that we meet certain safety criteria to be eligible to bid on contracts, and some of our contract fees or profits are subject to satisfying safety criteria. Unsafe work conditions also can increase employee turnover, which increases project costs and, therefore, our overall operating costs. If we fail to implement safety procedures or implement ineffective safety procedures, our employees could be injured, and we could be exposed to investigations and possible litigation. Our failure to maintain adequate safety standards through our safety programs could also result in reduced profitability or the loss of projects or clients.

34

Table of Contents

Our revenue mainly relies on successful tenders or acceptance of our quotations for construction projects that are non-recurring in nature, and any failure in securing projects from our existing customers and/or new customers in the future would affect our business operation and financial results.

We secure our construction projects mainly through a competitive tender or quotation process and were awarded each contract on a non-recurring basis. We do not have any long-term commitment with our customers, and our customers have no obligation to award any new projects to us. As such, we cannot assure that our existing customers or potential customers will invite us to participate in their tendering processes or submit quotations, or that we will be able to secure projects from them in the future. Upon completion of our contracts on hand, in the event that we are unable to receive new tender or quotation invitations or be awarded new contracts, our business in general and our results of operations and financial performance may be adversely and materially affected.

A significant portion of our revenue was generated from contracts awarded by a limited number of customers, and any significant decrease in the number of projects with our major customers may materially and adversely affect our financial condition and operating results.

A significant portion of our revenue was derived from a limited number of customers. Our five largest customers for the years ended March 31, 2023 and 2022, accounted for approximately 83.4% and 85.1% of our total revenue.

There is no assurance that we will continue to be awarded with contracts from our major customers in the future. If there is a significant decrease in the number of projects awarded by our major customers, and we are unable to secure suitable projects of comparable size and quantity as replacements from other customers, our financial condition and operating results would be materially and adversely affected. In addition, in the event that our major customers experience any financial difficulties or cash flow problems, this may result in delay or default in payments to us, in which case our business could be materially and adversely affected.

We may not be able to bill and receive the full amount of gross amounts due from customers for contract work, and our revenue may fluctuate due to variation orders.

Our revenue from construction contracts is recognized when our construction work performed is certified by the relevant customers and/or architects or consultants engaged by the customers. Gross amounts due from customers for contract work arise when progress billings have not yet taken place as at a financial period end date in respect to the construction work performed by us during that financial period. There is no assurance that we will be able to bill and receive the full amount of gross amounts due from our customers for contract work, as we may not be able to reach an agreement with the customers on the value of our work done. If we are not able to do so, our results of operation, liquidity, and financial position may be adversely affected.

Furthermore, the aggregate amount of revenue that we are able to derive from a project may deviate from the original contract sum specified in the relevant contract for the project due to variations (including addition, modification, or cancellation of certain contract work) instructed by our customers from time to time during the course of project execution. As such, there is no assurance that the amount of revenue derived from our projects will not be substantially different from the original contract sum as specified in the relevant contracts, and our financial condition may be adversely affected by any decrease in our revenue as a result of variation orders.

We rely on our subcontractors to help complete our projects and to supply the machinery required.

In line with the usual practice of the construction industry in Hong Kong, we engage third-party subcontractors to perform a portion of the work under our contracts instead of retaining a large pool of labor with different skill sets to maximize our cost efficiency and flexibility. We also rely on our subcontractors for supply of machinery required for carrying out of construction work. Our total subcontracting charges accounted for approximately 62.7% and 71.7% of our total cost of sales for the years ended March 31, 2023 and 2022.

Apart from the effect of any significant increase in the subcontracting costs that may impact our profitability, we may also be exposed to other legal liabilities if we are not able to monitor the performance of our subcontractors, or if our subcontractors violate any laws, rules, or regulations in relation to health and safety matters. We are further exposed to risks associated with any non-performance, delayed performance, or sub-standard performance by our subcontractors or their respective employees and may incur additional costs or be subject to liability due to delay

35

Table of Contents

in schedule or defect in the work of our subcontractors or if there is any accident-causing personal injuries or death to our subcontractors’ employees. These events may adversely impact our profitability, financial performance, and reputation, as well as result in litigation or damages claims.

In addition, our subcontractors may not always be readily available when our needs for subcontracting arise, and there is no assurance that we would be able to maintain good working relationships with our subcontractors in the future. Since we have not entered into any long-term service agreement with our subcontractors, they are not obliged to work for us in future projects on similar terms and conditions. There is no assurance that we would be able to find suitable alternative subcontractors that meet our project needs and requirements to complete the projects, which would in turn adversely affect our performance capacity and financial results.

Further, pursuant to the Employment Ordinance under Hong Kong law, a main contractor, or a main contractor and every superior subcontractor, is jointly and severally liable to pay any wages that become due to an employee who is employed by a subcontractor on any work that the subcontractor has contracted to perform, if such wages are not paid within the period specified in the Employment Ordinance. Our operations and, hence, our financial position may be adversely affected if any of our subcontractors violates its obligations to pay its employees.

As we from time to time engage subcontractors in our work, we may bear responsibilities for any non-performance, delayed performance, sub-standard performance, or non-compliance of our subcontractors.

We subcontract certain portions of our projects, such as piling construction, reinforcement fixing, concreting and design work, to our subcontractors who are independent third parties. Subcontracting may expose us to risks associated with non-performance, delayed performance, or sub-standard performance by our subcontractors. As a result, we may experience deterioration in the quality or delivery of our work, incur additional costs due to the delays, suffer a higher price in sourcing the services, equipment or supplies in default, or be subject to liability under the relevant projects. Such events could impact upon our profitability, financial performance, and reputation, or result in litigation or damage claims.

There is no assurance that we would be able to monitor the performance of our subcontractors as directly and efficiently as with our own staff. If our subcontractors fail to meet our requirements, we may experience delay in project completion, quality issues concerning the work done, or non-performance by subcontractors. Consequently, we may incur significant time and costs to carry out remedial actions, which would in turn adversely affect the profitability and reputation of our business and result in litigation or damage claims against us. If our subcontractors violate any laws, rules, or regulations, we may also be held liable for their violations and be subject to claims for losses and damages if such violations result in any personal injuries and/or property damages.

In addition, our subcontractors may not always be readily available whenever we need to engage them, and there is no assurance that we would be able to maintain good working relationships with our sub-contractors in the future. As at the date of this prospectus, we had not entered into any long-term service agreement with our subcontractors. Further, there is no assurance that we would be able to find suitable alternative subcontractors that meet our project needs and requirements to complete the projects, which would in turn adversely affect our operations and financial results.

There is no guarantee that safety measures and procedures implemented at our construction sites could prevent the occurrence of industrial accidents of all kinds, which in turn might lead to claims in respect to employees’ compensation, personal injuries, fatal accidents, and/or property damages against us.

We have adopted certain work safety measures and procedures for our staff and our subcontractors’ staff. We rely on our staff to oversee the implementation of safety measures and procedures, and we cannot guarantee that all of the safety measures and procedures are strictly adhered to at any time, nor can we assure you that our safety measures and procedures are sufficient to prevent the occurrence of industrial accidents of all kinds. If the safety measures and procedures implemented at our construction sites are insufficient or not strictly adhered to, it may result in industrial accidents that would in turn lead to claims in respect to employees’ compensation, personal injuries, fatal accidents, and/or property damage against us.

36

Table of Contents

We determine the price of our quotation or tender based on the estimated time and costs to be involved in a project and the actual time and costs incurred may deviate from our estimate due to unexpected circumstances, thereby leading to cost overruns and adversely affecting our operations and financial results.

We determine the price of our quotation or tender based on our estimated cost plus a certain mark-up margin. The actual time and costs incurred by us, however, may be adversely affected by various factors, including (i) the specifications, underground conditions, and difficulties of the project; (ii) the duration of the project; (iii) the site locations and the conditions and risk of adjacent building structures; (iv) unfavorable weather conditions; and (v) the resources availability. Significant changes in any of these or other relevant factors may lead to delay in completion or costs overrun by us, and there is no assurance that the actual time and costs incurred by us would match our initial estimate. As our contracts with customers were generally fixed-price contracts or re-measurement contracts for which our unit prices stated in the bill of quantities are fixed and without any price adjustment clause, once we agree on the quotation or tender price with our customer, we generally will have to bear any additional costs incurred. Such delays, cost overruns, or mismatch of actual time and costs with our estimates may cause our profitability to be lower than what we expected or may expose us to litigation or claims from customers in case of delays, thereby adversely affecting our operations and financial results.

Furthermore, the contracts we entered into normally contain specific completion schedule requirements and liquidated damages provisions (i.e., we may have to pay our customers liquidated damages if we or our subcontractors do not meet the schedules). Liquidated damages are typically levied at an agreed rate for each day of delay that is owing to our default. We may need to pay liquidated damages resulting from any failure to meet the completion schedule requirements of our contracts, to the extent that our customers do not grant us time extension. This may reduce or diminish our expected profit and cash inflow from the relevant contracts.

The geological conditions of construction sites are difficult to anticipate and may result in higher project expenses.

We are exposed to inherent project risk that the geological conditions of construction sites are difficult to be anticipated and unforeseen problems or circumstances may occur during project implementation. Site survey and geotechnical reports may not be sufficient to reveal precisely the actual geology beneath the construction site due to limitation in the scope of the underground investigation reports, and the investigation may not be able to reveal the existence of rocks or identify any antiquities, monuments, wartime bombs or structures beneath the site. All of these may present potential issues and uncertainties in carrying out our foundation work, such as the possible increase in the complexity of the project resulting from additional work procedures, workers, equipment, and time required to deal with any unexpected existence of rocks, antiquities, monuments, and wartime bombs, which may also lead to additional costs to be incurred. If such risk arises, the progress of our projects may be delayed and our project expenses may increase. As our construction contracts with customers are usually of a fixed sum or for re-measurement in accordance with our unit prices stated in the bills of quantities, which are fixed and without any price adjustment clause, we are subject to potential cost overruns and the subsequent adverse effect on our profitability.

There is no assurance that we can maintain the qualifications, licenses, and registrations for the operation of our construction business.

We are required to maintain certain qualifications, licenses, and registrations to conduct our construction business. To maintain such qualifications, licenses, or registrations, we must comply with the relevant requirements imposed by the relevant government departments of Hong Kong.

Further, the standards of compliance required may from time to time be subject to changes without substantial advance notice. We cannot assure you that all of the required qualifications, licenses, and registrations can be maintained or renewed in a timely manner or at all. If we fail to comply with any of the relevant requirements, our qualifications, licenses, or registrations could be temporarily suspended or revoked, or the renewal of our qualifications, licenses, or registrations upon expiry of their original terms may be delayed or refused. In such circumstances, our capability to undertake relevant work may be directly impacted, and our business may be materially and adversely affected.

We rely on the service of our Authorized Signatory(ies) and Technical Director for our registrations maintained with the Buildings Department of Hong Kong.

We maintain certain registrations with the Buildings Department of Hong Kong. In order to maintain such registrations, our Operating Subsidiary, Chiu & Lee Partners, must have at least one Authorized Signatory and one Technical Director to act for each of them for the purpose of the Buildings Ordinance and to carry out certain duties.

37

Table of Contents

The Building Authority of the Government of Hong Kong (the “Building Authority”) imposes certain requirements on the qualifications experience of such Authorized Signatory and Technical Director. Departure or loss or disqualification of the Authorized Signatory(ies) or Technical Director(s) may result in suspension of our registrations maintained with the Buildings Department of Hong Kong if no suitable replacement is identified and application to replace the position is made. In the event that we cannot maintain at least one Authorized Signatory and one Technical Director due to the departure or loss or disqualification of the abovementioned personnel and we cannot identify and recruit staff with adequate qualifications and experience eligible to become an Authorized Signatory or Technical Director in a timely manner, our registrations maintained with the Buildings Department of Hong Kong could be suspended or even revoked. In such event, our reputation, business operation, and financial position may be materially and adversely affected.

Cash inflows and outflows in connection with construction projects may be irregular and, thus, may affect our net cash flow position.

In a construction project, cash outflows for payment of certain operating expenditures may not align with progress payments to be received during the relevant periods. In general, we do not receive any prepayment from our customers. Nevertheless, during the commencement of a project, we may incur various costs, including: (i) purchase costs of construction materials and supplies, (ii) rental costs for machinery, and (iii) settlement of our workers’ salaries and our subcontractors’ fees, while progress payments will be paid after our construction work commences and is certified by our customers and/or architects or consultants engaged by our customers. Accordingly, the cash inflows and outflows for a particular project may fluctuate as the construction work progresses. If, during any particular period of time, there exists too many projects that require substantial cash outflow while we have significantly less cash inflows during that period, our cash flow position may be adversely affected.

Further, we are subject to credit risks of our customers and our liquidity is dependent on our customers making prompt progress payments and/or release of retention monies due to us. We rely on cash inflow from our customers to meet our payment obligation to our suppliers and subcontractors, which is dependent on prompt settlement of progress payment and timely release of retention monies by our customers. As such, we may record a significant cash outflow in the event that we take up too many capital-intensive projects during a particular period of time.

We cannot assure you that we will be able to recover all or any part of the amounts due from our customers or we will be able to collect all or any part of the trade receivables from our customers within the agreed credit terms or at all. Further, in the event that disputes arise between us and the main contractor or customer in relation to the variation orders, there is a possibility that we may take a longer time than the credit period offered to collect payments. Any failure by our customers to make payments on time and in full may lead to mismatch in our cash flows, which will negatively affect our cash flow position and affect (i) our ability to repay our suppliers and subcontractors; and (ii) our tendering decisions, as we may not be in a position to take up any more new projects with a high upfront costs. This will negatively affect our business operation and financial performance.

We may be liable for damage caused to underground service utilities and infrastructures and/or foundations of aged buildings adjacent to the construction sites where we carry out our construction projects.

When we carry out work in our construction projects, we may encounter storm water and foul water drains, fresh and flush water mains, electric cables, telephone and Internet cables, cable television wire, gas mains, and other services utilities and infrastructures that are laid underground or below carriageways and footways. If damage is made to these services utilities during our work, we may be liable for the costs of repair of such utilities and the relevant remedial work will increase our costs for the projects and may cause delay in our project schedule. Further, there may be some aged buildings adjacent to the construction sites where we carry out our construction projects, and we may be required to revise our project plan to avoid excessive settlement or vibration that may cause damage to adjacent structures. As such, this may lead to delay of our projects and incur additional costs in our construction.

Claims in connection with employees’ compensation or personal injuries may arise and affect our reputation and operations.

Injuries to workers and casualties at construction sites are a common inherent risk in the construction industry. Claims of such nature expose us to the risk of bearing higher insurance premiums in the future and may damage our reputation as a main contractor if they turn into high-profile cases and become widely reported in the media or within the industry. Such incidents may negatively affect our business prospects, reputation, and results of operations.

38

Table of Contents

We face keen competition from other players in the market.

The construction industry in Hong Kong is competitive. As of November 14, 2022, there were 154, 120, and 208 contractors registered under Buildings Department of Hong Kong’s register of Specialist Contractors with sub-register of the foundation work category, demolition work category, and site formation work category, respectively, and 804 contractors registered under Buildings Department’s register of general building contractors. Some of our competitors may have certain advantages, including stronger brand names, greater access to capital, longer operating history, longer and more established relationship with main contractors or project owners, and greater marketing and other forms of resources. Further, some of the existing market players have been listed on the stock exchange, which may give them an advantage in terms of financing capability and reputation. New participants may enter the industry, provided that they possess all the various licenses, resources, experience, and qualifications required. Increased competition may result in lower operating margins and loss of market share, resulting in an adverse impact on our profitability and operating results.

Any deterioration in the prevailing market conditions in the construction industry may adversely affect our performance and financial condition.

All our business operations are located in Hong Kong. Our direct customers are primarily property developers and main contractors of various types of property development and civil engineering projects in Hong Kong. The number of projects awarded to us depend highly on the prevailing market conditions in the construction industry, including shortage of skilled labor, economic fluctuations in Hong Kong, availability of new projects in the private sector; and general conditions and development of Hong Kong economy. If there is any significant deterioration in any of these factors, our operating results and financial conditions could be adversely affected.

We are dependent on our key executives, management team, and professional staff.

Our success and growth depend on the knowledge, experience, and expertise of our management team who is responsible for overseeing the financial condition and performance, construction projects, and formulating business strategies. For example, Mr. Keung Yun Yuen and Mr. Chan Lee Chuen, our directors, each has approximately 30 years of experience in the construction industry.

As we focus on various work scopes, including the overall management of the projects, the planning, and the devising of detailed work programs, design, and technical submissions, it is important for us to retain our management staff and technical personnel with appropriate and necessary industry expertise. We have entered into a service agreement with each of our directors and employment contracts with our senior management and technical personnel. These service agreements and employment contracts can be terminated by either the Company or our directors or employees. There could be an adverse impact on our operations should a significant number of our directors, senior management, or other key personnel with relevant expertise terminate his or her employment with us and appropriate persons could not be found to replace them in a timely manner. There is no assurance that we will be able to attract and retain capable staff members or that they will not resign in the future.

We may be unable to obtain sufficient funding on terms acceptable to us, or at all.

The future expansion of our business may require us to incur additional borrowings and diversify sources of funding. Whether we are able to raise additional capital at costs acceptable to us depends on the financial success of our current business and the successful implementation of our key strategic initiatives. This may be affected by various financial, economic, and market conditions and other factors, some of which are beyond our control. If we are unable to obtain sufficient banking facilities on acceptable terms to meet our operational and expansion demands, this may put strains on our cash flow and our ability to successfully implement our expansion plans.

Our insurance coverage may be inadequate to protect us from potential losses.

For construction projects where we act as the main contractor, we take out employees’ compensation insurance and contractors’ all-risk insurance, which cover our and our subcontractors’ employees, and the work performed by us and them. Similarly, where we undertake the role of subcontractor in a project, we are covered by the employees’ compensation insurance and contractors’ all-risk insurance taken out by the project’s main contractor.

Nonetheless, there is no assurance that all potential losses and expenses incurred from damages or liabilities in relation to our business can be fully covered by the insurance taken out by us. To the extent that our insurance does not cover such losses, damage, or liabilities, the resulting payment to cover such losses, damage, or liabilities may have a material adversely effect on our business.

39

Table of Contents

We may be subject to litigation, arbitration, or other legal proceeding risk.

We may be subject to arbitration claims and lawsuits in the ordinary course of our business. As of the date of this prospectus, the Company, Orange Space, and Chiu & Lee Partners are not a party to, and are not aware of any threat of, any legal proceeding that, in the opinion of our management, is likely to have a material adverse effect on our business, financial condition, or operations. Actions brought against us may result in settlements, awards, injunctions, fines, penalties, and other results adverse to us. A substantial judgment, settlement, fine, or penalty could be material to our operating results or cash flows for a particular period, depending on our results for that period, or could cause us significant reputational harm, which could harm our business prospects.

We rely on our customers and subcontractors for the provision of machinery and equipment at construction sites.

Our foundation work and site formation projects can be generally regarded as machinery-intensive work. As such, our ability to handle existing projects or compete for new projects highly depends on the number of machinery and equipment available for deployment at construction sites. As of the date of this prospectus, the machinery and equipment are limited, and we mainly rely on our customers and our subcontractors to procure the machinery. As such, we may be unable to procure and/or handle further projects should we fail to identify suitable machinery and equipment.

Nevertheless, there can be no assurance that we would be able to rent a sufficient number of machinery at reasonable costs and in a timely manner, nor we can guarantee that they would function properly at all material times and they would not become obsolete as a result of technological developments in the construction industry. We can also not guarantee that our customers and subcontractors can arrange immediate repair and/or replacement for impaired machinery and equipment for our projects in a timely and cost-effective manner.

As a result, we may not be able to expand our capacity successfully in order to cope with the increasing demands expected from future projects. If we fail to do so, our ability to handle existing projects or compete for new projects may be significantly impaired.

We rely on a stable workforce to carry out our construction projects. If we or our subcontractors experience any shortage of labor, industrial actions, strikes, or material increase in labor costs, our operations and financial results would be adversely affected.

We rely on a stable workforce, either directly employed by us or our subcontractors, to carry out our construction projects. In particular, a large number of construction workers and machinery operators with various skills and expertise are required for each construction project.

The economy in Hong Kong and globally has experienced general increases in inflation and labor costs in recent years. As a result, average wages in Hong Kong and certain other regions are expected to continue to increase. In addition, we are required by Hong Kong laws and regulations to pay various statutory employee benefits, including making contributions for and in respect of the employees to a mandatory provident fund scheme for the benefit of our employees. We expect that our labor costs, including wages and employee benefits, will continue to increase.

In view of the current situation in the labor market, there is no assurance that the supply of labor and average labor costs will be stable. All labor-intensive projects are more susceptible to labor shortage, and our subcontracting costs include the labor costs of our subcontractors. If there is a significant increase in the costs of labor and we have to retain our labor (or our subcontractors retain their labor) by increasing their wages, our staff cost and/or subcontracting cost will increase and thus lower our profitability. On the other hand, if we or our subcontractors fail to retain our existing labor and/or recruit sufficient labor in a timely manner to cope with our existing or future projects, we may not be able to complete our projects on schedule and may be subject to liquidated damages and/or incur a loss.

We may be unable to successfully implement our future business plans and objectives.

Our future business plans may be hindered by factors beyond our control, such as competition within the industry we operate; our ability to cope with high exposure to financial risk, operational risk, market risk, and credit risk as our business and customer base expands; and our ability to provide, maintain, and improve the level of human and other resources in servicing our customers. As such, we cannot assure that our future business plans will materialize, that our objectives will be accomplished fully or partially, or that our business strategies will generate the intended benefits to us as initially contemplated. If we fail to implement our business development strategies successfully, our business performance could be materially and adversely affected.

40

Table of Contents

We may in the future pursue acquisitions and joint ventures as part of our growth strategy. Any future acquisition or joint venture may result in exposure to potential liabilities of the acquired companies and significant transaction costs, and it may also present new risks associated with entering additional markets or offering new products or services and integrating the acquired companies or newly established joint ventures. Moreover, we may not have sufficient management, financial, and other resources to integrate companies we acquire or to successfully operate joint ventures, and we may be unable to profitably operate our expanded company structure. Additionally, any new business that we may acquire or joint ventures we may form, once integrated with our existing operations, may not produce expected or intended results.

A sustained outbreak of the COVID-19 pandemic could have a material adverse impact on our business, operating results, and financial condition.

Since late December 2019, the outbreak of COVID-19 spread rapidly throughout China and later to the rest of the world. On January 30, 2020, the International Health Regulations Emergency Committee of the World Health Organization declared the outbreak a PHEIC, and later, on March 11, 2020, a global pandemic. The COVID-19 outbreak has led governments across the globe to impose a series of measures intended to contain its spread, including border closures, travel bans, quarantine measures, social distancing, and restrictions on business operations and large gatherings. From 2020 to the middle of 2021, a COVID-19 vaccination program had been greatly promoted around the globe; however, several types of COVID-19 variants emerged in different parts of the world.

Supply chain disruptions have become a major challenge for the global economy since the start of the COVID-19 pandemic. For instance, China’s extended COVID-19 lockdown of Shanghai, a major port and business center, has led to logistical disruptions that have almost cause the transport of goods to be ground to a halt. These shortages and supply-chain disruptions are significant and widespread. Lockdowns in several countries across the world, labor shortages, robust demand for tradable goods, disruptions to logistics networks, and capacity constraints have resulted in increases in freight costs and delivery times. Companies that are reliant on the movement of goods and materials, such as our Company, which relies on construction materials, may suffer from plant closures and supply shortages across the extended supply network.

In addition, multiple infected cases within a construction site may result in shortage of labor and, in more serious cases, may cause a temporary halt in the site’s construction operation for a few days. Hence, our productivity and progress may also be negatively affected.

We, our customers, subcontractors, and suppliers have not experienced any material suspensions or cancellations of our projects due to the COVID-19 outbreak during the years ended March 31, 2022 and 2021. Any future impact on our results of operations will depend on, to a large extent, future developments and new information that may emerge regarding the duration and severity of the COVID-19 pandemic and the actions taken by government authorities and other entities to contain the spread or treat its impact, almost all of which are beyond our control. Given the general slowdown in economic conditions globally and volatility in the capital markets, as well as the general negative impact of the COVID-19 outbreak on the construction industry, we cannot assure you that we will be able to maintain the growth rate we have experienced or projected. We will continue to closely monitor the situation throughout 2023 and beyond.

A severe or prolonged downturn in the global economy, whether caused by economic or political instability, could materially and adversely affect our business and results of operations.

The recent global market and economic crisis stemming from COVID-19 resulted in recessions occurring in most major economies. The International Monetary Fund forecasts global gross domestic product to weaken from 5.9% in 2021 to 4.4% in 2022. Continued concerns about the systemic impact of potential long-term and widespread recession, energy costs, geopolitical issues, sovereign debt issues, COVID-19 and new variants thereof, and the availability and cost of credit have contributed to increased market volatility and diminished expectations for economic growth around the world. The difficult economic outlook has negatively affected businesses and consumer confidence and contributed to significant volatility.

There is continuing uncertainty over the long-term effects of the expansionary monetary and fiscal policies adopted by the central banks and financial authorities of some of the world’s leading economies, including Hong Kong’s. There have also been concerns over unrest in several geographic areas, which may result in significant

41

Table of Contents

market volatility. Any prolonged slowdown in the global and/or Hong Kong economy may have a negative impact on our business, results of operations, and financial condition, and continued turbulence in the international markets may adversely affect our ability to access the capital markets to meet liquidity needs.

Our business is conducted solely in Hong Kong and is therefore heavily dependent on the economy of Hong Kong. Economic conditions in Hong Kong are highly sensitive to global cycle and money flows. If there is any significant decline in the Hong Kong economy and we are unable to generate business in other geographic locations, our profitability and business prospects will be materially affected. Also, major market disruptions and adverse changes in market conditions and uncertainty in the regulatory climate worldwide may adversely affect our business and industry or impair our ability to borrow or make any future financial arrangements.

The credit and financial markets have experienced extreme volatility and disruptions due to the current conflict between Ukraine and Russia, and the uncertain resolution of this conflict could result in protracted and/or severe damage to the global economy. The conflict is expected to have further global economic consequences, including but not limited to the possibility of severely diminished liquidity and credit availability, declines in consumer confidence, declines in economic growth, increases in inflation rates and uncertainty about economic and political stability. The extent and duration of the military action, sanctions, and resulting market disruptions are impossible to predict, but they could be substantial, even though we do not have any direct exposure to Russia or the adjoining geographic regions. Prolonged unrest, intensified military activities, or more extensive sanctions impacting the regions could have a material adverse effect on the global economy, and such effect could in turn have a material adverse effect on the business outlook of our business.

Risks Related to Our Ordinary Shares

There has been no public market for our Ordinary Shares prior to this offering; if an active trading market does not develop, you may not be able to resell our Ordinary Shares at any reasonable price.

The offering under this prospectus is an IPO of our Ordinary Shares. Prior to the closing of the offering, there was no public market for our Ordinary Shares. While we plan to list our Ordinary Shares on the Nasdaq Capital Market, our listing application may not be approved. If our application to the Nasdaq Capital Market is not approved or we otherwise determine that we will not be able to secure the listing of the Ordinary Shares on the Nasdaq Capital Market, we will not complete the offering. In addition, an active trading market may not develop following the closing or, if developed, may not be sustained. The lack of an active market may impair your ability to sell your Ordinary Shares at the time you wish to sell them or at a price that you consider reasonable. An inactive market may also impair our ability to raise capital by selling Ordinary Shares and may impair our ability to acquire other companies by using our Ordinary Shares as consideration.

The trading price of our Ordinary Shares may be volatile, which could result in substantial losses to you.

The trading prices of our Ordinary Shares are likely to be volatile and could fluctuate widely due to factors beyond our control. This may happen due to broad market and industry factors, such as performance and fluctuation in the market prices or underperformance or deteriorating financial results of other listed companies based in Hong Kong and China. The securities of some of these companies have experienced significant volatility since their IPOs, including, in some cases, substantial price declines in the trading prices of their securities. The trading performances of other Hong Kong and Chinese companies’ securities after their offerings may affect the attitudes of investors toward Hong Kong-based, U.S.-listed companies, which consequently may affect the trading performance of our Ordinary Shares, regardless of our actual operating performance. In addition, any negative news or perceptions about inadequate corporate governance practices or fraudulent accounting, corporate structure, or matters of other Hong Kong and Chinese companies may also negatively affect the attitudes of investors toward Hong Kong and Chinese companies in general, including us, regardless of whether we have conducted any inappropriate activities. Furthermore, securities markets may from time to time experience significant price and volume fluctuations that are unrelated to our operating performance, which may have a material and adverse effect on the trading price of our Ordinary Shares.

42

Table of Contents

In addition to the above factors, the price and trading volume of our Ordinary Shares may be highly volatile due to multiple factors, including the following:

        regulatory developments affecting us or our industry;

        variations in our revenues, profit, and cash flow;

        changes in the economic performance or market valuations of other financial services firms;

        actual or anticipated fluctuations in our quarterly results of operations and changes or revisions of our expected results;

        changes in financial estimates by securities research analysts;

        detrimental negative publicity about us, our services, our officers, directors, Controlling Shareholder, our business partners, or our industry;

        announcements by us or our competitors of new service offerings, acquisitions, strategic relationships, joint ventures, capital raisings, or capital commitments;

        additions to or departures of our senior management;

        litigation or regulatory proceedings involving us, our officers, directors, or Controlling Shareholder;

        release or expiry of lock-up or other transfer restrictions on our outstanding Ordinary Shares; and

        sales or perceived potential sales of additional Ordinary Shares.

Any of these factors may result in large and sudden changes in the volume and price at which our Ordinary Shares will trade. In the past, shareholders of public companies have often brought securities class action suits against those companies following periods of instability in the market price of their securities. If we were involved in a class action suit, it could divert a significant amount of our management’s attention and other resources from our business and operations and require us to incur significant expenses to defend the suit, which could harm our results of operations. Any such class action suit, whether or not successful, could harm our reputation and restrict our ability to raise capital in the future. In addition, if a claim is successfully made against us, we may be required to pay significant damages, which could have a material adverse effect on our financial condition.

We rely on dividends and other distributions on equity paid by our subsidiaries to fund our cash and financing requirements, and any limitation on the ability of our subsidiaries to make payments to us could have a material adverse effect on our ability to conduct our business.

CKHL is a holding company, and we rely on dividends and other distributions on equity paid by our subsidiaries for our cash and financing requirements, including the funds necessary to pay dividends and other cash distributions to our shareholders and to service any debt we may incur. We do not expect to pay cash dividends in the foreseeable future. We anticipate that we will retain any earnings to support operations and to finance the growth and development of our business. If any of our subsidiaries incurs debt on its own behalf in the future, the instruments governing the debt may restrict its ability to pay dividends or make other distributions to us.

According to the BVI Business Companies Act 2004 (as amended), a BVI company may make dividends distribution to the extent that immediately after the distribution, the value of the company’s assets exceeds its liabilities and that such company is able to pay its debts as they fall due. According to the Companies Ordinance of Hong Kong, a Hong Kong company may only make a distribution out of profits available for distribution. Under the current practice of the Inland Revenue Department of Hong Kong, no tax is payable in Hong Kong in respect to dividends paid by us. Any limitation on the ability of our Hong Kong subsidiary to pay dividends or make other distributions to us could materially and adversely limit our ability to grow, make investments or acquisitions that could be beneficial to our business, pay dividends, or otherwise fund and conduct our business.

Any limitation on the ability of our subsidiaries to pay dividends or make other distributions to us could materially and adversely limit our ability to grow, make investments or acquisitions that could be beneficial to our business, pay dividends, or otherwise fund and conduct our business.

43

Table of Contents

Our lack of effective internal controls over financial reporting may affect our ability to accurately report our financial results or prevent fraud, which may affect the market for and price of our Ordinary Shares.

Prior to filing the registration statement of which this prospectus is a part, we were a private company with limited accounting personnel and other resources for addressing our internal control over financial reporting. Our management has not completed an assessment of the effectiveness of our internal control over financial reporting, and our independent registered public accounting firm has not conducted an audit of our internal control over financial reporting. As of March 31, 2023, we have identified certain material weakness in our internal control over financial reporting. As defined in the standards established by the PCAOB, a “material weakness” is a deficiency, or a combination of deficiencies, in internal control over financial reporting, such that there is a reasonable possibility that a material misstatement of our annual or interim financial statements will not be prevented or detected on a timely basis. The material weaknesses identified related to (i) inadequate segregation of duties for certain key functions due to limited staff and resources, and (ii) a lack of independent directors and an audit committee. We intend to implement measures designed to improve our internal control over financial reporting to address the underlying causes of these material weaknesses, including (i) hiring more qualified staff to fill the key roles in the operations, and (ii) appointing independent directors, establishing an audit committee, and strengthening corporate governance. We intend to implement the above measures prior to the listing, and we expect the remediation to be completed upon listing.

We will be subject to the requirement that we maintain internal controls and that management perform periodic evaluation of the effectiveness of our internal controls. Effective internal control over financial reporting is important to prevent fraud. As a result, our business, financial condition, results of operations, and prospects, as well as the market for and trading price of our Ordinary Shares, may be materially and adversely affected if we do not have effective internal controls. We may not discover any problems in a timely manner, and in such an event, our shareholders could lose confidence in our financial reporting, which would harm our business and the trading price of our Ordinary Shares. The absence of internal controls over financial reporting may inhibit investors from purchasing our Ordinary Shares and may make it more difficult for us to raise funds in debt or equity financing. Additional material weaknesses or significant deficiencies may be identified in the future. If we identify such issues or if we are unable to produce accurate and timely financial statements, our stock price may decline and we may be unable to maintain compliance with the Nasdaq Listing Rules.

Our Ordinary Shares are expected to initially trade under $5.00 per share and thus would be known as a “penny stock.” Trading in penny stocks has certain restrictions, and these restrictions could negatively affect the price and liquidity of our Ordinary Shares.

Our share is expected to initially trade below $5.00 per share. As a result, our share would be known as a “penny stock,” which is subject to various regulations involving disclosures to be given to you prior to the purchase of any penny stock. The SEC has adopted regulations that generally define a “penny stock” to be any equity security that has a market price of less than $5.00 per share, subject to certain exceptions. Depending on market fluctuations, our Ordinary Shares could be considered to be “penny stock.” A penny stock is subject to rules that impose additional sales practice requirements on broker/dealers who sell these securities to persons other than established Members and accredited investors. For transactions covered by these rules, the broker/dealer must make a special suitability determination for the purchase of these securities. In addition, a broker/dealer must receive the purchaser’s written consent to the transaction prior to the purchase and must also provide certain written disclosures to the purchaser. Consequently, the “penny stock” rules may restrict the ability of broker/dealers to sell our Shares, and they may negatively affect the ability of holders of our Shares to resell them. These disclosures require you to acknowledge that you understand the risks associated with buying penny stocks and that you can absorb the loss of your entire investment. Penny stocks generally do not have a very high trading volume. Consequently, the price of the stock is often volatile, and you may not be able to buy or sell the stock at any time.

If we fail to meet applicable listing requirements, Nasdaq may delist our Ordinary Shares from trading, in which case the liquidity and market price of our Ordinary Shares could decline.

Assuming our shares are listed on Nasdaq, we cannot assure you that we will be able to meet the continued listing standards of Nasdaq in the future. If we fail to comply with the applicable listing standards and Nasdaq delists our Ordinary Shares, we and our shareholders could face significant material adverse consequences, including:

        a limited availability of market quotations for our Ordinary Shares;

        reduced liquidity for our Ordinary Shares;

44

Table of Contents

        a determination that our Ordinary Shares are “penny stock,” which would require brokers trading in our Ordinary Shares to adhere to more stringent rules and possibly result in a reduced level of trading activity in the secondary trading market for our Ordinary Shares;

        a limited amount of news about us and analyst coverage of us; and

        a decreased ability for us to issue additional equity securities or obtain additional equity or debt financing in the future.

The U.S. National Securities Markets Improvement Act of 1996 prevents or pre-empts the states from regulating the sale of certain securities, which are referred to as “covered securities.” Because we expect that our shares will be listed on Nasdaq, such securities will be covered securities. Although the states are pre-empted from regulating the sale of our securities, this statute does allow the states to investigate companies if there is a suspicion of fraud, and, if there is a finding of fraudulent activity, then the states can regulate or bar the sale of covered securities in a particular case. Further, if we were no longer listed on Nasdaq, our securities would not be covered securities and we would be subject to regulations in each state in which we offer our securities.

If you purchase our Ordinary Shares in this offering, you will incur immediate and substantial dilution in the book value of your shares.

If you purchase shares in this offering, you will pay substantially more than our net tangible book value per share. As a result, you will experience immediate and substantial dilution of US$3.14 per share, representing the difference between our pro forma as adjusted net tangible book value per share of US$0.86 as of March 31, 2023, after giving effect to the net proceeds to us from this offering, assuming no change to the number of shares offered by us as set forth on the cover page of this prospectus, and an assumed public offering price of US$4.00 per share. See “Dilution” for a more complete description of how the value of your investment in our shares will be diluted upon the completion of this offering.

If a limited number of participants in this offering purchase a significant percentage of the offering, the effective public float may be smaller than anticipated and the price of our Ordinary Shares may be more volatile than it otherwise would be.

As a company conducting a relatively modest public offering, we are subject to the risk that a small number of investors may hold a high percentage of Ordinary Shares sold in this offering, even if the initial sales by the underwriters are designed to comply with the Nasdaq listing requirements. If this were to happen, investors could find our shares to be more volatile than they might otherwise anticipate. Companies that experience such volatility in their stock price may be more likely to be the subject of securities litigation. In addition, if a large portion of our public float were to be held by a few investors, smaller investors may find it more difficult to sell their shares and we may cease to meet the Nasdaq public stockholder requirements.

Our directors, officers, and principal shareholders have significant voting power and may take actions that may not be in the best interests of our other shareholders.

As of the date of this prospectus, our directors, officers, and principal shareholders hold in aggregate 90.2% or more of our shares. After this offering, our directors, officers, and principal shareholders will hold in aggregate 78.1% or more of our shares. We will be a “controlled company” as defined under the Nasdaq Stock Market Rules because, immediately after the completion of this offering, our Controlling Shareholder will own 78.1% of our total issued and outstanding Ordinary Shares, representing 78.1% of the total voting power, assuming that the underwriters do not exercise their over-allotment option.

The interests of these shareholders may not be the same as or may even conflict with your interests. For example, these shareholders could attempt to delay or prevent a change in control of us, even if such change in control would benefit our other shareholders, which could deprive our shareholders of an opportunity to receive a premium for their Ordinary Shares as part of a sale of us or our assets and might affect the prevailing market price of our Ordinary Shares due to investors’ perceptions that conflicts of interest may exist or arise. As a result, this concentration of ownership may not be in the best interests of our other shareholders.

45

Table of Contents

Our board of directors may decline to register the transfer of Ordinary Shares in certain circumstances.

Our board of directors may under certain circumstances decline to register a transfer including but not limited to, any Ordinary Share which is not fully paid up or on which we have a lien, failure of the shareholder or any person proposing to acquire our shares to provide sufficient information to show the right to make the transfer, or if our board of directors has reason to believe that any certification or other information provided pursuant to any such request is inaccurate or incomplete.

Our board of directors may also decline to recognize any instrument of transfer of any Ordinary Share unless (i) a fee of such maximum as Nasdaq may from time to time determine to be payable (or such lesser sum as our board of directors may from time to time require) has been paid to our Company; (ii) the instrument of transfer is lodged at the registered office of our Company or, as the case may be, the transfer office of our Company accompanied by the certificate of the Ordinary Shares to which it relates, and such other evidence as our board of directors may reasonably require to show the right of the transferor to make the transfer (and, if the instrument of transfer is executed by some other person on his behalf, the authority of that person so to do); (iii) the instrument of transfer is in respect of only one class of share of our Company; (iv) the shares of our Company concerned are free of any lien in favor of our Company; and (v) if applicable, the instrument of transfer is properly stamped. Although unlikely, where our board of directors made their decision to refuse or delay to register a transfer of Ordinary Shares, dissident investors could be exposed to significant, including, but not limited to, legal and financial risks, without any guarantee of acquiring the contested Ordinary Shares. Litigation is time-consuming, expensive, and complex and may harm the Company’s reputation, which may in turn destroy or impair the value of the Ordinary Shares. Generally, courts have been reluctant to interfere with the directors’ exercise of discretion, and the applicant would bear the burden of proving that the application is well-founded.

If our board of directors shall refuse to register a transfer of any Ordinary Share, it shall, within two months after the date on which the transfer was lodged with our Company, send to each of the transferor and the transferee notice of such refusal and, except where the subject Ordinary Share is not a fully paid Ordinary Share, the reason(s) for such refusal. The registration of transfers of shares or of any class of shares of or Company may, after compliance with any notice requirement of Nasdaq, be suspended at such times and for such periods (not exceeding in the whole thirty (30) days in any year) as our board of directors may determine.

This, however, is unlikely to affect market transactions of the Ordinary Shares purchased by investors in the public offering. Once the Ordinary Shares have been listed, the legal title to such Ordinary Shares and the registration details of those Ordinary Shares in the Company’s register of members will remain with the Depository Trust Company. All market transactions with respect to those Ordinary Shares will then be carried out without the need for any kind of registration by the directors, as the market transactions will all be conducted through the Depository Trust Company systems.

Because the amount, timing, and whether or not we distribute dividends at all is entirely at the discretion of our board of directors, you must rely on price appreciation of our Ordinary Shares for return on your investment.

Our board of directors has complete discretion as to whether to distribute dividends. In addition, our shareholders may by ordinary resolution declare a dividend, but no dividend may exceed the amount recommended by our board of directors. In either case, all dividends are subject to certain restrictions under Cayman Islands law, namely that the Company may only pay dividends out of profits or share premium and provided that under no circumstances may a dividend be paid if this would result in the Company being unable to pay its debts as they fall due in the ordinary course of business. Even if our board of directors decides to declare and pay dividends, the timing, amount, and form of future dividends, if any, will depend on, among other things, our future results of operations and cash flow; our capital requirements and surplus; the amount of distributions, if any, received by us from our subsidiaries; and our financial condition, contractual restrictions, and other factors deemed relevant by our board of directors. Accordingly, the return on your investment in our Ordinary Shares will likely depend entirely upon any future price appreciation of our Ordinary Shares. We cannot assure you that our Ordinary Shares will appreciate in value after this offering or even maintain the price at which you purchased the Ordinary Shares. You may not realize a return on your investment in our Ordinary Shares, and you may even lose your entire investment in our Ordinary Shares.

46

Table of Contents

Our management has broad discretion to determine how to use the funds raised in the offering and may use them in ways that may not enhance our results of operations or the price of our Ordinary Shares.

We anticipate that we will use the net proceeds from this offering for our construction business and other corporate purposes. Our management will have significant discretion as to the use of the net proceeds to us from this offering and could spend the proceeds in ways that do not improve our results of operations or enhance the market price of our Ordinary Shares.

Our disclosure controls and procedures may not prevent or detect all errors or acts of fraud.

Upon the closing of this offering, we will become subject to the periodic reporting requirements of the Exchange Act. We will design our disclosure controls and procedures to provide reasonable assurance that information we must disclose in reports we file or submit under the Exchange Act is accumulated and communicated to management, and recorded, processed, summarized, and reported within the time periods specified in the rules and forms of the SEC. We believe that any disclosure controls and procedures, no matter how well-conceived and operated, can provide only reasonable, not absolute, assurance that the objectives of the control system are met.

These inherent limitations include the realities that judgments in decision-making can be faulty and that breakdowns can occur because of simple errors or mistakes. Additionally, controls can be circumvented by the individual acts of a person, by collusion of two or more people or by an unauthorized override of the controls. Accordingly, because of the inherent limitations in our control system, misstatements due to error or fraud may occur and not be detected.

We do not intend to pay dividends for the foreseeable future.

We currently intend to retain any future earnings to finance the operation and expansion of our business, and we do not expect to declare or pay any dividends in the foreseeable future. As a result, you may only receive a return on your investment in our Ordinary Shares if the market price of our Ordinary Shares increases. Our board of directors has complete discretion as to whether to distribute dividends, subject to certain requirements of Cayman Islands law. In addition, our shareholders may by ordinary resolution declare a dividend, but no dividend may exceed the amount recommended by our directors.

Securities analysts may not publish favorable research or reports about our business or may publish no information at all, which could cause our Ordinary Share price or trading volume to decline.

If a trading market for our shares develops, the trading market will be influenced to some extent by the research and reports that industry or financial analysts publish about us and our business. We do not control these analysts. As a new public company, we may be slow to attract research coverage and the analysts who publish information about our Ordinary Shares will have had relatively little experience with us or our industry, which could affect their ability to accurately forecast our results and could make it more likely that we fail to meet their estimates. In the event we obtain securities or industry analyst coverage, if any of the analysts who cover us provide inaccurate or unfavorable research or issue an adverse opinion regarding our share price, our share price could decline. If one or more of these analysts cease coverage of us or fail to publish reports covering us regularly, we could lose visibility in the market, which in turn could cause our share price or trading volume to decline and result in the loss of all or a part of your investment in us.

Certain judgments obtained against us by our shareholders may not be enforceable.

We are a company incorporated under the laws of the Cayman Islands. We conduct our operations outside the United States and substantially all of our assets are located outside the United States. In addition, substantially all of our directors and executive officers and the experts named in this prospectus reside outside the United States, and most of their assets are located outside the United States. As a result, it may be difficult or impossible for you to bring an action against us or against them in the United States in the event that you believe that your rights have been infringed under the U.S. federal securities laws or otherwise. Even if you are successful in bringing an action of this kind, the laws of the Cayman Islands, Hong Kong, or other relevant jurisdictions may render you unable to enforce a judgment against our assets or the assets of our directors and officers.

Appleby, our counsel as to the laws of the Cayman Islands, has advised us that there is uncertainty as to whether the courts of the Cayman Islands would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in the Cayman Islands against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States.

47

Table of Contents

Appleby has informed us that any final and conclusive judgment for a definite sum (not being a sum payable in respect of taxes or other charges of a like nature nor a fine or other penalty) and/or certain non-monetary judgments rendered in any action or proceedings brought against our Company in a foreign court (other than certain judgments of a superior court of certain states of the Commonwealth of Australia) will be recognized as a valid judgment by the courts of the Cayman Islands without re-examination of the merits of the case. On general principles, we would expect such proceedings to be successful provided that the court which gave the judgment was competent to hear the action in accordance with private international law principles as applied in the Cayman Islands and the judgment is not contrary to public policy in the Cayman Islands, has not been obtained by fraud or in proceedings contrary to natural justice.

CFN Lawyers, our counsel as to the laws of Hong Kong has advised us that there is uncertainty as to whether the courts of Hong Kong would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in Hong Kong against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States. A judgment of a court in the United States predicated upon U.S. federal or state securities laws may be enforced in Hong Kong at common law by bringing an action in a Hong Kong court on that judgment for the amount due thereunder and then seeking summary judgment on the strength of the foreign judgment, provided that the foreign judgment, among other things, is (1) for a debt or a definite sum of money (not being taxes or similar charges to a foreign government taxing authority or a fine or other penalty), and (2) final and conclusive on the merits of the claim, but not otherwise. Such a judgment may not, in any event, be so enforced in Hong Kong if (a) it was obtained by fraud, (b) the proceedings in which the judgment was obtained were opposed to natural justice, (c) its enforcement or recognition would be contrary to the public policy of Hong Kong, (d) the court of the United States was not jurisdictionally competent, or (e) the judgment was in conflict with a prior Hong Kong judgment. Hong Kong has no arrangement for the reciprocal enforcement of judgments with the United States. As a result, there is uncertainty as to the enforceability in Hong Kong, in original actions or in actions for enforcement, of judgments of U.S. courts of civil liabilities predicated solely upon the federal securities laws of the United States or the securities laws of any state or territory within the United States. See “Enforceability of Civil Liabilities.”

You may have more difficulties protecting your interests than you would as a shareholder of a U.S. corporation.

We are an exempted company incorporated under the laws of the Cayman Islands. Our corporate affairs are governed by the provisions of our Memorandum and Articles of Association, and by the provisions of the Companies Act and the common law of the Cayman Islands. The rights of shareholders to take action against the directors, actions by minority shareholders, and the fiduciary duties of our directors to us under Cayman Islands law are to a large extent governed by the common law of the Cayman Islands. The common law of the Cayman Islands is derived in part from comparatively limited judicial precedent in the Cayman Islands as well as from the common law of England, the decisions of whose courts are of persuasive authority, but are not binding, on a court in the Cayman Islands.

The rights of shareholders and the fiduciary duties of our directors and officers under Cayman Islands law are not as clearly established as they would be under statutes or judicial precedents in some jurisdictions in the United States, and some states (such as Delaware) have more fully developed and judicially interpreted bodies of corporate law than the Cayman Islands. In addition, Cayman Islands companies may not have standing to initiate a shareholder derivative action in a federal court of the United States.

Shareholders of Cayman Islands-exempted companies like us have no general rights under Cayman Islands law to obtain copies of the register of members or corporate records of the company. They will, however, have such rights as may be set out in the company’s articles of association. A Cayman Islands exempted company may maintain its principal register of members and any branch registers in any country or territory, whether within or outside the Cayman Islands, as the company may determine from time to time. There is no requirement for an exempted company to make any returns of members to the Registrar of Companies in the Cayman Islands. The names and addresses of the members are, accordingly, not a matter of public record and are not available for public inspection. However, an exempted company shall make available at its registered office, in electronic form or any other medium, such register of members, including any branch register of member, as may be required of it upon service of an order or notice by the Tax Information Authority pursuant to the Tax Information Authority Act (2013 Revision) of the Cayman Islands. This may make it more difficult for you to obtain the information needed to establish any facts necessary for a shareholder motion or to solicit proxies from other shareholders in connection with a proxy contest.

48

Table of Contents

As a result of all of the above, our public shareholders may have more difficulty in protecting their interests in the face of actions taken by management, members of the board of directors, or our Controlling Shareholder than they would as public shareholders of a company incorporated in the United States. For a discussion of significant differences between the provisions of the Companies Act and the laws applicable to companies incorporated in the United States and their shareholders, see “Description of Share Capital — Differences in Corporate Law.”

Cayman Islands economic substance requirements may have an effect on our business and operations.

Pursuant to the International Tax Cooperation (Economic Substance) Act, 2018 of the Cayman Islands (‘‘ES Act’’) that came into force on 1 January 2019, a ‘‘relevant entity’’ is required to satisfy the economic substance test set out in the ES Act. A ‘‘relevant entity’’ includes an exempted company incorporated in the Cayman Islands as is the Company; however, it does not include an entity that is tax resident outside the Cayman Islands. Accordingly, for so long as the Company is a tax resident outside the Cayman Islands, including in Hong Kong, it is not required to satisfy the economic substance test set out in the ES Act.

We are a foreign private issuer within the meaning of the rules under the Exchange Act, and, as such, we are exempt from certain provisions applicable to U.S. domestic public companies.

Because we qualify as a foreign private issuer under the Exchange Act, we are exempt from certain provisions of the securities rules and regulations in the United States that are applicable to U.S. domestic issuers, including:

        the rules under the Exchange Act requiring the filing with the SEC of quarterly reports on Form 10-Q or current reports on Form 8-K;

        the sections of the Exchange Act regulating the solicitation of proxies, consents, or authorizations in respect to a security registered under the Exchange Act;

        the sections of the Exchange Act requiring insiders to file public reports of their stock ownership and trading activities and liability for insiders who profit from trades made in a short period of time; and

        the selective disclosure rules by issuers of material non-public information under Regulation FD.

We will be required to file an annual report on Form 20-F within four months of the end of each fiscal year. In addition, we intend to publish our results on a quarterly basis as press releases, distributed pursuant to the rules and regulations of Nasdaq Capital Market. Press releases relating to financial results and material events will also be furnished to the SEC on Form 6-K. However, the information we are required to file with or furnish to the SEC will be less extensive and less timely compared to that required to be filed with the SEC by U.S. domestic issuers. As a result, you may not be afforded the same protections or information that would be made available to you were you investing in a U.S. domestic issuer.

As a foreign private issuer, we are permitted to adopt certain home country practices in relation to corporate governance matters that differ significantly from Nasdaq corporate governance listing standards. These practices may afford less protection to shareholders than they would enjoy if we complied fully with Nasdaq corporate governance listing standards.

As a foreign private issuer, we are permitted to take advantage of certain provisions in the Nasdaq rules that allow us to follow our home country law for certain governance matters. Certain corporate governance practices in our home country, the Cayman Islands, may differ significantly from corporate governance listing standards. Currently, we do not intend to rely on home country practices with respect to our corporate governance after we complete this offering. However, if we choose to follow home country practices in the future, our shareholders may be afforded less protection than they would otherwise enjoy under the Nasdaq corporate governance listing standards applicable to U.S. domestic issuers.

We may lose our foreign private issuer status in the future, which could result in significant additional costs and expenses.

We are a foreign private issuer, and therefore, we are not required to comply with all of the periodic disclosure and current reporting requirements of the Exchange Act. The determination of foreign private issuer status is made annually on the last business day of an issuer’s most recently completed second fiscal quarter. We would lose our

49

Table of Contents

foreign private issuer status if, for example, more than 50% of our Ordinary Shares are directly or indirectly held by residents of the United States and we fail to meet additional requirements necessary to maintain our foreign private issuer status. If we lose our foreign private issuer status on this date, we will be required to file with the SEC periodic reports and registration statements on U.S. domestic issuer forms, which are more detailed and extensive than the forms available to a foreign private issuer. We will also have to mandatorily comply with U.S. federal proxy requirements, and our officers, directors, and principal shareholders will become subject to the short-swing profit disclosure and recovery provisions of Section 16 of the Exchange Act. In addition, we will lose our ability to rely upon exemptions from certain corporate governance requirements under the Nasdaq rules. As a U.S.-listed public company that is not a foreign private issuer, we will incur significant additional legal, accounting, and other expenses that we will not incur as a foreign private issuer in order to maintain a listing on a U.S. securities exchange.

There can be no assurance that we will not be a PFIC for U.S. federal income tax purposes for any taxable year, which could result in adverse U.S. federal income tax consequences to U.S. holders of our Ordinary Shares.

A non-U.S. corporation will be a PFIC for any taxable year if either (i) at least 75% of its gross income for such year consists of certain types of “passive” income, or (ii) at least 50% of the value of its assets (based on an average of the quarterly values of the assets) during such year is attributable to assets that produce passive income or are held for the production of passive income (the “asset test”). Based on our current and expected income and assets (taking into account the expected cash proceeds and our anticipated market capitalization following this offering), we do not presently expect to be a PFIC for the current taxable year or the foreseeable future. However, no assurance can be given in this regard because the determination of whether we are or will become a PFIC is a fact-intensive inquiry made on an annual basis that depends, in part, upon the composition of our income and assets. In addition, there can be no assurance that the Internal Revenue Service (“IRS”) will agree with our conclusion or that the IRS would not successfully challenge our position. Fluctuations in the market price of our Ordinary Shares may cause us to become a PFIC for the current or subsequent taxable years because the value of our assets for the purpose of the asset test may be determined by reference to the market price of our Ordinary Shares. The composition of our income and assets may also be affected by how, and how quickly, we use our liquid assets and the cash raised in this offering. If we were to be or become a PFIC for any taxable year during which a U.S. holder holds our Ordinary Shares, certain adverse U.S. federal income tax consequences could apply to such U.S. holder. See “Material Tax Income Consideration — Material U.S. Federal Income Tax Considerations for U.S. Holders — PFIC Consequences.”

We are an emerging growth company within the meaning of the Securities Act and may take advantage of certain reduced reporting requirements.

We are an emerging growth company, as defined in the JOBS Act, and we may take advantage of certain exemptions from requirements applicable to other public companies that are not emerging growth companies, including, most significantly, not being required to comply with the auditor attestation requirements of Section 404 of Sarbanes-Oxley for so long as we remain an emerging growth company. As a result, if we elect not to comply with such auditor attestation requirements, our investors may not have access to certain information they may deem important.

The JOBS Act also provides that an emerging growth company does not need to comply with any new or revised financial accounting standards until such date that a private company is otherwise required to comply with such new or revised accounting standards. We do not plan to opt out of such exemptions afforded to an emerging growth company. As a result of this election, our financial statements may not be comparable to companies that comply with public company effective data.

We will incur increased costs as a result of being a public company, particularly after we cease to qualify as an “emerging growth company.”

Upon consummation of this offering, we will incur significant legal, accounting, and other expenses as a public company that we did not incur as a private company. The Sarbanes-Oxley Act of 2002 (“Sarbanes-Oxley”), as well as rules subsequently implemented by the SEC, impose various requirements on the corporate governance practices of public companies. We are an “emerging growth company,” as defined in the JOBS Act and will remain an emerging growth company until the earlier of (1) the last day of the fiscal year (a) following the fifth anniversary of the completion of this offering, (b) in which we have total annual gross revenue of at least US$1.235 billion, or (c) in which we are deemed to be a large accelerated filer, which means the market value of our Ordinary Shares that is held by non-affiliates exceeds US$700 million as of the end of any second fiscal quarter before that time;

50

Table of Contents

and (2) the date on which we have issued more than US$1 billion in non-convertible debt during the prior three-year period. An emerging growth company may take advantage of specified reduced reporting and other requirements that are otherwise applicable generally to public companies. These provisions include exemption from the auditor attestation requirement under Section 404 in the assessment of the emerging growth company’s internal control over financial reporting and permission to delay the adoption of new or revised accounting standards until such time as those standards apply to private companies.

Compliance with these rules and regulations increases our legal and financial compliance costs and makes some corporate activities more time consuming and costly. After we are no longer an “emerging growth company,” or until five years following the completion of our IPO, whichever is earlier, we expect to incur significant expenses and devote substantial management effort toward ensuring compliance with the requirements of Section 404 of Sarbanes-Oxley and the other rules and regulations of the SEC. For example, as a public company, we will be required to increase the number of independent directors and adopt policies regarding internal controls and disclosure controls and procedures. We will incur additional costs in obtaining director and officer liability insurance. In addition, we will incur additional costs associated with our public company reporting requirements. It may also be more difficult for us to find qualified persons to serve on our board of directors or as executive officers. We are currently evaluating and monitoring developments with respect to these rules and regulations, and we cannot predict or estimate with any degree of certainty the amount of additional costs we may incur or the timing of such costs.

As a “controlled company” under the rules of the Nasdaq Capital Market, we may choose to exempt our Company from certain corporate governance requirements that could have an adverse effect on our public shareholders.

Our directors and officers beneficially own a majority of the voting power of our issued and outstanding Ordinary Shares. Under Rule 4350(c) of the Nasdaq Capital Market, a company of which more than 50% of the voting power is held by an individual, group, or another company is a “controlled company” and may elect not to comply with certain corporate governance requirements, including the requirement that a majority of our directors be independent, as defined in the Nasdaq Capital Market Rules, and the requirement that our compensation and nominating and corporate governance committees consist entirely of independent directors. Although we do not intend to rely on the “controlled company” exemption under the Nasdaq listing rules, we could elect to rely on this exemption in the future. If we elect to rely on the “controlled company” exemption, a majority of the members of our board of directors might not be independent directors and our nominating and corporate governance and compensation committees might not consist entirely of independent directors. Accordingly, during any time while we remain a controlled company relying on the exemption and during any transition period following a time when we are no longer a controlled company, you would not have the same protections afforded to shareholders of companies that are subject to all of the Nasdaq Capital Market corporate governance requirements. Our status as a controlled company could cause our Ordinary Shares to be less attractive to certain investors or otherwise harm our trading price.

51

Table of Contents

SPECIAL NOTE REGARDING FORWARD-LOOKING STATEMENTS

This prospectus contains forward-looking statements that involve substantial risks and uncertainties. In some cases, you can identify forward-looking statements by the words “may,” “might,” “will,” “could,” “would,” “should,” “expect,” “intend,” “plan,” “goal,” “objective,” “anticipate,” “believe,” “estimate,” “predict,” “potential,” “continue,” and “ongoing,” or the negative of these terms, or other comparable terminology intended to identify statements about the future. These statements involve known and unknown risks, uncertainties, and other important factors that may cause our actual results, levels of activity, performance, or achievements to be materially different from the information expressed or implied by these forward-looking statements. The forward-looking statements and opinions contained in this prospectus are based upon information available to us as of the date of this prospectus and, while we believe such information forms a reasonable basis for such statements, such information may be limited or incomplete, and our statements should not be read to indicate that we have conducted an exhaustive inquiry into, or review of, all potentially available relevant information. Forward-looking statements include statements about:

        timing of the development of future business;

        capabilities of our business operations;

        expected future economic performance;

        competition in our market;

        continued market acceptance of our services;

        changes in the laws that affect our operations;

        inflation and fluctuations in foreign currency exchange rates;

        our ability to obtain and maintain all necessary government certifications, approvals, and/or licenses to conduct our business;

        continued development of a public trading market for our securities;

        the cost of complying with current and future governmental regulations and the impact of any changes in the regulations on our operations;

        managing our growth effectively;

        projections of revenue, earnings, capital structure, and other financial items;

        fluctuations in operating results;

        dependence on our senior management and key employees; and

        other factors set forth under “Risk Factors.”

You should refer to the section titled “Risk Factors” for a discussion of important factors that may cause our actual results to differ materially from those expressed or implied by our forward-looking statements. As a result of these factors, we cannot assure you that the forward-looking statements in this prospectus will prove to be accurate. Furthermore, if our forward-looking statements prove to be inaccurate, the inaccuracy may be material. In light of the significant uncertainties in these forward-looking statements, you should not regard these statements as a representation or warranty by us or any other person that we will achieve our objectives and plans in any specified time frame, or at all. We undertake no obligation to publicly update any forward-looking statements, whether as a result of new information, future events, or otherwise, except as required by law.

You should read this prospectus and the documents that we reference in this prospectus and have filed as exhibits to the registration statement, of which this prospectus forms a part, completely and with the understanding that our actual future results may be materially different from what we expect. We qualify all of our forward-looking statements by these cautionary statements.

52

Table of Contents

INDUSTRY AND MARKET DATA

This prospectus includes statistical and other industry and market data that we obtained from industry publications and research, surveys, and studies conducted by third parties, as well as estimates by our management based on such data. None of these third parties are affiliated with us, and the information contained in this prospectus has not been reviewed or endorsed by any of them. The market data and estimates used in this prospectus involve a number of assumptions and limitations, and you are cautioned not to give undue weight to such data and estimates. Industry publications, research, surveys, studies, and forecasts generally state that the information they contain has been obtained from sources believed to be reliable but that the accuracy and completeness of such information is not guaranteed. Forecasts and other forward-looking information obtained from these sources are subject to the same qualifications and uncertainties as the other forward-looking statements in this prospectus.

While we believe that the information from these industry publications, surveys, and studies is reliable, the industry in which we operate is subject to a high degree of uncertainty and risk due to a variety of important factors, including those described in the section titled “Risk Factors.” These and other factors could cause results to differ materially from those expressed in the estimates made by the independent parties and by us.

Market size of the construction industry in Hong Kong

Between 2013 and 2021, the construction industry in Hong Kong maintained growth with a compounded annual growth rate of 4.12%. Despite the impact of COVID-19 outbreak on the construction industry since early 2019, the gross value of construction works performed remained at a steady level for the years of 2019 and 2021.

Source: Construction & Miscellaneous Service Statistics Section — Census and Statistics Department of Hong Kong

53

Table of Contents

Based on the breakdown of the gross value of construction works performed by main contractors in the private and public sector below, contrary to the gross value of construction works in the public sector which has recorded a slight decrease since the COVID-19 outbreak in 2019, the gross value of construction works in the private sector has recovered steadily since the COVID-19 outbreak.

____________

Notes:

(1)      Derived by deflating the nominal value with an appropriate price index to the price level in the base period of 2000.

(2)      Includes projects commissioned by private developers. Projects under the Private Sector Participation Scheme are also included.

(3)      Includes projects commissioned by the Government of the Hong Kong Special Administrative Region, MTR Corporation Limited and Airport Authority. Projects under the Home Ownership Scheme, which are commissioned by the Housing Authority, are also included.

Source: Construction & Miscellaneous Service Statistics Section — Census and Statistics Department of Hong Kong

Overview of the Building Construction and Foundation Industry in Hong Kong

Growth Drivers

Sustained supply of residential units

The Hong Kong Long Term Housing Strategy was announced in 2014 to be the first long-term strategic document in housing since 1998, with three strategic directions set out to, among other things, stabilize the residential property market through steady land supply and timely demand-side management measures, and to promote good sales and tenancy practices for private residential properties. According to the Long Term Housing Strategy Annual Progress Report 2022, the projected housing demand based on established mechanism for the ten-year period from 2023 – 24 to 2032 – 33 is 421,000 units (rounded up to 430,000 units), and the Hong Kong government has set a target of supplying 301,000 public housing units and 129,000 private housing units.

Urban Renewal Program

According to the Hong Kong’s Urban Renewal Authority, there will be 326,000 private housing units aged 70 or above by 2046, and there is an urgent need to step up the rejuvenation of dilapidated urban areas, especially for those located at densely built urban core, such as Sham Shui Po and Kowloon City. As stated in the Annual Report 2019 – 20 of Urban Renewal Authority, there were more than 10,000 buildings in Hong Kong aged 50 years or above, and the number is forecast to reach 28,000 by 2046. To address the aging problem, the Hong Kong government has increased the three-year target of 10,000 transitional housing units within the next three years to 15,000 units, in

54

Table of Contents

order to relieve the pressure of families living in unpleasant living conditions. Moreover, with a growing emphasis on the preservation of these aged buildings by the means of proper repair and maintenance work under the Integrated Building Rehabilitation Assistance Scheme and Operating Building Bright 2.0, there is a rising demand for building demolition and development, building additions, and alterations work.

Expanding commercial area and business district

The private sector construction industry is substantially contributed by the commercial building construction segment. According to the Rating and Valuation Department of the Hong Kong government, the completion of private offices is expected to increase to 275.3 thousand m2 in 2022, while the completion of private commercial space is forecasted to increase to 173.3 thousand m2 in 2022. The growth is mainly owing to the “Energizing Kowloon East” program, which the Hong Kong government targets to develop a new central business district around the Kowloon East area, in order to provide a vast amount of office spaces and community facilities to support the long-term economic development of Hong Kong. The existing supply of commercial gross floor area in Kowloon East has reached about 2.9 million m2 by October 2020, with the potential to provide an additional 4.1 million m2 in the future.

Upstream and Downstream Analysis

The following diagram depicts the relationship between upstream and downstream entities in the building construction and foundation industry:

Customers

Landowners, property developers, and governmental departments are typically the customers to the main contractors in the building construction and foundation industry, and construction work is often initiated by these parties. For private sectors, for instance, landowners and property developers obtain land sites through auctions, usually for residential, commercial, and industrial projects, and then commission such construction work to main contractors. Depending on the nature of the construction activity, such work may include site formation, foundation work, piling, demolition, erection of architectural superstructure, and structural alteration.

55

Table of Contents

Main contractors

After obtaining projects from customers, the main contactors will start to perform construction work depending on the nature of the project.

Subcontractors

Given the scope of the project or the skillset required, the main contractors may consider outsourcing part of the construction work to some subcontractors depending on their specialist knowledge and experience in the field. Accordingly, multilayer subcontracting is a common practice in Hong Kong’s construction industry.

Suppliers

Suppliers are usually manufacturers, machinery trading service providers, and/or rental service providers. Such suppliers supply the necessary construction materials, such as concrete, steel, and trade and lease machinery, to the main contractors and the subcontractors for the construction projects and, on certain occasions, may also deal directly with the landowners or property developers of the construction projects.

Overview of foundation and site formation industry in Hong Kong

Both foundation work and site formation work belong to the early stage of a construction project, and they are closely related, as foundation work is usually carried out after the prior site formation work has been finished. Site formation work, including the levelling of land, slope stabilization, construction of retaining walls, and access roads, generally involves the preparation of a construction site for subsequent foundation and superstructure work, while foundation work, including piling, pile cap construction excavation, and lateral support work, connects an architectural structure to the ground and transfers loads from the structure to the ground.

Overview of the general building work industry in Hong Kong

General building work refers to the construction work performed by main contractors and subcontractors at construction sites on “buildings,” which term includes residential, commercial, industrial, and storage service buildings and other types of buildings in machinery is a part of general building work. In general, superstructure building work refers to the building work in relation to the parts of the structure above the ground level, which generally include structural concrete construction for superstructure on typical floors, roofing work, installation of window walls and installation of building services work.

Entry barriers

Industry experience

Knowledge of civil engineering, geology, and technical expertise are several of the barriers to enter the foundation industry, given that such industry knowledge can only be accumulated through years of formal education, and vocational, and on-site practical training. Potential players that lack industry experience would encounter difficulties when entering the industry.

Sufficient capital and adequate capital management

Sufficient capital for project initiations and adequate capital management throughout the construction process to finance project operations are two essential factors for new entrants to take into consideration. Before project initiations, contractors have to ensure an abundant amount of cash for procurement of raw materials, leasing specialized machinery, recruitment of skilled labor, and other payment for its suppliers and subcontractors. During the construction process, sufficient capital is also required to guarantee the payment of wages, surety bond, and machinery rental for operation work, as contractors often need to pay for their suppliers and subcontractors before getting paid by their customers.

56

Table of Contents

USE OF PROCEEDS

Based upon an IPO price of $4.00 per Ordinary Share, we estimate that we will receive net proceeds from this offering, after deducting the estimated underwriting discounts and the estimated offering expenses payable by us, of approximately $4,352,559 if the underwriters do not exercise their over-allotment option, and $5,313,039 if the underwriters exercise their over-allotment option in full, after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us.

Each $1.00 increase (decrease) in the assumed IPO price of $4.00 per Ordinary Share would increase (decrease) the net proceeds to us from this offering by $1,600,800, assuming that the number of Ordinary Shares offered by us, as set forth on the cover page of this prospectus, remains the same, and after deducting the underwriting discounts and commissions, non-accountable expense allowance and estimated offering expenses payable by us. An increase (decrease) of 1 million in the number of Ordinary Shares we are offering would increase (decrease) the net proceeds to us from this offering by $3,680,000, assuming the assumed IPO price remains the same, and after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us.

The primary purpose of this offering is to create a public market for our Ordinary Shares for the benefit of all shareholders. We plan to use the net proceeds of this offering as follows:

        Approximately 40% for purchasing machinery and robotics equipment;

        Approximately 20% for employing additional staff; and

        The balance to fund working capital and for other general corporate purposes.

The foregoing represents our current intentions based upon our present plans and business conditions to use and allocate the net proceeds of this offering. Our management, however, will have significant flexibility and discretion to apply the net proceeds of this offering. If an unforeseen event occurs or business conditions change, we may use the proceeds of this offering differently than as described in this registration statement. We reserve the right to change the use of proceeds that we presently anticipate and describe in this prospectus.

To the extent that the net proceeds we receive from this offering are not immediately used for the above purposes, we intend to invest our net proceeds in short-term, interest-bearing bank deposits or debt instruments.

57

Table of Contents

DIVIDEND POLICY

We currently intend to retain all available funds and future earnings, if any, for the operation and expansion of our business, and we do not anticipate declaring or paying any dividends in the foreseeable future. Any future determination related to our divided policy will be made at the discretion of our board of directors after considering our financial condition, results of operations, capital requirements, contractual requirements, business prospects, other factors the board of directors deems relevant, and subject to the restrictions contained in any future financing instruments.

During the year ended March 31, 2023, Chiu & Lee Partners declared cash dividends in the amount of HK$26,607,539 (approximately US$3,411,223) to its sole shareholder Orange Space Limited, and having received the dividend income, Orange Space Limited declared the same amount of dividend to its shareholder, CKHL and CKHL also declared the same amount of dividend to its shareholders.

For the cash dividend declared for the year ended March 31, 2023 to the shareholders of CKHL, Mr. Wong Chi Wai and Ling Chi Fai amounting to HK$1,303,769.5 (approximately US$167,145) was waived by Mr. Wong Chi Wai and Ling Chi Fai respectively. For the cash dividend declared for the year ended March 31, 2023 to the shareholder of CKHL, Fly Cloud Limited, which is wholly owned by Mr. Keung Yun Yuen and amounting to HK$24,000,000 (approximately US$3,076,923), HK$10,387,048 (approximately US$1,331,673) was offset by the amount due from Mr. Keung Yun Yuen in March 2023 and the remaining HK$13,612,952 (approximately US$1,745,250) has been settled in April 2023.

During the year ended March 31, 2022, Chiu & Lee Partners declared cash dividends in the amount of HK$12,000,000 (approximately US$1,538,462) to the then direct shareholder, Mr. Keung Yun Yuen. For the cash dividend declared for the year ended March 31, 2022, HK$10,704,314 (approximately US$,1372,348) was offset by the amount due from Mr. Keung Yun Yuen in February 2022 and HK$1,295,681 (approximately US$166,113) was offset from Mr. Keung Yun Yuen in May 2022.

Save as disclosed above, during the years ended March 31, 2023 and 2022, CKHL did not declare or pay any dividends and there was no transfer of assets among CKHL and its subsidiaries.

The declaration, amount, and payment of any future dividends will be at the sole discretion of our board of directors, subject to compliance with applicable Cayman Islands laws regarding solvency. Our board of directors will take into account general economic and business conditions; our financial condition and results of operations; our available cash and current and anticipated cash needs; capital requirements; contractual, legal, tax, and regulatory restrictions; and other implications on the payment of dividends by us to our shareholders or by our subsidiaries to us, and such other factors as our board of directors may deem relevant.

Subject to the Companies Act and our Articles of Association, our Company in general meeting may declare dividends in any currency to be paid to the members but no dividend shall be declared in excess of the amount recommended by our board of directors. Subject to a solvency test, as prescribed in the Companies Act, and the provisions, if any, of our Memorandum and Articles of Association, a company may pay dividends and distributions out of its share premium account. In addition, based upon English case law which is likely to be persuasive in the Cayman Islands, dividends may be paid out of profits.

As we are a holding company incorporated in the Cayman Islands, we rely on dividends paid to us by our subsidiaries for our cash requirements, including funds to pay any dividends and other cash distributions to our shareholders, service any debt we may incur, and pay our operating expenses. Our ability to pay dividends to our shareholders will depend on, among other things, the availability of dividends from our subsidiaries. According to the BVI Business Companies Act 2004 (as amended), a BVI company may make dividends distribution to the extent that immediately after the distribution, the value of the company’s assets exceeds its liabilities and that such company is able to pay its debts as they fall due. According to the Companies Ordinance of Hong Kong, a Hong Kong company may only make a distribution out of profits available for distribution. Under the current practice of the Inland Revenue Department of Hong Kong, no tax is payable in Hong Kong in respect to dividends paid by us.

Cash dividends, if any, on our Ordinary Shares will be paid in U.S. dollars.

58

Table of Contents

CAPITALIZATION

The following table sets forth our capitalization as of March 31, 2023, on:

        an actual basis; and

        a pro forma as adjusted basis to give effect to the sale of 1,740,000 Ordinary Shares in this offering at the assumed IPO price of US$4.00 per Ordinary Share after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us, assuming the underwriters do not exercise the over-allotment option.

You should read this information together with our audited consolidated financial statements appearing elsewhere in this prospectus and the information set forth under the sections titled “Exchange Rate Information,” “Use of Proceeds,” and “Management’s Discussion and Analysis of Financial Condition and Results of Operations.”

 

As of March 31, 2023

   

Actual

 

Adjusted(1)

   

US$

 

US$

Ordinary Shares, US$0.0001 par value per share: 500,000,000 shares authorized; 11,250,000 shares issued and outstanding; 12,990,000 shares issued and outstanding pro forma

 

1,125

 

1,299

Additional paid-in capital

 

256,410

 

4,608,795

Retained earnings

 

6,560,178

 

6,560,178

Total stockholders’ equity

 

6,817,713

 

11,170,272

         

Short-term and long-term bank borrowing

 

4,261,379

 

4,261,379

Finance lease liabilities – non-current

 

142,029

 

142,029

Operating lease liabilities – non-current

 

3,925

 

3,925

Total indebtedness

 

4,407,333

 

4,407,733

Total capitalization

 

11,225,046

 

15,577,605

____________

(1)      Reflects the sale of Ordinary Shares in this offering at an assumed IPO of US$4.00 per Ordinary Share, after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us. The pro forma as adjusted information is illustrative only, and we will adjust this information based on the actual IPO price and other terms of this offering determined at pricing. Additional paid-in capital reflects the net proceeds we expect to receive after deducting the underwriting discounts and commissions (underwriting discount equal to 8.0% per Ordinary Share), and estimated offering expenses payable by us (US$1,900,641). We estimate that such net proceeds will be approximately US$4,352,559. For an itemization of an estimation of the total offering expenses payable by us, see “Expenses Related to this Offering.”

59

Table of Contents

DILUTION

If you invest in our Ordinary Shares in this offering, your interest will be immediately diluted to the extent of the difference between the IPO price per Ordinary Share in this offering and the net tangible book value per Ordinary Share after this offering. Dilution results from the fact that the IPO price per Ordinary Share is substantially in excess of the net tangible book value per Ordinary Share. As of March 31, 2023, we had a historical net tangible book value of US$5,767,799, or US$0.51 per Ordinary Share. Our net tangible book value per Ordinary Share represents total tangible assets less intangible asset, all divided by the number of Ordinary Shares outstanding as of March 31, 2023.

After giving effect to the sale of Ordinary Shares in this offering at the assumed IPO price of US$4.00 per Ordinary Share, we will have 12,990,000 Ordinary Shares outstanding, and after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us, our pro forma as adjusted net tangible book value on March 31, 2023, would have been US$11,170,272, or US$0.86 per Ordinary Share. This represents an immediate increase in pro forma as adjusted net tangible book value of US$0.35 per Ordinary Share to existing investors and immediate dilution of US$3.14 per Ordinary Share to new investors. The following table illustrates this dilution to new investors purchasing Ordinary Shares in this offering:

 

Post-Offering(1)

 

Full Exercise of Over-allotment
Option(2)

Assumed IPO price per Ordinary Share

 

$

4

 

$

4

Net tangible book value per Ordinary Share as of March 31, 2023

 

$

0.51

 

$

0.51

Increase in pro forma as adjusted net tangible book value per Ordinary Share attributable to new investors purchasing Ordinary Shares in this offering

 

$

0.35

 

$

0.40

Pro forma as adjusted net tangible book value per Ordinary Share after this offering

 

$

0.86

 

$

0.92

Dilution per Ordinary Share to new investors in this offering

 

$

3.14

 

$

3.08

____________

(1)      Assumes gross proceeds from the offering of 1,740,000 Ordinary Shares, and assumes that the underwriters’ over-allotment option has not been exercised.

(2)      Assumes gross proceeds from the offering of 2,010,000 Ordinary Shares, and assumes that the underwriters’ over-allotment option has been exercised in full.

Each US$1.00 increase (decrease) in the assumed IPO price of US$4.00 per Ordinary Share would increase (decrease) our pro forma as adjusted net tangible book value as of March 31, 2023, after this offering by approximately US$0.12 per Ordinary Share, and would increase (decrease) dilution to new investors by US$0.88 per Ordinary Share, assuming that the number of Ordinary Shares offered by us, as set forth on the cover page of this prospectus, remains the same, and after deducting the underwriting discounts and commissions, non-accountable expense allowance, and estimated offering expenses payable by us.

If the underwriters exercise their over-allotment option in full, the pro forma as adjusted net tangible book value per Ordinary Share after this offering would be US$0.92, the increase in net tangible book value per Ordinary Share to existing shareholders would be US$0.40, and the immediate dilution in net tangible book value per Ordinary Share to new investors in this offering would be US$3.08.

To the extent that we issue additional Ordinary Shares in the future, there will be further dilution to new investors participating in this offering.

60

Table of Contents

The following table summarizes, on a pro forma basis as of March 31, 2023, the differences between the existing shareholders and the new investors with respect to the number of Ordinary Shares purchased from us in this offering, the total consideration paid, and the average price per Ordinary Shares paid at the assumed IPO price of US$4.00 per Ordinary Shares, before deducting estimated underwriting discounts and estimated offering expenses. The total number of Ordinary Shares does not include Ordinary Shares issuable upon the exercise of the over-allotment option granted to the underwriters.

 

Ordinary Shares
purchased

 

Total
consideration

 

Average
price per
Ordinary
Share

   

Number

 

Percent

 

Amount

 

Percent

 

Existing shareholders

 

11,250,000

 

86.6

%

 

$

257,535

 

3.6

%

 

$

0.023

New investors

 

1,740,000

 

13.4

%

 

$

6,960,000

 

96.4

%

 

$

4

Total

 

12,990,000

 

100.0

%

 

$

 7,217,535

 

100.0

%

 

$

0.56

61

Table of Contents

EXCHANGE RATE INFORMATION

CKHL is a holding company with operations conducted in Hong Kong through its key Operating Subsidiary in Hong Kong, Chiu & Lee Partners, using Hong Kong dollars. Chiu & Lee Partners’ reporting currency is Hong Kong dollars. Translations of amounts from HK$ into US$ are solely for the convenience of the reader and were calculated at the rate of US$1 = HK$ 7.8, representing the noon buying rate in The City of New York for cable transfers of HK$ as certified for customs purposes by the Federal Reserve Bank of New York on the last trading day of March 31, 2023. No representation is made that the HK$ amount represents or could have been, or could be converted, realized or settled into US$ at that rate, or at any other rate.

62

Table of Contents

CORPORATE HISTORY AND STRUCTURE

Corporate History and Structure

We are a company principally engaged in construction work dating back to 1981. We have obtained the relevant registrations for our business operations via our key Operating Subsidiary, Chiu & Lee Partners, as a general building contractor from the Buildings Department of Hong Kong since 1999 and further attained the registrations as a specialist contractor in the demolition work category, foundation work category, and site formation work category from the Buildings Department of Hong Kong since 2006. As of the date of this prospectus, our Controlling Shareholder owns 90.2% of our issued share capital.

In June 1981, Chiu & Lee Partners was incorporated, as a company with limited liability under the laws of Hong Kong.

In February 2022, Orange Space Limited was incorporated under the laws of the British Virgin Islands, as an intermediate holding company.

In March 2022, CKHL was incorporated under the laws of the Cayman Islands as an exempted company with limited liability, as the holding company of our BVI and Hong Kong subsidiaries.

In April 2022, as part of the reorganization, CKHL acquired, through Orange Space, all the shares of Chiu & Lee Partners from the Controlling Shareholder and became the ultimate holding company of Orange Space and Chiu & Lee Partners. On May 4, 2022, CKHL issued 11,249,999 Ordinary Shares to the Controlling Shareholder. On May 4, 2022, the Controlling Shareholder sold 551,250 Ordinary Shares each to Mr. Ling Chi Fai and Mr. Wong Chi Wai, respectively. Mr. Ling Chi Fai and Mr. Wong Chi Wai are individuals that have no affiliation with CKHL and its subsidiaries.

Our principal office is located at Room 2620, 26/F., New Tech Plaza, 34 Tai Yau Street, San Po Kong, Kowloon, Hong Kong. Our telephone number is (+852) 2155 9690. Our registered office in the Cayman Islands is located at the office of Appleby Global Services (Cayman) Limited, 71 Fort Street, PO Box 500, George Town, Grand Cayman, Kyl-1106, Cayman Islands.

Our agent for service of process in the United States is Cogency Global Inc., located at 122 East 42nd Street, 18th Floor New York, NY 10168. Information contained on, or that can be accessed through, our website is not a part of, and shall not be incorporated by reference into, this prospectus.

The chart below illustrates our corporate structure and identifies our subsidiaries as of the date of this prospectus and upon completion of this offering (assuming the underwriters do not exercise the over-allotment option):

63

Table of Contents

Name

 

Background

 

Ownership

ORANGE SPACE LIMITED

 

- A BVI company

- Incorporated in February 2022

- Issued Share Capital of US$100 - Intermediate holding company

 

100% owned by CKHL

Chiu & Lee Partners Construction Co., Limited

 

- A Hong Kong company

- Incorporated in June 1981

- Issued Share Capital of HK$2,000,000

- Provision of construction services

 

100% owned by Orange Space

We are offering 1,740,000 Ordinary Shares of CKHL, our Cayman holding company, representing 13.4% of the Ordinary Shares following completion of the offering of CKHL, assuming the underwriters do not exercise the over-allotment option.

We will be a “controlled company” as defined under the Nasdaq Stock Market Rules because, immediately after the completion of this offering, our Controlling Shareholder will own 78.1% of our total issued and outstanding Shares, representing 78.1% of the total voting power, assuming that the underwriters do not exercise their over-allotment option.

At each general meeting, each shareholder who is present in person or by proxy (or, in the case of a shareholder being a corporation, by its duly authorized representative) will have one vote for each Ordinary Share that such shareholder holds. There are no prohibitions to cumulative voting under the laws of the Cayman Islands, but our Memorandum and Articles of Association do not provide for cumulative voting.

64

Table of Contents

MANAGEMENT’S DISCUSSION AND ANALYSIS OF
FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our consolidated financial statements and related notes included elsewhere in this prospectus. This discussion and analysis and other parts of this prospectus contain forward-looking statements based upon current beliefs, plans, and expectations that involve risks, uncertainties, and assumptions. Our actual results and the timing of selected events could differ materially from those anticipated in these forward-looking statements as a result of several factors, including those set forth under “Risk Factors” and elsewhere in this prospectus. You should carefully read the “Risk Factors” section of this prospectus to gain an understanding of the important factors that could cause actual results to differ materially from our forward-looking statements.

Overview

We are a holding company incorporated in the Cayman Islands with operations conducted by our Hong Kong subsidiary, Chiu & Lee Partners.

We are an established one-stop shop construction services provider in Hong Kong with over 40 years of experience in the construction industry. We principally engage in (i) foundation and site formation work, which mainly include piling work, excavation and lateral support works and pile cap construction, work; (ii) general building work and associated services, which mainly include development of superstructures, alterations, and additions work; and (iii) other construction work, which mainly includes demolition work.

Key Factors that Affect Results of Operations

Our results of operations have been and will continue to be affected by a number of factors, including those set out below:

Economic, political, and social conditions in China and Hong Kong, as well as its government policies, laws, and regulations

Our key operations are in Hong Kong. However, due to the long-arm provisions under the current PRC laws and regulations, the PRC government may exercise significant oversight and discretion over the conduct of our business and may intervene in or influence our operations at any time, which could result in a material change in our operations and/or the value of our Ordinary Shares. Accordingly, our business, prospects, financial condition, and results of operations may be influenced to a significant degree by the political, economic, and social conditions in the PRC generally and by the continued economic growth in China as a whole. Accordingly, our results of operations and prospects are, to a significant degree, subject to economic, political, and legal developments in the PRC.

Hong Kong is a Special Administrative Region of the PRC, and the basic policies of the PRC regarding Hong Kong are reflected in the Basic Law, namely the Hong Kong’s constitutional document, which provides Hong Kong with a high degree of autonomy and executive, legislative, and independent judicial powers, including that of final adjudication under the principle of “one country, two systems.” However, there is no assurance that there will not be any changes in the economic, political, and legal environment in Hong Kong in the future. Since our operation is based in Hong Kong, any change of such political arrangements may pose immediate threat to the stability of the economy in Hong Kong, thereby directly and adversely affecting our results of operations and financial positions.

Competition from other players in the market

We generally secure our projects after undergoing a tendering process. We submit quotation or tender price for a project that is based on our project cost estimate and a mark-up margin. The construction industry in Hong Kong is highly competitive, and it is often the case that multiple of our competitors bid for the same project that we do. We thus generally scale down our mark-up margin to be submitted to the project owner when competition for a project is perceived to be intense, and hence, the operating profit margin and our results of operation may be adversely affected.

65

Table of Contents

Our ability to attract new customers and secure new projects

Our success depends in large part upon widespread adoption of our quality, safety, and timeliness by our customers. In order to attract new customers and continue to expand our customer base, we must appeal to and attract customers who identify with our project management expertise. In addition, our projects are non-recurrent in nature, and our future success depends in part on our ability to increase our project backlog over time. If we are unable to timely secure sufficient new projects when existing projects are completed, our turnover and, hence, results of operations may have a material setback and we may also suffer from higher staff turnover.

Cost control and management

Our cost of sales mainly comprises (i) subcontracting fees, (ii) direct labor costs, (iii) cost of materials and tools, and (iv) other construction costs. Although we determine our project prices based on a cost-plus method with reference to the time and costs estimated to be involved in a project, the actual time and costs involved in completing our foundation and related projects may be adversely escalated in materials and labor, adverse weather conditions, and changes in rules, regulations, and policies in Hong Kong. Therefore, the failure to control and manage the cost and time involved in a project may give rise to delays in completion of work and/or cost overruns, which in turn may materially and adversely affect our financial condition, profitability, and liquidity.

Collectability and timing of collection of our trade receivables and retention receivables

We normally receive progress payments from our customers on a regular basis with reference to the value of work done, and a portion of such payment, which is in general up to 10% of each interim payment, and up to a maximum limit of 5% to 10% of the contract sum, is usually withheld by our customers as retention money, and normally, part will be remitted to us after completion of our work and the remaining will be remitted to us upon the agreement of the final account between our customers and us according to the contract terms. Accordingly, we are subject to considerable credit risk, and there can be no assurance that the retention money or any future retention money will be remitted by our customers to us on a timely basis and in full. Any late payment, whether arising from payment practice of our customers or delay in completion of our projects, may adversely affect our future liquidity position.

The COVID-19 pandemic could have a material adverse impact on our business, operating results, and financial condition.

The COVID-19 pandemic and the travel restrictions, quarantines, and other related public health measures and actions taken by governments and the private sector have adversely affected global economies, financial markets, and the overall environment for our business, and the extent to which it may continue to impact our results of operations and overall financial performance remains uncertain. The global macroeconomic effects of the pandemic may persist indefinitely, even after the pandemic has subsided.

Supply chain disruptions have become a major challenge for the global economy since the start of the COVID-19 pandemic. These shortages and supply-chain disruptions are significant and widespread. Lockdowns in several countries across the world, labor shortages, robust demand for tradable goods, disruptions to logistics networks, and capacity constraints have resulted in increases in freight costs and delivery times. Companies that are reliant on the movement of goods and materials, such as our Company, which relies on construction materials, may suffer from plant closures and supply shortages across the extended supply network.

In addition, multiple infected cases within a construction site may result in shortage of labor and in more serious cases may cause a temporary halt in the site’s construction operation for a few days. Hence, our productivity and progress may also be negatively affected.

Basis of Presentation

Our consolidated financial statements have been prepared in accordance with U.S. GAAP and pursuant to the regulations of SEC. They include the financial statements of our Company and our subsidiaries. All transactions and balances among these entities have been eliminated upon consolidation.

Please also refer to the summary of the significant accounting policies of our Company discussed in Note 2 to the consolidated financial statements for the two years ended March 31, 2023.

66

Table of Contents

Income taxes

Cayman Islands

The Company is incorporated in the Cayman Islands. The Cayman Islands currently levy no taxes on individuals or corporations based upon profits, income, gains or appreciations and there is no taxation in the nature of inheritance tax or estate duty. There are no other taxes likely to be material to our Company levied by the government of the Cayman Islands save for certain stamp duties which may be applicable, from time to time, on certain instruments.

BVI

We own Orange Space, which is incorporated in the BVI and is not subject to tax on income or capital gains under current BVI law. In addition, upon payments of dividends by these entities to their shareholders, no BVI withholding tax will be imposed.

Hong Kong

We own Chiu & Lee Partners, our Operating Subsidiary, through Orange Space. Chiu & Lee Partners is incorporated in Hong Kong and is subject to Hong Kong profits tax at a rate of 8.25% for the assessable profits of first HK$2 million and 16.5% for the remaining assessable profits. Under Hong Kong tax law, Chiu & Lee Partners is exempted from income tax on its foreign-derived income, and there is no withholding tax in Hong Kong on remittance of dividends.

Recently issued accounting pronouncements

See the discussion of the recent accounting pronouncements contained in Note 2 to the consolidated financial statements, “Recent accounting pronouncements”.

Results of Operations

Year ended March 31, 2022, compared to year ended March 31, 2023

The following table sets forth a summary of the consolidated results of operations of us for the periods indicated, both in absolute amount and as a percentage of our total revenues.

 

For the year ended March 31,

   

2022

 

2023

   

US$

 

US$

 

% of change

Revenues

 

60,724,303

 

 

77,852,447

 

 

28.2

%

Cost of sales

 

(54,774,465

)

 

(71,740,688

)

 

31.0

%

Gross profit

 

5,949,838

 

 

6,111,759

 

 

2.7

%

Operating expenses:

   

 

   

 

   

 

General and administrative expenses

 

(1,340,311

)

 

(2,717,523

)

 

102.8

%

Total operating expenses

 

(1,340,311

)

 

(2,717,523

)

 

102.8

%

Income from operations

 

4,609,527

 

 

3,394,236

 

 

(26.4

)%

Other income (expense)

 

(13,546

)

 

173,548

 

 

N/A

 

Profit from operations

 

4,595,981

 

 

3,567,784

 

 

(22.4

)%

Interest expense

 

(108,829

)

 

(183,806

)

 

68.9

%

Income before tax expense

 

4,487,152

 

 

3,383,978

 

 

(24.6

)%

Income tax expense

 

(717,724

)

 

(530,865

)

 

(26.0

)%

Net income

 

3,769,428

 

 

2,853,113

 

 

(24.3

)%

Revenues

Our revenues increased by 28.2% to US$77,852,447 for the year ended March 31, 2023, from US$60,724,303 for the year ended March 31, 2022. The revenues increase was principally driven by the increase in the number of projects of larger scale undertaken by us during the year ended March 31, 2023. The top 3 construction projects contributed about US$32.4 million, or 42% of our revenues in fiscal year 2023 while top 3 construction projects contributed US$21.7 million, or 36% of our revenues in fiscal year 2022. About 28 projects contributed revenue during the year ended March 31, 2023, as compared to 28 projects for the year ended March 31, 2022.

67

Table of Contents

Revenues from foundation and site formation projects and superstructure projects, which together account for over 97% of our revenues, also demonstrated a significant increase, by 21.3% and 66.6% to US$55,784,659 and US$21,598,103 for the year ended March 31, 2023, from US$45,972,316 and US$12,965,504 for the year ended March 31, 2022, respectively. The following table sets out revenues generated from different services during the two years ended March 31, 2022 and 2023:

 

For the year ended March 31,

   

2022

 

2023

   

US$

 

%

 

US$

 

%

Revenues

       

 

       

 

Demolition

 

1,052,093

 

1.7

%

 

188,337

 

0.2

%

Foundation & site formation

 

45,972,316

 

75.7

%

 

55,784,659

 

71.7

%

Superstructure

 

12,965,504

 

21.4

%

 

21,598,103

 

27.7

%

Alterations and additions and others

 

734,390

 

1.2

%

 

281,348

 

0.4

%

Total

 

60,724,303

 

100

%

 

77,852,447

 

100

%

Our management attributed the increased in our scale of business operation to (i) Chiu & Lee Partners’ recent track record of completing noticeable number of and sizeable foundation and site formation projects; (ii) our active submission of quotations; and (iii) Mr. Keung Yun Yuen’s business network. After joining Chiu & Lee Partners as managing director in November 2017, Mr. Keung Yun Yuen had formulated business plans to grow our business and built business relationship with new customers. We believe that our efforts in business development and ability to complete projects attracted new customers and some of the customers also became our recurring customers. As such, we were experiencing a remarkable growth in revenue for the year ended March 31, 2023.

Cost of sales

Our cost of sales increased by 31.0% to US$71,740,688 for the year ended March 31, 2023, from US$54,774,465 for the year ended March 31, 2022. The increase in the cost of sales corresponded to the increase in revenue. Our cost of sales mainly comprised subcontracting fees, cost of materials and tools, direct labor costs, and other construction costs with subcontracting fees and cost of materials and tools accounting for over 90% of the total cost of services in each of the years ended March 31, 2022 and 2023. Depending on the agreements with subcontractors, our subcontractors may either provide labor and tools or labor, tools, and construction materials. As such, the proportion of subcontracting fees and cost of materials and tools may fluctuate over projects.

Gross profit and gross profit margin

Our gross profit increased by 2.7% to US$6,111,759 for the year ended March 31, 2023, from US$5,949,838 for the year ended March 31, 2022. Our gross profit margin decreased to 7.9% for the year ended March 31, 2023, from 9.8% for the year ended March 31, 2022. The decrease in gross profit margin could be attributed to the higher proportion of revenue generated from superstructure projects, as superstructure projects normally have less risk and uncertainties than foundation & site formation projects and hence lower gross profit margin. Most of the contracts we undertake are contracts with fixed schedules of rates whereby we bear the risks of price fluctuation. In addition, we also bid for projects at a lower budgeted profit margin if the projects have a larger contract sum, such as superstructure projects, as these projects tend to have larger contract sum than foundation & site formation projects but are also relatively straight-forward involving less uncertainties and risks. The following table sets out the gross profit and gross profit margin for our different services for the years ended March 31, 2022 and 2023:

 

For the year ended March 31,

   

2022

 

2023

   

Gross profit

 

Gross profit margin

 

Gross profit

 

Gross profit
margin

   

US$

 

%

 

US$

 

%

Demolition

 

262,028

 

24.9

%

 

57,432

 

30.5

%

Foundation & site formation

 

5,254,342

 

11.4

%

 

5,912,400

 

10.6

%

Superstructure

 

367,225

 

2.8

%

 

119,272

 

0.6

%

Alterations and additions and others

 

66,243

 

9.0

%

 

22,655

 

8.1

%

Overall

 

5,949,838

 

9.8

%

 

6,111,759

 

7.9

%

68

Table of Contents

General and administrative expenses

For the years ended March 31, 2023 and 2022, our general and administrative expenses consisted of office and rental expenses, travelling expenses, depreciation, staff costs, provision of expected credit loss and other miscellaneous expenses. The following table sets forth a breakdown of our general and administrative expenses for the years ended March 31, 2023 and 2022:

 

For the year ended
March 31,

   

2022

 

2023

   

US$

 

US$

Office and rental expenses

 

79,052

 

161,461

Travelling expenses

 

59,740

 

59,606

Depreciation

 

86,379

 

32,733

Legal and professional fee

 

16,595

 

124,039

Staff costs

 

481,192

 

750,891

Impairment loss allowance (expected credit loss)

 

596,192

 

1,565,198

Other miscellaneous expenses

 

21,161

 

23,595

   

1,340,311

 

2,717,523

Our general and administrative expenses increased by 102.8% to US$2,717,523 for the year ended March 31, 2023, from US$1,340,311 for the year ended March 31, 2022, principally due to the increase in provision for expected credit loss, increase in staff costs, and legal and professional fee. For fiscal year 2023, the impairment loss allowance (expected credit loss) significantly increased as compared to 2022. It was because a major customer (Customer D) in fiscal year had accumulated long aged receivables we had made specific provisions of US$212,883 and US$926,332 to the retention receivable and accounts receivable due from Customer D for prudent reasons. For detailed discussion, please refer to the paragraph headed “Accounts receivable, net” in this section below.

Provision for doubtful accounts

The allowance for doubtful debts is based on management’s best estimates of expected credit loss on historical collection experience, the financial condition of its customers, billing disputes and assumptions for the future movement of different economic drivers and how these drivers will affect each other, at the end of the periods indicated. As of March 31, 2022 and 2023, our Company recorded a provision for credit loss of US$290,426 and US$781,981 for contract assets, and US$429,621 and US$1,360,315 for accounts receivable, respectively.

Interest expense

Our interest expense is mainly related to our bank borrowings and increased by 68.9% to US$183,806 for the year ended March 31, 2023, from US$108,829 for the year ended March 31, 2022. The increase in interest expense was principally attributable to the obtaining of new banking facilities during the year ended March 31, 2023 and the increase in interest rate in the second half of the fiscal year 2023.

Other income and expenses

Other income and expenses primarily comprised of government grants, interest income from investment on life insurance policy, sales of steel reinforcement, decrease in surrender value of investment in life insurance policy, rental income, and reversal of retention payables.

The following table sets forth a breakdown of other income or expenses for the years ended March 31, 2022 and 2023:

 

For the year ended
March 31,

   

2022

 

2023

   

US$

 

US$

Government grants

 

14,969

 

 

162,462

 

Interest income from investment on life insurance policy

 

23,660

 

 

67,443

 

Sales of steel reinforcement

 

38,309

 

 

 

Change in surrender value of investment in life insurance policy

 

(105,727

)

 

(179,320

)

Rental income

 

 

 

38,462

 

Reversal of retention payables

 

 

 

72,050

 

Other miscellaneous income (expense), net

 

15,243

 

 

12,451

 

   

(13,546

)

 

173,548

 

69

Table of Contents

Our other expense was US$13,546 for the year ended March 31, 2022, which was mainly attributed to adverse change in surrender value of investment in life insurance policy. Our other income was US$173,548 for the year ended March 31, 2023, mainly attributable to Hong Kong government grants received, reversal of retention payables and interest income from investment of life insurance policy. These government grants were related to the Hong Kong government’s announced Anti-epidemic Fund and Innovation Technology Funds. There were no unfulfilled conditions or other contingencies relating to the government subsidies.

Income tax expense

We are not subject to any income tax in the Cayman Islands and the BVI pursuant to the rules and regulations in those jurisdictions, but our subsidiary, Chiu & Lee Partners, is subject to Hong Kong profits tax. Our income tax expense decreased by 26.0% to US$530,865 for the year ended March 31, 2023, from US$717,724 for the year ended March 31, 2022, primarily attributable to a decrease in our taxable income. Our effective income tax rate, being tax charged for the year divided by profits before taxation, was 15.7% for the year ended March 31, 2023, and 16.0% for the year ended March 31, 2022.

Net income

Our net income decreased by 24.3% to US$2,853,113 for the year ended March 31, 2023, as compared to US$3,769,428 for the year ended March 31, 2022. The decrease in net income was due primarily to the increase in general and administrative expenses and interest expenses as disclosed in the foregoing.

LIQUIDITY AND CAPITAL RESOURCES

Cash Flows

Year ended March 31, 2022, compared to year ended March 31, 2023

Our use of cash was primarily related to operating activities, payment for acquiring property, plant and equipment, payment for life insurance policy, and payment of dividends. We have historically financed our operations primarily through our cash flow generated from our operations and banking facilities.

The following table sets forth a summary of our cash flows information for the years indicated:

 

Year ended
March 31,

   

2022

 

2023

   

US$

 

US$

Cash and cash equivalents and restricted cash at the beginning of the year

 

2,356,708

 

 

2,189,896

 

Net cash provided by operating activities

 

661,261

 

 

4,946,995

 

Net cash used in investing activities

 

(941,595

)

 

(1,387,885

)

Net cash provided by (used in) financing activities

 

113,522

 

 

(1,246,269

)

Cash and cash equivalents and restricted cash at the end of the year

 

2,189,896

 

 

4,502,737

 

Cash provided by operating activities

Our cash inflow from operating activities was principally from receipt of progress payments from customers. Our cash outflows from operating activities were principally due to the payments for purchase of materials from suppliers, subcontracting fees, staff costs, and administrative and other operating expenses. Net cash provided by operating activities reflects our net income adjusted for non-cash items, including depreciation, credit loss, changes in accounts receivable, prepaid expenses, deposits and other receivable, due from a director, accounts payable, accruals and other current liabilities, income tax payable, deferred tax assets, contract liabilities, and lease liabilities — operating lease.

For the year ended March 31, 2022, we had net cash provided by operating activities of US$661,261, reflecting our net income of US$3,769,428, as adjusted for non-cash items, the effects of which was offset by cash used due to change in operating activities of US$3,108,167. Adjustments for non-cash items consisted of (i) change in surrender value of investment in life insurance policy of US$105,727; (ii) change in investment in life insurance policy of US$30,440 (iii) non-cash operating lease expense of US$116,215; (iv) depreciation of right-of-use assets — finance lease of US$41,112; (v) depreciation of property, plant and equipment of US$15,358; (vi) credit loss of US$596,192;

70

Table of Contents

(vii) increase in deferred tax assets of US$69,298; (viii) increase in accounts receivable of US$10,241,687; (ix) increase in prepaid expenses, deposits and other receivable of US$357,855; (x) decrease of due from director of US$15,603; (xi) increase in accounts payable, accruals and other current liabilities of US$9,477,038; (xii) increase in contract liabilities of US$1,102,972; (xiii) decrease in income tax payable of US$214,338; (xiv) increase in contract assets of US$3,610,975; and (xv) decrease in lease liabilities — operating lease of US$114,671.

For the year ended March 31, 2023, we had net cash provided by operating activities of US$4,946,995, reflecting our net income of US$2,853,113, as adjusted for non-cash items, the effects which were partly offset by cash provided due to change in operating activities of US$2,093,882. Adjustments for non-cash items consisted of (i) change in surrender value of investment in life insurance policy of US$179,320; (ii) change in investment in life insurance policy of US$34,365 (iii) non-cash operating lease expense of US$118,537; (iv) depreciation of right-of-use assets — finance lease of US$65,780; (v) depreciation of property, plant and equipment of US$42,735; (vi) credit loss of US$1,565,198; (vii) increase in deferred tax assets of US$223,384; (viii) decrease in accounts receivable of US$2,052,832; (ix) increase in prepaid expenses, deposits and other receivable of US$718,710; (x) increase in accounts payable, accruals and other current liabilities of US$5,295,068; (xi) decrease in income tax payable of US$7,408; (xii) decrease in contract liabilities of US$1,471,271; (xiii) increase in contract assets of US$4,719,211; and (xiv) decrease in lease liabilities — operating lease of US$119,969.

Although there was a slight decrease in net income for the year ended March 31, 2023 as compared with 2022, cash provided by operating activities significantly increased as we manage to decrease year-end accounts receivable, which led to significant improvement of cash provided by operating activities. As compared to the year ended March 31, 2022 when we recorded an increase in accounts receivable as of March 31, 2022, albeit partly offset by the increase in accounts payable. Approaching the year ended March 31, 2022, we had completed significant works in a few concurrent large-scale foundation & site formation projects with a major customer (“Customer D”), which is a foundation contractor listed on the Main Board of The Stock Exchange of Hong Kong Limited. There was as such a temporal build-up of accounts receivable balance with Customer D as of March 31, 2022 and it is an industry norm that the main contractors in Hong Kong take a considerable longer time for final payments to be issued to subcontractors when projects are practically completed than issuing interim payments during projects being undertaken, which normally are issued within 30 to 60 days upon invoices. Accounts receivable due from Customer D represented 45.3% of our total accounts receivable as of March 31, 2022. As an industry practice, we entered into back-to-back contracts with our subcontractors whereby we adopt a pay-when-paid condition with our subcontractors. This helped our management with operating cash flow amid the foreseeable variability of settlement period of contract payments from our customers, especially for practically completed projects as it is not unusual to take a year to negotiate and agree a final account, or even longer in case there are complex variation instructions and alteration works as compared to original construction plans. With a different mix of customers contributing revenues to the Company, during the year ended March 31, 2023, proportion of accounts receivable due from Customer D decreased to 35.6% of our total account accounts receivable as of March 31, 2023.

Net cash used in investing activities

For the years ended March 31, 2023 and 2022, cash used in investing activities was US$1,387,885 and US$941,595. For the year ended March 31, 2022, cash used in investment activities was for the initial payment for acquiring property, plant and equipment of US$147,436 and payment for life insurance policy of US$794,159. For the year ended March 31, 2023, cash used in investment activities was for the initial payment for acquiring property, plant and equipment of US$28,205 and payment for life insurance policy of US$1,359,680.

Net cash used in/provided by financing activities

For the year ended March 31, 2022, net cash provided by financing activities was US$113,522. Financing cash inflow was from the proceeds from new bank loans of US$2,881,008 while being offset by cash outflows including (i) advance to related party of US$1,372,348; (ii) repayment of bank loans of US$930,873; (iii) initial payment of finance lease of US$51,282; (iv) principal payment of finance lease liabilities of US$32,767; and (v) payment of offering costs of US$380,216.

For the year ended March 31, 2023, net cash used in financing activities was US$1,246,269. Financing cash inflow was from the proceeds from new bank loans of US$3,781,831 while being offset by cash outflows including (i) advance to related party of US$1,497,786; (ii) repayment of bank loans of US$2,720,453; (iii) initial payment of finance lease of US$26,565; (iv) principal payment of finance lease liabilities of US$113,598; and (v) payment of offering costs of US$669,698.

71

Table of Contents

Critical Accounting Policies and Estimates

The preparation of financial statements in conformity with US GAAP requires management to make estimates and assumptions that affect the reported amounts of assets, liabilities and contingencies at the date of the financial statements as well as the reported amounts of revenues and expenses during the reporting period. As a result, management is required to routinely make judgments and estimates about the effects of matters that are inherently uncertain. Actual results may differ from these estimates under different conditions or assumptions.

Critical accounting policy is both material to the presentation of financial statements and requires management to make difficult, subjective or complex judgments that could have a material effect on financial condition or results of operations. Accounting estimates and assumptions may become critical when they are material due to the levels of subjectivity and judgment necessary to account for highly uncertain matters or the susceptibility of such matters to change, and that have a material impact on financial condition or operating performance.

Critical accounting estimates are estimates that require us to make assumptions about matters that were highly uncertain at the time the accounting estimate were made and if different estimates that we reasonably could have used in the current period, or changes in the accounting estimate that are reasonably likely occur from period to period, have a material impact on the presentation of our financial condition, changes in financial condition or results of operations. Due to the level of activity and lack of complex transactions, we believe there are currently no critical accounting policies and estimates that affect the preparation of our financial statements.

Current Assets and Current Liabilities

The following table sets forth a breakdown of our current assets and liabilities as of the dates indicated.

 

As of March 31,

   

2022

 

2023

   

US$

 

US$

CURRENT ASSETS

       

 

Cash and cash equivalents

 

1,933,486

 

4,502,737

 

Restricted cash

 

256,410

 

 

Accounts receivable, net

 

14,560,585

 

11,434,111

 

Contract assets, net

 

1,543,500

 

5,391,789

 

Deferred costs

 

380,216

 

1,049,914

 

Prepaid expenses, deposits, and other receivable – current

 

204,868

 

854,142

 

Total current assets

 

18,879,065

 

23,232,693

 

         

 

CURRENT LIABILITIES

       

 

Bank loans – current

 

1,408,939

 

1,995,043

 

Finance lease liabilities – current

 

85,483

 

125,111

 

Operating lease liabilities – current

 

86,386

 

62,986

 

Accounts payable, accruals, and other current liabilities

 

15,128,533

 

20,423,601

 

Contract liabilities

 

1,471,271

 

 

Dividend payable

 

166,113

 

1,745,250

 

Income taxes payable

 

102,440

 

95,032

 

Total current liabilities

 

18,449,165

 

24,447,023

 

Net current assets

 

429,900

 

(1,214,330

)

Accounts receivable, net

Accounts receivable represented receivables from our customers arising from our contract work. We generally grant our customers a credit period typically ranging from 30 to 60 days, depending on their reputation and transaction history. Our accounts receivable decreased by 21.5% to US$11,434,111 as of March 31, 2023, from US$14,560,585 as of March 31, 2022.

As compared to 2023, accounts receivable as of March 31, 2022 were apparently higher despite having lower revenue because as of March 31, 2022, among the accounts receivable, the largest balance was attributed to Customer D and accounts receivable due from Customer D represented 45.3% of our total accounts receivable as of March 31, 2022 (35.6% of accounts receivable were due from Customer D as of March 31, 2023). We were engaged by Customer D in four foundation and excavation and lateral support projects which are located in the same major redevelopment area in Hong Kong. As these projects were substantial in size and took place in overlapping periods, revenue recognized

72

Table of Contents

from Customer D increased significantly and hence its balance of accounts receivable as of March 31, 2022 also increased. Our management regularly reviews the settlement status of and credit risks associated with Customer D’s accounts receivable. During the year ended March 31, 2023, our revenues from projects were generated from a wider mix of customers, as such, as construction contracts from Customer D are being completed, the accounts receivable due from and revenue recognized from Customer D had both decreased during the year ended March 31, 2023. It is common in the construction industry that customers take relatively longer time, around 12-18 months, to prepare the final accounts of the project before the final payment is made to the contractor. For the sake of prudence, as the balance due from Customer D had become long outstanding, we had made specific provision to the accounts receivable due from Customer D and are taking measures to reduce the credit risk exposure, including purchasing fixed assets from Customer D by offsetting the accounts receivable following the fiscal year 2023.

Restricted cash

Restricted cash represents funds that are pledged as security for our banking facilities. All restricted bank deposits are denominated in HK$. Our restricted bank deposits were US$256,410 as of March 31, 2022. Bank loans amounted to HK$25 million with interest bearing ranging from 2.75% per annum to 5% per annum (2.25% and 5% for FY2022) were secured by our restricted bank deposit and a personal guarantee of a director of Chiu & Lee Partners. The balance of restricted cash was reduced to nil as of March 31, 2023 as these bank loans matured prior to the fiscal year end.

Contract assets

Our contract assets represent revenue recognized before being unconditionally entitled to the consideration under the payment terms set out in the contract. Our contract assets — current portion increased by 249.3% to US$5,391,789 as of March 31, 2023, from US$1,543,500 as of March 31, 2022. The increase in contract assets is mainly due to the significant increase in retention receivables attributable to the increase in scale of operations, i.e. value of projects undertaken increased.

Contract liabilities

Our contract liabilities represent payments received or receivable (contracts receivable) in excess of revenue recognized on uncompleted contract excluding retainage. Contract liabilities were US$1,471,271 as there were advanced payments received for certain projects which were ongoing as of March 31, 2022. Contract liabilities were nil as of March 31, 2023.

Deferred costs

We recognized deferred costs of US$1,049,914 and US$380,216 as of March 31, 2023 and March 31, 2022 which were fees paid to professional parties whose services were to be rendered for the preparation of the listing of our Ordinary Shares.

Prepaid expenses, deposits, and other receivable current

Prepaid expenses, deposits and other receivable — current increased by US$649,274 to US$854,142 as of March 31, 2023 from US$204,868 as of March 31, 2022, due to the increase of bond collateral by US$635,897. Bond collateral was required for our Group to take out surety or performance bonds as sometimes required by customers for undertaking construction projects.

Bank loans

During the two years ended March 31, 2022 and 2023, there were a number of bank loans in force granted by a bank in Hong Kong. Total bank loans (including current and non-current) amounted to US$3,200,001 and US$4,261,379 as of March 31, 2022 and March 31, 2023. We obtained these bank loans to support our general working capital requirements, purchase of machinery, and the payment of tax. These bank loans had a maturity of between 12 months and 120 months and unless demanded repayment by the bank, were to be repaid by straight line monthly repayments and required one or more of securities ranging from (i) personal undertaking and personal guarantee given by Mr. Keung Yun Yuen; (ii) charge over cash deposit with the lending bank; (iii) assignment of a life insurance; (iv) Chiu & Lee Partners maintaining a required level of adjusted tangible net worth; and/or (v) a guarantee issued by HKMC Insurance Limited under the Hong Kong SME Financing Guarantee Scheme, a loan guarantee

73

Table of Contents

scheme launched by the Hong Kong government to help small and medium enterprises to secure bank loans, which the lending bank required. The interest rates of these bank loans ranged from best lending rate minus 2.25% to best lending rate per annum, where the best lending rate had been 5.0% since April 2021 and rose to 5.125% in September 2022 and to 5.625% in December 2022 until March 31, 2023. The best lending rate is currently at 5.875%.

Accounts payable, accruals, and other current liabilities

The following table sets forth a breakdown of our accounts payable, accruals, and other current liabilities as of the dates indicated:

 

As of March 31,

2022

 

2023

   

US$

 

US$

Trade payables

 

10,285,196

 

12,445,006

Retention payables

 

4,754,205

 

7,961,337

   

15,039,401

 

20,406,343

Accrued expenses

 

89,132

 

17,258

Total

 

15,128,533

 

20,423,601

Our accounts payable comprises trade payables and retention payables. Our trade payables are mainly related to invoices of services provided by our subcontractors and the purchase of materials and tools from our suppliers. Our subcontractors and suppliers usually granted us a credit period between 14 and 60 days. Certain suppliers, especially newly engaged suppliers, may request prepayment before delivery. Our retention payables are mainly related to the retention money retained from the progress payments to our subcontractors as a similar practice that our customers withhold retention money from the progress payments to us. The retention money we withhold from our subcontractors is usually between 5% and 10% of each progress payment, subject to a cap of 5 to 10% of the subcontract sum.

Our accounts payable, accruals, and other current liabilities increased by 35.0% to US$20,423,601 as of March 31, 2023, from US$15,128,533 as of March 31, 2022, as both trade payables to our suppliers and subcontractors and retention payables to subcontractors increased during the year ended March 31, 2023.

The substantial increase in accounts payable, accruals, and other current liabilities was due to the increase in value of projects undertaken by us as we purchased construction materials and engaged subcontractors and the result of our Directors’ effort to negotiate with subcontractors and suppliers for a longer payment term to smooth our working capital requirements given the commencement of some new projects.

Income taxes payable

Our income taxes payable decreased by 7.2% to US$95,032 as of March 31, 2023, from US$102,440 as of March 31, 2022 as a result of lower taxable profit.

Contractual Obligations

The following table summarized our contractual obligations as of March 31, 2023:

 

Payment due by period

   

Less than
1 year

 

1 to 3 
years

 

3 to 5 
years

 

More than
5 years

 

Total

   

US$

 

US$

 

US$

 

US$

 

US$

Contractual Obligations:

                   

Operating leases

 

64,413

 

3,936

 

 

 

68,349

Financial leases

 

135,190

 

146,553

 

 

 

281,743

Bank loans

 

1,995,043

 

999,612

 

770,418

 

496,306

 

4,261,379

Total contractual obligations

 

2,194,646

 

1,150,101

 

770,418

 

496,306

 

4,611,471

74

Table of Contents

Off-Balance Sheet Arrangements

We have no off-balance sheet arrangements, including arrangements that would affect its liquidity, capital resources, market risk support, credit risk support, or other benefits.

Quantitative and Qualitative Disclosure About Market Risk

Credit risk

Assets that potentially subject us to a significant concentration of credit risk primarily consist of cash, accounts receivable, contract assets, and other current assets.

We believe that there is no significant credit risk associated with cash, which was held by reputable financial institutions in the jurisdictions where the Company and its subsidiaries are located. The Hong Kong Deposit Protection Board pays compensation up to a limit of HK$500,000 (approximately US$64,130) if the bank with which an individual/company holds its eligible deposit fails. As of March 31, 2023, cash balance of US$4,502,737 was maintained at financial institutions in Hong Kong and approximately HK$500,000 were insured by the Hong Kong Deposit Protection Board.

We have designed our credit policies with an objective to minimize exposure to credit risk. Our “Receivables” are very short term in nature and the associated risk is minimal. We conduct credit evaluations on our customers and generally do not require collateral or other security from such customers. We periodically evaluate the creditworthiness of the existing customers in determining an allowance for doubtful accounts primarily based upon the age of the receivables and factors surrounding the credit risk of specific customers.

Foreign currency risk

We are exposed to foreign currency risk primarily through service income or expenses that are denominated in a currency other than the functional currency of the operations to which they relate. The currencies giving rise to this risk are primarily US$. As HK$ is currently pegged to US$, our exposure to foreign exchange fluctuations is minimal.

Interest rate risk

We are exposed to cash flow interest rate risk in relation to variable rates of our bank borrowings. However, by borrowing at floating rate, we minimize fair value interest rate risk. We do not have an interest rate hedging policy to hedge against the risk of fluctuating interest rates. However, our management closely monitors interest rate exposures, assesses our Group’s ability to repay bank loans from time to time and takes measures as necessary to contain the assessed risk.

The following table presents the potential effects on net interest income or expenses of a hypothetical change of +/- 250 bps in year/period-end interest-rates, applied to the Group’s bank borrowings and cash and cash equivalents.

For the year ended March 31, 2022

 

For the year ended March 31, 2023

Notional
net interest
(expenses)/
income (US$)

 

Impact on
net interest
(expenses)/
income +250 bps

 

Impact on
net interest
(expenses)/
income -250 bps

 

Notional
net interest
(expenses)/
income (US$)

 

Impact on
net interest
(expenses)/
income +250 bps

 

Impact on
net interest
(expenses)/
income -250 bps

108,829

 

(67,247

)

 

65,737

 

183,806

 

(101,040

)

 

97,310

75

Table of Contents

BUSINESS

Overview

We are a holding company incorporated in the Cayman Islands with operations conducted by our Hong Kong Operating Subsidiary, Chiu & Lee Partners.

We are an established one-stop shop construction services provider in Hong Kong with over 40 years of experience in the construction industry. We principally engage in (i) foundation and site formation work, which mainly include piling work, excavation and lateral support work and pile cap construction, work; (ii) general building work and associated services, which mainly include development of superstructures, alterations, and additions work; and (iii) other construction work, which mainly includes demolition.

We are able to undertake construction work as either a main contractor or a subcontractor. Our construction services include both build-only and design-and-build. We undertake primarily construction projects in the private sector in Hong Kong.

We have been registered as a specialist contractor in the categories of foundation, site formation, and demolition work since 2006 and as a general building contractor since 1999 with the Buildings Department of Hong Kong.

Our Competitive Strengths

We believe the following competitive strengths differentiate us from our competitors:

Established market presence in the construction industry with over 40 years of operating history

We have more than 40 years of experience in the construction industry in Hong Kong. We have undertaken a number of foundation and site formation projects, demolition work, and general building work projects of various nature, including offices, hotels, schools, industrial buildings, and private residential buildings in Hong Kong. We had completed 20 construction projects with an aggregate contract sum of approximately HK$776 million for the years ended March 31, 2023 and 2022. As of the date of this prospectus, we have 14 construction projects on hand (including projects in progress and projects yet to commence) with a total awarded contract sum of approximately HK$1,267 million. We believe that our long-term presence in the construction industry in Hong Kong together with our proven track record during that time have enabled us to develop a good reputation and earned us trust from our customers in our ability to deliver quality work in a timely and satisfactory manner.

Possess a wide range of qualifications to undertake a range of construction projects

Under the current contractor registration system in Hong Kong, a contractor must register with the Buildings Department of Hong Kong as general building contractor or specialist contractor. Registered general building contractors may carry out general building works and street works which do not include any specialized works (including demolition works, foundation works, ground investigation field works, site formation works and ventilation works) designated for registered specialist contractors.

Under section 8B(2) of the Buildings Ordinance (Chapter 123 of the Laws of Hong Kong), an applicant for registration as general building contractor or as specialist contractor must satisfy the Building Authority on the following aspects:

1.      if the applicant is a corporation, the adequacy of its management structure;

2.      the appropriate experience and qualifications of the applicant’s personnel;

3.      the applicant’s ability to have access to plant and resources; and

4.      the ability of the person appointed to act for the applicant for the purposes of the Buildings Ordinance to understand building works and street works through relevant experience and a general knowledge of the basic statutory requirements.

For registration as a registered specialist contractor, an applicant must additionally satisfy the Building Authority that it has the necessary experience and, where appropriate, professional and academic qualifications, to undertake work in the specialist category.

76

Table of Contents

We have been a registered specialist contractor in the categories of foundation, site formation, and demolition work since 2006 and a registered general building contractor since 1999 with the Buildings Department of Hong Kong. We believe that the aforementioned qualifications granted by the respective government departments in the construction industry allow us to provide a wide range of construction services to our customers and give us a competitive edge in bidding for projects that require the range of services that can be offered by us. Our registrations with the Buildings Department of Hong Kong allow us to engage in foundation and site formation work, which mainly include piling work, excavation and lateral support work and pile cap construction, work; (ii) general building work and associated services, which mainly include development of superstructures, alteration, and addition work; and (iii) other construction work, which mainly includes demolition work.

We also believe that the abovementioned qualifications enable us to be the main contractor for a wide spectrum of construction services, which is value added to our customers, as time can be saved for appointing various contractors of different trades to take carry out the respective works on the construction sites.

Strong and stable network of subcontractors and suppliers

We have established long and stable business relationships with our subcontractors, among which, over 10 subcontractors have already had business relationships with us for over 4 years. Having long-term and stable working relationships with our subcontractors enable us to have comprehensive assessment of their ability and quality of work and have stable subcontracting services.

We also maintain good relationships with our major construction materials suppliers, among which over 10 suppliers have already had business relationships with us for over 4 years. This helps us to ensure the quality of materials supplied to us and ensure that we would have an adequate supply of materials, particularly under tight supply situations.

Stable relationships with our customers

We have established stable business relationships with our customers and among our five largest customers, by revenue, for the years ended March 31, 2023 and 2022. We have been providing construction services to them for a period ranging on an average of 3 to 4 years, and we have received recurring tender invitations from them on different projects. We believe that our operating history, together with the stable relationships with our customers, would increase our recognition and visibility in the market and enable us to attract potential business opportunities.

Experienced and professional management team

Our management members bring with them approximately 30 years of experience in the construction industry. Mr. Keung Yun Yuen, our director and chairman of the board, has been in the construction industry for approximately 30 years and has participated in hundreds of foundation, site formation, and demolition work projects. Mr. Chan Lee Chuen, our director and chief executive officer, has also been in the construction industry for almost 30 years and has amassed extensive experience acting as project manager and construction advisor for construction projects. Their qualifications and leadership have facilitated us in formulating business strategies and competitive tenders that are essential to us in securing new business. Their technical know-how and industry knowledge acquired and accumulated over the years have also assisted us in carrying out efficient management of project work and in coping with uncertainties encountered during the projects’ operation. We believe that our experienced and professional management team is an invaluable asset and will continue to contribute to our business development and future prospects.

Our Strategies

We intend to pursue the following strategies to further expand our business:

Adhere to our one-stop shop strategy and prudent financial management

Due to our experience in performing different kinds of construction work (including alterations and additions work, demolition work, foundation work, site formation work, and superstructure work), we can provide a one-stop shop experience to our customers (i.e., from demolition work to superstructure work and redevelopment projects). We provide both build-only and design-and-build construction services. To facilitate our business expansion, we will continue to promote our one-stop shop strategy actively.

77

Table of Contents

We will continue to identify and capture emerging opportunities and closely monitor our capital and cash positions, particularly labor costs and material costs, which have augmented tremendously in recent years. We will also continue to focus on our internal control system to ensure adequate cash flow for our ongoing capital requirements and to achieve maximum cost savings by streamlining our operation processes.

Compete for sizeable and profitable construction projects

The number and size of foundation work projects that can be executed by us concurrently at any given time is limited by our resources, including the capacity of our machinery and the availability and experience of our manpower. In other words, the bottleneck of our profitability would be caused by the insufficiency or the inability to locate machinery and skilled labor during the operation period of a project. As such, we believe that we should focus on deploying our resources toward competing for sizeable and profitable foundation work projects in Hong Kong. We will also sharpen our efforts in securing new projects; to this end, we will proactively maintain relationships with property developers, main contractors and subcontractors in Hong Kong and submit more quotes in an effort to fill our project pipeline. We consider that these measures have to be adopted concurrently, so as to minimize the idling time of machinery or avoid costs incurred for excessive manpower.

Grow through selected strategic acquisition for machinery and robotics

Most of our work requires the use of different machinery and equipment. Our capacity to carry out construction work for our customers depends largely on the availability of our machinery. We believe that possessing our own machinery is more cost effective than leasing or relying on the provision of machinery by third parties, such as our customers and subcontractors, because (i) we can ensure that the machinery is optimally serviced and exercise greater control over the deployment of our machinery, (ii) we will not be affected by fluctuation in the leasing costs of machineries, (iii) our reliance on available machinery and equipment from third parties is reduced, and (iv) the accuracy of our project cost estimation will be enhanced, thus enabling us to prepare tenders more accurately and competitively.

Integrating robotic technologies and applying automation in our construction work are crucial for us to maintain competitiveness and can enhance our technical ability and strengthen our capability to cope with the different needs and requirements of different projects. The implementation of on-site construction robots can also allow our construction workers to focus on more skilled work while robots complete more mundane tasks and pave way for a safer work site, with more risky tasks such as demolition work done by construction robots and repetitive tasks automated. We believe adding robotics to our construction work can increase our work efficiency, lower operation costs, and insurance expenses, while it may also help us counter unforeseeable labor shortages, such as during the times of a pandemic.

Enhance our participation in undertaking construction works from both the private sector and the public sector

Our capacity in undertaking construction projects depends on the amount of available working capital. There may be time lags between payments to our subcontractors and suppliers and receiving payments from our customers. We believe the proceeds from the offering will strengthen our available financial resources and working capital and allow our key Operating Subsidiary to undertake more projects.

Although we have been involved as a subcontractor for construction works in the public sector, our main focus and customer base is in the private sector. We believe it would be beneficial to diversify our customers to the public sector and will actively seek for more construction works from government departments and quasi-governmental organizations. We will seek through establishing a machinery fleet, strengthening our financial capacity and manpower to tend for more public sector projects to meet the respective work experience and qualify to be admitted as an approved contractor for site formation and as an approved specialist contractor for foundation works on the Approved Public Works Contractors List and the Approved Specialist Contractors List maintained by the Development Bureau of Hong Kong, respectively, allowing us to tender for public sector projects with larger contract sum as a main contractor.

Further enhance our project management capability

As we further expand our business and capture more sizeable projects, we will need additional project managers and engineers, quantity surveyors, safety officers, and site foremen with appropriate knowledge, qualifications, and experience to oversee and execute the daily operations of our projects as well as meet the relevant requirements

78

Table of Contents

set by government authorities. We consider that our reputation has been built on years of satisfactory construction management services we provided to our customers and in order to continually deliver quality work, we intend to expand our manpower by recruiting project management and support staff to cope with our business development.

OUR BUSINESS OPERATIONS

We principally provide (i) foundation and site formation work, which mainly include piling work, excavation and lateral support work and pile cap construction, work; (ii) general building work and associated services, which mainly include development of superstructures, alteration, and addition work; and (iii) other construction work, which mainly includes demolition work.

(i)     Foundation and site formation work:

79

Table of Contents

The foundation work that we generally provide includes (i) piling work, (ii) excavation and lateral support work, (iii) construction of footings and pile caps, and (iv) site formation work. Piling work normally refers to the installation of socketed H-piles, mini-piles, and bored piles as the foundation for buildings or other superstructures to be built above. The general purpose of excavation and lateral support work is to establish a supported area for deep excavation so as to facilitate subsequent construction of footing foundation or pile caps for further infrastructure development. Our foundation work services include both build-only and design-and-build, where the latter refers to the structural design to include construction drawings and engineering calculations, as well as seeking of regulatory approval for the construction of the foundation designed and subsequently carrying out the construction work.

Generally, site formation work mainly includes removal of buildings or unwanted structures, shrubs and trees, and surface soil and debris; excavation on sloping land to design formation level; reduction of natural slope or filling land areas; natural slope stabilization work; and construction of access roads and drainage systems at construction sites. Site formation work is aiming to prepare a construction site for subsequent foundation work, substructure construction, and/or superstructure construction.

(ii)    General building work (development of superstructures):

80

Table of Contents

Our general building work is generally the construction of low to high-rise residential, industrial, and school buildings for development and redevelopment projects. The scope of our superstructure construction work includes, but is not limited to, structural steel framework erection, structural concrete work, internal and external finishing work, roofing work, installation of window walls and curtain walls, and electrical and mechanical installation.

(iii)   Demolition work:

Demolition means dismantling, razing, destroying, or wrecking any building or structure or any part thereof by pre-planned and controlled methods. In general, the scope of demolition work includes demolition of existing structures and removal of waste in order to get the construction site ready for the next construction step.

OUR OPERATION FLOW

Set out below is the flow chart summarizing the usual workflow of a construction project:

81

Table of Contents

Invitation for tendering or quotation, preparation, and submission

As a usual practice, we are invited by our customers to submit a tender or provide a quotation for tendering for a potential project. Our tendering team generally consists of a director, a project manager, and a quantity surveyor. They assist our directors on the preliminary review and assessment of a potential project. We would consider (i) the specifications, environment conditions (for example, the underground and geological condition for a foundation project), and difficulties of the potential project; (ii) the duration of the potential project; (iii) the site location and the conditions and adjacent risk of building structures nearby; (iv) the resources’ availability; and (v) our previous experience with the customer. Once our directors consider the expected profitability of a potential project to be acceptable based on the review and assessment, we will prepare and submit a tender or provide a quotation to our customer accordingly.

Our directors and the tendering team would then prepare tender documents, including (i) method statements and a construction program with an estimated time frame for each stage, (ii) bills of quantities, (iii) work drawings (if required), (iv) terms of the contract, and (v) a site safety supervision plan in accordance with the specifications agreed with our customer.

Project acceptance

Upon receipt of our tender, our customer may by way of interview or enquiries clarify with us the particulars of our submitted tender. Once our customer decides to engage us, generally, we will be informed of our acceptance by a letter of award or letter of intent. We may then enter into a formal engagement agreement with the customer. For projects in which we act as subcontractor and that our customer is still in the process to be engaged as the main contractor, a legally binding pre-bid agreement, instead of a formal engagement, will be entered into upon pending the acceptance of our customer as the main contractor for the project. As soon as we are engaged by our customer, we would secure our engagement with our subcontractors and arrange with our suppliers for the supply of materials for the project.

Project execution

Once our engagement is confirmed, we commence the implementation of the project by: (i) forming a project team, (ii) planning and arranging the required machinery to be delivered to the construction site, (iii) procuring and arranging with suppliers for the required materials for the project, and (iv) negotiating and finalizing on the subcontracting arrangement if necessary.

Forming a project team

Depending on the scale and complexity of the project, our project team generally comprises the following key personnel: project manager, site agent, engineer, quantity surveyor, safety officer, foreman, machinery operator, and general laborers. Our directors will also closely monitor the progress of the project on a continuous basis and will ensure statutory requirements are complied with. Our project team will oversee the project on site and report to our directors on the project status and identify any problems that need to be resolved from time to time. Set out below are some general duties performed by the major roles of the project team:

Project Manager

Our project manager is mainly responsible for communicating with other members of the project team on the project status, reviewing the progress report and site daily record prepared by our engineer, and liaising with subcontractors for the work conducted by subcontractors. The project manager is also the principal communication channel with the customer of the construction project on site and deals with all technical issues with instructions from our customer. On an ongoing basis, our project manager will directly report to our directors for the project status and issues, and the project manager will attend the progress meeting to report the project progress to our customer.

Site Agent

Our site agent is responsible for inspecting fieldwork, including monitoring the work progress and communicating with our foreman about each project’s daily operations. For smaller projects, for which a project manager is not required, our site agent would also hold the responsibilities of the project manager.

82

Table of Contents

Engineer

Our engineer is responsible for preparing the site daily record to properly record (i) the number of workers, and (ii) a description of work performed by our workers or subcontractors. For our construction of excavation and lateral support system or other necessary temporary structures, depending on the subcontracting requirement, we may need to provide our construction designs with supporting calculations; the design work is prepared by our engineers and submitted to our customer for approval. Our engineer should pass the site daily record to the project manager for review and keep the site daily record in the site office for a spot check by our directors.

Quantity surveyor

Our quantity surveyor is responsible for inspecting the work progress on site, checking with our project manager for understanding the updated progress status, and preparing progress payment applications. For progress monitoring purposes, our quantity surveyor is required to update our project manager on the latest certified progress from our customer. The quantity surveyor’s duties also include measuring the materials delivered on site and the work done by our subcontractors, as well as assess suppliers’ and subcontractors’ payment requests.

Safety officer

Our safety officer is responsible for setting up safety plans for workers before carrying out their work at the construction site, inspecting machinery and equipment to ensure they are safe to be used, conducting regular safe walks to maintain a safe working environment and site tidiness, handling safety incidents, and keeping safety records.

Foreman

Our foreman is responsible for coordinating, providing guidance to, and supervising our workers and subcontractors on site. Our foreman is also required to act as a safety supervisor.

Planning and arranging machinery

Most of our work involves the usage of machinery. Our directors will determine the types of machinery to be used, the time for the use of machinery, and the logistics of delivery of machinery.

Purchasing of construction materials

In line with our tender awarded and the construction master program, our quantity surveyor will place orders with our list of approved suppliers and purchase the required materials. In some projects, certain construction materials might be purchased by our customer on our behalf for their projects. Our construction materials are purchased from and sent to the site directly by our suppliers and, as the materials are acquired on a project-by-project basis in accordance with the project specifications, we rely on the accurate estimation of the amount of construction materials needed, which our quantity surveyor normally allows for a small buffer in each batch of order to counter for wastage. As such, we do not retain any construction materials as inventory.

Negotiating on and/or finalizing the subcontracting arrangement to third parties

Depending on our capability, amount of resources, possession of the required machinery, cost effectiveness, and the complexity of the project, we divide the project into different trades, such as some kind of piling construction, reinforcement fixing, concreting and design work, and we subcontract these trades to subcontractors and we remain responsible for the overall project management.

Monitoring, quality inspection, and testing

Our project manager regularly provides progress reports to our directors. Such reports include, but are not limited to, project performance, machinery and facilities on site, delays and causes, and safety and environmental matters. In addition, we would normally hold progress meetings with our customer throughout the project duration. The key members of the project team will keep monitoring the progress of their respective work, and they are all supervised by the project manager. We adopt a stringent quality standard pursuant to which our project team is required

83

Table of Contents

to complete the construction work on time, avoid poor workmanship, and minimize defects. Our project team peruses the project specifications carefully and maintains constant dialogue with the main contractor (in projects where we are the subcontractor) and/or representative of the ultimate customer (in projects where we are the main contractor) so as to understand the acceptance standard before the completed work is to be inspected. The work progress of the site would be inspected by our quantity surveyor before we prepare the payment application to our customer. For materials or work that requires sampling and testing, we will engage a third party to perform testing on samples. Generally, samples selected for testing are delivered to an approved laboratory to perform mechanical tests, such as compression and tensile strength tests. Our project manager will review the test results and submit the same to our customers, when required.

Customer inspection and acceptance

In the course of execution of our construction projects, our customer would inspect our work done from time to time. Depending on the types of structures, samples may be taken out to a laboratory or loaded on site, and our customer’s acceptance will therefore be subject to confirmation of the samples’ strength or material consistency complying with the respective specifications. Upon its satisfaction, our customer would issue an approval form specifying the activity completed by stages. Once we have completed the entire project to the satisfaction of our customer, we will agree with our customer the final account, which will take into account the measurement of all our work done, retention payables, and value of variation orders. When the project is complete, a final account will also be agreed for the final payment and the retention payable, if any.

Progress payment

Based on the activity carried out in the preceding month, we will submit to our customer a payment application, which generally includes the estimated amount for our work done along with any variation, the list of materials delivered to the site, and the costs of the material delivered. The amount may be netted off with any costs of certain construction materials procured on our behalf by the main contractor (if we are its subcontractor). Once our customer is satisfied with our payment application, a payment certificate will be issued to us and the payment will be made to us accordingly. Our customers will usually retain up to 10% of each interim payment and up to a maximum limit of 5% of the contract sum as retention money for the project.

Defects liability period and release of retention money

For our projects, subject to the requirements of different projects, a defects liability period of up to 18 months from the date of completion of the project may be provided by us. During the defects liability period, we are responsible for remedial work that may arise from the defective work or materials used. Generally, the retention money will be withheld by our customer, 50% of which will be released to us on completion of the project and the remaining 50% upon the agreement of the final account between our customer and us, which usually takes approximately one year.

OUR PROJECTS

As at the date of this prospectus, we have 14 projects on hand (including projects in progress and projects that are awarded to us but have not yet commenced). For the years ended March 31, 2023 and 2022, we completed 10 and 10 projects, respectively.

84

Table of Contents

Below is a summary of the ongoing projects as at the date of this prospectus:

No.

 

Project

 

Nature of Works

 

Estimated/ Time of Completion

 

Termination Provisions

1. 

 

Hillier Street

 

Foundation works

 

October 2023

 

None

2. 

 

Hoi Yu Street

 

Site maintenance works

 

N/A

 

None

3. 

 

37 Barker Road

 

Demolition works

 

September 2023

 

None

4. 

 

The City University of Hong Kong 

 

Demolition works

 

September 2023

 

None

5. 

 

Gage Street Stage 2

 

Foundation works

 

September 2023

 

None

6. 

 

42-44 Yiu Wah Street

 

Foundation works

 

August 2023

 

None

7. 

 

24A and 24B Granville Road

 

Demolition and foundation works

 

October 2023

 

None

8. 

 

No. 71 How Ming Street

 

Foundation works

 

January 2024

 

None

9. 

 

No. 121 King Lam Street

 

Superstructure works

 

December 2023

 

None

10.

 

470-478 Chatham Road North

 

Foundation works

 

April 2025

 

None

11.

 

1-3 Granville Circuit

 

Foundation works

 

November 2023

 

None

12.

 

2-8 Mansfield Road

 

Foundation works

 

September 2023

 

None

13.

 

9-11 Mansfield Road

 

Foundation works

 

June 2024

 

None

14.

 

67-77 Nam On Street

 

Foundation works

 

July 2024

 

None

PRICING STRATEGY

Our pricing is determined on a cost-plus basis with emphasis on factors that include: (i) the difficulties and methodology of the project with references made to available site geological or investigation report and buildings erected in the vicinity, (ii) the estimated number and types of workers required, (iii) the estimated number and types of machinery required, (iv) the completion time requested by customer, (v) the estimated direct costs to be incurred, (vi) the prospect of obtaining future contracts from the customer, and (vii) the prevailing market conditions. Our directors consider that it is of utmost importance to estimate project cost accurately, as most of our construction projects in the private sector are a lump-sum contract or fixed unit price, which is based on estimated costs plus a mark-up margin, such that unexpected adverse fluctuation in price, budget, or time overrun may result in diminished project return or even a loss. Despite the contracts we enter into with our customers normally being lump-sum contracts, the total contract sum is normally based on the sum of individual rates and quantities listed in a set of schedules typically known as the bills of quantities. When there are changes in the quantities or scope of work, the bills of quantities are generally referred to for agreeing the price of the variations.

CUSTOMERS

Our customers are primarily property developers and main contractors of property development and civil engineering projects in Hong Kong.

Our five largest customers accounted for approximately 83.4% and 85.1% of our revenue, for the years ended March 31, 2023 and 2022.

We do not enter into long-term agreements with our customers, and our customers engage us on a project-by-project basis, which we believe is in line with market practice.

85

Table of Contents

Below are some of the generalized terms included in most of our contracts:

Contract period

 

:

 

We are required to follow the pre-determined work schedule. Such schedule may be extended from time to time pursuant to the terms of the contract.

Type and scope of work

 

:

 

In accordance with our customer’s requirements, we specify tasks, quantities, and rates in a format similar to a bill of quantities.

Contract sum

 

:

 

The final contract sum will be calculated with reference to a schedule of rates and breakdowns by specification of the type of work to be done, as well as the volume and quantities of construction materials and labor to be used.

Payment terms

 

:

 

Our customers pay us by stages, typically on a monthly basis (or as otherwise agreed), based on the measurement, valuation of work, and the agreed rates executed during the month.

Variation orders/contingencies

 

:

 

From time to time, we may be instructed to perform additional work or a varied scope of work. Unless otherwise agreed, such variations may be valued with reference to specified rates or by separate quotation.

Liquidated damage

 

:

 

The amount of liquidated damage payable by us per day if we fail to complete the agreed scope of work within the contract period as provided in the contract.

Retention monies

 

:

 

A portion of progress payment is usually withheld by the customer at a rate of 0% to 10%, but it is subject to a cap of 5% of the contract sum.

Defects liability period

 

:

 

In line with industry practice, our customers often specific a defects liability period of up to 18 months after practical or substantial completion of our projects. If any defect is found in our work, we are responsible for making good during the defects liability period.

SALES AND MARKETING

Our business opportunities arose mainly from invitation for quotation by customers, which are considered by our directors to be attributable to our well-established presence in the construction industry in Hong Kong and our good customer relationships. We currently do not maintain a sales and marketing team. We contact our customers to maintain a good relationship with them, to obtain market and industry information, and to seek business opportunities. We also rely on word of mouth by providing quality service in all of our projects to attract referrals or for retaining our customers in future projects.

SUPPLIERS

Our suppliers primarily supply the following materials to us: (i) construction materials, such as concrete, steel reinforcement bars, and structural steel and (ii) diesel fuel. We generally order construction materials and diesel fuel on a project-by-project basis, and we do not enter into any long-term contracts with our suppliers. The terms of our supply contracts include the type of materials, price, quantity, and payment terms. We select suppliers mainly based on: (i) quality of materials, (ii) timeliness of delivery, (iii) previous experience and length of partnership with the supplier, (iv) competitiveness of the price offered, and (v) reputation of the supplier. Unless otherwise stated in our agreement with the customer, we usually provide construction materials for our projects. As we are provided with the standard requirements of the materials and we are liable for the quality of our projects, except in the case that we are provided with materials by our customer, as subcontractor, we are able to choose our own suppliers for our projects.

SUBCONTRACTORS

Depending on our capability, availability of resources, possession of the required machinery, cost effectiveness, and the complexity of the project, we divide the project into different trades, such as some kind of piling construction, reinforcement fixing, concreting and design work, and subcontract these trades to subcontractors, and we remain responsible for the overall project management.

86

Table of Contents

Our subcontracted work includes piling, concreting, reinforcement fixing, drilling, and structural steel work. Our subcontractors include local sole proprietors, as well as companies that generally have the available skills, machinery, and/or manpower to perform the activities. We are responsible to our customers for the work performed in a project, including those carried out by our subcontractors. Our customers generally consent to our use of subcontractor for a project and do not limit which subcontractor we use. According to the subcontract agreements we enter into with our subcontractors, we have legal rights to hold our subcontractors liable for any loss and damages suffered by us.

As our customers engage us on a project-by-project basis, we have not entered into any long-term or standard contract with our subcontractors. The key terms of the subcontracting engagements include pricing, scope of work, time of performance, arrangement of labor, purchase of materials, and safety requirements.

We are liable to our customers for the performance and the quality of work done by our subcontractors. Therefore, our subcontractors are not allowed to subcontract parts of our projects without our permission. In the event that our subcontractors subcontract parts of our projects without our permission, we have the absolute discretion to terminate the contract immediately and our subcontractor shall be liable for our consequential additional costs incurred. We require our subcontractors to follow our in-house rules in relation to work quality, occupational safety, and environmental protection. In general, our project team will carry out supervision on our subcontractors on a continuing basis to check if they comply with our in-house rules.

MACHINERY AND MATERIALS

We rely on the use of machinery to enable us to carry out our construction work, especially in our foundation, site formation, and demolition projects. Accordingly, we utilize a broad range of machinery and robotics to perform different types of projects. We currently lease our machinery and construction robots from a third parties or rely mainly on our customer or subcontractor to provide for our construction work. Our directors believe that investment in machinery is crucial for us to have greater control and allow us to cater to projects of larger scale and increase our tender success rate in the future. The machinery and equipment we utilize in our projects include:

 

Air compressors are mainly used to force air into a chamber and compress the air to provide high-pressure air to power pneumatic tools, such as jackhammers.

 

Excavators are mainly used for performing excavation work, and consist of a boom, arm, bucket, and cab on an upper structure that can rotate. The upper structure sits atop an undercarriage with tracks or wheels.

87

Table of Contents

 

Drilling machines are mainly used to originate through or behind straight cylindrical holes in solid rigid bodies and/or enlarge existing holes.

 

Piling rigs are mainly used to drive piles into soil to provide foundation support.

 

Crawler cranes are mainly used for lifting and moving heavy materials.

 

Loaders are mainly used for moving construction materials.

88

Table of Contents

 

Others, which include mobile generators, rollers, and other commonly used construction machinery.

Major construction materials used by us include concrete, steel reinforcement bar, steel H-pile, mild steel casing, and diesel fuel. In order to ensure the conformity of the quality of the materials with the contractual requirements, we may purchase materials from our suppliers. Proposed materials will be approved by the customer via our project management team prior to order.

For projects of which we are the main contractor, unless specified under the agreement that we may have entered into with the subcontractor, we are responsible for the procurement of major construction materials for the projects, such as concrete and reinforcement steel. Our subcontractors are responsible for procuring the remaining construction materials required for the construction project, which costs are inclusive of the fees paid to the subcontractors. Occasionally, our customers may provide the construction materials on our behalf for their projects.

We enter into the agreements for the supply of materials from our list of approved suppliers after we have been awarded a construction contract and place the orders for the materials in advance of the commencement of construction work to fix the purchase price of the construction materials to minimize cost fluctuation and ensure stable supply. As we place orders with our list of approval suppliers on a project-by-project basis, we do not keep materials in inventory.

SEASONALITY

We believe that the construction industry in Hong Kong does not exhibit any significant seasonality.

QUALITY CONTROL

To maintain consistent quality of services for our customers, we have established a quality management system that is certified to be in compliance with the requirements of ISO 9001:2015. We take an active approach to monitor the progress of each project. Our directors and our project management team maintain frequent dialogue with our customers, suppliers, and subcontractors in order to make sure that each project is carried out according to the agreed plan.

MAJOR QUALIFICATIONS, LICENSES, AND CERTIFICATIONS

Registration and qualifications

As of the date of this prospectus, we hold various licenses and qualifications in respect to our operation.

Issuing authority

 

Type of registration

 

Category

 

Holder

 

Expiry date

Buildings Department of Hong Kong

 

Registered specialist contractor

 

Foundation work

 

Chiu & Lee Partners

 

October 24, 2024

Site formation work

 

Chiu & Lee Partners

 

January 9, 2025

Demolition work

 

Chiu & Lee Partners

 

February 7, 2025

   

Registered general building contractor

 

General building work

 

Chiu & Lee Partners

 

November 6, 2024

89

Table of Contents

Certifications

As of the date of this prospectus, we obtained the following certifications in recognition of our quality control system:

Certification

 

Description

 

Awarding
organization or
authority

 

Holder

 

Expiry date

ISO 9001:2015

 

Certification of quality management system(1)

 

Accredited Certification International Limited

 

Chiu & Lee Partners

 

May 19, 2024

ISO 14001:2015

 

Certification of environmental management system(1)

 

Accredited Certification International Limited

 

Chiu & Lee Partners

 

February 2, 2025

ISO 45001:2018

 

Certification of occupational health and safety management system(1)

 

Accredited Certification International Limited

 

Chiu & Lee Partners

 

December 23, 2023

____________

Notes:

(1)      The certification concerns our services to keep, restore and improve the facilities of buildings and surroundings, the design and construction of land piling, site formation and construction of building works and demolition and buildings and structures

COMPETITION

The foundation industry in Hong Kong is considered relatively fragmented. Our directors consider that there are market entry barriers to the foundation industry in Hong Kong that hinder new subcontractors from entry, including: (i) industry experience, (ii) specialized machinery, and (iii) sufficiency of working capital. Our main competitors in the foundation industry are mainly companies that are engaged in the foundation business in Hong Kong. We believe that we compete with other foundation subcontractors on our competitive strengths and we believe that our competitive strengths have contributed to our success. As such, even though competition within the foundation industry in Hong Kong will continue to intensify in the future, we are confident that we are able to withstand the intense competition with our competitive strengths.

INTELLECTUAL PROPERTY

To date, we do not own any patents, copyrights, trademarks or domains.

INSURANCE AND SURETY

All projects undertaken by us and the relevant employees are respectively protected by contractors’ all-risk and employees’ compensation insurance. Such insurances are taken out by us as main contractor. When acting as a subcontractor, we generally will not take out separate insurance policies but will rely on the insurance policies taken out and maintained by the relevant main contractor. The reliance of us on the main contractors’ insurance policies is explicitly provided for in the relevant subcontracting agreements.

We have insurance coverage for the liabilities under employee compensation and personal injury claims, which meets the statutory minimum insurance coverage of HK$200 million per incident. We consider such insurance coverage as to be generally sufficient for its liabilities under employees’ compensation claims and personal injury actions. We have also maintained office protection insurance, which covers loss of and damage to office contents in our office, and third-party liability insurance regarding the use of our motor vehicles.

We believe that our insurance coverage is in line with our industry norm. We review our insurance policies from time to time for adequacy in the breadth of coverage.

In addition, when we undertake construction work as a main contractor in the private sector, depending on the tender terms and our negotiation with the customers, we are sometimes required to provide a surety bond of up to 10% of the contract sum issued by a bank or an insurance company in favor of the customer to secure our due performance of the contract. The surety bonds will generally be released after the defects liability period.

90

Table of Contents

FACILITIES

We do not own any real property.

Our principal executive office is located at Room 2620, 26/F., New Tech Plaza, 34 Tai Yau Street, San Po Kong, Kowloon, Hong Kong. The office has a size of approximately 1,385 square feet, which we use as office space.

We believe that our facilities are adequate to meet our needs for the immediate future and that, should it be needed, suitable additional space will be available on commercially reasonable terms to accommodate any expansion of our operations.

EMPLOYEES

As of March 31, 2023, our Operating Subsidiary employed a total number of 55 employees in Hong Kong. Our Operating Subsidiary had 52 employees as of March 31, 2022. All of our employees were stationed in Hong Kong. The following table sets out a breakdown of our employees by function:

 

As of
March 31,
2023

 

As of
March 31,
2022

Director

 

2

 

2

Project manager

 

2

 

2

Quantity surveyor

 

3

 

2

Safety officer

 

2

 

1

Finance and administration

 

4

 

2

Project team

 

16

 

11

Machinery operators

 

8

 

3

General labor

 

18

 

29

   

55

 

52

We believe that our Operating Subsidiary maintains a good working relationship with its employees, and it has not experienced any significant problems with our employees or any disruption to our operations due to labor disputes, nor have we experienced any material difficulties in the recruitment and retention of experienced core staff or skilled personnel during the years ended March 31, 2023 and 2022. There has not been any trade union set up for our employees.

We also emphasize the continuing education and quality training of our staff to enhance its work performance. Our employees also receive in-house training on a regular basis to enhance their technical knowledge on industry quality standards, safety standards, site management, and operation of tools. We consider our training program to be only used as a platform to upgrade the skills of our employees regularly, but also used to encourage greater cohesion. These measures increase overall efficiency and loyalty, and they also serve as a means of retaining quality employees. We review the performance of our employees from time to time in order to determine salary adjustments and promotion appraisals.

OCCUPATIONAL HEALTH AND WORK SAFETY

We have adopted an occupational health and safety system as required by relevant occupational health and safety laws, rules, and regulations and managed by our safety department for the benefit of our employees and our subcontractors’ employees. We are committed to providing a safe and healthy working environment. It is also our concern not to put the general public in danger. Our occupational health and safety system has been implemented in compliance with the requirements of ISO 45001:2018 international standards.

Our safety officer is responsible for setting up safety plans for workers before carrying out their work on construction sites, inspecting machinery and equipment to ensure they are safe to be used, conducting regular safe walks to maintain a safe working environment and site tidiness, handling safety incidents, and keeping safety records. In addition, we will conduct regular internal safety audits and regular safety training provided to our staff.

LEGAL PROCEEDINGS

As of the date of this prospectus, we are not a party to, and we are not aware of any threat of, any legal proceeding that, in the opinion of our management, is likely to have a material adverse effect on our business, financial condition, or operations.

91

Table of Contents

From time to time, we may become involved in legal proceedings arising in the ordinary course of business. Other than the civil proceeding mentioned above, we are not involved in any litigation, arbitration, or claim of material importance, nor any material impact non-compliance incidents or systemic non-compliance incidents in respect to applicable laws and regulations.

COVID-19 UPDATE

Since late December 2019, the outbreak of a novel strain of coronavirus, later renamed COVID-19 spread rapidly throughout China and later to the rest of the world. On January 30, 2020, the International Health Regulations Emergency Committee of the World Health Organization declared the outbreak a Public Health Emergency of International Concern (PHEIC), and later, on March 11, 2020, a global pandemic. The COVID-19 outbreak has led governments across the globe to impose a series of measures intended to contain its spread, including border closures, travel bans, quarantine measures, social distancing, and restrictions on business operations and large gatherings.

This outbreak of COVID-19 and the uncertainty of the spread of disease has caused companies like us and our business partners to implement certain preventive measures in our construction sites, which we believe have reduced the efficiency of our workers and subcontractors and led to the slowing down of the progress of our projects on hand. Some construction sites in Hong Kong were also closed temporarily for two weeks in light of the number of confirmed COVID-19 cases of the workers on site.

COVID-19 has also impacted the supply of construction materials. As most of the primary construction materials, such as cement and reinforced steel, are imported from China, the production and logistics of those construction materials have been temporarily disrupted as enterprises were forced to shut down during the significant stages of the outbreak so as to contain further spread of COVID-19, which has triggered some fluctuations in the cost of construction materials during certain periods of the pandemic. We, our customers, subcontractors, and suppliers have not experienced any material suspensions or cancellations of our projects due to the COVID-19 outbreak during the years ended March 31, 2022 and 2021.

Any future impact on our results of operations will depend on, to a large extent, future developments and new information that may emerge regarding the duration and severity of the COVID-19 pandemic and the actions taken by government authorities and other entities to contain the spread or treat its impact, almost all of which are beyond our control. We will continue to closely monitor the situation throughout 2023 and beyond.

ENVIRONMENTAL PROTECTION

Our Operating Subsidiary’s operations are subject to certain environmental requirements pursuant to the laws in Hong Kong, including primarily those in relation to waste disposal, air and water pollution control, and noise control during the years ended March 31, 2023 and 2022. Under such environmental regulations, we are required to dispose of excavated materials and construction waste at specified facilities at costs based on the volume of waste. We are further required to operate within specified hours and generally not allowed to operate powered mechanical equipment on public holidays. A wastewater treatment facility is in place for discharging construction site effluent. In recognition of our environmental policies, our environmental management system for our Operating Subsidiary, Chiu & Lee Partners, has been assessed and certified as meeting the requirements of ISO 14001:2015. As of the date of this prospectus, we did not record any non-compliance with applicable environment requirements that resulted in prosecution or penalty being brought against us.

92

Table of Contents

REGULATIONS

The section sets forth a summary of the principal Hong Kong laws and regulations relevant to our business and operations in Hong Kong.

Hong Kong Regulations Related to Service Providers

Business Registration Ordinance (Chapter 310 of the Laws of Hong Kong)

The Business Registration Ordinance requires every person carrying on any business to make an application to the Commissioner of Inland Revenue in the prescribed manner for the registration of that business. The Commissioner of Inland Revenue must register each business for which a business registration application is made and, as soon as practicable after the prescribed business registration fee and levy are paid, issue a business registration certificate or branch registration certificate for the relevant business or the relevant branch, as the case may be.

Hong Kong Regulations Related to the Construction Industry

Construction Workers Registration Ordinance (Chapter 583 of the Laws of Hong Kong)

The Construction Workers Registration Ordinance provides, among others, for registration and regulation of construction workers. The principal object of the Construction Workers Registration Ordinance is to establish a system for registration of construction workers and to regulate construction workers who personally carry out construction work on construction site.

Under Sections 3(1) and 5 of the Construction Workers Registration Ordinance, the principal contractors/subcontractors/employers/controllers of construction sites are required to employ only registered construction workers to personally carry out construction work on construction sites.

Factories and Industrial Undertakings Ordinance (Chapter 59 of the Laws of Hong Kong)

The Factories and Industrial Undertakings Ordinance provides for the safety and health protection of workers in an industrial undertaking. Under the Factories and Industrial Undertakings Ordinance, it is the duty of a proprietor (including a person for the time being having the management or control of the business carried on in such industrial undertaking and also the occupier of any industrial undertaking) of an industrial undertaking to take care of, so far as is reasonably practicable, the health and safety at work of all persons employed by it at the industrial undertaking.

A proprietor who contravenes any of its duties under the Factories and Industrial Undertakings Ordinance commits an offense and is liable: (a) on summary conviction to a fine of HK$3,000,000; or (b) a conviction on indictment to a fine of HK$10,000,000. A proprietor who contravenes any of these requirements willfully and without reasonable excuse commits an offense and is liable: (a) on summary conviction to a fine of HK$3,000,000 and to imprisonment for six months; or (b) on conviction on indictment to a fine of HK$10,000,000 and to imprisonment for 2 years.

Buildings Ordinance (Chapter 123 of the Laws of Hong Kong)

The Buildings Ordinance regulates the planning, design, and construction of buildings and associated work. It provides that before the commencement of any building work: (i) prior approval and consent from the Building Authority must be obtained; (ii) authorized persons, such as architects, engineers, and surveyors, registered under the Buildings Ordinance must be appointed to coordinate the work and prepare and submit plans for the approval from the Building Authority; (iii) registered professionals must be appointed to design and supervise the work; and (iv) registered contractors must be appointed to carry out the work.

Section 14(1) of the Buildings Ordinance provides that no person shall commence or carry out any building work, including site formation work and foundation work, without having obtained such prior approval and consent from the Building Authority and such proper appointments. According to Section 41(3) of the Buildings Ordinance, building work (other than drainage work, ground investigation in the scheduled areas, site formation work, or minor work) in any building is exempt from the requirement for approval and consent from the Building Authority if the work does not involve the structure of the building.

93

Table of Contents

If the building work is within the purview of Section 41(3), the work must further comply with the building standards specified in the relevant Building Regulations empowered under the Buildings Ordinance. The Buildings Ordinance further requires that any authorized person of the buildings work must be appointed by the ultimate beneficiary of the work, the employer of the work, or the contractor.

Under the current contractors’ registration system in Hong Kong, the Buildings Department of Hong Kong keeps a register of general building contractors who are qualified to perform the duties of a general building contractor and a register of specialist contractors who are qualified to carry out specialized work (such as foundation work) specified in the category in the sub-register in which they are entered. The main contractors carrying out foundation and substructure construction work are required to register or work together with contractors who are registered on either the register of general building contractors or the register of specialist contractors (sub-register of foundation work category) with the Buildings Department of Hong Kong.

Under Section 8B(2) of the Buildings Ordinance, an applicant for registration as a registered general building contractor or registered specialist contractor must satisfy the Buildings Department of Hong Kong on the following aspects:

(i)     if it is a corporation, the adequacy of its management structure;

(ii)    the appropriate experience and qualifications of its personnel;

(iii)   its ability to have access to plants and resources; and

(iv)   the ability of the person appointed to act for the applicant for the purposes of the Buildings Ordinance to understand building work and street work through relevant experience and a general knowledge of the basic statutory requirements.

In considering each application, the Buildings Department of Hong Kong will consider the qualifications, competence, and experience of the following key personnel of the applicant:

(a)     a minimum of one person appointed by the applicant to act for the applicant for the purposes of the Buildings Ordinance, hereinafter referred to as the Authorized Signatory;

(b)    for a corporation, a minimum of one director from the board of directors of the applicant, hereinafter referred to as a “Technical Director” who is authorized by the board to:

(i)     have access to plant and resources;

(ii)    provide technical and financial support for the execution of building work and street work; and

(iii)   make decisions for the company and supervise the Authorized Signatory and other personnel;

for the purpose of ensuring that the work is carried out in accordance with the Buildings Ordinance; and

(c)     for a corporation that appoints a director who does not possess the required qualification or experience as Technical Director to manage the carrying out of building work and street work, another officer as authorized by the board of directors shall be appointed to assist the Technical Director.

In addition to the above key personnel, the applicant is also required to demonstrate that it has employed appropriate qualified staff members to assist the applicant and the above key personnel to execute, manage, and supervise the building work and street work.

For registration as a registered specialist contractor, the applicant must satisfy the Buildings Department of Hong Kong that it has the necessary experience and, where appropriate, professional and academic qualifications to undertake work in the specialist category and should also demonstrate that it has the access to engaging qualified persons to carry out the relevant specialized duties.

The Buildings Department of Hong Kong imposes specific requirements on the directors of a contractor and the person appointed by the contractor to act for it for the purposes of the Buildings Ordinance.

94

Table of Contents

Construction Industry Council Ordinance (Chapter 587 of the Laws of Hong Kong)

According to Section 32 of the Construction Industry Council Ordinance, construction industry levy (“CIL”) is payable by registered contractors appointed under Section 9 of the Buildings Ordinance or any persons who carry out construction operations in Hong Kong to the Construction Industry Council (“CIC”). “Construction operation” is exhaustively defined under Schedule 1 of the Construction Industry Council Ordinance, which includes building work and street work as defined in Section 2(1) of the Buildings Ordinance, construction, alteration, repair, maintenance, extension, demolition or dismantling, external or internal cleaning. and painting or decorating any external or internal surfaces or parts of any buildings or other temporary or permanent structures forming part of land.

After 2012, the CIL chargeable is 0.5% of the total value of the construction operations (as defined under Section 53 of the Construction Industry Council Ordinance) concerned (0.4% before 2012). Pursuant to Section 32 and Schedule 5 of the Construction Industry Council Ordinance, no CIL is chargeable for any construction operations not exceeding HK$3,000,000.

According to Section 34 of the Construction Industry Council Ordinance, the contractor and authorized person each is required to inform the CIC in a specified form (Form 1) in respect to the construction operations within 14 days after its commencement. Failure to give such notice without reasonable excuse may be liable to a fine at Level 1, which is fixed at HK$2,000. Notice is only required for term contracts or if the reasonable estimation of the total value of construction operations exceed HK$3,000,000.

Pursuant to Section 35 of the Construction Industry Council Ordinance, a contractor is required to give a Notice of Payment (“NOP”) in a specified form (Form 2) to the CIC within 14 days after the contractor receives a payment in respect to the construction operation. Failure to give the NOP without reasonable excuse may be liable to a fine at Level 3, which is fixed at HK$10,000.

Pursuant to Section 36 of the Construction Industry Council Ordinance, a contractor is required to give a Notice of Completion (“NOC”) in a specified form (Form 3) to the CIC within 14 days after the completion of the construction operation. Failure to give the NOC without reasonable excuse may be liable to a fine at Level 3, which is fixed at HK$10,000.

The CIC shall assess the CIL payable upon receiving the NOP or NOC and give a Notice of Assessment in writing specifying the amount of CIL. The CIC can also make the assessment notwithstanding if a NOP or NOC has been given. According to Section 41 of the Construction Industry Council Ordinance, if a contractor fails to give the NOP or NOC, a surcharge not exceeding twice the amount of the CIL payable may be imposed and a Notice of Surcharge in writing shall be given by the CIC.

Regulations Related to Employment and Labor Protection

Occupational Safety and Health Ordinance (Chapter 509 of the Laws of Hong Kong)

The Occupational Safety and Health Ordinance provides for the safety and health protection to employees in workplaces, both industrial and non-industrial. Employers must, as far as reasonably practicable, ensure the safety and health in their workplaces. Failure to comply with the above constitutes an offense, and the employer is liable (a) on summary conviction to a fine of HK$3,000,000; or (b) on conviction on indictment to a fine of HK$10,000,000. An employer who fails to do so intentionally, knowingly or recklessly commits an offense and is liable (a) on summary conviction to a fine of HK$3,000,000 and to imprisonment for 6 months; or (b) on conviction on indictment to a fine of HK$10,000,000 and to imprisonment for 2 years.

Employment Ordinance (Chapter 57 of the Laws of Hong Kong)

The Employment Ordinance is an ordinance enacted for, among other things, the protection of the wages of employees and the regulation of the general conditions of employment and employment agencies. Under the Employment Ordinance, an employee is generally entitled to, among other things, notice of termination of his or her employment contract; payment in lieu of notice; maternity protection in the case of a pregnant employee; not less than one rest day in every period of seven days; severance payments or long service payments; sickness allowance; statutory holidays or alternative holidays; and paid annual leave of up to 14 days depending on the period of employment.

95

Table of Contents

Employees’ Compensation Ordinance (Chapter 282 of the Laws of Hong Kong)

The Employees’ Compensation Ordinance establishes a no-fault and non-contributory employee compensation system for work injuries and lays down the rights and obligations of employers and employees in respect to injuries or death caused by accidents arising out of and in the course of employment or by prescribed occupational diseases.

Under the Employees’ Compensation Ordinance, if an employee sustains an injury or dies as a result of an accident arising out of and in the course of his or her employment, his or her employer is in general liable to pay compensation even if the employee might have committed acts of fault or negligence when the accident occurred. Similarly, an employee who suffers incapacity arising from an occupational disease is entitled to receive the same compensation as that payable to employees injured in occupational accidents.

According to Section 24 of the Employees’ Compensation Ordinance, a principal contractor shall be liable to pay compensation to subcontractors’ employees who are injured in the course of their employment to the subcontractor. The principal contractor is, nonetheless, entitled to be indemnified by the subcontractor who would have been liable to pay compensation to the injured employee independently of this section. The employees in question are required to serve a notice in writing on the principal contractor before making any claim or application against such principal contractor.

Pursuant to Section 40 of the Employees’ Compensation Ordinance, all employers (including contractors and subcontractors) are required to take out insurance policies to cover their liabilities both under the Employees’ Compensation Ordinance and at common law for injuries at work in respect to all their employees (including full-time and part-time employees). Under Section 40(1B) of the Employees’ Compensation Ordinance, where a principal contractor has undertaken to perform any construction work, it may take out an insurance policy for an amount not less than HK$200 million per event to cover its liability and that of its subcontractor(s) under the Employees’ Compensation Ordinance and at common law. Where a principal contractor has taken out a policy of insurance under Section 40(1B) of the Employees’ Compensation Ordinance, the principal contractor and a subcontractor insured under the policy shall be regarded as having complied with Section 40(1) of the Employees’ Compensation Ordinance.

An employer who fails to comply with the Employees’ Compensation Ordinance to secure an insurance cover is liable (i) on conviction upon indictment to a fine at Level 6 (currently at HK$100,000) and imprisonment for two years, and (ii) on summary conviction to a fine at Level 6 and imprisonment for one year.

According to Section 15 of the Employees’ Compensation Ordinance, an employer must notify the Commissioner for Labour of any work accident by submitting Form 2 or Form 2B (within 14 days for general work accidents and within seven days for fatal accidents), irrespective of whether the accident gives rise to any liability to pay compensation. If the happening of such accident was not brought to the notice of the employer or did not otherwise come to its knowledge within such periods of seven and 14 days, respectively, then such notice shall be given not later than seven days or, as may be appropriate, 14 days, after the happening of the accident was first brought to the notice of the employer or otherwise came to its knowledge.

Immigration Ordinance (Chapter 115 of the Laws of Hong Kong)

Pursuant to Section 38A of the Immigration Ordinance, a construction site controller (i.e., the principal or main contractor, which includes a subcontractor, owner, occupier, or other person who has control over or is in charge of a construction site) should take all practicable steps to prevent having illegal immigrants from being on the construction site and should prevent illegal workers who are not lawfully employable from taking employment on the construction site.

Where it is proved that an illegal immigrant was on a construction site, or such illegal worker, who is not lawfully employable, took employment on a construction site, the construction site controller commits an offense and is liable to a fine of HK$350,000.

Minimum Wage Ordinance (Chapter 608 of the Laws of Hong Kong)

The Minimum Wage Ordinance provides for a prescribed minimum hourly wage rate (currently at HK$40 per hour) during the wage period for every employee engaged under a contract of employment under the Employment Ordinance.

96

Table of Contents

Any provision of the employment contract that purports to extinguish or reduce the right, benefit, or protection conferred on the employee by the Minimum Wage Ordinance is void.

Mandatory Provident Fund Schemes Ordinance (Chapter 485 of the Laws of Hong Kong)

The Mandatory Provident Fund Schemes Ordinance (“MPFSO”) is an ordinance enacted for the purposes of providing for the establishment of non-governmental mandatory provident fund schemes (each, a “MPF Scheme”). The MPFSO requires every employer of an employee of 18 years of age or above but under 65 years of age to take all practical steps to ensure the employee becomes a member of a registered MPF Scheme. Subject to the minimum and maximum relevant income levels, it is mandatory for both employers and their employees to contribute 5% of the employee’s relevant income to the MPF Scheme. Any employer who contravenes this requirement commits a criminal offense and is liable on conviction to a fine and imprisonment. As of the date of this prospectus, the Company believes it has made all contributions required under the MPFSO.

Regulations Related to Hong Kong Taxation

Inland Revenue Ordinance (Chapter 112 of the Laws of Hong Kong)

Under the Inland Revenue Ordinance, where an employer commences to employ in Hong Kong an individual who is or is likely to be chargeable to tax, or any married person, the employer shall give a written notice to the Commissioner of Inland Revenue not later than three months after the date of commencement of such employment. Where an employer ceases or is about to cease to employ in Hong Kong an individual who is or is likely to be chargeable to tax, or any married person, the employer shall give a written notice to the Commissioner of Inland Revenue not later than one month before such individual ceases to be employed in Hong Kong.

Tax on dividends

Under the current practice of the Inland Revenue Department of Hong Kong, no tax is payable in Hong Kong in respect to dividends paid by the Company.

Capital gains and profit tax

No tax is imposed in Hong Kong in respect to capital gains from the sale of shares. However, trading gains from the sale of shares by persons carrying on a trade, profession, or business in Hong Kong, where such gains are derived from or arise in Hong Kong, will be subject to Hong Kong profits tax, which is imposed at the rates of 8.25% on assessable profits up to HKD2,000,000 and 16.5% on any part of assessable profits over HKD2,000,000 on corporations from the year of assessment commencing on or after April 1, 2018. Certain categories of taxpayers (for example, financial institutions, insurance companies, and securities dealers) are likely to be regarded as deriving trading gains rather than capital gains unless these taxpayers can prove that the investment securities are held for long-term investment purposes.

Stamp Duty Ordinance (Chapter 117 of the Laws of Hong Kong)

Under the Stamp Duty Ordinance, the Hong Kong stamp duty currently charged at the ad valorem rate of 0.13% on the higher of the consideration for or the market value of the shares will be payable by the purchaser on every purchase and by the seller on every sale of Hong Kong shares (in other words, a total of 0.26% is currently payable on a typical sale and purchase transaction of Hong Kong shares). In addition, a fixed duty of HKD5 is currently payable on any instrument of transfer of Hong Kong shares. Where one of the parties is a resident outside Hong Kong and does not pay the ad valorem duty due by it, the duty not paid will be assessed on the instrument of transfer (if any) and will be payable by the transferee. If no stamp duty is paid on or before the due date, a penalty of up to ten times the duty payable may be imposed.

97

Table of Contents

Regulations Related to Personal Data

Personal Data (Privacy) Ordinance (Chapter 486 of the Laws of Hong Kong)

The Personal Data (Privacy) Ordinance (“PDPO”) imposes a statutory duty on data users to comply with the requirements of the six data protection principles (the “Data Protection Principles”) contained in Schedule 1 to the PDPO. The PDPO provides that a data user shall not do an act, or engage in a practice, that contravenes a Data Protection Principle unless the act or practice, as the case may be, is required or permitted under the PDPO. The six Data Protection Principles are:

        Principle 1 — purpose and manner of collection of personal data;

        Principle 2 — accuracy and duration of retention of personal data;

        Principle 3 — use of personal data;

        Principle 4 — security of personal data;

        Principle 5 — information to be generally available; and

        Principle 6 — access to personal data.

Non-compliance with a Data Protection Principle may lead to a complaint to the Privacy Commissioner for Personal Data (the “Privacy Commissioner”). The Privacy Commissioner may serve an enforcement notice to direct the data user to remedy the contravention and/or instigate prosecution actions. A data user who contravenes an enforcement notice commits an offense that may lead to a fine and imprisonment.

The PDPO also gives data subjects certain rights, inter alia:

        the right to be informed by a data user whether the data user holds personal data of which the individual is the data subject;

        if the data user holds such data, to be supplied with a copy of such data; and

        the right to request correction of any data the individual considers to be inaccurate.

The PDPO criminalizes, including, but not limited to, the misuse or inappropriate use of personal data in direct marketing activities, non-compliance with a data access request, and the unauthorized disclosure of personal data obtained without the relevant data user’s consent. An individual who suffers damage, including injured feelings, by reason of a contravention of the PDPO in relation to his or her personal data may seek compensation from the data user concerned.

Regulations Related to Environmental Protection

Waste Disposal Ordinance (Chapter 354 of the Laws of Hong Kong)

The Waste Disposal Ordinance controls the production, storage, collection, treatment, reprocessing, recycling, and disposal of wastes. At present, livestock waste and chemical waste are subject to specific controls, while unlawful deposition of waste is prohibited. Import and export of waste is generally controlled through a permit system.

A contractor shall observe and comply with the Waste Disposal Ordinance and its subsidiary regulations, including, without limitation, the Waste Disposal (Charges for Disposal of Construction Waste) Regulation (Chapter 354N of the Laws of Hong Kong) and the Waste Disposal (Chemical Waste) (General) Regulation (Chapter 354C of the Laws of Hong Kong).

Under the Waste Disposal (Charges for Disposal of Construction Waste) Regulation, construction waste can only be disposed at designated prescribed facilities, and a main contractor who undertakes construction work with a value of HK$1,000,000 or above will be required, within 21 days after being awarded the contract, to establish a billing account in respect to that particular contract with the director of the Environmental Protection Department to pay any disposal charges for the construction waste generated from the construction work under that contract.

98

Table of Contents

Under the Waste Disposal Ordinance, a person shall not use, or permit to be used, any land or premises for the disposal of waste unless he has a license from the director of the Environmental Protection Department. A person who, except under and in accordance with a permit or authorization, does, causes, or allows another person to do anything for which such a permit or authorization is required commits an offense and is liable to a fine of HK$200,000 and to imprisonment for six months for the first offense and to a fine of HK$500,000 and to imprisonment for two years for a second or subsequent offense.

Water Pollution Control Ordinance (Chapter 358 of the Laws of Hong Kong)

The Water Pollution Control Ordinance controls the effluent discharged from all types of industrial, manufacturing, commercial, institutional, and construction activities into public sewers and public drains. For any industry/trade generating wastewater discharge (except domestic sewage that is discharged into communal sewers or unpolluted water to communal sewers or drains), they are subject to licensing control by the director of the Environmental Protection Department.

All discharges, other than domestic sewage to a communal sewer or drain or unpolluted water to a communal sewer or drain, must be covered by an effluent discharge license. The license specifies the permitted physical, chemical, and microbial quality of the effluent. The general guidelines are that the effluent does not damage sewers or pollute inland or inshore marine waters.

According to the Water Pollution Control Ordinance, unless being licensed under the Water Pollution Control Ordinance, a person who discharges any waste or polluting matter into the waters of Hong Kong in a water control zone or discharges any matter, other than domestic sewage and unpolluted water, into a communal sewer or communal drain in a water control zone commits an offense and is liable to imprisonment for six months and (a) for a first offense, a fine of HK$200,000; (b) for a second or subsequent offense, a fine of HK$400,000; and (c) in addition, if the offense is a continuing offense, a fine of HK$10,000 for each day during which it is proved to the satisfaction of the court that the offense has continued.

Air Pollution Control Ordinance (Chapter 311 of the Laws of Hong Kong)

The Air Pollution Control Ordinance is the principal legislation in Hong Kong for controlling emission of air pollutants and noxious odor from construction, industrial, and commercial activities, as well as other polluting sources. Subsidiary regulations of the Air Pollution Control Ordinance impose control on air pollutant emissions from certain operations through the issue of licenses and permits.

A contractor shall observe and comply with the Air Pollution Control Ordinance and its subsidiary regulations, including, without limitation, the Air Pollution Control (Open Burning) Regulation (Chapter 311O of the Laws of Hong Kong), the Air Pollution Control (Construction Dust) Regulation (Chapter 311R of the Laws of Hong Kong), and the Air Pollution Control (Smoke) Regulations (Chapter 311C of the Laws of Hong Kong). The contractor responsible for a construction site shall devise, arrange methods of working, and carry out the work in such a manner so as to minimize dust impacts on the surrounding environment, and it shall provide experienced personnel with suitable training to ensure that these methods are implemented. Asbestos control provisions in the Air Pollution Control Ordinance require that building work involving asbestos must be conducted only by registered qualified personnel and under the supervision of a registered consultant.

Noise Control Ordinance (Chapter 400 of the Laws of Hong Kong)

The Noise Control Ordinance controls, among others, the noise from construction, industrial, and commercial activities. A contractor shall comply with the Noise Control Ordinance and its subsidiary regulations in carrying out construction work. For construction activities that are to be carried out during the restricted hours and for percussive piling during the daytime, not being a general holiday, construction noise permits are required from the director of the Environmental Protection Department of Hong Kong in advance.

Under the Noise Control Ordinance, construction work that produces noise and the use of powered mechanical equipment (other than percussive piling) in populated areas are not allowed between 7:00 p.m. and 7:00 a.m. or at any time on general holidays, unless prior approval has been granted by the director of the Environmental Protection Department of Hong Kong through the construction noise permit system. The use of certain equipment is also subject to restrictions. Hand-held percussive breakers and air compressors must comply with noise emissions standards and be issued with a noise emission label from the director of the Environmental Protection Department of Hong Kong. Any

99

Table of Contents

person who carries out any construction work except as permitted is liable on first conviction to a fine of HK$100,000 and on subsequent convictions to a fine of HK$200,000, and in any case to a fine of HK$20,000 for each day during which the offense continues.

Air Pollution Control (Non-road Mobile Machinery) (Emission) Regulation (Chapter 311Z of the Laws of Hong Kong)

The Air Pollution Control (Non-road Mobile Machinery) (Emission) Regulation introduces regulatory control on the emission of non-road mobile machinery (“NRMMs”), including non-road vehicles and regulated machines such as crawler cranes, excavators, and air compressors.

Unless exempted, NRMMs that are regulated under this provision are required to comply with the emission standards prescribed under the regulation. From September 1, 2015, all regulated machines sold or leased for use in Hong Kong must be approved or exempted with a proper label in a prescribed format issued by the Environmental Protection Department pursuant to Section 4 of the regulation. Under Section 5 of the regulation, starting from December 1, 2015, only approved or exempted NRMMs with a proper label are allowed to be used in specified activities and locations including construction sites. However, existing NRMMs that are already in Hong Kong on or before November 30, 2015, will be exempted from complying with the emission requirements pursuant to Section 11 of the regulation. A period of six months (from June 1, 2015 to November 30, 2015, both dates inclusive) is allowed for existing NRMMs to apply for exemption.

Any person who sells or leases a regulated machine for use in Hong Kong, or uses a regulated machine in specified activities or locations, without (i) exemption or the Environmental Protection Department’s approval is liable to a fine of up to HK$200,000 and imprisonment for up to six months, and (ii) a proper label is liable to a fine of up to HK$50,000 and imprisonment for up to three months.

Regulation Related to Competition

Competition Ordinance (Chapter 619 of the Laws of Hong Kong)

The Competition Ordinance prohibits and deters undertakings in all sectors from adopting anticompetitive conduct which has the object or effect of preventing, restricting or distorting competition in Hong Kong. The Competition Ordinance lays down three forms of behaviour and imposes three rules which are intended to prevent and discourage anti-competitive conduct: (i) the first conduct rule under the Competition Ordinance prohibits agreements between undertakings that have the object or effect of preventing, restricting or distorting competition in Hong Kong; (ii) the second conduct rule under the Competition Ordinance prohibits undertakings with a substantial degree of market power in a market from abusing that power by engaging in conduct that has the object or effect of preventing, restricting or distorting competition in Hong Kong; and (iii) the merger rule under the Competition Ordinance prohibits mergers that have or are likely to have the effect of substantially lessening competition in Hong Kong. Currently, the merger rule only applies to the telecommunications sector. Each of the aforesaid rules is however subject to a number of exclusions and exemptions.

Pursuant to section 82 of the Competition Ordinance, if the Competition Commission has reasonable cause to believe that (a) a contravention of the first conduct rule has occurred; and (b) the contravention does not involve serious anti-competitive conduct, it must, before bringing proceedings in the Competition Tribunal against the undertaking whose conduct is alleged to constitute the contravention, issue a notice to the undertaking.

However, under section 67 of the Competition Ordinance, where a contravention of the first conduct rule has occurred and the contravention involves serious anti-competitive conduct or a contravention of the second conduct rule has occurred, the Competition Commission may, instead of bringing proceedings in the Competition Tribunal in the first instance, issue a notice (an “infringement notice”) to the person against whom it proposes to bring proceedings, offering not to bring those proceedings on condition that the person makes a commitment to comply with requirements of the infringement notice. “Serious anti-competitive conduct” means any conduct that consists of any of the following or any combination of the following — (a) fixing, maintaining, increasing or controlling the price for the supply of goods or services; (b) allocating sales, territories, customers or markets for the production or supply of goods or services; (c) fixing, maintaining, controlling, preventing, limiting or eliminating the production or supply of goods or services; (d) bid-rigging.

In the event of breaches of the Competition Ordinance, the Competition Tribunal may make orders including: imposing a pecuniary penalty if satisfied that an entity has contravened a competition rule; disqualifying a person from acting as a director of a company or taking part in the management of a company; prohibiting an entity from making or giving effect to an agreement; modifying or terminating an agreement; and requiring the payment of damages to a person who has suffered loss or damage.

100

Table of Contents

MANAGEMENT

Directors and Executive officers

 

Age

 

Position

Mr. Keung Yun Yuen

 

53

 

Chairman of the board

Mr. Chan Lee Chuen

 

49

 

Director and Chief Executive Officer

Ms. Choi Hiu Ying

 

34

 

Chief Financial Officer

Mr. Thirupathi Nachiappan*

 

56

 

Independent Director Appointee

Mr. Wong Heung Ming*

 

54

 

Independent Director Appointee

Dr. Liu Yuk Shing*

 

54

 

Independent Director Appointee

Mr. Ng Wai Leung

 

33

 

Quantity Surveyor Manager

____________

*        Has agreed to act as our independent director upon the SEC’s declaration of effectiveness of our registration statement on Form F-1, of which this prospectus is a part.

Mr. Keung Yun Yuen has served as our chairman of the board since April 2022. Mr. Keung joined Chiu & Lee Partners in November 2017 as managing director and is responsible for our overall management of the business and operations. Mr. Keung has accumulated almost 30 years of experience in the civil engineering industry in Hong Kong, specializing in foundation, site formation, and demolition work projects. Mr. Keung obtained a bachelor’s degree in civil engineering from National Taiwan University in 1992 and a master’s degree in civil engineering from Hong Kong University of Science and Technology in 2002. Mr. Keung has taken up the role as the Technical Director for the registration of specialist contractor for foundation, site formation and demolition works and registration of general building contractor and the Authorized Signatory for specialist contractor for foundation, site formation and demolition works of Chiu & Lee Partners under the Building Ordinance of Hong Kong.

Mr. Chan Lee Chuen has served as our chief executive officer since May 2022 and director since May 2022. Mr. Chan first joined Chiu & Lee Partners as senior project manager in September 2021. Mr. Chan is primarily responsible for assisting our chairman in our operation and overall project management. Mr. Chan has almost 30 years of experience in engineering and construction and has managed numerous of projects of various types of construction work. Mr. Chan obtained a higher diploma in civil engineering from the Hong Kong Polytechnic (currently known as The Hong Kong Polytechnic University) in 1993 and a bachelor’s degree in construction project management from University of Central Lancashire in 2013. Mr. Chan is a chartered construction manager of the Chartered Institute of Building in the United Kingdom since 2015 and has taken up the role as the Authorized Signatory of registration of general building contractor of Chiu & Lee Partners under the Building Ordinance of Hong Kong.

Ms. Choi Hiu Ying has served as our chief financial officer since May 2022. Mr. Choi first joined us as the chief financial officer of Chiu & Lee Partners in April 2022. Ms. Choi has more than ten years of experience in the accounting and financial sector, having taken up roles in accounting, investment, compliance, and investor relations. Ms. Choi has obtained a bachelor’s degree in commerce from Macquarie University in Australia in 2010 and is currently a member of CPA Australia.

Mr. Wong Heung Ming will serve as our director upon effectiveness of our registration statement on Form F-1 of which this prospectus is a part, and will be the chairman of the audit committee and a member of the nominating and corporate governance committee and compensation committee of CKHL. Mr. Wong has over twenty years of experience in advising multinational companies of finance, accounting, internal control and corporate governance matters. Mr. Wong has been serving as an independent non-executive director of Sansheng Holdings (Group) Co. Ltd. (2183.HK), an investing holding company mainly engaged in the property development and sales, property investment, hotel operation, construction and design services, consultation service and project management services since August 2022. Mr. Wong has been serving as an independent non-executive director of Helens International Holdings Company Limited (9869.HK), a China-based investment holding company mainly engaged in bar operation and franchise business, since August 2021. Mr. Wong has also been appointed as an independent director of Ostin Technology Group Co., Ltd. (Nasdaq: OST) since April 2022. Mr. Wong also has served as a director of TD Holdings, Inc. (Nasdaq: GLG), a company engaged in commodity trading and supply chain services businesses, since April 2021. Mr. Wong has served as an independent director of Meihua International Medical Technologies Co., Ltd (Nasdaq: MHUA) from April 2022 to June 2022. From May 2020 to March 2021, Mr. Wong served as the chief financial officer of Meten EdtechX Education Group Ltd. (Nasdaq: METX), a leading English language training service provider in China. He has served since November 2010 as an independent non-executive director of Shifang Holding Group Ltd. (1831.HK), a company listed on the Hong Kong Stock Exchange which provides a wide range of integrated print media and digital media services to advertisers and since March 2020 as an independent non-executive

101

Table of Contents

director of Raffle Interior Ltd. (1376.HK), a company engaged in the interior decoration business. Previously, he also served as the chief financial officer from March 2017 to November 2018 at Frontier Services Group Limited (0500.HK), a company listed on the Hong Kong Stock Exchange, which is a leading provider of integrated security, logistics, insurance and infrastructure services for clients operating in developing regions. He also served as the chief financial officer of Beijing Oriental Yuhong Waterproof Technology Co., Ltd., (SHE: 2271), a company listed on the Shenzhen Stock Exchange from July 2014 to September 2015, which is a leading waterproof materials manufacturer in China. Prior to that, Mr. Wong worked for Deloitte Touche Tohmatsu (China) and PricewaterhouseCoopers (China) for an aggregate of more than 11 years. Mr. Wong obtained a bachelor’s degree in accounting from the City University of Hong Kong in 1993 and a master’s degree in electronic commerce from the Open University of Hong Kong in 2003. He is a fellow member of the association of Chartered Certified Accountants and the Hong Kong Institute of Certified Public Accountants and a member of the Hong Kong Institute of Certified Internal Auditors.

Mr. Nachiappan Thirupathi will serve as our director upon effectiveness of our registration statement on Form F-1, of which this prospectus is a part, and will be the chairman of the nominating and corporate governance committee and a member of the audit committee and compensation committee of CKHL. Mr. Thirupathi has more than 30 years of work experience and has vast experience in entrepreneurship and in the international trade, marketing, and finance industries. Throughout his years of work experience, he has served as a director of a raw materials trading company in Hong Kong, a country representative of an established Panamanian law firm, and founded a consultancy company in Hong Kong providing independent consultancy services on international business and trade, environmental, social, and governance and corporate social responsibility. Mr. Thirupathi has also taken up service positions for numerous non-government organizations, non-profit organizations, charities, schools, and institutions in Hong Kong. Mr. Thirupathi obtained a master’s degree in business administration from the Institute of Management Studies and Training in India in 2008.

Dr. Liu Yuk Shing will serve as our director upon effectiveness of our registration statement on Form F-1, of which this prospectus is a part, and will be the chairman of the compensation committee and a member of the audit committee and nominating and corporate governance committee of CKHL. Dr. Liu has around 30 years of experience in the structural and civil engineering field. Dr. Liu has substantial experience in acting as project director, project structural engineer, and registered structural engineer for residential, industrial, and commercial developments in public and private sectors. He is also experienced in large-scale alterations and addition work, building renovation, and improvement work. Dr. Liu is currently the principal of a consultancy company aimed to deliver architectural and engineering solutions to government and private sectors and serves as chairman and committee member of various government and institutional bodies. Dr. Liu is also a part-time lecturer for the Department of Civil Engineering of The University of Hong Kong. Dr. Liu has obtained a higher diploma in structural engineering and a bachelor’s degree in civil engineering with first-class honors from Hong Kong Polytechnic (currently known as The Hong Kong Polytechnic University) in 1990 and 1994, respectively. Dr. Liu also obtained a master’s degree in engineering from The University of Hong Kong in 1998 and a doctoral degree in business administration from Tarlac State University in the Philippines in 2013.

Mr. Ng Wai Leung has served as our quantity surveyor manager since May 2022. Mr. Ng first joined Chiu & Lee Partners in December 2019 as a quantity surveyor manager and has more than ten years of experience in construction work projects. Prior to joining us, he previously served as a senior quantity surveyor of another construction firm in Hong Kong. Mr. Ng obtained a bachelor’s degree in surveying from The Hong Kong Polytechnic University in 2013.

Family Relationships

Save as disclosed above, none of our directors or executive officers have a family relationship as defined in Item 401 of Regulation S-K.

Employment Agreements and Indemnification Agreements

We intend to enter into employment agreements with each of our executive officers that will become effective upon the completion of this offering. Under these agreements, each of our executive officers will be employed for a specified time period — typically for one year. We may terminate employment for cause, at any time, without advance notice or remuneration, for certain acts of the executive officer, such as conviction or plea of guilty to a felony or any crime involving moral turpitude, negligent or dishonest acts to our detriment, or misconduct or a failure to perform agreed duties. We may also terminate an executive officer’s employment without cause upon 30 days’ advance written notice. In such case of termination by us, we will provide severance payments to the executive officer as expressly required by applicable law of the jurisdiction where the executive officer is based. The executive officer may resign at any time with 30 days’ advance written notice.

102

Table of Contents

Each executive officer has agreed to hold, at all times during and after the termination or expiry of his or her employment agreement, in strict confidence and not to use, except as required in the performance of his or her duties in connection with the employment or pursuant to applicable law, any of our confidential information, or the confidential or proprietary information disclosed to the executive officer by or obtained by the executive officer from us either directly or indirectly in writing, orally, or otherwise, if specifically indicated to be confidential or reasonably expected to be confidential.

We intend to enter into agreements with all directors whose service will begin upon the effectiveness of the registration statement of which this prospectus forms a part. Pursuant to the agreements, each director has agreed to attend and participate in such number of meetings of the board and of the committees of which he or she may become a member as regularly or specially called and will agree to serve as a director for a year and be up for re-election each year at our annual shareholder meeting. The directors’ services will be compensated by cash under the agreement in an amount determined by the board.

We intend to enter into indemnification agreements with each of our executive directors and executive officers. Under these agreements, we agree to indemnify them against certain liabilities and expenses that they incur in connection with claims made by reason of their being a director or officer of our company. Insofar as indemnification for liabilities arising under the Securities Act may be permitted to our directors, officers, or persons controlling us under the foregoing provisions, we have been informed that, in the opinion of the SEC, such indemnification is against public policy as expressed in the Securities Act and is therefore unenforceable.

Involvement in Certain Legal Proceedings

To the best of our knowledge, none of our directors or executive officers has, during the past ten years, been involved in any legal proceedings described in subparagraph (f) of Item 401 of Regulation S-K.

Board of Directors

Our board of directors will consist of five directors, comprising two executive directors and three independent directors, upon the SEC’s declaration of effectiveness of our registration statement on Form F-1, of which this prospectus is a part. A director is not required to hold any shares in our Company to qualify to serve as a director. Subject to making appropriate disclosures to the board of directors in accordance with our post-offering amended and restated memorandum and articles of association, a director may vote with respect to any contract, proposed contract, or arrangement in which he or she is interested; in voting in respect to any such matter, such director should take into account his or her directors duties. A director may exercise all the powers of the company to borrow money; mortgage its business, property, and uncalled capital; and issue debentures or other securities whenever money is borrowed or as security for any obligation of the Company or of any third party.

Board Diversity

We seek to achieve board diversity through the consideration of a number of factors when selecting the candidates to our board, including, but not limited to, gender, skills, age, professional experience, knowledge, cultural, education background, ethnicity, and length of service. The ultimate decision of the appointment will be based on merit and the contribution that the selected candidates will bring to our board.

Our directors have a balanced mix of knowledge and skills. We will have three independent directors with different industry backgrounds, representing a majority of the members of our board. Our board is well balanced and diversified in alignment with our business development and strategy.

Committees of the Board of Directors

We have to established an audit committee, a compensation committee, and a nominating and corporate governance committee under the board of directors and have adopted a charter for each of the three committees. Each committee’s members and functions are described below.

103

Table of Contents

Audit Committee

Concurrent with the listing of our Company Ordinary Shares on Nasdaq, our audit committee will consist of Mr. Nachiappan Thirupathi, Mr. Wong Heung Ming, and Dr. Liu Yuk Shing, and it will be chaired by Mr. Wong Heung Ming. We have determined that each of these three director nominees satisfies the “independence” requirements of the Nasdaq Listing Rules and meets the independence standards under Rule 10A-3 under the Exchange Act. We have determined that Mr. Wong Heung Ming qualifies as an “audit committee financial expert.” The audit committee will oversee our accounting and financial reporting processes and the audits of our financial statements. The audit committee will be responsible for, among other things:

        selecting the independent registered public accounting firm and pre-approving all auditing and non-auditing services permitted to be performed by the independent registered public accounting firm;

        reviewing with the independent registered public accounting firm any audit problems or difficulties and management’s responses;

        reviewing and approving all proposed related party transactions, as defined in Item 404 of Regulation S-K under the Securities Act;

        discussing the annual audited financial statements with management and the independent registered public accounting firm;

        reviewing the adequacy and effectiveness of our accounting and internal control policies and procedures and any special steps taken to monitor and control major financial risk exposures;

        annually reviewing and reassessing the adequacy of our audit committee charter;

        meeting separately and periodically with management and the independent registered public accounting firm;

        monitoring compliance with our code of business conduct and ethics, including reviewing the adequacy and effectiveness of our procedures to ensure proper compliance; and

        reporting regularly to the board.

Compensation Committee

Concurrent with the listing of our Ordinary Shares on Nasdaq, our compensation committee will consist of Mr. Nachiappan Thirupathi, Mr. Wong Heung Ming and Dr. Liu Yuk Shing, and it will be chaired by Dr. Liu Yuk Shing. We have determined that each of these directors satisfies the “independence” requirements of the Nasdaq Listing Rules. The compensation committee assists the board in reviewing and approving the compensation structure, including all forms of compensation, relating to our directors and executive officers. Our chief executive officer may not be present at any committee meeting during which their compensation is deliberated upon. The compensation committee will be responsible for, among other things:

        reviewing and approving, or recommending to the board for its approval, the compensation for our chief executive officer and other executive officers;

        reviewing and recommending to the board for determination with respect to the compensation of our non-employee directors;

        reviewing periodically and approving any incentive compensation or equity plans, programs, or other similar arrangements; and

        selecting a compensation consultant, legal counsel, or other adviser only after taking into consideration all factors relevant to that person’s independence from management.

104

Table of Contents

Nominating and Corporate Governance Committee

Concurrent with the listing of our Company Ordinary Shares on Nasdaq, our nominating and corporate governance committee will consist of Mr. Nachiappan Thirupathi, Mr. Wong Heung Ming and Dr. Liu Yuk Shing, and it will be chaired by Mr. Nachiappan Thirupathi. We have determined that each of these directors satisfies the “independence” requirements of the Nasdaq Listing Rules. The nominating and corporate governance committee assists the board in selecting individuals qualified to become our directors and in determining the composition of the board and its committees. The nominating and corporate governance committee will be responsible for, among other things:

        recommending nominees to the board for election or re-election to the board or for appointment to fill any vacancy on the board;

        reviewing annually with the board the current composition of the board in regard to characteristics such as independence, knowledge, skills, experience, expertise, diversity, and availability of service to us;

        selecting and recommending to the board the names of directors to serve as members of the audit committee and the compensation committee, as well as of the nominating and corporate governance committee itself;

        developing and reviewing the corporate governance principles adopted by the board and advising the board with respect to significant developments in the law, practice of corporate governance, and our compliance with such laws and practices; and

        evaluating the performance and effectiveness of the board as a whole.

Foreign Private Issuer Exemption

We are a “foreign private issuer,” as defined by the SEC. As a result, in accordance with the rules and regulations of Nasdaq, we may choose to comply with home country governance requirements and certain exemptions thereunder rather than complying with Nasdaq corporate governance standards. We may choose to take advantage of the following exemptions afforded to foreign private issuers:

        Exemption from filing quarterly reports on Form 10-Q, from filing proxy solicitation materials on Schedule 14A or 14C in connection with annual or special meetings of shareholders, from providing current reports on Form 8-K disclosing significant events within four days of their occurrence, and from the disclosure requirements of Regulation FD.

        Exemption from Section 16 rules regarding sales of Ordinary Shares by insiders, which will provide less data in this regard than shareholders of U.S. companies that are subject to the Exchange Act.

        Exemption from the Nasdaq rules applicable to domestic issuers requiring disclosure within four business days of any determination to grant a waiver of the code of business conduct and ethics to directors and officers. Although we will require board approval of any such waiver, we may choose not to disclose the waiver in the manner set forth in the Nasdaq rules, as permitted by the foreign private issuer exemption.

Furthermore, Nasdaq Rule 5615(a)(3) provides that a foreign private issuer, such as us, may rely on our home country corporate governance practices in lieu of certain of the rules in the Nasdaq Rule 5600 Series and Rule 5250(d), provided that we nevertheless comply with Nasdaq’s Notification of Noncompliance requirement (Rule 5625), the Voting Rights requirement (Rule 5640), and that we have an audit committee that satisfies Rule 5605(c)(3), consisting of committee members that meet the independence requirements of Rule 5605(c)(2)(A)(ii). If we rely on our home country corporate governance practices in lieu of certain of the rules of Nasdaq, our shareholders may not have the same protections afforded to shareholders of companies that are subject to all of the corporate governance requirements of Nasdaq. If we choose to do so, we may utilize these exemptions for as long as we continue to qualify as a foreign private issuer.

105

Table of Contents

Duties of Directors

As a matter of Cayman Islands law, a director of a Cayman Islands company is in the position of a fiduciary with respect to the company and therefore it is considered that he owes the following duties to the company — a duty to act bona fide in the best interests of the company, a duty not to make a profit based on his or her position as director (unless the company permits him to do so) and a duty not to put himself in a position where the interests of the company conflict with his or her personal interest or his or her duty to a third party. A director of a Cayman Islands company owes to the company a duty to act with skill and care. It was previously considered that a director need not exhibit in the performance of his or her duties a greater degree of skill than may reasonably be expected from a person of his or her knowledge and experience. However, English and Commonwealth courts have moved towards an objective standard with regard to the required skill and care and these authorities are likely to be followed in the Cayman Islands.

Compensation of Directors and Executive Officers

For the years ended March 31, 2023 and 2022, we paid an aggregate of HK$2,645,500 (approximately US$339,167) and HK$1,578,000 (approximately US$202,308), respectively, in cash (including salaries and mandatory provident fund) to our directors and executive officers. Our Hong Kong subsidiary is required by law to contribute amounts equal to certain percentages of each employee’s salary for his or her mandatory provident fund. We have not made any agreements with our directors or executive officers to provide benefits upon termination of employment.

Equity Compensation Plan Information

We have not adopted any equity compensation plans.

Outstanding Equity Awards at Fiscal Year-End

As of March 31, 2023 and 2022, we had no outstanding equity awards.

106

Table of Contents

RELATED PARTY TRANSACTIONS

Before the completion of this offering, we intend to adopt an audit committee charter, which will require the committee to review all related-party transactions on an ongoing basis and all such transactions be approved by the audit committee.

Set forth below are the related party transactions of our company that occurred during the past three fiscal years.

As of March 31, 2023, 2022 and 2021, we had fund advances to our director, Mr. Keung Yun Yuen, of nil, nil and US$15,603, respectively. The balance is unsecured and interest-free. All advances to our director, Mr. Keung Yun Yuen, are expected to be settled before the listing of the Ordinary Shares.

Policies and Procedures for Related-Party Transactions

Our board of directors has created an audit committee in connection with this offering that will be tasked with review and approval of all related-party transactions.

107

Table of Contents

PRINCIPAL SHAREHOLDERS

The following table sets forth information regarding the beneficial ownership of our Ordinary Shares as of the date of this prospectus by our officers, directors, and 5% or greater beneficial owners of Ordinary Shares. There is no other person or group of affiliated persons known by us to beneficially own more than 5% of our Ordinary Shares. The following table assumes that none of our officers, directors or 5% or greater beneficial owners of our Ordinary Shares will purchase shares in this offering. In addition, the following table assumes that the over-allotment option has not been exercised. Holders of our Ordinary Shares are entitled to one (1) vote per share and vote on all matters submitted to a vote of our shareholders, except as may otherwise be required by law.

We have determined beneficial ownership in accordance with the rules of the SEC. These rules generally attribute beneficial ownership of securities to persons who possess sole or shared voting power or investment power with respect to those securities. The person is also deemed to be a beneficial owner of any security of which that person has a right to acquire beneficial ownership within 60 days. Unless otherwise indicated, the person identified in this table has sole voting and investment power with respect to all shares shown as beneficially owned by him, subject to applicable community property laws.

 

Ordinary Shares beneficially
owned prior to this offering

 

Ordinary Shares beneficially
held immediately after this offering

Name of Beneficial Owner

 

Number of
Ordinary
Shares

 

Approximate
percentage of
outstanding
Ordinary
Shares

 

Number of
Ordinary
Shares

 

Approximate
percentage of
outstanding
Ordinary
Shares
(5)

Directors, director nominees, and executive officers

       

 

       

Mr. Keung Yun Yuen(1)(3)

 

10,147,500

 

90.2

%

 

10,147,500

 

78.1%

Mr. Chan Lee Chuen(1)

 

 

 

 

 

Ms. Choi Hiu Ying(1)

 

 

 

 

 

Mr. Wong Heung Ming(1)

 

 

 

 

 

Mr. Nachiappan Thirupathi(1)

 

 

 

 

 

Dr. Liu Yuk Shing(1)

 

 

 

 

 

Mr. Ng Wai Leung(1)

 

 

 

 

 

5% or greater shareholders

       

 

       

Mr. Keung Yun Yuen(1)

 

10,147,500

 

90.2

%

 

10,147,500

 

78.1%

Fly Cloud Limited(4)

 

10,147,500

 

90.2

%

 

10,147,500

 

78.1%

____________

(1)      Except as otherwise indicated below, the business address for our directors and executive officers is at Room 2620, 26/F., New Tech Plaza, 34 Tai Yau Street, San Po Kong, Kowloon, Hong Kong.

(2)      Each of Mr. Nachiappan Thirupathi, Mr. Wong Heung Ming and Dr. Liu Yuk Shing will serve as our director upon the effectiveness of our registration statement on Form F-1 of which this prospectus is a part.

(3)      Mr. Keung Yun Yuen, a director of the Company, owns 100% of the equity interests in Fly Cloud Limited.

(4)      Fly Cloud Limited is controlled by Mr. Keung Yun Yuen. Pursuant to Section 13(d) of the Exchange Act and the rules promulgated thereunder, Mr. Keung may be deemed to have voting and investment power with respect to the 10,147,500 Ordinary Shares held by Fly Cloud Limited. The registered address of Fly Cloud Limited is Mandar House, 3rd Floor, Johnson’s Ghut, Tortola, BVI.

(5)      Based on Ordinary Shares outstanding immediately after the completion of this offering, assuming the underwriters do not exercise the over-allotment option.

As of the date of this prospectus, none of our outstanding Ordinary Shares are held by record holders in the United States. None of our major shareholders have different voting rights from other shareholders. We are not aware of any arrangement that may, at a subsequent date, result in a change of control of our company.

108

Table of Contents

DESCRIPTION OF SHARE CAPITAL

A copy of our Memorandum and Articles of Association is filed as an exhibit to the registration statement of which this prospectus is a part.

We are an exempted company incorporated with limited liability in the Cayman Islands and, upon completion of this offering, our affairs will be governed by our Memorandum and Articles of Association, the Companies Act and the common law of the Cayman Islands.

As of the date of this prospectus, our authorized share capital is US$50,000 divided into 500,000,000 Ordinary Shares, par value US$0.0001 each.

As of the date immediately prior to this offering, 11,250,000 Ordinary Shares of par value US$0.0001 per share were issued, fully paid and outstanding. Upon completion of this offering, we will have 12,990,000 Ordinary Shares issued and outstanding, assuming the underwriters do not elect to exercise their option to purchase additional Ordinary Shares from us.

Assuming that we obtain the requisite shareholder approval, we will adopt our Memorandum and Articles of Association which will become effective and replace our current memorandum and articles of association in its entirety immediately prior to the completion of this offering. The following are summaries of certain material provisions of our Memorandum and Articles of Association and the Companies Act insofar as they relate to the material terms of our Ordinary Shares.

Ordinary Shares

General

All of our outstanding Ordinary Shares are fully paid and non-assessable. Certificates representing the Ordinary Shares are issued in registered form. Our shareholders who are non-residents of the Cayman Islands may freely hold and vote their Ordinary Shares. We may not issue shares to bearer.

Dividends

Subject to the Companies Act and our Articles of Association, our Company in general meeting may declare dividends in any currency to be paid to the members but no dividend shall be declared in excess of the amount recommended by our board of directors.

Except in so far as the rights attaching to, or the terms of issue of, any share may otherwise provide:

(i)     all dividends shall be declared and paid according to the amounts paid up on the shares in respect of which the dividend is paid, although no amount paid up on a share in advance of calls shall for this purpose be treated as paid up on the share;

(ii)    all dividends shall be apportioned and paid pro rata in accordance with the amount paid up on the shares during any portion(s) of the period in respect of which the dividend is paid; and

(iii)   our board of directors may deduct from any dividend or other monies payable to any member all sums of money (if any) presently payable by him to our Company on account of calls, instalments or otherwise.

Where our board of directors or our Company in general meeting has resolved that a dividend should be paid or declared, our board of directors may resolve:

(aa)   that such dividend be satisfied wholly or in part in the form of an allotment of shares credited as fully paid up, provided that the members entitled to such dividend will be entitled to elect to receive such dividend (or part thereof) in cash in lieu of such allotment; or

(bb)  that the members entitled to such dividend will be entitled to elect to receive an allotment of shares credited as fully paid up in lieu of the whole or such part of the dividend as our board of directors may think fit.

109

Table of Contents

Upon the recommendation of our board of directors, our Company may by ordinary resolution in respect of any one particular dividend of our Company determine that it may be satisfied wholly in the form of an allotment of shares credited as fully paid up without offering any right to members to elect to receive such dividend in cash in lieu of such allotment.

Any dividend, bonus or other sum payable in cash to the holder of shares may be paid by cheque or warrant sent through the post. Every such cheque or warrant shall be made payable to the order of the person to whom it is sent and shall be sent at the holder’s or joint holders’ risk and payment of the cheque or warrant by the bank on which it is drawn shall constitute a good discharge to our Company. Any one of two or more joint holders may give effectual receipts for any dividends or other monies payable or property distributable in respect of the shares held by such joint holders.

Whenever our board of directors or our Company in general meeting has resolved that a dividend be paid or declared, our board of directors may further resolve that such dividend be satisfied wholly or in part by the distribution of specific assets of any kind.

Our board of directors may, if it thinks fit, receive from any member willing to advance the same, and either in money or money’s worth, all or any part of the money uncalled and unpaid or instalments payable upon any shares held by him, and in respect of all or any of the monies so advanced may pay interest at such rate (if any) not exceeding 20% per annum, as our board of directors may decide, but a payment in advance of a call shall not entitle the member to receive any dividend or to exercise any other rights or privileges as a member in respect of the share or the due portion of the shares upon which payment has been advanced by such member before it is called up.

All dividends, bonuses or other distributions unclaimed for one year after having been declared may be invested or otherwise used by our board of directors for the benefit of our Company until claimed and our Company shall not be constituted a trustee in respect thereof. All dividends, bonuses or other distributions unclaimed for six years after having been declared may be forfeited by our board of directors and, upon such forfeiture, shall revert to our Company.

No dividend or other monies payable by our Company on or in respect of any share shall bear interest against our Company.

Our Company may exercise the power to cease sending cheques for dividend entitlements or dividend warrants by post if such cheques or warrants remain uncashed on two consecutive occasions or after the first occasion on which such a cheque or warrant is returned undelivered.

Voting Rights

Subject to any special rights, restrictions or privileges as to voting for the time being attached to any class or classes of shares at any general meeting: (a) on a poll every member present in person or by proxy or, in the case of a member being a corporation, by our duly authorized representative shall have one vote for every share which is fully paid or credited as fully paid registered in his name in the register of members of our Company but so that no amount paid up or credited as paid up on a share in advance of calls or instalments is treated for this purpose as paid up on the share; and (b) on a show of hands every member who is present in person (or, in the case of a member being a corporation, by our duly authorized representative) or by proxy shall have one vote. Where more than one proxy is appointed by a member which is a Clearing House (as defined in the Articles) (or its nominee(s)) or a central depository house (or its nominee(s)), each such proxy shall have one vote on a show of hands. On a poll, a member entitled to more than one vote need not use all his votes or cast all the votes he does use in the same way.

Transfer of Ordinary Shares

Subject to the Companies Act and our Articles of Association, all transfers of shares shall be effected by an instrument of transfer in the usual or common form or in such other form as our board of directors may approve and may be under hand or, if the transferor or transferee is a Clearing House (as defined in the Articles) (or its nominee(s)) or a central depository house (or its nominee(s)), under hand or by machine imprinted signature, or by such other manner of execution as our board of directors may approve from time to time.

Execution of the instrument of transfer shall be by or on behalf of the transferor and the transferee, provided that our board of directors may dispense with the execution of the instrument of transfer by the transferor or transferee or accept mechanically executed transfers. The transferor shall be deemed to remain the holder of a share until the name of the transferee is entered in the register of members of our Company in respect of that share.

110

Table of Contents

Our board of directors may, in our absolute discretion, at any time and from time to time remove any share on the principal register to any branch register or any share on any branch register to the principal register or any other branch register. Unless our board of directors otherwise agrees, no shares on the principal register shall be removed to any branch register nor shall shares on any branch register be removed to the principal register or any other branch register. All removals and other documents of title shall be lodged for registration and registered, in the case of shares on any branch register, at the registered office and, in the case of shares on the principal register, at the place at which the principal register is located.

Our board of directors may, in our absolute discretion, decline to register a transfer of any share (not being a fully paid up share) to a person of whom it does not approve or on which our Company has a lien. It may also decline to register a transfer of any share issued under any share option scheme upon which a restriction on transfer subsists or a transfer of any share to more than four joint holders.

Our board of directors may decline to recognize any instrument of transfer unless a certain fee, up to such maximum sum as Nasdaq may determine to be payable, is paid to our Company, the instrument of transfer is properly stamped (if applicable), is in respect of only one class of share and is lodged at our registered office or the place at which the principal register is located accompanied by the relevant share certificate(s) and such other evidence as our board of directors may reasonably require is provided to show the right of the transferor to make the transfer (and if the instrument of transfer is executed by some other person on his behalf, the authority of that person so to do).

The registration of transfers of shares or of any class of shares may, after compliance with any notice requirement of Nasdaq, be suspended at such times and for such periods (not exceeding in the whole thirty days in any year) as our board of directors may determine.

Fully paid shares shall be free from any restriction on transfer (except when permitted by Nasdaq) and shall also be free from all liens.

Procedures on liquidation

A resolution that our Company be wound up by the court or be wound up voluntarily shall be a special resolution of our shareholders.

Subject to any special rights, privileges or restrictions as to the distribution of available surplus assets on liquidation for the time being attached to any class or classes of shares:

(i)     if our Company is wound up, the surplus assets remaining after payment to all creditors shall be divided among the members in proportion to the capital paid up on the shares held by them respectively; and

(ii)    if our Company is wound up and the surplus assets available for distribution among the members are insufficient to repay the whole of the paid-up capital, such assets shall be distributed, subject to the rights of any shares which may be issued on special terms and conditions, so that, as nearly as may be, the losses shall be borne by the members in proportion to the capital paid up on the shares held by them, respectively.

If our Company is wound up (whether the liquidation is voluntary or compelled by the court), the liquidator may, with the sanction of a special resolution and any other sanction required by the Companies Act, divide among the members in specie or kind the whole or any part of the assets of our Company, whether the assets consist of property of one kind or different kinds, and the liquidator may, for such purpose, set such value as he deems fair upon any one or more class or classes of property to be so divided and may determine how such division shall be carried out as between the members or different classes of members and the members within each class. The liquidator may, with the like sanction, vest any part of the assets in trustees upon such trusts for the benefit of members as the liquidator thinks fit, but so that no member shall be compelled to accept any shares or other property upon which there is a liability.

Calls on Ordinary Shares and Forfeiture of Ordinary Shares

Subject to these Articles and to the terms of allotment, our board of directors may, from time to time, make such calls as it thinks fit upon the members in respect of any monies unpaid on the shares held by them respectively (whether on account of the nominal value of the shares or by way of premium) and not by the conditions of allotment of such shares made payable at fixed times. A call may be made payable either in one sum or by instalments. If the sum payable in respect of any call or instalment is not paid on or before the day appointed for payment thereof, the person or persons from whom the sum is due shall pay interest on the same at such rate not exceeding 20% per annum

111

Table of Contents

as our board of directors shall fix from the day appointed for payment to the time of actual payment, but our board of directors may waive payment of such interest wholly or in part. Our board of directors may, if it thinks fit, receive from any member willing to advance the same, either in money or money’s worth, all or any part of the money uncalled and unpaid or instalments payable upon any shares held by him, and in respect of all or any of the monies so advanced our Company may pay interest at such rate (if any) not exceeding 20% per annum as our board of directors may decide.

If a member fails to pay any call or instalment of a call on the day appointed for payment, our board of directors may, for so long as any part of the call or instalment remains unpaid, serve not less than 14 days’ notice on the member requiring payment of so much of the call or instalment as is unpaid, together with any interest which may have accrued and which may still accrue up to the date of actual payment. The notice shall name a further day (not earlier than the expiration of 14 days from the date of the notice) on or before which the payment required by the notice is to be made, and shall also name the place where payment is to be made. The notice shall also state that, in the event of non-payment at or before the appointed time, the shares in respect of which the call was made will be liable to be forfeited.

If the requirements of any such notice are not complied with, any share in respect of which the notice has been given may at any time thereafter, before the payment required by the notice has been made, be forfeited by a resolution of our board of directors to that effect. Such forfeiture will include all dividends and bonuses declared in respect of the forfeited share and not actually paid before the forfeiture.

A person whose shares have been forfeited shall cease to be a member in respect of the forfeited shares but shall, nevertheless, remain liable to pay to our Company all monies which, at the date of forfeiture, were payable by him to our Company in respect of the shares together with (if our board of directors shall in our discretion so require) interest thereon from the date of forfeiture until payment at such rate not exceeding 20% per annum as our board of directors may prescribe.

Redemption of Ordinary Shares

Subject to the Companies Act, our Articles of Association, and, where applicable, the Nasdaq listing rules or any other law or so far as not prohibited by any law and subject to any rights conferred on the holders of any class of Shares, any power of our Company to purchase or otherwise acquire all or any of its own Shares (which expression as used in this Article includes redeemable Shares) be exercisable by our board of directors in such manner, upon such terms and subject to such conditions as it thinks fit.

Subject to the Companies Act, our Articles of Association, and to any special rights conferred on the holders of any Shares or attaching to any class of Shares, Shares may be issued on the terms that they may, at the option of our Company or the holders thereof, be liable to be redeemed on such terms and in such manner, including out of capital, as our board of directors may deem fit.

Variations of Rights of Shares

Subject to the Companies Act and without prejudice to our Articles of Association, if at any time the share capital of our Company is divided into different classes of shares, all or any of the special rights attached to any class of shares may (unless otherwise provided for by the terms of issue of the shares of that class) be varied, modified or abrogated with the sanction of a special resolution passed at a separate general meeting of the holders of the shares of that class. The provisions of the Articles relating to general meetings shall mutatis mutandis apply to every such separate general meeting, but so that the necessary quorum (whether at a separate general meeting or at its adjourned meeting) shall be not less than a person or persons together holding (or, in the case of a member being a corporation, by our duly authorized representative) or representing by proxy not less than one-third in nominal value of the issued shares of that class. Every holder of shares of the class shall be entitled on a poll to one vote for every such share held by him, and any holder of shares of the class present in person or by proxy may demand a poll.

Any special rights conferred upon the holders of any shares or class of shares shall not, unless otherwise expressly provided in the rights attaching to the terms of issue of such shares, be deemed to be varied by the creation or issue of further shares ranking pari passu therewith.

General Meetings of Shareholders

Our Company must hold an annual general meeting each fiscal year other than the fiscal year of our Company’s adoption of our Articles of Association.

112

Table of Contents

Extraordinary general meetings may be convened on the requisition of one or more members holding, at the date of deposit of the requisition, not less than one tenth of the paid up capital of our Company having the right of voting at general meetings. Such requisition shall be made in writing to our board of directors or the secretary of our Company for the purpose of requiring an extraordinary general meeting to be called by our board of directors for the transaction of any business specified in such requisition. Such meeting shall be held within two months after the deposit of such requisition. If within 21 days of such deposit, our board of directors fails to proceed to convene such meeting, the requisitionist(s) himself (themselves) may do so in the same manner, and all reasonable expenses incurred by the requisitionist(s) as a result of the failure of our board of directors shall be reimbursed to the requisitionist(s) by our Company.

Every general meeting of our Company shall be called by at least 10 clear days’ notice in writing. The notice shall be exclusive of the day on which it is served or deemed to be served and of the day for which it is given, and must specify the time, place and agenda of the meeting and particulars of the resolution(s) to be considered at that meeting and the general nature of that business.

Although a meeting of our Company may be called by shorter notice than as specified above, such meeting may be deemed to have been duly called if it is so agreed:

(i)     in the case of an annual general meeting, by all members of our Company entitled to attend and vote thereat; and

(ii)    in the case of any other meeting, by a majority in number of the members having a right to attend and vote at the meeting holding not less than 95% of the total voting rights at the meetings of all our shareholders.

All business transacted at an extraordinary general meeting shall be deemed special business. All business shall also be deemed special business where it is transacted at an annual general meeting, with the exception of the election of Directors which shall be deemed ordinary business.

No business other than the appointment of a chairman of a meeting shall be transacted at any general meeting unless a quorum is present when the meeting proceeds to business, and continues to be present until the conclusion of the meeting.

The quorum for a general meeting shall be two members entitled to vote and present in person (or in the case of a member being a corporation, by our duly authorized representative) or by proxy representing not less than one-third (1/3) in nominal value of the total issued voting shares in our Company throughout the meeting.

Inspection of Books and Records

Our shareholders have no general right to inspect or obtain copies of the register of members or corporate records of our company. They will, however, have such rights as may be set out in our Articles of Association.

Changes in Capital

Subject to the Companies Act, our shareholders may, by ordinary resolution:

(a)     increase our share capital by new shares of the amount fixed by that ordinary resolution and with the attached rights, priorities and privileges set out in that ordinary resolution;

(b)    consolidate and divide all or any of our share capital into shares of larger amount than our existing shares;

(c)     sub-divide our shares or any of them into our shares of smaller amount than is fixed by our Company’s Memorandum of Association, so, however, that in the subdivision the proportion between the amount paid and the amount, if any, unpaid on each reduced our shares shall be the same as it was in case of the share from which the reduced our shares is derived;

(d)    cancel any shares which, at the date of the passing of that ordinary resolution, have not been taken or agreed to be taken by any person and diminish the amount of our share capital by the amount of the shares so cancelled; and

(e)     convert all or any of our paid up shares into stock, and reconvert that stock into paid up shares of any denomination.

113

Table of Contents

Subject to the Companies Act and to any rights for the time being conferred on the shareholders holding a particular class of shares, our shareholders may, by special resolution, reduce our share capital or any capital redemption reserve in any way.

Certain Cayman Islands Company Considerations

Exempted Company

We are an exempted company with limited liability under the Companies Act. The Companies Act distinguishes between ordinary resident companies and exempted companies. Any company that is registered in the Cayman Islands but conducts business mainly outside of the Cayman Islands may apply to be registered as an exempted company. The requirements for an exempted company are essentially the same as for an ordinary company except for the exemptions and privileges listed below:

        an exempted company does not have to file an annual return of its shareholders with the Registrar of Companies in the Cayman Islands;

        an exempted company’s register of members is not open to inspection;

        an exempted company does not have to hold an annual general meeting;

        an exempted company may issue no par value, negotiable or bearer shares;

        an exempted company may obtain an undertaking against the imposition of any future taxation;

        an exempted company may register by way of continuation in another jurisdiction and be deregistered in the Cayman Islands;

        an exempted company may register as a limited duration company; and

        an exempted company may register as a segregated portfolio company.

“Limited liability” means that the liability of each shareholder is limited to the amount unpaid by the shareholder on the shares of the company.

Differences in Corporate Law

The Companies Act is modeled after that of England and Wales but does not follow recent statutory enactments in England. In addition, the Companies Act differs from laws applicable to United States corporations and their shareholders. Set forth below is a summary of the significant differences between the provisions of the Companies Act applicable to us and the laws applicable to companies incorporated in the State of Delaware.

This discussion does not purport to be a complete statement of the rights of holders of our Ordinary Shares under applicable law in the Cayman Islands or the rights of holders of the common stock of a typical corporation under applicable Delaware law.

Mergers and Similar Arrangements

The Companies Act permits mergers and consolidations between Cayman Islands companies and between Cayman Islands companies and non-Cayman Islands companies. For these purposes, (a) “merger” means the merging of two or more constituent companies and the vesting of their undertaking, property and liabilities in one of such companies as the surviving company, and (b) a “consolidation” means the combination of two or more constituent companies into a consolidated company and the vesting of the undertaking, property and liabilities of such companies to the consolidated company. In order to effect such a merger or consolidation, the directors of each constituent company must approve a written plan of merger or consolidation, which must then be authorized by (a) a special resolution of the shareholders of each constituent company, and (b) such other authorization, if any, as may be specified in such constituent company’s articles of association. The plan must be filed with the Registrar of Companies of the Cayman Islands together with a declaration as to the solvency of the consolidated or surviving company, a statement setting out the assets and liabilities of each constituent company and an undertaking that a copy of the certificate of

114

Table of Contents

merger or consolidation will be given to the members and creditors of each constituent company and that notification of the merger or consolidation will be published in the Cayman Islands Gazette. Court approval is not required for a merger or consolidation which is effected in compliance with these statutory procedures.

A merger between a Cayman Islands parent company and its Cayman subsidiary or subsidiaries does not require authorization by a resolution of shareholders. For this purpose a subsidiary is a company of which at least ninety percent (90%) of the issued shares entitled to vote are owned by the parent company.

The consent of each holder of a fixed or floating security interest over a constituent company is required unless this requirement is waived by a court in the Cayman Islands.

Save in certain circumstances, a dissentient shareholder of a Cayman constituent company is entitled to payment of the fair value of his shares upon dissenting to a merger or consolidation. The exercise of appraisal rights will preclude the exercise of any other rights save for the right to seek relief on the grounds that the merger or consolidation is void or unlawful.

Separate from the statutory provisions relating to mergers and consolidations, the Companies Act also contains statutory provisions that facilitate the reconstruction and amalgamation of companies by way of schemes of arrangement, provided that the arrangement is approved by a majority in number of each class of shareholders and creditors with whom the arrangement is to be made, and who must in addition represent three-fourths in value of each such class of shareholders or creditors, as the case may be, that are present and voting either in person or by proxy at a meeting, or meetings, convened for that purpose. The convening of the meetings and subsequently the arrangement must be sanctioned by the Grand Court of the Cayman Islands. While a dissenting shareholder has the right to express to the court the view that the transaction ought not to be approved, the court can be expected to approve the arrangement if it determines that:

        the statutory provisions as to the required majority vote have been met;

        the shareholders have been fairly represented at the meeting in question and the statutory majority are acting bona fide without coercion of the minority to promote interests adverse to those of the class;

        the arrangement is such that may be reasonably approved by an intelligent and honest man of that class acting in respect of his interest; and

        the arrangement is not one that would more properly be sanctioned under some other provision of the Companies Act.

The Companies Act also contains a statutory power of compulsory acquisition which may facilitate the “squeeze out” of dissentient minority shareholder upon a tender offer. When a tender offer is made and accepted by holders of ninety percent (90%) of the shares affected within four months, the offeror may, within a two-month period commencing on the expiration of such four-month period, require the holders of the remaining shares to transfer such shares to the offeror on the terms of the offer. An objection can be made to the Grand Court of the Cayman Islands.

If an arrangement and reconstruction is thus approved, the dissenting shareholder would have no rights comparable to appraisal rights, which would otherwise ordinarily be available to dissenting shareholders of Delaware corporations, providing rights to receive payment in cash for the judicially determined value of the shares.

Shareholders’ Suits

In principle, we will normally be the proper plaintiff and as a general rule a derivative action may not be brought by a minority shareholder. However, based on English authorities, which would in all likelihood be of persuasive authority in the Cayman Islands, the Cayman Islands court can be expected to follow and apply the common law principles (namely the rule in Foss v. Harbottle and the exceptions thereto) so that a non-controlling shareholder may be permitted to commence a class action against or derivative actions in the name of the company to challenge actions where:

        a company acts or proposes to act illegally or ultra vires;

        the act complained of, although not ultra vires, could only be effected duly if authorized by more than a simple majority vote that has not been obtained; and

        those who control the company are perpetrating a “fraud on the minority”.

115

Table of Contents

Indemnification of Directors and Executive Officers and Limitation of Liability

Cayman Islands law does not limit the extent to which a company’s memorandum and articles of association may provide for indemnification of officers and directors, except to the extent any such provision may be held by the Cayman Islands courts to be contrary to public policy, such as to provide indemnification against civil fraud or the consequences of committing a crime. Our Memorandum and Articles of Association provide that that we shall indemnify our officers and directors against all actions, proceedings, costs, charges, expenses, losses, damages or liabilities incurred or sustained by such directors or officer, other than by reason of such person’s dishonesty, willful default or fraud, in or about the conduct of our company’s business or affairs (including as a result of any mistake of judgment) or in the execution or discharge of his duties, powers, authorities or discretions, including without prejudice to the generality of the foregoing, any costs, expenses, losses or liabilities incurred by such director or officer in defending (whether successfully or otherwise) any civil proceedings concerning our company or its affairs in any court whether in the Cayman Islands or elsewhere.

This standard of conduct is generally the same as permitted under the Delaware General Corporation Act for a Delaware corporation. In addition, we intend to enter into indemnification agreements with our directors and senior executive officers that will provide such persons with additional indemnification beyond that provided in our Memorandum and Articles of Association. Insofar as indemnification for liabilities arising under the Securities Act may be permitted to our directors, officers or persons controlling us under the foregoing provisions, we have been informed that, in the opinion of the SEC, such indemnification is against public policy as expressed in the Securities Act and is therefore unenforceable.

Directors’ Fiduciary Duties

Under Delaware corporate law, a director of a Delaware corporation has a fiduciary duty to the corporation and its shareholders. This duty has two components: the duty of care and the duty of loyalty. The duty of care requires that a director act in good faith, with the care that an ordinarily prudent person would exercise under similar circumstances. Under this duty, a director must inform himself of, and disclose to shareholders, all material information reasonably available regarding a significant transaction. The duty of loyalty requires that a director act in a manner he or she reasonably believes to be in the best interests of the corporation. He or she must not use his or her corporate position for personal gain or advantage. This duty prohibits self-dealing by a director and mandates that the best interest of the corporation and its shareholders take precedence over any interest possessed by a director, officer or controlling shareholder and not shared by the shareholders generally. In general, actions of a director are presumed to have been made on an informed basis, in good faith and in the honest belief that the action taken was in the best interests of the corporation. However, this presumption may be rebutted by evidence of a breach of one of the fiduciary duties. Should such evidence be presented concerning a transaction by a director, a director must prove the procedural fairness of the transaction, and that the transaction was of fair value to the corporation.

As a matter of Cayman Islands law, a director of a Cayman Islands company is in the position of a fiduciary with respect to the company and therefore it is considered that he owes the following duties to the company — a duty to act bona fide in the best interests of the company, a duty not to make a profit based on his or her position as director (unless the company permits him to do so) and a duty not to put himself in a position where the interests of the company conflict with his or her personal interest or his or her duty to a third party. A director of a Cayman Islands company owes to the company a duty to act with skill and care. It was previously considered that a director need not exhibit in the performance of his or her duties a greater degree of skill than may reasonably be expected from a person of his or her knowledge and experience. However, English and Commonwealth courts have moved towards an objective standard with regard to the required skill and care and these authorities are likely to be followed in the Cayman Islands.

Shareholder Action by Written Consent

Under the Delaware General Corporation Act, a corporation may eliminate the right of shareholders to act by written consent by amendment to its certificate of incorporation. Our Articles of Association provide that any action required or permitted to be taken at general meetings of our Company may only be taken upon the vote of shareholders at general meeting and shareholders may approve corporate matters by way of a unanimous written resolution without a meeting being held.

116

Table of Contents

Shareholder Proposals

Under the Delaware General Corporation Act, a shareholder has the right to put any proposal before the annual meeting of shareholders, provided it complies with the notice provisions in the governing documents. A special meeting may be called by the board of directors or any other person authorized to do so in the governing documents, but shareholders may be precluded from calling special meetings.

The Companies Act does not provide shareholders with rights to requisition a general meeting nor any right to put any proposal before a general meeting. However, these rights may be provided in a company’s articles of association. Our Articles of Association allow any one or more of our shareholders who together hold shares which carry in aggregate not less than one tenth of the paid up capital of our company having the right of voting at general meetings to requisition an extraordinary general meeting of our shareholders, in which case our board is obliged to convene an extraordinary general meeting and to put the resolutions so requisitioned to a vote at such meeting. Other than this right to requisition a shareholders’ meeting, our Articles of Association do not provide our shareholders with any other right to put proposals before annual general meetings or extraordinary general meetings. As an exempted Cayman Islands company, we are not obliged by law to call shareholders’ annual general meetings.

Cumulative Voting

Under the Delaware General Corporation Act, cumulative voting for elections of directors is not permitted unless the corporation’s certificate of incorporation specifically provides for it. Cumulative voting potentially facilitates the representation of minority shareholders on a board of directors since it permits the minority shareholder to cast all the votes to which the shareholder is entitled on a single director, which increases the shareholder’s voting power with respect to electing such director. As permitted under Cayman Islands law, our Articles of Association do not provide for cumulative voting. As a result, our shareholders are not afforded any less protections or rights on this issue than shareholders of a Delaware corporation.

Removal of Directors

Under the Delaware General Corporation Law, a director of a corporation with a classified board may be removed only for cause with the approval of a majority of the outstanding shares entitled to vote, unless the certificate of incorporation provides otherwise. Under our Articles of Association, directors may be removed by an ordinary resolution of our shareholders.

Transactions with Interested Shareholders

The Delaware General Corporation Act contains a business combination statute applicable to Delaware corporations whereby, unless the corporation has specifically elected not to be governed by such statute by amendment to its certificate of incorporation, it is prohibited from engaging in certain business combinations with an “interested shareholder” for three years following the date that such person becomes an interested shareholder. An interested shareholder generally is a person or a group who or which owns or owned 15% or more of the target’s outstanding voting stock within the past three years. This has the effect of limiting the ability of a potential acquirer to make a two-tiered bid for the target in which all shareholders would not be treated equally. The statute does not apply if, among other things, prior to the date on which such shareholder becomes an interested shareholder, the board of directors approves either the business combination or the transaction which resulted in the person becoming an interested shareholder. This encourages any potential acquirer of a Delaware corporation to negotiate the terms of any acquisition transaction with the target’s board of directors.

Cayman Islands law has no comparable statute. As a result, we cannot avail ourselves of the types of protections afforded by the Delaware business combination statute. However, although Cayman Islands law does not regulate transactions between a company and its significant shareholders, it does provide that such transactions must be entered into bona fide in the best interests of the company and for a proper corporate purpose and not with the effect of constituting a fraud on the minority shareholders.

117

Table of Contents

Dissolution; Winding Up

Under the Delaware General Corporation Act, unless the board of directors approves the proposal to dissolve, dissolution must be approved by shareholders holding 100% of the total voting power of the corporation. Only if the dissolution is initiated by the board of directors may it be approved by a simple majority of the corporation’s outstanding shares. Delaware law allows a Delaware corporation to include in its certificate of incorporation a supermajority voting requirement in connection with dissolutions initiated by the board.

Under Cayman Islands law, a company may be wound up by either an order of the courts of the Cayman Islands or by a special resolution of its members or, if the company is unable to pay its debts as they fall due, by an ordinary resolution of its members. The court has authority to order winding up in a number of specified circumstances including where it is, in the opinion of the court, just and equitable to do so. Under the Companies Act and our Articles of Association, our company may be dissolved, liquidated or wound up by a special resolution of our shareholders.

Variation of Rights of Shares

Under the Delaware General Corporation Act, a corporation may vary the rights of a class of shares with the approval of a majority of the outstanding shares of such class, unless the certificate of incorporation provides otherwise. Under our Articles of Association, if our share capital is divided into more than one class of shares, we may vary the rights attached to any class with the sanction of a special resolution passed at a separate meeting of the holders of the shares of that class.

Amendment of Governing Documents

Under the Delaware General Corporation Act, a corporation’s governing documents may be amended with the approval of a majority of the outstanding shares entitled to vote, unless the certificate of incorporation provides otherwise. As permitted by Cayman Islands law, our Memorandum and Articles of Association may only be amended by a special resolution of our shareholders.

Rights of Non-Resident or Foreign Shareholders

There are no limitations imposed by our Memorandum and Articles of Association on the rights of non-resident or foreign shareholders to hold or exercise voting rights on our shares. In addition, there are no provisions in our Memorandum and Articles of Association governing the ownership threshold above which shareholder ownership must be disclosed.

Listing

We have applied to have our Ordinary Shares listed on the Nasdaq Capital Market under the symbol “CKHL.” We cannot guarantee that we will be successful in listing our Ordinary Shares on the Nasdaq Capital Market; however, we will not complete this offering unless we are listed on the Nasdaq Stock Market.

Transfer Agent

The transfer agent of our Ordinary Shares is Vstock Transfer, LLC located at 18 Lafeyette Place, Woodmere, New York 11593.

History of Securities Issuance

Securities/Purchaser

 

Date of
Issuance

 

Number of
Securities

 

Consideration

Ordinary Shares

       

 

   

Keung Yun Yuen

 

May 4, 2022

 

11,250,000

*

 

USD 1,125.00

____________

*        On May 4, 2022, Keung Yun Yuen transferred 551,250 Ordinary Shares to each of Ling Chi Fai and Wong Chi Wai at a total consideration of US$100,000 each.

118

Table of Contents

SHARES ELIGIBLE FOR FUTURE SALE

Before this offering, there was no established public market for our Ordinary Shares, and while we intend to apply for approval to have our Ordinary Shares listed on the Nasdaq Capital Market, we cannot assure you that a liquid trading market for the Ordinary Shares will develop or be sustained after this offering. Future sales of substantial amounts of our Ordinary Shares in the public markets after this offering, or the perception that such sales may occur, could adversely affect market prices prevailing from time to time. As described below, only a limited number of our Ordinary Shares currently outstanding will be available for sale immediately after this offering due to contractual and legal restrictions on resale. Nevertheless, after these restrictions lapse, future sales of substantial amounts of our Ordinary Shares, including Ordinary Shares issued upon exercise of outstanding options, in the public market in the United States, or the possibility of such sales, could negatively affect the market price in the United States of our Ordinary Shares and our ability to raise equity capital in the future.

Upon the closing of this offering, we will have 12,990,000 outstanding Ordinary Shares, assuming no exercise of the underwriters’ over-allotment option. Of that amount, 1,740,000 Ordinary Shares will be publicly held by investors participating in this offering, and 11,250,000 Ordinary Shares will be held by our existing shareholders, some of whom may be our affiliates as that term is defined in Rule 144 under the Securities Act. As defined in Rule 144, an affiliate of an issuer is a person that directly, or indirectly through one or more intermediaries, controls, or is controlled by, or is under common control with, the issuer.

All of the Ordinary Shares sold in this offering will be freely transferable by persons other than our affiliates in the United States without restriction or further registration under the Securities Act. Ordinary Shares purchased by one of our affiliates may not be resold, except pursuant to an effective registration statement or an exemption from registration, including an exemption under Rule 144 under the Securities Act described below.

The Ordinary Shares issued and outstanding prior to this offering are restricted securities, as that term is defined in Rule 144 under the Securities Act. These restricted securities may be sold in the United States only if they are registered or if they qualify for an exemption from registration under Rule 144 or Rule 701 under the Securities Act. These rules are described below.

Rule 144

In general, persons who have beneficially owned restricted Ordinary Shares for at least six months, and any affiliate of the Company who owns either restricted or unrestricted securities, are entitled to sell their securities without registration with the SEC under an exemption from registration provided by Rule 144 under the Securities Act.

Non-Affiliates

Any person who is not deemed to have been one of our affiliates at the time of, or at any time during the three months preceding, a seller may sell an unlimited number of restricted securities under Rule 144 if:

        the restricted securities have been held for at least six months, including the holding period of any prior owner other than one of our affiliates;

        we have been subject to the Exchange Act periodic reporting requirements for at least 90 days before the sale; and

        we are current in our Exchange Act reporting at the time of sale.

Any person who is not deemed to have been an affiliate of ours at the time of, or at any time during the three months preceding, a sale and has held the restricted securities for at least one year, including the holding period of any prior owner other than one of our affiliates, will be entitled to sell an unlimited number of restricted securities without regard to the length of time we have been subject to Exchange Act periodic reporting or whether we are current in our Exchange Act reporting.

119

Table of Contents

Affiliates

Persons seeking to sell restricted securities who are our affiliates at the time of, or any time during the three months preceding, a sale, would be subject to the restrictions described above. They are also subject to additional restrictions, by which such person would be required to comply with the manner of sale and notice provisions of Rule 144 and would be entitled to sell within any three month period only that number of securities that does not exceed the greater of either of the following:

        1% of the number of Ordinary Shares then outstanding, which will equal approximately 112,500 Ordinary Shares immediately after the closing of this offering based on the number of Ordinary Shares outstanding as of March 31, 2022; or

        the average weekly trading volume of our Ordinary Shares in the form of Ordinary Shares on the Nasdaq Capital Market during the four calendar weeks preceding the filing of a notice on Form 144 with respect to the sale.

Additionally, persons who are our affiliates at the time of, or any time during the three months preceding, a sale may sell unrestricted securities under the requirements of Rule 144 described above, without regard to the six month holding period of Rule 144, which does not apply to sales of unrestricted securities.

Rule 701

Rule 701 under the Securities Act, as in effect on the date of this prospectus, permits resales of shares in reliance upon Rule 144 but without compliance with certain restrictions of Rule 144, including the holding period requirement. If any of our employees, executive officers, or directors purchase shares under a written compensatory plan or contract, they may be entitled to rely on the resale provisions of Rule 701, but all holders of Rule 701 shares would be required to wait until 90 days after the date of this prospectus before selling any such shares. However, the Rule 701 shares would remain subject to lock-up arrangements as described below and would only become eligible for sale when the lock-up period expires.

Regulation S

Regulation S under the Securities Act provides an exemption from registration requirements in the United States for offers and sales of securities that occur outside the United States. Rule 903 of Regulation S provides the conditions to the exemption for a sale by an issuer, a distributor, their respective affiliates, or anyone acting on their behalf. Rule 904 of Regulation S provides the conditions to the exemption for a resale by persons other than those covered by Rule 903. In each case, any sale must be completed in an offshore transaction, as that term is defined in Regulation S, and no directed selling efforts, as that term is defined in Regulation S, may be made in the United States.

We are a foreign issuer as defined in Regulation S. As a foreign issuer, securities that we sell outside the United States pursuant to Regulation S are not considered to be restricted securities under the Securities Act, and, subject to the offering restrictions imposed by Rule 903, are freely tradable without registration or restrictions under the Securities Act, unless the securities are held by our affiliates. We are not claiming the potential exemption offered by Regulation S in connection with the offering of newly issued shares outside the United States and will register all of the newly issued shares under the Securities Act.

Subject to certain limitations, holders of our restricted shares who are not our affiliates or who are our affiliates by virtue of their status as our officer or director may resell their restricted shares in an “offshore transaction” under Regulation S if:

        none of the shareholder, its affiliate, nor any person acting on their behalf engages in directed selling efforts in the United States, and

        in the case of a sale of our restricted shares by an officer or director who is our affiliate solely by virtue of holding such position, no selling commission, fee, or other remuneration is paid in connection with the offer or sale other than the usual and customary broker’s commission that would be received by a person executing such transaction as agent.

Additional restrictions are applicable to a holder of our restricted shares who will be our affiliate other than by virtue of his or her status as our officer or director.

120

Table of Contents

Lock-up Agreements

Our directors, executive officers, and principal shareholders (defined as owners of 5% or more of our Ordinary Shares) have agreed, subject to limited exceptions, not to offer; pledge; announce the intention to sell; sell; contract to sell; sell any option or contract to purchase; purchase any option or contract to sell; grant any option, right, or warrant to purchase; or otherwise dispose of, directly or indirectly, or enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of our Ordinary Shares or such other securities for a period of 180 days after the effective date of the registration statement of which this prospectus forms a part, without the prior written consent of the representative. See “Underwriting.”

121

Table of Contents

MATERIAL INCOME TAX CONSIDERATIONS

The following summary of the material Cayman Islands, Hong Kong and U.S. federal income tax consequences of an investment in our Ordinary Shares is based upon laws and relevant interpretations thereof in effect as of the date of this prospectus, all of which are subject to change. This summary does not deal with all possible tax consequences relating to an investment in our Ordinary Shares, such as the tax consequences under state, local and other tax laws. The discussion is not intended to be, nor should it be construed as, legal or tax advice to any particular prospective purchaser. To the extent that the discussion relates to matters of Cayman Islands tax law, it represents the opinion of Appleby, our Cayman Islands counsel. To the extent that the discussion relates to matters of Hong Kong tax law, it represents the opinion of our Hong Kong counsel. To the extent that the discussion relates to matters of U.S. Federal Income Taxation, it represents the opinion of K&L Gates LLP, our U.S. counsel.

Cayman Islands Taxation

The Cayman Islands currently levy no taxes on individuals or corporations based upon profits, income, gains or appreciations and there is no taxation in the nature of inheritance tax or estate duty. There are no other taxes likely to be material to our Company levied by the Government of the Cayman Islands save for certain stamp duties which may be applicable, from time to time, on certain instruments. No stamp duty is payable in the Cayman Islands on transfers of shares of Cayman Islands companies save for those which hold interests in land in the Cayman Islands. There are no exchange control regulations or currency restrictions in effect in the Cayman Islands.

Hong Kong Profits Taxation

Our subsidiary incorporated in Hong Kong was subject to 16.5% Hong Kong profits tax on their taxable income assessable profits generated from operations arising in or derived from Hong Kong for the year of assessment of 2022/2023 and 2021/2022. As from year of assessment of 2018/2019 onwards, Hong Kong profits tax rates are 8.25% on assessable profits up to HK$2,000,000 and 16.5% on any part of assessable profits over HK$2,000,000. Under Hong Kong tax laws, our Hong Kong subsidiary is exempted from Hong Kong income profits tax on its foreign-derived income profits. In addition, payments of dividends from our Hong Kong subsidiary to us are not subject to any tax withholding in Hong Kong.

Material U.S. Federal Income Tax Considerations for U.S. Holders

The following discussion describes the material U.S. federal income tax consequences relating to the ownership and disposition of our Ordinary Shares by U.S. Holders (as defined below). This discussion applies to U.S. Holders that purchase our Ordinary Shares pursuant to this offering and hold such Ordinary Shares as capital assets. This discussion is based on the U.S. Internal Revenue Code of 1986, as amended, U.S. Treasury regulations promulgated thereunder, and administrative and judicial interpretations thereof, all as in effect on the date hereof and all of which are subject to change, possibly with retroactive effect. This discussion does not address all of the U.S. federal income tax consequences that may be relevant to specific U.S. Holders in light of their particular circumstances or to U.S. Holders subject to special treatment under U.S. federal income tax law (such as certain financial institutions; insurance companies; dealers or traders in securities or other persons that generally mark their securities to market for U.S. federal income tax purposes; tax-exempt entities or governmental organizations; retirement plans; regulated investment companies; real estate investment trusts; grantor trusts; brokers, dealers, or traders in securities, commodities, currencies, or notional principal contracts; certain former citizens or long-term residents of the United States; persons who hold our Ordinary Shares as part of a “straddle,” “hedge,” “conversion transaction,” “synthetic security,” or integrated investment; persons that have a “functional currency” other than the U.S. dollar; persons that own directly, indirectly, or through attribution 10% or more of the voting power of our Ordinary Shares; corporations that accumulate earnings to avoid U.S. federal income tax; partnerships and other pass-through entities; and investors in such pass-through entities). This discussion does not address any U.S. state or local or non-U.S. tax consequences or any U.S. federal estate, gift, or alternative minimum tax consequences.

As used in this discussion, the term “U.S. Holder” means a beneficial owner of our Ordinary Shares who is, for U.S. federal income tax purposes, (i) an individual who is a citizen or resident of the United States; (ii) a corporation (or entity treated as a corporation for U.S. federal income tax purposes) created or organized in or under the laws of the United States, any state thereof, or the District of Columbia; (iii) an estate, the income of which is subject to U.S. federal income tax regardless of its source; or (iv) a trust (x) with respect to which a court within the United States

122

Table of Contents

is able to exercise primary supervision over its administration and one or more U.S. persons has the authority to control all of its substantial decisions, or (y) that has elected under applicable U.S. Treasury regulations to be treated as a domestic trust for U.S. federal income tax purposes.

If an entity treated as a partnership for U.S. federal income tax purposes holds our Ordinary Shares, the U.S. federal income tax consequences relating to an investment in such Ordinary Shares will depend in part upon the status and activities of such entity and the particular partner. Any such entity should consult its own tax advisor regarding the U.S. federal income tax consequences applicable to it and its partners of the purchase, ownership, and disposition of our Ordinary Shares.

Persons considering an investment in our Ordinary Shares should consult their own tax advisors as to the particular tax consequences applicable to them relating to the purchase, ownership, and disposition of our Ordinary Shares, including the applicability of U.S. federal, state, and local tax laws and non-U.S. tax laws.

PFIC Consequences

In general, a corporation organized outside the United States will be treated as a PFIC for any taxable year in which either (i) at least 75% of its gross income is “passive income” (“PFIC income test”), or (ii) on average at least 50% of its assets, determined on a quarterly basis, are assets that produce passive income or are held for the production of passive income (“PFIC asset test”). Passive income for this purpose generally includes, among other things, dividends, interest, royalties, rents, and gains from the sale or exchange of property that gives rise to passive income. Assets that produce or are held for the production of passive income generally include cash (even if held as working capital or raised in a public offering) marketable securities, and other assets that may produce passive income. Generally, in determining whether a non-U.S. corporation is a PFIC, a proportionate share of the income and assets of each corporation in which it owns, directly or indirectly, at least a 25% interest (by value) is taken into account.

Although PFIC status is determined on an annual basis and generally cannot be determined until the end of a taxable year, based on the nature of our current and expected income and the current and expected value and composition of our assets, we do not presently expect to be a PFIC for our current taxable year or the foreseeable future. However, there can be no assurance given in this regard because the determination of whether we are or will become a PFIC is a fact-intensive inquiry made on an annual basis that depends, in part, upon the composition of our income and assets. In addition, there can be no assurance that the IRS will agree with our conclusion or that the IRS would not successfully challenge our position.

If we are a PFIC in any taxable year during which a U.S. Holder owns our Ordinary Shares, the U.S. Holder could be liable for additional taxes and interest charges under the “PFIC excess distribution regime” upon (i) a distribution paid during a taxable year that is greater than 125% of the average annual distributions paid in the three preceding taxable years, or, if shorter, the U.S. Holder’s holding period for our Ordinary Shares; and (ii) any gain recognized on a sale, exchange, or other disposition, including a pledge, of our Ordinary Shares, whether or not we continue to be a PFIC. Under the PFIC excess distribution regime, the tax on such distribution or gain would be determined by allocating the distribution or gain ratably over the U.S. Holder’s holding period for our Ordinary Shares. The amount allocated to the current taxable year (i.e., the year in which the distribution occurs or the gain is recognized) and any year prior to the first taxable year in which we are a PFIC will be taxed as ordinary income earned in the current taxable year. The amount allocated to other taxable years will be taxed at the highest marginal rates in effect for individuals or corporations, as applicable, to ordinary income for each such taxable year, and an interest charge, generally applicable to underpayments of tax, will be added to the tax.

If we are a PFIC for any year during which a U.S. Holder holds our Ordinary Shares, we must generally continue to be treated as a PFIC by that holder for all succeeding years during which the U.S. Holder holds such Ordinary Shares, unless we cease to meet the requirements for PFIC status and the U.S. Holder makes a “deemed sale” election with respect to our Ordinary Shares. If the election is made, the U.S. Holder will be deemed to sell our Ordinary Shares it holds at their fair market value on the last day of the last taxable year in which we qualified as a PFIC, and any gain recognized from such deemed sale would be taxed under the PFIC excess distribution regime. After the deemed sale election, the U.S. Holder’s Ordinary Shares would not be treated as shares of a PFIC unless we subsequently become a PFIC.

123

Table of Contents

If we are a PFIC for any taxable year during which a U.S. Holder holds our Ordinary Shares and one of our non-U.S. subsidiaries is also a PFIC (i.e., a lower-tier PFIC), such U.S. Holder would be treated as owning a proportionate amount (by value) of the shares of the lower-tier PFIC and would be taxed under the PFIC excess distribution regime on distributions by the lower-tier PFIC and on gain from the disposition of shares of the lower-tier PFIC even though such U.S. Holder would not receive the proceeds of those distributions or dispositions. Any of our non-U.S. subsidiaries that have elected to be disregarded as entities separate from us or as partnerships for U.S. federal income tax purposes would not be corporations under U.S. federal income tax law and, accordingly, cannot be classified as lower-tier PFICs. However, non-U.S. subsidiaries that have not made the election may be classified as a lower-tier PFIC if we are a PFIC during your holding period and the subsidiary meets the PFIC income test or PFIC asset test. Each U.S. Holder is advised to consult its tax advisors regarding the application of the PFIC rules to any of our non-U.S. subsidiaries.

If we are a PFIC, a U.S. Holder will not be subject to tax under the PFIC excess distribution regime on distributions or gain recognized on our Ordinary Shares if a valid “mark-to-market” election is made by the U.S. Holder for our Ordinary Shares. An electing U.S. Holder generally would take into account, as ordinary income each year, the excess of the fair market value of our Ordinary Shares held at the end of such taxable year over the adjusted tax basis of such Ordinary Shares. The U.S. Holder would also take into account, as an ordinary loss each year, the excess of the adjusted tax basis of such Ordinary Shares over their fair market value at the end of the taxable year, but only to the extent of the excess of amounts previously included in income over ordinary losses deducted as a result of the mark-to-market election. The U.S. Holder’s tax basis in our Ordinary Shares would be adjusted to reflect any income or loss recognized as a result of the mark-to-market election. Any gain from a sale, exchange, or other disposition of our Ordinary Shares in any taxable year in which we are a PFIC would be treated as ordinary income, and any loss from such sale, exchange, or other disposition would be treated first as ordinary loss (to the extent of any net mark-to-market gains previously included in income) and thereafter as capital loss. If, after having been a PFIC for a taxable year, we cease to be classified as a PFIC because we no longer meet the PFIC income test or PFIC asset test, the U.S. Holder would not be required to take into account any latent gain or loss in the manner described above, and any gain or loss recognized on the sale or exchange of the Ordinary Shares would be classified as a capital gain or loss.

A mark-to-market election is available to a U.S. Holder only for “marketable stock.” Generally, stock will be considered marketable stock if it is “regularly traded” on a “qualified exchange” within the meaning of applicable U.S. Treasury regulations. A class of stock is regularly traded during any calendar year during which such class of stock is traded, other than in de minimis quantities, on at least 15 days during each calendar quarter.

Our Ordinary Shares will be marketable stock as long as they remain listed on the Nasdaq Capital Market and are regularly traded. A mark-to-market election will not apply to the Ordinary Shares for any taxable year during which we are not a PFIC, but it will remain in effect with respect to any subsequent taxable year in which we become a PFIC. Such election will not apply to any of our non-U.S. subsidiaries. Accordingly, a U.S. Holder may continue to be subject to tax under the PFIC excess distribution regime with respect to any lower-tier PFICs notwithstanding the U.S. Holder’s mark-to-market election for the Ordinary Shares.

Our Company and all distributions, interest, and other amounts paid by us in respect to our shares to persons who are not resident in the Cayman Islands are exempt from all provisions of the Income Tax Ordinance in the Cayman Islands. No estate, inheritance, succession, or gift tax, rate, duty, levy, or other charge is payable by persons who are not resident in the Cayman Islands with respect to any of our shares, debt obligations, or other securities. All instruments relating to transactions in respect to our shares, debt obligations, or other securities and all instruments relating to other transactions relating to our business are exempt from payment of stamp duty in the Cayman Islands, except for those that hold interests in land in the Cayman Islands. There are currently no withholding taxes or exchange control regulations in the Cayman Islands applicable to us or our shareholders.

The tax consequences that would apply if we are a PFIC would also be different from those described above if a U.S. Holder were able to make a valid qualified electing fund (“QEF”) election. As we do not expect to provide U.S. Holders with the information necessary for a U.S. Holder to make a QEF election, prospective investors should assume that a QEF election will not be available.

The U.S. federal income tax rules relating to PFICs are very complex. Prospective U.S. investors are strongly urged to consult their own tax advisors with respect to the impact of PFIC status on the purchase, ownership, and disposition of our Ordinary Shares, the consequences to them of an investment in a PFIC, any elections available with respect to the Ordinary Shares, and the IRS information reporting obligations with respect to the purchase, ownership, and disposition of Ordinary Shares of a PFIC.

124

Table of Contents

Distributions

Subject to the discussion above under “PFIC Consequences,” a U.S. Holder that receives a distribution with respect to our Ordinary Shares generally will be required to include the gross amount of such distribution in gross income as a dividend when actually or constructively received to the extent of the U.S. Holder’s pro rata share of our current and/or accumulated earnings and profits (as determined under U.S. federal income tax principles). To the extent a distribution received by a U.S. Holder is not a dividend because it exceeds the U.S. Holder’s pro rata share of our current and accumulated earnings and profits, it will be treated first as a tax-free return of capital and reduce (but not below zero) the adjusted tax basis of the U.S. Holder’s Ordinary Shares. To the extent the distribution exceeds the adjusted tax basis of the U.S. Holder’s Ordinary Shares, the remainder will be taxed as capital gain. Because we may not account for our earnings and profits in accordance with U.S. federal income tax principles, U.S. Holders should expect all distributions to be reported to them as dividends.

Distributions on our Ordinary Shares that are treated as dividends generally will constitute income from sources outside the United States for foreign tax credit purposes and generally will constitute passive category income. Such dividends will not be eligible for the “dividends received” deduction generally allowed to corporate shareholders with respect to dividends received from U.S. corporations. Dividends paid by a “qualified foreign corporation” to certain non-corporate U.S. Holders may be eligible for taxation at a reduced capital gains rate rather than the marginal tax rates generally applicable to ordinary income, provided that a holding period requirement (more than 60 days of ownership, without protection from the risk of loss, during the 121-day period beginning 60 days before the ex-dividend date) and certain other requirements are met. Each U.S. Holder is advised to consult its tax advisors regarding the availability of the reduced tax rate on dividends to its particular circumstances. However, if we are a PFIC for the taxable year in which the dividend is paid or the preceding taxable year (see discussion above under “PFIC Consequences”), we will not be treated as a qualified foreign corporation, and therefore, the reduced capital gains tax rate described above will not apply.

Dividends will be included in a U.S. Holder’s income on the date of the depositary’s receipt of the dividend. The amount of any dividend income paid in Cayman Islands dollars will be the U.S. dollar amount calculated by reference to the exchange rate in effect on the date of receipt, regardless of whether the payment is in fact converted into U.S. dollars. If the dividend is converted into U.S. dollars on the date of receipt, a U.S. Holder should not be required to recognize foreign currency gain or loss in respect to the dividend income. A U.S. Holder may have foreign currency gain or loss if the dividend is converted into U.S. dollars after the date of receipt.

A non-U.S. corporation (other than a corporation that is classified as a PFIC for the taxable year in which the dividend is paid or the preceding taxable year) generally will be considered to be a qualified foreign corporation with respect to any dividend it pays on Ordinary Shares that are readily tradable on an established securities market in the United States.

Sale, Exchange or Other Disposition of Our Ordinary Shares

Subject to the discussion above under “PFIC Consequences,” a U.S. Holder generally will recognize capital gain or loss for U.S. federal income tax purposes upon the sale, exchange, or other disposition of our Ordinary Shares in an amount equal to the difference, if any, between the amount realized (i.e., the amount of cash plus the fair market value of any property received) on the sale, exchange, or other disposition and such U.S. Holder’s adjusted tax basis in the Ordinary Shares. Such capital gain or loss generally will be long-term capital gain taxable at a reduced rate for non-corporate U.S. Holders or long-term capital loss if, on the date of sale, exchange, or other disposition, the Ordinary Shares were held by the U.S. Holder for more than one year. Any capital gain of a non-corporate U.S. Holder that is not long-term capital gain is taxed at ordinary income rates. The deductibility of capital losses is subject to limitations. Any gain or loss recognized from the sale or other disposition of our Ordinary Shares will generally be gain or loss from sources within the United States for U.S. foreign tax credit purposes.

Medicare Tax

Certain U.S. Holders that are individuals, estates, or trusts and whose income exceeds certain thresholds generally are subject to a 3.8% tax on all or a portion of their net investment income, which may include their gross dividend income and net gains from the disposition of our Ordinary Shares. If you are a U.S. person that is an individual, estate, or trust, you are encouraged to consult your tax advisor regarding the applicability of this Medicare tax to your income and gains in respect to your investment in our Ordinary Shares.

125

Table of Contents

Information Reporting and Backup Withholding

U.S. Holders may be required to file certain U.S. information reporting returns with the IRS with respect to an investment in our Ordinary Shares, including, among others, IRS Form 8938 (Statement of Specified Foreign Financial Assets). As described above under “PFIC Consequences,” each U.S. Holder who is a shareholder of a PFIC must file an annual report containing certain information. U.S. Holders paying more than $100,000 for our Ordinary Shares may be required to file IRS Form 926 (Return by a U.S. Transferor of Property to a Foreign Corporation) reporting this payment. Substantial penalties may be imposed upon a U.S. Holder that fails to comply with the required information reporting.

Dividends on and proceeds from the sale or other disposition of our Ordinary Shares may be reported to the IRS unless the U.S. Holder establishes a basis for exemption. Backup withholding may apply to amounts subject to reporting if the holder (i) fails to provide an accurate U.S. taxpayer identification number or otherwise establish a basis for exemption, or (ii) is described in certain other categories of persons. However, U.S. Holders that are corporations generally are excluded from these information reporting and backup withholding tax rules.

Backup withholding is not an additional tax. Any amounts withheld under the backup withholding rules generally will be allowed as a refund or a credit against a U.S. Holder’s U.S. federal income tax liability if the required information is furnished by the U.S. Holder on a timely basis to the IRS.

U.S. Holders should consult their own tax advisors regarding the backup withholding tax and information reporting rules.

126

Table of Contents

UNDERWRITING

In connection with this offering, we will enter into an underwriting agreement with EF Hutton, division of Benchmark Investments, LLC, as representative of the underwriters named therein in this offering. The representative may retain other brokers or dealers to act as sub-agents or selected dealers on their behalf in connection with this offering. The underwriters have agreed to purchase from us, on a firm commitment basis, the number of Ordinary Shares set forth opposite its name below, at the offering price less the underwriting discounts set forth on the cover page of this prospectus:

Name of Underwriters

 

Number of
Ordinary Shares

EF Hutton, division of Benchmark Investments, LLC

 

 

Total

 

1,740,000

The underwriters are committed to purchase all the Ordinary Shares offered by this prospectus if they purchase any Ordinary Shares. The underwriters are not obligated to purchase the Ordinary Shares covered by the underwriter’s over-allotment option to purchase Ordinary Shares as described below. The underwriters are offering the Ordinary Shares, subject to prior sale, when, as, and if issued to and accepted by them, subject to approval of legal matters by their counsel and other conditions contained in the underwriting agreement, such as the receipt by the underwriters of officer’s certificates and legal opinions. The underwriters reserve the right to withdraw, cancel, or modify offers to the public and to reject orders in whole or in part.

Pricing of this Offering

Prior to this offering, there has been no public market for our Ordinary Shares. The IPO price for our Ordinary Shares will be determined through negotiations between us and the representative. Among the factors to be considered in these negotiations will be prevailing market conditions, our financial information, market valuations of other companies that we and the representative believe to be comparable to us, estimate of our business potential and earning prospects, the present state of our development, and other factors deemed relevant. The IPO price of our Ordinary Shares in this offering does not necessarily bear any direct relationship to the assets, operations, book value, or other established criteria of value of our company.

Over-Allotment Option

We have granted to the underwriters a 45-day option to purchase up to an aggregate of 261,000 additional Ordinary Shares (equal to 15% of the number of Ordinary Shares sold in the offering) at the offering price per Ordinary Share less underwriting discounts and commissions. The underwriters may exercise this option for 45 days from the date of closing of this offering solely to cover sales of Ordinary Shares by the underwriters in excess of the total number of Ordinary Shares set forth in the table above. If any of the additional Ordinary Shares are purchased, the underwriters will offer the additional Ordinary Shares at $[      ] per Ordinary Share, the offering price of each Ordinary Share.

Discounts and Expenses

The underwriting discounts for the shares and the over-allotment shares are equal to 8.0% of the IPO price.

The following table shows the price per share and total IPO price, underwriting discounts, and proceeds before expenses to us. The total amounts are shown assuming both no exercise and full exercise of the over-allotment option.

     

Total

   

Per Share

 

No Exercise of
Over-allotment
Option

 

Full Exercise of
Over-allotment
Option

IPO price(1)

 

$

4.00

 

$

6,960,000

 

$

8,004,000

Underwriting discounts to be paid by us

 

$

0.32

 

$

556,800

 

$

640,320

Proceeds to us, before expenses

 

$

3.68

 

$

6,403,200

 

$

7,363,680

____________

(1)      Based on an assumed public offering price of US$4.00 per share.

127

Table of Contents

We have agreed to pay all expenses relating to the offering, including, without limitation: (a) all filing fees and expenses relating to the registration of the Shares with the Commission; (b) all fees and expenses relating to the listing of the Shares on Nasdaq; (c) all fees associated with the review of the offering by FINRA; (d) all fees, expenses and disbursements relating to the registration, qualification or exemption of shares offered under “blue sky” securities laws or the securities laws of foreign jurisdictions designated by the representative, including the reasonable fees and expenses of the representative’s blue sky counsel; (e) all fees, expenses and disbursements relating to the registration, qualification or exemption of the shares under the securities laws of such foreign jurisdictions; (f) the costs of mailing and printing the offering materials; (g) transfer and/or stamp taxes, if any, payable upon our transfer of the Shares to the representative; and (h) the fees and expenses of our accountants; and (i) actual accountable expenses of the representative not to exceed $150,000 for fees and expenses including “road show”, diligence, and reasonable legal fees and disbursements for the representative’s legal counsel. Additionally, we have agreed to provide an expense advance to the representative of $50,000 to be applied against out-of-pocket accountable expense, which will be returned to us to the extent such out-of-pocket accountable expenses are not actually incurred in accordance with FINRA Rule 5110(g)(4)(A).

We estimate that the total expenses of the offering payable by us, excluding the underwriting discounts and non-accountable expense allowance, will be approximately $1,900,641.

The underwriters intend to offer our Ordinary Shares to their retail customers only in states in which we are permitted to offer our Ordinary Shares. We have relied on an exemption to the blue sky registration requirements afforded to “covered securities.” Securities listed on a National Securities Exchange are “covered securities.” If we were unable to meet the National Securities Exchange listing standards, then we would be unable to rely on the covered securities exemption to blue sky registration requirements and we would need to register the offering in each state in which we planned to sell shares. Consequently, we will not complete this offering unless we meet the National Securities Exchange’s listing requirements and our application to list on the exchange is approved.

The foregoing does not purport to be a complete statement of the terms and conditions of the underwriting agreement. A form of the underwriting agreement is included as an exhibit to the registration statement of which this prospectus forms a part.

Right of First Refusal

We have granted the representative a right of first refusal, for a period of twelve (12) months from the closing of the offering, to act as the sole investment banker, book-runner, and/or placement agent, at the representative’s sole discretion, for each and every future public and private equity and debt offering, including all equity linked financings (each being referred to as a subject transaction), during such twelve (12) month period, on terms and conditions customary to the representative for such subject transactions. The representative shall have the sole right to determine whether or not any other broker dealer shall have the right to participate in the subject transactions and the economic terms of such participation.

Tail Fee

We have also agreed to pay the representative, subject to certain exceptions, a cash fee equal to eight percent (8.0%) of the gross proceeds received by the Company from the sale of any equity, debt and/or equity derivative instruments to any investor actually introduced by the representative to the Company during the period from the date the representative was engaged until the final closing of this offering (the “Engagement Period”), in connection with any public or private financing or capital raise (each a “Tail Financing”), and such Tail Financing is consummated at any time during the Engagement Period or within the twelve (12) month period following the expiration or termination of the Engagement Period (the “Tail Period”), provided that such Tail Financing is by a party actually introduced to the Company in an offering in which the Company has direct knowledge of such party’s participation. The right to receive a fee in connection with the Tail Financing shall be subject to FINRA Rule 5110(g), and the Company shall have a right of termination for cause, which includes that the Company may terminate the representative’s engagement upon the representative’s material failure to provide the underwriting services required by the underwriting agreement. The Company’s exercise of the right of termination for cause will eliminate any obligations with respect to the payment of any termination fee or provision of any tail financing fee, including the tail financing set forth above.

128

Table of Contents

Lock-up Agreements

Our directors, executive officers, and principal shareholders (defined as owners of 5% or more of our Ordinary Shares) have agreed, subject to limited exceptions, not to offer; pledge; announce the intention to sell; sell; contract to sell; sell; any option or contract to purchase; purchase any option or contract to sell; grant any option, right, or warrant to purchase; or otherwise dispose of, directly or indirectly, or enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of our Ordinary Shares or such other securities for a period of 180 days after the effective date of registration statement of which this prospectus forms a part, without the prior written consent of the representative.

No Sales of Similar Securities

We have agreed not to offer; pledge; announce the intention to sell; sell; contract to sell; sell any option or contract to purchase; purchase any option or contract to sell; grant any option, right, or warrant to purchase; or otherwise transfer or dispose of, directly or indirectly, any Ordinary Shares or any securities convertible into or exercisable or exchangeable for Ordinary Shares or enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of our Ordinary Shares, whether any such transaction is to be settled by delivery of Ordinary Shares or such other securities, in cash or otherwise, without the prior written consent of the representative, for a period of 180 days from the effective date of registration statement of which this prospectus forms a part.

Foreign Regulatory Restrictions on Purchase of our Ordinary Shares

We have not taken any action to permit a public offering of our Ordinary Shares outside the United States or to permit the possession or distribution of this prospectus outside the United States. People outside the United States who come into possession of this prospectus must inform themselves about and observe any restrictions relating to this offering of our Ordinary Shares and the distribution of this prospectus outside the United States.

Indemnification

We have agreed to indemnify the underwriters against liabilities relating to the offering arising under the Securities Act and the Exchange Act and to contribute to payments that the underwriters may be required to make for these liabilities.

Application for Nasdaq Listing

We intend to apply to have our Ordinary Shares approved for listing/quotation on the Nasdaq Capital Market under the symbol “CKHL.” We will not consummate and close this offering without a listing approval letter from Nasdaq Capital Market. Our receipt of a listing approval letter is not the same as an actual listing on the Nasdaq Capital Market. The listing approval letter will serve only to confirm that, if we sell a number of Ordinary Shares in this offering sufficient to satisfy applicable listing criteria, our Ordinary Shares will in fact be listed. We do not intend to apply to list the representative’s warrants on any security exchange.

Electronic Offer, Sale, and Distribution

A prospectus in electronic format may be made available on websites or through other online services maintained by the underwriters or selling group members, if any, or by their affiliates, and the underwriters may distribute prospectus electronically. The underwriters may agree to allocate a number of Ordinary Shares to selling group members for sale to their online brokerage account holders. The Ordinary Shares to be sold pursuant to Internet distributions will be allocated on the same basis as other allocations. Other than the prospectus in electronic format, the information on, or that can be accessed through, these websites and any information contained in any other website maintained by these entities is not part of, and is not incorporated by reference into, this prospectus or the registration statement of which this prospectus forms a part, has not been approved and/or endorsed by us or the underwriters, and it should not be relied upon by investors.

In connection with this offering, certain of the underwriters or securities dealers may distribute prospectuses by electronic means, such as e-mail.

129

Table of Contents

Passive Market Making

Any underwriter who is a qualified market maker on Nasdaq may engage in passive market making transactions on Nasdaq, in accordance with Rule 103 of Regulation M under the Exchange Act, during a period before the commencement of offers or sales of the shares and extending through the completion of the distribution. Passive market makers must comply with applicable volume and price limitations and must be identified as a passive market maker. In general, a passive market maker must display its bid at a price not in excess of the highest independent bid for such security. If all independent bids are lowered below the passive market maker’s bid, however, the passive market maker’s bid must then be lowered when certain purchase limits are exceeded.

Potential Conflicts of Interest

The underwriters and their affiliates may, from time to time, engage in transactions with and perform services for us in the ordinary course of their business for which they may receive customary fees and reimbursement of expenses. In the ordinary course of their various business activities, the underwriters and their affiliates may make or hold a broad array of investments and actively trade debt and equity securities (or related derivative securities) and financial instruments (including bank loans) for their own accounts and for the accounts of their customers, and such investment and securities activities may involve securities and/or instruments of our Company. The underwriters and their affiliates may also make investment recommendations and/or publish or express independent research views in respect to such securities or instruments and may at any time hold, or recommend to clients that they acquire, long and/or short positions in such securities and instruments.

Selling Restrictions

Other than in the United States, no action may be taken, and no action has been taken, by us or the underwriters that would permit a public offering of the Ordinary Shares offered by, or the possession, circulation, or distribution of, this prospectus in any jurisdiction where action for that purpose is required. The Ordinary Shares offered by this prospectus may not be offered or sold, directly or indirectly, nor may this prospectus or any other offering material or advertisements in connection with the offer and sale of any such shares be distributed or published in any jurisdiction, except under circumstances that will result in compliance with the applicable rules and regulations of that jurisdiction. Persons into whose possession this prospectus comes are advised to inform themselves about and to observe any restrictions relating to the offering and the distribution of this prospectus. This prospectus does not constitute an offer to sell or a solicitation of an offer to buy any Ordinary Shares offered by this prospectus in any jurisdiction in which such an offer or a solicitation is unlawful.

In addition to the offering of the Ordinary Shares in the United States, the underwriters may, subject to applicable foreign laws, also offer the Ordinary Shares in certain countries.

Price Stabilization, Short Positions, and Penalty Bids

Until the distribution of the Ordinary Shares offered by this prospectus is completed, rules of the SEC may limit the ability of the underwriters to bid for and to purchase our Ordinary Shares. As an exception to these rules, the underwriters may engage in transactions effected in accordance with Regulation M under the Exchange Act that are intended to stabilize, maintain, or otherwise affect the price of our Ordinary Shares. The underwriters may engage in over-allotment sales, syndicate-covering transactions, stabilizing transactions, and penalty bids in accordance with Regulation M.

        Stabilizing transactions consist of bids or purchases made by the managing underwriter for the purpose of preventing or slowing a decline in the market price of our securities while this offering is in progress.

        Short sales and over-allotments occur when the managing underwriter, on behalf of the underwriting syndicate, sells more of our shares than they purchase from us in this offering. In order to cover the resulting short position, the managing underwriter may exercise the over-allotment option described above and/or may engage in syndicate-covering transactions. There is no contractual limit on the size of any syndicate-covering transaction. The underwriters will deliver a prospectus in connection with any such short sales. Purchasers of shares sold short by the underwriters are entitled to the same remedies under the federal securities laws as any other purchaser of units covered by the registration statement.

130

Table of Contents

        Syndicate-covering transactions are bids for or purchases of our securities on the open market by the managing underwriter on behalf of the underwriters in order to reduce a short position incurred by the managing underwriter on behalf of the underwriters.

        A penalty bid is an arrangement permitting the managing underwriter to reclaim the selling concession that would otherwise accrue to an underwriter if the Ordinary Shares originally sold by the underwriter were later repurchased by the managing underwriter and therefore were not effectively sold to the public by such underwriter.

Stabilization, syndicate-covering transactions, and penalty bids may have the effect of raising or maintaining the market price of our Ordinary Shares or preventing or delaying a decline in the market price of our Ordinary Shares. As a result, the price of our Ordinary Shares may be higher than the price that might otherwise exist in the open market.

Neither we nor the underwriters make any representation or prediction as to the effect that the transactions described above may have on the prices of our Ordinary Shares. These transactions may occur on Nasdaq or on any trading market. If any of these transactions are commenced, they may be discontinued without notice at any time.

Notice to Prospective Investors in Hong Kong

The contents of this prospectus have not been reviewed by any regulatory authority in Hong Kong. You are advised to exercise caution in relation to the offer. If you are in any doubt about any of the contents of this prospectus, you should obtain independent professional advice. Please note that (i) our shares may not be offered or sold in Hong Kong, by means of this prospectus or any document other than to “professional investors” within the meaning of Part I of Schedule 1 of the SFO and any rules made thereunder, or in other circumstances which do not result in the document being a “prospectus” within the meaning of the Companies (Winding Up and Miscellaneous Provisions) Ordinance (Cap.32, Laws of Hong Kong) (“CO”) or which do not constitute an offer or invitation to the public for the purpose of the CO or the SFO; and (ii) no advertisement, invitation, or document relating to our shares may be issued or may be in the possession of any person for the purpose of issue (in each case whether in Hong Kong or elsewhere), which is directed at, or the contents of which are likely to be accessed or read by, the public in Hong Kong (except if permitted to do so under the securities laws of Hong Kong) other than with respect to the shares that are or are intended to be disposed of only to persons outside Hong Kong or only to “professional investors” within the meaning of the SFO and any rules made thereunder.

Notice to Prospective Investors in the PRC

This prospectus may not be circulated or distributed in the PRC and the shares may not be offered or sold, and will not be offered or sold, to any person or re-offered or resold directly or indirectly to any resident of the PRC, except pursuant to applicable laws, rules, and regulations of the PRC. For the purpose of this paragraph only, the PRC does not include Taiwan and the Special Administrative Regions of Hong Kong and Macau.

Notice to Prospective Investors in Taiwan

The Ordinary Shares have not been and will not be registered with the Financial Supervisory Commission of Taiwan, pursuant to relevant securities laws and regulations, and may not be offered or sold in Taiwan through a public offering or in any manner that would constitute an offer within the meaning of the Securities and Exchange Act of Taiwan or would otherwise require registration with or the approval of the Financial Supervisory Commission of Taiwan.

Notice to Prospective Investors in the Cayman Islands

The shares are not being, and may not be offered to, the public or to any person in the Cayman Islands for purchase or subscription by us or on our behalf. The shares may be offered to exempted companies incorporated under the Companies Act (as revised) (as amended), but only where the offer will be made to, and received by, the relevant Cayman Islands company entirely outside of the Cayman Islands.

131

Table of Contents

EXPENSES RELATED TO THIS OFFERING

Set forth below is an itemization of the total expenses, excluding the underwriting discounts and commissions and non-accountable expense allowance, that are expected to be incurred in connection with the sale of Ordinary Shares in this offering. With the exception of the registration fee payable to the SEC, the Nasdaq Capital Market listing fee, and the filing fee payable to FINRA, all amounts are estimates.

SEC registration fee

 

$

882

The Nasdaq Capital Market listing fee

 

$

50,000

FINRA filing fee

 

$

2,750

Printing and engraving expenses

 

$

34,649

Legal fees and expenses

 

$

712,400

Accounting fees and expenses

 

$

1,047,875

Miscellaneous expenses

 

$

52,085

Total

 

$

1,900,641

____________

*        To be completed by amendment.

132

Table of Contents

LEGAL MATTERS

We are being represented by K&L Gates LLP with respect to certain legal matters of U.S. federal securities. We may rely upon CFN Lawyers with respect to matters governed by Hong Kong law. The validity of our Ordinary Shares and certain other matters of Cayman Islands law will be passed upon for us by Appleby. The underwriters are being represented by The Crone Law Group P.C. in connection with this offering.

EXPERTS

The consolidated financial statements as of and for the years ended March 31, 2023 and 2022, included in this prospectus have been so included in reliance on the report of ZH CPA, LLC, an independent registered public accounting firm, given on the authority of said firm as experts in auditing and accounting. The registered business address of ZH CPA, LLC is 1600 Broadway, Suite 1600, Denver, Colorado, 80202 USA.

133

Table of Contents

ENFORCEABILITY OF CIVIL LIABILITIES

We are incorporated under the laws of the Cayman Islands as an exempted company with limited liability. We are incorporated in the Cayman Islands because of certain benefits associated with being a Cayman Islands exempted company, such as political and economic stability, an effective judicial system, a favorable tax system, the absence of foreign exchange control or currency restrictions, and the availability of professional and support services. However, the Cayman Islands has a less developed body of securities laws as compared to the United States and provides less protection for investors. In addition, Cayman Islands companies do not have standing to sue before the federal courts of the United States.

Substantially all of our assets are located outside the United States. In addition, most of our directors and executive officers are nationals or residents of jurisdictions other than the United States and substantially all of their assets are located outside the United States. As a result, it may be difficult or impossible for you to effect service of process within the United States upon us or these persons, or to enforce judgments obtained in U.S. courts against us or them, including judgments predicated upon the civil liability provisions of the securities laws of the United States, or any state in the United States. It may also be difficult for you to enforce judgments obtained in U.S. courts based on the civil liability provisions of the U.S. federal securities laws against us and our executive officers and directors.

We have appointed Cogency Global Inc. as our agent to receive service of process with respect to any action brought against us in the United States in connection with this offering under the federal securities laws of the United States or of any state in the United States.

Enforceability

Appleby, our counsel as to the laws of the Cayman Islands has advised us that there is uncertainty as to whether the courts of the Cayman Islands would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in the Cayman Islands against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States.

Appleby has informed us that any final and conclusive judgment for a definite sum (not being a sum payable in respect of taxes or other charges of a like nature nor a fine or other penalty) and/or certain non-monetary judgments rendered in any action or proceedings brought against our Company in a foreign court (other than certain judgments of a superior court of certain states of the Commonwealth of Australia) will be recognized as a valid judgment by the courts of the Cayman Islands without re-examination of the merits of the case. On general principles, we would expect such proceedings to be successful provided that the court which gave the judgment was competent to hear the action in accordance with private international law principles as applied in the Cayman Islands and the judgment is not contrary to public policy in the Cayman Islands, has not been obtained by fraud or in proceedings contrary to natural justice.

Substantially all of our assets are located outside the United States. In addition, a majority of our directors and officers are nationals or residents of jurisdictions other than the United States and all or a substantial portion of their assets are located outside the United States. As a result, it may be difficult for investors to effect service of process within the United States upon us or these persons.

Name

 

Position

 

Nationality

 

Residence

Mr. Keung Yun Yuen

 

Chairman of the board

 

Chinese

 

Hong Kong

Mr. Chan Lee Chuen

 

Director and Chief Executive Officer

 

Chinese

 

Hong Kong

Ms. Choi Hiu Ying

 

Chief Financial Officer

 

Chinese

 

Hong Kong

Mr. Thirupathi Nachiappan

 

Independent Director Appointee

 

Indian

 

Hong Kong

Mr. Wong Heung Ming

 

Independent Director Appointee

 

Chinese

 

Hong Kong

Dr. Liu Yuk Shing

 

Independent Director Appointee

 

Chinese

 

Hong Kong

Mr. Ng Wai Leung

 

Quality Surveyor Manager

 

Chinese

 

Hong Kong

134

Table of Contents

Hong Kong

CFN Lawyers, our counsel as to the laws of Hong Kong, has advised us that there is uncertainty as to whether the courts of Hong Kong would (i) recognize or enforce judgments of U.S. courts obtained against us or our directors or officers predicated upon the civil liability provisions of the securities laws of the United States or any state in the United States, or (ii) entertain original actions brought in Hong Kong against us or our directors or officers predicated upon the securities laws of the United States or any state in the United States.

A judgment of a court in the United States predicated upon U.S. federal or state securities laws may be enforced in Hong Kong at common law by bringing an action in a Hong Kong court on that judgment for the amount due thereunder and then seeking summary judgment on the strength of the foreign judgment, provided that the foreign judgment, among other things, is (1) for a debt or a definite sum of money (not being taxes or similar charges to a foreign government taxing authority or a fine or other penalty), and (2) final and conclusive on the merits of the claim, but not otherwise. Such a judgment may not, in any event, be so enforced in Hong Kong if (a) it was obtained by fraud, (b) the proceedings in which the judgment was obtained were opposed to natural justice, (c) its enforcement or recognition would be contrary to the public policy of Hong Kong, (d) the court of the United States was not jurisdictionally competent, or (e) the judgment was in conflict with a prior Hong Kong judgment.

Hong Kong has no arrangement for the reciprocal enforcement of judgments with the United States. As a result, there is uncertainty as to the enforceability in Hong Kong, in original actions or in actions for enforcement, of judgments of U.S. courts of civil liabilities predicated solely upon the federal securities laws of the United States or the securities laws of any state or territory within the United States.

135

Table of Contents

WHERE YOU CAN FIND ADDITIONAL INFORMATION

We have filed with the SEC a registration statement (including amendments and exhibits to the registration statement) on Form F-1 under the Securities Act. This prospectus, which forms a part of the registration statement, does not contain all of the information included in the registration statement and the exhibits and schedules to the registration statement. Certain information is omitted, and you should refer to the registration statement and its exhibits and schedules for that information. If a document has been filed as an exhibit to the registration statement, we refer you to the copy of the document that has been filed. Each statement in this prospectus relating to a document filed as an exhibit is qualified in all respects by the filed exhibit.

You may review a copy of the registration statement, including exhibits and any schedule filed therewith, and obtain copies of such materials at the SEC’s Public Reference Room at 100 F Street, N.E., Washington, D.C. 20549. You may obtain information on the operation of the Public Reference Room by calling the SEC at 1-800-SEC-0330. The SEC maintains a website at http://www.sec.gov that contains reports, proxy and information statements, and other information regarding issuers, like us, which file electronically with the SEC.

Upon completion of this offering, we will be subject to the information reporting requirements of the Exchange Act applicable to foreign private issuers. Accordingly, we will be required to file reports and other information with the SEC, including annual reports on Form 20-F and reports on Form 6-K. Those reports may be inspected without charge at the locations described above. As a foreign private issuer, we will be exempt from the rules under the Exchange Act related to the furnishing and content of proxy statements, and our officers, directors, and principal shareholders will be exempt from the reporting and short-swing profit recovery provisions contained in Section 16 of the Exchange Act. In addition, we will not be required under the Exchange Act to file periodic reports and financial statements with the SEC as frequently or as promptly as U.S. companies whose securities are registered under the Exchange Act.

We maintain a website at www.chikock.com.hk. Information contained on, or that can be accessed through, our website is not a part of, and shall not be incorporated by reference into, this prospectus.

136

Table of Contents

F-1

Table of Contents

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Shareholders and Board of Directors of
Chi Ko Holdings Limited

Opinion on the Consolidated Financial Statements

We have audited the accompanying balance sheets of Chi Ko Holdings Limited and its subsidiaries (the “Company”) as of March 31, 2023 and 2022, and the related consolidated statements of operations and comprehensive income, changes in shareholders’ equity, and cash flows for each of the years in the two-year period ended March 31, 2023, and the related notes (collectively referred to as the consolidated financial statements). In our opinion, the consolidated financial statements present fairly, in all material respects, the financial position of the Company as of March 31, 2023 and 2022, and the results of its operations and its cash flows for each of the years in the two-year period ended March 31,2023, in conformity with accounting principles generally accepted in the United States of America.

Basis for Opinion

These consolidated financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on the Company’s consolidated financial statements based on our audits. We are a public accounting firm registered with the PCAOB and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audits in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the consolidated financial statements are free of material misstatement, whether due to error or fraud. The Company is not required to have, nor were we engaged to perform, an audit of its internal control over financial reporting. As part of our audits, we are required to obtain an understanding of internal control over financial reporting, but not for the purpose of expressing an opinion on the effectiveness of the Company’s internal control over financial reporting. Accordingly, we express no such opinion.

Our audits included performing procedures to assess the risks of material misstatement of the consolidated financial statements, whether due to error or fraud, and performing procedures that respond to those risks. Such procedures included examining, on a test basis, evidence regarding the amounts and disclosures in the consolidated financial statements. Our audits also included evaluating the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the consolidated financial statements. We believe that our audits provide a reasonable basis for our opinion.

/s/ ZH CPA, LLC

We have served as the Company’s auditor since 2022.

Denver, Colorado

September 21, 2023

F-2

Table of Contents

CHI KO HOLDINGS LIMITED
CONSOLIDATED BALANCE SHEETS

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Assets

       

Current assets:

       

Cash and cash equivalents

 

1,933,486

 

4,502,737

Restricted cash

 

256,410

 

Accounts receivable, net

 

14,560,585

 

11,434,111

Contract assets, net

 

1,543,500

 

5,391,789

Deferred costs

 

380,216

 

1,049,914

Prepayment, deposits and other receivable – current

 

204,868

 

854,142

Total current assets

 

18,879,065

 

23,232,693

         

Property, plant and equipment, net

 

132,078

 

117,548

Right-of-use assets – Finance lease

 

318,975

 

386,016

Right-of-use assets – Operating lease

 

104,669

 

67,975

Contract assets – non-current, net

 

6,469,905

 

6,849,271

Prepayment and deposits – non-current

 

842,391

 

911,827

Investment in life insurance policy, cash surrender value

 

657,992

 

1,803,987

Deferred tax assets

 

84,325

 

307,709

Total non-current assets

 

8,610,335

 

10,444,333

TOTAL ASSETS

 

27,489,400

 

33,677,026

         

Liabilities

       

Current liabilities:

       

Bank loans – current

 

1,408,939

 

1,995,043

Finance lease liabilities – current

 

85,483

 

125,111

Operating lease liabilities – current

 

86,386

 

62,986

Accounts payable, accruals, and other current liabilities

 

15,128,533

 

20,423,601

Contract liabilities

 

1,471,271

 

Dividend payable

 

166,113

 

1,745,250

Income taxes payable

 

102,440

 

95,032

Total current liabilities

 

18,449,165

 

24,447,023

         

Non-current liabilities

       

Bank loans – non-current

 

1,791,062

 

2,266,336

Finance lease liabilities – non-current

 

188,999

 

142,029

Operating lease liabilities – non-current

 

18,651

 

3,925

Total non-current liabilities

 

1,998,712

 

2,412,290

TOTAL LIABILITIES

 

20,447,877

 

26,859,313

         

Commitments and contingencies

 

 

         

Shareholders’ equity

       

Ordinary shares USD0.0001 par value; 500,000,000 shares authorized; 11,250,000 and 11,250,000 shares issued and outstanding

 

1,125

 

1,125

Additional paid in capital

 

256,410

 

256,410

Retained earnings

 

6,783,988

 

6,560,178

Total shareholders’ equity

 

7,041,523

 

6,817,713

TOTAL LIABILITIES AND SHAREHOLDERS’ EQUITY

 

27,489,400

 

33,677,026

The accompanying notes are an integral part of these consolidated financial statements.

F-3

Table of Contents

CHI KO HOLDINGS LIMITED
CONSOLIDATED STATEMENTS OF OPERATIONS AND COMPREHENSIVE INCOME

 

For the year ended
March 31,

   

2022

 

2023

   

USD

 

USD

Revenues

 

60,724,303

 

 

77,852,447

 

Cost of sales

 

(54,774,465

)

 

(71,740,688

)

Gross profit

 

5,949,838

 

 

6,111,759

 

     

 

   

 

Operating expenses:

   

 

   

 

General and administrative expenses

 

(1,340,311

)

 

(2,717,523

)

Total operating expenses

 

(1,340,311

)

 

(2,717,523

)

     

 

   

 

Income from operations

 

4,609,527

 

 

3,394,236

 

     

 

   

 

Other income (expense)

 

(13,546

)

 

173,548

 

Interest expense

 

(108,829

)

 

(183,806

)

Total other expense, net

 

(122,375

)

 

(10,258

)

Income before tax expense

 

4,487,152

 

 

3,383,978

 

Income tax expense

 

(717,724

)

 

(530,865

)

Net income

 

3,769,428

 

 

2,853,113

 

     

 

   

 

Other comprehensive income

 

 

 

 

Total comprehensive income

 

3,769,428

 

 

2,853,113

 

     

 

   

 

Net earnings per share attributable to ordinary shareholders

   

 

   

 

Basic and diluted

 

0.34

 

 

0.25

 

Weighted average number of ordinary shares used in computing net income per share

   

 

   

 

Basic and diluted

 

11,250,000

 

 

11,250,000

 

The accompanying notes are an integral part of these consolidated financial statements.

F-4

Table of Contents

CHI KO HOLDINGS LIMITED
CONSOLIDATED STATEMENTS OF CHANGES IN SHAREHOLDERS’ EQUITY

 

Ordinary shares

 

Additional
Paid-in
Capital

 

Retained
Earnings

 

Total Stockholders’
Equity

   

Number of
Shares

 

Amount

 
       

USD

 

USD

 

USD

 

USD

Balance as of April 1, 2021

 

11,250,000

 

1,125

 

256,410

 

4,553,022

 

 

4,810,557

 

Dividend declared

 

 

 

 

(1,538,462

)

 

(1,538,462

)

Net income

 

 

 

 

3,769,428

 

 

3,769,428

 

Balance as of March 31, 2022

 

11,250,000

 

1,125

 

256,410

 

6,783,988

 

 

7,041,523

 

Dividend declared

 

 

 

 

(3,076,923

)

 

(3,076,923

)

Net income

 

 

 

 

2,853,113

 

 

2,853,113

 

Balance as of March 31, 2023

 

11,250,000

 

1,125

 

256,410

 

6,560,178

 

 

6,817,713

 

The accompanying notes are an integral part of these consolidated financial statements.

F-5

Table of Contents

CHI KO HOLDINGS LIMITED
CONSOLIDATED STATEMENTS OF CASH FLOWS

 

For the year ended
March 31,

   

2022

 

2023

   

USD

 

USD

Operating activities

   

 

   

 

Net income

 

3,769,428

 

 

2,853,113

 

Non-cash item adjustments:

   

 

   

 

Change in surrender value of investment in life insurance policy

 

105,727

 

 

179,320

 

Interest income and premium charge of life insurance policy

 

30,440

 

 

34,365

 

Non-cash operating lease expense

 

116,215

 

 

118,537

 

Depreciation of right-of-use assets – finance lease

 

41,112

 

 

65,780

 

Depreciation of property, plant and equipment

 

15,358

 

 

42,735

 

Credit loss

 

596,192

 

 

1,565,198

 

Deferred tax recovery

 

(69,298

)

 

(223,384

)

Change in operating assets and liabilities:

   

 

   

 

Change in accounts receivable

 

(10,241,687

)

 

2,052,832

 

Change in prepayment, deposits and other receivable

 

(357,855

)

 

(718,710

)

Change in due from a director

 

15,603

 

 

 

Change in accounts payable, accruals, and other current liabilities

 

9,477,038

 

 

5,295,068

 

Change in contract liabilities

 

1,102,972

 

 

(1,471,271

)

Change in income tax payable

 

(214,338

)

 

(7,408

)

Change in contract assets, net

 

(3,610,975

)

 

(4,719,211

)

Change in lease liabilities – operating lease

 

(114,671

)

 

(119,969

)

Cash provided by operating activities

 

661,261

 

 

4,946,995

 

     

 

   

 

Investing activities

   

 

   

 

Purchase of property, plant and equipment

 

(147,436

)

 

(28,205

)

Purchase of life insurance policy

 

(794,159

)

 

(1,359,680

)

Cash used in investing activities

 

(941,595

)

 

(1,387,885

)

     

 

   

 

Financing activities

   

 

   

 

Advance to related party

 

(1,372,348

)

 

(1,497,786

)

Proceeds from new bank loans

 

2,881,008

 

 

3,781,831

 

Repayment of bank loans

 

(930,873

)

 

(2,720,453

)

Initial payment of finance lease

 

(51,282

)

 

(26,565

)

Principal payment of finance lease liabilities

 

(32,767

)

 

(113,598

)

Payment of offering costs

 

(380,216

)

 

(669,698

)

Cash provided by/(used in) financing activities

 

113,522

 

 

(1,246,269

)

Net change in cash and cash equivalents and restricted cash

 

(166,812

)

 

2,312,841

 

Cash and cash equivalents and restricted cash as of beginning of the year

 

2,356,708

 

 

2,189,896

 

Cash and cash equivalents and restricted cash as of the end of the year

 

2,189,896

 

 

4,502,737

 

     

 

   

 

Supplementary Cash Flows Information

   

 

   

 

Cash paid for interest

 

(103,891

)

 

(169,528

)

Cash paid for income tax

 

(1,001,360

)

 

(761,657

)

Dividend declared but not paid

 

166,113

 

 

1,745,250

 

Dividend declared and offset against due from related party

 

1,372,349

 

 

1,331,673

 

Right-of-use assets obtained in exchange for new operating lease liabilities

 

135,838

 

 

113,002

 

Right-of-use assets obtained in exchange for new finance lease liabilities

 

256,410

 

 

132,821

 

The accompanying notes are an integral part of these consolidated financial statements.

F-6

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

1.      ORGANIZATION AND PRINCIPAL ACTIVITIES

Chi Ko Holdings Limited (the “Company”) was incorporated in the Cayman Islands on March 29, 2022 under the Companies Act as an exempted company with limited liability. The Company conducts its primary operations of construction works services in Hong Kong through its indirectly held wholly owned subsidiaries that are incorporated and domiciled in Hong Kong, namely Chiu & Lee Partners Construction Company Limited. The Company holds Chiu & Lee Partners Construction Company Limited (“Chiu & Lee Partners”) via a wholly owned subsidiary, namely Orange Space Limited (“Orange Space”) which was incorporated and is domiciled in the British Virgin Islands.

Details of the Company and its subsidiaries are set out in the table as follows:

Name

 

Date of
incorporation

 

Percentage of
effective
ownership

 

Place of
incorporation

 

Principal activities

2022

 

2023

 

Chi Ko Holdings Limited

 

March 29, 2022

 

Parent

 

Parent

 

Cayman Islands

 

Investment holdings

Orange Space Limited

 

February 22, 2022

 

100%

 

100%

 

The British Virgin Islands

 

Investment holdings

Chiu & Lee Partners Construction Company Limited

 

June 19, 1981

 

100%

 

100%

 

Hong Kong

 

Provision of construction works services

Reorganization

Pursuant to the Company’s reorganization (“Reorganization”) that took place on April 13, 2022 (“Closing Date”), the former shareholders of Chiu & Lee Partners, namely Keung, Yun Yuen transferred all the shares of, inter alia, Chiu & Lee Partners to Orange Space in consideration of Orange Space allotting and issuing 99 shares to the Company credited as fully paid.

Following such share exchanges, Orange Space and Chiu & Lee Partners became the Company’s wholly-owned subsidiaries, whereas Fly Cloud Limited became the controlling shareholders of the Company holding 100% of the issued share capital of the Company respectively.

The combination has been treated as a corporate restructuring (reorganization) of entities under common control and thus the current capital structure has been retroactively presented in prior periods as if such structure existed at that time and in accordance with ASC 805-50-45-5, the entities under common control are presented on a combined basis for all periods to which such entities were under common control. Since all of the subsidiaries were under common control for the entirety of the years ended March 31, 2023 and 2022, the results of these subsidiaries are included in the financial statements for both periods. (“Reorganization”). After the Restructuring, the Company has 11,250,000 ordinary shares issued and outstanding.

The discussion and presentation of financial statements herein assumes the completion of the Restructuring, which is accounted for retroactively as if it occurred on April 1, 2021, and the equity has been retroactively adjusted to reflect the change as well.

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Basis of presentation

The consolidated financial statements include all accounts of the Company and its wholly owned subsidiaries (Collectively, the “Company”) and have been prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”).

F-7

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Consolidation

The consolidated financial statements include the financial statements of the Company and its subsidiaries. All inter-company transactions and balances between the Company and its subsidiaries have been eliminated upon consolidation.

Measurement of credit losses on financial instruments

On April 1, 2019, the Company adopted ASU 2016-13, “Financial Instruments — Credit Losses (Topic 326) — Measurement of Credit Losses on Financial Instruments,” for financial assets stated at amortized cost including accounts receivable, refundable deposits, bonds and other receivables, retention receivables and contract assets. The Company assessed that the impact of adoption of ASU 2016-13 was $nil. This guidance replaced the “incurred loss” impairment methodology with an approach based on “expected losses” to estimate credit losses on certain types of financial instruments and requires consideration of a broader range of reasonable and supportable information to inform credit loss estimates. The guidance requires financial assets to be presented at the net amount expected to be collected. The allowance for credit losses is a valuation account that is deducted from the cost of the financial asset to present the net carrying value at the amount expected to be collected on the financial asset.

Use of estimates

The preparation of consolidated financial statements in accordance with U.S. GAAP requires management to make estimates and assumptions that affect the amounts reported and disclosed in the consolidated financial statements and accompanying notes. Actual amounts could differ from these estimates and differences could be material. Changes in estimates are recorded in the period they are identified.

Judgments, estimates and underlying assumptions are evaluated on an ongoing basis by management and are based on historical experience and other factors including expectations of future events that are believed to be reasonable under the circumstances. However, existing circumstances and assumptions about future developments may change due to market changes or circumstances and such changes are reflected in the assumptions when they occur.

Significant estimates required to be made by management include, but are not limited to, allowance of expected credit losses. Actual results could differ from those estimates.

The measurement of the expected credit loss allowance for financial assets measured at amortized cost is an area that requires the use of significant assumptions about future economic conditions and credit behavior (e.g. the likelihood of customers defaulting and the resulting losses). A number of significant judgements are also required in applying the accounting requirements for measuring expected credit loss, such as:

        Assessing relevant historical and forward-looking quantitative and qualitative information;

        Choosing appropriate models and assumptions for the measurement of expected credit loss.

Risks and uncertainties

The main operations of the Company are located in Hong Kong. Accordingly, the Company’s business, financial condition, and results of operations may be influenced by political, economic, and legal environments in Hong Kong, as well as by the general state of the economy in Hong Kong. The Company’s results may be adversely affected by changes in the political, regulatory and social conditions in Hong Kong. Although the Company has not experienced losses from these situations and believes that it is in compliance with existing laws and regulations including its organization and structure disclosed in Note 1, such experience may not be indicative of future results.

The Company’s business, financial condition and results of operations may also be negatively impacted by risks related to natural disasters, extreme weather conditions, health epidemics and other catastrophic incidents, which could significantly disrupt the Company’s operations.

F-8

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Concentration risks

Significant customers and suppliers are those that account for greater than 10% if the Company’s revenue and purchase, respectively.

During the years ended March 31, 2023 and 2022, there were five and five customers generated income which accounted for over 10% of the total revenue generated for that year, respectively. The details are as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Customer A

 

10.8

%

 

24.0

%

Customer B

 

10.1

%

 

19.2

%

Customer C

 

6.0

%

 

16.9

%

Customer D

 

37.5

%

 

12.3

%

Customer E

 

13.9

%

 

11.1

%

Customer F

 

12.8

%

 

3.0

%*

As of March 31, 2023 and 2022, accounts receivable due from these customers as a percentage of consolidated accounts receivable are as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Customer A

 

2.8

%

 

9.7

%

Customer B

 

14.4

%

 

21.7

%

Customer C

 

0.6

%

 

12.2

%

Customer D

 

45.3

%

 

35.6

%

Customer E

 

19.3

%

 

3.8

%

Customer F

 

9.3

%

 

3.3

%

During the years ended March 31, 2023 and 2022, there were two suppliers accounted for over 10% of the total subcontracting fees, cost of materials and tools for that year. The details are as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Supplier A

 

42.7

%

 

16.9

%

Supplier B

 

15.1

%

 

3.3

%

Supplier C

 

4.2

%

 

16.3

%

As of March 31, 2023 and 2022, accounts payable due to these suppliers as a percentage of consolidated accounts payable are as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Supplier A

 

31.1

%

 

12.0

%

Supplier B

 

23.7

%

 

13.1

%

Supplier C

 

4.1

%

 

15.4

%

F-9

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Foreign currency translation and transaction and Convenience translation

The Company’s reporting currency is the USD. The Company’s operations are principally conducted in Hong Kong where Hong Kong dollar is the functional currency.

Transactions denominated in other than the functional currencies are re-measured into the functional currency of the entity at the exchange rates prevailing on the transaction dates. Monetary assets and liabilities denominated in currencies other than the applicable functional currencies are translated into the functional currency at the prevailing rates of exchange at the balance date. The resulting exchange differences are reported in the statements of operations and comprehensive income.

The exchanges rates used for translation from Hong Kong dollar to USD was 7.8000, a pegged rate determined by the linked exchange rate system in Hong Kong. This pegged rate was used to translate Company’s balance sheets, income statement items and cash flow items for both 2023 and 2022.

Certain Risks and Concentration

Following the Outbreak of COVID-19 (the “Outbreak”), a series of precautionary and control measures have been and will continue to be implemented in Hong Kong. The directors of the Company will keep continuous attention on monitoring the development of the Outbreak. Based on the currently available information, the directors of the Company consider that the Outbreak would not have a material financial impact on the Company’s overall operation and sales performance.

As an infectious disease, the Outbreak was first reported in late December 2019 and has since spread to various countries all over the world. On 11 March 2020, the World Health Organization announced that COVID-19 be characterized as a pandemic based on its assessment and the governments of different countries have taken drastic measures to curb the spread of the Epidemic. The Epidemic has not only endangered the health of citizens but has also disrupted the business operations of various enterprises. While the Company’s business operations are primarily based in Hong Kong and the Company’s customers are located in Hong Kong, there was no significant impact on the Company’s business in 2022 and 2023 given that all of the construction sites remained open with normal working hours since the Outbreak.

Credit Risk

Credit risk is the potential financial loss to the Company resulting from the failure of a customer or a counterparty to settle its financial and contractual obligations to the Company, as and when they fall due. As the Company does not hold any collateral, the maximum exposure to credit risk is the carrying amounts of trade and other receivables (exclude prepayments), contract assets, investment in life insurance policy, retention receivables and cash and bank deposits presented on the consolidated statements of financial position. The Company has no other financial assets which carry significant exposure to credit risk.

Interest Rate Risk

The Company is exposed to interest rate risk primarily relates to the variable-rate bank loans and is mainly concentrated on the fluctuation of Hong Kong Prime Rate arising from the Company’s bank loans. The Company has not used any derivative instruments to mitigate its exposure associated with interest rate risk.

Labor Price Risk

Our business requires a substantial number of personnel. Any failure to retain stable and dedicated labor by us may lead to disruption to our business operations. Although we have not experienced any labor shortage to date, we have observed an overall tightening and increasingly competitive labor market. We have experienced, and expect to continue to experience, increases in labor costs due to increases in salary, social benefits and employee headcount. We compete with other companies in our industry and other labor-intensive industries for labor, and we may not be able to offer competitive remuneration and benefits compared to them. If we are unable to manage and control our labor costs, our business, financial condition and results of operations may be materially and adversely affected.

F-10

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Liquidity Risk

Liquidity risk is the risk that the Company will encounter difficulty in meeting the obligations associated with its financial liabilities that are settled by delivering cash or another financial asset. The Company’s approach to managing liquidity is to ensure, as far as possible, that it will always have sufficient liquidity to meet its liabilities when due, under both normal and stressed conditions, without incurring unacceptable losses or risking damage to the Company’s reputation.

Typically, the Company ensures that it has sufficient cash on demand to meet expected operational expenses for a period of 60 days, including the servicing of financial obligations; this excludes the potential impact of extreme circumstances that cannot reasonably be predicted, such as natural disasters.

Fair Value Measurement

Accounting guidance defines fair value as the price that would be received from selling an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. When determining the fair value measurements for assets and liabilities required or permitted to be recorded at fair value, the Company considers the principal or most advantageous market in which it would transact, and it considers assumptions that market participants would use when pricing the asset or liability.

Accounting guidance establishes a fair value hierarchy that requires an entity to maximize the use of observable inputs and minimize the use of unobservable inputs when measuring fair value. A financial instrument’s categorization within the fair value hierarchy is based upon the lowest level of input that is significant to the fair value measurement. Accounting guidance establishes three levels of inputs that may be used to measure fair value:

        Level 1: Quoted prices in active markets for identical assets or liabilities.

        Level 2: Observable, market-based inputs, other than quoted prices, in active markets for identical asset or.

        Level 3: Unobservable inputs to the valuation methodology that are significant to the measurement of the fair value of the assets or liabilities.

The Company’s financial instrument include cash and cash equivalents, restricted cash, accounts receivable, deposit and other receivable, investment in life insurance policy, accounts payables and accruals, bank loans, lease liabilities, dividends payable and due from a director. The carrying amounts of these financial instruments approximate their fair values due to the short-term nature of these instruments. For lease liabilities, fair value approximates their carrying value at the year end as the interest rates used to discount the host contracts approximate market rates. The carrying amount of the long-term bank loan approximates its fair value due to the fact that the related interest rate approximates the interest rates currently offered by financial institutions for similar debt instruments of comparable maturities.

The Company noted no transfers between levels during any of the periods presented. The Company did not have any instruments that were measured at fair value on a recurring nor non-recurring basis as of March 31, 2023 and 2022.

Related Parties

The Company adopted ASC 850, Related Party Disclosures, for the identification of related parties and disclosure of related party transactions.

Cash and Cash Equivalents

Cash and cash equivalents consist of petty cash on hand and cash held in banks, which are highly liquid and have original maturities of three months or less and are unrestricted as to withdrawal or use. The Company maintains all bank accounts in Hong Kong. Cash balances in bank accounts in Hong Kong are protected under Deposit Protection Scheme in accordance with the Deposit Protection Scheme Ordinance. The maximum protection is up to HKD500,000 per depositor per Scheme member, including both principal and interest.

F-11

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Restricted Cash

Restricted cash represent cash deposits pledged to a bank to secure banking facilities granted to a wholly-owned subsidiary of the Company for bank loans amounted to USD3,200,001 with interest bearing ranging from 2.3% per annum to 5% per annum as at March 31, 2022. There were no restricted cash pledged for bank loan as at March 31, 2023.

Accounts Receivable Net

Accounts receivable represent an unconditional right to consideration arising from our performance under contracts with customers which include retainage amount that is conditional only on the passage of time. The Company grant credit to customers, without collateral, under normal payment terms (typically 30 to 60 days after invoicing). Generally, invoicing occurs within 45 days after the related works are performed. The carrying value of such receivable, net of the expected credit loss and allowance for doubtful accounts, represents its estimated realizable value. The Company expect to collect the outstanding balance of current accounts receivable, net within the next 12 months. The Company has elected to use probability of default and loss given default methods to estimate allowance for credit loss.

For those past due balances over 1 year and other higher risk receivables identified by management are reviewed individually for collectability. In establishing an allowance for credit losses, the Company uses reasonable and supportable information, which is based on historical collection experience, the financial condition of its customers, billing disputes and assumptions for the future movement of different economic drivers and how these drivers will affect each other. Probability of default constitutes a key input in measuring allowance for credit losses. Probability of default is an estimate of the likelihood of default over a given time horizon, the calculation of which includes historical data, assumptions and expectations of future conditions. The Company writes off potentially uncollectible accounts receivable against the allowance for credit losses if it is determined that the amounts will not be collected or if a settlement with respect to a disputed receivable is reached for an amount that is less than the carrying value.

Contract Assets and Contract Liabilities

Contract assets, excluding any amounts presented as receivable, included two parts: revenue recognized in excess of amounts billed, and retainage. Certain of our contracts contain retention provisions whereby a portion of the revenue earned is withheld from payment as a form of security until contractual provisions are satisfied. Contract assets were assessed for impairment in accordance with ASC 326.

Contract liabilities consist of payment received from customers in excess of revenue recognized.

Contract assets and liabilities are reported in a net position on a contract-by-contract basis at the end of each reporting period.

Deferred Offering Costs

Deferred offering costs consist principally of all direct offering costs incurred by the Company, such as underwriting, legal, accounting, consulting, printing, and other registration related costs in connection with the initial public Offering (“IPO”) of the Company’s ordinary shares. Such costs are deferred until the closing of the offering, at which time the deferred costs are offset against the offering proceeds. In the event the offering is unsuccessful or aborted, the costs will be expensed.

Property, plant and equipment

Property, plant and equipment is carried at historical cost less accumulated depreciation and impairment charge. Historical cost includes expenditure that is directly attributable to the acquisition of the items.

Major modifications or refurbishments which extend the useful life of the assets are capitalized and depreciated over the adjusted remaining useful life of the assets.

F-12

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Property, plant and equipment is calculated using the straight-line method to allocate their cost to their residual values over their estimated useful lives, as follows:

 

Useful lives

 

Residual values

Machinery

 

4 years

 

Motor vehicle

 

4 years

 

The assets’ residual values and useful lives are reviewed, and adjusted if appropriate, at the end of each reporting period.

Upon retirements or disposition of property, plant and equipment, the cost and related accumulated depreciation are removed any resulting gain or loss is recognized in consolidated statements of operations and comprehensive income. The cost of maintenance and repairs is charged to expenses as incurred.

Impairment of long lived assets

The Company reviews its long-lived assets for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may no longer be recoverable. When these events occur, the Company measures impairment by comparing the carrying value of the long-lived assets to the estimated undiscounted future cash flows expected to result from the use of the assets and their eventual disposition. If the sum of the expected undiscounted cash flow is less than the carrying amount of the assets, the Company would recognize an impairment loss, which is the excess of carrying amount over the fair value of the assets, using the expected future discounted cash flows. No impairment of long-lived assets was recognized as of March 31, 2023 and 2022.

Commitments and contingencies

In the normal course of business, the Company is subject to commitments and contingencies, including operating lease commitments, legal proceedings and claims arising out of its business that relate to a wide range of matters, such as government investigations and tax matters. The Company recognizes a liability for such contingency if it determines it is probable that a loss will occur, and a reasonable estimate of the loss can be made. The Company may consider many factors in making these assessments on liability for contingencies, including historical and the specific facts and circumstances of each matter.

Revenue recognition

In May 2014, the FASB issued Topic 606, “Revenue from Contracts with Customers”. This topic clarifies the principles for recognizing revenue and develops a common revenue standard for U.S. GAAP. Simultaneously, this topic supersedes the revenue recognition requirements in Topic 605, Revenue Recognition, and most industry-specific guidance throughout the Industry Topics of the Codification.

The Company perform a majority of services including foundation, site formation, general building work and demolition under master and subcontracting construction agreements and other contracts that contain customer-specified construction requirements. These agreements include discrete pricing for individual tasks. A contractual agreement exists when each party involved approves and commits to the agreement, the rights of the parties and payment terms are identified, the agreement has commercial substance, and collectability of consideration is probable. Construction services are performed for the sole benefit of our customers, whereby the assets being created or maintained are controlled by the customer and the services we perform do not have alternative benefits for us. Contract revenue is recognized as our obligations are satisfied over time consistent with our services are performed and customers simultaneously receive and consume the benefits the Company provide.

F-13

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

The Company recognizes contract revenue over time, as performance obligations are satisfied, due to the continuous transfer of control to the customer in accordance with ASC Topic 606, Revenue from Contracts with Customers. Upon adoption of ASC Topic 606, contracts which include construction services are generally accounted for as a single deliverable (a single performance obligation) and are no longer segmented between types of services. The Company has not bundled any goods or services that are not considered distinct.

Output measures such as construction works delivered are utilized to assess progress against specific contractual performance obligations for the majority of services. The selection of the method to measure progress towards completion requires judgment and is based on the nature of the services to be provided. The Company expects the reference to progress certificates issued by customers depicts the Company’s performance in transferring control of goods or services promised to customers for individual projects, the Company satisfies the performance obligation over time and therefore, the output method using construction works delivered best represents the measure of progress against the performance obligations incorporated within the contractual agreements. This method captures the amount of works delivered pursuant to contracts and is used only when performance does not produce significant amounts of work in process prior to complete satisfaction of the performance obligation and the gross billing value of contracting work can be measured reliably.

The typical contract length of the Company entered is ranged from 12 months to 24 months.

Contracted but not yet recognized revenue was approximately USD78.6 million and USD51.7 million as of March 31, 2023 and 2022.

The nature of the Company’s contracts gives rise to several types of variable consideration, including unpriced change orders and claims; and liquidated damages and penalties. The Company recognizes revenue for variable consideration when it is probable that a significant reversal in the amount of cumulative revenue recognized will not occur. The Company estimates the amount of revenue to be recognized on variable consideration using the expected value (i.e., the sum of a probability-weighted amount) or the most likely amount method, whichever is expected to better predict the amount. Factors considered in determining whether revenue associated with claims (including change orders in dispute and unapproved change orders in regard to both scope and price) should be recognized include the following: (a) the contract or other evidence provides a legal basis for the claim, (b) additional costs were caused by circumstances that were unforeseen at the contract date and not the result of deficiencies in the company’s performance, (c) claim-related costs are identifiable and considered reasonable in view of the work performed, and (d) evidence supporting the claim is objective and verifiable. If the requirements for recognizing revenue for claims or unapproved change orders are met, revenue is recorded only when the costs associated with the claims or unapproved change orders have been incurred and only up to the amount of cost incurred.

The Company generally provides limited warranties for work performed under its construction contracts. The warranty periods typically extend for a limited duration following substantial completion of the Company’s work on the project. Historically, warranty claims have not resulted in material costs incurred for which the Company was not compensated for by the customer.

There were no material amounts of unapproved change orders or claims recognized during fiscal 2023 and fiscal 2022.

Cost of sales

Cost of sales consists primarily of subcontracting fees, cost of materials and tools, direct labor costs and other overhead costs that are directly attributable to services provided.

General and administrative expenses

General and administrative expenses mainly consist of administrative staff cost, amortization of right-of-use assets — operating lease, office supplies and upkeep expenses, impairment loss allowance, insurance fees and other miscellaneous administrative expenses.

F-14

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Leases

In February 2016, the FASB issued ASU 2016-02, Leases (Topic 842), which requires lease assets and liabilities to be recorded on the balance sheet. The Company adopted this ASU and related amendments as of April 1, 2019 under the modified retrospective approach and elected to early adopt the following lease policies in conjunction with the adoption of ASU 2016-02: (i) for leases that have lease terms of 12 months or less, the Company also elected to apply ASC 842 recognition requirements; and (ii) the Company elected to apply the package of practical expedients for existing arrangements entered into prior to April 1, 2019 to not reassess (a) whether an arrangement is or contains a lease, (b) the lease classification applied to existing leases, and (c) initial direct costs.

For any new or modified lease, the Company determines whether a contract is or contains a lease at the inception of the contract. The Company records right-of-use (“ROU”) assets and lease obligations for its finance and operating leases, which are initially recognized based on the discounted future lease payments over the term of the lease. Lease term is defined as the non-cancellable period of the lease plus any options to extend or terminate the lease when it is reasonably certain that the Company will exercise the option. The Company has also elected to recognize ROU asset and lease obligations for its short-term leases, which are defined as leases with an initial term of 12 months or less. For the classes of buildings, the Company has elected to not separate lease from non-lease components. For leases in which the lease and non-lease components have been combined, the non-lease components includes expenses such as common area maintenance, utilities, and repairs and maintenance.

Income taxes

The Company accounts for income taxes under ASC 740. Deferred tax assets and liabilities are recognized for the future tax consequences attributable to differences between the consolidated financial statement carrying amounts of existing assets and liabilities and their respective tax bases.

Deferred tax assets and liabilities are measured using enacted tax rates expected to apply to taxable income in the years in which those temporary differences are expected to be reversed or settled. The effect on deferred tax assets and liabilities of a change in tax rates is recognized in income in the period including the enactment date. Valuation allowances are established, when necessary, to reduce deferred tax assets to the amount expected to be realized. Current income taxes are provided for in accordance with the laws of the relevant taxing authorities.

The provisions of ASC 740-10-25, “Accounting for Uncertainty in Income Taxes,” prescribe a more-likely-than-not threshold for consolidated financial statement recognition and measurement of a tax position taken (or expected to be taken) in a tax return. This interpretation also provides guidance on the recognition of income tax assets and liabilities, classification of current and deferred income tax assets and liabilities, accounting for interest and penalties associated with tax positions, and related disclosures.

The Company did not accrue any liability, interest or penalties related to uncertain tax positions in its provision for income taxes line of its consolidated statements of income for the years ended March 31, 2023 and 2022, respectively. The Company does not expect that its assessment regarding unrecognized tax positions will materially change over the next 12 months.

Earnings per share

Basic earnings per share is computed by dividing net earnings attributable to ordinary shareholders by the weighted average number of ordinary shares outstanding during the year. Diluted earnings per share reflect the potential dilution that could occur if securities or other contracts to issue ordinary shares were exercised or converted into ordinary shares.

F-15

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

2.      SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES (cont.)

Recent accounting pronouncements

The Company is an “emerging growth company” (“EGC”) as defined in the Jumpstart Our Business Startups Act of 2012 (the “JOBS Act”). Under the JOBS Act, EGC can delay adopting new or revised accounting standards issued subsequent to the enactment of the JOBS Act until such time as those standards apply to private companies.

Other accounting standards that have been issued by FASB that do not require adoption until a future date are not expected to have a material impact on the consolidated financial statements upon adoption. The Company does not discuss recent standards that are not anticipated to have an impact on or are unrelated to its consolidated financial condition, results of operations, cash flows or disclosures.

3.      ACCOUNTS RECEIVABLE, NET

Accounts receivable, net, consists of the following:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Accounts receivable

 

14,990,207

 

 

12,794,426

 

Less: allowance for credit loss

 

(429,621

)

 

(1,360,315

)

Accounts receivable, net

 

14,560,586

 

 

11,434,111

 

The movements in the allowance for credit loss for the years ended March 31, 2022 and 2023 were as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Balance at beginning of the year

 

64,914

 

429,621

 

Additions

 

364,707

 

1,073,643

 

Less: write off

 

 

(142,949

)

Balance at end of the year

 

429,621

 

1,360,315

 

4.      PREPAID EXPENSES, DEPOSITS AND OTHER RECEIVABLE

Prepaid expenses, deposits and other receivable mainly consists of deposit for surety bond for the construction income and deposit for renting premises and materials purchase.

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Prepaid operating expenses and other receivable

 

42,756

 

 

24,189

 

Bond collateral

 

842,391

 

 

1,478,288

 

Deposits

 

115,302

 

 

263,492

 

Other receivable

 

46,810

 

 

 

   

1,047,259

 

 

1,765,969

 

Less: Non-current portion

 

(842,391

)

 

(911,827

)

Prepaid expenses, deposits and other receivable in current assets

 

204,868

 

 

854,142

 

F-16

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

5.      INVESTMENT IN LIFE INSURNACE POLICY, CASH SURRENDER VALUE

Investment in life insurance policy was life insurance purchase for Mr. Keung Yun Yuen, a director of the Company with Chiu & Lee Partners Construction Co. Ltd, as beneficiary.

As of March 31, 2022, the insured amount of the contract (“death benefit”) was USD1,532,883. The investment amount for the policy was USD794,172 and the balance was US$657,992, which represents the adjustments of premiums paid of US$54,100, interest income earned of US$23,660 and cash surrender charge of US$105,727 for the year ended March 31, 2022. The Company may surrender any time and receive cash based on the cash value of the policy at the date of withdrawal, which is calculated by the insurer.

As of March 31, 2023, the insured amount of the contract (“death benefit”) was USD4,092,658. The aggregated investment amount which consisted of two life insurance policies, was USD2,153,839 and the balance was US$1,803,987, which represents the adjustments of premiums paid of US$101,538, interest income earned of US$67,173 and cash surrender charge of US$179,320 for the year ended March 31, 2023.

6.      Leases

(a) Finance leases

The Company has entered into finance lease obligations with principal amount of approximately USD448,000 and USD342,000 as of March 31, 2023 and 2022 respectively for certain of its motor vehicles and equipment.

(b) Operating leases

The Company leases office spaces for varying periods in Hong Kong. As the majority of the leases do not provide an implicit rate, the Company used an incremental borrowing rate based on the information available at commencement date in determining the present value of lease payments. The Company’s lease agreements do not contain any material guarantees or restrictive covenants. The Company does not have any sublease activities. Short-term leases, defined as leases with initial term of 12 months or less, are also reflected on the Consolidated Balance Sheets. For purposes of calculating lease liabilities for such leases, the Company have combined lease and non-lease components.

The components of lease expenses are as follows:

 

For the year ended
March 31,

   

2022

 

2023

   

USD

 

USD

Operating lease expense

 

121,152

 

127,888

Finance lease expense

       

Amortization of right-of-use assets

 

41,112

 

65,780

Interest on lease liabilities

 

7,768

 

15,291

Total finance lease expense

 

48,880

 

81,071

The components of finance expenses are as follows:

 

For the year ended
March 31,

   

2022

 

2023

Finance lease:

   

 

   

 

Right-of-use assets, at cost

 

395,217

 

 

528,038

 

Accumulated amortization

 

(76,242

)

 

(142,022

)

Right-of-use assets, net

 

318,975

 

 

386,016

 

    

F-17

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

6.      Leases (cont.)

Other information about the Company’s leases is as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Cash paid for amounts included in the measurement of lease liabilities:

   

 

   

 

Operating cash flows used in operating leases

 

118,101

 

 

129,177

 

Operating cash flows used in finance leases

 

7,768

 

 

15,291

 

Initial payment of financial leases

 

51,282

 

 

26,565

 

Financing cash flows used in finance leases

 

32,767

 

 

113,598

 

Right-of-use assets obtained in exchange for new operating lease liabilities

 

135,838

 

 

113,002

 

Right-of-use assets obtained in exchange for new finance lease liabilities

 

256,410

 

 

132,821

 

Weighted-average remaining lease term-operating

 

1.03 years

 

 

0.90 years

 

Weighted-average remaining lease term-finance

 

3.03 years

 

 

2.07 years

 

Weighted average discount rate-operating

 

5.00

%

 

5.00

%

Weighted average discount rate-finance

 

5.01

%

 

4.85

%

The following is a maturity analysis of the annual undiscounted cash flows for lease liabilities as of March 31, 2023:

 

Operating
leases

 

Finance
leases

 

Total

   

USD

 

USD

 

USD

Years ending March 31,

   

 

   

 

   

 

2024

 

64,413

 

 

135,190

 

 

199,603

 

2025

 

3,936

 

 

123,025

 

 

126,961

 

2026

 

 

 

23,528

 

 

23,528

 

2027

 

 

 

 

 

 

2028 and thereafter

 

 

 

 

 

 

Total undiscounted lease payments

 

68,349

 

 

281,743

 

 

350,092

 

Less: imputed interest

 

(1,438

)

 

(14,603

)

 

(16,041

)

Lease liabilities recognized in the Consolidated Balance Sheet

 

66,911

 

 

267,140

 

 

334,051

 

7.      PROPERTY, PLANT AND EQUIPMENT

Property, plant and equipment consists of the following as of March 31, 2023 and 2022:

 

As of March 31

   

2022

 

2023

   

USD

 

USD

Machinery

 

147,436

 

 

147,436

 

Motor vehicle

 

 

 

28,205

 

Less: accumulated depreciation

 

(15,358

)

 

(58,093

)

Total property, plant and equipment, net

 

132,078

 

 

117,548

 

Depreciation expenses recognized for the year ended March 31, 2023 and 2022 was USD42,735 and USD15,358 respectively. The motor vehicle was acquired for the purpose of the use of the project engineer to go to and from the project sites.

F-18

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

8.      BANK LOANS

The bank loans consisted of the following at March 31, 2023:

Bank Name

 

Principal Amount

 

Amount –
HKD

 

Amount –
USD

 

Issuance
Date

 

Expiration
Date

 

Interest

HSBC

 

HKD3,308,225

 

286,438

 

36,723

 

2020-06-02

 

2023-06-01

 

HKBLR* – 2.25%

HSBC

 

HKD6,000,000

 

2,683,837

 

344,082

 

2020-04-03

 

2025-04-02

 

HKBLR

HSBC

 

USD342,546

 

2,035,257

 

260,930

 

2021-05-10

 

2028-05-09

 

USBLR** – 0.25%

HSBC

 

HKD10,000,000

 

7,759,464

 

994,803

 

2021-06-07

 

2028-06-06

 

HKBLR* – 1%

HSBC

 

HKD2,000,000

 

1,345,613

 

172,514

 

2021-06-07

 

2026-06-06

 

HKBLR* – 1%

HSBC

 

HKD5,691,775

 

5,691,775

 

729,715

 

2022-06-06

 

2032-06-05

 

HKBLR – 2.25%

HSBC

 

USD325,376

 

2,300,149

 

294,891

 

2022-07-07

 

2029-07-06

 

USBLR** – 1%

HSBC

 

HKD5,900,000

 

5,408,334

 

693,376

 

2023-02-27

 

2024-02-26

 

HIBOR*** + 1.8%

HSBC

 

HKD2,039,089

 

2,039,089

 

261,422

 

2023-01-13

 

2023-05-15

 

4.825%

HSBC

 

HKD3,688,803

 

3,688,803

 

472,923

 

2023-02-16

 

2023-06-16

 

4.825%

Total

     

33,238,759

 

4,261,379

           

The bank loans consisted of the following at March 31, 2022:

Bank Name

 

Principal Amount

 

Amount –
HKD

 

Amount –
USD

 

Issuance
Date

 

Expiration
Date

 

Interest

HSBC

 

HKD3,308,225

 

1,411,627

 

180,978

 

2020-06-02

 

2023-06-01

 

HKBLR* – 2.25%

HSBC

 

HKD6,000,000

 

3,873,497

 

496,602

 

2020-04-03

 

2025-04-02

 

HKBLR

HSBC

 

USD342,546

 

2,376,041

 

304,621

 

2021-05-10

 

2028-05-09

 

USBLR** – 0.25%

HSBC

 

HKD10,000,000

 

9,056,515

 

1,161,092

 

2021-06-07

 

2028-06-06

 

HKBLR* – 1%

HSBC

 

HKD2,000,000

 

1,724,693

 

221,114

 

2021-06-07

 

2026-06-06

 

HKBLR* – 1%

HSBC

 

HKD7,800,000

 

6,517,635

 

835,594

 

2022-01-21

 

2023-01-20

 

HKBLR* – 1.5%

Total

     

24,960,008

 

3,200,001

           

____________

*        Hong Kong Dollar Best Lending Rate

**      United States Dollar Best Lending Rate

***    Hong Kong Interbank Offered Rate

The Company’s bank loans are denominated in HKD or USD.

As of March 31, 2023 and 2022, the bank loans amounted to USD4,261,379 and USD3,200,001 respectively with interest bearing ranging from 3.3% to 7.0% per annum (2022: ranging from 2.3% to 5% per annum). The securities of these loans are ranging from (i) personal undertaking and personal guarantee given by Mr. Keung Yun Yuen; (ii) charge over cash deposit with the lending bank (see note 2 — restricted cash); (iii) assignment of life insurance with carrying amount of approximately USD1,804,000 (2022: approximately USD658,000); (iv) Chiu & Lee Partners maintaining a required level of adjusted tangible net worth; and/or (v) a guarantee issued by HKMC Insurance Limited under the Hong Kong SME Financing Guarantee Scheme, a loan guarantee scheme launched by the Hong Kong government to help small and medium enterprises to secure bank loans, which the lending bank required.

During the fiscal year ended March 31, 2023, the Company entered into certain financial facilities with its principal bank and drew down loans with principal amount of approximately USD3,782,000 (2022: approximately USD2,881,000). The bank facility bears interest rate ranged from the Bank’s HKD Best Lending Rate minus 2.25% per annum; at HIBOR plus 1% per annum; at USD Best Lending Rate minus 1% per annum or at 4.825% per annum (2022: ranged from the Bank’s HKD Best Lending Rate minus 1% – 1.5% per annum or at USD Best Lending Rate minus 0.25% per annum.)

F-19

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

8.      BANK LOANS (cont.)

The following are the matures of the above borrowings:

 

Amount

   

USD

Years ending March 31,

   

2024

 

1,995,043

2025

 

570,105

2026

 

429,507

2027

 

386,029

2028 and thereafter

 

880,695

Total Bank Borrowings

 

4,261,379

During the years ended March 31, 2023 and 2022, interest expense related to these credit facilities was USD162,924 and USD97,599 respectively.

9.      Accounts payable, accruals, and other current liabilities

Account payable, accruals and other current liabilities consists of the following:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Trade payables

 

10,285,196

 

12,445,006

Retention payables

 

4,754,205

 

7,961,337

Accrued expenses

 

89,132

 

17,258

   

15,128,533

 

20,423,601

10.    CONTRACT Assets, RETENTION RECEIVABLES AND CONTRACT LIABILITIES

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Contract assets – current, net:

   

 

   

 

Revenue recognized in excess of amounts paid or payable (contracts receivable) to the company on uncompleted contracts (contract asset), excluding retainage

 

1,506,431

 

 

2,538,174

 

Retainage included in contract assets due to being conditional on something other than solely passage of time

 

180,613

 

 

3,262,167

 

Less: allowance for credit loss

 

(143,544

)

 

(408,552

)

   

1,543,500

 

 

5,391,789

 

     

 

   

 

Contract assets – non-current, net:

   

 

   

 

Retainage due to being conditional on something other than solely passage of time

 

6,616,787

 

 

7,222,700

 

Less: allowance for credit loss

 

(146,882

)

 

(373,429

)

   

6,469,905

 

 

6,849,271

 

Contract liabilities:

   

 

   

 

Payments received or receivable (contracts receivable) in excess of revenue recognized on uncompleted contracts (contract liability), excluding retainage

 

(1,471,271

)

 

 

   

(1,471,271

)

 

 

F-20

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

10.    CONTRACT Assets, RETENTION RECEIVABLES AND CONTRACT LIABILITIES (cont.)

 

Year ended March 31,

   

2022

 

2023

   

USD

 

USD

Information about contract liabilities:

   

 

   

 

Revenue recognized that was included in contract liabilities as of April 1, 2021 and 2022

 

(368,299

)

 

(1,471,271

)

The increase in contract assets is primarily attributable to the increases in scale of operation, i.e. value of projects undertaken during the year ended March 31, 2023. The Company expected that those amounts of contract assets excluding retainage to be recovered/realized within 12 months.

The movements in the allowance for credit loss for the years ended March 31, 2022 and 2023 were as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Balance at beginning of the year

 

58,941

 

290,426

Additions

 

231,485

 

491,555

Balance at end of the year

 

290,426

 

781,981

11.    income tax

Pursuant to the current rules and regulations, the Cayman Islands and the BVI currently levy no taxes on individuals or corporations based upon profits, income, gains or appreciations and there is no taxation in the nature of inheritance tax or estate duty. Therefore, the Company is not subject to any income tax in the Cayman Islands or the BVI.

The Company is subject to Hong Kong profits tax at a rate of 16.5% on their taxable income generated from operations in Hong Kong before April 1, 2018. Starting from the financial year commencing on April 1, 2018, the two-tiered profits tax regime took effect, under which the tax rate is 8.25% for assessable profits on the first HKD2 million and 16.5% for any assessable profits in excess of HKD2 million.

Composition of income tax expenses

The following table sets forth current and deferred portion of income tax expenses:

 

Year ended March 31,

   

2022

 

2023

   

USD

 

USD

Current income tax expenses

 

787,022

 

 

750,237

 

Deferred income tax recovery

 

(69,298

)

 

(219,372

)

Income tax expense

 

717,724

 

 

530,865

 

F-21

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

11.    income tax (cont.)

Reconciliation between the income tax expenses computed by applying the Hong Kong enterprise tax rate to income before income taxes and actual provision were as follows:

 

Year ended March 31,

   

2022

 

2023

   

USD

 

USD

Income before income tax

 

4,487,152

 

 

3,383,978

 

Cayman Islands statutory income tax rate

 

0

%

 

0

%

Income tax calculated at statutory rate

 

 

 

 

(Increase) decrease in income tax expense resulting from:

   

 

   

 

Rate differences in various jurisdictions

 

740,380

 

 

558,356

 

Tax effect of non-taxable income

 

(38,611

)

 

(62,359

)

Tax effect of non-deductible expenditure

 

107,689

 

 

276,163

 

Deferred income tax recovery

 

(69,298

)

 

(219,372

)

Tax reduction related to 2-tiered profits tax regime

 

(22,436

)

 

(21,923

)

Income tax expense

 

717,724

 

 

530,865

 

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Deferred tax assets

 

118,807

 

 

353,478

 

Deferred tax liabilities

 

(34,482

)

 

(45,769

)

   

84,325

 

 

307,709

 

The significant components of the Company’s deferred tax assets and liabilities are as follows:

 

As of March 31,

   

2022

 

2023

   

USD

 

USD

Deferred tax assets:

   

 

   

 

Provision for credit loss

 

118,807

 

 

353,478

 

Total deferred tax assets

 

118,807

 

 

353,478

 

Deferred tax liabilities:

   

 

   

 

Right-of-use assets – finance lease

 

(20,474

)

 

(33,904

)

Property, plant and equipment

 

(14,008

)

 

(11,865

)

Total deferred tax liabilities

 

(34,482

)

 

(45,769

)

Net deferred tax assets

 

84,325

 

 

307,709

 

As of March 31, 2023 and 2022, the Company had no unrecognized tax benefit.

12.    REVENUE AND SEGMENT INFORMATION

The Company follows FASB ASC Topic 280, Segment Reporting, which requires that companies disclose segment data based on how management makes decision about allocating resources to segments and evaluating their performance. Reportable operating segments include components of an entity about which separate financial information is available and which operating results are regularly reviewed by the chief operating decision maker (“CODM”), Mr. Keung, Yun Yuen, to make decisions about resources to be allocated to the segment and assess each operating segment’s performance.

Based on the management’s assessment, the Company determined that it has only one operating segment which is the provision of construction works and therefore one reportable segment as defined by ASC 280. For the years ended March 31, 2023 and 2022, revenue and assets within Hong Kong contributed over 90% of the Company’s total

F-22

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

12.    REVENUE AND SEGMENT INFORMATION (cont.)

revenue and assets. The single segment represents the Company’s core business of providing (i) foundation and site formation work; (ii) development of superstructures; (iii) demolition work; and (iv) alteration and addition work, and other general building work services to its customers in Hong Kong.

The following table presents revenue by major revenue type for the years ended March 31, 2023 and 2022, respectively:

 

Year ended March 31

   

2022

 

2023

   

USD

 

USD

Foundation and site formation work

 

45,972,316

 

55,784,659

Development of superstructures

 

12,965,504

 

21,598,103

Demolition work

 

1,052,093

 

188,337

Alteration, addition work and others

 

734,390

 

281,348

Total

 

60,724,303

 

77,852,447

The following table presents cost by major revenue type for the years ended March 31, 2023 and 2022, respectively:

 

Year ended March 31

   

2022

 

2023

   

USD

 

USD

Foundation and site formation work

 

40,717,974

 

49,872,259

Development of superstructures

 

12,598,279

 

21,478,831

Demolition work

 

790,065

 

130,905

Alteration, addition work and others

 

668,147

 

258,693

Total

 

54,774,465

 

71,740,688

13.    OTHER INCOME (EXPENSE)

Other income (expense), net, consists of the following:

 

Year ended March 31

   

2022

 

2023

   

USD

 

USD

Government grants

 

14,969

 

 

162,462

 

Interest income from investment in life insurance policy

 

23,660

 

 

67,443

 

Sale of materials

 

38,309

 

 

 

Change in surrender value of investment in life insurance policy

 

(105,727

)

 

(179,320

)

Rental income

 

 

 

38,462

 

Reversal of retention payables

 

 

 

72,050

 

Other miscellaneous income (expense), net

 

15,243

 

 

12,451

 

Total other income (expense), net

 

(13,546

)

 

173,548

 

F-23

Table of Contents

CHI KO HOLDINGS LIMITED
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

14.    COMMITMENTS AND CONTINGENCIES

Commitments

As at March 31, 2023, save as disclosed in notes 6 and 8 in the consolidated financial statements, the Company did not have any significant capital and other commitments.

Contingencies

In the ordinary course of business, the Company may be subject to legal proceedings regarding contractual and employment relationships and a variety of other matters. The Company records contingent liabilities resulting from such claims, when a loss is assessed to be probable, and the amount of the loss is reasonably estimable. The Company accrues costs associated with these matters when they become probable and the amount can be reasonably estimated. Legal cost incurred in connection with loss contingencies are expensed as incurred.

On September 1, 2021, Chiu & Lee Partners, a subsidiary of the Company, received a summonses (the “Summonses”) issued by West Kowloon Magistrates’ Courts alleging that Chiu & Lee Partners has contravened a construction sites safety regulations under the Factories and Industrial Undertakings Ordinance (Chapter 59 of the Laws of Hong Kong).

Based on the inquiry with the legal representative, it is estimated that the maximum exposure to loss is ranged from HKD20,000 to HKD80,000. The Company assessed that it is reasonably possible that the court will fine against them and accrued legal liabilities of USD6,410 (equivalent to HKD50,000) for the year ended March 31, 2023. On 11 April 2023, the case has been finalized by imposing fine of an aggregate amount of USD2,051 (equivalent to HK$16,000) on the Company.

In the opinion of management, there were no pending or threatened claims and litigation as of March 31, 2023 and through the issuance date of these consolidated financial statements.

15.    DIVIDEND AND DIVIDEND PAYABLE

On March 31, 2023, an interim dividend of HKD2.37 per ordinary share on its outstanding shares as of that date has been declared. Certain shareholders had agreed to waive their right to receive dividend before the listing of the Company. Eventually, an interim dividend of HKD24 million (equivalent to USD3,076,923) has been declared and USD1,331,673 (equivalent to HKD10,387,048) has been settled by offsetting against the amount due from a director owned by Mr. Keung Yun Yuen. The remaining USD1,745,250 (equivalent to HKD13,612,952) has been settled in April 2023.

On February 28, 2022, Chiu & Lee Partners, a subsidiary of the Company, approved and declared a cash dividend of HKD60 per ordinary share on its outstanding shares as of that date. As such, a cash dividend of HKD12,000,000 (equivalent to USD1,538,462) has been declared and USD1,372,349 (equivalent to HKD10,704,319) has been settled as of March 31, 2022. The remaining USD166,113 (equivalent to HKD1,295,681) has been settled in May 2022.

16.    RECLASSIFICATION OF PRIOR YEAR PRESENTATION

Certain prior year amounts have been reclassified for consistency with the current year presentation. These reclassifications had no effect on the reported results of operations.

17.    SUBSEQUENT EVENTS

The Company has assessed all events from March 31, 2023, up through the date that these consolidated financial statements are available to be issued, unless as disclosed below, there are not any material subsequent events that require disclosure in these consolidated financial statements.

On April 1, 2023, Chiu & Lee Partners, a subsidiary of the Company, as tenant entered into a lease agreement with a landlord, in relation to the lease of an office premise. As a result, amounting to approximately USD1,810,000 of right-of-use assets and lease liabilities has been recognized under the lease agreement.

F-24

Table of Contents

Chi Ko Holdings Limited

1,740,000 Ordinary Shares

______________________________

PRELIMINARY PROSPECTUS

______________________________

EF Hutton

division of Benchmark Investments, LLC

        , 2023

Until and including             , 2023 (25 days after the date of this prospectus), all dealers that buy, sell, or trade our Ordinary Shares, whether or not participating in this offering, may be required to deliver a prospectus. This delivery requirement is in addition to the obligation of dealers to deliver a prospectus when acting as underwriters and with respect to their unsold allotments or subscriptions.

 

Table of Contents

PART II

INFORMATION NOT REQUIRED IN PROSPECTUS

Item 6. Indemnification of Directors and Officers.

Cayman Islands law does not limit the extent to which a company’s articles of association may provide indemnification of officers and directors, except to the extent that any such provision may be held by the Cayman Islands courts to be contrary to public policy, such as providing indemnification against fraud or dishonesty.

Pursuant to our Memorandum and Articles of Association that will become effective immediately prior to the completion of this offering, the directors, alternate directors, secretary and other officers for the time being of the Company and the trustees (if any) for the time being acting in relation to any of the affairs of the Company, and their respective executors or administrators, shall be indemnified and secured harmless out of the assets of the Company from and against all actions, costs, charges, losses, damages and expenses which they or any of them, their or any of their executors or administrators, shall or may incur or sustain by reason of any act done, concurred in or omitted in or about the execution of their duty or supposed duty in their respective offices or trusts, except such (if any) as they shall incur or sustain through their own dishonesty, wilful default or fraud, and none of them shall be answerable for the acts, receipts, neglects or defaults of any other of them, or for joining in any receipt for the sake of conformity, or for any bankers or other persons with whom any moneys or effects of the Company shall be lodged or deposited for safe custody, or for the insufficiency or deficiency of any security upon which any moneys of the Company shall be placed out or invested, or for any other loss, misfortune or damage which may arise in the execution of their respective offices or trusts, or in relation thereto, except as the same shall happen by or through their own dishonesty, wilful default or fraud.

We intend to enter into indemnification agreements with each of our directors and executive officers in connection with this offering. Under these agreements, we have agreed to indemnify our directors and executive officers against certain liabilities and expenses incurred by such persons in connection with claims made by reason of their being a director or officer of our Company.

The underwriting agreement in connection with this offering also provides for indemnification of us and our officers, directors, or persons controlling us for certain liabilities.

We intend to obtain directors’ and officers’ liability insurance coverage that will cover certain liabilities of directors and officers of our company arising out of claims based on acts or omissions in their capacities as directors or officers.

Item 7. Recent Sales of Unregistered Securities.

During the past three years, we have issued the following securities which were not registered under the Securities Act. We believe that each of the following issuance was exempt from registration under the Securities Act in reliance on Regulation D under the Securities Act or pursuant to Section 4(a)(2) of the Securities Act regarding transactions not involving a public offering or in reliance on Regulation S under the Securities Act regarding sales by an issuer in offshore transactions. No underwriters were involved in these issuances of securities.

Securities/Purchaser

 

Date of Issuance

 

Number of Securities

 

Consideration

Ordinary Shares

           

Keung Yun Yuen

 

May 4, 2022

 

11,250,000(1)

 

USD 1,125.00

____________

(1)      On May 4, 2022, Keung Yun Yuen transferred 551,250 Ordinary Shares to each of Ling Chi Fai and Wong Chi Wai at a total consideration of US$100,000 each.

II-1

Table of Contents

Item 8. Exhibits and Financial Statement Schedules.

(a)     The following documents are filed as part of this registration statement:

See the Exhibit Index attached to this registration statement, which is incorporated by reference herein.

(b)    Financial Statement Schedules

Schedules have been omitted because the information required to be set forth therein is not applicable or has been included in the consolidated financial statements or notes thereto.

Item 9. Undertakings.

(a)     The undersigned registrant hereby undertakes to provide to the underwriters at the closing specified in the underwriting agreements, certificates in such denominations and registered in such names as required by the underwriters to permit prompt delivery to each purchaser.

(b)    Insofar as indemnification for liabilities arising under the Securities Act may be permitted to directors, officers, and controlling persons of the registrant pursuant to the provisions described in Item 6 hereof, or otherwise, the registrant has been advised that in the opinion of the SEC, such indemnification is against public policy as expressed in the Securities Act and is, therefore, unenforceable. In the event that a claim for indemnification against such liabilities (other than the payment by the registrant of expenses incurred or paid by a director, officer, or controlling person of the registrant in the successful defense of any action, suit, or proceeding) is asserted by such director, officer, or controlling person in connection with the securities being registered, the registrant will, unless in the opinion of its counsel the matter has been settled by controlling precedent, submit to a court of appropriate jurisdiction the question whether such indemnification by it is against public policy as expressed in the Securities Act and will be governed by the final adjudication of such issue.

(c)     The undersigned registrant hereby undertakes that:

(1)    For purposes of determining any liability under the Securities Act, the information omitted from the form of prospectus filed as part of this registration statement in reliance upon Rule 430A and contained in a form of prospectus filed by the registrant pursuant to Rule 424(b)(1) or (4) or 497(h) under the Securities Act shall be deemed to be part of this registration statement as of the time it was declared effective.

(2)    For the purpose of determining any liability under the Securities Act, each post-effective amendment that contains a form of prospectus shall be deemed to be a new registration statement relating to the securities offered therein, and the offering of such securities at that time shall be deemed to be the initial bona fide offering thereof.

II-2

Table of Contents

EXHIBIT INDEX

Exhibit
Number

 

Description of Exhibit

1.1

 

Form of Underwriting Agreement

3.1

 

Memorandum and Articles of Association, as currently in effect

3.2

 

Form of Amended and Restated Memorandum and Articles of Association (to be effective in connection with the completion of this offering)

4.1

 

Specimen certificate evidencing Ordinary Shares

5.1**

 

Opinion of Appleby regarding the validity of the Ordinary Shares being registered

8.1**

 

Opinion of Appleby regarding certain Cayman Islands tax matters (included in Exhibit 5.1)

8.2**

 

Opinion of CFN Lawyers regarding certain legal matters and tax matters of the subsidiary in Hong Kong

10.1

 

Form of Indemnification Agreement between the registrant and its officers and directors

10.2

 

Form of Director Agreement between the registrant and its directors

10.3

 

Form of Independent Director Agreement between the registrant and its independent directors

10.4

 

Form of Employment Agreement between the registrant and its officers

10.5

 

Office Lease Contract, by and between Appleland Investments Limited and Chiu & Lee Partners, dated as of May 18, 2022

21.1

 

List of Subsidiaries

23.1**

 

Consent of ZH CPA, LLC, an independent registered public accounting firm

23.2**

 

Consent of Appleby (included in Exhibit 5.1)

23.3**

 

Consent of CFN Lawyers (included in Exhibit 8.2)

23.4

 

Consent of Thirupathi Nachiappan

23.5

 

Consent of Wong Heung Ming

23.6

 

Consent of Liu Yuk Shing

24.1*

 

Power of Attorney (included on signature page)

99.1

 

Code of Business Conduct and Ethics

99.2

 

Audit Committee Charter

99.3

 

Nominating Committee Charter

99.4†

 

Compensation Committee Charter

99.5†

 

Request for Waiver and Representation under Item 8.A.4 of Form 20-F

107†

 

Calculation of Filing Fee Table

____________

        Previously filed.

*        To be filed by amendment.

**      Filed herewith.

II-3

Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Act, as amended, the registrant certifies that it has reasonable grounds to believe that it meets all of the requirements for filing on Form F-1 and has duly caused this registration statement to be signed on its behalf by the undersigned, thereunto duly authorized, in Hong Kong, on October 25, 2023.

 

Chi Ko Holdings LIMITED

   

By:

 

/s/ Keung Yun Yuen

       

Name: Keung Yun Yuen

       

Title: Director and Chairman

KNOW ALL BY THOSE PRESENT, that each person whose signature appears below hereby constitutes and appoints and each of them, his or her true and lawful agent, proxy, and attorney-in-fact, with full power of substitution and resubstitution, for and in his or her name, place and stead, in any and all capacities, to (1) act on, sign, and file with the SEC any and all amendments (including post-effective amendments) to this registration statement together with all schedules and exhibits thereto and any subsequent registration statement filed pursuant to Rule 462(b) under the Securities Act, together with all schedules and exhibits thereto; (2) act on, sign, and file such certificates, instruments, agreements, and other documents as may be necessary or appropriate in connection therewith; (3) act on and file any supplement to any prospectus included in this registration statement or any such amendment or any subsequent registration statement filed pursuant to Rule 462(b) under the Securities Act; and (4) take any and all actions that may be necessary or appropriate to be done, as fully for all intents and purposes as he or she might or could do in person, hereby approving, ratifying, and confirming all that such agent, proxy, and attorney-in-fact or any of his or her substitutes may lawfully do or cause to be done by virtue thereof.

Pursuant to the requirements of the Securities Act, this registration statement has been signed by the following persons in the capacities and on the dates indicated.

Signature

 

Title

 

Date

/s/ Keung Yun Yuen

 

Chairman of the Board and Director

 

October 25, 2023

Name: Keung Yun Yuen

       

/s/ Chan Lee Chuen

 

Chief Executive Officer and Director

 

October 25, 2023

Name: Chan Lee Chuen

       

/s/ Choi Hiu Ying

 

Chief Finance Officer

 

October 25, 2023

Name: Choi Hiu Ying

 

(Principal Accounting and Financial Officer)

   

/s/ Wong Heung Ming

 

Independent Director

 

October 25, 2023

Name: Wong Heung Ming

       

/s/ Nachiappan Thirupathi

 

Independent Director

 

October 25, 2023

Name: Nachiappan Thirupathi

       

/s/ Liu Yuk Shing

 

Independent Director

 

October 25, 2023

Name: Liu Yuk Shing

       

/s/ Ng Wai Leung

 

Quantity surveyor manager

 

October 25, 2023

Name: Ng Wai Leung

       

II-4

Table of Contents

SIGNATURE OF AUTHORIZED U.S. REPRESENTATIVE OF THE REGISTRANT

Pursuant to the Securities Act, the undersigned, the duly authorized representative in the United States of CKHL, has signed this registration statement or amendment thereto in New York, New York on October 25, 2023.

 

Authorized U.S. Representative
Cogency Global Inc.

   

By:

 

/s/ Colleen A. De Vries

       

Name:

 

Colleen A. De Vries

       

Title:

 

Senior Vice President on behalf of Cogency Global Inc.

II-5