EX-4.31 10 ef20039025_ex4-31.htm EXHIBIT 4.31

Exhibit 4.31A

  BARECON 2017  

STANDARD BAREBOAT CHARTER PARTY
PART I

 
1.    Place and date
      05 March 2025
 
2.    Owners (Cl. 1)
(i)Name: T.A.C.K. SHIPPING, S.Aguaranteed by
Kowa Kaiun Co.Ltd.

(ii)  Place of registered office:
World Trade Center, 53rd StreetUrbanizacion
Marbella5th FloorSuite 502Panama City,
Republic of Panama

(iii) Law of registry:
Panama

   
3.    Charterers (Cl1)
(i)    Name: GUADELOUPE Shipping Company Inc.
guaranteed by Performance Shipping Inc.
 
(ii)   Place of registered office:
Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, The Marshall Islands MH 96960
 
(iii) Law of registry: The Republic of the Marshall Islands

 
           
 
4.    Vessel (Cl. 1 and 3)
(i) Name: HULL H1597 “P. MARSEILLE”
(ii) IMO Number: 1057218
(iii) Flag State: Marshall Islands or Liberia
(iv)  Type: LR2 Tanker

   
(v) GT/NT:
(vi)  Summer DWT:
(vii) When/where built: Shanghai Waigaoqiao Shipbuilding
(viii)  Classification Society: IACS classification society in Charterer’s option
 
 
5.    Date of last special survey by the Vessel’s Classification Society
    N/A
   
6.    Validity of class certificate (state number of months to apply)
(i)    Delivery (Cl. 3): N/A
(ii)   Redelivery (Cl. 10): minimum 3 months

 
 
7.    Latent Defects (state number of months to apply) (Cl. 1,3)
N/A
   
8.     Port or place of delivery (Cl. 3)
 As per MOA Clause 5

 
 
9.    Delivery notices (Cl. 4)
N/A
   
10.  Time for delivery (Cl4)
As per MOA Clause 5

 
 
11.  Cancelling date (Cl. 4,5)
31 October 2026
   
12Port or place of redelivery (Cl.10)
Worldwide range, safely afloat at an accessible safe berth or anchorage at a safe port or place (excluding war risk areas in accordance with the terms of the Vessel’s Insurances), in Charterers’ option.

 
 
13.  Redelivery notices (Cl. 10)
Thirty (30) and twenty (20), fifteen (15), seven (7), and three running days’ approximate notices and two (2) running days’ definite notice
   
14Trading limits (Cl11)
World Wide trading within institute Warranty Limits (IWL), provided that, Charterers shall be permitted to trade outside of IWL if they pay any applicable premium and/or expenses. North Korea, Russia and any other states or regions sanctioned by UN, USA, EU, UK or Japan shall be excluded. If Charterers call at a state which results in a breach of sanctions applicable to the Charterers and/or the Vessel then Charterers to undertake to indemnify Owners in accordance with Clause 22 and
 

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.


STANDARD BAREBOAT CHARTER PARTY
PART I
       
Clause 51.
 
 
15. Bunker fuels, unused oils and greases (optional, state if (a) (actual net price), or (b) (current net market price) to apply) (Cl. 9)
N/A

   
16Charter period (Cl. 2)
8 years from Delivery
 
 
17.  Charter hire (state currency and amount) (Cl. 2,10 and 15)
(i)   Charter hire:
A: Fixed part: USD 6,850 per day; plus
B: Floating part: (1M CME  TERM SOFR +2.05% Margin) x No of days/360 x Loan Outstanding
Margin as per line 44
Loan Outstanding as per Clause 49
 
(ii)  Charter hire for optional period: N/A

   
18.     Optional period and notice (Cl. 2)
(i)   State extension period in months: N/A
(ii)   State when declarable: N/A
 
 
19Rate of interest payable (Cl. 15(g))
1 month CME TERM SOFR plus 2.05 percentage points per annum
   
20Owners’ bank details (state beneficiary and bank account) (Cl. 15)
The Nishi-Nippon City Bank Ltd.
 
Branch Code:
SWIFT Code:
USD Account No :
Account Name:
Beneficiary:

 
 
21.  New class and other regulatory requirements (Cl. 13(b))
(i)  State if 13(b)(i) or (ii) to apply: Clause 13(b)(I) to apply
(ii)  Threshold amount (AMT): N/A
(iii)  Vessel’s expected remaining life in years on the Delivery Date: N/A

 
22.   Mortgage(s), if any (state if 16(a) or (b) to apply; if 16 (b) applies state date of Financial Instrument and name of Mortgagee(s)/Place of business) (Cl. 1, 16)
First priority ship mortgage in favor of the Nishi-Nippon City Bank Ltd. Japan


 
23Insured Total Loss value (Cl. 17)
See Clause 47
   
24Insuring party (state if Cl. 17(b) (Charterers to insure) or Cl. 17(c) (Owners to insure) to apply)
Clause 17(b)
And See Clause 47
 
 
25. Performance guarantee (state amount and entity) (Cl. 27) (optional)
See Clause 43

 
 
26.  Dispute Resolution (state 33(a), 33(b), 33(c) or 33(d); if 33(c) is agreedstate Singapore or English law; if 33(d) is agreedstate governing law and place of arbitration) (Cl. 33)
(a) English law, London arbitration

 
 
27.   Newbuilding Vessel (indicate with yes” or “no” whether PART III applies and if “yes”, complete details below) (optional)
No
 

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.


STANDARD BAREBOAT CHARTER PARTY
PART I
 
(i)    Name of Builders:
(ii)   Hull number:
(iii)  Date of newbuilding contract:
(iv)  Liquidated damages for physical defects or deficiencies (state party):
(v)  Liquidated damages for delay in delivery (state party):

 

 
28. Purchase Option (indicate with “yesor “nowhether PART IV applies) (optional)
 
No, see however Clause 45
   
29.  Bareboat Charter Registry (indicate with yes” or ‘‘no” whether PART V applies and if “yes”, complete details below) (optional) No
(i)   Underlying Registry: N/A
(ii)  Bareboat Charter Registry: N/A
 
 
30. Notice to Owners (state full style details for serving notices) (Cl. 34)
c/o Kowa Kaiun Co.Ltd.
470-1 Oaza Nagashima,
Kaminoseki-choKumage-gun,
Yamaguchi, Japan

Email:

Attention: Takayuki Hanada
   
31. Notice to Charterers (state full style details for serving notices) (Cl. 34)
GUADELOUPE SHIPPING COMPANY INC.
c/o PERFORMANCE SHIPPING MANAGEMENT INC.
373 Syngrou Ave. & 2-4 Ymittou str., 17564, Palaio Faliro, Athens, Greece

Email:

Attention: Mr. Andreas Nikolaos
Michalopoulos
 
 
       

It is mutually agreed that this Charter Party shall be performed subject to the conditions contained in this Charter Party which shall include PART I, and PART II and Rider Clauses 39-54In the event of a conflict of conditions, the provisions of PART I shall prevail over those of PART II and Rider Clauses 39-54 to the extent of such conflict but no further. It is further mutually agreed that PART III and/or PART IV and/or PART V shall only apply and only form part of this Charter Party if expressly agreed and stated in BOX 2728 and 29. If PART III and/or PART IV and/or PART V applies, it is further agreed that in the event of a conflict of conditionsthe provisions of PART I and PART II shall prevail over those of PART III and/or PART IV and/or PART V to the extent of such conflict but nor further.
 
 
T.A.C.K. SHIPPING, S.A.
Signature (Owners)
   
GUADELOUPE SHIPPING COMPANY INC.
Signature(Charterers)
 
 
   

 
       
/s/ Andreas Nikolaos Michalopoulos
 
 
Name: Takayuki Hanada
Title: Representative Director / Treasurer
   
Name: Andreas Nikolaos Michalopoulos
Title: Director / Attorney-in-fact
 
           
 
Kowa Kaiun Co.Ltd.
   
Performance Shipping Inc.
 
 
Signature (Guarantor)
   
Signature (Guarantor)
 
           
        /s/ Andreas Nikolaos Michalopoulos  
 
Name: Takayuki Hanada
Title: Executive Director
   
Name: Andreas Nikolaos Michalopoulos
Title: Director / Chief Executive Officer
 
 
   
 

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
0 1. Definition
1    
2
  In this Charter Party:
3    
4  
“Banking Day” means a day on which banks are open in the places stated in Boxes 30 and 31, New York,
5  
TokyoLondonAthensShanghai and, for payments in US dollarsin New York.
6    
7  
“Builder” means Shanghai Waigaoqiao Shipbuilding Company Limiteda corporation organized and existing
8  
under the laws of the Peoples Republic of Chinahaving its registered office at 3001 Zhouhai RoadPudong
9
 
New DistrictShanghai 200137the Peoples Republic of China
10  

11
 
“Building Contract” means the ship building contract dated 18 December 2023 (as amended by Addendum
12  
no.1 dated 18 December 2023) made between the Construction Seller and the Sellers as buyer.
13
   
14   “Charterers” means the party identified in Box 3.
15
   
16
  “CharterersEvent of Defaulthas the meaning given to it in Clause 31(a) and a CharterersEvent of Default
17
  is “continuing” if such Charterers’ Event of Default has not been remedied by the Charterers or waived by the
18
  Owners.
19    
20   Compulsory Acquisitionhas the meaning given to it in Clause 30(b).
21  

22  
Construction Sellermeans together (i) the Builder and (ii) China Shipbuilding Trading Company Limiteda
23
 
company incorporated and existing under the laws of the People’s Republic of Chinahaving its registered
24
 
office al 56(Yi)Zhongguancun Nan Da Jie, Beijing 100044the Peoples Republic of China.
25    
26  
“Crew” means the Master, officers and ratings and any other personnel employed on board the Vessel.
27    
28
 
“Delivery Date” means the date of delivery of the Vessel by the Owners to the Charterers under this Charter
29  
Party.
30    
31   
 
“Financial Instrument” means the mortgage, deed of covenant or other such financial security instrument as
32 
 
identified in Box 22.
33    
34  
 
“Fixed Hiremeans the fixed part of the Charter Hire identified in Box 17(i)(A).
35    
36 
 
“Flag State” means the flag state in Box 4 or such other flag state to which the Charterers may have re-
37
 
registered the Vessel with the Owners’ consent during the Charter Period.
38    
39
 
Guaranteeshas the meaning ascribed to it in Clause 43
40    
41
 
“Latent Defect” means a defect which could not be discovered on such an examination as a reasonably
42
  careful skilled  person would make.
43    
44
 
“Marginmeans 2.05% per annum.
45  
46
 
MOAmeans the Memorandum of Agreement entered into between the Owners (as buyers) and the
47
 
 Charterers (as sellers) dated 05 March 2025.
48  
49
  Mortgageemeans The Nishi-Nippon City Bank Ltd.
50
   
51 
  “Outstanding Principal” means at any relevant time the aggregate of the amount of $45,000,000 less the
52
 
aggregate Fixed Hire which has at any relevant time been received by the Owners in accordance with this
53   
 
Charter Party.
 
Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
54
 
55
 
“Owners” means the party identified in Box 2.
56
   
57
 
“Parties” means the Owners and the Charterers.
58
   
59
 
Permitted Liens” means:
60
   
61
 
(i)   any liens for unpaid master’s and crew’s wages in accordance with first class ship ownership and
62
 
management practice and not being enforced through arrest; or
63
   
64  
(ii)   general average and salvage not being enforced through arrest; or
65


66
 
(iii)  liens in favour of suppliersnecessaries and other similar liens arising by operation of law or in the
67
 
ordinary course of tradingoperationrepair or maintenance of the Vesselsuch liens not being enforced
68
 
through arrest and not as a result of failure of payment by the Chartererstheir agents or any sub-
69
 
charterers of the Vessel; or
70
 

71
 
(iv)  any security interest created by any security documents granted by the Charterers in relation to the
72
 
Vessel; or
73
   
74
 
(v)   any liens created by or on the instructions or with the prior consent of the Owners.
75
   
76
 
Purchase Optionhas the meaning ascribed to it in Clause 45
77
   
78
 
OwnersPut Optionhas the meaning ascribed to it in Clause 46.
79
   
80
 
QELhas the meaning ascribed to it in Clause 43
81    
82  
“Total Loss” means an actual, constructivecompromised, agreed or arranged total loss of the Vessel under
83
 
the insurances.
84  

85  
Variable Hiremeans the floating part of the Charter Hire identified In Box 17(i)(B).
86  
87 
 
Vesselmeans the vessel described in Box 4 including its equipmentmachineryboilersfixtures and fittings.
88  
  
89  
2. Charter Period
90    
91
 
The Owners have agreed to let and the Charterers have agreed to hire the Vessel for the period stated in
92
 
Box 16 (Charter Period). The Charter Period shall commence simultaneously with delivery of the Vessel by
93
 
the Charterers as sellers to the Owners as buyers under the MOA and subject to the terms and conditions of
94
 
this Charter Party shall end on the date falling eight (8) years from the Delivery Date.
95
   
96
 
The Charterers shall have the option to extend the Charter Period by the period stated in Box 18(i) at the rate
97
 
stated in Box 17(ii), which option shall be exercised by written notice to the Owners latest as stated in Box
98
  18(ii).
99
   
100
  Subject to the terms and conditions herein provided, during the Charter Period the Vessel shall be in the full
101
  possession and at the absolute disposal for all purposes of the Charterers and under their complete control
102
 
in every respect.
103
   
104
3.
Delivery See Clause 3940 and 41
105
   
106
   
107
  (not applicable when Part III applies, as stated in Box 27).

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
108
   
109
(a)  
The Owners shall deliver the Vessel in a seaworthy condition and in every respect ready for service under
110

this Charter Party and in accordance with the particulars stated in Boxes 4 to 6.
111


112

If the Charterers have inspected the Vessel prior to delivery, the Vessel shall be delivered by the Owners in
113

the same condition as at the time of inspection, fair wear and tear excepted.
114


115

The Vessel shall be delivered by the Owners and taken over by the Charterers at the port or place stated in
116

Box 8 at such readily accessible safe berth or mooring as the Charterers may direct.
117
   
118
(b)  
The Vessel shall be properly documented on delivery in accordance with the laws and regulations of the Flag
119

State and the requirements of the Classification Society stated in Box 4. The Vessel upon delivery shall have
120

her survey cycles up-to-date and class certificates valid and unextended for at least the number of months
121

stated in Box 6(i) free of any conditions or recommendations. If Box 6(i) is not filled in, then six (6) months
122

shall apply.
123


124
(c)  
Without prejudice to the Charterer’s rights with respect to any breach by the Owners of (i) this Charter Party 
125

or (ii) any laws and/or sanctions, the delivery of the Vessel by the Owners and the taking over of the Vessel
126

by the Charterers shall constitute a full performance by the Owners of all the Owners’ obligations under this
127

Clause, and thereafter the Charterers shall not be entitled to make or assert any claim against the Owners on
128

account of any conditions, representations or warranties expressed or implied with respect to the Vessel but
129

the Owners shall be liable for the cost of but not the time for repairs or renewals arising out of Latent Defects
130

in the Vessel existing at the time of delivery under this Charter Party, provided such Latent Defects manifest
131

themselves within the number of months after delivery stated in Box 7. If Box 7 is not filled in, then twelve (12)
132

months shall apply.
133


134
4.
Time for Delivery See Clause 39
135


136

(not applicable when Part III applies, as stated in Box 27)
137


138

The Vessel shall not be delivered before the date stated in Box 10 without the Charterers’ consent and the
139

Owners shall exercise due diligence to deliver the Vessel not later than the date stated in Box 11.
140


141

The Owners shall keep the Charterers informed of the Vessel’s itinerary for voyage leading up to delivery
142

and shall serve the Charterers with the number of days approximate/definite notice of the Vessel’s delivery
143

stated in Box 9. Following the tender of any such notices the Owners shall give or allow to be given to the
144

Vessel only such further employment orders as are reasonably expected when given to allow delivery to
145

occur by the date noticed.
146

 
147
5.
Cancelling See Clause 39
148


149

(not applicable when Part III applies, as stated in Box 27)
150


151
(a)  
Should the Vessel not be delivered by the cancelling date stated in Box 11, the Charterers shall have the
152

option of cancelling this Charter Party.
153


154
(b)  
If it appears that the Vessel will be delayed beyond the cancelling date, the Owners may, as soon as they are
155

in a position to state with reasonable certainty the day on which the Vessel should be ready, serve notice thereof
156

to the Charterers asking whether they will exercise their option of cancelling, and the option must then be
157

declared within three (3) Banking Days after receipt by the Charterers of such notice. If the Charterers do
158

not then exercise their option of cancelling, the new date of readiness as notified shall be substituted
159

for the cancelling date stated in Box 11 for the purpose of this Clause 5 (Cancelling).
160


161
(c)  
Cancellation under this Clause 5 (Cancelling) shall be without prejudice to any claim the Charterers may

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
162

otherwise have against the Owners under this Charter Party.

163


164
6.
Familiarisation
165


166
(a)  
The Charterers shall have the right to place a maximum of two (2) representatives on board the Vessel at
167

their sole risk and expense for a reasonable period prior to the delivery of the Vessel.
168


169

The Charterers and the Charterers’ representatives shall sign the Owners’ usual letter of indemnity prior to
170

embarkation.
171


172
(b)  
The Owners shall have the right to place a maximum of two (2) representatives on board the Vessel at their
173

sole risk and expense for a reasonable-period at a convenient port for a maximum of (60) days prior to
174

expected date of  redelivery of the Vessel subject to not causing any disruption to the Vessel’s itinerary or
175

operations.
176


177

The Owners and the Ownersrepresentatives shall sign the Charterers’ usual letter of indemnity prior to
178

embarkation.
179


180
(c)  
Such representatives shall be on board for the purpose of familiarisation and in the capacity of observers only,
181

and they shall not interfere in any respect with the operation of the Vessel and follow the Masters instructions.
182

The Owners representatives while onboard shall be allowed use of the Vessel’s communication systems while
183

on board but such use shall never interfere with the Vessel’s operationCharterer shall cooperate with Owners
184

representatives reasonable comments, requests and questions which they may have for familiarisation
185

purposeCosts for communication to be settled by Owners upon redelivery. This clause shall not apply if the
186

Charterers exercise their Purchase Option as set out in Clause 45 or the Owners exercise their Put Option as
187

set out in Clause 46.
188


189
7.
Surveys on Delivery and Redelivery See Clause 42
190


191
(a)  
The Owners and Charterers shall each appoint and pay for their respective surveyors for the purpose of
192

determining and agreeing in writing the condition of the Vessel at the time of delivery and redelivery hereunder.
193

The Owners shall bear all the Vessel’s expenses related to the on-hire survey including loss of time, if any.
194

The Charterers shall bear all the Vessel’s expenses related to the off-hire survey including loss of time, if any.
195


196
(b)  
Divers’ inspection on delivery/re-delivery
197


198

The Charterers shall have the option at delivery and the Owners shall have the option at redelivery, at their
199

respective time, cost and expense, to arrange for an underwater inspection by a diver approved by the
200

Classification Society, in the presence of a Classification Society surveyor, to determine the condition of the
201

rudder, propeller, bottom and other underwater parts of the Vessel.Not earlier than 45 days or later than 30
202

days or if not possible then as soon as the Vessel becomes available before re-delivery of the Vessel, the
203

Owners and the Charterers shall jointly agree upon the appointment of a surveyor for the purpose of
204

determining the condition of the Vessel at the time of re-delivery hereunder. The surveyor, whose decision
205

shall be final and binding on both parties, shall report in writing, specifying all items, if any, which have not
206

been properly maintained in accordance with the terms and conditions of the Charter and the work required
207

to correct such deficiencies. The costs of such a surveyor shall be equally shared between the parties. In the
208

event that the parties are not able to agree upon a single surveyor, each shall appoint their own and the two
209

surveyors so appointed shall conduct a joint survey of the Vessel. In such an event each party shall pay their
210

own appointed surveyor’s costs. The survey shall be carried out at the point of re-delivery and in Charterers
211

time. Any works required as a result of such survey shall be carried out by Charterers prior to their re-delivery
212

of the Vessel. Charterers shall have the option to pay a compensation based on the surveyors’ assessment
213

to the Owners for any works required instead of performing the required works before redelivery (unless the
214

required works are class affecting). In the event that two surveyors so appointed disagree, the matter shall
215

be referred to arbitration in accordance with Clause 33. This clause shall not apply if the Charterers exercise

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
216

their Purchase Option as set out in Clause 45 or the Owners exercise their Put Option as set out in Clause
217

46.
218


219
8.
Inventories
220


221

A complete inventory of the Vessel’s equipment, outfit, spare parts and consumable stores on board the
222

Vessel shall be made by the parties on delivery and redelivery of the Vessel.
223


224
9.
Bunker fuels, oils and greases
225


226

On redelivery, Owners to pay for all bunkers, fuels and unused lubrication and hydraulic oils and greases in
227

storage tanks and unopened drums in accordance with, either:
228


229

(a)   Charterers’ last invoice price paid (not to be older than 6 months); or otherwise
230


231

(b)   if such invoices are not available on account of the Vessel being employed on sub time charter, the sub-
232

time charter prices; or otherwise
233


234

(c)   the current market price prevailing at the port of redelivery (or, if unavailable, at the nearest bunkering
235

port).
236


237

The Charterers and the Owners, respectively, shall at the time of delivery and redelivery take over and pay
238

for all bunker fuels and unused lubricating and hydraulic oils and greases in storage tanks and unopened
239

drums at:
240


241
(a)*
 The actual price-paid (excluding barging expenses) as evidenced by invoices or vouchers.
242


243
(b)*
The current market price (excluding barging expenses) at the port and date of delivery/redelivery of the Vessel
244

or, if unavailable, at the nearest bunkering port.
245


246

*Subclauses(a)and(b)are alternatives; state alternative agreed in-Box 15 is not filled in, then
247

subclause(a)shall apply.
248


249
10.
Redelivery
250


251

At the expiration of the Charter Period the Vessel shall be redelivered by the Charterers and taken over by
252

the Owners at the port or place stated in Box 12 at such readily accessible safe berth or mooring as the
253

Owners Charterers may direct (acting reasonably).
254


255

The Charterers shall keep the Owners informed of the Vessel’s itinerary for the voyage leading up to
256

redelivery and shall serve the Owners with the number of days approximate/definite notices of the Vessel’s
257

redelivery stated in Box 13.
258


259

The Charterers warrant that they will not permit the Vessel to commence a voyage (including any preceding
260

ballast voyage) which cannot reasonably be expected to be completed in time to allow redelivery of the
261

Vessel within the Charter Period and in accordance with the notices given. Notwithstanding the above, should
262

the Charterers fail to redeliver the Vessel within the Charter Period, the Charterers shall pay the daily
263

equivalent to the rate of hire stated in Box 17(i) applicable at the time plus ten (10) per cent or the market
264

rate, whichever is the higher, for the number of days by which the Charter Period is exceeded. Such payment
265

of enhanced hire rate shall be without prejudice to any claims the Owners may have against the Charterers
266

in this respect.
267

All other termsconditions and provisions of this Charter Party shall continue to apply.
268


269

Subject to the provisions of Clause 13 (Maintenance and Operation), the Vessel shall be redelivered to the

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
270
 
Owners in the same condition and class as that in which it was delivered, fair wear and tear not affecting
271
 
class excepted.
272
 
273
 
The Vessel upon redelivery shall have her survey cycles up lo date and class certificates valid and
274
 
unextended for at least the number of months agreed in Box 6(ii) free of any conditions or recommendations
275
 
by the Classification Society or the relevant authorities at the time of redelivery. If Box 6(1) is not filled in,
276
 
then six (6) months shall apply. 
277

278
 
All plansdrawings and manuals (excluding ISM/ISPS manuals) and maintenance records shall remain on
279
 
board and accessible to the Owners upon redelivery. Any other technical documentation regarding the Vessel
280
 
which may be in the Charterers’ possession shall promptly after redelivery be forwarded to the Owners at
281
 
their expenseif they so request. The Charterers may keep the Vessel’s log books but the Owners shall have
282
 
the right to make copies of the same.
283
   
284
 
This clause shall not apply if the Charterers exercise their Purchase Option in Clause 45 of this Charter Party
285
 
or the Owners exercise their Put Option in Clause 46 in which event a Protocol of Delivery and Acceptance
286
 
will be signed.
287
 
288
11.
 Trading Restrictions
289
 
290
 
The Vessel shall be employed in lawful trades for the carriage of lawful merchandise within the trading limits
291
 
stated in Box 14.
292
 
293
 
The Charterers undertake not to employ the Vessel or allow the Vessel to be employed otherwise than in
294
 
conformity with the terms of the contracts of insurance (including any warranties expressed or implied therein)
295
 
without first obtaining the consent of the insurers to such employment and complying with such requirements
296
 
as to additional premium or otherwise as the insurers may require. In case insurers’ consent is required,
297
 
Charterers will notify the Owners in writing, which notification may be by way of copying in the Owners in the
298
 
Charterers’ relevant notice to the insurers prior to the intended entry into such area, and, upon reasonable
299
 
request by the Owners, furnishing the Owners with the proof of extension of the insurance coverages
300
 
practically obtainable within a reasonable period from such request.
301
 
302
 
The Charterers will not do or permit to be done anything which might cause any breach or infringement of
303
 
the laws and regulations of the Flag State, or of the places where the Vessel trades.
304
 
305
 
Notwithstanding any other provisions contained in this Charter Party it is agreed that nuclear fuels or
306
 
radioactive products or waste are specifically excluded from the cargo permitted to be loaded or carried under
307

this Charter Party. This exclusion does not apply to radio-isotopes used or intended to be used for any
308

Industrial, commercial, agriculturalmedical or scientific purposes provided the Owners’ prior approval has
309

been obtained to loading thereof. 
310

311
12.
Contracts of Carriage
312
 
313
 
(a)  The Charterers are shall use reasonable commercial efforts to procure that all documents issued during
314
 
the Charter Period evidencing the terms and conditions agreed in respect of carriage of goods shall contain
315
 
a paramount clause which shall incorporate the Hague or Hague-Visby Rules unless any other legislation
316

relating to carrier’s liability for cargo is compulsorily applicable in the trade. The documents shall also
317

contain the New Jason Clause and the Both-to-Blame Collision Clause.
318


319
 
(b)  The Charterers are to procure that all passenger tickets issued during the Charter Period for the carriage
320

of passengers and their luggage under this Charter Party shall contain a paramount clause-which shall
321

incorporate the Athens Convention Relating to the Carriage of Passengers and their Luggage by sea, 1974,
322

and any protocol thereto, unless any other legislation relating to carrier’s liability for passengers and their
323

luggage is compulsorily applicable in the trade.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
324
   
325
13.
Maintenance and Operation
326
   
327
(a)
Maintenance
328
 
329
 
During the Charter Period the Vessel shall be in the full possession and at the absolute disposal for all
330
 
purposes of the Charterers and under their complete control in every respect, unless Charter’s Default
331
 
occured. The Charterers shall properly maintain the Vessel in a good state of repairin efficient operating
332
 
condition and in accordance with good commercial maintenance practice andat their own expensemaintain
333
 
the Vessel’s Class with the Classification Society stated in Box 4 and all necessary certificates. The Charterers
334
 
shall have the option to change the Vessel’s Classification Society to any JAGS classification society but time
335
 
and cost to be for Charterers’ account.
336
 
337
(b)
New Class and Other Regulatory Requirements
338


339
 
(i)*     In the event of any structural changes or new equipment becoming necessary for the continued
340
 
operation of the vessel by reason of new class requirements or by compulsory legislation (“Requires
341
 
Modification”) all such costs shall be for the Charterers’ account.
342
 
In the event of any improvement deemed necessary by the Charterers in connection with the operation
343
 
of the Vessel, or structural changes or new equipment being necessary for the continued operation of
344
 
the Vessel by reason of new class requirements or by compulsory legislation, the cost of compliance
345
 
shall be for the Charterers’ account. Notwithstanding the foregoing, Charterers are allowed to make
346
 
improvements to the Vessel provided cost of the same to be for Charterers account.
347
 
348
 
(ii)*    In the event of any structural changes or new equipment becoming necessary for the continued
349
 
operation of the Vessel by reason of a Required Modification, the costs shall be appointed as follows:
350
 
351
 
(1)   if the costs of the Required Modification are less than the amount stated in Box 21(ii), such
352
 
costs shall be for the Charterers’ account;
353
 
354
 
(2)   if the costs of the Required Modification are greater than the amount stated in Box 21(ii), the
355
 
charterers’ portion of costs shall be apportioned using the formula below, all costs other than
356
 
the Charterers’ portion of costs shall be for the Owners’ account.
357


358
 
AMT =agreed amount stated in Box 21(ii)
359
   
360
 
GRM=cost of Required Modification.
361
   
362
 
MEL=modification’s expected life in years
363


364
 
VEL =the Vessel’s expected remainIng life in years stated in Box 21(iii)
365
   
366
 
RPY =remaining Charter period in years
367
 
368
 
(i) If the Required Modification is expected to last for the remaining life of the Vessel, then;
369
 
370
 
Charterers’ portion of costs = CRM/VEL X RPY
371
 
372
 
(ii) If the Requires Modification is not expected to last for the remaining life-of-.the Vessel, then:
373
 
374
 
Charterers’ portion of costs= CRM/MEL x RPY
375
 
376
 
Subclauses 13(b)(i) and 13(b)(ii) are alternatives, state alternative agreed in Box 21(i). If Box 21(i) is not
377
 
filled in, then subclause 13(b)(i) shall apply.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
378
 
379
(c)
Financial Security
380


381
 
The Charterers shall maintain financial security or responsibility in respect of third party liabilities as required
382
 
by any government, including federalstate or municipal or other division or authority thereof, to enable the
383
 
Vessel, without penalty or charge, lawfully to enter, remain at, or leave any port, place, territorial or contiguous
384
 
waters of any country, state or municipality in performance of this Charter Party without any delay. This
385
 
obligation shall apply whether or not such requirements have been lawfully imposed by such government or
386
 
division or authority thereof. The Charterers shall make and maintain all arrangements by bond or otherwise
387

as may be reasonably necessary to satisfy such requirements at the Charterers’ sole expense and the
388

Charterers shall indemnify the Owners against all direct consequences whatsoever (including loss of time)
389

for any failure or inability to do so.
390
   
391
(d)
Operation of the Vessel
392


393
 
The Charterers shall at their own expense crew, victual, navigateoperate, supply, fuel, maintain and repair
394

the Vessel during the Charter Period and they shall be responsible for all costs and expenses whatsoever
395

relating to their use and operation of the Vessel, including any taxes and fees. The Crew shall be the servants
396

of the Charterers for all purposes whatsoevereven if for any reason appointed by the Owners.
397


398
(e)
 Information to Owners
399


400
 
The Charterers shall keep the Owners advised of the intended employment, planned dry-docking and major
401

repairs of the Vessel, as reasonably required by the Owners.
402


403
(f)
Flag and Name of Vessel
404
   
405
 
The Owners have no right to change the name or flag of the Vessel during the Charter Period. During the
406

Charter Period, the Charterers shall have the liberty to paint the Vessel in their own colours, install and display
407

their funnel insignia and fly their own house flagThe Charterers shall also have the liberty, with the Owners’
408

prior written consent, which shall not be unreasonably withheld or delayedto change the flag and/or the name
409
 
of the Vessel during the Charter Period by providing 30 days prior notice to the Owners and such expense
410

shall be for Charterer’s account. In case Charterers do not exercise their Purchase Option as set out in Clause
411
 
45 or the Owners do not exercise their Put Option as set out in Clause 46, painting and re-painting, instalment
412

and re-instalment, registration and re-registration at re-delivery, if required by the Owners, shall be at the
413

Charterers’ expense and time. Any annual tonnage tax plus Agency fee and tonnage tax arising as a result
414

of a flag change undertaken by the Charterers shall be for the account of the Charterers during the Charter
415

period. Change of flag (including Bareboat flag registration) during charter period to be accepted/agreed by
416

Owners and Charterers which to be Charterers’ Account (which agreement not to be unreasonably withheld
417

or delayed).
418
 
Any cost and fee for initial registration of title to the Vessel and legal documentation cost for documenting the
419

lease and security to be Charterers’ account; however such cost not to exceed USD15,000.
420


421
(g)
Changes to the Vessel
422
 
423
 
Subject to-subclause 13(b) (New Class-and Other Regulatory Requirements), the Charterers shall make no
424

structural or substantial changes to the Vessel without the Owner’s prior written approval. If the Owner’s agree
425

to such changes, the Charterers shall, if-the Owners so require, restore the Vessel, prior to redelivery of the
426

Vessel, to its former condition.
427


428
 
Subclause 13(b) notwithstanding, Charterers are permitted to make improvements to the Vessel provided
429
 
cost of same to be for Charterers’ account.
430


431
 
Charterers to inform to the Owners any changes or improvement occurred and to provide any documents or

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
432
 
certificate for such changes or improvement.
433    
434
(h)
Use of the Vessel’s Outfit and Equipment
435    
436  
The Charterers shall have the use of all outfit, equipment and spare parts on board the Vessel at the time of
437   delivery, provided the same or their substantial equivalent shall be returned to the Owners on redelivery in
438   the same good order and condition as on delivery as the inventory (see Clause 8 (inventories))ordinary
439   wear and tear excepted. The Charterers shall from time to time during the Charter Period replace such
440   equipment that become becomes unfit for use. The Charterers shall procure that all repairs to or replacement
441   of any damaged, worn or lost parts or equipment will be effected in such manner (both as regards
442   workmanship and quality of materials, including spare parts) as not to materially diminish the value of the
443   Vessel.
444    
445  
The Charterers have the right to fit additional equipment at their expense and risk but the Charterers shall
446  
remove such equipment at the end of the Charter Period if requested by the Owners (acting reasonably)Any
447  
hired equipment on board the Vessel at the time of delivery shall be kept and maintained by the Charterers
448  
and the Charterers shall assume the obligations and liabilities of the Owners under any lease contracts in
449  
connection therewith and shall reimburse the Owners for all expenses incurred in connection therewith, also
450  
for any new hired equipment required in order to comply with any regulations.
451    
452
(i)
Periodical Dry-Docking
453    
454  
The Charterers shall dry-dock the Vessel and clean and paint her underwater parts whenever the same may
455  
be necessarybut not less than once every sixty (60) calendar months or such other period as may be required
456  
by the Classification Society or Flag State.
457    
458  14.
Inspection during the Charter Period
459    
460  
Not more than once in each calendar year during the Charter Periodthe Owners shall have the right at any
461  
time after giving reasonable notice to the Charterers (provided that such inspection shall not delay or interfere
462  
with the Vessel’s operation and/or trading and/or loading or unloading) to inspect the Vessel or instruct a duly
463  
authorised surveyor to carry out such inspection on their behalf to ascertain its condition and satisfy
464  
themselves that the Vessel is being properly repaired and maintained or for any other reasonable commercial
465  
reason they consider necessary (provided it does not unduly interfere with the commercial operation of the
466  
Vessel)The Owners representative and the surveyor shall sign the Charterers usual letter of indemnity prior
467  
to embarkation.
468    
469  
The fees for such inspections shall be paid for by the Owners. All time used in respect of inspection shall be
470  
for the Charterersaccount and form part of the Charter Period.
471    
472  
The Charterers shall also permit the Owners to inspect the Vessel’s class records, log books, certificates,
473  
maintenance and other records whenever requested and shall whenever required by the Owners when
474  
reasonably required upon the Owners’ request and shall furnish them the Owners with full information
475  
regarding any casualties or other accidents or damage to the Vessel as may be requested by the Owners.
476    
477  15.
Hire
478    
479  (a)
The Charterers shall pay hire due to the Owners punctually in accordance with the terms of this Charter Party.
480    
481
 (b)
The Charterers shall pay to the Owners for the hire of the Vessel a lump sum in the-amount the rate stated in
482  
Box 17(i) which shall be payable not later than monthly every thirty (30) running days in advance, the first lump
483  
sum being payable on the Delivery Date and hour of the Vessel’s delivery to the Charterers subsequent sums
484  
falling due al consecutive monthly periods on the corresponding calendar day thereafter (each such day the
485  
Hire Payment Date”)Hire shall be paid continuously throughout the Charter Periodsubject to the terms of

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
486
 
this Charter PartyEach payment of Fixed Hire shall be deemed to have been applied on receipt by the
487
 
Owners towards reducing the Outstanding Principal.
488
   
489
 (c)
Payment of hire shall be made to the Owners’ bank account stated in Box 20.
490
   
491
 
All payments of Charter hire and any other payments due under this Charter shall be made without any set-
492
 
off whatsoever and free and clear of any withholding or deduction for, or on account of, any present or future
493
 
income, freight, stamp or other taxes, levies, imposts, dutiesfees, chargesrestrictions or conditions of any
494
 
nature unless required by law. If the Charterers are required by any authority in any country to make any
495
 
withholding or deduction from any such payment, the sum due from the Charterers in respect of such payment
496
 
will be increased to the extent necessary to ensure that, after the making of such withholding or deduction the
497
 
Owners receive a net sum equal to the amount which it would have received had no such deduction or
498
 
withholding been required to be made. If tax regulations change during the Charter Periodthe Owners shall
499
 
notify the Charterers as soon as they become aware and will provide reasonable co-operation in order to
500
 
avoid any additional expenses to CharterersHowever, where there is a failure to make punctual payment of
501
 
hire due to oversight, negligenceerrors or omissions on the part of the Charterers or their bankers, the
502
 
Owners shall give the Charterers five (5) Banking Days to rectify the failureand when so rectified within five
503
 
(5) Banking Days following the Ownersnoticethe payment shall stand as regular and punctual. Failure by
504
 
the Charterers to pay hire within five (5) Banking Days of their receiving the Ownersnotice as provided herein,
505
 
shall entitle the Owners to withdraw the Vessel from the service of the Charterers and terminate the Charter
506  
without further notice.
507    
508
(d)
If the Charterers fail to make punctual payment of hire due, the Owners shall give the Charterers threefive
509  
(35) Banking Days written notice to rectify the failure, and when so rectified within those threefive (35) Banking
510  
Days following the Ownersnotice, the payment shall stand as punctual.
511    
512  
Failure by the Charterers to pay hire due in full within threefive (35) Banking Days of their receiving a written
513  
notice from Owners shall entitle the Ownerswithout prejudice to any other rights or claims the Owners may
514  
have against the Charterersto terminate this Charter Party at any time thereafter, as long as hire remains
515
 
outstanding.
516
   
517
(e)
If the Owners choose not to exercise any of the rights afforded to them by this Clause in respect of any
518
 
particular late payment of hire, or a series of late payments of hire, under the Charter Party, this shall not be
519
 
construed as a waiver of their right to terminate the Charter Party.
520
   
521
(f)
Any delay in payment of hire shall entitle the Owners to interest at the rate per annum as agreed in Box 19. If
522
 
Box 19 has not been filled in the one month Interbank offered rate in London (LIBOR or its successor) for the
523
 
currency state in Box 17, as quoted on the date when the hire fell due, increased by three (3) per cent, shall
524
 
apply.
525
   
526
(g)
Payment of interest due under Subclause 15(g) shall be made within seven (7) running days of the date of
527
 
the Ownersinvoice specifying the amount payable or, in the absence of an invoice, at the time of the next
528
 
Hire Payment Date.
529
   
530
(h)
Final payment of hire, if for a period of less than thirty (30) running daysone calendar monthshall be
531
 
calculated proportionally according to the number of days and hours remaining before redelivery to the
532
 
Owners or delivery by the Owners to the Charters should Charterers exercise the Purchase Option or Owners
533
 
exercise the Put Option and advance payment to be effected accordingly.
534
   
535
(i)
The Charterer may prepay the BBC Hire with at least two (2) month prior written notice to the OwnersSuch
536
 
prepayment (the Prepayment Amount’’) shall be in multiples of  USD 1,000,000 (United States Dollars one
537
 
million) and shall be maximum only two times per annum. Any such prepayments shall be applied against the
538
 
Outstanding Charter Hire Principal under this Charter Party and the fixed portion of BBC Hire (as referred as
539
 
Fixed Ratein Box 17 of Part I hereof) shall be recalculated (and reduced pro rata over the remaining BBC

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
540  
Period) with effect from the next month. The amounts of the Purchase Option Prices, Owners Put Option prices
541
 
and Minimum Insured Value shall be correspondingly recalculated (and reduced) according to the
542
 
Outstanding Charter Hire Principal after application of such Prepayment AmountEach such prepayment of
543
 
the Charter Hire shall be permitted only if the Owner/Mortgagee and the Charterer shall mutually agree to the
544
 
amount of the remaining Charter Hire, Purchase Option PriceOwners Put Option Price and Minimum Insured
545
 
Value so recalculated.
546
   
547
(j)
Any moneys required under this Agreement to be paid by the Charterers to the Owners or any of them shall
548
 
be validly paidif paid to the Ownersbank account stated in Box 20and by such payment to the Owners
549
 
bank account stated in Box 20 any payor shall be validly released from its obligation to make such payment.
550
   
551
 16.
Mortgage
552
   
553
 
(only to apply if Box 22 has been appropriately filled in)
554
   
555
 (a)*
 The Owners warrant that they have not effected any mortgage(s) of the Vessel and that they shall not effect
556
 
any mortgage(s) without the prior consent of the charterers, which shall not be unreasonably withheld.
557
   
558
(b)*
Subject to the provisions of any quiet enjoyment letter (includingfor the avoidance of doubtthe QEL), the
559
 
Vessel chartered under this Charter Party is financed by a mortgage according to the Financial Instrument.
560
 
The Charterers undertake upon the written request of the Owners to comply, and provide such customary
561
 
information and documents relating to the Vessel and/or the Charterers as may be reasonably required  to
562
 
enable the Owners to comply with all such instructions or directions in regard to the employment, insurances
563
 
operationrepairs and maintenance of the Vessel as laid down in the Financial Instrument (which Owners
564
 
warrant are always in conformity withand shall not impose any additional obligations on Charterers, with
565
 
regards to employment, insuranceoperationrepairs and maintenance provisions of this Charter Party) or
566
 
as may be directed from time to time during the currency of the Charter Party by the mortgagee(s) in
567
 
conformity with the Financial Instrumentincluding the display or posting of such notices as the Mortgagees
568
 
may requireThe Charterers confirm that, for this-purpose, they have acquainted themselves with all relevant
569
 
terms, conditions and provisions of the Financial Instrument and agree to acknowledge this in writing in any
570
 
form that may be required by the mortgagee(s).The Financial Instrument shall secure an amount of up to the
571
 
Outstanding Principal and shall be enforceable by the Mortgagee only if there has occurred and is continuing
572
 
a CharterersEvent of Default under this Charter Party The Owners warrant that they have not effected any
573
 
mortgage(s) other than stated in Box 22 and that they shall not agree to any amendment of the mortgage(s)
574
 
referred to in Box 22 or effect any other mortgage(s) without the prior consent of the Charterers, which small
575
 
not be unreasonably withheld.
576
   
577
 
*(Optional, Subclauses 16(a) and 16(b) are alternatives; indicate alternative agreed in Box 22)
578
   
579
17.
Insurance See also Clause 47
580
   
581
(a)
General
582
   
583
 
(i) The value of the Vessel for hull and machinery (including increased value) and war risks insurance is the
584
 
sum stated in Box 23, or such other sum as the parties may from time to time agree in writing. The party
585
 
insuring the Vessel shall do so on such terms and conditions and with such insurers as the other party shall
586
 
approve in writing, which approve shall not be unreasonably withheld, and shall name the other party as co
587
 
assured.
588
   
589
 
(ii) [Notwithstanding that the pParties are co-assured]these insurance provisions shall neither exclude nor
590
 
discharge liability between the Owners and the Charterers under this Charter Party, but are intended to secure
591
 
payment of the loss insurance proceeds as a first resort to make good the Owners’ loss. If such payment is
592
 
made to the Owners it shall be treated as satisfaction (but not exclusion or discharge) of the Charterers
593
 
liability towards the Owners. For the avoidance of doubtsuch payment is no bar to a claim by the Owners

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
594
 
and/or their insurers against the Charterers to seek indemnity by way of subrogation
 595    
596
 
(iii) Nothing herein shall prejudice any right of recovery of the Owners or the Charterers (or their insurers)
597
 
against third parties.
598
   
599
(b)*
Charterers to Insure
600
   
601
 
(i) During the Charter Period the Vessel shall be kept insured by the Charterers at their expense against hull
602
 
and machinery, war, and protection and indemnity risks (and any risks against which it is compulsory to insure
603
 
for the operation of the Vessel, including maintaining financial security in accordance with subclause 13(c)
604
 
(Financial Security)).
605
   
606
 
(ii) Such insurances shall be arranged by the Charterers to protect the interests of the Owners and the
607
 
Charterers and the mortgagee(s) (if any), and the Charterers shall be at liberty to protect under such
608
 
insurances the interests of any managers manager they may appoint.
609
   
610
 
(iii) The Charterers shall upon the written request of the Owners, provide information and promptly execute
611
 
such customary documents as may be reasonably required to enable the Owners to comply with the insurance
612
 
provisions of the Financial Instrument, provided that such documents are not prejudicial to the Charterers
613
 
interests.
614
   
615
 (c)*
Owners to Insure
616
   
617
 
(i) During the Charter Period the Vessel shall be kept insured by the Owners at their expense against hull and
618
 
machinery and war risks. The Charterers shall progress claims for reoovery against any third parties for the
619
 
benefit of the Owners’ and the Charterers’ respective interests
620
   
621
 
(ii) During the Charter Period the Vessel shall be kept insured by the Charterers at their expense against
622
 
Protection and Indemity risk (and any risks against which it is compulsory to insure for the operation of the
623
 
Vessel, including maintaining financial security in accordance with subclause 13(c) (Financial Security)
624
   
625
 
(iii) In the-event that any act or negligence of the Charterers prejudices any of the insurances herein provided,
626
 
the Charterers shall pay to the Owners all losses and indemnify the Owners against all claims and demands
627
 
which would otherwise have been covered by such insurances.
628
   
629
 
*Subclauses 17(b) and 17(c) are alternatives, state alternative agreed in Box 24. If Box 24 is not filled in, then
630
 
subclause 17(b) (Charterers to Insure) shall apply.
631
   
632
 18. 
Repairs
633
   
634
(a)
Subject to the provisions of any Financial Instrument, and the approval of the Owners, the Charterers shall
635

effect all the insured repairs, and undertake settlement of all miscellaneous expenses in connection with such
636

repairs as well as all insured charges, expenses and liabilities
637
   
638

To the extent of coverage under the insurances provided for under the provisions of subclause 17(c) (Owners
639
 
to Insure), the Charterers shall be reimbursed under the Owners’ insurances for such expenditures upon
640
 
presentation of accounts.
641
   
642
  (b)
The Charterers shall remain responsible for and effect repairs and settlement of costs and expenses incurred
643

thereby in respect of repairs not covered by the insurances and/o not exceeding any deductibles provided for
644

in the insurances.
645

 
646
 (c)
 All time used for repairs under the provisions of subclauses 18(a) and 18(b) and for repairs of Latent Defects
647

according to Clause 3 (Delivery) above including any deviation, shall be for the Charterer’s account and shall

   

   



Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
648
 
form part of the Charter Period.
649
   
650
19.
Total loss
651
   
652
(a)
The Charterers shall be liable to the Owners by way of damages if the Vessel becomes a Total LossSubject
653
 
to the provisions of any Financial Instrument, if the Vessel becomes a Total Loss, all insurance payments for
654
 
such loss shall be paid in accordance with Clause 47 to the Owners (or the Mortgagees as assignees thereof)
655
 
who shall distribute the monies between the Owners (or the Mortgagees as assignees thereof) and the
656
 
Charterers in accordance with Clause 47according to their respective interests, which (distribution) shall
657
 
satisfy and discharge the Charterersliability to the Owners under the terms hereof. The Charterers undertake
658
 
to notify the Owners and the mortgagee(s), if anyof any occurrences in consequence of which the Vessel is
659
 
likely to become a Total Loss.
660    
661
(b)
Notwithstanding any other clause herein, it is recognised that the Charterers have a continuing obligation to
662
 
protect and preserve the Vessel as an asset of the Owners. The Charterers shall have a continuing duty after
663
 
the termination of the Charter Party to preserve and present claims on behalf of Owners and Charterers and/or
664
 
any subrogated insurers against any third party held responsible for the Total Loss during the Charter Period
665
 
and account for any recovery achieved
666    
667
(c)
 The Owners or the Charterers, as the case may be, shall upon the request of the other pParty (acting
668
 
reasonably)promptly execute such documents as may be required to enable the other pParty to abandon
669
 
the Vessel to the insurers and claim a constructive total loss
670    
671
20.
 Lien
672
   
673
 
The Owners shall have a lien upon all cargoes, hires and freights (including deadfreight and demurrage)
674
 
belonging or due to the Charterers or any sub-charterersor to the extent permitted by law or equity, for any
675
 
amounts due under this Charter Party and the Charterers shall have a lien on the Vessel for all monies paid
676
 
in advance and not earned. The Owners and the Charterers shall provide the amount of any such lien upon
677
 
the other pPartys reasonable request, provided that such request shall not be made by either pParty more
678
 
than twice in any calendar year during the Charter Period
679
   
680
21.
 Non-Lien
681
   
682
 
The Charterers will not suffernor permit to be continued, any lien or encumbrance incurred by them or their
683
 
agents, which might have priority over the title and interest of Owners in the Vessel (other than any Permitted
684
 
Liens).
685
   
686
22.
Indemnity
687
   
688
(a)
The Charterers shall indemnify the Owners against any direct and proven loss, damage or expense arising
689
 
out of or in relation to the operation of the Vessel by the Charterersand against any lien of whatsoever nature
690
 
arising out of an event occurring during the Charter Period (other than a Permitted Lien). This shall include
691
 
indemnity for any direct and proven loss, damage or expense arising out of or in relation to any international
692
 
convention which may impose liability upon the Owners or sanctions implemented by the United Nations,
693
 
European UnionUnited States of America or United Kingdom or Japan.
694
   
695
(b)
Without prejudice to the generality of the foregoingthe Charterers agree to indemnify the Owners against all
696
 
direct and proven consequences or liabilities arising from the Masterofficers or agents signing bills of lading
697
 
or other documents
698    
699
(c)
 If the Vessel is arrested or otherwise detained for any reason whatsoever other than those covered in
700
 
subclause (d), the Charterers shall at their own expense take all reasonable steps to secure that within a
701
 
reasonable time the Vessel is releasedincluding the provision of bail.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
702
   
703
 (d)
If the Vessel is arrested or otherwise detained by reason of a claim or claims against the Owners and/or any
704
 
other company or other entity which belongs to the same group of companies of which the Owners are part,
705
 
or which is otherwise associated or related loor affiliated withthe Owners, the Owners shall at their own
706
 
expense take all reasonable steps to secure that within a reasonable time the Vessel is released, including
707
 
the provision of bail. If within a 45 days period after such arrest or detainmentthe Vessel is not so released,
708
 
the Charterers may, at their option but without obligation to do sotake all necessary steps to obtain such
709
 
releaseand all expenses of the Charterers in connection therewith shall be reimbursed by the Owners on
710
 
demandand the Owners shall take reasonable steps to minimise any costs to the Charterer arising out of
711
 
any such arrest.
712
 
713
 
In such circumstances the Owners shall indemnify the Charterers against any lossdamage or expense
714
 
incurred by the Charterers (including hire paid under this Charter Party) as a direct consequence of such
715
 
arrest or detention. 
716    
71’7
(e)
The indemnities of the Charterers under this Clause 22 shall not extend to events occurring after the end of
718
 
Charter Periodbut as to any event occurring before the end of the Charter Period shall continue in full force
719
 
and effect notwithstanding the termination of the chartering of the Vessel under this Charter Party for any
720

reason until four (4) years from the early termination of this Charter or the end of the Charter Period or the
721
 
sale of the Vessel by the Owners to any personprovided that if, prior to the expiry of the aforesaid period of
722
 
four (4) yearsany event or dispute arises in respect of which the Owners are to be indemnified under this
723
 
Clause 22the indemnities of the Charterers under this Clause 22 shall continue in full force and effect until
724
 
the Owners have been fully indemnified in accordance with this Clause 22.
725
   
726
(f)
The Owners will notify the Charterers as soon as they become aware of any claim against the Owners which
727
 
may give rise to indemnification under this Clause 22The Owners will not settle any claims or discharge any
728
 
court judgments in respect of any claim unless it has first negotiated with the Charterers in good faith for a
729
 
reasonable period of timeprovided that the Owners may settle any claim or discharge any court judgment if
730
 
failure so to do would give rise to substantial losses or damages for, or reputational damage tothe Owners.
731
   
732
(g)
The Owners will notand the Charterers willbe responsible for the conduct of any claim or potential claim that
733
 
may give rise to an indemnity liability of the Charterers under this Clause 22 and the Charterers may be entitled
734
 
(at their own cost and expense) to take such actions as they may reasonably deem fit to defend or avoid
735
 
liability under any such claim or take action against any third party in respect of liability under any such claim.
736
   
737
(h)
 The Charterer to undertake to the Owner and the Owners Financiers to protectcover, compensate for any
738
 
claimdamage and loss caused by oil pollution and any cargo claim (clean or dirty).
739
   
740
23.
 Salvage
741
   
742
 
All salvage and towage performed by the Vessel shall be for the Charterers’ benefit and the cost of repairing
743
 
damage occasioned thereby shall be borne by the Charterers. 
744    
745
24.
 Wreck Removal
746
 
747
 
If the Vessel becomes a wreck, or any part of the Vessel is lost or abandonedand is an obstruction to
748
 
navigation or poses a hazard and has to be raised, removed, destroyedmarked or lit by order of any lawful
749
 
authority having jurisdiction over the area or as a result of any applicable law, the Charterers shall be liable
750
 
for any and all direct and documented expenses in connection with raising, removal, destructionlighting or
751
 
making of the Vessel and shall indemnify the Owners against any direct and proven sums whatsoever, which
752
 
the Owners become liable to pay as a consequence
753    
754
25.
General Average
755    
                
Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
756

The Owners shall not contribute to General Average.
757


758
26.
Assignment, Novation, Sub-Charter and Sale See also Clauses 43 and 44
759


760
(a)
The Charterers shall not assign or novate this Charter Party nor sub-charter the Vessel on a bareboat basis
761

except with the prior consent in writing of the Owners, which shall not be unreasonably withheld or delayed,
762

and subject to such terms and conditions as the Owners shall approve.
763


764
(b)
 See also Clauses 43 and 44. The Owners shall not sell the Vessel during the currency of this Charter Party
765

except with the prior written consent of the Charterers, which shall not be unreasonably withheld, and subject
766

to the buyer accepting a novation of this Charter Party.
767


768
(c)   
The Owners shall be entitled to assign their rights under this Charter Party.
769


770
27.
Performance Guarantee See Clause 43
771


772

(Optional, to apply only if Box 25 filled in)
773


774

The Charterers undertake to furnish, before delivery of the Vessel, a guarantee or bond in the amount of and
775

from the entity stated in Box 25 in a form acceptable to the Owners as guarantee for full performance of their
776

obligations under this Charter Party.
777


778
28.
Anti-Corruption
779


780
(a)
The pParties agree that in connection with the performance of this Charter Party they shall each:
781


782

(i) comply at all times with all applicable anti-corruption legislation and have procedures in place that areto
783

the best of its knowledge and belief, designed to prevent the commission of any offence under such legislation
784

by any member of its organisation and/or by any person providing services for it or on its behalf; and
785


786

(ii) make and keep books, records, and accounts which in reasonable detail accurately and fairly reflect the
787

transactions in connection with this Charter Party.
788


789
(b)
If either pParty fails to comply with any applicable anti-corruption legislation, it shall defend and indemnify the
790

other pParty against any finepenalty, liabilityloss or damage and for any related costs (includingwithout
791

limitation, court costs and legal fees) arising from such breach.
792


793
(c)
Without prejudice to any of its other rights under this Charter Party, either pParty may terminate this Charter
794

Party without incurring any liability to the other pParty if:
795


796

(i) at any time the other pParty or any member of its organisation has committed a breach of any applicable
797

anti-corruption legislation in connection with this Charter Party; and
798


799

(ii) such breach causes the non-breaching pParty to be in breach of any applicable anti-corruption legislation.
800


801

Any such right to terminate must be exercised without undue delay.
802


803
(d)
Each pParty represents and warrants that in connection with the negotiation of this Charter Party neither it
804

nor any member of its organisation has committed any breach of applicable anti-corruption legislation. Breach
805

of this subclause (d) shall entitle the other pParty to terminate the Charter Party without incurring any liability
806

to the other.
807


808
29.
Sanctions and Designated Entitles
809



Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
810
(a)
The provisions of this clause shall apply in relation to any applicable sanction, prohibition or restriction
811

imposed on any specified persons, entitles or bodies including the designation of specified vessels or fleets
812

and Owners or Charterers under United Nations Resolutions or trade or economic applicable sanctions, laws
813

or regulations of the European Union or the United States of America or the United Kingdom or Japan.
814


815
(b)
The Owners and Charterers respectively warrant for themselves (and in respect of any sub-charterer or
816

manager which belongs to the same group of companies of which the Charterers are partthe Charterers
817

hereby undertake to take necessary steps to ensure) (and in the case of any sub-charter, the Charterers
818

 further warrant in respect of any sub-charterers, shippers, receivers, or cargo interests) that at the date of this
819

fixture and throughout the duration of this Charter Party they are not subject to any of the sanctions,
820

prohibitions, restrictions or designation referred to in subclause (a) which prohibit or render unlawful any
821

performance under this Charter Party.The Owners further warrant that the Vessel is not a designated vessel.
822


823
(c)
If at any time during the performance of this Charter Party either pParty becomes aware that the other pParty
824

is in breach of warranty in this Clausethe pParty not in breach shall comply with the laws and regulations of
825

any Government to which that pParty or the Vessel is subject, and follow any orders or directions which may
826

be given by any body acting with powers to compel compliance, including where applicable the OwnersFlag
827

State. In the absence of any such orders, directions, law or regulationsthe pParty not in breach mayin its
828

optionterminate the Charter Party forthwith in accordance with Clause 31 (Termination). However, In the
829

event that a sub-charterer managing or other parties who have any contractual relationships with the
830

Charterers in respect of the Vessel are subject to sanctionsprohibitionsrestrictions or designation referred
831

to in subclause (a)Owners may not terminate the Charter Party before giving Charterers a reasonable period
832

to take necessary measures to remedy such breach and to ensure such a breach does not continue.
833


834
(d)
Ifin compliance with the provisions of this Clauseanything is done or is not done, such shall not be deemed
835

a deviation but shall be considered sue fulfilment of this Charter Party.
836


837
(e)
Notwithstanding anything in this Clause to the contrarythe Owners or the Charterers shall not be required to
838

do anything which constitutes a violation of the laws and regulations of any state to which either of them is
839

subject.
840


841
(f)
The Owners or the Charterers shall be liable to indemnify the other pParty against any and all direct and
842

proven claims, lossesdamagecosts and fines whatsoever suffered by the other pParty resulting from any
843

breach of warranty in this ClauseIf such calling constitutes a breach of sanctions, then Charterers to
844

undertake to indemnify Owners against all direct and proven Joss and costs sustained as a result of such
845

violationCharterers shall indemnify the Owners and hold the Owners harmless in respect of any direct and
846

proven liability, lossdamage or expenses of whatsoever nature which the Owners may sustain resulting from
847

the operation of the Vessel (including but not limited to hereunder those arising from Vessel entering/operating
848

in war area or warlike area).
849
   
850
30.
Requisition/Acquisition
851
   
852 (a)
 In the event of the requisition for hire of the Vessel by any governmental or other competent authority at any
853
time during the Charter Period, this Charter Party shall not be deemed to be frustrated or otherwise terminated.
854

The Charterers shall continue to pay hire according to the Charter Party until the time when the Charter Party
855

would have expired or terminated pursuant to any of the provisions hereof. Howeverif any requisition hire or
856

compensation is received by the Owners for the remainder of the Charter Period or the period of the requisition,
857

whichever is shorter, it shall be payable by the Owners to the Charterers.
858


859
(b)
In the event of the Owners being deprived of their ownership in the Vessel by any compulsory acquisition of
860

the Vessel or requisition for title by any governmental or other competent authority (hereinafter referred to as
861

“Compulsory Acquisition”)thenirrespective of the date during the Charter Period when Compulsory
862

Acquisition may occur, this Charter Party shall be deemed terminated as of the date of such Compulsory
863

AcquisitionIn such event hire to be considered as earned and to be paid up to the date and time of such

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
864
 
Compulsory Acquisition. The Owners shall be entitled to any compensation received for such Compulsory
865
 
Acquisitionwhich shall be applied towards reducing the Outstanding Principal.
866
   
867
31.
 Termination
868
 
869
(a)
 Charterers’ Default
870
   
871
 
The Owners shall be entitled to terminate this Charter Party by written notice to the Charterers and to claim
872
 
damages including, but not limited to, for the loss of the reminder remainder of the Charter Party under the
873
 
following circumstanceseach of which shall be a “Charterers’ Event of Default” for the purposes of this
874
 
Charter Partyand to claim damages including,-but-not limited to, for the loss of the reminder--remainder of the
875
  Charter Party:
876
   
877
 
(i) Non-payment of hire (see Clause15 (Hire))subject to all applicable grace periods.
878


879
 
(ii) Charterers’ failure to comply with the requirements of:
880
   
881
 
(1) 
Clause 11 (Trading Restrictions); or
882
   
883
 
(2)  
Subclause 17(b) (Charterers to Insure)
884
 
885
 
andif capable of remedy, such requirement is not remedied within 30 days of the earlier of the date on which
886
 
(A) the Charterers became aware of the failure to comply and (B) the Charterersreceived the Owners’ written
887
 
notification to do so.
888
   
889
 
(iii) The Charterers do not rectify any failure to comply with the requirements of subclause 13(a) (Maintenance)
890
 
as soon as practically possible after the Owners have notified them to do sounlessand in any event so that
891
 
the Vessel’s insurance cover is not prejudiced by such failure.
892
   
893
 
(iv) If the Charterers are in breach of any material provisions of this Charter Party other than those referred
894
 
to in Clause 31 (a)(i)(ii) and (iii) above, and if capable of remedy, such breach is not rectified by the Charterers
895
 
within 30 days of the earlier of the date on which (A) the Charterers became aware of the failure to comply
896
 
and (B) the Charterersreceived the Ownerswritten notification do to so
897    
898
(b)
 Owners’ Default
899
 
900
 
The Charterers shall be entitled to terminate this Charter Party with immediate effect by written notice to the
901
 
Owners and to claim damages includingbut not limited tofor the loss of the remainder of the Charter Party:
902
   
903
 
(i) If the Owners shall by any act or omission be in breach of their obligations under this Charter Party to the
904
 
extent that the Charterers are deprived of the useoperation, possession or enjoyment of the Vessel and such
905
 
breach continues for a period of fourteenthirty (1430) running days after written notice thereof has been given
906
 
by the Charterers to the Owners; or
907    
908
 
(ii) if the Owners fail to arrange or maintain the insurances in accordance with subclause17(c) (Owners to
909
 
Insure).
910
   
911
(c)
Loss of Vesse
912    
913
 
This Charter Party shall be deemed to be terminatedwithout prejudice to any accrued rights or obligations,
914
 
if the Vessel becomes lost either when it has become an actual total loss or agreement has been reached
915
 
with the Vessels underwriters in respect of its constructive total loss or if such agreement with the Vessel’s
916
 
underwriters is not reached it is adjudged by a competent tribunal that a constructive loss of the Vessel has
917
 
occurred, or has been declared missingThe date upon which the Vessel is to be treated as declared missing

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
918
 
shall be ten (10) days after the Vessel was last reported or when the Vessel is recorded as missing by the
919
 
Vessels underwriters, whichever occurs first.
920    
921
(d)
Bankruptcy
922
   
923
 
Either pParties shall be entitled to terminate this Charter Party with immediate effect by written notice to the
924
 
other pParties if that other pParties has a petition presented for its winding up or administration or any other
925
 
action is taken with a view to its winding up (otherwise than for the purpose of solvent reconstruction or
926
 
amalgamation), or becomes bankrupt or commits an act of bankruptcy, or makes any arrangement or
927
 
composition for the benefit or creditors, or has a receiver or manager or administrative receiver or
928
 
administrator or liquidator appointed in respect of any of its assets, or suspends payments, or anything
929
 
analogous to any of the foregoing under the law of any jurisdiction happens to it, or ceases or threatens to
930
 
cease to carry on business.
931    
932
(e)
The termination of this Charter Party shall be without prejudice to all rights accrued due between the pParties
933
 
prior to the date of termination and to any claim that pParty might have
934    
935
32.
 Repossession
936
   
937
 
In the event of the early termination of this Charter Party in accordance with the applicable provisions of this
938
 
Charter Party, the Owners shall have the right to repossess the Vessel from the Charterers at its current or
939
 
next port of call, or at a port or place convenient to them without hindrance or interference by the Charterers,
940
 
courts or local authoritiesPending physical repossession of the Vesselthe Charterers shall hold the Vessel
941
 
as gratuitous bailee only to the OwnersThe Owners shall arrange for an authorised representative to board
942
 
the deemed to be repossessed by the Owners from the Charterers upon the boarding of the Vessel by the
943
 
Owners’ representativeAll arrangements and expenses relating to the settling of wagesdisembarkation and
944
 
repatriation of the Crew shall be the sole responsibility of the Charterers. 
945    
946
33.
 BIMCO Dispute Resolution Clause 2017
947


948
(a)*
This Charter Party shall be governed by and construed in accordance with English law and any dispute arising
949
 
out of or in connection with this Charter Party shall be referred to arbitration in London in accordance with
950
 
the Arbitration Act 1996 or any statutory modification or re-enactment thereof save to the extent necessary to
951
 
give effect to the provisions of this Clause.
952    
953
 
The arbitration shall be conducted in accordance with the London Maritime Arbitrators Association (LMAA)
954
 
Terms current at the time when the arbitration proceedings are commenced.
955
 
956
 
The reference shall be to three arbitrators. A pParty wishing to refer a dispute to arbitration shall appoint its
957
 
arbitrator and send notice of such appointment in writing to the other pParty requiring the other pParty to
958
 
appoint its own arbitrator within fourteen (14) calendar days of that notice and stating that it will appoint its
959
 
arbitrator as sole arbitrator unless the other pParty appoints its own arbitrator and gives notice that it has done
960
 
so within the fourteen (14) days specified. If the other pParty does not appoint its own arbitrator and give
961
 
notice that it has done so within the fourteen (14) days specifiedthe pParty referring a dispute to arbitration
962
 
may, without the requirement of any further prior notice to the other pParty, appoint its arbitrator as sole
963
 
arbitrator and shall advise the other pParty accordingly. The award of the sole arbitrator shall be binding on
964
 
both pParties as if he had been appointed by agreement.
965    
966
 
Nothing herein shall prevent the pParties agreeing in writing to vary these provisions to provide for the
967
 
appointment of a sole arbitrator.
968    
969
 
In cases where neither the claim nor any counterclaim exceeds the sum of USD 100,000 (or such other sum
970
 
as the pParties may agree) the arbitration shall be conducted in accordance with the LMAA Small Claims
971
 
Procedure current at the time when the arbitration proceedings are commenced.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
972
   
973
 
In cases where the claim or any counterclaim exceeds the sum agreed for the LMAA Small Claims Procedure
974
 
and neither the claim nor any counterclaim exceeds the sum of USO 400,000 (or such other sum as the
975
 
pParties may agree) the arbitration shall be conducted in accordance with the LMAA Intermediate Claims
976
 
Procedure current at the time when the arbitration proceedings are commenced.
977
   
978
(b)* This Charter Party shall be governed by U.S. maritime law or, if this Charter Party is not a maritime contract
979
 
under U.S. law, by the laws of the state of New York. Any dispute arising out of or in connection with this
980
 
Charter Party shall-be referred to three (3) persons at New York, one to be appointed by each of the parties
981
 
hereto, and the third by the two so-chosen. The decision of the arbitrators or any two of them shall be final,
982
 
and for the purposes of enforcing any award, judgment may be entered on an award by any court of
983
 
competent jurisdiction. The proceedings shall be conducted in accordance with the SMA Rules current as of
984
 
the date of this Charter Party. 
985    
986
 
In cases where neither the claim nor any counterclaim exceeds the sum of USD 100,000 (or such other sum
987
 
as the parties may agree) the arbitration shall be conducted in accordance with the SMA Rules for Shortened
988
 
Arbitration Procedure current as of the date of this-Charter Party.
989
   
990
(c)* This charter Party shall be governed by-and construed in accordance with Singapore**/English**law.
991
   
992
 
Any dispute arising out of or in connection with this Charter Party, including any question regarding its
993
 
existence, validity or termination shall be referred to and finally resolved by arbitration in Singapore in   
994
  accordance with the Singapore lnternational Arbitration Act (Chapter143A) and any statutory modification or
995   re-enactment thereof save to the extent necessary to give effect to the provisions of this Clause.
996


997
 
The arbitration shall be conducted in accordance with the Arbitration Rules of the Singapore Chamber of
998
 
Maritime Arbitration (SCMA) current at the time when the arbitration proceedings are commenced. 
999
   
1000
 
The reference to arbitration of disputes under this Clause shall be to three arbitrators. A party wishing to refer
1001
 
a dispute to arbitration shall appoint its arbitrator and send notice of such appointment in Writing to the other
1002
 
party requiring the other party to appoint its own arbitrator and give notice that it has done so within fourteen
1003
 
(14) calendar days of that notice and stating that it will appoint its own arbitrator as sole arbitrator unless the
1004
 
other party appoints its own arbitrator and gives notice that it has done so within the fourteen (14) days
1005
 
specified. If the other party does not give notice that it has done so within the fourteen (14) days specified,
1006
 
the party referring a dispute to arbitration-may, without the requirement of any further prior notice to the other
1007
 
party, appoint its arbitrator as sole arbitrator and shall advise the other party accordingly. The award of a sole
1008
 
arbitrator shall be binding on both parties as if he had been appointed by agreement.
1009
   
1010
 
Nothing herein shall prevent the parties agreeing in writing to vary these provisions to provide for the
1011
 
appointment of a sole arbitrator. 
1012  
1013
 
In cases where neither the claim nor any counterclaim exceeds the sum of USD 150,000 (or such ether sum
1014
 
as the parties may agree) the arbitration shall be conducted before a single-arbitrator in accordance with the
1015
 
SCMA Small Claims Procedure current at the time when the arbitration proceedings are commenced.
1016
 
1017
 
**Delete whichever does not apply. If neither or both are deleted, then English law shall apply by default.
1018    
1019
(d)* This Charter Party shall be governed by and construed in accordance with the laws of the place mutually
1020
 
agreed by the Parties and any dispute arising out of or in connection with this Charter Party shall be referred
1021
 
the arbitration at a mutually agreed place, subject to the procedures applicable there.
1022
   
1023
 
(e) The pParties may agree at any time to refer to mediation any difference and/or dispute arising out of or in
1024
 
connection with this Charter PartyIn the case of any dispute in respect of which arbitration has been
1025
 
commenced under subclause (a), (c) or (d)the following shall apply:

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
1026
   
1027
 
(i) Either pParty may at any time and from time to time elect to refer the dispute or part of the dispute to
1028

meditation by service on the other pParty of a written notice (the Mediation Notice”) calling on the other
1029  
pParty to agree to mediation.
1030
   
1031
 
(ii) The other pParty shall thereupon within fourteen (14) calendar days of receipt of the Mediation Notice
1032
 
confirm that they agree to mediation, in which case the pParties shall thereafter agree a mediator within a
1033   further fourteen (14) calendar days, falling which on the application of either pParty a mediator will be
1034
  appointed promptly by the Arbitration Tribunal(” the Tribunal”) or such person as the Tribunal may designate
1035
  for that purposeThe mediation shall be conducted in such place and in accordance with such procedure and
1036
  on such terms as the pParties may agree or, in the event of disagreement, as may be set by the mediator.
1037
   
1038
 
(iii) If the other pParty does not agree to mediate, that fact may be brought to the attention of the Tribunal and
1039
 
may be taken into account by the Tribunal when allocating the costs of the arbitration as between the pParties.
1040
   
1041
 
(iv) The mediation shall not affect the right of either pParty to seek such relief or take such steps as it considers
1042

necessary to protect its interest.
1043    
1044
 
(v) Either pParty may advise the Tribunal that they have agreed to mediationThe arbitration procedure shall
1045
 
continue during the conduct of the mediation but the Tribunal may take the mediation timetable into account
1046
 
when setting the timetable for steps in the arbitration.
1047
   
1048
 
(vi) Unless otherwise agreed or specified in the mediation termseach pParty shall bear its own costs incurred
1049
 
in the mediation and the pParties shall share equally the mediator’s costs and expenses.
1050
   
1051
 
(vii) The mediation process shall be without prejudice and confidential and no information or documents
1052
 
disclosed during it shall be revealed to the Tribunal except to the extent that they are disclosable under the
1053
 
law and procedure governing the arbitration.
1054    
1055
 
(Note: The pParties should be aware that the mediation process may not necessarily interrupt time limits.)
1056
   
1057
 
*Subclauses (a)(b), (c) and (d) are alternatives; indicate alternative agreed in Box 26.
1058
   
1059
 
If Box 26 in Part I is not appropriately filled in, subclause (a) of this Clause-shall apply. Subclause (e) shall
1060
 
apply in all cases except for alternative (b) 
1061  
1062
34.
Notice
1063
   
1064
 
All notices, requests and other communications required or permitted by any clause of this Charter Party
1065
 
shall be given in writing and shall be sufficiently given or transmitted if delivered by hand, email, express
1066   courier service or registered mail and addressed if to the Owners as stated in Box 30 or such other address
1067   or email address as the Owners may hereafter designate in writing, and if to the Charterers as stated in Box
1068   31 or such other address or email address as the Charterers may hereafter designate in writingAny such
1069  
communication shall be deemed to have been given on the date of actual receipt by the pParty to which it is
1070
 
addressed.
1071
   
1072
35.
Partial Validity
1073
   
1074
 
If by reason of any enactment or judgment any provision of this Charter Party shall be deemed or held to be
1075
 
illegal, void or unenforceable in whole or in part, all other provisions of this Charter Party shall be unaffected
1076  
thereby and shall remain in full force and effect.
1077
   
1078
36.
 Entire Agreement
1079
 

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART II
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
1080
 
 This Charter Party is the entire agreement of the partieswhich supersedes all previsions written or oral
1081  
understandings and which may not be modified except by a written amendment signed by both parties.
1082
   
1083
37.
Headings
1084
   
1085
 
The headings of this Charter Party are for identification only and shall not be deemed to be part hereof or be 
1086  
taken into consideration in the interpretation or construction of this Charter Party.
1087
   
1088
38.
 Singular/Plural
1089
   
1090
 
The singular includes the plural and vice versa as the context admits or requires

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART III
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
PROVISIONS TO APPLY FOR NEWBUILDING VESSELS ONLY
(OPTINAL, only applicable if 27 has been completed)
1091
1.
Specifications and Building Contract
1092
   
1093
(a)   The Vessel shall be constructed in accordance with the building contract between the Builders and the Owners
1094
 
including the specifications and plans incorporated therein (“Building Contract”). The Owners shall provide
1095
 
the Charterers with copy of the Building Contract to the extent relevant to this Charter Party.
1096
   
1097
(b)   No variations shall be made to the Building Contract without the Charterers’ prior written consent. The
1098
 
Charterers shall be entitled to request change orders in accordance with the Building Contract. Any additional
1099  
costs or consequences due to Charterers’ change orders shall be borne by the Charterers. 
1100
   
1101
(c)    The Owners and the Charterers will liaise and cooperate in all matters regarding the construction of the Vessel
1102
 
and the Building Contract. The Charterers shall have the right to send their representative to the Builders’
1103
 
yard to inspect the Vessel during its construction.
1104
   
1105
(d)   The Owners shall assign their guarantee rights under the Building Contract to the Charterers, if permitted. If
1106
 
not permitted, the Owners shall exercise their guarantee rights against the Builders for the benefit of the
1107   Charterers. The Charterers shall be obliged to accept such sums as the Owners are reasonably able to
1108
 
recover under the guarantee provisions of the Building Contract.
1109
   
1110
2.      Delivery and Cancellation
1111
 
1112   
(a)   (i) Subject to the provisions of Clause 3 (Liquidated Damages) hereunder, the Charterers shall be obliged to
1113
 
accept the Vessel from the Owners, constructed and delivered in accordance with the Building Contract and 
1114   including buyers supplies, on the date of delivery  by the Builders. The Charterers undertake that having
1115   accepted the Vessel they will not thereafter raise any claims against the Owners in respect of the Vessel’s
1116  
performance or specification of defects, if any:
1117

 
1118

(ii) The date of delivery for purpose of this Charter shall be the date (“the Delivery Date”) when the Vessel is
1119

 in fact delivered by the Builders to the Owners in accordance  with the Building Contract, whether that is before 
1120
or after the scheduled delivery date under the Building Contract. The Owners shall be under no responsibility.
1121
for any delay whatsoever in delivery of the Vessel to the Charterers under this Charter Party, except to the 
1122
extent caused solely by the Owners’ acts or omissions resulting in a default by the Owners under the Building
1123
Contract. The Owners shall be responsible to the Charterers for any direct losses incurred by the Charterers,
1124

if the Vessel is not delivered to the Owners due solely to the Owners’ acts or omissions resulting in a default
1125

by-the Owners under the Building Contract.
1126

1127
(iii) The Owners and the Charterers shall on the Delivery Date sign a Protocol of Delivery and Acceptance
1128

evidencing delivery of the Vessel hereunder.
1129

 
1130
(b)   (i) The Owners’ obligation to charter the Vessel to the Charterers hereunder is conditional upon delivery of
1131

the Vessel to the Owners by the Builders in accordance with the Building Contract.
1132


1133

(ii) If for any reason other than a default by the under the Building Contract, the Builders become
1134
entitled under that Contract not to deliver the Vessel and exercise that right, the Owners shall be entitled to
1135

cancel this Charter Party-by written notice to the Charterers.
1136


1137

(iii) If for any reason the Owners become entitled to cancel the Building Contract and exercise that right, the
1138

Owners shall be entitled to cancel this Charter Party by written notice to the Charterers. If, however, the 
1139
Owners do not exercise their right to cancel the Building Contract, the Charterers shall be entitled to cancel
1140
this Charter Party by written notice to the Owners.
1141


1142
3.     Liquidated Damages
1143

 
1144
(a)    Any liquidated damages for physical defects or deficiencies and any costs incurred in pursuing a claim therefor

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART III
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
PROVISIONS TO APPLY FOR NEWBUILDING VESSELS ONLY
(OPTINAL, only applicable if 27 has been completed)
1145
 
shall be created in Box 27(iv) or if not filled in shall be shared equally between the parties.
1146
 
1147
(b)
Any liquidated damages for delay in delivery under the Building Contract and any costs incurred in pursuing
1148
 
a claim therefor shall be credited to the party stated in Box 27(v) or if not filled in shall be shared equally
1149
 
between the parties.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART IV
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
PURCHASEOPTION
(OPTINALonly applicable if Box 28 has been completed)

1150
See Clause 45
1151
1.  The Charterers shall have an option to purchase the Vessel (the “Purchase Option”) exercisable on each of
1152

the dates stated below as follows:
1153
   

  Date (state number of months after delivery of the Vessel)
  Purchase Price (the “Purchase Option Price”)
 



(months)
  (amount and currency)

 










1154
   
1155
2.     To exercise their Purchase Option, the Charterers shall notify the Owners in writing not later than six (6) 
1156

months prior to the relevant date stated In the table above. Such notification shall not be withdrawn or
1157

cancelled
1158
   
1159
3.     If theCharterers exercise their Purchase Option, the ownership of the Vessel shall be transferred to them on 
1160

the relevant date. If such date is not Banking Day, the-ownership of the Vessel shall be transferred on the 
1161

next Banking Day, on a strictly “as is/where is” basis, at-the Charterers’ sole cost and expense.
1162
   
1163
4.     The Owners shall-obtain and provide the Charterers with such-documents and take such actions as the 
1164

Charterers may reasonably request to facilitate the sale and the registration of the Vessel under the flag 
1165

designated by the Charterers.
1166
   
1167
5.     The Owners warrant that the Vessel at the time of transfer of ownership shall be free of any of Owners
1168

encumbrance or mortgage and that they have not committed any act or omission which would impair title to 
1169

the Vessel.
1170
   
1171
6-     The Owners make no representation or warranty as to the seaworthiness, value, condition, design, 
1172
  merchantability or operation of the Vessel, or as to the quality of the material, equipment or workmanship in .
1173
  the Vessels, or as to the fitness of the Vessel for any particular trade.
1174
   
1175
7.      In exchange for the transfer of ownership of the Vessel, the Charterers shall pay the Purchase Option Price.
1176

to the bank account nominated by the Owners together with any unpaid charter hire and other amounts due 
1177

and payable under this Charter Party.
1178
   
1179
8.     Upon payment and transfer of ownership in accordance with Clause 7 above, this Charter Party and all rights
1180

and obligations of the parties shall terminate without prejudice to all rights accrued due between the parties
1181

 prior to the date of termination and any claim that either party might have.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

PART V
BARECON 2017 STANDARD BAREBOAT CHARTER PARTY
PROVISIONS TO APPLY FOR VESSELS REGISTERED IN A BAREBOAT CHARTER REGISTRY
(OPTIONAL, only to apply if expressly agreed and stated in Box 29)

1182
1.     Definitions
1183
 
1184
 
“Bareboat Charter Registry” shall mean the registry stated in Box 29(ii) whose flag the Vessel will fly and in 
1185
  which the Charterers are registered as the bareboat charterers during the period of this Charter Party.
1186
   
1187
 
“Underlying Registry’’ shall mean the registry slated in Box 29(i) in which the Owners of the Vessel are
1188
   registered as Owners and to which jurisdiction and control of the Vessel will revert upon termination of the
1189
 
Bareboat Charter registration.
1190
   
1191
 2.    The Owners have agreed to and the Charterers shall arrange for the Vessel to be registered under the 
1192
  Bareboat Charter Registry. The Charterers shall be responsible for all costs thereof.
1193
   
1194
3.     Upon termination of this Charter Party for any reason whatsoever the  Charterers shall immediately arrange
1195
  for the deletion of the Vessel from the Bareboat Registry.
1196
   
1197
4.     ln the event of the Vessel being deleted from the Bareboat Charter Registry due to any default by the Owners,
1198
  the Charterers shall have the right terminate this Charter forthwith and without prejudice to any other claim 
1199
  they may have against the Owners under this Charter Party.

Copyright © 2017 Norwegian Shipbrokers’ Association.
All rights reserved.

Exhibit 4.31B

Rider Clauses 39 to 54
to be deemed incorporated to the
Bareboat Charter Party
Dated 05 March 2025
(the “Charter”)
Between

GUADELOUPE SHIPPING COMPANY INCas Charterers
T.A.C.K. SHIPPINGS.A. as Owners
in respect of the vessel

MT “HULL H1597tbn P. MARSEILLE


39.
Delivery
 
(a) This Charter Party constitutes the lease financing of the Vessel which is currently under construction under the Building Contract for the account of the Charterers, and to be sold to the Owners as finance lessor under the MOA.
 
The Owners’ obligations to charter the Vessel to the Charterers hereunder are conditional upon (i) delivery of the Vessel to the Charterers by the Construction Seller under the Building Contract and (ii) delivery of the Vessel by the Charterers to the Owners under the MOA.
 
If the Building Contract is cancelled, rescinded or otherwise terminated for any reason whatsoever or the Vessel is not delivered by the Construction Seller to the Charterers under the Building Contract or is rejected by the Charterers under the Building Contract for any reason whatsoeverthen the Charterers shall give written notice thereof to the Owners and upon Owners’ receipt of such notice, the MOA and this Charter Party shall, save as hereafter provided, cease to have effect without any liability on the parties hereto and the parties shall be released from all obligations, liabilities and responsibilities hereunder, save that initial registration of title to the Vessel and legal documentation cost for documenting the lease and security to be Charterer’s account such cost not to exceed USD15,000.
 
The Charterers shall take delivery of the Vessel under this Charter Party immediately after delivery by the Charterers as sellers to the Owners as buyers under the MOAand the Owners shall deliver the Vessel to the Charterers under this Charter Party immediately after the Owners take delivery of the Vessel under the MOA.
 
In the event that the Vessel is not delivered under the MOA or the MOA is cancelled, terminated or rescinded for any reason, this Charter shall automatically terminate without any liability between the parties hereunder and initial registration of title to the Vessel and legal documentation cost for documenting the lease and security to be Charterer’s account such cost not to exceed USD15,000.
 
(b) It is acknowledged that the Charterers shall, by way of purchase from the Owners or otherwise, at the time of delivery of the Vessel under this Clause 39, own any bunkers, unused lubricating and hydraulic oils and greases in storage tanks and unopened drums and unused stores and provisions (hereinafter referred to as the “Bunkers”) remaining on board the Vessel on the Delivery Date and as a result the Owners and the Charterers will not settle the Bunkers at the time of delivery of the Vessel under this Charter Party.
 
(c) {USD45,000,000*(1 month CME TERM SOFR at the time of remittance + 2.0%)/360) (the “Remittance Interest Cost”) from the day of remittance of the fund till the closing date to be covered by Charterers provided that no Remittance Interest Cost shall be payable if the delay is due to Ownersdefault, negligence or wilful misconduct.


The extra interest cost, if any, shall be paid together with the second hire payment due under the terms of this Charter Party.
 
(d) The Charterers undertake to assign all their rights, benefits and remedies under article IX (Warranty of Quality) of the Building Contract and any guarantee granted to the Charterers by any supplier or vendor of any equipment (together, a Builder’s Warranty) and (ii) on the Delivery Dateprovided that the Assignments of Guarantees can be agreed upon, notify the Construction Seller and, as soon as practicably possible thereafterany such supplier or vendor of such assignments (the Assignments of Guarantees).
 
In respect of any repairs, replacements or defects which appear within the first 12 months from delivery by the Construction Seller or within such other period as may be stipulated in a guarantee of any supplier, the Owners shall, as assignees of the rights of the Charterers pursuant to the Assignments of Guarantees, issue a power of attorney in favour of the Charterers to authorize the Charterersup to but not after the occurrence of a Charterers’ Event of Default, to compel the Construction Seller or any supplier or vendor to repair, replace or remedy any defects or to recover from the Construction Seller or any supplier any expenditure incurred in carrying out such repairs, replacements or remedies.

Notwithstanding the Assignment of Guarantees, the Owners shall have no obligation to enforce or follow up on any guarantee or warranty thereby assigned, and it shall be the Chartererssole responsibility to enforce such guarantees, liaise and make arrangements with the Construction Seller and relevant supplier and/or vendor as they see fit, all at their own expense.
 
Any liquidated damages for physical defects or deficiencies shall be deemed to be earnings for the purposes of this Charter and shall be used for the repair of any defects or deficiencies or for the compensation of the Charterers in respect of all documented expenses and costs incurred by the Charterers in respect thereof.
 
The costs of pursuing a claim or claims against the Construction Seller or any supplier under this Clause (including any liability to the Construction Seller} shall be borne by the Charterers and the Charterers shall fully indemnify the Owners for any liability for which the Owners may be liable pursuant to such claim or claims.
 
Any sum recovered pursuant to a Builders Warranty of over $500,000 shall be paid to the Owners but so that:
(i)        the sum received by the Owners shall be paid over to the Charterers upon the Charterers providing evidence satisfactory to the Owners that the repairs in respect of which such payment have been completed and that all repair accounts and other liabilities connected therewith have been paid by the Charterers; and
(ii)        with the prior written consent of the Owners, be paid on account of the repairs which are being carried out; and any other such sum recovered pursuant to a Builder’s Warranty shall be paid to the Charterers which shall apply it in completing all repairs in respect of which such money was received.


40.
Conditions for delivery
 

a)
Prior to delivery of the Vessel under this Charter Party, each of the Parties shall exchange the following documents:


(i)
a copy of this Charter Party executed by each Party;
 

(ii)
a copy of the memorandum and articles of association (or equivalent documents) (and all amendments thereto) of the Owners and the Charterers;



(iii)
a copy of certificate of good standing or equivalent, stating all directors of the Owners and the Charterers dated not earlier than thirty (30) Banking Days prior to the date of delivery of the Vessel to the Ownerswith the original to follow as soon as possible after delivery of the Vessel, to the Owners;
 

(iv)
A PDF copy of one (1) Resolutions of the Board of Directors of the Charterers, authorisingapproving and ratifying the BBCP and the MOA and any further addenda thereto, authorising nominated individuals as signatories of and empowering these and/or other individuals to execute the Power of Attorney referred to below, the Bill of Sale and all other documents required for the sale and delivery of the Vessel to the Owners, duly executed on behalf of the Charterers;
 

(v)
A PDF copy of one (1) Resolutions of the Board of Directors of the Charterers• Guarantor, authorising, approving and ratifying (i) the MOA any further addenda thereto, (ii) the BBCP and any further addenda thereto, (iii) the Performance Guarantee, authorising nominated individuals as signatories of and empowering these and/or other individuals to execute the Power of Attorney duly executed on behalf of the Charterers’ Guarantor;
 

(vi)
A PDF copy of one (1) Resolutions of the Board of Directors of the Ownersauthorising, approving and ratifying the BBCP and the MOA and any further addenda thereto, authorising nominated individuals as signatories of and empowering these and/or other individuals to execute the Power of Attorney referred to below, the Bill of Sale and all other documents required for the sale and delivery of the Vessel to the Owners, duly executed on behalf of the Owners;
 

(vii)
A PDF copy of one (1) Resolutions of the Board of Directors of the Owners’ Guarantor, authorisingapproving and ratifying (i) the MOA and any further addenda thereto, (ii) the BBCP and any further addenda thereto, (iii) the Performance Guarantee, authorising nominated individuals as signatories of and empowering these and/or other individuals to execute the Power of Attorney duly executed on behalf of the Owners’ Guarantor;


(viii)
A PDF copy of one (1) Power of Attorney in favor of the persons who are to act on behalf of Charterers and CharterersGuarantors in connection with above (vi) and (vii)with the original to follow as soon as possible after delivery of the Vessel to the Owners;
 

(ix)
A PDF copy of one (1) Power of Attorney in favor of the persons who are to act on behalf of Owners and Owners’ Guarantors in connection with above (iv) and (v), with the original to follow as soon as possible after delivery of the Vessel to the Owners;


(x)
the Guarantees and QEL referred to in Clause 43duly executed; and
 

(xi)
a copy of the protocol of delivery and acceptance in relation to the Vessel executed by the Owners and the Charterers;
 

(xii)
such other documents as each of the Owner and Charterer may reasonably require.
 

41.
Vessel’s condition on delivery
 
The Vessel shall be delivered under this Charter Party in the same condition and with the same equipment, inventory and spare parts as she is delivered to the Owners under the MOA The Charterers know the Vessels condition at the time of delivery, and expressly agree that the Vessel’s condition as delivered under the MOA is acceptable and in accordance with the provisions of this Charter Party. The Vessel shall be delivered to the Charterers under this Charter Party strictly “as is/where isThe Owners neither make nor shall be deemed to have made or given any representation or warranty whether statutory or otherwise and whether express or implied as to the seaworthinessvaluecondition, quality, merchantability, design, description, operation, suitability or fitness for use for any purpose of the Vessel (with everything belonging to her), or as to the absence of any latent or other defectswhether or not discoverable, or as to the absence of any obligations based on strict liability in tort, which are hereby excluded (hereinafter collectively, referred to as the Vessel’s Conditions”).


The Charterers hereby acknowledge and agree that they have not relied upon any representation, condition or warranty, whether statutory or otherwise and whether express or implied as to any Vessels Conditions, in entering into this Charter Party, and accordingly the Charterers shall have no claim against the Owners under this Charter Party or otherwise whatsoever in relation to the Vessel’s Conditions.
 

42.
Survey and Inspection on re-delivery of the Vessel


(a)
Condition of Vessel
 
The Vessel with everything belonging to her shall be at the Charterersrisk and expense until she is re-delivered to the Ownersbut subject to the terms and conditions of this Charter Party she shall be re-delivered and taken over as she was at the time of the survey(s) in accordance with this Clause 42, fair wear and tear excepted.
 

(b)
Survey:
 
Not earlier than 45 days or later than 30 days (or if not possible then as soon as the Vessel becomes available) before re-delivery of the Vessel, the Owners and the Charterers shall jointly agree upon the appointment of a surveyor for the purpose of determining the condition of the Vessel at the time of re- delivery hereunder.
 
The surveyor, whose decision shall be final and binding on both Parties, shall report in writing, specifying all itemsif any, which have not been properly maintained in accordance with the terms and conditions of the Charter and the work required to repair such deficiencies.

The costs of such a surveyor shall be equally shared between the Parties. In the event that the parties are not able to agree upon a single surveyor, each shall appoint their own and the two surveyors so appointed shall conduct a joint survey of the Vessel. In such an event, each Party shall pay their own appointed surveyor’s costs.
 
The survey shall be carried out at the point of re-delivery and in Charterers time and shall not interfere with the operation of the Vessel. Any works required as a result of such survey shall be carried out by Charterers prior to their re-delivery of the Vessel. In the event that two surveyors so appointed disagree, the matter shall be referred to arbitration in accordance with Clause 33.

This clause shall not apply if Charterers exercise their purchase option as set out in Clause 45 or if Owners exercise their Put Option as set out in Clause 46.
 

(c)
Underwater Inspection:

In connection with the redelivery of the Vessel under the Charter, the Vessel shall not be dry-docked unless required by the Classification Society. In lieu of dry-dockingOwners shall have the right to appoint a diver acceptable to the Classification Society to undertake an underwater inspection at a convenient port with due consultation between Owners and Charterers. Such divers’ inspection shall be carried out at Owners’ expense (unless damage affecting the class is found, in which case the Charterers shall bear the cost) and without interference to the Vessel’s normal operation.

Should such underwater inspection reveal damages that affect the class of the Vessel whereby such damage repairs cannot be made to the Vessel without dry-docking and the Classification Society will not grant an extension, then Vessel is to be dry-docked as soon as possible by Charterers to repair such damages to the Classification Society’s satisfaction at Charterers’ time and expense.


If in the opinion of the Classification Society the damages do not necessitate immediate dry-docking, then the Classification Society shall issue a certificate showing the extent and place of damage and Charterers shall repair same to the satisfaction of the Classification Society at next dry-docking, provided that such dry-docking is within the Charter Period. If the next Classification Society dry-docking is after the re-delivery of the Vessel under this Charter Party, the Charterers shall in their option (i) repair such damages before redelivery of the Vessel hereunder or (ii) provide the Owners with an agreed lump sum, (the Charterers and the Owners shall each select a reputable shipyard in the redelivery range and obtain from such shipyard a quotation for the cost of repairs of the damage. The estimated cost of repairs shall be refined as the average of the two quotations obtained from the two shipyards), a first class bank guarantee or sum a cash deposit to be provided, in the Charterers’ option, covering the expected costs of such repairs.
 
This Clause 42 shall not apply if the Charterers exercise their Purchase Option as set out in Clause 45 or the Owners exercise their Put Option as set out in Clause 46.


43.
OwnersAssignment, Performance Guarantee and Quiet Enjoyment Letter
 
The Owners may not assign, transfer or novate their rights and in the case of a novation, obligations under this Charter without the prior written consent of the Charterers. Subject to the Mortgagee providing a quiet enjoyment letter, the Owners may assign their rights under this Charter Party to the Mortgagee, including but not limited to assignments of earnings and assignment of this Charter.

The Charterers are entitled to require a quiet enjoyment letter (the “QEL”) from the Mortgagee or such other financiers of the Owners, substantially in the form attached hereto as Appendix D, which confirms that the Charterers shall have free use of the Vessel under this Charter Party (including the right to exercise the Purchase Option) while there has occurred no Charterers’ Event of Default which is continuing under this Charter Party. The Owners shall procure that the Mortgagee or (as the case may be) such other financiers will provide the quiet enjoyment letter to the Charterers as a condition precedent to the Owners’ entry into the Financial Instrument on or before the Delivery Date.

The performance of the Charterers hereunder shall be guaranteed by Performance Shipping Inc. whereas the performance of the Owners shall be guaranteed by Kowa Kaiun Co., Ltd. (each, a “Guarantee”) The guarantees shall be in the format attached hereto as appendix B.
 
Upon delivery of the Vessel under this Charter Party, the Owners and the Charterers shall execute an assignment of insurances with the Ownersfinancier in a form and substance acceptable to each party thereto (but each acting reasonably), under which (inter alia) the Owners and the Charterers assign and agree to assign any and all their respective interests on insurance proceeds in respect of the Vessel to the extent as required by this Charter Party.
 

44.
Transfer of the Vessel
 

(a)
Any change of ownership of the Vessel or of the legal and/or beneficial ownership of the Owners during the Charter Period shall require the Charterers’ prior written approval which Charterers shall be at full discretion whether to grant or decline.


(b)
Each of the Owners and Charterers shall during the Charter Period be entitled to assign their position under the Charter Party to another third party entity. Such right shall be subject to (i) the prior written consent of the other Party, such consent not be unreasonable withheld, and (ii) that the guarantees granted by Performance Shipping Incand Kowa Kaiun Co., Ltd. shall continue to remain in full force and effect irrespective of the said assignment(s) under the Charter. Each Party shall bear their own costs related to such assignment.



(c)
If, as a result of a change in law relating specifically to the circumstances of the Charterers and/or the Owners after the date of this Charter Party there would be material adverse economic consequences to the Charterers of them continuing to perform their obligations under this Charter Party the Charterers shall have the option, to novate this Charter Party to an affiliate provided always thatnotwithstanding such novation, this Charter Party would continue on identical terms (save for logical, consequential or mutually agreed amendments) and Performance Shipping Inc. shall remain jointly and severally liable with such affiliate to the Owners for performance of all obligations by such affiliate pursuant to this Charter Party after such novation.

The Charterers agree and undertake to enter into (and procure that such affiliate and Performance Shipping Inc. enter into) or deliver to the Owners any such documents as the Owners (at their sole discretion) shall reasonably require in connection with such novation, including but not limited to such additional security documents and legal opinions as the Owners may reasonably requireAny reasonable and properly documented costs or expenses (including but not limited to legal costs) in relation to such novation and any conditions imposed by the Owners in giving their consent shall be borne by the Charterers.
 

(d)
In the event of the early termination of this Charter Party by the Owners due to a Charterers’ Event of Default which is continuing or due to any of the circumstances described in Clause 31(d) occurring to the Charterers, unless the Charterers have paid to the Owners the full amount of the then Outstanding Principal plus any other sums due from the Charterers to the Owners under this Charter Party, the Owners shall be entitled to sell the Vessel, whereupon they shall retain from the relevant proceeds an amount equal to the then Outstanding Principal plus any other sums then due from the Charterers to the Owners under this Charter Party and, thereafterpay the excess to the Charterers.
 

45.
Charterers’ Purchase Option
 
The Charterers or its nominee shall have an option to purchase the Vessel from the Owners commencing from the date falling twenty-four months after the Delivery Date (the “Purchase Option Commencement Date”) for the duration of the Charter Period (the “Purchase Option”) at the following prices (the “Purchase Option Price”) or pro rata for the current year:
 
The Purchase Option Price to be paid to the Owners upon delivery of the Vessel:
The Purchase Option Price = A - [ (A-B) / 365 x C]
 
Where:
 
A: the amount indicted below of the end of the year immediately prior to the applicable delivery date;
B: the amount indicted below of the end of the year of such delivery date; and
C: the actual number of days from the beginning of the year to which the delivery date belongs:


(i)
at a price of the Outstanding Principal x 102.00% at the end of year 2 of the Charter Period;

(ii)
at a price of the Outstanding Principal x 101.65% at the end of year 3 of the Charter Period;

(iii)
at a price of the Outstanding Principal x 101.20% at the end of year 4 of the Charter Period;

(iv)
at a price of the Outstanding Principal plus USD40,000 at the end of year 5 of the Charter Period;

(v)
at a price of the Outstanding Principal plus USD40,000 at the end of year 6 of the Charter Period;

(vi)
at a price of the Outstanding Principal plus USD40,000 at the end of year 7 of the Charter Period;

(vii)
at a price of the Outstanding Principal plus USD40,000 at the end of year 8 of the Charter Period.
 

If a breach by the Owners in the performance of any of their obligations under this Charter Party occurs and is continuing, then the Charterers may exercise their Purchase Option earlier than the Purchase Option Commencement Date, provided that in the event the Charterers exercise their Purchase Option and the relevant breach is subsequently remedied, such remedy shall not affect the exercise of the Purchase Option. The Purchase Option Price shall in such event be set at as follows or pro-rata for the current year:
 
at a price of USD 45,000,000.00 at the end of year 0 of the Charter Period;
at a price of USD 42,500,000.00 at the end of year 1 of the Charter Period;

Registration costand bank related costs including lifting charge and escrow agent fees, if any, shall be for the Charterers account; however such cost not to exceed USD 10,000.

The Charterers must give a minimum of 75 (seventy-five) calendar days’ notice to the Owners of their intention to buy the Vessel. The Purchase Option Price to be paid to the Owners upon delivery of the Vessel is in accordance with clause 3 of the memorandum of agreement attached to this Charter Party as Appendix A. The Vessel shall be delivered as soon as possible after expiry of the 75 (seventy-five) days’ notice and Owners undertake to render all necessary assistance in order to achieve this. Once the Purchase Option has been exercised by Charterers, they may not withdraw same.
 
The Charterers or its nominee shall accept the Vessel on an “AS IS, WHERE IS” basis and the Owners shall take such steps to obtain and furnish such documents as may reasonably be required by the Charterers (or their nominee) in order to transfer the legal and beneficial title and interest in the Vessel to the Charterers (or their nominee) (including without limitation a bill of sale in respect of the Vessel executed and (if required) notarized) and take such other actions as the Charterers may reasonably request in order to facilitate the sale and re-registration of the Vessel under such flag as the Charterers may designate.
 
With respect to such sale, the Owners warrant that the Vessel at such sale shall be free of any encumbrances, mortgages, charters, maritime liens and any other debts whatsoever (in each case, created by the Owners) created or incurred by the Owners and that the Owners have not committed any act or omission which would impair title to the Vessel and Owners hereby agree to indemnify and hold harmless Charterers in respect of any and all damagescosts and expenses whatsoever resulting from any breach of such warranty.

Upon completion of such purchase of the Vessel as set out in this Clause 45 or in the subsequent Clause 46, this Charter Party and all further rights and obligations of the Parties hereunder (except for indemnities and other obligations that by their nature should survive the termination of this Charter Party) shall terminate.
 

46.
Owners’ Put Option
 
The Owners have the option to sell the Vessel back to the Charterers or its nominee at the end of the eight (8) year of this Charter Party. In case Charterers have not exercised their Purchase Option75 (seventy-five) calendar days before the end of the Charter Period at the latestthe Owners may exercise their Put Option, in which case the Charterer shall purchase the Vessel for the Outstanding Principal plus USD 40,000 (“Put Option Fee”)The Owners must give a minimum of 60 (sixty) days’ notice of their intention to sell the Vessel. The Put Option Price shall be paid to the Owners upon delivery of the Vessel, which shall take place on the last day of the Charter Period.

The Charterers or its nominee shall accept the Vessel on an “AS IS, WHERE IS” basis and the Owners shall, take such steps to obtain and furnish such documents as may reasonably be required by the Charterers (or their nominee) in order to transfer the legal and beneficial title and interest in the Vessel to the Charterers (or their nominee) (including without limitation a bill of sale in respect of the Vessel executed and (if required) notarized) and take such other actions as the Charterers may reasonably request in order to facilitate the sale and re-registration of the Vessel under such flag as the Charterers may designate.


With respect to such sale, the Owners warrant that the Vessel at such sale shall be free of any encumbrances, mortgages, charters, maritime liens and any other debts whatsoever (in each case, created by the Owners) created or incurred by the Owners and that the Owners have not committed any act or omission which would impair title to the Vessel and Owners hereby agree to indemnify and hold harmless Charterers in respect of any and all damagescosts and expenses whatsoever resulting from any breach of such warranty.

Registration costand bank related costs including lifting charge and escrow agent fees, if anyshall be for the Charterers account; however such cost not to exceed USD 10,000.


47.
Insurance
 

(a)
The Charterers undertake with the Owners that throughout the Charter Period:
 

(i)
without prejudice to their obligations under Clause 17 hereofthey will keep the Vessel insured on such terms as widely accepted in the commercial shipping market and shall be reasonably acceptable to the Owners and the Mortgagee with such insurers (including P&I and war risks associations) as shall be reasonably acceptable to the Owners with deductibles reasonably acceptable to the Owners and that any P&I association which is a member of the International Group of P&I Clubs and H&M underwriters with security rating A. The Charterers shall advise the Owners of their current H&M underwriters for the Ownersapproval, such approval not to be unreasonably withheld or delayed (it being agreed and understood by the Charterers that there shall be no element of self-insurance or insurance through captive insurance companies without the prior written consent of the Owners);
 

(ii)
the policies in respect of the insurances against fire and usual marine risks and the policies or entries in respect of the insurances against war risks shall, in each case, be endorsed to the effect that payment of a claim for a Total Loss will be made to the Owners (or the Mortgagees as assignees thereof) (who shall upon the receipt thereof apply the same in the manner described in Clause 47(e) hereof);
 

(iii)
the Charterers shall procure that duplicates of all cover notespolicies and certificates of entry shall be furnished to the Owners for their custody, upon request;
 

(iv)
the Charterers shall procure that the insurers and the war risk and protection and indemnity associations with which the Vessel is entered shall:
 

(A)
provide the Owners and (if applicable) the Mortgagee with a letter or letter of undertaking in standard market form, and

(B)
supply to the Owners such information in relation to the insurances effected, or to be effected, with them as the Owners may from time to time reasonably require; and


(v)
the Charterers shall procure that the policies, entries or other instruments evidencing the insurances are endorsed to the effect that the insurers shall give to the Owners not less than fourteen (14) days prior written notification of any amendment, suspension, cancellation or termination of the insurances, unless subject to any automatic termination/cancellation of cover provisions in the relevant insurances, in which event, if such insurances are automatically terminated/cancelledOwners shall be advised promptly and Charterers shall immediately procure re-instatement or replacement insurances of those terminated/cancelled insurances.



(b)
Notwithstanding anything to the contrary contained in Clauses 17 and 47 (b) hereof, the Vessel shall be kept insured during the Charter Period in respect of marine and war risks on hull and machinery basis for not less than the total insured value (H&M valueHull Interest and freight interest) specified in column(b) in the table set out below in respect of the one-yearly period during the Charter Period specified in column (a) (on the assumption that the first such period commenced on the Delivery Date) against such amount (hereinafter referred to as the “Minimum Insured Value”):
 
  (a)   (b)
 
Year
 
Minimum Insured Value
 
1
 
USD 49 500,000
 
2
 
USD 46,750,000
 
3
 
USD 44,000,000
 
4
 
USD 41,250,000
 
5
 
USD 38,500,000
 
6
 
USD 35,750,000
 
7
 
USD 33,000,000
 
8
 
USD 30,250,000


(c)
If the Vessel becomes a Total Loss or becomes subject to Compulsory Acquisition, the chartering of the Vessel to the Charterers hereunder shall cease and the Charterers shall:-
 

(i)
immediately pay to the Owners all hireand any other amounts, which have fallen due for payment under this Charter Party and have not been paid as at up to the date on which the Total Loss or Compulsory Acquisition occurred as described below (the “Date of Loss”) together with interest thereon as set out in Clause 15 (g) and shall cease to be under any liability to pay any hire, but not any other amounts, thereafter becoming due and payable under this Charter Party. All hire and any other amounts prepaid by the Charterers relating to the period after the Date of Lossand any insurance proceeds received by the Owners and/or their mortgagee after payment by the Charterers as aforesaid, shall be forthwith refunded by the Owners and any hire paid in advance to be adjusted/reimbursed.


(ii)
For the purpose of ascertaining the Date of Loss:-


(A)
an actual total loss of the Vessel shall be deemed to have occurred at noon (London time) on the actual date the Vessel was lost but in the event of the date of the loss being unknown the actual total loss shall be deemed to have occurred at noon (London time) on the date on which it is acknowledged by the insurers to have occurred;
 

(B)
a constructive, compromised, agreed, or arranged total loss of the Vessel shall be deemed to have occurred at noon (London time) on the date that notice claiming such a total loss of the Vessel is given to the insurers, or, if the insurers do not admit such a claim, at the date and time at which a total loss is subsequently admitted by the insurers or the date and time adjudged by a competent court of law or arbitration tribunal to have occurred. Either the Owners or, with the prior written consent of the Owners (such consent not to be unreasonably withheld), the Charterers shall be entitled to give notice claiming a constructive total lose but prior to the giving of such notice there shall be consultation between the Charterers and the Owners and the Party proposing to give such notice shall be supplied with all such information as such Party may request; and
 

(C)
Compulsory Acquisition shall be deemed to have occurred at the time of occurrence of the relevant circumstances described in Clause 30(b) hereof.
 

(d)
(i) All moneys up to the Minimum Insured Value payable under the insurances effected by the Charterers pursuant to Clauses 17 and 47, or other compensationin respect of a Total Loss or pursuant to Compulsory Acquisition of the Vessel shall be received in full by the Owners (or the mortgagees as assignees thereof) and applied by the Owners (or, as the case may be, the mortgagees) as follows:


FIRSTLYin payment of all the Owners’ or the Charterers’ reasonable and properly incurred costs incidental to the collection thereof,
 
SECONDLYin or towards payment to the Owners (to the extent that the Owners have not already received the same in full) of a sum equal to the Purchase Option Price as per the table in Clause 45 immediately above, for the year in which the Date of Loss occurs and which shall be calculated pro rata per diem,

THIRDLY, towards any other applicable sums due from the Charterers to the Owners under this Charter Party, and
 
FORTHLY, in payment of any surplus to the Charterers by way of a rebate of hire and compensation for early termination.
 
If, in accordance with the terms of the relevant Loss Payable Clause, any part of the insurance proceeds or compensation payable under this sub-clause (d)(i) is received and applied by the mortgagees as assignees toward payment of the indebtedness due to such mortgagees by the Owners pursuant to the Financial Instrument, then the remainder of such insurance proceeds shall be distributed between the Owners and the Charterers in accordance with the order set out in this sub-clause (d)(i) above and, for the purposes of such distribution, the afore-mentioned part of the insurance proceeds received by the mortgagees shall reduce the afore-mentioned sums payable to the Owners accordingly. Under no circumstances will the sum of the insurance proceeds or compensation received under this sub-clause (d)(i) and applied by the mortgagees as assignees toward payment of the indebtedness due to such mortgagees by the Owners pursuant to the Financial Instrument, exceed the aggregate sum payable to the Owners in accordance with this sub-clause (d)(i) above.
 
(ii) Any moneys in excess of the Minimum Insured Value payable under the insurances effected by the Charterers pursuant to Clauses 17 and 47, or other compensationin respect of a Total Loss or pursuant to Compulsory Acquisition of the Vessel shall be received in full by the Charterers.
 

(e)
In respect of partial losses, any payment by underwriters not exceeding USD 500,000 shall be paid directly to the Charterers who shall apply the same for the repairsalvage or other charges involved or as a reimbursement if the Charterers fully repaired the damage to the satisfaction of the Owners and paid all of the salvage or other charges in respect of which payment is made. Any moneys in excess of USD 500,000 payable under such insurance (other than in respect of a Total Loss) shall be paid to the Charterers subject to the prior written consent of the Owners or the Owners’ mortgagee but such consent shall not be unreasonably withheld or delayed. In the absence of such prior written consent the money shall be paid to the Owners or the Owners’ mortgagee.
 

(f)
The provisions of Clauses 17 and 47 hereof shall not apply in any way to the proceeds of any additional insurance cover effected by the Owners and/ or the Charterers for their own account and benefit.


(g)
The Charterers shall promptly notify the Owners of:
 
(i) any accident to the Vessel involving repairs the cost of which exceeds USD500,000 or the equivalent in any other currencies; or
 
(ii) any occurrence in consequence whereof the Vessel has become a Total Loss or Compulsory Acquisition.



48.
Inconsistency
 
In case of any inconsistency between (i) the standard terms of this Charter Party and (ii) the amendments and Rider 39 to 53 (inclusive), the latter shall prevail.


49.
Loan Outstanding for Interest Portion
 
In the charter hire structure set out in Box 17the Variable Hire shall be calculated as follows:
 
(X) x (Y) x (Z) ÷ (A)

Where:
X         =       Amount of the loan outstanding (as set out in the table below)
Y         =      (Margin) + (1-month CME TERM SOFR)
Z          =      Number of days during the hire period in question
A         =      360 days.

The 1-month CME TERM SOFR to be used is the one published by CME GROUP five (5) Banking Days prior to the hire payment due dateShould the 3-month CME TERM SOFR published by CME GROUP turn negative, then zero (0) to be applied in calculation of hire payment.
 
In case that CME TERM SOFR ceases to be available, the Owners shall reasonably designate the alternative interest rate after consultation with the Charterers but such rate shall not exceed the cost to the Mortgagee of funding the outstanding loan balance on the Vessel from any reasonable source and such rate so applied shall only apply for so long as CME TERM SOFR remains unavailable.

Loan Outstanding
(USD)
       (USD)
1st Year 1st Month 45,000,000    2nd Year 13th Month
 42,500,000
 1st Year 2nd Month
44,791,667
   2nd Year 14th Month
 42,291,667
 1st Year 3rd Month
44,583,333
   2nd Year 15th Month
 42,083,333
 1st Year 4th Month
44,375,000
   2nd Year 16th Month
 41,875,000
 1st Year 5th Month
44,166,667
   2nd Year 17th Month  41,666,667
 1st Year 6th Month
43,958,333
   2nd Year 18th Month
 41,458,333
 1st Year 7th Month
43,750,000
   2nd Year 19th Month
 41,250,000
 1st Year
8th Month
43,541,667
   2nd Year 20th Month
 41,041,667
 1st Year 9th Month
43,333,333
   2nd Year 21st Month
 40,833,333
 1st Year 10th Month
43,125,000
   2nd Year 22nd Month
 40,625,000
 1st Year 11th Month
42,916,667
   2nd Year 23rd Month
 40,416,667
 1st Year
12th Month
42,708,333
   2nd Year 24th Month
 40,208,333
  3rd Year  25th Month
40,000,000
   4th Year  37th Month
37,500,000
  3rd Year  26th Month
39,791,667
   4th Year  38th Month
37,291,667
  3rd Year  27th Month  39,583,333    4th Year  39th Month
37,083,333
  3rd Year  28th Month
39,375,000
   4th Year  40th Month
 36,875,000
  3rd Year  29th Month
39,166,667
   4th Year
41st Month
 36,666,667
  3rd Year  30th Month
38,958,333
   4th Year  42nd Month  36,458,333
  3rd Year  31st Month
38,750,000
   4th Year  43rd Month
 36,250,000
  3rd Year  32nd Month
38,541,667
   4th Year  44th Month  36,041,667
  3rd Year  33rd Month
38,333,333
   4th Year  45th Month  35,833,333
  3rd Year  34th Month  38,125,000    4th Year  46th Month
 35,625,000
  3rd Year  35th Month  37,916,667    4th Year  47th Month  35,416,667
  3rd Year
36th Month
37,708,333
   4th Year  48th Month  35,208,333
5th Year  49th Month
35,000,000
  6th Year  61st Month
 32,500,000
 5th Year  50th Month  34,791,667    6th Year  62nd Month  32,291,667
 5th Year  51st Month  34,583,333    6th Year  63rd Month  32,083,333
 5th Year  52nd Month
34,375,000
   6th Year  64th Month  31,875,000
 5th Year  53rd Month  34,166,667   6th Year
 65th Month  31,666,667
 5th Year  54th Month
33,958,333
  6th Year
 66th Month
 31,458,333
 5th Year  55th Month  33,750,000    6th Year  67th Month  31,250,000
 5th Year  56th Month
33,541,667
   6th Year  68th Month
 31,041,667
 5th Year  57th Month  33,333,333    6th Year  69th Month
 30,833,333
 5th Year
58th Month
33,125,000
   6th Year
 70th Month
 30,625,000
 5th Year  59th Month
32,916,667
   6th Year
 71st Month
 30,416,667
 5th Year  60th Month
32,708,333
   6th Year  72nd Month  30,208,333


7th Year
73rd Month
30,000,000
 
8th Year
85th Month
27,500,000
7th Year
74th Month
29,791,667
8th Year
86th Month
27,291,667
7th Year
75th Month
29,583,333
8th Year
87th Month
27,083,333
7th Year
76th Month
29,375,000
8th Year
88th Month
26,875,000
7th Year
77th Month
29,166,667
8th Year
89th Month
26,666,667
7th Year
78th Month
28,958,333
8th Year
90th Month
26,458,333
7th Year
79th Month
28,750,000
8th Year
91st Month
26,250,000
7th Year
80th Month
28,541,667
8th Year
92nd Month
26,041,667
7th Year
81st Month
28,333,333
8th Year
93rd Month
25,833,333
7th Year
82nd Month
28,125,000
8th Year
94th Month
25,625,000
7th Year
83rd Month
27,916,667
8th Year
95th Month
25,416,667
7th Year
84th Month
27,708,333
8th Year
96th Month
25,208,333
 

50.
Disclosure

The Charterers shall supply the Owners as soon as reasonably practicable, but in any event i) within one hundred and eighty (180) days after the end of each of its financial years, the audited financial statements of Performance Shipping Inc. for that financial year.
 

51.
Money laundering, sanctionsanti-corruption:
 
Notwithstanding any other clause in this Chartereach Party warrantsrepresents and undertakes to the other Party on a continuing basis:
 
(Money laundering):
that itand parties acting on its behalf in relation to this Charter, shall observe and abide with, including but not limited any law, official requirement or other regulatory measure or procedure implemented to combat money laundering as defined in any laws or regulations applicable to such Partyand
 
(Sanctions):
that it, nor any of their directors and, executive managers and ultimate owners, are or will become sanctioned by USA, the UK, Japan, the European union or the United Nations or any other nation or governmental body or organization relevant to the trading of the Vessel under this Charter to the extent that non-compliance by it would result in an actual breach of any applicable sanctions, and

that it, its directors and executive managers, has not been a party, directly, to any contract or conduct in contravention of any applicable sanctions legislation or directives of either the USA, the UK, Japan, the European union or the United Nations or any other nation or governmental body or organization relevant to the trading of the Vessel under this Charter to the extent that non-compliance by it would result in an actual breach of any applicable sanctions. Moreover, the Party is acting for itself only and is not acting on behalf of any other individual or corporation, and

(Anti-corruption):
that it, its directors, performance guarantors, executive managers and ultimate owners of the Charterers; shall comply with all applicable anti-corruption laws, regulations and contractual provisions, including without limitation the US Foreign Corrupt Practices Act and the UK Bribery Act, and
 
that it, its directors, performance guarantors, executive managers and ultimate owners of the Charterers; shall not, directly or through third parties, in relation to the Charter, give, promise or attempt to give, or approve or authorize the giving ofanything of value to any person, any public official or any entity for the purpose of:
 
-
securing any improper advantage for either Party;
 
-
inducing or influencing anyone improperly to take action or refrain from taking action in order for either Party to obtain or retain business, or to secure the direction of business to either Party;
 
-
inducing or influencing anyone to use his/her influence with any Government or public international organization for such purpose; and that:


 
-
to the best of its knowledge, none of its directors, executive managers or owners nor the directors, executive managers and owners of affiliated companies; have carried out any of the actions described above;
 
-
all remuneration received under this Charter is solely intended as compensation for the services expressly provided under this Charter, including the Parties’ related documented costs and expenses, and that it is not receiving remuneration for any other purpose; and,
 
-
neither the Partynor any of its affiliated companies, directors, executive managers or owners shall use any part of said remuneration for any purpose prohibited under this Clause 51.

(Indemnification):
if such calling constitute a breach of sanctionsthen Charterers to undertake to indemnify Owners against all direct and proven loss and costs sustained as a result of such violationCharterers shall indemnify the Owners and hold the Owners harmless in respect of any direct and proven liability, loss, damage or expenses of whatsoever nature which the Owners may sustain resulting from the operation of the Vessel (including but not limited to hereunder those arising from Vessel entering/operating in war area or warlike area).
 
(Others):
that neither it, its directors, executive managers and owners, nor the directorsexecutive managers and owners of affiliated companies; have been suspended from doing business in any form subject to investigation or charged with or sentenced for relevant criminal behaviour, fraud, false statements, corruption or other related activities;


52.
Confidentiality

The discussions between the Parties shall be kept strictly confidential by both Parties and may only be disclosed to each Party’s advisors and financiers on a need to know basisand as may be required to be disclosed under applicable law, regulatory rules and regulations, government authorities or relevant stock exchange rules.
 

53.
Counterparts
 
This Charter Party may be executed in any number of counterparts and any single counterpart or set of counterparts signed, in either case, by all the parties hereto shall be deemed to constitute a full and original agreement for all purposes.
 

54.
EU ETS

Emission Allowances” means an allowance, credit, quotapermit or equivalentrepresenting a right of a vessel to emit a specified quantity of greenhouse gas emissions recognized by the Emission Scheme, or generally in connection with emissionscarbon reduction or other environmental or sustainability measures relating to the operation of the Vessel.

“Emission Schememeans a greenhouse gas emissions trading scheme and any emissions, carbon reduction or other environmental or sustainability measures relating to the Vesselwhich for the purposes of this Clause shall include (without limitation) the European Union Emissions Trading System and any other similar systems imposed by any similar or equivalent international, regional, national or local scheme implemented by the IMO or any other authority that regulate the issuance, allocation, trading or surrendering of Emission Allowances.


(i)
The Charterer shall be the sole responsible party for compliance of all Emission Scheme obligations in relation to the Vesseland whether or not such obligations are, pursuant to any domestic or international law or regulation, directed to the Owner as registered or beneficial owner of the Vessel.



(ii)
Notwithstanding sub-paragraph (i) above, the Charterer shall be permitted to sub-delegate such Emission Scheme responsibility on to any entity, including without limitation to the relevant holder of Document of Compliance under the ISM Code in respect of the Vessel. Such sub-delegation shall be documented and copy of such documentation shall be made available to the Owner.
 

(iii)
The Charterers shall co-operate with the Owner and assist the Owner to deliver all such forms as are required to be filed to any relevant authorities in relation to the delegation and assumption of any Emission Scheme responsibilities.
 

(iv)
Without limiting the foregoing, throughout the Charter Period the Chartereror any mandated by the Charterer entity, shall provide and pay for the Emission Allowances corresponding to the Vessel’s emissions under the scope of the applicable Emission Scheme without any delay whatsoever.
 

(v)
Emission Allowances, taxes, charges, levies, fees, finescosts or expenses incurred or imposed in connection with any Emissions Scheme, shall be for the Charterers’ account and are to be settled directly by them or their mandated entity.
 

(vi)
The Charterer shall ensure that the Chartereror any mandated by the Charterer entity, shall comply, acknowledge in writing in any form that may be reasonably required, and provide all such information and documents to the Owner as necessary to enable the Owners and any Emission Scheme obligor to document and evidence to any authority their delegation/mandating of all Emission Scheme obligations in relation to the Vessel (and the assumption of same by the relevant mandated entity), as may be required from time to time during the Charter Period by the Owner, any manager or other mandated entity, and any relevant Emission Scheme authority, in conformity with the provisions of this Clause. In relation to the Emission Scheme being the European Union Emissions Trading System, the Owner and the Charterer, or any mandated by the Charterer entity, shall complete and sign a mandate form in form and substance as required (from time to time) by the EU Commission Implementing Regulation (EU) 2023/2599, the Directive 2003/87/EC, currently and indicatively in form as appended hereto (Appendix C) (the “Mandate Form”).


(vii)
The Owner undertake to relay to the Charterer, without delay, any information that might be received by the Owner for any reason whatsoever, including by error of any authority, and which might relate to compliance with any Emission Scheme.

IN WITNESS HEREOF the Owners and the Charterers have signed and executed TWO COPIES of this Agreement the day and year first written.

 
T.A.C.KSHIPPINGS.A.
 
GUADELOUPE SHIPPING COMPANY INC.
 
Signature (Owners)
  Signature (Charterers)
 
  /s/ Andreas Nikolaos Michalopoulos
 
Name: Takayuki Hanada
  Name: Andreas Nikolaos Michalopoulos
 
Title: Representative Director / Treasurer
  Title: Director / Attorney-in-fact
 
Kowa Kaiun Co.Ltd.
 
Performance Shipping Inc.
 
Signature (Guarantor)
 
Signature (Guarantor)
       /s/ Andreas Nikolaos Michalopoulos
  Name: Takayuki Hanada
 
Name: Andreas Nikolaos Michalopoulos
  Title: Executive Director  
Title: Director/ Chief Executive Officer


List of Appendices:
 
Appendix A:          Memorandum of Agreement for purchase option
Appendix B:          Form of performance guarantees
Appendix C:          Mandate Form of EU-ETS Obligation
Appendix D:          Form of Quiet Enjoyment Letter