EX-10.60 19 dex1060.htm EURO 126.1 MILLION PRIDE OF HAWAII CREDIT AGREEMENT Euro 126.1 million Pride of Hawaii Credit Agreement

Exhibit 10.60

EXECUTION COPY

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

 

 

 

€126,075,000

CREDIT AGREEMENT

among

NCL CORPORATION LTD.,

as Parent,

PRIDE OF HAWAII, LLC,

as Borrower,

VARIOUS LENDERS,

KFW IPEX-BANK GMBH,

as Facility Agent and Collateral Agent,

NORDEA BANK NORGE ASA,

as Documentation Agent,

and

COMMERZBANK AKTIENGESELLSCHAFT,

as Hermes Agent

 

 

Dated November 18, 2010

 

 

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT,

DNB NOR BANK ASA,

HSBC BANK PLC,

KFW IPEX-BANK GMBH

and

NORDEA BANK NORGE ASA,

as Joint Lead Arrangers

 

 

 


TABLE OF CONTENTS

 

          Page  
SECTION 1.    Definitions and Accounting Terms      1   
1.01    Defined Terms      1   
SECTION 2.    Amount and Terms of Credit Facility      31   
2.01    The Commitments      31   
2.02    Amount and Timing of Each Borrowing; Currency of Disbursements      32   
2.03    Notice of Borrowing      33   
2.04    Disbursement of Funds      33   
2.05    Pro Rata Borrowings      34   
2.06    Interest      34   
2.07    Interest Periods      35   
2.08    Increased Costs, Illegality, Market Disruption, etc.      36   
2.09    Indemnification; Breakage Costs      38   
2.10    Change of Lending Office; Limitation on Additional Amounts      39   
2.11    Replacement of Lenders      39   
2.12    Disruption to Payment Systems, Etc.      40   
SECTION 3.    Commitment Commission; Fees; Reductions of Commitment      41   
3.01    Commitment Commission      41   
3.02    Voluntary Reduction or Termination of Commitments      41   
3.03    Mandatory Reduction of Commitments      41   
SECTION 4.    Prepayments; Repayments; Taxes      42   
4.01    Voluntary Prepayments      42   
4.02    Mandatory Repayments and Commitment Reductions      43   
4.03    Method and Place of Payment      44   
4.04    Net Payments; Taxes      44   
4.05    Application of Proceeds      45   
SECTION 5.    Conditions Precedent to the Initial Borrowing Dates      47   
5.01    Effective Date      47   
5.02    Intercreditor Agreement.      47   
5.03    Corporate Documents; Proceedings; etc.      48   
5.04    Know Your Customer      48   
5.05    Construction Contract and Other Material Agreements      48   
5.06    Assignment of Contracts      48   
5.07    Collateral and Guaranty Requirements      50   
5.08    Consents Under Existing Credit Facilities      50   
5.09    Process Agent      50   
5.10    Equity Payment      50   
5.11    Financing Statements      50   

 

(i)


5.12    Opinions of Counsel      51   
5.13    Security Trust Deed      52   
5.14    Litigation      52   
SECTION 6.    Conditions Precedent to each Borrowing Date      52   
6.01    No Default; Representations and Warranties      52   
6.02    Consents      52   
6.03    Refund Guarantees      53   
6.04    ECF Payment      54   
6.05    Fees, Costs, etc.      54   
6.06    Construction Contract      54   
6.07    Hermes Cover      54   
6.08    Notice of Borrowing      54   
6.09    Solvency Certificate      54   
6.10    Litigation      55   
SECTION 7.    Conditions Precedent to each Delivery Date      55   
7.01    Delivery of Vessel      55   
7.02    Evidence of 90% Payment      55   
7.03    Hermes Compliance; Compliance with Applicable Laws and Regulations      55   
SECTION 8.    Representations and Warranties      55   
8.01    Entity Status      55   
8.02    Power and Authority      56   
8.03    No Violation      56   
8.04    Governmental Approvals      56   
8.05    Financial Statements; Financial Condition      57   
8.06    Litigation      57   
8.07    True and Complete Disclosure      57   
8.08    Use of Proceeds      57   
8.09    Tax Returns and Payments      57   
8.10    No Material Misstatements      58   
8.11    The Security Documents      58   
8.12    Capitalization      59   
8.13    Subsidiaries      59   
8.14    Compliance with Statutes, etc.      59   
8.15    Winding-up, etc.      59   
8.16    No Default      59   
8.17    Pollution and Other Regulations      59   
8.18    Ownership of Assets      60   
8.19    Concerning the Collateral Vessel      60   
8.20    Citizenship      60   
8.21    Collateral Vessel Classification      61   
8.22    No Immunity      61   
8.23    Fees, Governing Law and Enforcement      61   
8.24    Form of Documentation      61   

 

(ii)


8.25    Pari Passu or Priority Status    61
8.26    Solvency    62
8.27    No Undisclosed Commissions    62
8.28    Completeness of Documentation    62
8.29    Money Laundering    62
SECTION 9.    Affirmative Covenants    62
9.01    Information Covenants    62
9.02    Books and Records; Inspection    64
9.03    Maintenance of Property; Insurance    65
9.04    Corporate Franchises    65
9.05    Compliance with Statutes, etc.    65
9.06    Hermes Cover    65
9.07    End of Fiscal Years    65
9.08    Performance of Obligations    66
9.09    Payment of Taxes    66
9.10    Further Assurances    66
9.11    Ownership of Subsidiaries    66
9.12    Consents and Registrations    66
9.13    Flag of Collateral Vessel    67
9.14    “Know Your Customer” and Other Similar Information    67
SECTION 10.    Negative Covenants    67
10.01    Liens    67
10.02    Consolidation, Merger, Amalgamation, Sale of Assets, Acquisitions, etc.    69
10.03    Dividends    70
10.04    Advances, Investments and Loans    71
10.05    Transactions with Affiliates    71
10.06    Free Liquidity    73
10.07    Total Net Funded Debt to Total Capitalization    73
10.08    Collateral Maintenance    73
10.09    Consolidated EBITDA to Consolidated Debt Service    74
10.10    Business; Change of Name    74
10.11    Subordination of Indebtedness    74
10.12    Activities of Borrower, etc.    75
10.13    Material Amendments or Modifications of Construction Contracts    75
10.14    No Place of Business    75
SECTION 11.    Events of Default    75
11.01    Payments    75
11.02    Representations, etc.    75
11.03    Covenants    76
11.04    Default Under Other Agreements    76
11.05    Bankruptcy, etc.    76
11.06    Total Loss    77
11.07    Security Documents    77

 

(iii)


11.08    Guaranties    78
11.09    Judgments    78
11.10    Cessation of Business    78
11.11    Revocation of Consents    78
11.12    Unlawfulness    78
11.13    Insurances    79
11.14    Disposals    79
11.15    Government Intervention    79
11.16    Change of Control    79
11.17    Material Adverse Change    79
11.18    Repudiation of Construction Contract or other Material Documents    79
SECTION 12.    Agency and Security Trustee Provisions    80
12.01    Appointment and Declaration of Trust    80
12.02    Nature of Duties    81
12.03    Lack of Reliance on the Agents    81
12.04    Certain Rights of the Agents    81
12.05    Reliance    81
12.06    Indemnification    82
12.07    The Agents in their Individual Capacities    82
12.08    Resignation by an Agent    82
12.09    The Joint Lead Arrangers    83
12.10    Impaired Agent    83
12.11    Replacement of an Agent    84
12.12    Resignation by the Hermes Agent    84
SECTION 13.    Benefit of Agreement    85
13.01    Assignments and Transfers by the Lenders    85
13.02    Assignment or Transfer Fee    86
13.03    Assignments and Transfers to Hermes    86
13.04    Limitation of Responsibility to Existing Lenders    86
13.05    [Intentionally Omitted].    87
13.06    Procedure and Conditions for Transfer    87
13.07    Procedure and Conditions for Assignment    88
13.08    Copy of Transfer Certificate or Assignment Agreement to Parent    89
13.09    Security over Lenders’ Rights    89
13.10    Assignment by a Credit Party    90
13.11    Lender Participations    90
13.12    Increased Costs    90
SECTION 14.    Miscellaneous    90
14.01    Payment of Expenses, etc.    90
14.02    Right of Set-off    92
14.03    Notices    92
14.04    No Waiver; Remedies Cumulative    93
14.05    Payments Pro Rata    93

 

(iv)


14.06    Calculations; Computations    94  
14.07    GOVERNING LAW; EXCLUSIVE JURISDICTION OF ENGLISH COURTS; SERVICE OF PROCESS      94   
14.08    Counterparts      95   
14.09    Effectiveness      95   
14.10    Headings Descriptive      95   
14.11    Amendment or Waiver; etc.      95   
14.12    Survival      97   
14.13    Domicile of Loans      97   
14.14    Confidentiality      97   
14.15    Register      97   
14.16    Third Party Rights      98   
14.17    Judgment Currency      98   
14.18    Language      98   
14.19    Waiver of Immunity      99   
14.20    “Know Your Customer” Notice      99   
14.21    Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer      99   
14.22    Partial Invalidity      100   
SECTION 15.    Parent Guaranty      100   
15.01    Guaranty and Indemnity      100   
15.02    Continuing Guaranty      101   
15.03    Reinstatement      101   
15.04    Waiver of Defenses      101   
15.05    Guarantor Intent      101   
15.06    Immediate Recourse      102   
15.07    Appropriations      102   
15.08    Deferral of Guarantor’s Rights      102   
15.09    Additional Security      103   
     
SCHEDULE 1.01(a)    -    Commitments
SCHEDULE 1.01(b)    -    Existing Jade Scheduled Repayments
SCHEDULE 1.01(c)    -    Mandatory Costs
SCHEDULE 5.06    -    Notices, Acknowledgments and Consents
SCHEDULE 5.12    -    Initial Borrowing Date Required Opinion Items
SCHEDULE 6.10    -    Material Litigation
SCHEDULE 8.03    -    Existing Agreements
SCHEDULE 8.12    -    Capitalization
SCHEDULE 8.13    -    Subsidiaries
SCHEDULE 8.19    -    Collateral Vessel
SCHEDULE 8.21    -    Approved Classification Societies
SCHEDULE 9.03    -    Required Insurances
SCHEDULE 10.01    -    Existing Liens
SCHEDULE 14.03A    -    Credit Party Addresses
SCHEDULE 14.03B    -    Lender Addresses

 

(v)


EXHIBIT A    -    Form of Notice of Borrowing
EXHIBIT B    -    Form of BankAssure Report
EXHIBIT C    -    Form of Insurance Broker Certificate
EXHIBIT D    -    Form of Secretary’s Certificate
EXHIBIT E    -    Form of Transfer Certificate
EXHIBIT F    -    Form of Assignment of Charter and Earnings
EXHIBIT G    -    Form of Assignment of Insurances
EXHIBIT H    -    Form of Deed of Covenants
EXHIBIT I-1    -    Form of Vessel 1 Assignment of Contracts
EXHIBIT I-2    -    Form of Vessel 2 Assignment of Contracts
EXHIBIT J    -    Form of Solvency Certificate
EXHIBIT K    -    Form of Assignment Agreement
EXHIBIT L    -    Form of Compliance Certificate
EXHIBIT M-1    -    Form of Tranche A Intercreditor Agreement
EXHIBIT M-2    -    Form of Tranche B Intercreditor Agreement
EXHIBIT M-3    -    Form of Jade Intercreditor Agreement
EXHIBIT N    -    Form of Security Trust Deed
EXHIBIT O-1    -    Form of Vessel 1 Assignment of KfW Refund Guarantee
EXHIBIT O-2    -    Form of Vessel 2 Assignment of KfW Refund Guarantee
EXHIBIT P    -    Form of Charterer’s Assignment and Subordination

 

(vi)


THIS CREDIT AGREEMENT, is made by way of deed November 18, 2010, among NCL CORPORATION LTD., a Bermuda company with its registered office as of the date hereof at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Parent”), PRIDE OF HAWAII, LLC, a Delaware limited liability company with its registered office as of the date hereof at Corporate Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Borrower”), the Lenders party hereto from time to time, KFW IPEX-BANK GMBH, as Facility Agent (in such capacity, the “Facility Agent”) and as Collateral Agent under the Security Documents (in such capacity, the “Collateral Agent”), NORDEA BANK NORGE ASA, as Documentation Agent (in such capacity, the “Documentation Agent”), COMMERZBANK AKTIENGESELLSCHAFT, as Hermes Agent (in such capacity, the “Hermes Agent”), and each of DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, DNB NOR BANK ASA, HSBC BANK PLC, KFW IPEX-BANK GMBH and NORDEA BANK NORGE ASA, each in their capacity as joint lead arranger in respect of the credit facility provided for herein (together, the “Joint Lead Arrangers”). All capitalized terms used herein and defined in Section 1 are used herein as therein defined.

W I T N E S S E T H:

WHEREAS, the Borrower has requested that the Lenders make available to the Borrower a multi-draw term loan credit facility (the “Jade Term Loan Facility”) pursuant to which Loans may be incurred to finance, in part, the construction and acquisition costs of the New Vessels and the related Hermes Premium;

WHEREAS, Norwegian Jewel Limited, an Isle of Man company (the “Jewel Borrower”), the Parent, the lenders from time to time party thereto, the Facility Agent, the Collateral Agent, the Documentation Agent and the Hermes Agent have entered into that certain credit agreement (as amended, amended and restated, supplemented, novated or otherwise modified from time to time, the “Other Term Loan Facility” and collectively with the Jade Term Loan Facility, the “Term Loan Facilities”) dated as of the date hereof pursuant to which loans thereunder may be incurred to finance, in part, the construction and acquisition cost of the New Vessels and the related Hermes Premium;

WHEREAS, the Lenders and the lenders under the Other Term Loan Facility have agreed to commit to provide the Term Loan Facilities in an aggregate principal amount of up to €126,075,000 subject to and upon the terms and conditions set forth herein and in the Other Term Loan Facility; and

WHEREAS, subject to and upon the terms and conditions set forth herein, the Lenders are willing to make available to the Borrower the Jade Term Loan Facility provided for herein;

NOW, THEREFORE, IT IS AGREED:

SECTION 1. Definitions and Accounting Terms.

1.01 Defined Terms. As used in this Agreement, the following terms shall have the following meanings (such meanings to be equally applicable to both the singular and plural


forms of the terms defined) and references to this Agreement or any other document (or to any specified provision of this Agreement or any other document) shall be construed as references to this Agreement, that provision or that document as from time to time amended, restated, supplemented and/or novated:

Acceptable Bank” means (a) a bank or financial institution which has a rating for its long-term unsecured and non credit-enhanced debt obligations of A- or higher by S&P or A2 or higher by Moody’s or a comparable rating from an internationally recognized credit rating agency; or (b) any other bank or financial institution approved by each Agent.

Acceptable Flag Jurisdiction” shall mean the Bahamas, Bermuda, Panama, the Marshall Islands, the United States or such other flag jurisdiction as may be acceptable to the Required Lenders in their reasonable discretion.

Acquisition” means any transaction or series of related transactions for the purpose of or resulting, directly or indirectly, in (a) the acquisition of all or substantially all of the assets of a Person, or of any business or division of a Person, (b) the acquisition of in excess of fifty percent (50%) of the Capital Stock of any Person or otherwise causing any Person to become a Subsidiary of a Borrower, or (c) a merger, amalgamation or consolidation or any other combination with another Person.

Adjusted Construction Price” shall mean, for each New Vessel, the sum of the Initial Construction Price of such New Vessel and the total permitted increases to the Initial Construction Price of such New Vessel pursuant to Permitted Change Orders (it being understood that the Final Construction Price may exceed the Adjusted Construction Price).

Affiliate” shall mean, with respect to any Person, any other Person directly or indirectly controlling, controlled by, or under direct or indirect common control with, such Person; provided, however, that for purposes of Section 10.05, an Affiliate of the Parent or any of its Subsidiaries, as applicable, shall include any Person that directly or indirectly owns more than 10% of any class of the Capital Stock of the Parent or such Subsidiary, as applicable, and any officer or director of the Parent or such Subsidiary. A Person shall be deemed to control another Person if such Person possesses, directly or indirectly, the power to direct or cause the direction of the management and policies of such other Person, whether through the ownership of voting securities, by contract or otherwise. Notwithstanding anything to the contrary contained above, for purposes of Section 10.05, neither the Facility Agent, nor the Collateral Agent, nor the Joint Lead Arrangers nor any Lender (or any of their respective affiliates) shall be deemed to constitute an Affiliate of the Parent or its Subsidiaries in connection with the Credit Documents or its dealings or arrangements relating thereto.

Affiliate Transaction” shall have the meaning provided in Section 10.05.

Agent” or “Agents” shall mean, individually and collectively, the Facility Agent, the Collateral Agent, the Delegate Collateral Agent, the Documentation Agent and the Hermes Agent.

Agreement” shall mean this Credit Agreement, as modified, supplemented, amended, restated or novated from time to time.

 

-2-


Aggregate Initial Construction Price” shall mean the sum of the Initial Construction Price for Vessel 1 and the Initial Construction Price for Vessel 2.

Apollo” shall mean Apollo Management, L.P., and its Affiliates.

Applicable Margin” shall mean a percentage per annum equal to 1.60%.

Appraised Value” of the Collateral Vessel at any time shall mean the average of the fair market value of the Collateral Vessel on an individual charter free basis as set forth on the appraisals most recently delivered to, or obtained by, the Facility Agent prior to such time pursuant to Section 9.01(c).

Approved Appraisers” shall mean Brax Shipping AS; Barry Rogliano Salles S.A., Paris; Clarksons, London; R.S. Platou Shipbrokers, A.S., Oslo; and Fearnsale, a division of Astrup Fearnley AS, Oslo.

Approved Stock Exchange” shall mean the New York Stock Exchange, NASDAQ or such other stock exchange in the United States of America, the United Kingdom or Hong Kong as is approved in writing by the Facility Agent or, in each case, any successor thereto.

Assignment Agreement” shall mean an Assignment Agreement substantially in the form of Exhibit K (appropriately completed) or any other form agreed between the relevant assignor and assignee (and if required to be executed by the Borrower, the Borrower); provided that if such other form does not contain the undertaking set out in Clause 7 of Exhibit K it shall not be a Creditor Accession Undertaking as defined in, and for the purposes of, the ECF Intercreditor Agreements.

Assignment of Charter and Earnings” shall have the meaning provided in the definition of “Collateral and Guaranty Requirements”.

Assignments of Contracts” shall have the meaning provided in Section 5.06(b).

Assignment of Insurances” shall have the meaning provided in the definition of “Collateral and Guaranty Requirements”.

Assignments of KfW Refund Guarantees” shall have the meaning provided in Section 5.06(b).

Bankruptcy Code” shall have the meaning provided in Section 11.05(b).

Bareboat Charterer” shall have the meaning provided in the definition of “Collateral and Guaranty Requirements”.

Basel II” shall mean the “International Convergence of Capital Measurement and Capital Standards, a Revised Framework” published by the Basel Committee on Banking Supervision in June 2004 in the form existing on the date of this Agreement.

 

-3-


Borrower” shall have the meaning provided in the first paragraph of this Agreement.

Borrowing” shall mean the borrowing of Loans from all the Lenders (other than any Lender which has not funded its share of a Borrowing in accordance with this Agreement) having Commitments on a given date.

Borrowing Date” shall have the meaning provided in Section 2.02.

Breakaway One” shall mean Breakaway One, Ltd., a Bermuda company.

Breakaway One Facility” shall mean that certain Credit Agreement dated as of the date hereof among the Parent as guarantor, Breakaway One as borrower, various lenders party thereto, KfW IPEX-Bank GmbH, as facility agent, collateral agent and CIRR agent, Nordea Bank Norge ASA, as documentation agent, and Commerzbank AG, as Hermes agent.

Breakaway Two” shall mean Breakaway Two, Ltd., a Bermuda company.

Breakaway Two Facility” shall mean that certain Credit Agreement dated as of the date hereof among the Parent as guarantor, Breakaway Two as borrower, various lenders party thereto, KfW IPEX-Bank GmbH, as facility agent, collateral agent and CIRR agent, Nordea Bank Norge ASA, as documentation agent, and Commerzbank AG, as Hermes agent.

Business Day” shall mean any day except Saturday, Sunday and any day which shall be in New York, London, Frankfurt am Main or Norway a legal holiday or a day on which banking institutions are authorized or required by law or other government action to close.

Capital Stock” means:

(1) in the case of a corporation, corporate stock or shares;

(2) in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock;

(3) in the case of a partnership or limited liability company, partnership or membership interests (whether general or limited); and

(4) any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person.

Cash Balance” shall mean, at any date of determination, the unencumbered and otherwise unrestricted cash and Cash Equivalents of the NCLC Group.

Cash Equivalents” shall mean (i) securities issued or directly and fully guaranteed or insured by the United States or any agency or instrumentality thereof (provided that the full faith and credit of the United States is pledged in support thereof) having maturities of not more than one year from the date of acquisition, (ii) time deposits and certificates of deposit of any commercial bank having, or which is the principal banking subsidiary of a bank

 

-4-


holding company having capital, surplus and undivided profits aggregating in excess of $200,000,000, with maturities of not more than one year from the date of acquisition by any Person, (iii) repurchase obligations with a term of not more than 90 days for underlying securities of the types described in clause (i) above entered into with any bank meeting the qualifications specified in clause (ii) above, (iv) commercial paper issued by any Person incorporated in the United States rated at least A-1 or the equivalent thereof by S&P or at least B-1 or the equivalent thereof by Moody’s and in each case maturing not more than one year after the date of acquisition by any other Person, and (v) investments in money market funds substantially all of whose assets are comprised of securities of the types described in clauses (i) through (iv) above.

CERCLA” shall mean the Comprehensive Environmental Response, Compensation, and Liability Act of 1980, as the same may be amended from time to time, 42 U.S.C. § 9601 et seq.

Change of Control” shall mean (x) at any time when the ordinary Capital Stock of the Parent (or a parent company of the Parent in a Qualified IPO) is not listed on an Approved Stock Exchange or at any time when a dividend is to be paid to the existing shareholders of the Parent by way of a share issue pursuant to a public offering on an Approved Stock Exchange, the Permitted Holders in the aggregate do not, directly or indirectly, control the Parent and beneficially own, directly or indirectly, at least 51% of the issued Capital Stock of, and Equity Interest in, the Parent; or (y) at any time following the listing of the ordinary Capital Stock of the Parent (or a parent company of the Parent in a Qualified IPO) on an Approved Stock Exchange:

 

  (i) any Third Party:

 

  (A) owns legally and/or beneficially and either directly or indirectly at least thirty three per cent (33%) of the ordinary share capital of the Parent; or

 

  (B) has the right or the ability to control either directly or indirectly the affairs of or the composition of the majority of the board of directors (or equivalent) of the Parent; and

at the same time as any of the events described in paragraphs (A) or (B) of this definition have occurred and are continuing, the Permitted Holders in the aggregate do not, directly or indirectly, beneficially own at least 51% of the issued Capital Stock of, and Equity Interest in, the Parent; or

 

  (ii) the Parent (or such parent company of the Parent) ceases to be a listed company on an Approved Stock Exchange without the prior written consent of the Required Lenders,

(and, for the purpose of Section 11.16 “control” of any company, limited partnership or other legal entity (a “body corporate”) controlled by a Permitted Holder means that one or more members of a Permitted Holder in the aggregate has, directly or indirectly, the power to direct the management and policies of such a body corporate, whether through the ownership of more than 50% of the issued voting capital of that body corporate or by contract, trust or other arrangement).

 

-5-


Charterer’s Assignment and Subordination” shall have the meaning provided in the definition of “Collateral and Guaranty Requirements”.

Collateral” shall mean all property (whether real or personal) with respect to which any security interests have been granted (or purported to be granted) pursuant to any Security Document, including, without limitation, all Earnings and Insurance Collateral, the Construction Risk Insurances in respect of each New Vessel, the Collateral Vessel, the Refund Guarantees in respect of each New Vessel, the Construction Contracts in respect of each New Vessel and all cash and Cash Equivalents at any time delivered as collateral thereunder or as collateral required hereunder.

Collateral Agent” shall have the meaning provided in the first paragraph of this agreement, and shall include any successor thereto acting as mortgagee, security trustee or collateral agent for the Secured Creditors pursuant to the Security Documents.

Collateral and Guaranty Requirements” shall mean with respect to the Collateral Vessel, the requirement that:

(i) (A) the Borrower shall have duly authorized, executed and delivered an Assignment of Charter and Earnings substantially in the form of Exhibit F or otherwise reasonably acceptable to the Joint Lead Arrangers (as modified, supplemented or amended from time to time, the “Assignment of Charter and Earnings”) and an Assignment of Insurances substantially in the form of Exhibit G or otherwise reasonably acceptable to the Joint Lead Arrangers (as modified, supplemented or amended from time to time, the “Assignment of Insurances”), in each case (to the extent incorporated into or required by such Exhibits or otherwise agreed by the Borrower and the Joint Lead Arrangers) with appropriate notices, acknowledgements and consents relating thereto and (B) the Borrower shall use its commercially reasonable efforts to obtain an Assignment and Subordination Agreement from NCL (Bahamas) Ltd. (the “Bareboat Charterer”) substantially in the form of Exhibit P (as modified, supplemented or amended from time to time, the “Charterer’s Assignment and Subordination”) with respect to the bareboat charter of the Collateral Vessel by the Bareboat Charterer, with (to the extent incorporated into or required by such Exhibit or otherwise agreed by the Borrower, the Bareboat Charterer and the Collateral Agent) appropriate notices, acknowledgements and consents relating thereto, together covering all of the Borrower’s, and with respect to the Charterer’s Assignment and Subordination, the Bareboat Charterer’s, present and future Earnings and Insurance Collateral, in each case together with:

(a) proper financing statements (Form UCC-1 or the equivalent) fully prepared for filing in accordance with the UCC or in other appropriate filing offices of each jurisdiction as may be necessary or, in the reasonable opinion of the Collateral Agent, desirable to perfect or give notice to third parties of, as the case may be, the security interests purported to be created by the Assignment of Charter and Earnings, the Assignment of Insurances and the Charterer’s Assignment and Subordination; and

 

-6-


(b) certified copies of lien search results (Form UCC11) listing all effective financing statements that name each Credit Party as debtor and that are filed in the District of Columbia and Florida, together with Form UCC-3 Termination Statements (or such other termination statements as shall be required by local law) fully prepared for filing if required by applicable law to terminate financing statement which covers the Collateral except to the extent evidencing Permitted Liens.

(ii) the Borrower shall have duly authorized, executed and delivered, and caused to be registered in the appropriate vessel registry a mortgage and a deed of covenants (as modified, amended or supplemented from time to time in accordance with the terms thereof and hereof, and together with the Vessel Mortgage delivered pursuant to the definition of Flag Jurisdiction Transfer, the “Vessel Mortgage”), substantially in the form of Exhibit H or otherwise reasonably acceptable to the Joint Lead Arrangers with respect to the Collateral Vessel, and the Vessel Mortgage shall be effective to create in favor of the Collateral Agent a legal, valid and enforceable security interest, in and Lien upon the Collateral Vessel, which shall be prior to any other Liens and security interest in the Collateral Vessel other than Permitted Liens (which Permitted Liens shall include, for the avoidance of doubt, the Liens pursuant to the Senior Loan Agreements);

(iii) all filings, deliveries of notices and other instruments and other actions by the Credit Parties and/or the Collateral Agent necessary or desirable in the reasonable opinion of the Collateral Agent to perfect and preserve the security interests described in clauses (i) through and including (iii) above shall have been duly effected and the Collateral Agent shall have received evidence thereof in form and substance reasonably satisfactory to the Collateral Agent; and

(iv) the Facility Agent shall have received each of the following:

(a) certificates of ownership from appropriate authorities showing (or confirmation updating previously reviewed certificates and indicating) the registered ownership of the Collateral Vessel by the Borrower; and

(b) the results of maritime registry searches with respect to the Collateral Vessel, indicating that the Collateral Vessel has been deleted from all new building registers and that there are no record liens other than Liens in favor of the Collateral Agent and/or the Lenders and Permitted Liens; and

(c) class certificates reasonably satisfactory to it from Det Norske Veritas or another classification society listed on Schedule 8.21 hereto (or another internationally recognized classification society reasonably acceptable to the Facility Agent), indicating that the Collateral Vessel meets the criteria specified in Section 8.21; and

(d) certified copies of all Management Agreements; and

(e) certified copies of all ISM and ISPS Code documentation for the Collateral Vessel; and

 

-7-


(f) the Facility Agent shall have received a report, in substantially the form of Exhibit B or otherwise reasonably acceptable to the Facility Agent, from BankAssure or another firm of independent marine insurance brokers reasonably acceptable to the Facility Agent with respect to the insurance maintained (or to be maintained) by the Credit Parties in respect of the Collateral Vessel, together with a certificate in substantially the form of Exhibit C or otherwise reasonably acceptable to the Facility Agent, from another broker certifying that such insurances (i) are placed with such insurance companies and/or underwriters and/or clubs, in such amounts, against such risks, and in such form, as are customarily insured against by similarly situated insureds and (ii) include the Required Insurance. In addition, the Borrower shall reimburse the Facility Agent for the reasonable and documented costs of procuring customary mortgagee interest insurance and additional perils insurance in connection with the Collateral Vessel as contemplated by Section 9.03 (including Schedule 9.03).

Collateral Disposition” shall mean (i) the sale, lease, transfer or other disposition of the Collateral Vessel by the Borrower to any Person (it being understood that a Permitted Chartering Arrangement is not a Collateral Disposition) or the sale of 100% of the Capital Stock of the Borrower or (ii) any Event of Loss of the Collateral Vessel.

Collateral Vessel” shall mean the vessel owned by the Borrower and known on the date hereof as the NORWEGIAN JADE (IMO 9304057).

Commitment” shall mean, for each Lender, at any time, an amount equal to such Lender’s Percentage of the Total Allocable Commitments. The maximum Commitment of each Lender on the Effective Date is set forth on Schedule 1.01(a).

Commitment Letter” shall have the meaning provided in Section 14.09.

Commitment Termination Date” shall mean December 8, 2014.

Commitment Commission” shall have the meaning provided in Section 3.01(a).

Consolidated Debt Service” shall mean, for any relevant period, the sum (without double counting), determined in accordance with GAAP, of:

(i) the aggregate principal payable or paid during such period on any Indebtedness for Borrowed Money of any member of the NCLC Group, other than:

(a) principal of any such Indebtedness for Borrowed Money prepaid at the option of the relevant member of the NCLC Group or by virtue of “cash sweep” or “special liquidity” cash sweep provisions (or analogous provisions) in any debt facility of the NCLC Group;

(b) principal of any such Indebtedness for Borrowed Money prepaid upon a sale or an Event of Loss of any vessel owned or leased under a capital lease by any member of the NCLC Group; and

 

-8-


(c) balloon payments of any such Indebtedness for Borrowed Money payable during such period (and for the purpose of this paragraph (c) a “balloon payment” shall not include any scheduled repayment installment of such Indebtedness for Borrowed Money which forms part of the balloon);

(ii) Consolidated Interest Expense for such period;

(iii) the aggregate amount of any dividend or distribution of present or future assets, undertakings, rights or revenues to any shareholder of any member of the NCLC Group (other than the Parent, or one of its wholly owned Subsidiaries) or any Dividends other than the tax distributions described in Section 10.03(ii) in each case paid during such period; and

(iv) all rent under any capital lease obligations by which the Parent, or any consolidated Subsidiary is bound which are payable or paid during such period and the portion of any debt discount that must be amortized in such period,

as calculated in accordance with GAAP and derived from the then latest consolidated unaudited financial statements of the NCLC Group delivered to the Facility Agent in the case of any period ending at the end of any of the first three fiscal quarters of each fiscal year of the Parent and the then latest audited consolidated financial statements (including all additional information and notes thereto) of the Parent and its consolidated Subsidiaries together with the auditors’ report delivered to the Facility Agent in the case of the final quarter of each such fiscal year.

Consolidated EBITDA” shall mean, for any relevant period, the aggregate of:

(i) Consolidated Net Income from the Parent’s operations for such period; and

(ii) the aggregate amounts deducted in determining Consolidated Net Income for such period in respect of gains and losses from the sale of assets or reserves relating thereto, Consolidated Interest Expense, depreciation and amortization, impairment charges and any other non-cash charges and deferred income tax expense for such period.

Consolidated Interest Expense” shall mean, for any relevant period, the consolidated interest expense (excluding capitalized interest) of the NCLC Group for such period.

Consolidated Net Income” shall mean, for any relevant period, the consolidated net income (or loss) of the NCLC Group for such period as determined in accordance with GAAP.

Construction Contract” shall mean the Vessel 1 Construction Contract and/or the Vessel 2 Construction Contract, as applicable.

Construction Risk Insurances” shall mean any and all insurance policies related to a Construction Contract and the construction of a New Vessel.

 

-9-


Credit Documents” shall mean this Agreement, Sections 7 and 8 of the Commitment Letter, each Security Document, the Security Trust Deed, any Transfer Certificate, any Assignment Agreement, each Intercreditor Agreement and, after the execution and delivery thereof, each additional guaranty or additional security document executed pursuant to Section 9.10.

Credit Document Obligations” shall mean, except to the extent consisting of obligations, liabilities or indebtedness with respect to Interest Rate Protection Agreements or Other Hedging Agreements, the full and prompt payment when due (whether at the stated maturity, by acceleration or otherwise) of all obligations, liabilities and indebtedness (including, without limitation, principal, premium, interest, fees and indemnities (including, without limitation, all interest that accrues after the commencement of any case, proceeding or other action relating to the bankruptcy, insolvency, reorganization or similar proceeding of any Credit Party at the rate provided for in the respective documentation, whether or not a claim for post-petition interest is allowed in any such proceeding)) of each Credit Party to the Lender Creditors (provided, in respect of the Lender Creditors which are Lenders, such aforementioned obligations, liabilities and indebtedness shall arise only for such Lenders (in such capacity) in respect of Loans and/or Commitments), whether now existing or hereafter incurred under, arising out of, or in connection with this Agreement and the other Credit Documents to which such Credit Party is a party (including, in the case of each Credit Party that is a Guarantor, all such obligations, liabilities and indebtedness of such Credit Party under the Parent Guaranty) and the due performance and compliance by such Credit Party with all of the terms, conditions and agreements contained in this Agreement and in such other Credit Documents.

Credit Party” shall mean the Borrower, the Parent, each Subsidiary of the Parent that owns a direct interest in the Borrower, until the Vessel 1 Delivery Date, Breakaway One and, until the Vessel 2 Delivery Date, Breakaway Two.

Default” shall mean any event, act or condition which with notice or lapse of time, or both, would constitute an Event of Default.

Defaulting Lender” shall mean any Lender with respect to which a Lender Default is in effect.

Delegate Collateral Agent” shall mean Deutsche Schiffsbank Aktiengesellschaft in its capacity as trustee for the Secured Creditors with respect to the Trust Property Delegated (as defined in the Security Trust Deed) pursuant to the Security Trust Deed.

Delivery Date” shall mean the Vessel 1 Delivery Date and/or the Vessel 2 Delivery Date, as applicable.

Discharged Rights and Obligations” shall have the meaning provided in Section 13.06(c).

Dispute” shall have the meaning provided in Section 14.07(a).

 

-10-


Disqualified Stock” means, with respect to any Person, any Capital Stock of such Person which, by its terms (or by the terms of any security into which it is convertible or for which it is redeemable or exchangeable), or upon the happening of any event:

(1) matures or is mandatorily redeemable, pursuant to a sinking fund obligation or otherwise (other than as a result of a change of control or asset sale),

(2) is convertible or exchangeable for Indebtedness or Disqualified Stock of such Person, or

(3) is redeemable at the option of the holder thereof, in whole or in part (other than solely as a result of a change of control or asset sale), in each case prior to 91 days after the later of the Tranche A Loan Maturity Date and the Tranche B Loan Maturity Date; provided, however, that only the portion of Capital Stock which so matures or is mandatorily redeemable, is so convertible or exchangeable or is so redeemable at the option of the holder thereof prior to such date shall be deemed to be Disqualified Stock; provided, however, that if such Capital Stock is issued to any employee or to any plan for the benefit of employees of the Parent or its Subsidiaries or by any such plan to such employees, such Capital Stock shall not constitute Disqualified Stock solely because it may be required to be repurchased by the Parent in order to satisfy applicable statutory or regulatory obligations or as a result of such employee’s termination, death or disability; provided, further, that any class of Capital Stock of such Person that by its terms authorizes such Person to satisfy its obligations thereunder by delivery of Capital Stock that is not Disqualified Stock shall not be deemed to be Disqualified Stock.

Disruption Event” means either or both of:

(a) a material disruption to those payment or communications systems or to those financial markets which are, in each case, required to operate in order for payments to be made in connection with this Agreement (or otherwise in order for the transactions contemplated by the Credit Documents to be carried out) which disruption is not caused by, and is beyond the control of, any of the parties to this Agreement; or

(b) the occurrence of any other event which results in a disruption (of a technical or systems-related nature) to the treasury or payments operations of a party to this Agreement preventing such party, or any other party to this Agreement:

(i) from performing its payment obligations under the Credit Documents; or

(ii) from communicating with other parties to this Agreement in accordance with the terms of the Credit Documents,

and which (in either such case) is not caused by, and is beyond the control of, the party to this Agreement whose operations are disrupted.

Dividend” shall mean, with respect to any Person, that such Person or any Subsidiary of such Person has declared or paid a dividend or returned any equity capital to its

 

-11-


stockholders, partners or members or the holders of options or warrants issued by such Person with respect to its Capital Stock or membership interests or authorized or made any other distribution, payment or delivery of property (other than common stock or the right to purchase any of such stock of such Person) or cash to its stockholders, partners or members or the holders of options or warrants issued by such Person with respect to its Capital Stock or membership interests as such, or redeemed, retired, purchased or otherwise acquired, directly or indirectly, for a consideration any shares of any class of its Capital Stock or any other Capital Stock outstanding on or after the Effective Date (or any options or warrants issued by such Person with respect to its Capital Stock or other Equity Interests), or set aside any funds for any of the foregoing purposes, or shall have permitted any of its Subsidiaries to purchase or otherwise acquire for a consideration any shares of any class of the Capital Stock or any other Equity Interests of such Person outstanding on or after the Effective Date (or any options or warrants issued by such Person with respect to its Capital Stock or other Equity Interests). Without limiting the foregoing, “Dividends” with respect to any Person shall also include all payments made or required to be made by such Person with respect to any stock appreciation rights, plans, equity incentive or achievement plans or any similar plans or setting aside of any funds for the foregoing purposes.

Documentation Agent” shall have the meaning provided in the first paragraph of this Agreement, and shall include any successor thereto.

Dollars” and the sign “$” shall each mean lawful money of the United States.

Dollar Availability” shall mean, on any Borrowing Date, a Dollar amount equal to the excess of:

(x) the aggregate principal amount of Existing Jade Loans that the Borrower has repaid from and after the Effective Date and up to and including such Borrowing Date as determined pursuant to the schedule of repayments of Existing Jade Loans as set forth on Schedule 1.01(b) (“Existing Jade Scheduled Repayments”) (subject to Dollar-to-Dollar reduction to the extent the Borrower shall not have made the Existing Jade Scheduled Repayments as of such Borrowing Date); provided that such amount may be increased by the amount of voluntary and mandatory prepayments (other than of the Existing Jade Scheduled Repayments) of Existing Jade Loans that the Borrower has made on or prior to such Borrowing Date in 2011, 2012, 2013 and 2014, minus

(y) the Dollar amount of Loans borrowed prior to such Borrowing Date under this Agreement.

Dollar Maximum Amount” shall mean $130,194,139.00, or such greater amount as shall be agreed in writing by the Facility Agent, Hermes and the Parent.

Dollar Equivalent” shall mean, with respect to the Euro denominated Commitments being utilized on a Borrowing Date, the amount calculated by applying (x) in the event that the Borrower and/or the Parent have entered into Earmarked Foreign Exchange Arrangements with respect to the installment payment to be partially or wholly financed by the Loans to be disbursed on such Borrowing Date, the EUR/USD weighted average rate with

 

-12-


respect to such Borrowing Date (i) as notified by the Borrower to the Facility Agent in the Borrowing Notice at least three Business Days prior to the relevant Borrowing Date, (ii) which EUR/USD weighted average rate for any particular set of Earmarked Foreign Exchange Arrangements shall take account of all applicable foreign exchange spot, forward and derivative arrangements, including collars, options and the like, entered into in respect of such Borrowing Date and (iii) for which the Borrower has provided evidence to the Facility Agent to determine which foreign exchange arrangements (including spot transactions) will be the Earmarked Foreign Exchange Arrangements that shall apply to such Borrowing Date and (y) in the event that the Borrower and/or the Parent have not entered into Earmarked Foreign Exchange Arrangements with respect to the installment payment to be partially or wholly funded by the Loans to be disbursed on such Borrowing Date, the Spot Rate applicable to such Borrowing Date.

Dormant Subsidiary” means a Subsidiary that owns assets in an amount equal to no more than $5,000,000 or is dormant or otherwise inactive.

Earmarked Foreign Exchange Arrangements” shall mean the Euro/Dollar foreign exchange arranged by the Borrower and/or the Parent in connection with an installment payment to be partially or wholly financed by the Loans to be disbursed on the date on which such installment payment is to be made.

Earnings and Insurance Collateral” shall mean all “Earnings” and “Insurances”, as the case may be, as defined in the respective Assignment of Charter and Earnings, Charterer’s Assignment and Subordination, and the Assignment of Insurances.

ECF Borrowers” shall mean Breakaway One with respect to the Breakaway One Facility and Breakaway Two with respect to the Breakaway Two Facility.

ECF Collateral” shall mean all property (whether real or personal) with respect to which any security interest shall have been granted (or purported to be granted) pursuant to the Assignments of Contracts.

ECF Loans” shall mean loans made to an ECF Borrower under the relevant Export Credit Facility.

ECF Intercreditor Agreements” shall mean the Tranche A Intercreditor Agreement and the Tranche B Intercreditor Agreement.

Effective Date” has the meaning specified in Section 14.09.

Eligible Transferee” shall mean and include a commercial bank, insurance company, financial institution, fund or other Person which regularly purchases interests in loans or extensions of credit of the types made pursuant to this Agreement.

Environmental Approvals” shall have the meaning provided in Section 8.17(b).

Environmental Claims” shall mean any and all administrative, regulatory or judicial actions, suits, demands, demand letters, directives, claims, liens, notices of

 

-13-


noncompliance or violation, relating in any way to any Environmental Law or any permit issued, or any approval given, under any such Environmental Law (hereafter, “Claims”), including, without limitation, (a) any and all Claims by governmental or regulatory authorities for enforcement, cleanup, removal, response, remedial or other actions or damages pursuant to any applicable Environmental Law, and (b) any and all Claims by any third party seeking damages, contribution, indemnification, cost recovery, compensation or injunctive relief in connection with alleged injury or threat of injury to health, safety or the environment due to the presence of Hazardous Materials.

Environmental Law” shall mean any applicable Federal, state, foreign or local statute, law, rule, regulation, ordinance, code, binding and enforceable guideline, binding and enforceable written policy and rule of common law now or hereafter in effect and in each case as amended, and any judicial or administrative interpretation thereof, including any judicial or administrative order, consent decree or judgment, to the extent binding on the Parent or any of its Subsidiaries, relating to the environment, and/or Hazardous Materials, including, without limitation, CERCLA; OPA; the Federal Water Pollution Control Act, 33 U.S.C. § 1251 et seq.; the Hazardous Material Transportation Act, 49 U.S.C. § 1801 et seq.; the Occupational Safety and Health Act, 29 U.S.C. § 651 et seq. (to the extent it regulates occupational exposure to Hazardous Materials); and any state and local or foreign counterparts or equivalents, in each case as amended from time to time.

Environmental Release” shall mean any spilling, leaking, pumping, pouring, emitting, emptying, discharging, injecting, escaping, leaching, dumping, disposing or migration into the environment.

Equity Interests” means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt security that is convertible into, or exchangeable for, Capital Stock).

Euro” and the sign “” shall each mean single currency in the member states of the European Communities that adopt or have adopted the Euro as its lawful currency under the legislation of the European Union for European Monetary Union.

Eurodollar Rate” shall mean with respect to each Interest Period for a Loan, the offered rate (rounded upward to the nearest 1/100 of 1%) for deposits of Dollars for a period equivalent to such period at or about 11:00 A.M. (Frankfurt time) on the second Business Day before the first day of such period as is displayed on Reuters LIBOR 01 Page (or such other service as may be nominated by the British Bankers’ Association as the information vendor for displaying the London Interbank Offered Rates of major banks in the London Interbank Market) (the “Screen Rate”), provided that if on such date no such rate is so displayed, the Eurodollar Rate for such period shall be the arithmetic average (rounded upward to the nearest 1/100 of 1%) of the rate quoted to the Facility Agent by the Reference Banks for deposits of Dollars in an amount approximately equal to the amount in relation to which the Eurodollar Rate is to be determined for a period equivalent to such applicable Interest Period by the prime banks in the London interbank Eurodollar market at or about 11:00 A.M. (Frankfurt time) on the second Business Day before the first day of such period, in each case rounded upward to the nearest 1/100 of 1%.

 

-14-


Event of Default” shall have the meaning provided in Section 11.

Event of Loss” shall mean any of the following events: (x) the actual or constructive total loss of the Collateral Vessel or the agreed or compromised total loss of the Collateral Vessel; or (y) the capture, condemnation, confiscation, requisition (but excluding any requisition for hire by or on behalf of any government or governmental authority or agency or by any persons acting or purporting to act on behalf of any such government or governmental authority or agency), purchase, seizure or forfeiture of, or any taking of title to, the Collateral Vessel. An Event of Loss shall be deemed to have occurred: (i) in the event of an actual loss of the Collateral Vessel, at the time and on the date of such loss or if such time and date are not known at noon Greenwich Mean Time on the date which the Collateral Vessel was last heard from; (ii) in the event of damage which results in a constructive or compromised or arranged total loss of the Collateral Vessel, at the time and on the date on which notice claiming the loss of the Collateral Vessel is given to the insurers; or (iii) in the case of an event referred to in clause (y) above, at the time and on the date on which such event is expressed to take effect by the Person making the same. Notwithstanding the foregoing, if the Collateral Vessel shall have been returned to the Borrower or any Subsidiary of the Borrower following any event referred to in clause (y) above prior to the date upon which payment is required to be made under Section 4.02(b) hereof, no Event of Loss shall be deemed to have occurred by reason of such event so long as the requirements set forth in Section 9.10 have been satisfied.

Excluded Taxes” shall have the meaning provided in Section 4.04(a).

Existing Jade Facility” shall mean that certain secured loan agreement dated 20 April 2004 between the Borrower, the several banks party thereto as arrangers and underwriters, the several banks party thereto as lenders, HSBC Bank plc as agent, Commerzbank Aktiengesellschaft as Hermes agent and HSBC Bank plc as trustee, including all amendments, amendments and restatements, supplements, novations or other modifications thereto.

Existing Jade Loans” shall mean all loans and other advances made to the Borrower under the Existing Jade Facility.

Existing Jade Scheduled Repayments” shall have the meaning provided in the definition of “Dollar Availability”.

Existing Lender” shall have the meaning provided in Section 13.01.

Export Credit Documents” shall mean the “Credit Documents” as defined in the Export Credit Facilities.

Export Credit Facilities” shall mean the Breakaway One Facility and the Breakaway Two Facility.

Facility Agent” shall have the meaning provided in the first paragraph of this Agreement, and shall include any successor thereto.

Facility Office” means (a) in respect of a Lender, the office or offices notified by that Lender to the Facility Agent in writing on or before the date it becomes a Lender (or,

 

-15-


following that date, by not less than five Business Days’ written notice) as the office or offices through which it will perform its obligations under this Agreement; or (b) in respect of any other Lender Creditor, the office in the jurisdiction in which it is resident for tax purposes.

Final Construction Price” shall mean the actual final construction price of a New Vessel.

Flag Jurisdiction Transfer” shall mean the transfer of the registration and flag of the Collateral Vessel from one Acceptable Flag Jurisdiction to another Acceptable Flag Jurisdiction, provided that the following conditions are satisfied with respect to such transfer:

(i) On each Flag Jurisdiction Transfer Date, the Borrower shall have duly authorized, executed and delivered, and caused to be recorded in the appropriate vessel registry a Vessel Mortgage that is reasonably satisfactory in form and substance to the Facility Agent with respect to the Collateral Vessel and such Vessel Mortgage shall be effective to create in favor of the Collateral Agent and/or the Lenders a legal, valid and enforceable first priority security interest, in and lien upon the Collateral Vessel, subject only to Permitted Liens. All filings, deliveries of instruments and other actions necessary or desirable in the reasonable opinion of the Collateral Agent to perfect and preserve such security interests shall have been duly effected and the Collateral Agent shall have received evidence thereof in form and substance reasonably satisfactory to the Collateral Agent.

(ii) On each Flag Jurisdiction Transfer Date, to the extent that any Security Documents are released or discharged pursuant to Section 14.21(b), the Borrower shall have duly authorized, executed and delivered corresponding Security Documents in favor of the Collateral Agent for the new Acceptable Flag Jurisdiction.

(iii) On each Flag Jurisdiction Transfer Date, the Facility Agent shall have received from counsel, an opinion addressed to the Facility Agent and each of the Lenders and dated such Flag Jurisdiction Transfer Date, which shall (x) be in form and substance reasonably acceptable to the Facility Agent and (y) cover the recordation of the security interests granted pursuant to the Vessel Mortgage to be delivered on such date and such other matters incident thereto as the Facility Agent may reasonably request.

(iv) On each Flag Jurisdiction Transfer Date:

(A) The Facility Agent shall have received (x) certificates of ownership from appropriate authorities showing (or confirmation updating previously reviewed certificates and indicating) the registered ownership of the Collateral Vessel transferred on such date by the Borrower and (y) the results of maritime registry searches with respect to the Collateral Vessel transferred on such date, indicating no record liens other than Liens in favor of the Collateral Agent and/or the Lenders and Permitted Liens.

(B) The Facility Agent shall have received a report, in form and scope reasonably satisfactory to the Facility Agent, from a firm of independent marine insurance brokers reasonably acceptable to the Facility Agent with respect to the

 

-16-


insurance maintained by the Borrower in respect of the Collateral Vessel transferred on such date, together with a certificate from another broker certifying that such insurances (i) are placed with such insurance companies and/or underwriters and/or clubs, in such amounts, against such risks, and in such form, as are customarily insured against by similarly situated insureds for the protection of the Facility Agent and/or the Lenders as mortgagee and (ii) conform with the Required Insurance applicable to the Collateral Vessel.

(v) On or prior to each Flag Jurisdiction Transfer Date, the Facility Agent shall have received a certificate, dated the Flag Jurisdiction Transfer Date, signed by any one of the chairman of the board, the president, any vice president, the treasurer or an authorized manager, member, general partner, officer or attorney-in-fact of the Borrower, certifying that (A) all necessary governmental (domestic and foreign) and third party approvals and/or consents in connection with the Flag Jurisdiction Transfer being consummated on such date and otherwise referred to herein shall have been obtained and remain in effect or that no such approvals and/or consents are required, (B) there exists no judgment, order, injunction or other restraint prohibiting or imposing materially adverse conditions upon such Flag Jurisdiction Transfer or the other related transactions contemplated by this Agreement and (C) copies of resolutions approving the Flag Jurisdiction Transfer of the Borrower and any other related matters the Facility Agent may reasonably request.

(vi) On each Flag Jurisdiction Transfer Date, the Collateral and Guaranty Requirements for the Transferred Collateral Vessel shall have been satisfied or waived by the Facility Agent for a specific period of time.

Flag Jurisdiction Transfer Date” shall mean the date on which a Flag Jurisdiction Transfer occurs.

Free Liquidity” shall mean, at any date of determination, the aggregate of the Cash Balance and any Commitments under this Agreement or any other amounts available for drawing under other revolving or other credit facilities of the NCLC Group, which remain undrawn, could be drawn for general working capital purposes or other general corporate purposes and would not, if drawn, be repayable within six months.

GAAP” shall have the meaning provided in Section 14.06(a).

Grace Period” shall have the meaning provided in Section 11.05(c).

Guarantor” shall mean Parent.

Hazardous Materials” shall mean: (a) any petroleum or petroleum products, radioactive materials, asbestos in any form that is or could become friable, urea formaldehyde foam insulation, transformers or other equipment that contain dielectric fluid containing levels of polychlorinated biphenyls, and radon gas; (b) any chemicals, materials or substances defined as or included in the definition of “hazardous substances,” “hazardous waste,” “hazardous materials,” “extremely hazardous substances,” “restricted hazardous waste,” “toxic substances,” “toxic pollutants,” “contaminants,” or “pollutants,” or words of similar import, under any

 

-17-


applicable Environmental Law; and (c) any other chemical, material or substance, exposure to which is prohibited, limited or regulated by any governmental authority under Environmental Laws.

Hermes” shall mean the Federal Republic of Germany represented by the Federal Ministry of Economics and Technology (Bundesministerium für Wirtschaft und Technologie) represented by Euler Hermes Kreditversicherungs-AG and PriceWaterhouseCoopers Wirtschaftsprüfungsgesellschaft AG.

Hermes Agent” shall have the meaning provided in the first paragraph of this Agreement, and shall include any successor thereto, acting as attorney-in-fact for the Lenders with respect to the Hermes Cover to the extent described in this Agreement.

Hermes Cover” shall mean the export credit guarantee (Exportkreditgarantie) on the terms of Hermes’ Declaration of Guarantee (Gewährleistungs-Erklärung) for [*] of the principal amount of the Loans and any interests and secondary financing costs of the Federal Republic of Germany acting through Euler Hermes Kreditversicherungs-AG for the period of the Loans on the terms and conditions applied for by the Lenders, and shall include any successor thereto (it being understood that the Hermes Cover shall be issued on the basis of Hermes’ applicable Hermes guidelines (Richtlinien) and general terms and conditions (Allgemeine Bedingungen)).

Hermes Insurance Premium” shall mean the amount payable in Euro by the Borrower and the Jewel Borrower to Hermes through the Hermes Agent in respect of the Hermes Cover relating to the Term Loan Facilities, which shall not in the aggregate for the Jade Term Loan Facility and the Other Term Loan Facility exceed [*].

Hermes Issuing Fees” shall mean the [*] payable in Euro by the Borrower to Hermes through the Hermes Agent by way of handling fees in respect of the Hermes Cover.

Hermes Premium” shall mean the aggregate of the Hermes Issuing Fees and the Hermes Insurance Premium.

Impaired Agent” shall mean an Agent at any time when:

 

  (i) it has failed to make (or has notified a party to this Agreement that it will not make) a payment required to be made by it under the Credit Documents by the due date for payment;

 

  (ii) such Agent otherwise rescinds or repudiates a Credit Document;

 

  (iii) (if such Agent is also a Lender) it is a Defaulting Lender; or

 

  (iv) an Insolvency Event has occurred and is continuing with respect to such Agent

unless, in the case of paragraph (i) above: (a) its failure to pay is caused by administrative or technical error or a Disruption Event, and payment is made within five Business Days of its due date; or (b) such Agent is disputing in good faith whether it is contractually obliged to make the payment in question.

 

-18-


Indebtedness” shall mean any obligation for the payment or repayment of money, whether as principal or as surety and whether present or future, actual or contingent including, without limitation, pursuant to an Interest Rate Protection Agreement or Other Hedging Agreement.

Indebtedness for Borrowed Money” shall mean Indebtedness (whether present or future, actual or contingent, long-term or short-term, secured or unsecured) in respect of:

 

  (i) moneys borrowed or raised;

 

  (ii) the advance or extension of credit (including interest and other charges on or in respect of any of the foregoing);

 

  (iii) the amount of any liability in respect of leases which, in accordance with GAAP, are capital leases;

 

  (iv) the amount of any liability in respect of the purchase price for assets or services payment of which is deferred for a period in excess of 180 days;

 

  (v) all reimbursement obligations whether contingent or not in respect of amounts paid under a letter of credit or similar instrument; and

 

  (vi) (without double counting) any guarantee of Indebtedness falling within paragraphs (i) to (v) above;

provided that the following shall not constitute Indebtedness for Borrowed Money:

 

  (a) loans and advances made by other members of the NCLC Group which are subordinated to the rights of the Lenders;

 

  (b) loans and advances made by any shareholder of the Parent which are subordinated to the rights of the Lenders on terms reasonably satisfactory to the Facility Agent; and

 

  (c) any liabilities of the Parent or any other member of the NCLC Group under any Interest Rate Protection Agreement or any Other Hedging Agreement or other derivative transactions of a non-speculative nature.

Information” shall have the meaning provided in Section 8.10(a).

Initial Borrowing Dates” shall mean the Tranche A Initial Borrowing Date and the Tranche B Initial Borrowing Date.

Initial Construction Price” shall mean for each New Vessel an amount of up to €615,000,000 for the construction of such New Vessel in each case pursuant to the relevant Construction

 

-19-


Contract, payable by the relevant ECF Borrower to the Yard through the four installments of the Initial Contract Price referred to in Article 8, Clauses 2.1(i) through and including (iv) of each Construction Contract (each, a “Pre-delivery Installment”) and the installment of the Initial Contract Price referred to in Article 8, Clause 2.1(v) of each Construction Contract.

Insolvency Event” in relation to any of the parties to this Agreement shall mean that such party:

 

  (i) is dissolved (other than pursuant to a consolidation, amalgamation or merger);

 

  (ii) becomes insolvent or is unable to pay its debts or fails or admits in writing its inability generally to pay its debts as they become due;

 

  (iii) makes a general assignment, arrangement or composition with or for the benefit of its creditors;

 

  (iv) institutes or has instituted against it, by a regulator, supervisor or any similar official with primary insolvency, rehabilitative or regulatory jurisdiction over it in the jurisdiction of its incorporation or organization or the jurisdiction of its head or home office, a proceeding seeking a judgment of insolvency or bankruptcy or any other relief under any bankruptcy or insolvency law or other similar law affecting creditors’ rights, or a petition is presented for its winding-up or liquidation by it or such regulator, supervisor or similar official;

 

  (v) has instituted against it a proceeding seeking a judgment of insolvency or bankruptcy or any other relief under any bankruptcy or insolvency law or other similar law affecting creditors’ rights, or a petition is presented for its winding-up or liquidation, and, in the case of any such proceeding or petition instituted or presented against it, such proceeding or petition is instituted or presented by a person or entity not described in paragraph (iv) above and (a) results in a judgment of insolvency or bankruptcy or the entry of an order for relief or the making of an order for its winding-up or liquidation; or (b) is not dismissed, discharged, stayed or restrained in each case within 30 days of the institution or presentation thereof;

 

  (vi) has exercised in respect of it one or more of the stabilization powers pursuant to Part 1 of the Banking Act 2009 and/or has instituted against it a bank insolvency proceeding pursuant to Part 2 of the Banking Act 2009 or a bank administration proceeding pursuant to Part 3 of the Banking Act 2009;

 

  (vii) has a resolution passed for its winding-up, official management or liquidation (other than pursuant to a consolidation, amalgamation or merger);

 

-20-


  (viii) seeks or becomes subject to the appointment of an administrator, provisional liquidator, conservator, receiver, trustee, custodian or other similar official for it or for all or substantially all its assets;

 

  (ix) has a secured party take possession of all or substantially all its assets or has a distress, execution, attachment, sequestration or other legal process levied, enforced or sued on or against all or substantially all its assets and such secured party maintains possession, or any such process is not dismissed, discharged, stayed or restrained, in each case within 30 days thereafter;

 

  (x) causes or is subject to any event with respect to it which, under the applicable laws of any jurisdiction, has an analogous effect to any of the events specified in paragraphs (i) to (ix) above; or

 

  (xi) takes any action in furtherance of, or indicating its consent to, approval of, or acquiescence in, any of the foregoing acts.

Intercreditor Agreements” shall mean the Jade Intercreditor Agreement and the ECF Intercreditor Agreements.

Interest Determination Date” shall mean, with respect to any Loan, the second Business Day prior to the commencement of any Interest Period relating to such Loan.

Interest Period” shall have the meaning provided in Section 2.07.

Interest Rate Protection Agreement” shall mean any interest rate swap agreement, interest rate cap agreement, interest collar agreement, interest rate hedging agreement, interest rate floor agreement or other similar agreement or arrangement entered into between a Lender or its Affiliate, or a Joint Lead Arranger or its Affiliate, and the Parent and/or the Borrower in relation to the Credit Document Obligations of the Borrower under this Agreement.

Investments” shall have the meaning provided in Section 10.04.

Jade Collateral” shall mean all Collateral other than the ECF Collateral.

Jade Intercreditor Agreement” shall mean the fourth deed of co-ordination between the Borrower, HSBC Bank plc as first mortgagee, DnB NOR Bank ASA as second mortgagee, DnB NOR Bank ASA as third mortgagee and the Facility Agent as fourth mortgagee, substantially in the form of Exhibit M-3 or otherwise agreed by the parties thereto.

Jade Term Loan Facility” shall have the meaning provided in the recitals hereto.

Joint Lead Arrangers” shall have the meaning provided in the first paragraph of this Agreement, and shall include any successor thereto.

 

-21-


Lender” shall mean each financial institution listed on Schedule 1.01(a), as well as any Person which becomes a “Lender” hereunder pursuant to Section 13.

Lender Creditors” shall mean the Lenders holding from time to time outstanding Loans and/or Commitments, and the Agents, each in their respective capacities.

Lender Default” shall mean, as to any Lender, (i) the wrongful refusal (which has not been retracted) of such Lender or the failure of such Lender to make available its portion of any Borrowing, unless such failure to pay is caused by administrative or technical error or a Disruption Event and payment is made within three Business Days of its due date; (ii) such Lender having been deemed insolvent or having become the subject of a takeover by a regulatory authority or with respect to which an Insolvency Event has occurred and is continuing; (iii) such Lender having notified the Facility Agent and/or any Credit Party (x) that it does not intend to comply with its obligations under Section 2.01 in circumstances where such non-compliance would constitute a breach of such Lender’s obligations under such Section or (y) of the events described in preceding clause (ii); or (iv) if such Lender is a lender under an Export Credit Facility, such Lender not being in compliance with its refinancing obligations under its respective “Refinancing Agreement” under and as defined in either Export Credit Facility.

Lien” shall mean any mortgage, pledge, hypothecation, assignment, deposit arrangement, encumbrance, lien (statutory or other), preference, priority or other security agreement of any kind or nature whatsoever (including, without limitation, any conditional sale or other title retention agreement, any financing or similar statement or notice filed under the UCC or any other similar recording or notice statute, and any lease having substantially the same effect as any of the foregoing); provided that in no event shall an operating lease be deemed to constitute a Lien.

Lim Family” shall mean:

(i) the late Tan Sri Lim Goh Tong;

(ii) his spouse;

(iii) his direct lineal descendants;

(iv) the personal estate of any of the above persons; and

(v) any trust created for the benefit of one or more of the above persons and their estates.

Loan” shall have the meaning provided in Section 2.01.

Management Agreements” shall mean any agreements entered into by the Borrower with the Manager or such other commercial manager and/or a technical manager (in each case reasonably acceptable to the Facility Agent, it being understood that NCL (Bahamas) Ltd. is acceptable) with respect to the management of the Collateral Vessel.

 

-22-


Manager” shall mean the company providing commercial and technical management and crewing services for the Collateral Vessel pursuant to the Management Agreements, which as of the first Initial Borrowing Date is NCL (Bahamas) Ltd., a company organized and existing under the laws of Bermuda.

Mandatory Costs” means the percentage rate per annum calculated in accordance with Schedule 1.01(c).

Market Disruption Event” shall mean:

(i) at or about noon on the Interest Determination Date for the relevant Interest Period the Screen Rate is not available and none or only one of the Lenders supplies a rate to the Facility Agent to determine the Eurodollar Rate for the relevant Interest Period; or

(ii) before 5:00 P.M. Frankfurt time on the Interest Determination Date for the relevant Interest Period, the Facility Agent receives notifications from Lenders the sum of whose Commitments and/or outstanding Loans at such time equal at least 50% of the sum of the Total Allocable Commitment and/or aggregate outstanding Loans of the Lenders at such time that (x) the cost to such Lenders of obtaining matching deposits in the London interbank Eurodollar market for the relevant Interest Period would be in excess of the Eurodollar Rate for such Interest Period or (y) such Lenders are unable to obtain funding in the London interbank Eurodollar market.

Material Adverse Effect” shall mean the occurrence of anything since June 30, 2010 which has had or would reasonably be expected to have a material adverse effect on (x) the property, assets, business, operations, liabilities, or condition (financial or otherwise) of the Parent and its subsidiaries taken as a whole, (y) the consummation of the transactions hereunder, the acquisition of a New Vessel and the relevant Construction Contract, or (z) the rights or remedies of the Lenders, or the ability of the Parent and its relevant Subsidiaries to perform their obligations owed to the Lenders and the Agents under this Agreement.

Materials of Environmental Concern” shall have the meaning provided in Section 8.17(a).

Moody’s” shall mean Moody’s Investors Service, Inc. and its successors.

NCLC Fleet” shall mean the vessels owned by the companies in the NCLC Group.

NCLC Group” shall mean the Parent and its Subsidiaries.

New Lender” shall mean a Person who has been assigned the rights or transferred the rights and obligations of an Existing Lender, as the case may be, pursuant to the provisions of Section 13.

New Vessels” shall mean Vessel 1 and Vessel 2.

 

-23-


Non-Defaulting Lender” shall mean and include each Lender other than a Defaulting Lender.

Notice of Borrowing” shall have the meaning provided in Section 2.03.

Notice Office” shall mean (x) in the case of the Facility Agent, the office of the Facility Agent located at Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, Attention: Ship Finance, X2a4, Claudia Wenzel, fax: +49 69 7431 2944, email: claudia.wenzel@kfw.de or such other office as the Facility Agent may hereafter designate in writing as such to the other parties hereto and (y) in the case of the Hermes Agent, the office of the Hermes Agent located at Kaiserplatz / Kaiserstr. 16, D-60311 Frankfurt am Main, Germany, Attention: Corporate Banking, Structured Export & Trade Finance, Klaus-Dieter Schmedding, fax: +49 69 136 23742, email Klaus-dieter.schmedding@commerzbank.com (with an additional copy to exportfinance@commerzbank.com) or such other office as the Hermes Agent may hereafter designate in writing as such to the other parties hereto.

OPA” shall mean the Oil Pollution Act of 1990, as amended, 33 U.S.C. § 2701 et seq.

Other Creditors” shall mean any Lender or any Affiliate thereof and their successors, transferees and assigns if any (even if such Lender subsequently ceases to be a Lender under this Agreement for any reason), together with such Lender’s or Affiliate’s successors, transferees and assigns with which the Parent and/or the Borrower enters into any Interest Rate Protection Agreements or Other Hedging Agreements from time to time.

Other Hedging Agreement” shall mean any foreign exchange contracts, currency swap agreements, commodity agreements or other similar agreements or arrangements entered into between a Lender or its Affiliate, or a Joint Lead Arranger or its Affiliates, and the Parent and/or the Borrower in relation to the Credit Document Obligations of the Borrower under this Agreement and designed to protect against the fluctuations in currency or commodity values.

Other Obligations” shall mean the full and prompt payment when due (whether at the stated maturity, by acceleration or otherwise) of all obligations, liabilities and indebtedness (including, without limitation, all interest that accrues after the commencement of any case, proceeding or other action relating to the bankruptcy, insolvency, reorganization or similar proceeding of any Credit Party at the rate provided for in the respective documentation, whether or not a claim for post-petition interest is allowed in any such proceeding) owing by any Credit Party to the Other Creditors under, or with respect to any Interest Rate Protection Agreement or Other Hedging Agreement, whether such Interest Rate Protection Agreement or Other Hedging Agreement is now in existence or hereafter arising, and the due performance and compliance by such Credit Party with all of the terms, conditions and agreements contained therein.

Other Term Loan Credit Documents” shall mean collectively, the “Credit Documents” as defined in the Other Term Loan Facility.

Other Term Loan Facility” shall have the meaning provided in the recitals hereto.

 

-24-


Parent” shall have the meaning provided in the first paragraph of this Agreement.

Parent Guaranty” shall mean the guaranty of the Parent pursuant to Section 15.

PATRIOT Act” shall have the meaning provided in Section 14.09.

Payment Date” shall mean the last Business Day of each December, March, June and September, commencing with December, 2010.

Payment Office” shall mean the office of the Facility Agent located at Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, or such other office as the Facility Agent may hereafter designate in writing as such to the other parties hereto.

Percentage” for each Lender shall equal the percentage set forth opposite each Lender’s name on Schedule 1.01(a) hereto as such percentage may be adjusted from time to time as a result of assignments and/or transfers to or from such Lender pursuant to Sections 2.11 or 13.04(b).

Permitted Change Orders” shall mean change orders and similar arrangements under a Construction Contract which increase the relevant Initial Construction Price to the extent that the aggregate amount of such increases does not exceed [*] of such Initial Construction Price (it being understood that the actual amount of change orders and similar arrangements may exceed [*] of such Initial Construction Price).

Permitted Chartering Arrangements” shall mean:

 

  (i) any charter or other form of deployment (other than a demise or bareboat charter) of the Collateral Vessel made between members of the NCLC Group;

 

  (ii) any demise or bareboat charter of the Collateral Vessel made between members of the NCLC Group provided that (a) each of the Borrower and the charterer assigns the benefit of any such charter or sub-charter to the Collateral Agent, (b) each of the Borrower and the charterer assigns its interest in the insurances and earnings in respect of the Collateral Vessel to the Collateral Agent, and (c) the charterer agrees to subordinate its interests in the Collateral Vessel to the interests of the Collateral Agent as mortgagee of the Collateral Vessel, all on terms and conditions reasonably acceptable to the Collateral Agent;

 

  (iii) any charter or other form of deployment of the Collateral Vessel to a charterer that is not a member of the NCLC Group provided that no such charter or deployment shall be made (a) on a demise or bareboat basis, or (b) for a period which, with the exercise of any options for extension, could be for longer than 13 months, or (c) other than at or about market rate at the time when the charter or deployment is fixed; and

 

-25-


  (iv) any charter or other form of deployment in respect of the Collateral Vessel entered into after the Effective Date and which is permissible under the provisions of any financing documents relating to the Collateral Vessel.

Permitted Holders” shall mean (i) the Lim Family (together or individually) and (ii) Apollo and any Person directly controlled by Apollo.

Permitted Liens” shall have the meaning provided in Section 10.01.

Person” shall mean any individual, partnership, joint venture, firm, corporation, association, trust or other enterprise or any government or political subdivision, department or instrumentality thereof.

Pre-delivery Installment” shall have the meaning provided in the definition of Initial Construction Price.

Pro Rata Share” shall have the definition provided in Section 4.05.

Projections” shall mean any projections and any forward-looking statements (including statements with respect to booked business) of the NCLC Group furnished to the Lenders or the Facility Agent by or on behalf of any member of the NCLC Group prior to the Effective Date.

Qualified IPO” means an initial public offering of the Parent or a parent company of the Parent in either case on an Approved Stock Exchange resulting in at least [*] of equity (x) in the case of an initial public offering by a parent company of the Parent, being contributed to the Parent or (y) in the case of an initial public offering by the Parent, sold by the Parent.

Reference Banks” shall mean each Joint Lead Arranger.

Refund Guarantee” shall mean a refund guarantee arranged by the Yard in respect of a Pre-delivery Installment and provided by one or more financial institutions contemplated by the relevant Construction Contract, or by other financial institutions reasonably satisfactory to the Joint Lead Arrangers, as credit support for the Yard’s obligations thereunder.

Register” shall have the meaning provided in Section 14.15.

Relevant Obligations” shall have the meaning provided in Section 13.07(c)(ii).

Replaced Lender” shall have the meaning provided in Section 2.11.

Replacement Lender” shall have the meaning provided in Section 2.11.

Representative” shall have the meaning provided in Section 4.05(d).

Required Insurance” shall have the meaning provided in Section 9.03.

 

-26-


Required Lenders” shall mean, at any time, Non-Defaulting Lenders, the sum of whose outstanding Commitments and/or principal amount of Loans at such time represent an amount greater than 66- 2/3% of the sum of the Total Allocable Commitment (less the aggregate Commitments of all Defaulting Lenders at such time) and the aggregate principal amount of outstanding Loans (less the amount of outstanding Loans of all Defaulting Lenders at such time).

S&P” shall mean Standard & Poor’s Rating Services, a division of the McGraw-Hill Companies, Inc., and its successors.

Scheduled Repayment” shall have the meaning provided in Section 4.02(a).

Screen Rate” shall have the meaning specified in the definition of Eurodollar Rate.

Secured Creditors” shall mean the “Secured Creditors” as defined in the Security Documents.

Secured Obligations” shall mean (i) the Credit Document Obligations, (ii) the Other Obligations, (iii) any and all sums advanced by any Agent in order to preserve the Collateral or preserve the Collateral Agent’s security interest in the Collateral on behalf of the Lenders, (iv) in the event of any proceeding for the collection or enforcement of any indebtedness, obligations or liabilities of the Credit Parties referred to in clauses (i) and (ii) above, after an Event of Default shall have occurred and be continuing, the expenses in connection with retaking, holding, preparing for sale or lease, selling or otherwise disposing of or realizing on the Collateral, or of any exercise by the Collateral Agent of its rights hereunder on behalf of the Lenders, together with reasonable attorneys’ fees and court costs, and (v) all amounts paid by any Secured Creditor as to which such Secured Creditor has the right to reimbursement under the Security Documents.

Security Documents” shall mean, as applicable, the Assignments of Contracts, the Assignment of Charter and Earnings, the Assignment of Insurances, the Charterer’s Assignment and Subordination, the Assignments of KfW Refund Guarantees, the Vessel Mortgage, and, after the execution thereof, each additional security document executed pursuant to Sections 9.10 and/or 12.01(b).

Security Trust Deed” shall mean the Security Trust Deed executed by, inter alia, the Borrower, the Guarantor, the Collateral Agent, the Facility Agent, the Original Secured Creditors (as defined therein) and the Delegate Collateral Agent, and shall be substantially in the form of Exhibit N or otherwise reasonably acceptable to the Facility Agent.

Senior Loan Agreements” shall have the meaning provided in the Jade Intercreditor Agreement, and shall include any modifications, refinancings, replacements, novations and amendments thereof.

Specified Requirements” shall mean the requirements set forth in clauses (i)(A) and (i)(B) (excluding, for the avoidance of doubt, clauses (i)(a) or (i)(b)), (ii) and (iv)(f) of the definition of “Collateral and Guaranty Requirements.”

 

-27-


Spot Rate” shall mean the spot exchange rate quoted by the Facility Agent equal to the weighted average of the rates on the actual transactions of the Facility Agent on the date two Business Days prior to the date of determination thereof (acting reasonably), which spot exchange rate shall be final and conclusive absent manifest error.

Subsidiary” shall mean, as to any Person, (i) any corporation more than 50% of whose stock of any class or classes having by the terms thereof ordinary voting power to elect a majority of the directors of such corporation (irrespective of whether or not at the time stock of any class or classes of such corporation shall have or might have voting power by reason of the happening of any contingency) is at the time owned by such Person and/or one or more Subsidiaries of such Person and (ii) any partnership, limited liability company, association, joint venture or other entity in which such Person and/or one or more Subsidiaries of such Person has more than a 50% Equity Interest at the time.

Supervision Agreements” shall mean any agreements (if any) entered or to be entered into between the Parent, as applicable, the Borrower and a Supervisor providing for the construction supervision of the relevant New Vessel, the terms and conditions of which shall be in form and substance reasonably satisfactory to the Facility Agent.

Supervisor” shall have the meaning provided in the Construction Contracts.

Tax Benefit” shall have the meaning provided in Section 4.04(c).

Taxes” and “Taxation” shall have the meaning provided in Section 4.04(a).

Term Loan Facilities” shall have the meaning provided in the recitals hereto.

Test Period” shall mean each period of four consecutive fiscal quarters then last ended, in each case taken as one accounting period.

Third Party” shall mean any Person or group of Persons acting in concert who or which does not include a member of the Lim Family or Apollo.

Total Allocable Commitment” shall mean, at any time, an amount equal to 50% of the Total Commitment at such time; provided that, at any time and from time to time after the Effective Date, the Parent may reallocate portions of the then applicable Total Commitment between this Agreement and the Other Term Loan Facility in its own discretion by giving the Facility Agent 5 Business Days’ written notice thereof; provided that, at no time shall the sum of the Total Allocable Commitment under this Agreement and the “Total Allocable Commitment” (under and as defined in the Other Term Loan Facility) exceed the Total Commitment at such time.

Total Capitalization” shall mean, at any date of determination, the Total Net Funded Debt plus the consolidated stockholders’ equity of the NCLC Group at such date determined in accordance with GAAP and derived from the then latest unaudited consolidated financial statements of the NCLC Group delivered to the Facility Agent in the case of the first three quarters of each fiscal year and the then latest audited consolidated financial statements of the NCLC Group delivered to the Facility Agent in the case of each fiscal year; provided it is understood that the effect of any impairment of intangible assets shall be added back to stockholders’ equity.

 

-28-


Total Commitment” shall mean, at any time, an amount denominated in Euro equal to the lesser of (i) €126,075,000 and (ii) the sum of (x) 10% of the Aggregate Initial Construction Price and (y) 100% of the aggregate amount of the Hermes Premium payable in respect of this Agreement and the Other Term Loan Facility, as such Total Commitment may be reduced pursuant to Sections 3.02, 3.03 and 4.02 of this Agreement and the Other Term Loan Facility.

Total Net Funded Debt” shall mean, as at any relevant date:

(i) Indebtedness for Borrowed Money of the NCLC Group on a consolidated basis; and

(ii) the amount of any Indebtedness for Borrowed Money of any person which is not a member of the NCLC Group but which is guaranteed by a member of the NCLC Group as at such date;

less an amount equal to any Cash Balance as at such date; provided that any Commitments and other amounts available for drawing under other revolving or other credit facilities of the NCLC Group which remain undrawn shall not be counted as cash or indebtedness for the purposes of this Agreement.

Tranche A Borrowing Date” shall mean a Borrowing Date in respect of Tranche A Loans.

Tranche A Initial Borrowing Date” shall mean the date occurring on or after the Effective Date on which the initial Borrowing of Tranche A Loans occurs.

Tranche A Intercreditor Agreement” shall mean the intercreditor deed executed by inter alia, (a) each Lender, each other Secured Creditor, the Collateral Agent, the Documentation Agent and the Hermes Agent, (b) each lender, each other secured creditor, the collateral agent, the documentation agent, the Hermes agent and the borrower under the Breakaway One Facility, (c) each lender, each other secured creditor, the collateral agent, the documentation agent, the Hermes agent and the borrower under the Other Term Loan Facility and (d) each additional Authorized Representative (as defined therein) from time to time party thereto, and acknowledged by the Borrower and the Guarantor substantially in the form of Exhibit M-1.

Tranche A Loan” shall have the meaning provided in Section 2.01(b).

Tranche A Loan Maturity Date” shall mean the third anniversary of the Vessel 1 Delivery Date.

Tranche B Borrowing Date” shall mean a Borrowing Date in respect of Tranche B Loans.

 

-29-


Tranche B Initial Borrowing Date” shall mean the date occurring on or after the Effective Date on which the initial Borrowing of Tranche B Loans occurs.

Tranche B Intercreditor Agreement” shall mean the intercreditor deed executed by inter alia, (a) each Lender, each other Secured Creditor, the Collateral Agent, the Documentation Agent and the Hermes Agent, (b) each lender, each other secured creditor, the collateral agent, the documentation agent, the Hermes agent and the borrower under the Breakaway Two Facility, (c) each lender, each other secured creditor, the collateral agent, the documentation agent, the Hermes agent and the borrower under the Other Term Loan Facility and (d) each additional Authorized Representative (as defined therein) from time to time party thereto, and acknowledged by the Borrower and the Guarantor substantially in the form of Exhibit M-2.

Tranche B Loan” shall have the meaning provided in Section 2.01(b).

Tranche B Loan Maturity Date” shall mean the third anniversary of the Vessel 2 Delivery Date.

Transaction” shall mean collectively (i) the execution, delivery and performance by each Credit Party of the Credit Documents to which it is a party, the incurrence of Loans on each Borrowing Date and the use of proceeds thereof, (ii) the execution, delivery and performance by the relevant credit parties party to the Other Term Loan Credit Documents to which they are a party, the incurrence of the loans thereunder and the use of proceeds thereof, (iii) the execution, delivery and performance by the relevant credit parties party to the Export Credit Documents to which they are a party, the incurrence of the loans thereunder and the use of proceeds thereof and (iv) the payment of all fees and expenses in connection with the foregoing.

Transfer Certificate” means a certificate substantially in the form set out in Exhibit E or any other form agreed between the Facility Agent and the Parent.

UCC” shall mean the Uniform Commercial Code as from time to time in effect in the relevant jurisdiction.

United States” and “U.S.” shall each mean the United States of America.

Vessel 1” shall mean the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.678 to be constructed by the Yard pursuant to the Vessel 1 Construction Contract.

Vessel 1 Assignment of Contracts” shall have the meaning provided in Section 5.06(a).

Vessel 1 Assignment of KfW Refund Guarantee” shall have the meaning provided in Section 5.06(a).

Vessel 1 Construction Contract” shall mean the Shipbuilding Contract (in Relation to Vessel 1), dated as of 24 September, 2010, among Breakaway One, the Parent and the Yard, as such Shipbuilding Contract may be amended, modified or supplemented from time to time in accordance with the terms thereof and hereof.

 

-30-


Vessel 1 Delivery Date” shall mean the date of delivery of Vessel 1 to Breakaway One, which is currently scheduled to occur in April 2013.

Vessel 2” shall mean the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S-692 to be constructed by the Yard pursuant to the Vessel 2 Construction Contract.

Vessel 2 Assignment of Contracts” shall have the meaning provided in Section 5.06(b).

Vessel 2 Assignment of KfW Refund Guarantee” shall have the meaning provided in Section 5.06(b).

Vessel 2 Construction Contract” shall mean the Shipbuilding Contract (in relation to Vessel 2), dated as of September 24, 2010, among the Breakaway Two, the Parent and the Yard as such Shipbuilding Contract may be amended, modified or supplemented from time to time in accordance with the terms thereof and hereof.

Vessel 2 Delivery Date” shall mean the date of delivery of Vessel 2 to Breakaway Two, which is currently scheduled to occur in April 2014.

Vessel Mortgage” shall have the meaning provided in the definition of “Collateral and Guaranty Requirements”.

Vessel Value” shall have the meaning set forth in Section 10.08.

Yard” shall mean Meyer Werft GmbH, Papenburg/Germany, the shipbuilder constructing the New Vessels pursuant to the Construction Contracts.

SECTION 2. Amount and Terms of Credit Facility.

2.01 The Commitments. (a) Subject to and upon the terms and conditions set forth herein, each Lender severally agrees to make on and after the first Initial Borrowing Date and prior to the Commitment Termination Date and at the times specified in Section 2.02 term loans to the Borrower (each a “Loan” and collectively the “Loans”), which Loans (i) shall bear interest in accordance with Section 2.06, (ii) shall be denominated and repayable in Dollars, (iii) shall be disbursed on any Borrowing Date, (iv) disbursed on any Borrowing Date shall not exceed on such Borrowing Date for all Lenders the Dollar Equivalent of the maximum available amount for such Borrowing Date as set forth in Section 2.02, (v) disbursed on any Borrowing Date shall not exceed for any Lender the Dollar Equivalent of the Commitment of such Lender on such Borrowing Date, (vi) disbursed on any Borrowing Date shall not exceed the Dollar Availability on any such Borrowing Date and (vii) shall not in the aggregate exceed the Dollar Maximum Amount.

 

-31-


(b) Loans disbursed to indirectly fund installments and delivery payments to the Yard in respect of (x) Vessel 1 together with 50% of the Loans disbursed to fund payments of the Hermes Premium hereunder shall be herein referred to as “Tranche A Loans” and (y) Vessel 2 together with 50% of the Loans disbursed to fund payments of the Hermes Premium hereunder shall be herein referred to as “Tranche B Loans”.

2.02 Amount and Timing of Each Borrowing; Currency of Disbursements. (a) The Loans will be available on one or more dates (including each Initial Borrowing Date, each a “Borrowing Date”):

(i) to indirectly fund installments and delivery payments to the Yard under the Construction Contracts for the New Vessels on or after the dates such payments are due and owing; provided that on any Borrowing Date, the Loans shall be available to the Borrower to indirectly fund installments and delivery payments to the Yard in respect of a New Vessel if and only if ECF Loans under the Export Credit Facility for such New Vessel have been, or contemporaneously with the making of such Loans are, made available to the applicable ECF Borrower on or prior to such Borrowing Date to fund such installments and delivery payments (as the case may be), and

(ii) to fund payments of the applicable Hermes Premium on and after the dates on which such Hermes Premium is due and owing (including to reimburse the Parent or the Borrower for amounts it paid out of cash on hand) (it being understood and agreed that the Lenders shall be authorized to disburse directly to Hermes the proceeds of Loans in an amount equal to the Hermes Premium that is then due and owing, without any action on the part of the Borrower (including, without limitation, without delivery by the Borrower of a Notice of Borrowing to the Facility Agent in respect thereof), so long as the Facility Agent provides the Borrower with notice thereof).

(b) Loans made on each Borrowing Date shall be disbursed by the Facility Agent to the Borrower and/or its designee(s), as set forth in Section 2.04, in Dollars and, subject to the Dollar Availability on such Borrowing Date, shall be in an amount equal to the Dollar Equivalent of the amount of the Total Allocable Commitment utilized to make such Loans on such Borrowing Date pursuant to this Section 2.02, provided that in the event that the Borrower has not (i) notified the Facility Agent in the Notice of Borrowing that it has entered into Earmarked Foreign Exchange Arrangements with respect to the amount required to be paid to Hermes or to the Yard on such Borrowing Date and (ii) provided reasonably sufficient evidence to the Facility Agent of such Earmarked Foreign Exchange Arrangements in the Notice of Borrowing, the Facility Agent on such Borrowing Date shall convert the Dollar amount of the Loans to be made by each Lender into Euro at the Spot Rate applicable for such Borrowing Date (it being understood that the same Spot Rate shall be used for such conversion as is used to calculate the Dollar Equivalent referred to in this Section 2.02(b)), and shall inform each Lender thereof, and such Euro amount shall thereafter be disbursed to the Borrower and/or its designee(s) as set forth in Section 2.04 (it being understood that each Lender shall remit its Loans to the Facility Agent in Dollars on such Borrowing Date).

(c) No Borrowing Date may occur (x) in the case of Tranche A Loans, after December 23, 2013 and (y) in the case of Tranche B Loans, after December 8, 2014.

 

-32-


2.03 Notice of Borrowing. Subject to the second parenthetical in Section 2.02(a)(ii), whenever the Borrower desires to make a Borrowing hereunder, it shall give the Facility Agent at its Notice Office at least three Business Days’ prior written notice of each Loan to be made hereunder, provided that any such notice shall be deemed to have been given on a certain day only if given before 11:00 A.M. (Frankfurt time) (unless such 11:00 A.M. deadline is waived by the Facility Agent in the case of the first Initial Borrowing Date). Each such written notice (each a “Notice of Borrowing”), except as otherwise expressly provided in Section 2.08, shall be irrevocable and shall be given by the Borrower substantially in the form of Exhibit A, appropriately completed to specify (i) the portion of the Total Commitment to be utilized on such Borrowing Date, (ii) whether the Loans to be made on such Borrowing Date shall consist of Tranche A Loans or Tranche B Loans, (iii) if the Borrower and/or the Parent and/or an ECF Borrower has entered into Earmarked Foreign Exchange Arrangements with respect to the installment payments due and owing under the relevant Construction Contract to be funded by the Loans to be incurred on such Borrowing Date, the Dollar Equivalent of the portion of the Total Commitment to be borrowed on such Borrowing Date and evidence of such Earmarked Foreign Exchange Arrangements, (iv) the date of such Borrowing (which shall be a Business Day), (v) the initial Interest Period to be applicable thereto (vi) to which account(s) the proceeds of such Loans are to be deposited (it being understood that pursuant to Section 2.04 the Borrower may designate one or more accounts of the Yard, Hermes and/or the provider of the foreign exchange arrangements referenced in the definition of Dollar Equivalent), (vii) that all representations and warranties made by each Credit Party, in or pursuant to the Credit Documents are true and correct in all material respects (unless stated to relate to a specific earlier date, in which case such representations and warranties shall have been true and correct in all material respects as of such date) and no Event of Default is or will be continuing after giving effect to such Borrowing and (viii) the Dollar Availability on such Borrowing Date together with calculations evidencing the determination of such Dollar Availability (in form and substance reasonably satisfactory to the Facility Agent). The Facility Agent shall promptly give each Lender which is required to make Loans, notice of such proposed Borrowing, of such Lender’s proportionate share thereof and of the other matters required by the immediately preceding sentence to be specified in the Notice of Borrowing.

2.04 Disbursement of Funds. No later than 12:00 Noon (Frankfurt time) on the date specified in each Notice of Borrowing, each Lender will make available its pro rata portion of each Borrowing requested in the Notice of Borrowing to be made on such date. All such amounts shall be made available in the currency required by Section 2.02(b) in immediately available funds at the Payment Office of the Facility Agent, and the Facility Agent will make available to (I) in the case of Loans disbursed in Dollars, the Borrower (and/or its designee(s), to the extent possible and to the extent such designee is a provider of Earmarked Foreign Exchange Arrangements referenced in the definition of Dollar Equivalent) and (II) in the case of Loans disbursed in Euro, designee(s) of the Borrower (to the extent any such designee is the Yard or, in the case of the Hermes Premium, Hermes), in each case prior to 3:00 P.M. (Frankfurt Time) on such day, to the extent of funds actually received by the Facility Agent prior to 12:00 Noon (Frankfurt Time) on such day in each case at the Payment Office in the account(s) specified in the applicable Notice of Borrowing, the aggregate of the amounts so made available by the Lenders. Unless the Facility Agent shall have been notified by any Lender prior to the date of Borrowing that such Lender does not intend to make available to the Facility Agent such Lender’s portion of any Borrowing to be made on such date, the Facility Agent may assume that

 

-33-


such Lender has made such amount available to the Facility Agent on such date of Borrowing and the Facility Agent may, in reliance upon such assumption, make available to the Borrower a corresponding amount. If such corresponding amount is not in fact made available to the Facility Agent by such Lender, the Facility Agent shall be entitled to recover such corresponding amount on demand from such Lender. If such Lender does not pay such corresponding amount forthwith upon the Facility Agent’s demand therefor, the Facility Agent shall promptly notify the Borrower and the Borrower shall immediately pay such corresponding amount to the Facility Agent. The Facility Agent shall also be entitled to recover on demand from such Lender or the Borrower, as the case may be, interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Facility Agent to the Borrower until the date such corresponding amount is recovered by the Facility Agent, at a rate per annum equal to (i) if recovered from such Lender, at the overnight Eurodollar Rate and (ii) if recovered from the Borrower, the rate of interest applicable to the respective Borrowing, as determined pursuant to Section 2.06. Nothing in this Section 2.04 shall be deemed to relieve any Lender from its obligation to make Loans hereunder or to prejudice any rights which the Borrower may have against any Lender as a result of any failure by such Lender to make Loans hereunder.

2.05 Pro Rata Borrowings. All Borrowings of Loans under this Agreement shall be incurred from the Lenders pro rata on the basis of their Commitments. It is understood that no Lender shall be responsible for any default by any other Lender of its obligation to make Loans hereunder and that each Lender shall be obligated to make the Loans provided to be made by it hereunder, regardless of the failure of any other Lender to make its Loans hereunder. The obligations of the Lenders under this Agreement are several and not joint and no Lender shall be responsible for the failure of any other Lender to satisfy its obligations hereunder.

2.06 Interest. (a) The Borrower agrees to pay interest in respect of the unpaid principal amount of each Loan from the date the proceeds thereof are made available to the Borrower until the maturity (whether by acceleration or otherwise) of such Loan at a rate per annum which shall, during each Interest Period applicable thereto, be equal to the sum of the Applicable Margin plus the Eurodollar Rate for such Interest Period plus any Mandatory Costs.

(b) If the Borrower fails to pay any amount payable by it under a Credit Document on its due date, interest shall accrue on the overdue amount (in the case of overdue interest to the extent permitted by law) from the due date up to the date of actual payment (both before and after judgment) at a rate which is, subject to paragraph (c) below, 2% plus the rate which would have been payable if the overdue amount had, during the period of non-payment, constituted a Loan for successive Interest Periods, each of a duration selected by the Facility Agent (acting reasonably). Any interest accruing under this Section 2.06(b) shall be immediately payable by the Borrower on demand by the Facility Agent.

(c) If any overdue amount consists of all or part of a Loan which became due on a day which was not the last day of an Interest Period relating to that Loan:

(i) the first Interest Period for that overdue amount shall have a duration equal to the unexpired portion of the current Interest Period relating to that Loan; and

 

-34-


(ii) the rate of interest applying to the overdue amount during that first Interest Period shall be 2% plus the rate which would have applied if the overdue amount had not become due.

Default interest (if unpaid) arising on an overdue amount will be compounded with the overdue amount at the end of each Interest Period applicable to that overdue amount but will remain immediately due and payable.

(d) Accrued and unpaid interest shall be payable in respect of each Loan, (i) on the last day of each Interest Period applicable thereto and every three months in the case of Interest Periods in excess of three months, (ii) on any repayment or prepayment date (on the amount repaid or prepaid), (iii) at maturity (whether by acceleration or otherwise) and (iv) after such maturity, on demand.

(e) Upon each Interest Determination Date, the Facility Agent shall determine the Eurodollar Rate for each Interest Period applicable to the Loans to be made pursuant to the applicable Borrowing and shall promptly notify the Borrower and the respective Lenders thereof. Each such determination shall, absent manifest error, be final and conclusive and binding on all parties hereto.

2.07 Interest Periods. At the time the Borrower gives any Notice of Borrowing in respect of the making of Loans by the Lenders (in the case of the initial Interest Period applicable thereto) or on the third Business Day prior to the expiration of an Interest Period applicable to such Loans (in the case of any subsequent Interest Period), it shall have the right to elect, by giving the Facility Agent notice thereof, the interest period (each an “Interest Period”) applicable to such Loans, which Interest Period shall, at the option of the Borrower, be a three or six month period; provided that:

(a) all Loans comprising a Borrowing shall at all times have the same Interest Period;

(b) the initial Interest Period for any Loan shall commence on the date of Borrowing of such Loan and each Interest Period occurring thereafter in respect of such Loan shall commence on the day on which the immediately preceding Interest Period applicable thereto expires;

(c) if any Interest Period relating to a Loan begins on a day for which there is no numerically corresponding day in the calendar month at the end of such Interest Period, such Interest Period shall end on the last Business Day of such calendar month;

(d) if any Interest Period would otherwise expire on a day which is not a Business Day, such Interest Period shall expire on the first succeeding Business Day; provided, however, that if any Interest Period for a Loan would otherwise expire on a day which is not a Business Day but is a day of the month after which no further Business Day occurs in such month, such Interest Period shall expire on the immediately preceding Business Day;

 

-35-


(e) no Interest Period longer than three months may be selected at any time when an Event of Default (or, if the Facility Agent or the Required Lenders have determined that such an election at such time would be disadvantageous to the Lenders, a Default) has occurred and is continuing;

(f) no Interest Period in respect of any Borrowing of any Loans shall be selected which extends beyond the Tranche A Loan Maturity Date (in the case of Tranche A Loans) or the Tranche B Loan Maturity Date (in the case of Tranche B Loans); and

(g) at no time shall there be more than ten Borrowings of Loans subject to different Interest Periods.

If upon the expiration of any Interest Period applicable to a Borrowing, the Borrower has failed to elect a new Interest Period to be applicable to such Loans as provided above, the Borrower shall be deemed to have elected a three month Interest Period to be applicable to such Loans effective as of the expiration date of such current Interest Period.

2.08 Increased Costs, Illegality, Market Disruption, etc. (a) In the event that any Lender shall have reasonably determined (which determination shall, absent manifest error, be final and conclusive and binding upon all parties hereto):

(i) at any time, that such Lender shall incur increased costs (including, without limitation, pursuant to Basel II to the extent Basel II is applicable), Mandatory Costs (as set forth on Schedule 1.01(c)) or reductions in the amounts received or receivable hereunder with respect to any Loan because of, without duplication, any change since the Effective Date in any applicable law or governmental rule, governmental regulation, governmental order, governmental guideline or governmental request (whether or not having the force of law) or in the interpretation or administration thereof and including the introduction of any new law or governmental rule, governmental regulation, governmental order, governmental guideline or governmental request, such as, for example, but not limited to: (A) a change in the basis of taxation of payment to any Lender of the principal of or interest on such Loan or any other amounts payable hereunder (except for changes in the rate of tax on, or determined by reference to, the net income or net profits of such Lender, or any franchise tax based on net income or net profits, of such Lender pursuant to the laws of the jurisdiction in which such Lender is organized or in which such Lender’s principal office or applicable lending office is located or any subdivision thereof or therein), but without duplication of any amounts payable in respect of Taxes pursuant to Section 4.04, or (B) a change in official reserve requirements; or

(ii) at any time, that the making or continuance of any Loan has been made unlawful by any law or governmental rule, governmental regulation or governmental order;

then, and in any such event, such Lender shall promptly give notice (by telephone confirmed in writing) to the Borrower and to the Facility Agent of such determination (which notice the Facility Agent shall promptly transmit to each of the Lenders). Thereafter (x) in the case of

 

-36-


clause (i) above, the Borrower agrees (to the extent applicable), to pay to such Lender, upon its written demand therefor, such additional amounts as shall be required to compensate such Lender or such other corporation for the increased costs or reductions to such Lender or such other corporation and (y) in the case of clause (ii) above, the Borrower shall take one of the actions specified in Section 2.08(b) as promptly as possible and, in any event, within the time period required by law. In determining such additional amounts, each Lender will act reasonably and in good faith and will use averaging and attribution methods which are reasonable, provided that such Lender’s determination of compensation owing under this Section 2.08(a) shall, absent manifest error be final and conclusive and binding on all the parties hereto. Each Lender, upon determining that any additional amounts will be payable pursuant to this Section 2.08(a), will give prompt written notice thereof to the Borrower, which notice shall show in reasonable detail the basis for the calculation of such additional amounts; provided that, subject to the provisions of Section 2.10(b), the failure to give such notice shall not relieve the Borrower from its Credit Document Obligations hereunder.

(b) At any time that any Loan is affected by the circumstances described in Section 2.08(a)(i) or (ii), the Borrower may (and in the case of a Loan affected by the circumstances described in Section 2.08(a)(ii) shall) either (x) if the affected Loan is then being made initially, cancel the respective Borrowing by giving the Facility Agent notice in writing on the same date or the next Business Day that the Borrower was notified by the affected Lender or the Facility Agent pursuant to Section 2.08(a)(i) or (ii) or (y) if the affected Loan is then outstanding, upon at least three Business Days’ written notice to the Facility Agent, in the case of any Loan, repay all outstanding Borrowings (within the time period required by the applicable law or governmental rule, governmental regulation or governmental order) which include such affected Loans in full in accordance with the applicable requirements of Section 4.02; provided that if more than one Lender is affected at any time, then all affected Lenders must be treated the same pursuant to this Section 2.08(b).

(c) If any Lender determines that after the Effective Date (i) the introduction of or effectiveness of or any change in any applicable law or governmental rule, governmental regulation, governmental order, governmental guideline, governmental directive or governmental request (whether or not having the force of law) concerning capital adequacy, or any change in interpretation or administration thereof by any governmental authority, central bank or comparable agency will have the effect of increasing the amount of capital required or expected to be maintained by such Lender, or any corporation controlling such Lender, based on the existence of such Lender’s Commitments hereunder or its obligations hereunder, (ii) compliance with any law or regulation or any request from or requirement of any central bank or other fiscal, monetary or other authority made after the Effective Date (including any which relates to capital adequacy or liquidity controls or which affects the manner in which a Lender allocates capital resources to obligations under this Agreement, any Interest Rate Protection Agreement and/or any Other Hedging Agreement) or (iii) to the extent that such change is not discretionary and is pursuant to law, a governmental mandate or request, or a central bank or other fiscal or monetary authority mandate or request, any change in the risk weight allocated by such Lender to the Borrower after the Effective Date, then the Borrower agrees (to the extent applicable) to pay to such Lender, upon its written demand therefor, such additional amounts as shall be required to compensate such Lender or such other corporation for the increased cost to such Lender or such other corporation or the reduction in the rate of return to such Lender or such other corporation

 

-37-


as a result of such increase of capital. In determining such additional amounts, each Lender will act reasonably and in good faith and will use averaging and attribution methods which are reasonable, provided that such Lender’s determination of compensation owing under this Section 2.08(c) shall, absent manifest error be final and conclusive and binding on all the parties hereto. Each Lender, upon determining that any additional amounts will be payable pursuant to this Section 2.08(c), will give prompt written notice thereof to the Borrower, which notice shall show in reasonable detail the basis for calculation of such additional amounts; provided that, subject to the provisions of Section 2.10(b), the failure to give such notice shall not relieve the Borrower from its Credit Document Obligations hereunder.

(d) If a Market Disruption Event occurs in relation to any Lender’s share of a Loan for any Interest Period, then the rate of interest on each Lender’s share of that Loan for the Interest Period shall be the percentage rate per annum which is the sum of:

(i) the Applicable Margin;

(ii) the rate determined by such Lender and notified to the Facility Agent by 5:00 P.M. (Frankfurt time) on the Interest Determination Date for such Interest Period to be that which expresses as a percentage rate per annum the cost to each such Lender of funding its participation in that Loan for a period equivalent to such Interest Period from whatever source it may reasonably select; provided that the rate provided by a Lender pursuant to this clause (ii) shall not be disclosed to any other Lender and shall be held as confidential by the Facility Agent and the Borrower; and

(iii) the Mandatory Costs, if any, applicable to such Lender of funding its participation in that Loan.

(e) If a Market Disruption Event occurs and the Facility Agent or the Borrower so require, the Facility Agent and the Borrower shall enter into negotiations (for a period of not more than 30 days) with a view to agreeing a substitute basis for determining the rate of interest. Any alternative basis agreed pursuant to the immediately preceding sentence shall, with the prior consent of all the Lenders and the Borrower, be binding on all parties. If no agreement is reached pursuant to this clause (e), the rate provided for in clause (d) above shall apply for the entire applicable Interest Period.

(f) If any Reference Bank ceases to be a Lender under this Agreement, (x) it shall cease to be a Reference Bank and (y) the Facility Agent shall, with the approval (which shall not be unreasonably withheld) of the Borrower, nominate as soon as reasonably practicable another Lender to be a Reference Bank in place of such Reference Bank.

2.09 Indemnification; Breakage Costs. The Borrower agrees to indemnify each Lender, within two Business Days of demand (in writing which request shall set forth in reasonable detail the basis for requesting and the calculation of such amount and which in the absence of manifest error shall be conclusive evidence as to the amount due), for all losses, expenses and liabilities (including, without limitation, any such loss, expense or liability incurred by reason of the liquidation or reemployment of deposits or other funds required by such Lender to fund its Loans but excluding any loss of anticipated profits) which such Lender may sustain in

 

-38-


respect of Loans made to the Borrower: (i) if for any reason (other than a default by such Lender or the Facility Agent) a Borrowing of Loans does not occur on a date specified therefor in a Notice of Borrowing (whether or not withdrawn by the Borrower or deemed withdrawn pursuant to Section 2.08(a)); (ii) if any prepayment or repayment (including any prepayment or repayment made pursuant to Section 2.08(a), Section 4.01 or Section 4.02 or as a result of an acceleration of the Loans pursuant to Section 11) of any of its Loans, or assignment and/or transfer of its Loans pursuant to Section 2.11, occurs on a date which is not the last day of an Interest Period with respect thereto; or (iii) if any prepayment of any of its Loans is not made on any date specified in a notice of prepayment given by the Borrower.

2.10 Change of Lending Office; Limitation on Additional Amounts. (a) Each Lender agrees that on the occurrence of any event giving rise to the operation of Section 2.08(a), Section 2.08(b), or Section 4.04 with respect to such Lender, it will, if requested by the Borrower, use reasonable good faith efforts (subject to overall policy considerations of such Lender) to designate another lending office for any Loans affected by such event or otherwise take steps to mitigate the effect of such event, provided that such designation shall be made and/or such steps shall be taken at the Borrower’s cost and on such terms that such Lender and its lending office suffer no economic, legal or regulatory disadvantage in excess of de minimus amounts, with the object of avoiding the consequence of the event giving rise to the operation of such Section. Nothing in this Section 2.10 shall affect or postpone any of the obligations of the Borrower or the rights of any Lender provided in Section 2.08 and Section 4.04.

(b) Notwithstanding anything to the contrary contained in Sections 2.08, 2.09 or 4.04 of this Agreement, unless a Lender gives notice to the Borrower that it is obligated to pay an amount under any such Section within 180 days of the later of (x) the date the Lender incurs the respective increased costs, Taxes, loss, expense or liability, reduction in amounts received or receivable or reduction in return on capital or (y) the date such Lender has knowledge of its incurrence of the respective increased costs, Taxes, loss, expense or liability, reductions in amounts received or receivable or reduction in return on capital, then such Lender shall only be entitled to be indemnified for such amount by the Borrower pursuant to said Section 2.08, 2.09, or 4.04, as the case may be, to the extent the costs, Taxes, loss, expense or liability, reduction in amounts received or receivable or reduction in return on capital are incurred or suffered on or after the date which occurs 180 days prior to such Lender giving notice to the Borrower that it is obligated to pay the respective amounts pursuant to said Section 2.08, 2.09 or 4.04, as the case may be. This Section 2.10(b) shall have no applicability to any Section of this Agreement other than said Sections 2.08, 2.09 and 4.04.

2.11 Replacement of Lenders. (x) If any Lender becomes a Defaulting Lender or otherwise defaults in its obligations to make Loans, (y) upon the occurrence of any event giving rise to the operation of Section 2.08(a) or Section 4.04 with respect to any Lender which results in such Lender charging to the Borrower material increased costs in excess of the average costs being charged by the other Lenders, or (z) as provided in Section 14.11(b) in the case of certain refusals by a Lender to consent to certain proposed changes, waivers, discharges or terminations with respect to this Agreement which have been approved by the Required Lenders, the Borrower shall (for its own cost) have the right, if no Default or Event of Default will exist immediately after giving effect to the respective replacement, to replace such Lender (the “Replaced Lender”) with one or more other Eligible Transferee or Eligible Transferees, none of

 

-39-


whom shall constitute a Defaulting Lender at the time of such replacement (collectively, the “Replacement Lender”) reasonably acceptable to the Facility Agent (it being understood that all then-existing Lenders are reasonably acceptable); provided that:

(a) at the time of any replacement pursuant to this Section 2.11, the Replacement Lender shall enter into one or more Transfer Certificates pursuant to Section 13.01(a) (and with all fees payable pursuant to said Section 13.02 to be paid by the Replacement Lender) pursuant to which the Replacement Lender shall acquire all of the Commitments and outstanding Loans of the Replaced Lender and, in connection therewith, shall pay to the Replaced Lender in respect thereof an amount equal to the sum (without duplication) of (x) an amount equal to the principal of, and all accrued interest on, all outstanding Loans of the Replaced Lender, and (y) an amount equal to all accrued, but unpaid, Commitment Commission owing to the Replaced Lender pursuant to Section 3.01;

(b) all obligations of the Borrower due and owing to the Replaced Lender at such time (other than those specifically described in clause (a) above) in respect of which the assignment purchase price has been, or is concurrently being, paid shall be paid in full to such Replaced Lender concurrently with such replacement; and

(c) if the Borrower elects to replace any Lender pursuant to clause (x), (y) or (z) of this Section 2.11, the Borrower shall also replace each other Lender that qualifies for replacement under such clause (x), (y) or (z).

Upon the execution of the respective Transfer Certificate and the payment of amounts referred to in clauses (a) and (b) above, the Replacement Lender shall become a Lender hereunder and the Replaced Lender shall cease to constitute a Lender hereunder, except with respect to indemnification provisions under this Agreement (including, without limitation, Sections 2.08, 2.09, 4.04, 14.01 and 14.05), which shall survive as to such Replaced Lender.

2.12 Disruption to Payment Systems, Etc. If either the Facility Agent determines (in its discretion) that a Disruption Event has occurred or the Facility Agent is notified by the Parent or the Borrower that a Disruption Event has occurred:

(i) the Facility Agent may, and shall if requested to do so by the Borrower or the Parent, consult with the Borrower with a view to agreeing with the Borrower such changes to the operation or administration of this Agreement as the Facility Agent may deem necessary in the circumstances;

(ii) the Facility Agent shall not be obliged to consult with the Borrower or the Parent in relation to any changes mentioned in clause (i) above if, in its opinion, it is not practicable to do so in the circumstances and, in any event, shall have no obligation to agree to such changes;

(iii) the Facility Agent may consult with the other Agents, the Joint Lead Arrangers and the Lenders in relation to any changes mentioned in clause (i) above but shall not be obliged to do so if, in its opinion, it is not practicable or necessary to do so in the circumstances;

 

-40-


(iv) any such changes agreed upon by the Facility Agent and the Borrower or the Parent pursuant to clause (i) above shall (whether or not it is finally determined that a Disruption Event has occurred) be binding upon the parties to this Agreement as an amendment to (or, as the case may be, waiver of) the terms of the Credit Documents, notwithstanding the provisions of Section 14.11, until such time as the Facility Agent is satisfied that the Disruption Event has ceased to apply;

(v) the Facility Agent shall not be liable for any damages, costs or losses whatsoever (including, without limitation for negligence or any other category of liability whatsoever but not including any claim based on the gross negligence, fraud or willful misconduct of the Facility Agent) arising as a result of its taking, or failing to take, any actions pursuant to or in connection with this Section 2.12; and

(vi) the Facility Agent shall notify the other Agents, the Joint Lead Arrangers and the Lenders of all changes agreed pursuant to clause (iv) above as soon as practicable.

SECTION 3. Commitment Commission; Fees; Reductions of Commitment.

3.01 Commitment Commission. (a) The Borrower agrees to pay the Facility Agent for distribution to each Non-Defaulting Lender a commitment commission (the “Commitment Commission”) for the period from the Effective Date to and including the Commitment Termination Date (or such earlier date as the Total Commitment shall have been terminated) computed at a rate for each day equal to 0.375 multiplied by the Applicable Margin multiplied by the Commitment for such day of such Non-Defaulting Lender divided by 360. Accrued Commitment Commission shall be due and payable quarterly in arrears on each Payment Date and on the Borrowing Date corresponding to the second Delivery Date to occur (or such earlier date upon which the Total Commitment is terminated).

(b) The Borrower shall pay to each Agent, for such Agent’s own account or for the account of the Lenders, such other fees as have been agreed to in writing by the Borrower and such Agent.

3.02 Voluntary Reduction or Termination of Commitments. Upon at least three Business Days’ prior notice to the Facility Agent at its Notice Office (which notice the Facility Agent shall promptly transmit to each of the Lenders), the Borrower shall have the right, at any time or from time to time, without premium or penalty, to reduce or terminate the Total Commitment, in whole or in part, in integral multiples of €5,000,000 in the case of partial reductions thereto, provided that (x) any partial reduction to the Total Commitment pursuant to this Section 3.02 shall only be effective if there is an equal reduction of the “Total Commitment” under and as defined in the Other Term Loan Facility and (y) each such reduction shall apply proportionately to permanently reduce the Commitment of each Lender.

3.03 Mandatory Reduction of Commitments. (a) In addition to any other mandatory commitment reductions pursuant to this Section 3.03 or any other Section of this Agreement, the Total Commitment (and the Commitment of each Lender) shall terminate in its entirety on the Commitment Termination Date.

 

-41-


(b) In addition to any other mandatory commitment reductions pursuant to this Section 3.03 or any other Section of this Agreement, the Total Commitment (and the Commitments of each Lender) shall be reduced:

(i) (immediately after the relevant Loans are made) on each Borrowing Date by the amount of Total Commitment utilized to make the Loans made on such Borrowing Date; and

(ii) on each borrowing date under the Other Term Loan Facility (immediately after the relevant loans are made on such borrowing date under the Other Term Loan Facility) by the amount of Total Commitment utilized to make the loans under the Other Term Loan Facility on such borrowing date.

(c) In addition to any other mandatory commitment reductions pursuant to this Section 3.03 or any other Section of this Agreement, the Total Commitment shall be terminated at the times required by Section 4.02.

(d) Each reduction to the Total Commitment pursuant to this Section 3.03 and Section 4.02 shall be applied proportionately to reduce the Commitment of each Lender.

(e) In addition to any other mandatory commitment reductions pursuant to this Section 3.03 or any other Section of this Agreement, the Total Commitment shall be reduced pursuant to Section 3.03 and 3.02 of the Other Term Loan Facility.

SECTION 4. Prepayments; Repayments; Taxes.

4.01 Voluntary Prepayments. The Borrower shall have the right to prepay the Loans, without premium or penalty except as provided by law, in whole or in part at any time and from time to time on the following terms and conditions:

(a) the Borrower shall give the Facility Agent prior to 12:00 Noon (Frankfurt time) at its Notice Office at least 30 Business Days’ prior written notice of its intent to prepay such Loans, the amount of such prepayment and the specific Borrowing or Borrowings pursuant to which made, which notice the Facility Agent shall promptly transmit to each of the Lenders;

(b) each prepayment shall be in an aggregate principal amount of at least $1,000,000 or such lesser amount of a Borrowing which is outstanding, provided that no partial prepayment of Loans made pursuant to any Borrowing shall reduce the outstanding Loans made pursuant to such Borrowing to an amount less than $1,000,000;

(c) at the time of any prepayment of Loans pursuant to this Section 4.01 on any date other than the last day of the Interest Period applicable thereto, the Borrower shall pay the amounts required pursuant to Section 2.09;

(d) in the event of certain refusals by a Lender as provided in Section 14.11(b) to consent to certain proposed changes, waivers, discharges or terminations with respect to this Agreement which have been approved by the Required Lenders, the Borrower

 

-42-


may, upon five Business Days’ written notice to the Facility Agent at its Notice Office (which notice the Facility Agent shall promptly transmit to each of the Lenders), prepay all Loans, together with accrued and unpaid interest, Commitment Commission, and other amounts owing to such Lender (or owing to such Lender with respect to each Loan which gave rise to the need to obtain such Lender’s individual consent) in accordance with said Section 14.11(b) so long as (A) the Commitment of such Lender (if any) is terminated concurrently with such prepayment (at which time Schedule 1.01(a) shall be deemed modified to reflect the changed Commitments) and (B) the consents required by Section 14.11(b) in connection with the prepayment pursuant to this clause (d) have been obtained; and

(e) each prepayment in respect of any Loans made pursuant to a Borrowing shall be applied (x) in inverse order of maturity and (y) except as expressly provided in the preceding clause (d), pro rata among the Loans comprising such Borrowing, provided that in connection with any prepayment of Loans pursuant to this Section 4.01, such prepayment shall not be applied to any Loan of a Defaulting Lender until all other Loans of Non-Defaulting Lenders have been repaid in full.

4.02 Mandatory Repayments and Commitment Reductions. (a) In addition to any other mandatory repayments pursuant to this Section 4.02 or any other Section of this Agreement, the outstanding Loans shall be repaid (without further action of the Borrower being required) in 6 equal semi-annual installments commencing on the first Business Day that is on or after the sixth month anniversary of (x) in the case of Tranche A Loans, the Borrowing Date in relation to the Vessel 1 Delivery Date and ending on the Tranche A Loan Maturity Date and (y) in the case of Tranche B Loans, the Borrowing Date in relation to the Vessel 2 Delivery Date and ending on the Tranche B Loan Maturity Date (each such repayment, a “Scheduled Repayment”).

(b) In addition to any other mandatory repayments or commitment reductions pursuant to this Section 4.02 or any other Section of this Agreement, but without duplication, on (i) the Business Day following the date of a Collateral Disposition (other than a Collateral Disposition constituting an Event of Loss) and (ii) the earlier of (A) the date which is 150 days following any Collateral Disposition constituting an Event of Loss involving the Collateral Vessel (or, in the case of an Event of Loss which is a constructive or compromised or arranged total loss of the Collateral Vessel, if earlier, 180 days after the date of the event giving rise to such damage) and (B) the date of receipt by the Borrower, any of its Subsidiaries or the Facility Agent of the insurance proceeds relating to such Event of Loss, the Borrower shall repay the outstanding Loans in full and the Total Allocable Commitment shall be automatically terminated and no further disbursements of Loans hereunder shall be permitted (without further action of the Borrower being required).

(c) In addition to any other mandatory repayments or commitment reductions pursuant to this Section 4.02 or any other Section of this Agreement, but without duplication, (x) if (i) the Vessel 1 Construction Contract is terminated prior to the Vessel 1 Delivery Date, (ii) Vessel 1 has not been delivered to Breakaway One by the Yard pursuant to the Vessel 1 Construction Contract by December 23, 2013 (iii) the Breakaway One Facility shall have been terminated or (iv) any of the events specified in Sections 11.05, 11.10 or 11.11 shall occur in respect of the Yard at any time prior to the Vessel 1 Delivery Date, within five Business Days of

 

-43-


the occurrence of such event the Borrower shall repay the outstanding Tranche A Loans in full and no further Loans shall be made in respect of installment and delivery payments in respect of Vessel 1, and (y) if (i) the Vessel 2 Construction Contract is terminated prior to the Vessel 2 Delivery Date, (ii) Vessel 2 has not been delivered to Breakaway Two by the Yard pursuant to the Vessel 2 Construction Contract by December 8, 2014 (iii) the Breakaway Two Facility shall have been be terminated or (iv) any of the events specified in Sections 11.05, 11.10 or 11.11 shall occur in respect of the Yard at any time prior to the Vessel 2 Delivery Date, within five Business Days of the occurrence of such event the Borrower shall repay the outstanding Tranche B Loans in full and no further Loans shall be made in respect of installment and delivery payments in respect of Vessel 2. Notwithstanding anything to the contrary in this Section 4.02(c), if the Borrower is not permitted to make such prepayment pursuant to the Senior Loan Agreements or the Jade Intercreditor Agreement, then the Borrower or the Parent shall post cash collateral or other collateral reasonably acceptable to the Required Lenders in an amount equal to the then-outstanding Tranche A Loans or Tranche B Loans (as the case may be).

(d) With respect to each repayment of Loans required by this Section 4.02, the Borrower may designate the specific Borrowing or Borrowings pursuant to which such Loans were made, provided that (i) all Loans with Interest Periods ending on such date of required repayment shall be paid in full prior to the payment of any other Loans and (ii) each repayment of any Loans comprising a Borrowing shall be applied pro rata among such Loans. In the absence of a designation by the Borrower as described in the preceding sentence, the Facility Agent shall, subject to the preceding provisions of this clause (d), make such designation in its sole reasonable discretion with a view, but no obligation, to minimize breakage costs owing pursuant to Section 2.09.

(e) Notwithstanding anything to the contrary contained elsewhere in this Agreement, (i) all outstanding Tranche A Loans shall be repaid in full on the Tranche A Loan Maturity Date and (ii) all outstanding Tranche B Loans shall be repaid in full on the Tranche B Loan Maturity Date.

4.03 Method and Place of Payment. Except as otherwise specifically provided herein, all payments under this Agreement shall be made to the Facility Agent for the account of the Lender or Lenders entitled thereto not later than 10:00 A.M. (New York time) on the date when due and shall be made in Dollars in immediately available funds at the Payment Office of the Facility Agent. Whenever any payment to be made hereunder shall be stated to be due on a day which is not a Business Day, the due date thereof shall be extended to the next succeeding Business Day (unless the next succeeding Business Day shall fall in the next calendar month, in which case the due date thereof shall be the previous Business Day) and, with respect to payments of principal, interest shall be payable at the applicable rate during such extension.

4.04 Net Payments; Taxes. (a) All payments made by any Credit Party hereunder will be made without setoff, counterclaim or other defense. All such payments will be made free and clear of, and without deduction or withholding for, any present or future taxes, levies, imposts, duties, fees, assessments or other charges of whatever nature now or hereafter imposed by any jurisdiction or by any political subdivision or taxing authority thereof or therein with respect to such payments (but excluding any tax imposed on or measured by the net income, net profits or any franchise tax based on net income or net profits, and any branch profits tax of a

 

-44-


Lender pursuant to the laws of the jurisdiction in which it is organized or the jurisdiction in which the principal office or applicable lending office of such Lender is located or any subdivision thereof or therein or due to failure to provide documents under Section 4.04(b), all such taxes “Excluded Taxes”) and all interest, penalties or similar liabilities with respect to such non-excluded taxes, levies, imposts, duties, fees, assessments or other charges to the extent imposed on taxes other than Excluded Taxes (all such non-excluded taxes, levies, imposts, duties, fees, assessments or other charges being referred to collectively as “Taxes” and “Taxation” shall be applied accordingly). The Borrower will furnish to the Facility Agent within 45 days after the date of payment of any Taxes is due pursuant to applicable law certified copies of tax receipts evidencing such payment by the Borrower. The Borrower agrees to indemnify and hold harmless each Lender, and reimburse such Lender upon its written request, for the amount of any Taxes so levied or imposed and paid by such Lender.

(b) Each Lender agrees (consistent with legal and regulatory restrictions and subject to overall policy considerations of such Lender) to file any certificate or document or to furnish to the Borrower any information as reasonably requested by the Borrower that may be necessary to establish any available exemption from, or reduction in the amount of, any Taxes; provided, however, that nothing in this Section 4.04(b) shall require a Lender to disclose any confidential information (including, without limitation, its tax returns or its calculations). The Borrower shall not be required to indemnify any Lender for Taxes attributed to such Lender’s failure to provide the required documents under this Section 4.04(b).

(c) If the Borrower pays any additional amount under this Section 4.04 to a Lender and such Lender determines in its sole discretion exercised in good faith that it has actually received or realized in connection therewith any refund or any reduction of, or credit against, its Tax liabilities in or with respect to the taxable year in which the additional amount is paid (a “Tax Benefit”), such Lender shall pay to the Borrower an amount that such Lender shall, in its sole discretion exercised in good faith, determine is equal to the net benefit, after tax, which was obtained by such Lender in such year as a consequence of such Tax Benefit; provided, however, that (i) any Lender may determine, in its sole discretion exercised in good faith consistent with the policies of such Lender, whether to seek a Tax Benefit, (ii) any Taxes that are imposed on a Lender as a result of a disallowance or reduction (including through the expiration of any tax credit carryover or carryback of such Lender that otherwise would not have expired) of any Tax Benefit with respect to which such Lender has made a payment to the Borrower pursuant to this Section 4.04(c) shall be treated as a Tax for which the Borrower is obligated to indemnify such Lender pursuant to this Section 4.04 without any exclusions or defenses and (iii) nothing in this Section 4.04(c) shall require any Lender to disclose any confidential information to the Borrower (including, without limitation, its tax returns).

4.05 Application of Proceeds. (a) Subject to the provisions of the applicable Intercreditor Agreements (to the extent such Intercreditor Agreements are operative), all proceeds collected by the Collateral Agent upon any sale or other disposition of such Collateral of each Credit Party, together with all other proceeds received by the Collateral Agent under and in accordance with this Agreement and the other Credit Documents (except to the extent released in accordance with the applicable provisions of this Agreement or any other Credit Document), shall be applied by the Facility Agent to the payment of the Secured Obligations as follows:

(i) first, to the payment of all amounts owing to the Collateral Agent or any other Agent of the type described in clauses (iii) and (iv) of the definition of “Secured Obligations”;

 

-45-


(ii) second, to the extent proceeds remain after the application pursuant to the preceding clause (i), an amount equal to the outstanding Credit Document Obligations shall be paid to the Lender Creditors as provided in Section 4.05(d) hereof, with each Lender Creditor receiving an amount equal to such outstanding Credit Document Obligations or, if the proceeds are insufficient to pay in full all such Credit Document Obligations, its Pro Rata Share of the amount remaining to be distributed, provided that to the extent such proceeds are (a) in respect of ECF Collateral related to Vessel 1, such proceeds will be applied first to the outstanding Credit Document Obligations in respect of Tranche A Loans and second to the outstanding Credit Document Obligations in respect of Tranche B Loans, and (b) in respect of ECF Collateral related to Vessel 2, such proceeds will be applied first to the outstanding Credit Document Obligations in respect of Tranche B Loans and second to the outstanding Credit Document Obligations in respect of Tranche A Loans;

(iii) third, to the extent proceeds remain after the application pursuant to the preceding clauses (i) and (ii), an amount equal to the outstanding Other Obligations shall be paid to the Other Creditors as provided in Section 4.05(d) hereof, with each Other Creditor receiving an amount equal to such outstanding Other Obligations or, if the proceeds are insufficient to pay in full all such Other Obligations, its Pro Rata Share of the amount remaining to be distributed, provided that to the extent such monies are (a) in respect of ECF Collateral related to Vessel 1, such proceeds will be applied first to the outstanding Other Obligations in respect of Tranche A Loans and second to the outstanding Other Obligations in respect of Tranche B Loans, and (b) in respect of ECF Collateral related to Vessel 2, such proceeds will be applied first to the outstanding Other Obligations in respect of Tranche B Loans and second to the outstanding Other Obligations in respect of Tranche A Loans; and

(iv) fourth, to the extent proceeds remain after the application pursuant to the preceding clauses (i) through (iii), inclusive, and following the termination of this Agreement, the Credit Documents, the Interest Rate Protection Agreements and the Other Hedging Agreements in accordance with their terms, to the relevant Credit Party or to whomever may be lawfully entitled to receive such surplus.

(b) For purposes of this Agreement, “Pro Rata Share” shall mean, when calculating a Secured Creditor’s portion of any distribution or amount, that amount (expressed as a percentage) equal to a fraction the numerator of which is the then unpaid amount of such Secured Creditor’s Credit Document Obligations or Other Obligations, as the case may be, and the denominator of which is the then outstanding amount of all Credit Document Obligations or Other Obligations, as the case may be.

(c) If any payment to any Secured Creditor of its Pro Rata Share of any distribution would result in overpayment to such Secured Creditor, such excess amount shall instead be distributed in respect of the unpaid Credit Document Obligations or Other

 

-46-


Obligations, as the case may be, of the other Secured Creditors, with each Secured Creditor whose Credit Document Obligations or Other Obligations, as the case may be, have not been paid in full to receive an amount equal to such excess amount multiplied by a fraction the numerator of which is the unpaid Credit Document Obligations or Other Obligations, as the case may be, of such Secured Creditor and the denominator of which is the unpaid Credit Document Obligations or Other Obligations, as the case may be, of all Secured Creditors entitled to such distribution.

(d) All payments required to be made hereunder shall be made (x) if to the Lender Creditors, to the Facility Agent under this Agreement for the account of the Lender Creditors, and (y) if to the Other Creditors, to the trustee, paying agent or other similar representative (each, a “Representative”) for the Other Creditors or, in the absence of such a Representative, directly to the Other Creditors.

(e) For purposes of applying payments received in accordance with this Section 4.05, the Collateral Agent shall be entitled to rely upon (i) the Facility Agent under this Agreement and (ii) the Representative for the Other Creditors or, in the absence of such a Representative, upon the Other Creditors for a determination (which the Facility Agent, each Representative for any Other Creditors and the Secured Creditors agree (or shall agree) to provide upon request of the Collateral Agent) of the outstanding Credit Document Obligations and Other Obligations owed to the Lender Creditors or the Other Creditors, as the case may be. Unless it has actual knowledge (including by way of written notice from an Other Creditor) to the contrary, the Collateral Agent, shall be entitled to assume that no Interest Rate Protection Agreements or Other Hedging Agreements are in existence.

(f) It is understood and agreed that each Credit Party shall remain jointly and severally liable to the extent of any deficiency between the amount of the proceeds of the Collateral pledged by it under and pursuant to the Security Documents and the aggregate amount of the Secured Obligations of such Credit Party.

SECTION 5. Conditions Precedent to the Initial Borrowing Dates. The obligation of each Lender to make Loans on each Initial Borrowing Date is subject at the time of the making of such Loans to the satisfaction or (other than in the case of Sections 5.02, 5.04, 5.05, 5.06, 5.07, 5.08, 5.10 and 5.12) waiver of the following conditions:

5.01 Effective Date. On or prior to the first Initial Borrowing Date, the Effective Date shall have occurred.

5.02 Intercreditor Agreement. (a) On or prior to the first Initial Borrowing Date, the Jade Intercreditor Agreement shall have been executed by the parties thereto and shall be in full force and effect;

(b) On or prior to the Tranche A Initial Borrowing Date, the Tranche A Intercreditor Agreement shall have been executed by the parties thereto and shall be in full force and effect; and

 

-47-


(c) On or prior to the Tranche B Initial Borrowing Date, the Tranche B Intercreditor Agreement shall have been executed by the parties thereto and shall be in full force and effect; and

5.03 Corporate Documents; Proceedings; etc. On the first Initial Borrowing Date, the Facility Agent shall have received a certificate, dated the Initial Borrowing Date, signed by the secretary or any assistant secretary of each Credit Party (or, to the extent such Credit Party does not have a secretary or assistant secretary, the analogous Person within such Credit Party), and attested to by an authorized officer, member or general partner of such Credit Party, as the case may be, in substantially the form of Exhibit D, with appropriate insertions, together with copies of the certificate of incorporation and by-laws (or equivalent organizational documents) of such Credit Party and the resolutions of such Credit Party referred to in such certificate.

5.04 Know Your Customer. On the first Initial Borrowing Date, the Facility Agent, the Hermes Agent and the Lenders shall have been provided with all information requested in order to carry out and be reasonably satisfied with all necessary “know your customer” information required pursuant to the PATRIOT ACT and such other documentation and evidence necessary in order for the Lenders to carry out and be reasonably satisfied with other similar checks under all applicable laws and regulations pursuant to the Transaction and the Hermes Cover in connection with each of the Facility Agent’s, the Hermes Agent’s and each Lender’s internal compliance regulations.

5.05 Construction Contract and Other Material Agreements. On or prior to the first Initial Borrowing Date, the Facility Agent shall have received a true, correct and complete copy of each Construction Contract, which shall be in full force and effect, and all other material contracts in connection with the construction, supervision and acquisition of each New Vessel that the Facility Agent may reasonably request and all such documents shall be reasonably satisfactory in form and substance to the Facility Agent (it being understood that the executed copy of each Construction Contract delivered to the Joint Lead Arrangers prior to the Effective Date and attached as an exhibit to the Commitment Letter is satisfactory).

5.06 Assignment of Contracts. (a) On the Tranche A Initial Borrowing Date, Breakaway One shall have duly authorized, executed and delivered a valid and effective second-priority (junior only to the Liens of the secured creditors under the Breakaway One Facility and pari passu with the Liens of the secured creditors under the Other Term Loan Facility) legal assignment in favor of the Collateral Agent of all of Breakaway One’s present and future interests in and benefits under (x) the Vessel 1 Construction Contract, (y) the Refund Guarantees in respect of Vessel 1 and (z) any and all Construction Risk Insurances in respect of Vessel 1 (it being understood that the Parent and/or Breakaway One will use commercially reasonable efforts to have the underwriters of the Construction Risk Insurances accept and endorse on such insurance policy a loss payable clause substantially in the form set forth in Annex 1 to Part 3 of the Vessel 1 Assignment of Contracts (as defined below), and it being further understood that certain of the Refund Guarantees in respect of Vessel 1 and none of the Construction Risk Insurances will have been issued on the Tranche A Initial Borrowing Date), which assignment shall be substantially in the form of Exhibit I-1 hereto or otherwise reasonably acceptable to the Joint Lead Arrangers and Breakaway One and customary for transactions of this type (as

 

-48-


modified, supplemented or amended from time to time, the “Vessel 1 Assignment of Contracts”), along with (to the extent incorporated into or required by such Exhibit or otherwise agreed by Breakaway One and the Facility Agent) appropriate notices and consents relating thereto, including, without limitation, those acknowledgments, notices and consents listed on Schedule 5.06; provided that, if the Refund Guarantee issued to Breakaway One on the Initial Borrowing Date (under and as defined in the Breakaway One Facility) shall have been issued by KfW IPEX-Bank GmbH, then such Refund Guarantee shall be assigned pursuant to a duly authorized, executed and delivered, valid and effective second-priority (junior only to the Liens of the secured creditors under the Breakaway One Facility and pari passu with the Liens of the secured creditors under the Other Term Loan Facility) legal assignment of Refund Guarantee in the form of Exhibit O-1 hereto or otherwise reasonably acceptable to the Joint Lead Arrangers and the Borrower and customary for transactions of this type, along with appropriate notices and consents relating thereto (to the extent incorporated into or required pursuant to such Exhibit or otherwise agreed by the Borrower and the Facility Agent) (as modified, supplemented or amended from time to time, the “Vessel 1 Assignment of KfW Refund Guarantees”); and

(b) On the Tranche B Initial Borrowing Date, Breakaway Two shall have duly authorized, executed and delivered a valid and effective second-priority (junior only to the Liens of the secured creditors under the Breakaway Two Facility and pari passu with the Liens of the secured creditors under the Other Term Loan Facility) legal assignment in favor of the Collateral Agent of all of Breakaway Two’s present and future interests in and benefits under (x) the Vessel 2 Construction Contract, (y) the Refund Guarantees in respect of Vessel 2 and (z) any and all Construction Risk Insurances in respect of Vessel 2 (it being understood that the Parent and/or Breakaway Two will use commercially reasonable efforts to have the underwriters of the Construction Risk Insurances accept and endorse on such insurance policy a loss payable clause substantially in the form set forth in Annex 1 to Part 3 of the Vessel 2 Assignment of Contracts (as defined below), and it being further understood that certain of the Refund Guarantees in respect of Vessel 2 and none of the Construction Risk Insurances will have been issued on the Tranche B Initial Borrowing Date), which assignment shall be substantially in the form of Exhibit I-2 hereto or otherwise reasonably acceptable to the Joint Lead Arrangers and Breakaway Two and customary for transactions of this type (as modified, supplemented or amended from time to time, the “Vessel 2 Assignment of Contracts” and together with the “Vessel 1 Assignment of Contracts”, the “Assignments of Contracts”), along with (to the extent incorporated into or required by such Exhibit or otherwise agreed by Breakaway Two and the Facility Agent) appropriate notices and consents relating thereto, including, without limitation, those acknowledgments, notices and consents listed on Schedule 5.06; provided that, if the Refund Guarantee issued to Breakaway Two on the Initial Borrowing Date (under and as defined in the Breakaway Two Facility) shall have been issued by KfW IPEX-Bank GmbH, then such Refund Guarantee shall be assigned pursuant to a duly authorized, executed and delivered, valid and effective second-priority (junior only to the Liens of the secured creditors under the Breakaway Two Facility and pari passu with the Liens of the secured creditors under the Other Term Loan Facility) legal assignment of Refund Guarantee in the form of Exhibit O-2 hereto or otherwise reasonably acceptable to the Joint Lead Arrangers and the Borrower and customary for transactions of this type, along with appropriate notices and consents relating thereto (to the extent incorporated into or required pursuant to such Exhibit or otherwise agreed by the Borrower and the Facility Agent) (as modified, supplemented or amended from time to time, the “Vessel 1 Assignment of KfW Refund Guarantees” and together with the Vessel 1 Assignment of KfW Refund Guarantee, the “Assignments of KfW Refund Guarantees”).

 

-49-


5.07 Collateral and Guaranty Requirements. On or prior to the first Initial Borrowing Date, the Collateral and Guaranty Requirements with respect to the Collateral Vessel shall have been satisfied or the Facility Agent shall have waived such requirements and/or conditioned such waiver on the satisfaction of such requirements within a specified period of time.

5.08 Consents Under Existing Credit Facilities. On or prior to the first Initial Borrowing Date, the Facility Agent shall have received evidence that all conditions, waivers, consents, acknowledgments and amendments in relation to any existing credit facilities of the Parent and/or any of its Subsidiaries required in connection with or in order to permit the transactions hereunder (including, without limitation, any prepayments required in connection therewith) shall have been obtained and/or satisfied.

5.09 Process Agent. On or prior to the first Initial Borrowing Date, the Facility Agent shall have received satisfactory evidence from the Parent, the Borrower and any other applicable Credit Party that they have each appointed an agent in London for the service of process or summons in relation to each of the Credit Documents.

5.10 Equity Payment. (a) On the Tranche A Initial Borrowing Date, the Facility Agent shall have received evidence, in form and substance reasonably satisfactory to the Facility Agent, that Breakaway One shall have funded from cash on hand an amount equal to 1% of the Initial Construction Price for Vessel 1 (other than from the proceeds of Loans, and loans under the ECF Facilities and the Other Term Loan Facility); and

(b) on the Tranche B Initial Borrowing Date, the Facility Agent shall have received evidence, in form and substance reasonably satisfactory to the Facility Agent, that Breakaway Two shall have funded from cash on hand an amount equal to 1% of the Initial Construction Price for Vessel 2 (other than from the proceeds of Loans, and loans under the ECF Facilities and the Other Term Loan Facility).

5.11 Financing Statements. On each Initial Borrowing Date, the Collateral Agent, in consultation with the applicable Credit Parties, shall have:

(a) prepared and filed proper financing statements (Form UCC-1 or the equivalent) fully prepared for filing under the UCC or in other appropriate filing offices of each jurisdiction as may be necessary or, in the reasonable opinion of the Collateral Agent, desirable to perfect or give notice to third parties, as the case may be, the security interests purported to be created by (i) the Vessel 1 Assignment of Contracts and the Vessel 1 Assignment of KfW Refund Guarantees (if any) with respect to the Tranche A Initial Borrowing Date or (ii) the Vessel 2 Assignment of Contracts and the Vessel 2 Assignment of KfW Refund Guarantees (if any) with respect to the Tranche B Initial Borrowing Date; and

 

-50-


(b) received certified copies of lien search results (Form UCC-11) listing all effective financing statements that name each Credit Party as debtor and that are filed in the District of Columbia and Florida, together with Form UCC-3 Termination Statements (or such other termination statements as shall be required by local law) fully prepared for filing if required by applicable laws for any financing statement which covers the Collateral except to the extent evidencing Permitted Liens.

5.12 Opinions of Counsel. The Facility Agent shall have received from:

(a) O’Melveny & Myers LLP (or another counsel reasonably acceptable to the Joint Lead Arrangers), special New York counsel to the Parent and Borrower, an opinion addressed to the Facility Agent and each of the Lenders and dated the first Initial Borrowing Date in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12;

(b) Cains (or another counsel reasonably acceptable to the Joint Lead Arrangers), special Isle of Man counsel to the Credit Parties, an opinion addressed to the Facility Agent and each of the Lenders and dated the first Initial Borrowing Date in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12;

(c) Cox Hallett Wilkinson (or another counsel reasonably acceptable to the Joint Lead Arrangers), special Bermudian counsel to the Credit Parties, an opinion addressed to the Facility Agent and each of the Lenders and dated (i) the first Initial Borrowing Date or (ii) the second Initial Borrowing Date, as applicable, in each case in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12;

(d) White & Case LLP (or another counsel reasonably acceptable to the Joint Lead Arrangers), special English counsel to the Documentation Agent for the benefit of the Joint Lead Arrangers, an opinion addressed to the Facility Agent (for itself and on behalf of the Lenders) and the Collateral Agent (for itself and on behalf of the Lenders) dated (i) the first Initial Borrowing Date or (ii) the second Initial Borrowing Date, as applicable, in each case, in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12;

(e) White & Case LLP (or another counsel reasonably acceptable to the Joint Lead Arrangers), special German counsel to the Documentation Agent for the benefit of the Joint Lead Arrangers, an opinion addressed to the Facility Agent and each of the Lenders and dated the first Initial Borrowing Date in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12;

 

-51-


(f) Graham Thompson & Co. (or another counsel reasonably acceptable to the Joint Lead Arrangers), special Bahamian counsel to the Credit Parties (or if the Collateral Vessel is not flagged in the Bahamas, counsel qualified in the jurisdiction of the flag of the Collateral Vessel and reasonably satisfactory to the Facility Agent), an opinion addressed to the Facility Agent and each of the Lenders and dated the first Initial Borrowing Date in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12; and

(g) Holland & Knight LLP (or another counsel reasonably acceptable to the Joint Lead Arrangers) special Florida counsel to the Credit Parties, an opinion addressed to the Facility Agent and each of the Lenders and dated the first Initial Borrowing Date in substantially the form delivered to the Borrower and the Lenders prior to the Effective Date, or otherwise reasonably satisfactory to the Joint Lead Arrangers, covering such matters set forth on Schedule 5.12.

5.13 Security Trust Deed. On the first Initial Borrowing Date, the Security Trust Deed shall have been executed by the parties thereto and shall be in full force and effect.

5.14 Litigation. On each Initial Borrowing Date, there shall be no actions, suits or proceedings (governmental or private) pending or, to the Parent or the Borrower’s knowledge, threatened (i) with respect to this Agreement, any other Credit Document, any Other Term Loan Credit Document or any Export Credit Document, or (ii) which has had, or, if adversely determined, could reasonably be expected to have, a Material Adverse Effect.

SECTION 6. Conditions Precedent to each Borrowing Date. The obligation of each Lender to make Loans on each Borrowing Date is subject at the time of the making of such Loans to the satisfaction or (other than in the case of Sections 6.01, 6.02, 6.03, 6.04, 6.06 and 6.07) waiver of the following conditions:

6.01 No Default; Representations and Warranties. At the time of each Borrowing and also after giving effect thereto (i) there shall exist no Default or Event of Default and (ii) all representations and warranties contained herein or in any other Credit Document shall be true and correct in all material respects both before and after giving effect to such Borrowing with the same effect as though such representations and warranties had been made on the Borrowing Date in respect of such Borrowing (it being understood and agreed that any representation or warranty which by its terms is made as of a specified date shall be required to be true and correct in all material respects only as of such specified date).

6.02 Consents. On or prior to each Borrowing Date, all necessary governmental (domestic and foreign) and material third party approvals and/or consents in connection with each Construction Contract, the Refund Guarantees (to the extent issued on or prior to such Borrowing Date), each New Vessel, the Collateral Vessel and the other transactions contemplated hereby (except to the extent specifically addressed in other sections of Section 5 or

 

-52-


this Section 6) shall have been obtained and remain in effect. On each Borrowing Date, there shall not exist any judgment, order, injunction or other restraint issued or filed or a hearing seeking injunctive relief or other restraint pending or notified prohibiting or imposing materially adverse conditions upon this Agreement, the Transaction or the other transactions contemplated by the Credit Documents.

6.03 Refund Guarantees. (a) On (i) the Tranche A Initial Borrowing Date, the Refund Guarantee for the Pre-delivery Installment in respect of Vessel 1 to be paid on the Initial Borrowing Date (under and as defined in the Breakaway One Facility) shall have been issued and assigned to the Collateral Agent pursuant to the Vessel 1 Assignment of Contracts (or, if such Refund Guarantee is issued by KfW IPEX-Bank GmbH, the Vessel 1 Assignment of KfW Refund Guarantees) and (ii) on each other Tranche A Borrowing Date other than the Vessel 1 Delivery Date, any additional Refund Guarantees for Vessel 1 that have been issued since the Tranche A Initial Borrowing Date shall have been assigned to the Collateral Agent by delivering a supplement to the relevant schedule to the Vessel 1 Assignment of Contracts (or, in the case of Refund Guarantees issued by KfW IPEX-Bank GmbH, a supplement to the relevant schedule of the Vessel 1 Assignment of KfW Refund Guarantees) to the Collateral Agent with the updated information, in each case along with (to the extent incorporated in or required by the Vessel 1 Assignment of Contracts) an appropriate notice and consent relating thereto, and the Joint Lead Arrangers shall have received reasonably satisfactory evidence to such effect. Each Refund Guarantee shall secure a principal amount equal to (x) the amount of the corresponding Pre-delivery Installment to be paid by Breakaway One to the Yard minus (y) the amount paid by the Yard to Breakaway One in respect of the corresponding Pre-delivery Installment under Article 8, Clause 2.8(i), (ii), (iii) or (iv) as the case may be, of the Vessel 1 Construction Contract pursuant to the terms of each Refund Guarantee, and the Joint Lead Arrangers shall have received reasonably satisfactory evidence to such effect.

(b) On (i) the Tranche B Initial Borrowing Date, the Refund Guarantee for the Pre-delivery Installment in respect of Vessel 2 to be paid on the Initial Borrowing Date (under and as defined in the Breakaway Two Facility) shall have been issued and assigned to the Collateral Agent pursuant to the Vessel 2 Assignment of Contracts (or, if such Refund Guarantee is issued by KfW IPEX-Bank GmbH, the Vessel 2 Assignment of KfW Refund Guarantees) and (ii) on each other Tranche B Borrowing Date other than the Vessel 2 Delivery Date, any additional Refund Guarantees for Vessel 2 that have been issued since the Tranche B Initial Borrowing Date shall have been assigned to the Collateral Agent by delivering a supplement to the relevant schedule to the Vessel 2 Assignment of Contracts (or, in the case of Refund Guarantees issued by KfW IPEX-Bank GmbH, a supplement to the relevant schedule of the Vessel 2 Assignment of KfW Refund Guarantees) to the Collateral Agent with the updated information, in each case along with (to the extent incorporated in or required by the Vessel 2 Assignment of Contracts) an appropriate notice and consent relating thereto, and the Joint Lead Arrangers shall have received reasonably satisfactory evidence to such effect. Each Refund Guarantee shall secure a principal amount equal to (x) the amount of the corresponding Pre-delivery Installment to be paid by Breakaway Two to the Yard minus (y) the amount paid by the Yard to Breakaway Two in respect of the corresponding Pre-delivery Installment under Article 8, Clause 2.8(i), (ii), (iii) or (iv) as the case may be, of the Vessel 2 Construction Contract pursuant to the terms of each Refund Guarantee, and the Joint Lead Arrangers shall have received reasonably satisfactory evidence to such effect.

 

-53-


6.04 ECF Payment. On each Borrowing Date (other than on an Initial Borrowing Date) on which the proceeds of Loans are being used to fund (or reimburse) a payment under a Construction Contract, the relevant ECF Borrower shall have paid (other than from proceeds of Loans or loans under the Other Term Loan Facility) [*] of the amount due on such Borrowing Date under the Construction Contract, which payment may be made from proceeds of ECF Loans under the relevant ECF Facility.

6.05 Fees, Costs, etc. On each Borrowing Date, the Borrower shall have paid to the Agents, the Joint Lead Arrangers and the Lenders all costs, fees, expenses (including, without limitation, reasonable fees and expenses of White & Case LLP and local and maritime counsel and consultants) and other compensation contemplated hereby payable to the Agents, the Joint Lead Arrangers and the Lenders or payable in respect of the transactions contemplated hereunder, to the extent then due; provided that any such costs, fees and expenses and other compensation shall have been invoiced to the Borrower at least three Business Days prior to such Borrowing Date.

6.06 Construction Contract. On each Borrowing Date, the Borrower shall have certified that all conditions and requirements under the relevant Construction Contract required to be satisfied on such Borrowing Date, including in connection with the respective payment installments to be made to the Yard on such Borrowing Date, shall have been satisfied (including, but not limited to, the relevant ECF Borrower’s payment to the Yard of the portion of the payment installment on the relevant New Vessel that is not being financed with proceeds of the Loans), other than those that are not materially adverse to the Lenders, it being understood that any litigation between the Yard and the Parent and/or Borrower shall be deemed to be materially adverse to the Lenders.

6.07 Hermes Cover. On each Borrowing Date, (x) the Facility Agent shall have received evidence from the Hermes Agent that the Hermes Cover is in full force and effect on terms acceptable to the Joint Lead Arrangers (it being understood that each Joint Lead Arranger shall have confirmed to the Hermes Agent that the terms of the Hermes Cover are acceptable), and all due and owing Hermes Premium to be paid in connection therewith shall have been paid in full, provided it is understood and agreed that the Hermes Cover shall have been granted as soon as the Hermes Agent and/or KfW IPEX-Bank GmbH receives the Declaration of Guarantee (Gewährleistungs-Erklärung) from Hermes and (y) all Loans and other financing to be made pursuant hereto shall be in material compliance with the Hermes Cover and all applicable requirements of law or regulation.

6.08 Notice of Borrowing. Prior to the making of each Loan, the Facility Agent shall have received the Notice of Borrowing required by Section 2.03(a).

6.09 Solvency Certificate. On each Borrowing Date, Parent shall cause to be delivered to the Facility Agent a solvency certificate from a senior financial officer of Parent, in substantially the form of Exhibit J or otherwise reasonably acceptable to the Facility Agent, which shall be addressed to the Facility Agent and each of the Lenders and dated such Borrowing Date, setting forth the conclusion that, after giving effect to the transactions hereunder (including the incurrence of all the financing contemplated with respect thereto and the purchase of each New Vessel), the Parent and its Subsidiaries, taken as a whole, are not

 

-54-


insolvent and will not be rendered insolvent by the Indebtedness incurred in connection therewith, and will not be left with unreasonably small capital with which to engage in their respective businesses and will not have incurred debts beyond their ability to pay such debts as they mature.

6.10 Litigation. On each Borrowing Date, other than as set forth on Schedule 6.10, there shall be no actions, suits or proceedings (governmental or private) pending or, to the Parent or the Borrower’s knowledge, threatened (i) with respect to this Agreement or any other Credit Document or (ii) which have had, or, if adversely determined, could reasonably be expected to have, a Material Adverse Effect.

The acceptance of the proceeds of each Loan shall constitute a representation and warranty by the Borrower to the Facility Agent and each of the Lenders that all of the applicable conditions specified in Section 5, this Section 6 and Section 7 applicable to such Loan have been satisfied as of that time.

SECTION 7. Conditions Precedent to each Delivery Date. The obligation of each Lender to make Loans on a Delivery Date is subject at the time of making such Loans to the satisfaction of the following conditions:

7.01 Delivery of Vessel. On each Delivery Date, the relevant New Vessel shall have been delivered in accordance with the terms of the relevant Construction Contract, other than those changes that would not be materially adverse to the interests of the Lenders.

7.02 Evidence of 90% Payment. On the Delivery Date, the relevant ECF Borrower shall have provided funding for an amount in the aggregate equal to the sum of at least (x) 90% of the Initial Construction Price for the relevant New Vessel out of which up to 80% of the Initial Construction Price may be funded by ECF Loans under the relevant ECF Facility, (y) [*] of the Permitted Change Orders, out of which up to [*] of such Permitted Change Orders may be funded by ECF Loans under the relevant ECF Facility and (z) [*] of the difference between the Final Construction Price and the Adjusted Construction Price for the relevant New Vessel (in each case, other than from proceeds of Loans or loans under the Other Term Loan Facility, but with respect to clauses (x) and (y) only, giving effect to proceeds from ECF Loans under the relevant ECF Facility) and the Facility Agent shall have received a certificate from an officer of the relevant ECF Borrower to such effect.

7.03 Hermes Compliance; Compliance with Applicable Laws and Regulations. On the Delivery Date, all Loans and other financing to be made pursuant hereto shall be in material compliance with all applicable requirements of law or regulation and the Hermes Cover.

SECTION 8. Representations and Warranties. In order to induce the Lenders to enter into this Agreement and to make the Loans, the Borrower or each Credit Party, as applicable, makes the following representations and warranties, in each case on a daily basis, all of which shall survive the execution and delivery of this Agreement and the making of the Loans:

8.01 Entity Status. The Parent and each of the other Credit Parties (i) is a Person duly organized, constituted and validly existing (or the functional equivalent) under the

 

-55-


laws of the jurisdiction of its formation, has the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted and (ii) is duly qualified and is authorized to do business and is in good standing (or the functional equivalent) in each jurisdiction where the ownership, leasing or operation of its property or the conduct of its business requires such qualifications except for failures to be so qualified or authorized or in good standing which, either individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.

8.02 Power and Authority. Each of the Credit Parties has the power to enter into and perform this Agreement (as applicable) and those of the other Credit Documents to which it is a party and the transactions contemplated hereby and thereby and has taken all necessary action to authorize the entry into and performance of this Agreement and such other Credit Documents and such transactions. This Agreement constitutes legal, valid and binding obligations of the Parent and the Borrower enforceable in accordance with its terms and in entering into this Agreement and borrowing the Loans (in the case of the Borrower), the Parent and the Borrower are each acting on their own account. Each other Credit Document constitutes (or will constitute when executed) legal, valid and binding obligations of each Credit Party expressed to be a party thereto enforceable in accordance with their respective terms

8.03 No Violation. The entry into and performance of this Agreement (as applicable), the other Credit Documents and the transactions contemplated hereby and thereby do not and will not conflict with:

 

  (a) any law or regulation or any official or judicial order; or

 

  (b) the constitutional documents of any Credit Party; or

 

  (c) except as set forth on Schedule 8.03, any agreement or document to which any member of the NCLC Group is a party or which is binding upon such Credit Party or any of its assets, nor result in the creation or imposition of any Lien on a Credit Party or its assets pursuant to the provisions of any such agreement or document (it being understood that the Export Credit Facilities and the Other Term Loan Facility shall create senior and pari passu Liens, respectively, on certain Collateral).

8.04 Governmental Approvals. Except for (x) the filing of those Security Documents which require registration in the Companies Registries in England and Wales, the Federal Republic of Germany, the Isle of Man Department of Economic Development, the Bahamas, any state of the United States of America and/or with the Registrar of Companies in Bermuda, which filing must be completed within (i) 21 days of the execution and delivery of the relevant Security Document(s) in the case of England and Wales and (ii) one month of the execution and delivery of the relevant Security Document(s) in the case of the Isle of Man, and (y) the registration of the Vessel Mortgage through the Bahamas Maritime Authority, all authorizations, approvals, consents, licenses, exemptions, filings, registrations, notarizations and other matters, official or otherwise, required in connection with the entry into, performance, validity and enforceability of this Agreement and each of the other Credit Documents and the transactions contemplated thereby have been obtained or effected and are in full force and effect

 

-56-


except for matters in respect of (I) the Construction Risk Insurances and the Refund Guarantees (in each case to the extent that such Collateral has not yet been delivered) and (II) Collateral to be delivered on the Delivery Date.

8.05 Financial Statements; Financial Condition. (a)(i) The audited consolidated balance sheets of the Parent and its Subsidiaries as at December 31, 2007, December 31, 2008 and December 31, 2009 and the unaudited consolidated balance sheets of the Parent and its Subsidiaries as at June 30, 2010 and the related consolidated statements of operations and of cash flows for the fiscal years or quarters, as the case may be, ended on such dates, reported on by and accompanied by, in the case of the annual financial statements, an unqualified report from PricewaterhouseCoopers LLP, present fairly in all material respects the consolidated financial condition of the Parent and its Subsidiaries as at such date, and the consolidated results of its operations and its consolidated cash flows for the respective fiscal years or quarters, as the case may be, then ended. All such financial statements, including the related schedules and notes thereto, have been prepared in accordance with GAAP applied consistently throughout the periods involved (except as approved by the aforementioned firm of accountants and disclosed therein).

(ii) The pro forma consolidated balance sheet of the Parent and its Subsidiaries as of June 30, 2010 (after giving effect to the Transaction and the financing therefor), a copy of which has been furnished to the Lenders prior to the first Initial Borrowing Date, presents a good faith estimate in all material respects of the pro forma consolidated financial position of the Parent and its Subsidiaries as of such date.

(b) Since December 31, 2009, nothing has occurred that has had or could reasonably be expected to have a Material Adverse Effect.

8.06 Litigation. No litigation, arbitration or administrative proceedings of or before any court, arbitral body or agency (including but not limited to investigative proceedings) are current or pending or, to the Parent or the Borrower’s knowledge, threatened, which might, if adversely determined, have a Material Adverse Effect.

8.07 True and Complete Disclosure. Each Credit Party has fully disclosed in writing to the Facility Agent all facts relating to such Credit Party which it knows or should reasonably know and which might reasonably be expected to influence the Lenders in deciding whether or not to enter into this Agreement.

8.08 Use of Proceeds. (a) All proceeds of the Tranche A Loans may be used only to finance (i) up to 10% of the Initial Construction Price of Vessel 1 and (ii) up to [*] of the Hermes Premium, and (b) all proceeds of the Tranche B Loans may be used to finance (i) up to 10% of the Initial Construction Price of Vessel 2 and (ii) up to [*] of the related Hermes Premium.

8.09 Tax Returns and Payments. The NCLC Group have complied with all taxation laws in all jurisdictions in which it is subject to Taxation and has paid all material Taxes due and payable by it; no material claims are being asserted against it with respect to Taxes, which might, if such claims were successful, have a material adverse effect on the ability of any Credit Party to perform its obligations under the Credit Documents or could otherwise be

 

-57-


reasonably expected to have a Material Adverse Effect. As at the Effective Date all amounts payable by the Parent and the Borrower hereunder may be made free and clear of and without deduction for or on account of any Taxation in the Parent and the Borrower’s jurisdiction.

8.10 No Material Misstatements. (a) All written information (other than the Projections, estimates and information of a general economic nature or general industry nature) (the “Information”) concerning the Parent and its Subsidiaries, and the transactions contemplated hereby prepared by or on behalf of the foregoing or their representatives and made available to any Lenders or any Agent in connection with the transactions contemplated hereby, when taken as a whole, was true and correct in all material respects, as of the date such Information was furnished to the Lenders or any Agent and as of the Effective Date and did not, taken as a whole, contain any untrue statement of a material fact as of any such date or omit to state a material fact necessary in order to make the statements contained therein, taken as a whole, not materially misleading in light of the circumstances under which such statements were made.

(b) The Projections and estimates and information of a general economic nature prepared by or on behalf of the Parent, the Borrower or any of their respective representatives and that have been made available to any Lenders or any Agent in connection with the transactions contemplated hereby (i) have been prepared in good faith based upon assumptions believed by the Parent, the Borrower to be reasonable as of the date thereof (it being understood that actual results may vary materially from the Projections), as of the date such Projections and estimates were furnished to the Lenders and as of the Effective Date, and (ii) as of the Effective Date, have not been modified in any material respect by the Parent or the Borrower.

8.11 The Security Documents. (a) None of the Collateral is subject to any Liens except Permitted Liens.

(b) After the execution and registration thereof, the Vessel Mortgage will create, as security for the obligations purported to be secured thereby, a valid and enforceable perfected security interest in and mortgage lien on the Collateral Vessel in favor of the Collateral Agent (or such other trustee as may be required or desired under local law) for the benefit of the Secured Creditors, superior and prior to the rights of all third Persons (except that the security interest and mortgage lien created on the Collateral Vessel may be subject to the Permitted Liens related thereto, including the Permitted Liens held by the creditors under the Senior Loan Agreements) and subject to no other Liens (other than Permitted Liens related thereto, including the Permitted Liens held pursuant to the Senior Loan Agreements).

(c) After the execution and delivery thereof and upon the taking of the actions mentioned in the immediately succeeding sentence, each of the Security Documents will create in favor of the Collateral Agent for the benefit of the Secured Creditors a legal, valid and enforceable fully perfected security interest in and Lien on all right, title and interest of the Credit Parties party thereto in the Collateral described therein, subject only to Permitted Liens. Subject to Sections 5.07, 8.04 and this Section 8.11 and the definition of “Collateral and Guaranty Requirements,” no filings or recordings are required in order to perfect the security interests created under any Security Document except for filings or recordings which shall have been made on or prior to the execution of such Security Document.

 

-58-


8.12 Capitalization. All the Capital Stock, as set forth on Schedule 8.12, in the Borrower and each other Credit Party (other than the Parent) is legally and beneficially owned directly or indirectly by the Parent and, except as permitted by Section 10.02, such structure shall remain so until the later of the Tranche A Loan Maturity Date and the Tranche B Loan Maturity Date.

8.13 Subsidiaries. On and as of the first Initial Borrowing Date, other than in respect of Dormant Subsidiaries (i) the Parent has no Subsidiaries other than those Subsidiaries listed on Schedule 8.13 which Schedule identifies the correct legal name, direct owner, percentage ownership and jurisdiction of organization of the Borrower and each such other Subsidiary on the date hereof, (ii) all outstanding shares of the Borrower and each other Subsidiary of the Parent have been duly and validly issued, are fully paid and non-assessable and have been issued free of preemptive rights, and (iii) neither the Borrower nor any Subsidiary of the Parent has outstanding any securities convertible into or exchangeable for its Capital Stock or outstanding any right to subscribe for or to purchase, or any options or warrants for the purchase of, or any agreement providing for the issuance (contingent or otherwise) of or any calls, commitments or claims of any character relating to, its Capital Stock or any stock appreciation or similar rights.

8.14 Compliance with Statutes, etc. The Parent and each of its Subsidiaries is in compliance in all material respects with all applicable statutes, regulations and orders of, and all applicable restrictions imposed by, all governmental bodies, domestic or foreign, in respect of the conduct of its business and the ownership of its property, except such noncompliances as could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

8.15 Winding-up, etc. None of the events contemplated in clauses (a), (b), (c) or (d) of Section 11.05 has occurred with respect to any Credit Party.

8.16 No Default. No event has occurred which constitutes a Default or Event of Default under or in respect of any Credit Document to which any Credit Party is a party or by which the Parent or any of its Subsidiaries may be bound (including (inter alia) this Agreement) and no event has occurred which constitutes a default under or in respect of any agreement or document to which any Credit Party is a party or by which any Credit Party may be bound, except to an extent as could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

8.17 Pollution and Other Regulations. Each of the Credit Parties:

(a) is in compliance with all applicable federal, state, local, foreign and international laws, regulations, conventions and agreements relating to pollution prevention or protection of human health or the environment (including, without limitation, ambient air, surface water, ground water, navigable waters, water of the contiguous zone, ocean waters and international waters), including without limitation, laws, regulations, conventions and agreements relating to (i) emissions, discharges, releases or threatened releases of chemicals, pollutants, contaminants, wastes, toxic substances, hazardous materials, oil, hazard substances, petroleum and petroleum products and by-products (“Materials of Environmental Concern”) or (ii) Environmental Law;

 

-59-


(b) has all permits, licenses, approvals, rulings, variances, exemptions, clearances, consents or other authorizations required under applicable Environmental Law (“Environmental Approvals”) and is in compliance with all Environmental Approvals required to operate its business as presently conducted or as reasonably anticipated to be conducted;

(c) has not received any notice, claim, action, cause of action, investigation or demand by any other person, alleging potential liability for, or a requirement to incur, investigatory costs, clean-up costs, response and/or remedial costs (whether incurred by a governmental entity or otherwise), natural resources damages, property damages, personal injuries, attorneys’ fees and expenses or fines or penalties, in each case arising out of, based on or resulting from (i) the presence or release or threat of release into the environment of any Materials of Environmental Concern at any location, whether or not owned by such person or (ii) Environmental Claim,

which is, or are, in each case, material; and

there are no circumstances that may prevent or interfere with such full compliance in the future.

There are no Environmental Claims pending or threatened against any of the Credit Parties which the Parent or the Borrower, in its reasonable opinion, believes to be material.

There are no past or present actions, activities, circumstances, conditions, events or incidents, including, without limitation, the release, emission, discharge or disposal of any Materials of Environmental Concern, that the Parent or the Borrower reasonably believes could form the basis of any bona fide material Environmental Claim against any of the Credit Parties.

8.18 Ownership of Assets. Except as permitted by Section 10.02, each member of the NCLC Group has good and marketable title to all its assets which is reflected in the audited accounts referred to in Section 8.05(a)

8.19 Concerning the Collateral Vessel. (a) The name, registered owner, official number, and jurisdiction of registration and flag of the Collateral Vessel is set forth on Schedule 8.19 (as updated from time to time by the Borrower pursuant to Section 9.13 with respect to flag jurisdiction, and otherwise (with respect to name, registered owner, official number and jurisdiction of registration) upon advance notice and in a manner that does not interfere with the Lenders’ Liens on the Collateral, provided that the Borrower shall take all steps requested by the Collateral Agent to preserve and protect the Liens created by the Security Documents on the Collateral Vessel) and (b) as of the first Initial Borrowing Date, the Collateral Vessel is and will be operated in material compliance with all applicable law, rules and regulations.

8.20 Citizenship. None of the Credit Parties has an establishment in the United Kingdom within the meaning of the Overseas Companies Regulation 2009 or a place of business

 

-60-


in the United States (in each case, except as already disclosed) or any other jurisdiction which requires any of the Security Documents to be filed or registered in that jurisdiction to ensure the validity of the Security Documents to which it is a party unless (x) all such filings and registrations have been made or will be made as provided in Sections 5.07, 8.04 and 8.11 and the definition of “Collateral and Guaranty Requirements” and (y) prompt notice of the establishment of such a place of business is given to the Facility Agent and the requirements set forth in Section 9.10 have been satisfied. The Borrower and each other Credit Party which owns or operates, or will own or operate, the Collateral Vessel at any time is, or will be, qualified to own and operate the Collateral Vessel under the laws of the Bahamas or such other jurisdiction in which the Collateral Vessel is permitted, or will be permitted, to be flagged in accordance with the terms of Section 9.13.

8.21 Collateral Vessel Classification. The Collateral Vessel is classified in the highest class available for vessels of its age and type with a classification society listed on Schedule 8.21 hereto or another internationally recognized classification society reasonably acceptable to the Collateral Agent, free of any overdue conditions or recommendations.

8.22 No Immunity. None of the Credit Parties nor any of their respective assets enjoys any right of immunity (sovereign or otherwise) from set-off, suit or execution in respect of their obligations under this Agreement or any of the other Credit Documents or by any relevant or applicable law.

8.23 Fees, Governing Law and Enforcement. No fees or taxes, including, without limitation, stamp, transaction, registration or similar taxes, are required to be paid to ensure the legality, validity, or enforceability of this Agreement or any of the other Credit Documents other than recording taxes which have been, or will be, paid as and to the extent due. Under the laws of the Bahamas or any other jurisdiction where the Collateral Vessel is flagged, the choice of the laws of England as set forth in the Credit Documents which are stated to be governed by the laws of England is a valid choice of law, and the irrevocable submission by each Credit Party to jurisdiction and consent to service of process and, where necessary, appointment by such Credit Party of an agent for service of process, in each case as set forth in such Credit Documents, is legal, valid, binding and effective.

8.24 Form of Documentation. Each of the Credit Documents is in proper legal form (under the laws of England, the Bahamas, the Isle of Man, Bermuda and each other jurisdiction where the Collateral Vessel is flagged or where the Credit Parties are domiciled) for the enforcement thereof under such laws. To ensure the legality, validity, enforceability or admissibility in evidence of each such Credit Document in England, the Bahamas, the Isle of Man and/or Bermuda it is not necessary that any Credit Document or any other document be filed or recorded with any court or other authority in England, the Bahamas, the Isle of Man and/or Bermuda, except as have been made, or will be made, in accordance with Sections 5, 6, 7 and 8, as applicable.

8.25 Pari Passu or Priority Status. The claims of the Agents and the Lenders against the Parent or the Borrower under this Agreement will rank at least pari passu with the claims of all unsecured creditors of the Parent or the Borrower (other than claims of such creditors to the extent that they are statutorily preferred) and in priority to the claims of any creditor of the Parent or the Borrower who is also a Credit Party.

 

-61-


8.26 Solvency. The Credit Parties, taken as a whole, are and shall remain, after the advance to them of the Loans or any of such Loans, solvent in accordance with the laws of Bermuda, the United States, England, the Isle of Man and the Bahamas and in particular with the provisions of the Bankruptcy Code and the requirements thereof.

8.27 No Undisclosed Commissions. There are and will be no commissions, rebates, premiums or other payments by or to or on account of any Credit Party, their shareholders or directors in connection with the Transaction as a whole other than as disclosed to the Facility Agent or any other Agent in writing.

8.28 Completeness of Documentation. The copies of each Management Agreement, Construction Contract, each Refund Guarantee and, to the extent applicable, Supervision Agreement delivered to the Facility Agent are true and complete copies of each such document constituting valid and binding obligations of the parties thereto enforceable in accordance with their respective terms and no amendments thereto or variations thereof have been agreed nor has any action been taken by the parties thereto which would in any way render such document inoperative or unenforceable, unless replaced by a management agreement or management agreements, refund guarantees or, to the extent applicable, a supervision agreement, as the case may be, reasonably satisfactory to the Facility Agent.

8.29 Money Laundering. Any borrowing by the Borrower hereunder, and the performance of its obligations hereunder and under the other Security Documents, will be for its own account and will not, to the best of its knowledge, involve any breach by it of any law or regulatory measure relating to “money laundering” as defined in Article 1 of the Directive (2005/EC/60) of the European Parliament and of the Council of the European Communities.

SECTION 9. Affirmative Covenants. The Parent and the Borrower hereby covenant and agree that on and after the first Initial Borrowing Date and until the Total Commitment has terminated and the Loans, together with interest, Commitment Commission and all other obligations incurred hereunder and thereunder, are paid in full (other than contingent indemnification and expense reimbursement claims for which no claim has been made):

9.01 Information Covenants. The Parent will provide to the Facility Agent (or will procure the provision of):

(a) Quarterly Financial Statements. Within 60 days after the close of the first three fiscal quarters in each fiscal year of the Parent, the consolidated balance sheets of the Parent and its Subsidiaries as at the end of such quarterly accounting period and the related consolidated statements of operations and cash flows, in each case for such quarterly accounting period and for the elapsed portion of the fiscal year ended with the last day of such quarterly accounting period, and in each case, setting forth comparative figures for the related periods in the prior fiscal year, all of which shall be certified by a financial officer of the Borrower, subject to normal year-end audit adjustments and the absence of footnotes;

 

-62-


(b) Annual Financial Statements. Within 120 days after the close of each fiscal year of the Parent, the consolidated balance sheets of the Parent and its Subsidiaries as at the end of such fiscal year and the related consolidated statements of operations and changes in shareholders’ equity and of cash flows for such fiscal year setting forth comparative figures for the preceding fiscal year and audited by independent certified public accountants of recognized international standing, together with an opinion of such accounting firm (which opinion shall not be qualified as to scope of audit or as to the status of the Parent as a going concern) to the effect that such consolidated financial statements fairly present, in all material respects, the financial position and results of operations of the Parent and its Subsidiaries on a consolidated basis in accordance with GAAP;

(c) Valuations. After the first Initial Borrowing Date, together with delivery of the financial statements described in Section 9.01(b) for each fiscal year, and at any other time within 15 days of a written request from the Facility Agent, appraisal reports of recent date (but in no event earlier than 90 days before the delivery of such reports) from two Approved Appraisers or such other independent firm of shipbrokers or shipvaluers nominated by the Borrower and approved by the Facility Agent (acting on the instructions of the Required Lenders) or failing such nomination and approval, appointed by the Facility Agent (acting on such instructions) in its sole discretion (each such valuation to be made without, unless reasonably required by the Facility Agent, physical inspection and on the basis of a sale for prompt delivery for cash at arm’s length on normal commercial terms as between a willing buyer and a willing seller without taking into account the benefit of any charterparty or other engagement concerning the Collateral Vessel), stating the then current fair market value of the Collateral Vessel. All such appraisals shall be conducted by, and made at the expense of, the Borrower (it being understood that the Facility Agent may and, at the request of the Lenders, shall, upon prior written notice to the Borrower (which notice shall identify the names of the relevant appraisal firms), obtain such appraisals and that the cost of all such appraisals will be for the account of the Borrower); provided that, unless an Event of Default shall then be continuing, in no event shall the Borrower be required to pay for appraisal reports from two appraisers on more than one occasion in any fiscal year of the Borrower, with the cost of any such reports in excess thereof to be paid by the Lenders on a pro rata basis;

(d) Filings. Promptly, copies of all financial information, proxy materials and other information and reports, if any, which the Parent or any of its Subsidiaries shall file with the Securities and Exchange Commission (or any successor thereto);

(e) Projections. (i) As soon as practicable (and in any event within 120 days after the close of each fiscal year), commencing with the fiscal year ending December 31, 2010, annual cash flow projections on a consolidated basis of the NCLC Group showing on a monthly basis advance ticket sales (for at least 12 months following the date of such statement) for the NCLC Group;

(ii) As soon as practicable (and in any event not later than January 31 of each fiscal year):

 

  (x) a budget for the NCLC Group for such new fiscal year including a 12 month liquidity budget for such new fiscal year;

 

-63-


  (y) updated financial projections of the NCLC Group for at least the next five years (including an income statement and quarterly break downs for the first of those five years); and

 

  (z) an outline of the assumptions supporting such budget and financial projections including but without limitation any scheduled drydockings;

(f) Officer’s Compliance Certificates. As soon as practicable (and in any event within 60 days after the close of each of the first three quarters of its fiscal year and within 120 days after the close of each fiscal year), a statement signed by one of the Parent’s financial officers substantially in the form of Exhibit L (commencing with the fourth quarter of the fiscal year ending December 31, 2010) and such other information as the Facility Agent may reasonably request;

(g) Litigation. On a quarterly basis, details of any material litigation, arbitration or administrative proceedings affecting any Credit Party which are instituted and served, or, to the knowledge of the Parent or the Borrower, threatened (and for this purpose proceedings shall be deemed to be material if they involve a claim in an amount exceeding $25,000,000 or the equivalent in another currency);

(h) Notice of Event of Default. Promptly upon (i) any Credit Party becoming aware thereof (and in any event within three Business Days), notification of the occurrence of any Event of Default and (ii) the Facility Agent’s request from time to time, a certificate stating whether any Credit Party is aware of the occurrence of any Event of Default;

(i) Status of Foreign Exchange Arrangements. Promptly upon reasonable request from any Joint Lead Arranger through the Facility Agent, an update on the status of the Parent and the Borrower’s foreign exchange arrangements with respect to the New Vessels, the Other Term Loan Facility, the Export Credit Facilities and this Agreement; and

(j) Other Information. Promptly, such further information in its possession or control regarding its financial condition and operations and those of any company in the NCLC Group as the Facility Agent may reasonably request.

All accounts required under this Section 9.01 shall be prepared in accordance with GAAP and shall fairly represent in all material respects the financial condition of the relevant company.

9.02 Books and Records; Inspection. The Parent will keep, and will cause each of its Subsidiaries to keep, proper books of record and account in all material respects, in which materially proper and correct entries shall be made of all financial transactions and the assets, liabilities and business of the Parent and its Subsidiaries in accordance with GAAP. The Parent will, and will cause each of its Subsidiaries to, permit officers and designated representatives of the Facility Agent at the reasonable request of any Joint Lead Arranger to visit and inspect, under guidance of officers of the Parent or such Subsidiary, any of the properties of the Parent or such Subsidiary, and to examine the books of account of the Parent or such Subsidiary and discuss the affairs, finances and accounts of the Parent or such Subsidiary with, and be advised as to the

 

-64-


same by, its and their officers and independent accountants, all upon reasonable prior notice and at such reasonable times and intervals and to such reasonable extent as the Facility Agent at the reasonable request of any such Joint Lead Arranger may reasonably request.

9.03 Maintenance of Property; Insurance. The Parent will (x) keep, and will procure that each of its Subsidiaries keeps, all of its real property and assets properly maintained and in existence and will comprehensively insure, and will procure that each of its Subsidiaries comprehensively insures, for such amounts and of such types as would be effected by prudent companies carrying on business similar to the Parent or its Subsidiaries (as the case may be) and (y) maintain (or cause the Borrower to maintain) insurance (including, without limitation, hull and machinery, war risks, loss of hire (if applicable), protection and indemnity insurance as set forth on Schedule 9.03 (the “Required Insurance”) with respect to the Collateral Vessel at all times.

9.04 Corporate Franchises. The Parent will, and will cause each of its Subsidiaries to, do all such things as are necessary to maintain its corporate existence (except as permitted by Section 10.02) in good standing and will ensure that it has the right and is duly qualified to conduct its business as it is conducted in all applicable jurisdictions and will obtain and maintain all franchises and rights necessary for the conduct of its business, except, in the case of Subsidiaries that are not Credit Parties, to the extent that a failure to do so could not reasonably be expected to have a Material Adverse Effect.

9.05 Compliance with Statutes, etc. The Parent will, and will cause each of its Subsidiaries to, comply with all applicable statutes, regulations and orders of, and all applicable restrictions (including all laws and regulations relating to money laundering) imposed by, all governmental bodies, domestic or foreign, in respect of the conduct of its business and the ownership of its property, except such non-compliances as could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

9.06 Hermes Cover. (a) The terms and conditions of the Hermes Cover are incorporated herein and in so far as they impose terms, conditions and/or obligations on the Collateral Agent and/or the Facility Agent and/or the Hermes Agent and/or the Lenders in relation to the Borrower or any other Credit Party then such terms, conditions and obligations are binding on the parties hereto and further in the event of any conflict between the terms of the Hermes Cover and the terms hereof the terms of the Hermes Cover shall be paramount and prevail. For the avoidance of doubt, neither the Parent nor the Borrower has any interest or entitlement in the proceeds of the Hermes Cover. In particular, but without limitation, the Borrower shall pay any difference between the amount of the Loans drawn to pay the Hermes Premium, and the Hermes Premium.

(b) The Borrower shall at all times promptly pay all due and owing Hermes Premium.

9.07 End of Fiscal Years. The Parent and the Borrower will maintain their fiscal year ends as in effect on the Effective Date.

 

-65-


9.08 Performance of Obligations. The Parent will, and will cause each of its Subsidiaries to, perform all of its obligations under the terms of each mortgage, indenture, security agreement and other debt instrument (including, without limitation, the Credit Documents) by which it is bound, except such non-performances as could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

9.09 Payment of Taxes. The Parent will pay and discharge, and will cause each of its Subsidiaries to pay and discharge, all material taxes, assessments and governmental charges or levies imposed upon it or upon its income or profits, or upon any properties belonging to it, in each case on a timely basis, and all lawful claims which, if unpaid, might become a Lien not otherwise permitted under Section 10.01, provided that neither the Parent nor any of its Subsidiaries shall be required to pay any such tax, assessment, charge, levy or claim which is being contested in good faith and by proper proceedings if it has maintained adequate reserves with respect thereto in accordance with generally accepted accounting principles.

9.10 Further Assurances. (a) The Borrower will, from time to time on being required to do so by the Facility Agent or the Hermes Agent, do or procure the doing of all such acts and/or execute or procure the execution of all such documents in a form reasonably satisfactory to the Facility Agent or the Hermes Agent (as the case may be) as the Facility Agent or the Hermes Agent may reasonably consider necessary for giving full effect to any of the Credit Documents or securing to the Agents and/or the Lenders or any of them the full benefit of the rights, powers and remedies conferred upon the Agents and/or the Lenders or any of them in any such Credit Document.

(b) The Borrower hereby authorizes the Collateral Agent to file one or more financing or continuation statements under the UCC (or any non-U.S. equivalent thereto), and amendments thereto, relative to all or any part of the Collateral without the signature of the Borrower, where permitted by law. The Collateral Agent will promptly send the Borrower a copy of any financing or continuation statements which it may file without the signature of the Borrower and the filing or recordation information with respect thereto.

(c) If at any time an ECF Borrower shall enter into a Supervision Agreement pursuant to the relevant Construction Contract, such ECF Borrower shall, substantially simultaneously therewith, duly authorize, execute and deliver a valid and effective second-priority (junior only to the Liens of the secured party under the relevant Export Credit Facility and pari passu only to the Liens of the secured party under the Other Term Loan Facility) legal assignment in favor of the Collateral Agent of all of such ECF Borrower’s present and future interests in and benefits under such Supervision Agreement, which such assignment shall be in form and substance reasonably acceptable to the Facility Agent and customary for this type of transaction.

9.11 Ownership of Subsidiaries. Other than “director qualifying shares” and similar requirements, the Parent shall at all times directly or indirectly own 100% of the Capital Stock or other Equity Interests of the Borrower (except as permitted by Section 10.02).

9.12 Consents and Registrations. The Parent and the Borrower shall obtain, and for so long as such ECF Borrower is a Credit Party, the Parent shall procure that the ECF

 

-66-


Borrowers obtain (and shall, at the request of the Facility Agent, promptly furnish certified copies to the Facility Agent of) all such authorizations, approvals, consents, licenses and exemptions as may be required under any applicable law or regulation to enable it or any Credit Party to perform its obligations under, and ensure the validity or enforceability of, each of the Credit Documents are obtained and promptly renewed from time to time and will procure that the terms of the same are complied with at all times. Insofar as such filings or registrations have not been completed on or before an Initial Borrowing Date, the Borrower will procure the filing or registration within applicable time limits of each applicable Security Document which requires filing or registration together with all ancillary documents required to preserve the priority and enforceability of the Security Documents.

9.13 Flag of Collateral Vessel. (a) The Borrower shall cause the Collateral Vessel to be registered under the laws and flag of the Bahamas or, provided that the requirements of a Flag Jurisdiction Transfer are satisfied, another Acceptable Flag Jurisdiction. Notwithstanding the foregoing, the relevant Credit Party may transfer the Collateral Vessel to an Acceptable Flag Jurisdiction pursuant to the requirements set forth in the definition of “Flag Jurisdiction Transfer”.

(b) Except as permitted by Section 10.02, the Borrower will own the Collateral Vessel and will procure that the Collateral Vessel is traded within the NCLC Fleet from the first Initial Borrowing Date until the later of the Tranche A Loan Maturity Date and the Tranche B Loan Maturity Date.

(c) The Borrower will at all times engage the Manager (or a replacement manager reasonably acceptable to the Facility Agent) to provide the commercial and technical management and crewing of the Collateral Vessel.

9.14 “Know Your Customer” and Other Similar Information. The Parent will, and will cause the Credit Parties, to provide (i) the “Know Your Customer” information required pursuant to the PATRIOT Act and applicable money laundering provisions and (ii) such other documentation and evidence necessary in order for the Lenders to carry out and be reasonably satisfied with other similar checks under all applicable laws and regulations pursuant to the Transaction and the Hermes Cover, in each case as requested by the Facility Agent, the Hermes Agent or any Lender in connection with each of the Facility Agent’s, the Hermes Agent’s and each Lender’s internal compliance regulations.

SECTION 10. Negative Covenants. The Parent and the Borrower hereby covenant and agree that on and after the first Initial Borrowing Date and until all Commitments have terminated and the Loans, together with interest, Commitment Commission and all other Credit Document Obligations incurred hereunder and thereunder, are paid in full (other than contingent indemnification and expense reimbursement claims for which no claim has been made):

10.01 Liens. The Parent will not, and will not permit any of its Subsidiaries to, create, incur, assume or suffer to exist any Lien upon or with respect to any Collateral, whether now owned or hereafter acquired, or sell any such Collateral subject to an understanding or agreement, contingent or otherwise, to repurchase such Collateral (including sales of accounts

 

-67-


receivable with recourse to the Parent or any of its Subsidiaries); provided that the provisions of this Section 10.01 shall not prevent the creation, incurrence, assumption or existence of the following (Liens described below are herein referred to as “Permitted Liens”):

(i) inchoate Liens for taxes, assessments or governmental charges or levies not yet due and payable or Liens for taxes, assessments or governmental charges or levies being contested in good faith and by appropriate proceedings for which adequate reserves have been established in accordance with generally accepted accounting principles;

(ii) Liens imposed by law, which were incurred in the ordinary course of business and do not secure Indebtedness for Borrowed Money, such as carriers’, warehousemen’s, materialmen’s and mechanics’ liens and other similar Liens arising in the ordinary course of business, and (x) which do not in the aggregate materially detract from the value of the Collateral and do not materially impair the use thereof in the operation of the business of the Parent or such Subsidiary or (y) which are being contested in good faith by appropriate proceedings, which proceedings (or orders entered in connection with such proceedings) have the effect of preventing the forfeiture or sale of the Collateral subject to any such Lien;

(iii) Liens in existence on the Effective Date which are listed, and the property subject thereto described, in Schedule 10.01, without giving effect to any renewals or extensions of such Liens, provided that the aggregate principal amount of the Indebtedness, if any, secured by such Liens does not increase from that amount outstanding on the Effective Date, less any repayments of principal thereof;

(iv) Liens created pursuant to the Security Documents including, without limitation, Liens created in relation to any Interest Rate Protection Agreement or Other Hedging Agreement;

(v) Liens arising out of judgments, awards, decrees or attachments with respect to which the Parent or any of its Subsidiaries shall in good faith be prosecuting an appeal or proceedings for review, provided that the aggregate amount of all such judgments, awards, decrees or attachments shall not constitute an Event of Default under Section 11.09;

(vi) Liens in respect of seamen’s wages which are not past due and other maritime Liens arising in the ordinary course of business up to an aggregate amount of [*];

(vii) Liens on the ECF Collateral securing the obligations under the Export Credit Facilities and the Other Term Loan Facility and any interest rate protection agreement or other hedging agreement in connection therewith, provided that such Liens are subject to the provisions of the ECF Intecreditor Agreements;

(viii) Liens on the Jade Collateral securing the obligations under the Senior Loan Agreements and any interest rate protection agreement or other hedging agreement in connection therewith, provided that such Liens are subject to the provisions of the Jade Intercreditor Agreement; and

 

-68-


(ix) Liens which rank after the Liens created by the Security Documents to secure the performance of bids, tenders, bonds or contracts; provided that (a) such bids, tenders, bonds or contracts directly relate to the Collateral Vessel, are incurred in the ordinary course of business and do not relate to the incurrence of Indebtedness for Borrowed Money, and (b) at any time outstanding, the aggregate amount of Liens under this clause (ix) shall not secure greater than [*] of obligations.

In connection with the granting of Liens described above in this Section 10.01 by the Parent or any of its Subsidiaries, the Facility Agent and the Collateral Agent shall be authorized to take any actions deemed appropriate by it in connection therewith (including, without limitation, by executing appropriate lien subordination agreements in favor of the holder or holders of such Liens, in respect of the item or items of equipment or other assets subject to such Liens).

10.02 Consolidation, Merger, Amalgamation, Sale of Assets, Acquisitions, etc. (a) The Parent will not, and will not permit any of its Subsidiaries to, wind up, liquidate or dissolve its affairs or enter into any transaction of merger, amalgamation or consolidation, or convey, sell, lease or otherwise dispose of all or substantially all of its property or assets, or make any Acquisitions, except that:

(i) any Subsidiary of the Parent (other than the Borrower) may merge, amalgamate or consolidate with and into, or be dissolved or liquidated into, the Parent or other Subsidiary of the Parent (other than the Borrower), so long as (x) in the case of any such merger, amalgamation, consolidation, dissolution or liquidation involving the Parent, the Parent is the surviving or continuing entity of any such merger, amalgamation, consolidation, dissolution or liquidation and (y) any security interests granted to the Collateral Agent for the benefit of the Secured Creditors pursuant to the Security Documents in the assets of such Subsidiary shall remain in full force and effect and perfected (to at least the same extent as in effect immediately prior to such merger, amalgamation, consolidation, dissolution or liquidation) and all actions required to maintain said perfected status have been taken;

(ii) the Parent and any Subsidiary of the Parent may make dispositions of assets so long as such disposition is permitted pursuant to Section 10.02(b);

(iii) the Parent and any Subsidiary of the Parent (other than the Borrower) may make Acquisitions; provided that (x) the Parent provides evidence reasonably satisfactory to the Required Lenders that the Parent will be in compliance with the financial undertakings contained in Sections 10.06 to 10.09 after giving effect to such Acquisition on a pro forma basis and (y) no Default or Event of Default will exist after giving effect to such Acquisition; and

(iv) the Parent and any Subsidiary of the Parent (other than the Borrower) may establish new Subsidiaries.

 

-69-


(b) The Parent will not, and will not permit any other company in the NCLC Group to, either in a single transaction or in a series of transactions whether related or not and whether voluntarily or involuntarily, sell, transfer, lease or otherwise dispose of all or a substantial part of its assets except that the following disposals shall not be taken into account:

(i) dispositions made in the ordinary course of trading of the disposing entity (excluding a disposition of the Collateral Vessel or other Collateral) including without limitation, the payment of cash as consideration for the purchase or acquisition of any asset or service or in the discharge of any obligation incurred for value in the ordinary course of trading;

(ii) dispositions of cash raised or borrowed for the purposes for which such cash was raised or borrowed;

(iii) dispositions of assets (other than the Collateral Vessel or other Collateral) owned by any member of the NCLC Group in exchange for other assets comparable or superior as to type and value;

(iv) a vessel (other than the Collateral Vessel or other Collateral) or any other asset owned by any member of the NCLC Group (other than the Borrower) may be sold, provided such sale is on a willing seller willing buyer basis at or about market rate and at arm’s length subject always to the provisions of any loan documentation for the financing of such vessel or other asset;

(v) the Credit Parties may sell, lease or otherwise dispose of the Collateral Vessel or sell 100% of the Capital Stock of the Borrower, provided that such sale is made at fair market value, the Total Allocable Commitment is permanently reduced to $0, and the Loans are repaid in full; and

(vi) Permitted Chartering Arrangements.

10.03 Dividends. The Parent will not, and will not permit any of its Subsidiaries to, authorize, declare or pay any Dividends with respect to the Parent or any of its Subsidiaries, except that:

(i) Subsidiaries of the Parent may pay Dividends to another member of the NCLC Group; provided that the Borrower shall procure that any Dividends or other distributions and interest paid or payable in connection with such Dividends or other distributions to NCL International, Ltd., NCL America Holdings, LLC or Arrasas Limited shall be received promptly by the Parent directly or indirectly by way of Dividend;

(ii) the Parent may pay Dividends in respect of the tax liability to each relevant jurisdiction in respect of consolidated, combined, unitary or affiliated tax returns for each relevant jurisdiction of the NCLC Group or holder of the Parent’s Capital Stock with respect to income taxable as a result of any member of the NCLC Group being taxed as a pass-through entity for U.S. Federal, state and local income tax purposes or attributable to any member of the NCLC Group; and

 

-70-


(iii) at any time following the listing of the ordinary Capital Stock of the Parent on an Approved Stock Exchange, the Parent may pay Dividends in an amount not to exceed 50% of Consolidated Net Income of the Parent and its Subsidiaries for the period (taken as one period) commencing on January 1, 2010 and ending on the date prior to such Dividend for which financial statements are available so long as (x) no Default or Event or Default exists or would result from such Dividend and (y) at the time of such Dividend and after giving effect thereto the ratio of Total Net Funded Debt to Consolidated EBITDA for the four consecutive fiscal quarters last ended for which financial statements have been provided to the Facility Agent pursuant to Section 9.01 is less than [*].

10.04 Advances, Investments and Loans. The Parent will not, and will not permit any other member of the NCLC Group to, purchase or acquire any margin stock (or other Equity Interests) or any other asset, or make any capital contribution to or other investment in any other Person (each of the foregoing an “Investment” and, collectively, “Investments”), in each case either in a single transaction or in a series of transactions (whether related or not), except that the following shall be permitted:

(i) Investments on arm’s length terms;

(ii) Investments for its use in its ordinary course of business;

(iii) Investments the cost of which is less than or equal to its fair market value at the date of acquisition; and

(iv) Investments permitted by Section 10.02.

10.05 Transactions with Affiliates. (a) The Parent will not, and will not permit any of its Subsidiaries to, directly or indirectly, make any payment to, or sell, lease, transfer or otherwise dispose of any of its properties or assets to, or purchase any property or assets from, or enter into or make or amend any transaction or series of transactions, contract, agreement, understanding, loan, advance or guarantee with, or for the benefit of, any Affiliate of such Person (each of the foregoing, an “Affiliate Transaction”) involving aggregate consideration in excess of [*] unless such Affiliate Transaction is on terms that are not materially less favorable to the Parent or any Subsidiary of the Parent than those that could have been obtained in a comparable transaction by such Person with an unrelated Person.

(b) The provisions of Section 10.05(a) shall not apply to the following:

(i) transactions between or among the Parent and/or any Subsidiary of the Parent (or an entity that becomes a Subsidiary of the Parent as a result of such transaction) and any merger, consolidation or amalgamation of the Parent or any Subsidiary of the Parent and any direct parent of the Parent, any Subsidiary of the Parent or, in the case of a Subsidiary of the Parent, the Parent; provided that such parent shall have no material liabilities and no material assets other than cash, Cash Equivalents and the Capital Stock of the Parent or such Subsidiary of the Parent, as the case may be, and such merger, consolidation or amalgamation is otherwise in compliance with the terms of this Agreement and effected for a bona fide business purpose;

 

-71-


(ii) Dividends permitted by Section 10.03 and Investments permitted by Section 10.04;

(iii) the payment of reasonable and customary fees and reimbursement of expenses paid to, and indemnity provided on behalf of, officers, directors, employees or consultants of the Parent or any Subsidiary of the Parent, any direct or indirect parent of the Parent;

(iv) payments by the Parent or any Subsidiary of the Parent to a Permitted Holder made for any financial advisory, financing, underwriting or placement services or in respect of other investment banking activities, including, without limitation, in connection with acquisitions or divestitures, which payments are approved by a majority of the board of directors of the Parent in good faith;

(v) any agreement to pay, and the payment of, monitoring, management, transaction, advisory or similar fees (A) in an aggregate amount in any fiscal year not to exceed the sum of (1) the greater of (i) [*] of Consolidated EBITDA of the Parent and (ii) [*] plus reasonable out of pocket costs and expenses in connection therewith and unpaid amounts accrued for prior periods; plus (2) any deferred fees (to the extent such fees were within such amount in clause (A)(1) above originally), plus (B) [*] of the value of transactions with respect to which an Affiliate provides any transaction, advisory or other services, plus (C) so long as no Event of Default has occurred and is continuing, in the event of an initial public offering, the present value of all future amounts payable pursuant to any agreement referred to in clause (A)(1) above in connection with the termination of such agreement with a Permitted Holder; provided that if any such payment pursuant to clause (C) is not permitted to be paid as a result of an Event of Default, such payment shall accrue and may be payable when no Event of Default is continuing to the extent that no further Event of Default would result therefrom;

(vi) transactions in which the Parent or any Subsidiary of the Parent, as the case may be, delivers to the Facility Agent a letter from an independent financial advisor stating that such transaction is fair to the Parent or any Subsidiary of the Parent, as the case may be, from a financial point of view or meets the requirements of Section 10.05(a);

(vii) payments or loans (or cancellation of loans) to officers, directors, employees or consultants which are approved by a majority of the board of directors of the Parent in good faith;

(viii) any agreement as in effect as of the Effective Date or any amendment thereto (so long as any such agreement together with all amendments thereto, taken as a whole, is not more disadvantageous to the Lenders in any material respect than the original agreement as in effect on the Effective Date) or any transaction contemplated thereby as determined in good faith by the Parent;

(ix) (A) transactions with customers, clients, suppliers or purchasers or sellers of goods or services, or transactions otherwise relating to the purchase or sale of goods or

 

-72-


services, in each case in the ordinary course of business and otherwise in compliance with the terms of this Agreement, which are fair to the Parent and its Subsidiaries in the reasonable determination of the Board of Directors or the senior management of the Parent, or are on terms at least as favorable as might reasonably have been obtained at such time from an unaffiliated party or (B) transactions with joint ventures or Subsidiaries of the Parent entered into in the ordinary course of business and consistent with past practice or industry norm;

(x) the issuance of Equity Interests (other than Disqualified Stock) of the Parent to any Person;

(xi) the issuances of securities or other payments, awards or grants in cash, securities or otherwise pursuant to, or the funding of, employment arrangements, stock option and stock ownership plans or similar employee benefit plans approved by the Board of Directors of the Parent or any direct or indirect parent of the Issuer or of a Subsidiary of the Parent, as appropriate, in good faith;

(xii) any contribution to the capital of the Parent;

(xiii) transactions between the Parent or any Subsidiary of the Parent and any Person, a director of which is also a director of the Parent or any Subsidiary of the Parent or any direct or indirect parent of the Parent; provided, however, that such director abstains from voting as a director of the Parent or any Subsidiary of the Parent or such direct or indirect parent, as the case may be, on any matter involving such other Person;

(xiv) pledges of Equity Interests of Subsidiaries of the Parent (other than the Borrower);

(xv) the formation and maintenance of any consolidated group or subgroup for tax, accounting or cash pooling or management purposes in the ordinary course of business;

(xvi) any employment agreements entered into by the Parent or any Subsidiary of the Parent in the ordinary course of business; and

(xvii) transactions undertaken in good faith (as certified by a responsible financial or accounting officer of the Parent in an officer’s certificate) for the purpose of improving the consolidated tax efficiency of the Parent and its Subsidiaries and not for the purpose of circumventing any provision set forth in this Agreement.

10.06 Free Liquidity. The Parent will not permit the Free Liquidity to be less than [*] at any time.

10.07 Total Net Funded Debt to Total Capitalization. The Parent will not permit the ratio of Total Net Funded Debt to Total Capitalization to be greater than [*] at any time.

10.08 Collateral Maintenance. The Borrower will not permit the Appraised Value of the Collateral Vessel (such value, the “Vessel Value”) to be less than [*] of the sum of

 

-73-


(x) the aggregate outstanding principal amount of Loans at such time and (y) the aggregate outstanding principal amount of loans under the Existing Jade Facility at such time; provided that, so long as any non-compliance in respect of this Section 10.08 is not caused by a voluntary Collateral Disposition, such non-compliance shall not constitute a Default or an Event of Default so long as within 10 Business Days of the occurrence of such default, the Borrower shall either (i) post additional collateral reasonably satisfactory to the Required Lenders in favor of the Collateral Agent (it being understood that cash collateral comprised of Dollars is satisfactory and that it shall be valued at par), pursuant to security documentation reasonably satisfactory in form and substance to the Collateral Agent and the Joint Lead Arrangers, in an aggregate amount sufficient to cure such non-compliance (and shall at all times during such period and prior to satisfactory completion thereof, be diligently carrying out such actions) or (ii) repay Loans in an amount sufficient to cure such non-compliance; provided, further, that, subject to the last sentence in Section 9.01(c), the covenant in this Section 10.08 shall be tested no more than once per calendar year beginning with 2011 in the absence of the occurrence of an Event of Default which is continuing.

10.09 Consolidated EBITDA to Consolidated Debt Service. The Parent will not permit the ratio of Consolidated EBITDA to Consolidated Debt Service for the NCLC Group at the end of any fiscal quarter, computed for the period of the four consecutive fiscal quarters ending as at the end of the relevant fiscal quarter, to be less than [*] unless the Free Liquidity of the NCLC Group at all times during such period of four consecutive fiscal quarters ending as at the end of such fiscal quarter was equal to or greater than [*].

10.10 Business; Change of Name. The Parent will not, and will not permit any of its Subsidiaries to, change its name, change its address as indicated on Schedule 14.03A to an address outside the State of Florida, or make or threaten to make any substantial change in its business as presently conducted or cease to perform its current business activities or carry on any other business which is substantial in relation to its business as presently conducted if doing so would imperil the security created by any of the Security Documents or affect the ability of the Parent or its Subsidiaries to duly perform its obligations under any Credit Document to which it is or may be a party from time to time (it being understood that name changes and changes of address to an address outside the State of Florida shall be permitted so long as new, relevant Security Documents are executed and delivered (and if necessary, recorded) in a form reasonably satisfactory to the Collateral Agent), in each case in the reasonable opinion of the Facility Agent; provided that any new leisure or hospitality venture embarked upon by any member of the NCLC Group (other than the Parent) shall not constitute a substantial change in its business.

10.11 Subordination of Indebtedness. The Parent shall procure that any and all of its Indebtedness with any other Credit Party and/or any shareholder of the Parent is at all times fully subordinated to the Credit Document Obligations. The Parent shall not make or permit to be made any repayments of principal, payments of interest or of any other costs, fees, expenses or liabilities arising from or representing Indebtedness with any shareholder of the Parent. Upon the occurrence of an Event of Default, the Parent shall not make any repayments of principal, payments of interest or of any other costs, fees, expenses or liabilities arising from or representing Indebtedness with any other Credit Party.

 

-74-


10.12 Activities of Borrower, etc. The Parent will not permit the Borrower to, and the Borrower will not:

(i) issue or enter into any guarantee or indemnity or otherwise become directly or contingently liable for the obligations of any other Person, other than (x) in the ordinary course of its business as owner of the Collateral Vessel and (y) in respect of the Senior Loan Agreements;

(ii) incur any Indebtedness other than (x) under the Credit Documents and the Senior Loan Agreements, and (y) in the ordinary course of its business as owner of the Collateral Vessel; and

(iii) engage in any business or own any significant assets or have any material liabilities other than (i) its ownership of the Collateral Vessel and (ii) those liabilities which it is responsible for under this Agreement and the other Credit Documents to which it is a party and the Senior Loan Agreements to which it is a party, provided that the Borrower may also engage in those activities that are incidental to (x) the maintenance of its existence in compliance with applicable law and (y) legal, tax and accounting matters in connection with any of the foregoing activities.

10.13 Material Amendments or Modifications of Construction Contracts. The Parent will not, and will not permit any of its Subsidiaries to, make any material amendments, modifications or changes to any term or provision of either Construction Contract that would amend, modify or change (i) the purpose of the relevant New Vessel or (ii) the Initial Construction Price under such Construction Contract in excess of [*] in the aggregate, in each case unless such amendment, modification or change is approved in advance by the Facility Agent and the Hermes Agent, and the same could not reasonably be expected to be adverse to the interests of the Lenders or the Hermes Cover.

10.14 No Place of Business. None of the Credit Parties shall establish a place of business in the United Kingdom or the United States of America, with the exception of those places of business already in existence on the Effective Date, unless prompt notice thereof is given to the Facility Agent and the requirements set forth in Section 9.10 have been satisfied.

SECTION 11. Events of Default. Upon the occurrence of any of the following specified events (each an “Event of Default”):

11.01 Payments. The Borrower or any other Credit Party does not pay on the due date any amount of principal or interest on any Loan (provided, however, that if any such amount is not paid when due solely by reason of some error or omission on the part of the bank or banks through whom the relevant funds are being transmitted no Event of Default shall occur for the purposes of this Section 11.01 until the expiry of three Business Days following the date on which such payment is due) or, within three days of the due date any other amount, payable by it under any Credit Document to which it may at any time be a party, at the place and in the currency in which it is expressed to be payable; or

11.02 Representations, etc. Any representation, warranty or statement made or repeated in, or in connection with, any Credit Document or in any accounts, certificate, statement

 

-75-


or opinion delivered by or on behalf of any Credit Party thereunder or in connection therewith is materially incorrect when made or would, if repeated at any time hereafter by reference to the facts subsisting at such time, no longer be materially correct; or

11.03 Covenants. Any Credit Party shall (i) default in the due performance or observance by it of any term, covenant or agreement contained in Section 9.01(h), Section 9.06, Section 9.11 or Section 10 or (ii) default in the due performance or observance by it of any other term, covenant or agreement contained in this Agreement or any other Credit Document and, in the case of this clause (ii), such default shall continue unremedied for a period of 30 days after written notice to the Borrower by the Facility Agent or any of the Lenders; or

11.04 Default Under Other Agreements. (a) Any event of default occurs under any financial contract or financial document relating to any Indebtedness of any member of the NCLC Group;

(b) Any such Indebtedness or any sum payable in respect thereof is not paid when due (after the expiry of any applicable grace period(s)) whether by acceleration or otherwise;

(c) Any Lien over any assets of any member of the NCLC Group becomes enforceable; or

(d) Any other Indebtedness of any member of the NCLC Group is not paid when due or is or becomes capable of being declared due prematurely by reason of default or any security for the same becomes enforceable by reason of default,

provided that:

(i) it shall not be a Default or Event of Default under this Section 11.04 unless the principal amount of the relevant Indebtedness as described in preceding clauses (a) through (d), inclusive, exceeds $15,000,000;

(ii) no Event of Default will arise under clauses (a), (c) and/or (d) until the earlier of (x) 30 days following the occurrence of the related event of default, Lien becoming enforceable or Indebtedness becoming capable of being declared due prematurely, as the case may be, and (y) the acceleration of the relevant Indebtedness or the enforcement of the relevant Lien; and

(iii) if at any time hereafter the Parent or any other member of the NCLC Group agrees to the incorporation of a cross default provision into any financial contract or financial document relating to any Indebtedness that is more onerous than this Section 11.04, then the Parent shall immediately notify the Facility Agent and that cross default provision shall be deemed to apply to this Agreement as if set out in full herein with effect from the date of such financial contract or financial document and during the term of that financial contract or financial document; or

11.05 Bankruptcy, etc. (a) Other than as expressly permitted in Section 10, any order is made or an effective resolution passed or other action taken for the suspension of payments or dissolution, termination of existence, liquidation, winding-up or bankruptcy of any member of the NCLC Group; or

 

-76-


(b) Any member of the NCLC Group shall commence a voluntary case concerning itself under Title 11 of the United States Code entitled “Bankruptcy,” as now or hereafter in effect, or any successor thereto (the “Bankruptcy Code”); or an involuntary case is commenced against any member of the NCLC Group, and the petition is not dismissed within 45 days after the filing thereof, provided, however, that during the pendency of such period, each Lender shall be relieved of its obligation to extend credit hereunder; or a custodian (as defined in the Bankruptcy Code) is appointed for, or takes charge of, all or substantially all of the property of any member of the NCLC Group, to operate all or any substantial portion of the business of any member of the NCLC Group, or any member of the NCLC Group commences any other proceeding under any reorganization, arrangement, adjustment of debt, relief of debtors, dissolution, insolvency or liquidation or similar law of any jurisdiction whether now or hereafter in effect relating to any member of the NCLC Group, or there is commenced against any member of the NCLC Group any such proceeding which remains undismissed for a period of 45 days after the filing thereof, or any member of the NCLC Group is adjudicated insolvent or bankrupt; or any order of relief or other order approving any such case or proceeding is entered; or any member of the NCLC Group makes a general assignment for the benefit of creditors; or any Company action is taken by any member of the NCLC Group for the purpose of effecting any of the foregoing; or

(c) A liquidator (subject to Section 11.05(e)), trustee, administrator, receiver, manager or similar officer is appointed in respect of any member of the NCLC Group or in respect of all or any substantial part of the assets of any member of the NCLC Group and in any such case such appointment is not withdrawn within 30 days (in this Section 11.05, the “Grace Period”) unless the Facility Agent considers in its sole discretion that the interest of the Lenders and/or the Agents might reasonably be expected to be adversely affected in which event the Grace Period shall not apply; or

(d) Any member of the NCLC Group becomes or is declared insolvent or is unable, or admits in writing its inability, to pay its debts as they fall due or becomes insolvent within the terms of any applicable law; or

(e) Anything analogous to or having a substantially similar effect to any of the events specified in this Section 11.05 shall have occurred under the laws of any applicable jurisdiction (subject to the analogous grace periods set forth herein); or

11.06 Total Loss. An Event of Loss shall occur resulting in the actual or constructive total loss of the Collateral Vessel or the agreed or compromised total loss of the Collateral Vessel and the proceeds of the insurance in respect thereof shall not have been received within 150 days of the event giving rise to such Event of Loss; or

11.07 Security Documents. At any time after the execution and delivery thereof, any of the Security Documents shall cease to be in full force and effect, or shall cease to give the Collateral Agent for the benefit of the Secured Creditors the Liens, rights, powers and privileges purported to be created thereby (including, without limitation, a perfected security interest in,

 

-77-


and Lien on, all of the material Collateral), in favor of the Collateral Agent, superior to and prior to the rights of all third Persons (except in connection with Permitted Liens), and subject to no other Liens (except Permitted Liens), or any “event of default” (as defined in the Vessel Mortgage) shall occur in respect of the Vessel Mortgage; or

11.08 Guaranties. (a) The Parent Guaranty, or any provision thereof, shall cease to be in full force or effect as to the Parent, or the Parent (or any Person acting by or on behalf of the Parent) shall deny or disaffirm the Parent’s obligations under the Parent Guaranty; or

(b) After the execution and delivery thereof, the Hermes Cover, or any material provision thereof, shall cease to be in full force or effect, or Hermes (or any Person acting by or on behalf of the Parent or the Hermes Agent) shall deny or disaffirm Hermes’ obligations under the Hermes Cover; or

11.09 Judgments. Any distress, execution, attachment or other process affects the whole or any substantial part of the assets of any member of the NCLC Group and remains undischarged for a period of 21 days or any uninsured judgment in excess of $15,000,000 following final appeal remains unsatisfied for a period of 30 days in the case of a judgment made in the United States and otherwise for a period of 60 days; or

11.10 Cessation of Business. Subject to Section 10.02, any member of the NCLC Group shall cease to carry on all or a substantial part of its business; or

11.11 Revocation of Consents. Any authorization, approval, consent, license, exemption, filing, registration or notarization or other requirement necessary to enable any Credit Party to comply with any of its obligations under any of the Credit Documents to which it is a party shall have been materially adversely modified, revoked or withheld or shall not remain in full force and effect and within 90 days of the date of its occurrence such event is not remedied to the satisfaction of the Required Lenders and the Required Lenders consider in their sole discretion that such failure is or might be expected to become materially prejudicial to the interests, rights or position of the Agents and the Lenders or any of them; provided that the Borrower shall not be entitled to the aforesaid 90 day period if the modification, revocation or withholding of the authorization, approval or consent is due to an act or omission of any Credit Party and the Required Lenders are satisfied in their sole discretion that the interests of the Agents or the Lenders might reasonably be expected to be materially adversely affected; or

11.12 Unlawfulness. At any time it is unlawful or impossible for:

(i) any Credit Party to perform any of its obligations under any Credit Document to which it is a party; or

(ii) the Agents or the Lenders, as applicable, to exercise any of their rights under any of the Credit Documents;

provided that no Event of Default shall be deemed to have occurred (x) (except where the unlawfulness or impossibility adversely affects any Credit Party’s payment obligations under this Agreement and/or the other Credit Documents (the determination of which shall be in the Facility Agent’s sole discretion) in which case the following provisions of this Section 11.12

 

-78-


shall not apply) where the unlawfulness or impossibility prevents any Credit Party from performing its obligations (other than its payment obligations under this Agreement and the other Credit Documents) and is cured within a period of 21 days of the occurrence of the event giving rise to the unlawfulness or impossibility and the relevant Credit Party, within the aforesaid period, performs its obligation(s), and (y) where the Facility Agent and/or the Lenders, as applicable, could, in its or their sole discretion, mitigate the consequences of unlawfulness or impossibility in the manner described in Section 2.10(a) (it being understood that the costs of mitigation shall be determined in accordance with Section 2.10(a)); or

11.13 Insurances. Borrower shall have failed to insure the Collateral Vessel in the manner specified in this Agreement or failed to renew the Required Insurance at least 10 Business Days prior to the date of expiry thereof and, if requested by the Facility Agent, produce prompt confirmation of such renewal to the Facility Agent; or

11.14 Disposals. The Borrower or any other member of the NCLC Group shall have concealed, removed, or permitted to be concealed or removed, any part of its property, with intent to hinder, delay or defraud its creditors or any of them, or made or suffered a transfer of any of its property which may be fraudulent under any bankruptcy, fraudulent conveyance or similar law; or shall have made any transfer of its property to or for the benefit of a creditor with the intention of preferring such creditor over any other creditor; or

11.15 Government Intervention. The authority of any member of the NCLC Group in the conduct of its business shall be wholly or substantially curtailed by any seizure or intervention by or on behalf of any authority and within 90 days of the date of its occurrence any such seizure or intervention is not relinquished or withdrawn and the Facility Agent reasonably considers that the relevant occurrence is or might be expected to become materially prejudicial to the interests, rights or position of the Agents and/or the Lenders; provided that the Borrower shall not be entitled to the aforesaid 90 day period if the seizure or intervention executed by any authority is due to an act or omission of any member of the NCLC Group and the Facility Agent is satisfied, in its sole discretion, that the interests of the Agents and/or the Lenders might reasonably be expected to be materially adversely affected; or

11.16 Change of Control. A Change of Control shall occur; or

11.17 Material Adverse Change. Any event shall occur which results in a Material Adverse Effect; or

11.18 Repudiation of Construction Contract or other Material Documents. Any party to the Construction Contract, any Credit Document or any other material documents related to the Credit Document Obligations hereunder shall repudiate the Construction Contract, such Credit Document or such material document in any way;

then, and in any such event, and at any time thereafter, if any Event of Default shall then be continuing, the Facility Agent, upon the written request of the Required Lenders and after having informed the Hermes Agent of such written request, shall by written notice to the Borrower, take any or all of the following actions, without prejudice to the rights of any Agent or, any Lender to enforce its claims against any Credit Party (provided that, if an Event of

 

-79-


Default specified in Section 11.05 shall occur, the result which would occur upon the giving of written notice by the Facility Agent to the Borrower as specified in clauses (i) and (ii) below shall occur automatically without the giving of any such notice): (i) declare the Total Commitment terminated, whereupon all Commitments of each Lender shall forthwith terminate immediately and any Commitment Commission shall forthwith become due and payable without any other notice of any kind; (ii) declare the principal of and any accrued interest in respect of all Loans and all Credit Document Obligations owing hereunder and thereunder to be, whereupon the same shall become, forthwith due and payable without presentment, demand, protest or other notice of any kind, all of which are hereby waived by each Credit Party; and (iii) enforce, as Collateral Agent, all of the Liens and security interests created pursuant to the Security Documents.

SECTION 12. Agency and Security Trustee Provisions.

12.01 Appointment and Declaration of Trust. (a) The Lenders hereby designate KfW IPEX-Bank GmbH, as Facility Agent (for purposes of this Section 12, the term “Facility Agent” shall include KfW IPEX-Bank GmbH (and/or any of its Affiliates) in its capacity as Collateral Agent under the Security Documents) to act as specified herein and in the other Credit Documents. The Lenders hereby further designate Nordea Bank Norge ASA, as Documentation Agent, to act as specified herein and in the other Credit Documents. Each Lender hereby irrevocably authorizes the Agents to take such action on its behalf under the provisions of this Agreement, the other Credit Documents and any other instruments and agreements referred to herein or therein and to exercise such powers and to perform such duties hereunder and thereunder as are specifically delegated to or required of the Agents by the terms hereof and thereof and such other powers as are reasonably incidental thereto. Each Agent may perform any of its duties hereunder by or through its respective officers, directors, agents, employees or affiliates and, may transfer from time to time any or all of its rights, duties and obligations hereunder and under the relevant Credit Documents (in accordance with the terms thereof) to any of its banking affiliates.

(b) KfW IPEX-Bank GmbH in its capacity as Collateral Agent pursuant to the Security Documents declares that it shall hold the Collateral in trust for the Secured Creditors in accordance with the terms contained in each Intercreditor Agreement, as applicable. The Collateral Agent shall have the right to delegate a co-agent or sub-agent from time to time to perform and benefit from any or all rights, duties and obligations hereunder and under the relevant Security Documents (in accordance with the terms thereof and the Security Trust Deed) and, in the event that any such duties or obligations are so delegated, the Collateral Agent is hereby authorized to enter into additional Security Documents or amendments to the then existing Security Documents to the extent it deems necessary or advisable to implement such delegation and, in connection therewith, the Parent will, or will cause the relevant Subsidiary to, use its commercially reasonable efforts to promptly deliver any opinion of counsel that the Facility Agent may reasonably require to the reasonable satisfaction of the Facility Agent.

(c) The Lenders hereby designate Commerzbank Aktiengesellschaft, as Hermes Agent, which Agent shall be responsible for any and all communication, information and negotiation required with Hermes in relation to the Hermes Cover. All notices and other communications provided to the Hermes Agent shall be mailed, telexed, telecopied, delivered or electronic mailed to the Notice Office of the Hermes Agent.

 

-80-


12.02 Nature of Duties. The Agents shall have no duties or responsibilities except those expressly set forth in this Agreement and the Security Documents. None of the Agents nor any of their respective officers, directors, agents, employees or affiliates shall be liable for any action taken or omitted by it or them hereunder, under any other Credit Document, under the Hermes Cover or in connection herewith or therewith, unless caused by such Person’s gross negligence or willful misconduct (any such liability limited to the applicable Agent to whom such Person relates). The duties of each of the Agents shall be mechanical and administrative in nature; none of the Agents shall have by reason of this Agreement or any other Credit Document any fiduciary relationship in respect of any Lender; and nothing in this Agreement or any other Credit Document, expressed or implied, is intended to or shall be so construed as to impose upon any Agents any obligations in respect of this Agreement, any other Credit Document or the Hermes Cover except as expressly set forth herein or therein.

12.03 Lack of Reliance on the Agents. Independently and without reliance upon the Agents, each Lender, to the extent it deems appropriate, has made and shall continue to make (i) its own independent investigation of the financial condition and affairs of the Credit Parties in connection with the making and the continuance of the Loans and the taking or not taking of any action in connection herewith, (ii) its own appraisal of the creditworthiness of the Credit Parties and (iii) its own appraisal of the Hermes Cover and, except as expressly provided in this Agreement, none of the Agents shall have any duty or responsibility, either initially or on a continuing basis, to provide any Lender with any credit or other information with respect thereto, whether coming into its possession before the making of the Loans or at any time or times thereafter. None of the Agents shall be responsible to any Lender for any recitals, statements, information, representations or warranties herein or in any document, certificate or other writing delivered in connection herewith or for the execution, effectiveness, genuineness, validity, enforceability, perfection, collectibility, priority or sufficiency of this Agreement, any other Credit Document, the Hermes Cover or the financial condition of the Credit Parties or any of them or be required to make any inquiry concerning either the performance or observance of any of the terms, provisions or conditions of this Agreement, any other Credit Document, the Hermes Cover, or the financial condition of the Credit Parties or any of them or the existence or possible existence of any Default or Event of Default.

12.04 Certain Rights of the Agents. If any of the Agents shall request instructions from the Required Lenders with respect to any act or action (including failure to act) in connection with this Agreement, any other Credit Document or the Hermes Cover, the Agents shall be entitled to refrain from such act or taking such action unless and until the Agents shall have received instructions from the Required Lenders; and the Agents shall not incur liability to any Person by reason of so refraining. Without limiting the foregoing, no Lender shall have any right of action whatsoever against the Agents as a result of any of the Agents acting or refraining from acting hereunder or under any other Credit Document in accordance with the instructions of the Required Lenders.

12.05 Reliance. Each of the Agents shall be entitled to rely, and shall be fully protected in relying, upon any note, writing, resolution, notice, statement, certificate, telex,

 

-81-


teletype or telecopier message, cablegram, radiogram, order or other document or telephone message signed, sent or made by any Person that the applicable Agent believed to be the proper Person, and, with respect to all legal matters pertaining to this Agreement, any other Credit Document, the Hermes Cover and its duties hereunder and thereunder, upon advice of counsel selected by the Facility Agent.

12.06 Indemnification. To the extent any of the Agents is not reimbursed and indemnified by the Borrower, the Lenders will reimburse and indemnify the applicable Agents, in proportion to their respective “percentages” as used in determining the Required Lenders (without regard to the existence of any Defaulting Lenders), for and against any and all liabilities, obligations, losses, damages, penalties, claims, actions, judgments, costs, expenses or disbursements of whatsoever kind or nature which may be imposed on, asserted against or incurred by such Agents in performing their respective duties hereunder or under any other Credit Document, in any way relating to or arising out of this Agreement or any other Credit Document; provided that no Lender shall be liable to an Agent for any portion of such liabilities, obligations, losses, damages, penalties, actions, judgments, suits, costs, expenses or disbursements resulting from such Agent’s gross negligence or willful misconduct.

12.07 The Agents in their Individual Capacities. With respect to its obligation to make Loans under this Agreement, each of the Agents shall have the rights and powers specified herein for a “Lender” and may exercise the same rights and powers as though it were not performing the duties specified herein; and the term “Lenders,” “Secured Creditors”, “Required Lenders” or any similar terms shall, unless the context clearly otherwise indicates, include each of the Agents in their respective individual capacity. Each of the Agents may accept deposits from, lend money to, and generally engage in any kind of banking, trust or other business with any Credit Party or any Affiliate of any Credit Party as if it were not performing the duties specified herein, and may accept fees and other consideration from the Borrower or any other Credit Party for services in connection with this Agreement and otherwise without having to account for the same to the Lenders.

12.08 Resignation by an Agent. (a) Any Agent may resign from the performance of all its functions and duties hereunder and/or under the other Credit Documents at any time by giving 15 Business Days’ prior written notice to the Borrower and the Lenders. Such resignation shall take effect upon the appointment of a successor Agent pursuant to clauses (b) and (c) below or as otherwise provided below.

(b) Upon notice of resignation by an Agent pursuant to clause (a) above, the Required Lenders shall appoint a successor Agent hereunder or thereunder who shall be a commercial bank or trust company reasonably acceptable to the Borrower; provided that the Borrower’s consent shall not be required pursuant to this clause (b) if an Event of Default exists at the time of appointment of a successor Agent.

(c) If a successor Agent shall not have been so appointed within the 15 Business Day period referenced in clause (a) above, the applicable Agent, with the consent of the Borrower (which shall not be unreasonably withheld or delayed), shall then appoint a commercial bank or trust company with capital and surplus of not less than $500,000,000 as successor Agent who shall serve as the applicable Agent hereunder or thereunder until such time,

 

-82-


if any, as the Lenders appoint a successor Agent as provided above; provided that the Borrower’s consent shall not be required pursuant to this clause (c) if an Event of Default exists at the time of appointment of a successor Agent.

(d) If no successor Agent has been appointed pursuant to clause (b) or (c) above by the 25th Business Day after the date such notice of resignation was given by the applicable Agent, the applicable Agent’s resignation shall become effective and the Required Lenders shall thereafter perform all the duties of such Agent hereunder and/or under any other Credit Document until such time, if any, as the Required Lenders appoint a successor Agent as provided above.

12.09 The Joint Lead Arrangers. Notwithstanding any other provision of this Agreement or any provision of any other Credit Document, each of Deutsche Schiffsbank Aktiengesellschaft, DnB NOR Bank ASA, HSBC Bank plc, KfW IPEX-Bank GmbH and Nordea Bank Norge ASA, is hereby appointed as a Joint Lead Arranger by the Lenders to act as specified herein and in the other Credit Documents. Each of the Joint Lead Arrangers in their respective capacities as such shall have only the limited powers, duties, responsibilities and liabilities with respect to this Agreement or the other Credit Documents or the transactions contemplated hereby and thereby as are set forth herein or therein; it being understood and agreed that the Joint Lead Arrangers shall be entitled to all indemnification and reimbursement rights in favor of any of the Agents as provided for under Sections 12.06 and 14.01. Without limitation of the foregoing, none of the Joint Lead Arrangers shall, solely by reason of this Agreement or any other Credit Documents, have any fiduciary relationship in respect of any Lender or any other Person.

12.10 Impaired Agent. (a) If, at any time, any Agent becomes an Impaired Agent, a Credit Party or a Lender which is required to make a payment under the Credit Documents to such Agent in accordance with Section 4.03 may instead either pay that amount directly to the required recipient or pay that amount to an interest-bearing account held with an Acceptable Bank within the meaning of paragraph (a) of the definition of “Acceptable Bank” and in relation to which no Insolvency Event has occurred and is continuing, in the name of the Credit Party or the Lender making the payment and designated as a trust account for the benefit of the party or parties hereto beneficially entitled to that payment under the Credit Documents. In each case such payments must be made on the due date for payment under the Credit Documents.

(b) All interest accrued on the amount standing to the credit of the trust account shall be for the benefit of the beneficiaries of that trust account pro rata to their respective entitlements.

(c) A party to this Agreement which has made a payment in accordance with this Section 12.10 shall be discharged of the relevant payment obligation under the Credit Documents and shall not take any credit risk with respect to the amounts standing to the credit of the trust account.

(d) Promptly upon the appointment of a successor Agent in accordance with Section 12.11, each party to this Agreement which has made a payment to a trust account in

 

-83-


accordance with this Section 12.10 shall give all requisite instructions to the bank with whom the trust account is held to transfer the amount (together with any accrued interest) to the successor Agent for distribution in accordance with Section 2.04

12.11 Replacement of an Agent. (a) After consultation with the Parent, the Required Lenders may, by giving 30 days’ notice to an Agent (or, at any time such Agent is an Impaired Agent, by giving any shorter notice determined by the Required Lenders) replace such Agent by appointing a successor Agent (subject to Section 12.08(b) and (c)).

(b) The retiring Agent shall (at its own cost if it is an Impaired Agent and otherwise at the expense of the Borrower) make available to the successor Agent such documents and records and provide such assistance as the successor Agent may reasonably request for the purposes of performing its functions as Agent under the Credit Documents.

(c) The appointment of the successor Agent shall take effect on the date specified in the notice from the Required Lenders to the retiring Agent. As from such date, the retiring Agent shall be discharged from any further obligation in respect of the Credit Documents but shall remain entitled to the benefit of this Section 12.11 (and any agency fees for the account of the retiring Agent shall cease to accrue from (and shall be payable on) that date).

(d) Any successor Agent and each of the other parties to this Agreement shall have the same rights and obligations amongst themselves as they would have had if such successor had been an original party to this Agreement.

12.12 Resignation by the Hermes Agent. (a) The Hermes Agent may resign from the performance of all its functions and duties hereunder and/or under the other Credit Documents at any time by giving 15 Business Days’ prior written notice to the Borrower and the Lenders. Such resignation shall take effect upon the appointment of a successor Hermes Agent pursuant to clauses (b) and (c) below or as otherwise provided below.

(b) Upon any such notice of resignation by the Hermes Agent, the Required Lenders shall appoint a successor Hermes Agent hereunder or thereunder who shall be a commercial bank or trust company reasonably acceptable to the Borrower; provided that the Borrower’s consent shall not be required pursuant to this clause (b) if an Event of Default exists at the time of appointment of a successor Hermes Agent.

(c) If a successor Hermes Agent shall not have been so appointed within such 15 Business Day period, the Hermes Agent, with the consent of the Borrower (which shall not be unreasonably withheld or delayed), shall then appoint a commercial bank or trust company with capital and surplus of not less than $500,000,000 as successor Hermes Agent who shall serve as Hermes Agent hereunder or thereunder until such time, if any, as the Lenders appoint a successor Hermes Agent as provided above; provided that the Borrower’s consent shall not be required pursuant to this clause (d) if an Event of Default exists at the time of appointment of a successor Hermes Agent.

(d) If no successor Hermes Agent has been appointed pursuant to clause (b) or (c) above by the 25th Business Day after the date such notice of resignation was given by the Hermes Agent, the Hermes Agent’s resignation shall become effective and the Required Lenders

 

-84-


shall thereafter perform all the duties of the Hermes Agent hereunder and/or under any other Credit Document until such time, if any, as the Required Lenders appoint a successor Hermes Agent as provided above.

SECTION 13. Benefit of Agreement. This Agreement shall be binding upon and inure to the benefit of and be enforceable by the respective successors and assigns of the parties hereto, subject to the provisions of this Section 13.

13.01 Assignments and Transfers by the Lenders. (a) Subject to Section 13.06 and 13.07, any Lender (or any Lender together with one or more other Lenders, each an “Existing Lender”) may:

(i) with the consent of the Hermes Agent and the written consent of the Federal Republic of Germany, where required according to the applicable General Terms and Conditions (Allgemeine Bedingungen) and the supplementary provisions relating to the assignment of Guaranteed Amounts (Ergänzende Bestimmungen für Forderungsabtretungen AB (FAB)), assign any of its rights or transfer by novation any of its rights and obligations under this Agreement or any Credit Document (including, without limitation, all of the Commitments and outstanding Loans, or if less than all, a portion equal to at least $10,000,000 in the aggregate for such Lender’s rights and obligations), to (x) its parent company and/or any Affiliate of such assigning or transferring Lender which is at least 50% owned (directly or indirectly) by such Lender or its parent company or (y) in the case of any Lender that is a fund that invests in bank loans, any other fund that invests in bank loans and is managed or advised by the same investment advisor of such Lender or by an Affiliate of such investment advisor, or

(ii) with the consent of the Hermes Agent, the written consent of the Federal Republic of Germany, where required according to the applicable General Terms and Conditions (Allgemeine Bedingungen) and the supplementary provisions relating to the assignment of Guaranteed Amounts (Ergänzende Bestimmungen für Forderungsabtretungen AB (FAB)) and consent of the Borrower (which consent, in the case of the Borrower (x) shall not be unreasonably withheld or delayed, (y) shall not be required if a Default or Event of Default shall have occurred and be continuing at such time and (z) shall be deemed to have been given ten Business Days after the Existing Lender has requested it in writing unless consent is expressly refused by the Borrower within that time) assign any of its rights in or transfer by novation any of its rights in and obligations under all of its Commitments and outstanding Loans, or if less than all, a portion equal to at least $10,000,000 in the aggregate for such Existing Lender’s rights and obligations, hereunder to one or more Eligible Transferees (treating any fund that invests in bank loans and any other fund that invests in bank loans and is managed or advised by the same investment advisor of such fund or by an Affiliate of such investment advisor as a single Eligible Transferee),

each of which assignees or transferees shall become a party to this Agreement as a Lender by execution of (I) an Assignment Agreement (in the case of assignments) and (II) a Transfer Certificate (in the case of transfers under Section 13.06); provided that (x) at such time, Schedule 1.01(a) shall be deemed modified to reflect the Commitments and/or outstanding

 

-85-


Loans, as the case may be , of such New Lender and of the Existing Lenders and (y) the consent of the Facility Agent shall be required in connection with any assignment or transfer pursuant to preceding clause (ii) (which consent, in each case, shall not be unreasonably withheld or delayed); and provided, further, that at no time shall a Lender assign or transfer its rights or obligations under this Agreement to a hedge fund, private equity fund, insurance company or other similar or related financing institution that is not in the primary business of accepting cash deposits from, and making loans to, the public.

(b) If (x) a Lender assigns or transfers any of its rights or obligations under the Credit Documents or changes its Facility Office and (y) as a result of circumstances existing at the date the assignment, transfer or change occurs, a Credit Party would be obliged to make a payment to the New Lender or Lender acting through its new Facility Office under Sections 2.08, 2.09 or 4.04, then the New Lender or Lender acting through its new Facility Office is only entitled to receive payment under that section to the same extent as the Existing Lender or Lender acting through its previous Facility Office would have been if the assignment, transfer or change had not occurred. This Section 13.01(b) shall not apply in respect of an assignment or transfer made in the ordinary course of the primary syndication of the Credit Agreement.

(c) Each New Lender, by executing the relevant Transfer Certificate or Assignment Agreement, confirms, for the avoidance of doubt, that the Facility Agent has authority to execute on its behalf any amendment or waiver that has been approved by or on behalf of the requisite Lender or Lenders in accordance with this Agreement on or prior to the date on which the transfer or assignment becomes effective in accordance with this Agreement and that it is bound by that decision to the same extent as the Existing Lender would have been had it remained a Lender.

(d) Each assignment and/or transfer shall be made by such Existing Lender on a pro rata basis with respect to such Existing Lender’s Commitments under this Agreement and the Other Term Loan Facility, and no assignment and/or transfer of an Existing Lender’s rights and obligations hereunder may be made unless such Existing Lender, simultaneously with such assignment and/or transfer, assigns all of its parallel rights and obligations under the Other Term Loan Facility.

13.02 Assignment or Transfer Fee. Unless the Facility Agent otherwise agrees and excluding an assignment or transfer (i) to an Affiliate of a Lender, (ii) made in connection with primary syndication of this Agreement or (iii) as set forth in Section 13.03, each New Lender shall, on the date upon which an assignment or transfer takes effect, pay to the Facility Agent (for its own account) a fee of $3,500.

13.03 Assignments and Transfers to Hermes. Nothing in this Agreement shall prevent or prohibit any Lender from assigning its rights or transferring its rights and obligations hereunder to Hermes without the consent of the Borrower and without being required to pay the non-refundable assignment fee of $3,500 referred to in Section 13.02 above.

13.04 Limitation of Responsibility to Existing Lenders. (a) Unless expressly agreed to the contrary, an Existing Lender makes no representation or warranty and assumes no responsibility to a New Lender for:

(i) the legality, validity, effectiveness, adequacy or enforceability of the Credit Documents, the Security Documents or any other documents;

 

-86-


(ii) the financial condition of any Credit Party;

(iii) the performance and observance by any Credit Party of its obligations under the Credit Documents or any other documents; or

(iv) the accuracy of any statements (whether written or oral) made in or in connection with any Credit Document or any other document,

and any representations or warranties implied by law are excluded.

(b) Each New Lender confirms to the Existing Lender, the other Lender Creditors and the Secured Creditors that it (1) has made (and shall continue to make) its own independent investigation and assessment of the financial condition and affairs of each Credit Party and its related entities in connection with its participation in this Agreement and has not relied exclusively on any information provided to it by the Existing Lender or any other Lender Creditor in connection with any Credit Document or any Lien (or any other security interest) created pursuant to the Security Documents and (2) will continue to make its own independent appraisal of the creditworthiness of each Credit Party and its related entities whilst any amount is or may be outstanding under the Credit Documents or any Commitment is in force.

(c) Nothing in any Credit Document obliges an Existing Lender to:

(i) accept a re-transfer or re-assignment from a New Lender of any of the rights and obligations assigned or transferred under this Section 13; or

(ii) support any losses directly or indirectly incurred by the New Lender by reason of the non-performance by any Credit Party of its obligations under the Credit Documents or otherwise.

13.05 [Intentionally Omitted].

13.06 Procedure and Conditions for Transfer. (a) Subject to Section 13.01, a transfer is effected in accordance with Section 13.06(c) when the Facility Agent executes an otherwise duly completed Transfer Certificate delivered to it by the Existing Lender and the New Lender. The Facility Agent shall, subject to Section 13.06(b), as soon as reasonably practicable after receipt by it of a duly completed Transfer Certificate appearing on its face to comply with the terms of this Agreement and delivered in accordance with the terms of this Agreement, execute that Transfer Certificate.

(b) The Facility Agent shall only be obliged to execute a Transfer Certificate delivered to it by the Existing Lender and the New Lender once it is satisfied it has complied with all necessary “know your customer” or similar checks under all applicable laws and regulations in relation to the transfer to such New Lender.

 

-87-


(c) On the date of the transfer:

(i) to the extent that in the Transfer Certificate the Existing Lender seeks to transfer by novation its rights and obligations under the Credit Documents and in respect of the Security Documents each of the Credit Parties and the Existing Lender shall be released from further obligations towards one another under the Credit Documents and in respect of the Security Documents and their respective rights against one another under the Credit Documents and in respect of the Security Documents shall be cancelled (being the “Discharged Rights and Obligations”);

(ii) each of the Credit Parties and the New Lender shall assume obligations towards one another and/or acquire rights against one another which differ from the Discharged Rights and Obligations only insofar as that Credit Party or other member of the NCLC Group and the New Lender have assumed and/or acquired the same in place of that Credit Party and the Existing Lender;

(iii) the Facility Agent, the Collateral Agent, the Hermes Agent the New Lender and the other Lenders shall acquire the same rights and assume the same obligations between themselves and in respect of the Security Documents as they would have acquired and assumed had the New Lender been an original Lender with the rights, and/or obligations acquired or assumed by it as a result of the transfer and to that extent the Facility Agent, the Collateral Agent, the Hermes Agent and the Existing Lender shall each be released from further obligations to each other under the Credit Documents, it being understood that the indemnification provisions under this Agreement (including, without limitation, Sections 2.08, 2.09, 4.04, 14.01 and 14.05) shall survive as to such Existing Lender;

(iv) the New Lender shall become a party to this Agreement as a “Lender”; and

(v) The New Lender shall enter into the documentation required for it to accede as a party to the ECF Intercreditor Agreements.

13.07 Procedure and Conditions for Assignment. (a) Subject to Section 13.01, an assignment may be effected in accordance with Section 13.07(c) below when the Facility Agent executes an otherwise duly completed Assignment Agreement delivered to it by the Existing Lender and the New Lender. The Facility Agent shall, subject to Section 13.07(b) below, as soon as reasonably practicable after receipt by it of a duly completed Assignment Agreement appearing on its face to comply with the terms of this Agreement and delivered in accordance with the terms of this Agreement, execute that Assignment Agreement.

(b) The Facility Agent shall only be obliged to execute an Assignment Agreement delivered to it by the Existing Lender and the New Lender once it is satisfied it has complied with all necessary “know your customer” or similar checks under all applicable laws and regulations in relation to the assignment to such New Lender.

(c) On the date of the assignment:

(i) the Existing Lender will assign absolutely to the New Lender its rights under the Credit Documents and in respect of any Lien (or any other security interest) created pursuant to the Security Documents expressed to be the subject of the assignment in the Assignment Agreement;

 

-88-


(ii) the Existing Lender will be released from the obligations (the “Relevant Obligations”) expressed to be the subject of the release in the Assignment Agreement (and any corresponding obligations by which it is bound in respect of any Lien (or any other security interest) created pursuant to the Security Documents), it being understood that the indemnification provisions under this Agreement (including, without limitation, Sections 2.08, 2.09, 4.04, 14.01 and 14.05) shall survive as to such Existing Lender;

(iii) the New Lender shall become a Party as a “Lender” and will be bound by obligations equivalent to the Relevant Obligations; and

(iv) The New Lender enters into the documentation required for it to accede as a party to any ECF Intercreditor Agreement.

13.08 Copy of Transfer Certificate or Assignment Agreement to Parent. The Facility Agent shall, as soon as reasonably practicable after it has executed a Transfer Certificate or an Assignment Agreement, send to the Parent a copy of that Transfer Certificate or Assignment Agreement.

13.09 Security over Lenders’ Rights. In addition to the other rights provided to Lenders under this Section 13, each Lender may without consulting with or obtaining consent from any Credit Party, at any time charge, assign or otherwise create a Lien (or any other security interest) or declare a trust in or over (whether by way of collateral or otherwise) all or any of its rights under any Credit Document to secure obligations of that Lender including, without limitation:

(i) any charge, assignment or other Lien (or any other security interest) or trust to secure obligations to a federal reserve or central bank; and

(ii) in the case of any Lender which is a fund, any charge, assignment or other Lien (or any other security interest) granted to any holders (or trustee or representatives of holders) of obligations owed, or securities issued, by that Lender as security for those obligations or securities,

except that no such charge, assignment or Lien (or any other security interest) or trust shall:

(i) release a Lender from any of its obligations under the Credit Documents or substitute the beneficiary of the relevant charge, assignment or other Lien (or any other security interest) or trust for the Lender as a party to any of the Credit Documents; or

(ii) require any payments to be made by a Credit Party or grant to any person any more extensive rights than those required to be made or granted to the relevant Lender under the Credit Documents.

 

-89-


13.10 Assignment by a Credit Party. No Credit Party may assign any of its rights or transfer by novation any of its rights, obligations or interest hereunder or under any other Credit Document without the prior written consent of the Hermes Agent and the Lenders.

13.11 Lender Participations. (a) Although any Lender may grant participations in its rights hereunder, such Lender shall remain a “Lender” for all purposes hereunder (and may not transfer by novation its rights and obligations or assign its rights under all or any portion of its Commitments hereunder except as provided in Sections 2.11 and 13.01) and the participant shall not constitute a “Lender” hereunder; and

(b) no Lender shall grant any participation under which the participant shall have rights to approve any amendment to or waiver of this Agreement or any other Credit Document except to the extent such amendment or waiver would (x) extend the final scheduled maturity of any Loan in which such participant is participating, or reduce the rate or extend the time of payment of interest or Commitment Commission thereon (except (m) in connection with a waiver of applicability of any post-default increase in interest rates and (n) that any amendment or modification to the financial definitions in this Agreement shall not constitute a reduction in the rate of interest for purposes of this clause (x)) or reduce the principal amount thereof, or increase the amount of the participant’s participation over the amount thereof then in effect (it being understood that a waiver of any Default or Event of Default or of a mandatory reduction in the Total Commitment shall not constitute a change in the terms of such participation, and that an increase in any Commitment or Loan shall be permitted without the consent of any participant if the participant’s participation is not increased as a result thereof), (y) consent to the assignment by the Borrower of any of its rights, or transfer by the Borrower of any of its rights and obligations, under this Agreement or (z) release all or substantially all of the Collateral under all of the Security Documents (except as expressly provided in the Credit Documents) securing the Loans hereunder in which such participant is participating. In the case of any such participation, the participant shall not have any rights under this Agreement or any of the other Credit Documents (the participant’s rights against such Lender in respect of such participation to be those set forth in the agreement executed by such Lender in favor of the participant relating thereto) and all amounts payable by the Borrower hereunder shall be determined as if such Lender had not sold such participation.

13.12 Increased Costs. To the extent that a transfer of all or any portion of a Lender’s Commitments and related outstanding Credit Document Obligations pursuant to Section 2.11 or Section 13.01 would, at the time of such assignment, result in increased costs under Section 2.08, 2.09 or 4.04 from those being charged by the respective assigning Lender prior to such assignment, then the Borrower shall not be obligated to pay such increased costs (although the Borrower shall be obligated to pay any other increased costs of the type described above resulting from changes after the date of the respective assignment).

SECTION 14. Miscellaneous.

14.01 Payment of Expenses, etc. The Borrower agrees that it shall: whether or not the transactions herein contemplated are consummated, (i) pay all reasonable documented out-of-pocket costs and expenses of each of the Agents (including, without limitation, the reasonable documented fees and disbursements of White & Case LLP, Bahamian counsel,

 

-90-


Bermudian counsel, Isle of Man counsel other counsel to the Facility Agent and the Joint Lead Arrangers and local counsel) in connection with the preparation, execution and delivery of this Agreement and the other Credit Documents and the documents and instruments referred to herein and therein and any amendment, waiver or consent relating hereto or thereto, and in connection with their respective syndication efforts with respect to this Agreement; (ii) pay all documented out-of-pocket costs and expenses of each of the Agents and each of the Lenders in connection with the enforcement of this Agreement and the other Credit Documents and the documents and instruments referred to herein and therein (including, without limitation, the fees and disbursements of counsel (excluding in-house counsel) for each of the Agents and for each of the Lenders); (iii) pay and hold the Facility Agent and each of the Lenders harmless from and against any and all present and future stamp, documentary, transfer, sales and use, value added, excise and other similar taxes with respect to the foregoing matters, the performance of any obligation under this Agreement or any Credit Document or any payment thereunder, and save the Facility Agent and save each of the Lenders harmless from and against any and all liabilities with respect to or resulting from any delay or omission (other than to the extent attributable to the Facility Agent or such Lender) to pay such taxes; and (iv) other than in respect of a wrongful failure by any Lender to fund its Commitments as required by this Agreement, indemnify the Agents and each Lender, and each of their respective officers, directors, trustees, employees, representatives and agents from and hold each of them harmless against any and all liabilities, obligations (including removal or remedial actions), losses, damages, penalties, claims, actions, judgments, suits, costs, expenses and disbursements (including reasonable attorneys’ and consultants’ fees and disbursements) incurred by, imposed on or assessed against any of them as a result of, or arising out of, or in any way related to, or by reason of, (a) any investigation, litigation or other proceeding (whether or not any of the Agents or any Lender is a party thereto) related to the entering into and/or performance of this Agreement or any other Credit Document or the proceeds of any Loans hereunder or the consummation of any transactions contemplated herein, or in any other Credit Document or the exercise of any of their rights or remedies provided herein or in the other Credit Documents, or (b) the actual or alleged presence of Hazardous Materials on the Collateral Vessel or in the air, surface water or groundwater or on the surface or subsurface of any property at any time owned or operated by the Borrower, the generation, storage, transportation, handling, disposal or Environmental Release of Hazardous Materials at any location, whether or not owned or operated by the Borrower, the non-compliance of the Collateral Vessel or property with foreign, federal, state and local laws, regulations, and ordinances (including applicable permits thereunder) applicable to the Collateral Vessel or property, or any Environmental Claim asserted against the Borrower or the Collateral Vessel or property at any time owned or operated by the Borrower, including, without limitation, the reasonable fees and disbursements of counsel and other consultants incurred in connection with any such investigation, litigation or other proceeding (but excluding any losses, liabilities, claims, damages, penalties, actions, judgments, suits, costs, disbursements or expenses to the extent incurred by reason of the gross negligence or willful misconduct of the Person to be indemnified or by reason of a failure by the Person to be indemnified to fund its Commitments as required by this Agreement). To the extent that the undertaking to indemnify, pay or hold harmless each of the Agents or any Lender set forth in the preceding sentence may be unenforceable because it violates any law or public policy, the Borrower shall make the maximum contribution to the payment and satisfaction of each of the indemnified liabilities which is permissible under applicable law.

 

-91-


14.02 Right of Set-off. In addition to any rights now or hereafter granted under applicable law or otherwise, and not by way of limitation of any such rights, upon the occurrence and during the continuance of an Event of Default, each Lender is hereby authorized at any time or from time to time, without presentment, demand, protest or other notice of any kind to the Parent or any Subsidiary of the Parent or to any other Person, any such notice being hereby expressly waived, to set off and to appropriate and apply any and all deposits (general or special) and any other Indebtedness at any time held or owing by such Lender (including, without limitation, by branches and agencies of such Lender wherever located) to or for the credit or the account of the Parent or any Subsidiary of the Parent but in any event excluding assets held in trust for any such Person against and on account of the Credit Document Obligations and liabilities of the Parent or such Subsidiary of the Parent, as applicable, to such Lender under this Agreement or under any of the other Credit Documents, including, without limitation, all interests in Credit Document Obligations purchased by such Lender pursuant to Section 14.05(b), and all other claims of any nature or description arising out of or connected with this Agreement or any other Credit Document, irrespective of whether or not such Lender shall have made any demand hereunder and although said Credit Document Obligations, liabilities or claims, or any of them, shall be contingent or unmatured. Each Lender upon the exercise of its rights to set-off pursuant to this Section 14.02 shall give notice thereof to the Facility Agent.

14.03 Notices. Except as otherwise expressly provided herein, all notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed: if to any Credit Party, at the address specified on Schedule 14.03A; if to any Lender, at its address specified opposite its name on Schedule 14.03B; and if to the Facility Agent or the Hermes Agent, at its Notice Office; or, as to any other Credit Party, at such other address as shall be designated by such party in a written notice to the other parties hereto and, as to each Lender, at such other address as shall be designated by such Lender in a written notice to the Parent, the Borrower and the Facility Agent; provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Facility Agent, the Hermes Agent, the Lenders, the Borrower and the Parent (x) agree that they shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and (y) they shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Facility Agent or the Hermes Agent shall not be effective until received by the Facility Agent or the Hermes Agent (as the case may be), or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by a Lender, the Borrower or the Parent to the Facility Agent or the Hermes Agent, only if it is addressed in such a manner as the Facility Agent shall specify for this purpose. A copy of any notice to the Facility Agent shall be delivered to the Hermes Agent at its Notice Office. If an Agent is an Impaired Agent the parties to this Agreement may, instead of communicating with each other through such Agent, communicate with each other directly and (while such Agent is an Impaired Agent) all the provisions of the Credit Documents which

 

-92-


require communications to be made or notices to be given to or by such Agent shall be varied so that communications may be made and notices given to or by the relevant parties to this Agreement directly. This provision shall not operate after a replacement Agent has been appointed.

14.04 No Waiver; Remedies Cumulative. No failure or delay on the part of an Agent or any Lender in exercising any right, power or privilege hereunder or under any other Credit Document and no course of dealing between the Borrower or any other Credit Party and an Agent or any Lender shall operate as a waiver thereof; nor shall any single or partial exercise of any right, power or privilege hereunder or under any other Credit Document preclude any other or further exercise thereof or the exercise of any other right, power or privilege hereunder or thereunder. The rights, powers and remedies herein or in any other Credit Document expressly provided are cumulative and not exclusive of any rights, powers or remedies which an Agent or any Lender would otherwise have. No notice to or demand on any Credit Party in any case shall entitle any Credit Party to any other or further notice or demand in similar or other circumstances or constitute a waiver of the rights of an Agent or any Lender to any other or further action in any circumstances without notice or demand.

14.05 Payments Pro Rata. (a) Except as otherwise provided in this Agreement, the Facility Agent agrees that promptly after its receipt of each payment from or on behalf of the Borrower in respect of any Credit Document Obligations hereunder, it shall distribute such payment to the Lenders (other than any Lender that has consented in writing to waive its pro rata share of any such payment) pro rata based upon their respective shares, if any, of the Credit Document Obligations with respect to which such payment was received.

(b) Other than in connection with assignments and participations (which are governed by Section 13), each of the Lenders agrees that, if it should receive any amount hereunder (whether by voluntary payment, by realization upon security, by the exercise of the right of setoff or banker’s lien, by counterclaim or cross action, by the enforcement of any right under the Credit Documents, or otherwise), which is applicable to the payment of the principal of, or interest on, the Loans, Commitment Commission, of a sum which with respect to the related sum or sums received by other Lenders is in a greater proportion than the total of such Credit Document Obligation then owed and due to such Lender bears to the total of such Credit Document Obligation then owed and due to all of the Lenders immediately prior to such receipt, then such Lender receiving such excess payment shall purchase for cash without recourse or warranty from the other Lenders an interest in the Credit Document Obligations of the respective Credit Party to such Lenders in such amount as shall result in a proportional participation by all the Lenders in such amount; provided that if all or any portion of such excess amount is thereafter recovered from such Lender, such purchase shall be rescinded and the purchase price restored to the extent of such recovery, but without interest.

(c) Notwithstanding anything to the contrary contained herein, the provisions of the preceding Sections 14.05(a) and (b) shall be subject to the express provisions of this Agreement which require, or permit, differing payments to be made to Non-Defaulting Lenders as opposed to Defaulting Lenders.

 

-93-


14.06 Calculations; Computations. (a) The financial statements to be furnished to the Lenders pursuant hereto shall be made and prepared in accordance with generally accepted accounting principles in the United States consistently applied throughout the periods involved (except as set forth in the notes thereto or as otherwise disclosed in writing by the Parent to the Lenders). In addition, all computations determining compliance with the financial covenants set forth in Sections 10.06 through 10.09, inclusive, shall utilize accounting principles and policies in conformity with those used to prepare the historical financial statements delivered to the Lenders for the fiscal year of the Parent ended December 31, 2009 (with the foregoing generally accepted accounting principles, subject to the preceding proviso, herein called “GAAP”). Unless otherwise noted, all references in this Agreement to “generally accepted accounting principles” shall mean generally accepted accounting principles as in effect in the United States.

(b) All computations of interest and Commitment Commission hereunder shall be made on the basis of a year of 360 days for the actual number of days (including the first day but excluding the last day) occurring in the period for which such interest or Commitment Commission are payable.

14.07 GOVERNING LAW; EXCLUSIVE JURISDICTION OF ENGLISH COURTS; SERVICE OF PROCESS. (a) THIS AGREEMENT AND ANY NON-CONTRACTUAL OBLIGATIONS ARISING OUT OF OR IN CONNECTION WITH IT ARE GOVERNED BY ENGLISH LAW.

(b) THE COURTS OF ENGLAND HAVE EXCLUSIVE JURISDICTION TO SETTLE ANY DISPUTE ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT (INCLUDING A DISPUTE RELATING TO THE EXISTENCE, VALIDITY OR TERMINATION OF THIS AGREEMENT OR ANY NON-CONTRACTUAL OBLIGATION ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT) (A “DISPUTE”). THE PARTIES HERETO AGREE THAT THE COURTS OF ENGLAND ARE THE MOST APPROPRIATE AND CONVENIENT COURTS TO SETTLE DISPUTES AND ACCORDINGLY NO PARTY HERETO WILL ARGUE TO THE CONTRARY. THIS SECTION 14.07 IS FOR THE BENEFIT OF THE LENDERS, AGENTS AND SECURED CREDITORS. AS A RESULT, NO SUCH PARTY SHALL BE PREVENTED FROM TAKING PROCEEDINGS RELATING TO A DISPUTE IN ANY OTHER COURTS WITH JURISDICTION. TO THE EXTENT ALLOWED BY LAW, THE LENDERS, AGENTS AND SECURED CREDITORS MAY TAKE CONCURRENT PROCEEDINGS IN ANY NUMBER OF JURISDICTIONS.

(c) WITHOUT PREJUDICE TO ANY OTHER MODE OF SERVICE ALLOWED UNDER ANY RELEVANT LAW, EACH CREDIT PARTY (OTHER THAN A CREDIT PARTY INCORPORATED IN ENGLAND AND WALES): (i) IRREVOCABLY APPOINTS EC3 SERVICES LIMITED, HAVING ITS REGISTERED OFFICE AT 51 EASTCHEAP, LONDON, EC3M 1JP, AS ITS AGENT FOR SERVICE OF PROCESS IN RELATION TO ANY PROCEEDINGS BEFORE THE ENGLISH COURTS IN CONNECTION WITH ANY CREDIT DOCUMENT AND (ii) AGREES THAT FAILURE BY AN AGENT FOR SERVICE OF PROCESS TO NOTIFY THE RELEVANT CREDIT PARTY OF THE PROCESS WILL NOT INVALIDATE THE PROCEEDINGS CONCERNED. IF ANY PERSON APPOINTED AS AN AGENT FOR

 

-94-


SERVICE OF PROCESS IS UNABLE FOR ANY REASON TO ACT AS AGENT FOR SERVICE OF PROCESS, THE PARENT (ON BEHALF OF ALL THE CREDIT PARTIES) MUST IMMEDIATELY (AND IN ANY EVENT WITHIN FIVE DAYS OF SUCH EVENT TAKING PLACE) APPOINT ANOTHER AGENT ON TERMS ACCEPTABLE TO THE FACILITY AGENT. FAILING THIS, THE FACILITY AGENT MAY APPOINT ANOTHER AGENT FOR THIS PURPOSE.

EACH PARTY TO THIS AGREEMENT EXPRESSLY AGREES AND CONSENTS TO THE PROVISIONS OF THIS SECTION 14.07.

14.08 Counterparts. This Agreement may be executed in any number of counterparts and by the different parties hereto on separate counterparts, each of which when so executed and delivered shall be an original, but all of which shall together constitute one and the same instrument. A set of counterparts executed by all the parties hereto shall be lodged with the Borrower and the Facility Agent.

14.09 Effectiveness. This Agreement shall take effect as a deed on the date (the “Effective Date”) on which (i) the Borrower, the Guarantor, the Agents and each of the Lenders who are initially parties hereto shall have signed a counterpart hereof (whether the same or different counterparts) and shall have delivered the same to the Facility Agent or, in the case of the Lenders and the other Agents, shall have given to the Facility Agent written or facsimile notice (actually received) at such office that the same has been signed and mailed to it, (ii) the Borrower shall have paid to the Facility Agent for its own account and/or the account of Lenders and/or Agents, as the case may be, the fees required to be paid pursuant to that certain commitment letter, dated October 11, 2010, among the Parent, the Hermes Agent, Deutsche Schiffsbank Aktiengesellschaft, DnB NOR Bank ASA, HSBC Bank plc, KfW IPEX-Bank GmbH and Nordea Bank Norge ASA (the “Commitment Letter”) and (iii) the Credit Parties shall have provided (x) the “Know Your Customer” information required pursuant to the USA PATRIOT Act (Title III of Pub.: 107-56 (signed into law October 26, 2001)) (the “PATRIOT Act”) and (y) such other documentation and evidence necessary in order to carry out and be reasonably satisfied with other similar checks under all applicable laws and regulations pursuant to the Transaction and the Hermes Cover, in each case as requested by the Facility Agent, the Hermes Agent or any Lender in connection with each of the Facility Agent’s, the Hermes Agent’s, Hermes’ and each Lender’s internal compliance regulations. The Facility Agent will give the Parent, the Borrower and each Lender prompt written notice of the occurrence of the Effective Date.

14.10 Headings Descriptive. The headings of the several sections and subsections of this Agreement are inserted for convenience only and shall not in any way affect the meaning or construction of any provision of this Agreement.

14.11 Amendment or Waiver; etc. (a) Neither this Agreement nor any other Credit Document nor any terms hereof or thereof may be changed, waived, discharged or terminated unless such change, waiver, discharge or termination is in writing signed by the respective Credit Parties party thereto, the Hermes Agent and the Required Lenders, provided that no such change, waiver, discharge or termination shall, without the consent of each Lender (other than a Defaulting Lender), (i) extend the final scheduled maturity of any Loan, extend the

 

-95-


timing for or reduce the principal amount of any Scheduled Repayment, increase or extend any Commitment (it being understood that waivers or modifications of conditions precedent, covenants, Defaults or Events of Default or of a mandatory reduction in the Commitments shall not constitute an increase of the Commitment of any Lender), or reduce the rate (including, without limitation, the Applicable Margin) or extend the time of payment of interest on any Loan or Commitment Commission or fees (except (x) in connection with the waiver of applicability of any post-default increase in interest rates and (y) any amendment or modification to the definitions used in the financial covenants set forth in Sections 10.06 through 10.09, inclusive, in this Agreement shall not constitute a reduction in the rate of interest for purposes of this clause (i)), or reduce the principal amount thereof (except to the extent repaid in cash), (ii) release any of the Collateral (except as expressly provided in the Credit Documents) under any of the Security Documents, (iii) amend, modify or waive any provision of Section 13 or this Section 14.11, (iv) change the definition of Required Lenders (it being understood that, with the consent of the Required Lenders, additional extensions of credit pursuant to this Agreement may be included in the determination of the Required Lenders on substantially the same basis as the extensions of Loans and Commitments are included on the Effective Date) or a provision which expressly requires the consent of all the Lenders, (v) consent to the assignment and/or transfer by the Parent and/or Borrower of any of its rights and obligations under this Agreement, or (vi) replace the Parent Guaranty or release the Parent Guaranty from the relevant guarantee to which such Guarantor is a party (other than as provided in such guarantee); provided, further, that no such change, waiver, discharge or termination shall (u) without the consent of Hermes, amend, modify or waive any provision that relates to the rights or obligations of Hermes and (v) without the consent of each Agent and/or each Joint Lead Arranger, as applicable, amend, modify or waive any provision relating to the rights or obligations of such Agent and/or such Joint Lead Arranger, as applicable.

(b) If, in connection with any proposed change, waiver, discharge or termination to any of the provisions of this Agreement as contemplated by clauses (i) through (vi), inclusive, of the first proviso to Section 14.11(a), the consent of the Required Lenders is obtained but the consent of each Lender (other than any Defaulting Lender) is not obtained, then the Borrower shall have the right, so long as all non-consenting Lenders are treated as described in either clauses (A) or (B) below, to either (A) replace each such non-consenting Lender or Lenders with one or more Replacement Lenders pursuant to Section 2.11 so long as at the time of such replacement, each such Replacement Lender consents to the proposed change, waiver, discharge or termination or (B) terminate such non-consenting Lender’s Commitment (if such Lender’s consent is required as a result of its Commitment), and/or repay outstanding Loans and terminate any outstanding Commitments of such Lender which gave rise to the need to obtain such Lender’s consent, in accordance with Section 4.01(d), provided that, unless the Commitments are terminated, and Loans repaid, pursuant to preceding clause (B) are immediately replaced in full at such time through the addition of new Lenders or the increase of the Commitments and/or outstanding Loans of existing Lenders (who in each case must specifically consent thereto), then in the case of any action pursuant to preceding clause (B) the Required Lenders (determined before giving effect to the proposed action) and the Hermes Agent shall specifically consent thereto, provided, further, that in any event the Borrower shall not have the right to replace a Lender, terminate its Commitment or repay its Loans solely as a result of the exercise of such Lender’s rights (and the withholding of any required consent by such Lender) pursuant to the second proviso to Section 14.11(a).

 

-96-


14.12 Survival. All indemnities set forth herein including, without limitation, in Sections 2.08, 2.09, 2.10, 4.04, 14.01 and 14.05 shall, subject to Section 14.13 (to the extent applicable), survive the execution, delivery and termination of this Agreement and the making and repayment of the Loans.

14.13 Domicile of Loans. Each Lender may transfer and carry its Loans at, to or for the account of any office, Subsidiary or Affiliate of such Lender. Notwithstanding anything to the contrary contained herein, to the extent that a transfer of Loans pursuant to this Section 14.13 would, at the time of such transfer, result in increased costs under Section 2.08, 2.09, or 4.04 from those being charged by the respective Lender prior to such transfer, then the Borrower shall not be obligated to pay such increased costs (although the Borrower shall be obligated to pay any other increased costs of the type described above resulting from changes after the date of the respective transfer).

14.14 Confidentiality. Each Lender agrees that it will use its best efforts not to disclose without the prior consent of the Parent or the Borrower (other than to their respective Affiliates or their respective Affiliates’ employees, auditors, advisors or counsel or to another Lender if the Lender or such Lender’s holding or parent company, Affiliates or board of trustees in its sole discretion determines that any such party should have access to such information, provided such Persons shall be subject to the provisions of this Section 14.14 to the same extent as such Lender) any information with respect to the Parent or any of its Subsidiaries which is now or in the future furnished pursuant to this Agreement or any other Credit Document, provided that the Hermes Agent may disclose any information to Hermes, provided, further, that any Lender may disclose any such information (a) as has become generally available to the public other than by virtue of a breach of this Section 14.14 by the respective Lender, (b) as may be required in any report, statement or testimony submitted to any municipal, state or Federal regulatory body having or claiming to have jurisdiction over such Lender or similar organizations (whether in the United States, the United Kingdom or elsewhere) or their successors, (c) as may be required in respect to any summons or subpoena or in connection with any litigation, (d) in order to comply with any law, order, regulation or ruling applicable to such Lender, (e) to an Agent (f) to any prospective or actual transferee or participant in connection with any contemplated transfer or participation of any of the Commitments or any interest therein by such Lender, provided that such prospective transferee expressly agrees to be bound by the confidentiality provisions contained in this Section 14.14 and (g) to Hermes and/or the Federal Republic of Germany and/or the European Union and/or any agency thereof or any person acting or purporting to act on any of their behalves. In the case of Section 14.14(g), each of the Parent and the Borrower acknowledges and agrees that any such information may be used by Hermes and/or the Federal Republic of Germany and/or the European Union and/or any agency thereof or any person acting or purporting to act on any of their behalves for statistical purposes and/or for reports of a general nature.

14.15 Register. The Facility Agent shall maintain a register (the “Register”) on which it will record the Commitments from time to time of each of the Lenders, the Loans made by each of the Lenders and each repayment and prepayment in respect of the principal amount of the Loans of each Lender. Failure to make any such recordation, or any error in such recordation shall not affect the Borrower’s obligations in respect of such Loans. With respect to any Lender, the assignment or transfer of the Commitments of such Lender and the rights to the principal of,

 

-97-


and interest on, any Loan made pursuant to such Commitments shall not be effective until such assignment or transfer is recorded on the Register maintained by the Facility Agent with respect to ownership of such Commitments and Loans. Prior to such recordation all amounts owing to the transferor with respect to such Commitments and Loans shall remain owing to the transferor. The registration of an assignment or transfer of all or part of any Commitments and Loans (as the case may be) shall be recorded by the Facility Agent on the Register only upon the acceptance by the Facility Agent of a properly executed and delivered Transfer Certificate or Assignment Agreement pursuant to Section 13.06(a) or 13.07(a), respectively.

14.16 Third Party Rights. Other than the Other Creditors with respect to Section 4.05, a person who is not a party to this Agreement has no right under the Contracts (Rights of Third Parties) Act 1999 to enforce or enjoy the benefit of any term of this Agreement unless expressly provided to the contrary in a Credit Document. Notwithstanding any term of any Credit Document, the consent of any person who is not a party to this Agreement is not required to rescind or vary this Agreement at any time.

14.17 Judgment Currency. If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from the Borrower hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Facility Agent could purchase the specified currency with such other currency at the Facility Agent’s Frankfurt office on the Business Day preceding that on which final judgment is given. The obligations of the Borrower in respect of any sum due to any Lender or an Agent hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by such Lender or an Agent (as the case may be) of any sum adjudged to be so due in such other currency such Lender or an Agent (as the case may be) may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to such Lender or an Agent, as the case may be, in the specified currency, the Borrower agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify such Lender or an Agent, as the case may be, against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to any Lender or an Agent, as the case may be, in the specified currency, such Lender or an Agent, as the case may be, agrees to remit such excess to the Borrower.

14.18 Language. All correspondence, including, without limitation, all notices, reports and/or certificates, delivered by any Credit Party to an Agent or any Lender shall, unless otherwise agreed by the respective recipients thereof, be submitted in the English language or, to the extent the original of such document is not in the English language, such document shall be delivered with a certified English translation thereof. In the event of any conflict between the English translation and the original text of any document, the English translation shall prevail unless the original text is a statutory instrument, legal process or any other document of a similar type or a notice, demand or other communication from Hermes or in relation to the Hermes Cover.

 

-98-


14.19 Waiver of Immunity. The Borrower, in respect of itself, each other Credit Party, its and their process agents, and its and their properties and revenues, hereby irrevocably agrees that, to the extent that the Borrower, any other Credit Party or any of its or their properties has or may hereafter acquire any right of immunity from any legal proceedings, whether in the United Kingdom, the United States, Bermuda, the Bahamas, Germany, the Isle of Man or elsewhere, to enforce or collect upon the Credit Document Obligations of the Borrower or any other Credit Party related to or arising from the transactions contemplated by any of the Credit Documents, including, without limitation, immunity from service of process, immunity from jurisdiction or judgment of any court or tribunal, immunity from execution of a judgment, and immunity of any of its property from attachment prior to any entry of judgment, or from attachment in aid of execution upon a judgment, the Borrower, for itself and on behalf of the other Credit Parties, hereby expressly waives, to the fullest extent permissible under applicable law, any such immunity, and agrees not to assert any such right or claim in any such proceeding, whether in the United Kingdom, the United States, Bermuda, the Bahamas, Germany, the Isle of Man or elsewhere.

14.20 “Know Your Customer” Notice. Each Lender hereby notifies each Credit Party that pursuant to the requirements of the PATRIOT Act and/or other applicable laws and regulations, it is required to obtain, verify, and record information that identifies each Credit Party, which information includes the name of each Credit Party and other information that will allow such Lender to identify each Credit Party in accordance with the PATRIOT Act and/or such other applicable laws and regulations, and each Credit Party agrees to provide such information from time to time to any Lender.

14.21 Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer. (a) In the event that any Person conveys, sells, leases, assigns, transfers or otherwise disposes of all or any portion of the Collateral to a Person that is not (and is not required to become) a Credit Party in a transaction permitted by this Agreement or the Credit Documents (including pursuant to a valid waiver or consent), each Lender hereby consents to the release and hereby directs the Collateral Agent to release any Liens created by any Credit Document in respect of such Collateral, and, in the case of a disposition of all of the Equity Interests of any Credit Party (other than the Borrower) in a transaction permitted by this Agreement and as a result of which such Credit Party would not be required to guaranty the Credit Document Obligations pursuant to Section 15, each Lender hereby consents to the release of such Credit Party’s obligations under the relevant guarantee to which it is a party. Each Lender hereby directs the Collateral Agent, and the Collateral Agent agrees, upon receipt of reasonable advance notice from the Borrower, to execute and deliver or, at the Borrower’s expense, file such documents and perform other actions reasonably necessary to release the relevant guarantee, as applicable, and the Liens when and as directed pursuant to this Section 14.21. In addition, the Collateral Agent agrees to take such actions as are reasonably requested by the Borrower and at the Borrower’s expense to terminate the Liens and security interests created by the Credit Documents when all the Credit Document Obligations (other than contingent indemnification Credit Document Obligations and expense reimbursement claims to the extent no claim therefore has been made) are paid in full and Commitments are terminated. Any representation, warranty or covenant contained in any Credit Document relating to any such Equity Interests or, asset of the Borrower shall no longer be deemed to be made once such Equity Interests or asset is so conveyed, sold, leased, assigned, transferred or disposed of.

 

-99-


(b) In the event that the Borrower desires to implement a Flag Jurisdiction Transfer with respect to the Collateral Vessel, upon receipt of reasonable advance notice thereof from the Borrower, the Collateral Agent shall use commercially reasonably efforts to provide, or (as necessary) procure the provision of, all such reasonable assistance as any Credit Party may request from time to time in relation to (i) the Flag Jurisdiction Transfer, (ii) the related deregistration of the Collateral Vessel from its previous flag jurisdiction, and (iii) the release and discharge of the related Security Documents provided that the relevant Credit Party shall pay all documented out of pocket costs and expenses reasonably incurred by the Collateral Agent or a Secured Creditor in connection with provision of such assistance. Each Lender hereby consents, in connection with any Flag Jurisdiction Transfer and subject to the satisfaction of the requirements thereof to be satisfied by the relevant Credit Party, to (i) deregister the Collateral Vessel from its previous flag jurisdiction and (ii) release and hereby direct the Collateral Agent to release the Collateral Vessel Mortgage. Each Lender hereby directs the Collateral Agent, and the Collateral Agent agrees to execute and deliver or, at the Borrower’s expense, file such documents and perform other actions reasonably necessary to release the Vessel Mortgage when and as directed pursuant to this Section 14.21(b).

14.22 Partial Invalidity. If, at any time, any provision of the Credit Documents is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions nor the legality, validity or enforceability of such provision under the law of any other jurisdiction will in any way be affected or impaired. Any such illegal, invalid or unenforceable provision shall to the extent possible be substituted by a legal, valid and enforceable provision which reflects the intention of the parties to this Agreement.

SECTION 15. Parent Guaranty.

15.01 Guaranty and Indemnity. The Parent irrevocably and unconditionally:

(i) guarantees to each Lender Creditor punctual performance by each other Credit Party of all that Credit Party’s Credit Document Obligations under the Credit Documents; or

(ii) undertakes with each Lender Creditor that whenever another Credit Party does not pay any amount when due under or in connection with any Credit Document, the Guarantor shall immediately on demand pay that amount as if it was the principal obligor; and

(iii) agrees with each Lender Creditor that if any obligation guaranteed by it is or becomes unenforceable, invalid or illegal, it will, as an independent and primary obligation, indemnify that Lender Creditor immediately on demand against any cost, loss or liability it incurs as a result of a Credit Party not paying any amount which would, but for such unenforceability, invalidity or illegality, have been payable by it under any Credit Document on the date when it would have been due. The amount payable by the Guarantor under this indemnity will not exceed the amount it would have had to pay under this Section 15 if the amount claimed had been recoverable on the basis of a guarantee.

 

-100-


15.02 Continuing Guaranty. This guarantee is a continuing guarantee and will extend to the ultimate balance of sums payable by any Credit Party under the Credit Documents, regardless of any intermediate payment or discharge in whole or in part.

15.03 Reinstatement. If any discharge, release or arrangement (whether in respect of the obligations of any Credit Party or any security for those obligations or otherwise) is made by a Lender Creditor in whole or in part on the basis of any payment, security or other disposition which is avoided or must be restored in insolvency, liquidation, administration or otherwise, without limitation, then the liability of the Guarantor under this Section 15 will continue or be reinstated as if the discharge, release or arrangement had not occurred.

15.04 Waiver of Defenses. The obligations of the Guarantor under this Section 15 will not be affected by an act, omission, matter or thing which, but for this Section 15, would reduce, release or prejudice any of its obligations under this Section 15 (without limitation and whether or not known to it or any Lender Creditor) including:

(i) any time, waiver or consent granted to, or composition with, any Credit Party or other person;

(ii) the release of any other Credit Party or any other person under the terms of any composition or arrangement with any creditor of any member of the NCLC Group;

(iii) the taking, variation, compromise, exchange, renewal or release of, or refusal or neglect to perfect, take up or enforce, any rights against, or security over assets of, any Credit Party or other person or any non-presentation or non-observance of any formality or other requirement in respect of any instrument or any failure to realize the full value of any security;

(iv) any incapacity or lack of power, authority or legal personality of or dissolution or change in the members or status of a Credit Party or any other person;

(v) any amendment, novation, supplement, extension restatement (however fundamental and whether or not more onerous) or replacement of a Credit Document or any other document or security including, without limitation, any change in the purpose of, any extension of or increase in any facility or the addition of any new facility under any Credit Document or other document or security;

(vi) any unenforceability, illegality or invalidity of any obligation of any person under any Credit Document or any other document or security; or

(vii) any insolvency or similar proceedings.

15.05 Guarantor Intent. Without prejudice to the generality of Section 15.04, the Guarantor expressly confirms that it intends that this guarantee shall extend from time to time to any (however fundamental) variation, increase, extension or addition of or to any of the Credit Documents and/or any facility or amount made available under any of the Credit Documents for the purposes of or in connection with any of the following: business acquisitions of any nature; increasing working capital; enabling investor distributions to be made; carrying out

 

-101-


restructurings; refinancing existing facilities; refinancing any other indebtedness; making facilities available to new borrowers; any other variation or extension of the purposes for which any such facility or amount might be made available from time to time; and any fees, costs and/or expenses associated with any of the foregoing.

15.06 Immediate Recourse. The Guarantor waives any right it may have of first requiring any Credit Party (or any trustee or agent on its behalf) to proceed against or enforce any other rights or security or claim payment from any person before claiming from the Guarantor under this Section 15. This waiver applies irrespective of any law or any provision of a Credit Document to the contrary.

15.07 Appropriations. Until all amounts which may be or become payable by the Credit Parties under or in connection with the Credit Documents have been irrevocably paid in full, each Lender Creditor (or any trustee or agent on its behalf) may:

(i) refrain from applying or enforcing any other moneys, security or rights held or received by that Lender Creditor (or any trustee or agent on its behalf) in respect of those amounts, or apply and enforce the same in such manner and order as it sees fit (whether against those amounts or otherwise) and the Guarantor shall not be entitled to the benefit of the same; and

(ii) hold in an interest-bearing suspense account any moneys received from the Guarantor or on account of the Guarantor’s liability under this Section 15.

15.08 Deferral of Guarantor’s Rights. Until all amounts which may be or become payable by the Credit Parties under or in connection with the Credit Documents have been irrevocably paid in full and unless the Facility Agent otherwise directs, the Guarantor will not exercise any rights which it may have by reason of performance by it of its obligations under the Credit Documents or by reason of any amount being payable, or liability arising, under this Section 15:

(i) to be indemnified by a Credit Party;

(ii) to claim any contribution from any other guarantor of any Credit Party’s obligations under the Credit Documents;

(iii) to take the benefit (in whole or in part and whether by way of subrogation or otherwise) of any rights of the Lender Creditors under the Credit Documents or of any other guarantee or security taken pursuant to, or in connection with, the Credit Documents by any Lender Creditor;

(iv) to bring legal or other proceedings for an order requiring any Credit Party to make any payment, or perform any obligation, in respect of which the Guarantor has given a guarantee, undertaking or indemnity under Section 15.01;

(v) to exercise any right of set-off against any Credit Party; and/or

 

-102-


(vi) to claim or prove as a creditor of any Credit Party in competition with any Lender Creditor.

If the Guarantor receives any benefit, payment or distribution in relation to such rights it shall hold that benefit, payment or distribution to the extent necessary to enable all amounts which may be or become payable to the Lender Creditors by the Credit Parties under or in connection with the Credit Documents to be repaid in full on trust for the Lender Creditors and shall promptly pay or transfer the same to the Facility Agent or as the Facility Agent may direct for application in accordance with Section 4.

15.09 Additional Security. This guarantee is in addition to and is not in any way prejudiced by any other guarantee or security now or subsequently held by any Credit Party.

*    *    *

 

-103-


IN WITNESS WHEREOF, the parties hereto have caused their duly authorized officers to execute and deliver this Agreement as a deed on the date first above written.

Signed as a deed and delivered on behalf of NCL CORPORATION LTD., a Bermuda company, as Parent and Guarantor, by [full name of person signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the company under a power of attorney dated [    ], 2010

 

By:  

/s/ Authorized Signatory

  Title:
Authorized signatory

Signed as a deed and delivered on behalf of PRIDE OF HAWAII, LLC, a Delaware limited liability company, as Borrower, by [full name of person signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the company under a power of attorney dated [    ], 2010

 

By:  

/s/ Authorized Signatory

  Title:
Authorized signatory


Signed as a deed and delivered on behalf of KFW IPEX-BANK GMBH, a bank organized under the laws of Germany, individually and as Facility Agent, Collateral Agent and a Joint Lead Arranger, by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


Signed as a deed and delivered on behalf of NORDEA BANK NORGE ASA, a bank organized under the laws of Norway, individually and as Documentation Agent and a Joint Lead Arranger by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


Signed as a deed and delivered on behalf of DNB NOR BANK ASA, a bank organized under the laws of Norway, individually and as a Joint Lead Arranger, by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


Signed as a deed and delivered on behalf of DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, a bank organized under the laws of Germany, individually and as a Joint Lead Arranger, by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


Signed as a deed and delivered on behalf of HSBC BANK PLC, a bank organized under the laws of England, individually and as a Joint Lead Arranger, by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


Signed as a deed and delivered on behalf of COMMERZBANK AKTIENGESELLSCHAFT, a bank organized under the laws of Germany, as Hermes Agent, by [full name of persons signing], being a person who, in accordance with the laws of that territory, is acting under the authority of the bank

 

By:  

/s/ Authorized Signatory

  Title:
By:  

/s/ Authorized Signatory

  Title:
Authorized signatories


SCHEDULE 1.01(a)

COMMITMENTS

 

Lender

   Commitments      Percentage  

Deutsche Schiffsbank Aktiengesellschaft

     € [*]         [*]   

DnB NOR Bank ASA

     € [*]         [*]   

HSBC Bank plc

     € [*]         [*]   

KfW IPEX-Bank GmbH

     € [*]         [*]   

Nordea Bank Norge ASA

     € [*]         [*]   

Total

   126,075,000         100
                 


SCHEDULE 1.01(b)

EXISTING JADE SCHEDULED REPAYMENTS

 

Date

   Jade
Availability
 

April 19, 2011

   $ 18,599,000   

October 19, 2011

   $ 18,599,000   

April 19, 2012

   $ 18,599,000   

October 19, 2012

   $ 18,599,000   

April 19, 2013

   $ 18,599,000   

October 21, 2013

   $ 18,599,000   

April 19, 2014

   $ 18,599,000   


SCHEDULE 1.01(c)

MANDATORY COSTS

 

1. The Mandatory Cost is an addition to the interest rate to compensate Lenders for the cost of compliance with (a) the requirements of the Bank of England and/or the Financial Services Authority (or, in either case, any other authority which replaces all or any of its functions) or (b) the requirements of the European Central Bank.

 

2. On the first day of each Interest Period (or as soon as possible thereafter) the Facility Agent shall calculate, as a percentage rate, a rate (the “Additional Cost Rate”) for each Lender, in accordance with the paragraphs set out below. The Mandatory Cost will be calculated by the Facility Agent as a weighted average of the Lenders' Additional Cost Rates (weighted in proportion to the percentage participation of each Lender in the relevant Loan) and will be expressed as a percentage rate per annum.

 

3. The Additional Cost Rate for any Lender lending from a Facility Office in a Participating Member State will be the percentage notified by that Lender to the Facility Agent. This percentage will be certified by that Lender in its notice to the Facility Agent to be its reasonable determination of the cost (expressed as a percentage of that Lender's participation in all Loans made from that Facility Office) of complying with the minimum reserve requirements of the European Central Bank in respect of loans made from that Facility Office.

 

4. The Additional Cost Rate for any Lender lending from a Facility Office in the United Kingdom will be calculated by the Facility Agent as follows:

in relation to a sterling Loan:

[*] per cent. per annum

in relation to a Loan in any currency other than sterling:

[*] per cent. per annum.

Where:

 

  A is the percentage of Eligible Liabilities (assuming these to be in excess of any stated minimum) which that Lender is from time to time required to maintain as an interest free cash ratio deposit with the Bank of England to comply with cash ratio requirements.

 

  B is the percentage rate of interest (excluding the Applicable Margin and the Mandatory Cost and, if the Loan is an Unpaid Sum, the additional rate of interest specified in paragraph (b) of Section 2.06 payable for the relevant Interest Period on the Loan.


SCHEDULE 1.01(c)

 

  C is the percentage (if any) of Eligible Liabilities which that Lender is required from time to time to maintain as interest bearing Special Deposits with the Bank of England.

 

  D is the percentage rate per annum payable by the Bank of England to the Facility Agent on interest bearing Special Deposits.

 

  E is designed to compensate Lenders for amounts payable under the Fees Rules and is calculated by the Facility Agent as being the average of the most recent rates of charge supplied by the Reference Banks to the Facility Agent pursuant to paragraph 7 below and expressed in pounds per £1,000,000.

 

5. For the purposes of this Schedule:

Eligible Liabilities” and “Special Deposits” have the meanings given to them from time to time under or pursuant to the Bank of England Act 1998 or (as may be appropriate) by the Bank of England;

Fees Rules means the rules on periodic fees contained in the Financial Services Authority Fees Manual or such other law or regulation as may be in force from time to time in respect of the payment of fees for the acceptance of deposits;

Fee Tariffs” means the fee tariffs specified in the Fees Rules under Column 1 of the activity group A.1 Deposit acceptors (ignoring any minimum fee or zero rated fee required pursuant to the Fees Rules but taking into account any applicable discount rate);

Participating Member State” means any member state of the European Communities that adopts or has adopted the euro as its lawful currency in accordance with legislation of the European Community relating to Economic and Monetary Union.

Tariff Base” has the meaning given to it in, and will be calculated in accordance with, the Fees Rules; and

Unpaid Sum” means any sum due and payable but unpaid by any Credit Party under the Credit Documents.

 

6. In application of the above formulae, A, B, C and D will be included in the formulae as percentages (i.e. 5 per cent. will be included in the formula as 5 and not as 0.05). A negative result obtained by subtracting D from B shall be taken as zero. The resulting figures shall be rounded to four decimal places.

 

7.

If requested by the Facility Agent, each Reference Bank shall, as soon as practicable after publication by the Financial Services Authority, supply to the Facility Agent, the rate of charge payable by that Reference Bank to the Financial Services Authority pursuant to the Fees Rules in respect of the relevant financial year of the Financial Services Authority


SCHEDULE 1.01(c)

 

(calculated for this purpose by that Reference Bank as being the average of the Fee Tariffs applicable to that Reference Bank for that financial year) and expressed in pounds per £1,000,000 of the Tariff Base of that Reference Bank.

 

8. Each Lender shall supply any information required by the Facility Agent for the purpose of calculating its Additional Cost Rate. In particular, but without limitation, each Lender shall supply the following information on or prior to the date on which it becomes a Lender:

 

  a) the jurisdiction of its Facility Office; and

 

  b) any other information that the Facility Agent may reasonably require for such purpose.

Each Lender shall promptly notify the Facility Agent of any change to the information provided by it pursuant to this paragraph.

 

9. The percentages of each Lender for the purpose of A and C above and the rates of charge of each Reference Bank for the purpose of E above shall be determined by the Facility Agent based upon the information supplied to it pursuant to paragraphs 7 and 8 above and on the assumption that, unless a Lender notifies the Facility Agent to the contrary, each Lender’s obligations in relation to cash ratio deposits and Special Deposits are the same as those of a typical bank from its jurisdiction of incorporation with a Facility Office in the same jurisdiction as its Facility Office.

 

10. The Facility Agent shall have no liability to any person if such determination results in an Additional Cost Rate which over or under compensates any Lender and shall be entitled to assume that the information provided by any Lender or Reference Bank pursuant to paragraphs 3, 7 and 8 above is true and correct in all respects.

 

11. The Facility Agent shall distribute the additional amounts received as a result of the Mandatory Cost to the Lenders on the basis of the Additional Cost Rate for each Lender based on the information provided by each Lender and each Reference Bank pursuant to paragraphs 3, 7 and 8 above.

 

12. Any determination by the Facility Agent pursuant to this Schedule in relation to a formula, the Mandatory Cost, an Additional Cost Rate or any amount payable to a Lender shall, in the absence of manifest error, be conclusive and binding on all parties to the Credit Agreement.

 

13.

The Facility Agent may from time to time, after consultation with the Parent and the Lenders, determine and notify to all parties to the Credit Agreement any amendments which are required to be made to this Schedule in order to comply with any change in law,


SCHEDULE 1.01(c)

 

regulation or any requirements from time to time imposed by the Bank of England, the Financial Services Authority or the European Central Bank (or, in any case, any other authority which replaces all or any of its functions) and any such determination shall, in the absence of manifest error, be conclusive and binding on all parties to the Credit Agreement.


SCHEDULE 5.06

NOTICES, ACKNOWLEDGMENTS AND CONSENTS

Notices

1. Notice of Assignment of the Construction Contract for Breakaway One, Ltd. in the form of Part 1 of Schedule 1 to the Vessel 1 Assignment of Contracts shall be delivered to the Yard.

2. Notice of Assignment of the Construction Contract for Breakaway Two, Ltd. in the form of Part 1 of Schedule 1 to the Vessel 2 Assignment of Contracts shall be delivered to the Yard.

3. Notice of Assignment of the Refund Guarantees for Breakaway One, Ltd. in the form of either (x) Part 2 of Schedule 1 to the Vessel 1 Assignment of Contracts or (y) Schedule 1 to the Vessel 1 Assignment of KfW Refund Guarantee, as applicable, shall be delivered to the applicable issuer of Refund Guarantee(s) issued on or prior to the Initial Borrowing Date (under and as defined in the Breakaway One Facility).

4. Notice of Assignment of the Refund Guarantees for Breakaway Two, Ltd. in the form of either (x) Part 2 of Schedule 1 to the Vessel 2 Assignment of Contracts or (y) Schedule 1 to the Vessel 2 Assignment of KfW Refund Guarantee, as applicable, shall be delivered to the applicable issuer of Refund Guarantee(s) issued on or prior to the Initial Borrowing Date (under and as defined in the Breakaway Two Facility).

Financing Statements

1. UCC-1 shall be filed with the Florida Secured Transaction Registry naming Breakaway One, Ltd. as Debtor and KfW IPEX-Bank GmbH in its capacity as Collateral Agent, as Secured Party.

2. UCC-1 shall be filed with the Florida Secured Transaction Registry naming Breakaway Two, Ltd. as Debtor and KfW IPEX-Bank GmbH in its capacity as Collateral Agent, as Secured Party.

3. UCC-1 shall be filed with the Secretary of State for the State of Delaware naming Pride of Hawaii, LLC as Debtor and KfW IPEX-Bank GmbH in its capacity as Collateral Agent, as Secured Party.


SCHEDULE 5.12

INITIAL BORROWING DATE OPINIONS

 

1. Pursuant to Section 5.12(a) and subject to the assumptions, qualifications and definitions set forth in such opinion, O’Melveny & Myers, Counsel to the Credit Parties opine as follows (capitalized terms used in this Clause 1 have the meanings ascribed to them in such opinion):

 

  A. The Borrower is a limited liability company existing under the laws of Delaware, with power under the Delaware Limited Liability Company Act (the “Delaware LLC Act”) and its certificate of formation and limited liability company agreement (its “LLC Organizational Documents”) to enter into each of the Transaction Documents to which it is a party, and to perform its obligations thereunder.

 

  B. The execution, delivery and performance by the Borrower of each of the Transaction Documents to which it is a party have been duly authorized by all necessary action under the Delaware LLC Act and its LLC Organizational Documents on the part of the Borrower.

 

  C. The Power of Attorney has been duly executed and delivered by the Borrower.

 

  D.

Certain of the Transaction Documents provide that they are to be governed by English law. To the extent that such Transaction Documents are governed by English law or the law of any other jurisdiction, we express no opinion as to those laws or their applicability to matters covered by this opinion, nor do we express any opinion as to whether or not New York law is applicable to such Transaction Documents. However, we are of the opinion that if the Transaction Documents were governed (or are actually governed, as the case may be) by the laws of the state of New York (without reference to New York choice of law principles that would result in the application of the laws of another jurisdiction), the execution and delivery by each Credit Party of each Transaction Document to which it is a party do not, and each Credit Party’s performance of its obligations under each Transaction Document to which it is a party will not, violate, breach, or constitute a default, or result in the creation or imposition of any lien, charge or encumbrance (other than the liens, charges or encumbrances under the Transaction Documents) upon any of the assets of such Credit Party or give any other party thereto the right to accelerate under, any existing obligation or restriction on such Credit Party under any other agreement (the “Other Agreements”) listed in Schedule I to the Officer’s Certificate. If any Other Agreement is governed by the laws of a jurisdiction other than the state of New York, we have assumed such Other Agreement would be interpreted in accordance with its plain meaning, except that technical terms would mean what lawyers generally understand them to mean for agreements governed by the laws of the state of New York. We express no opinion with respect to any provision of any


SCHEDULE 5.12

 

Other Agreement to the extent that an opinion with respect to such provision would require making any financial, accounting or mathematical calculation or determination.

 

  E. The execution and delivery by the Borrower of the Transaction Documents to which it is a party do not, and the Borrower’s performance of its obligations under each such Transaction Document will not, violate the current Delaware LLC Act or any current federal statute, rule or regulation that we have, in the exercise of customary professional diligence, recognized as applicable to the Borrower or to transactions of the type contemplated by the Transaction Documents.

 

  F. Upon the filing of the Delaware UCC Financing Statements with the Secretary of State of the State of Delaware (the “Delaware Filing Office”), the Facility Agent will have a perfected security interest in the Borrower’s interest in the Earnings (as defined in the Assignment of Earnings) in which a security interest may be perfected under Delaware Article 9 (as defined below) by the filing of a financing statement in the State of Delaware.

 

  (a) No order, consent, permit or approval of any federal governmental authority that we have, in the exercise of customary professional diligence, recognized as applicable to transactions of the type contemplated by the Transaction Documents is required on the part of the Borrower for the execution and delivery of, and performance of its obligations under, the Transaction Documents.

 

2. Pursuant to Section 5.12(b) and subject to the assumptions, qualifications and definitions set forth in such opinion, CAINS Advocates Limited, special Isle of Man counsel to the Borrower, opines as follows (capitalized terms used in this Clause 2 have the meanings ascribed to them in such opinion):

Status

The Borrower is a company limited by shares duly incorporated and validly existing under the laws of the Isle of Man and possesses the capacity to sue and to be sued in its own name.

No Liquidator or Receiver

As far as was shown on the Search Date on the file of the Borrower maintained by the Registrar, no steps have been or are being taken to appoint a receiver, liquidator or analogous person or body over or to wind up or dissolve the Borrower or to take analogous action.


SCHEDULE 5.12

 

Capacity

The Borrower has the corporate capacity to execute, deliver and perform its obligations under the Documents.

Authority

The Borrower has passed all necessary resolutions and taken all necessary corporate actions to authorise the execution, delivery and performance of each of the Documents and to incur the obligations referred to therein, and each of the Documents has been validly executed by and on behalf of the Borrower.

Authority and Due Execution

The Documents have been executed by duly authorised representatives of the Borrower and constitute legal, valid and binding obligations of the Borrower enforceable in accordance with their respective terms and conditions.

Approvals and Consents

No authorisations, approvals and consents (including without limitation any exchange control consents) from any governmental or other authorities in the Isle of Man are required to be obtained by the Borrower in relation to the execution and delivery by it of the Documents or the exercise of its rights and the performance of its obligations thereunder or to make the Documents admissible in evidence in the Isle of Man.

Non Conflict

The execution, delivery and performance of the Documents by the Borrower does not and will not:

(i) contravene any existing law or regulation of the Isle of Man to which it is subject; or

(ii) contravene any provision of the Borrower’s Memorandum and Articles of Association.

Filings and Registrations

In order not to be void against the liquidator and any creditor of the Borrower, each of the Security Documents should be delivered to the Registrar (together with the prescribed particulars) within one month of the date of its creation (pursuant to Section 138 of the Act); save for such delivery, it is not necessary or advisable under the laws of the Isle of Man, in order to ensure the validity, effectiveness and enforceability of the Documents, that the same be filed, registered or recorded in any public office in the Isle of Man or that any other action be taken.


SCHEDULE 5.12

 

Stamp and Registration Duties

The Documents do not give rise to any registration duty, stamp duty or similar duty in or imposed by the Isle of Man or any authority or agency thereof.

Immunity

The Borrower is subject to the jurisdiction of the Courts of the Isle of Man and is not entitled to claim any immunity from suit or execution of any judgment on the ground of sovereignty or otherwise.

Choice of Law

The choice of law provision in each of the Documents (save for the Mortgage) (providing for the same to be governed and construed in accordance with the laws of England) is a valid and binding obligation of the Borrower and will be recognised by the Courts of the Isle of Man as the proper law of the Documents.

Submission to Jurisdiction

The submission by the Borrower to the jurisdiction of the Courts of England contained in each of the Documents (save for the Mortgage) is a valid submission and is binding on the Borrower.

Enforcement of English Judgment

Any judgment for a fixed sum of money obtained against the Borrower in the High Court of England will be enforceable against it in the Isle of Man provided that such judgment is final and conclusive and was not obtained by fraud or contrary to public policy of the Isle of Man at the time or contrary to the rules of natural justice in the Isle of Man at the time and provided that the correct procedures under the laws of the Isle of Man (including registration of the English judgment with the Isle of Man Courts) are complied with.

Enforcement of Bahamian Judgment

There is no statutory procedure in the Isle of Man for the recognition or enforcement of judgments of the courts of the Bahamas. However, under Isle of Man common law, a foreign judgment in personam given by the court of a foreign country with jurisdiction to give that judgment may be recognised and enforced by an action for the amount due under it provided that the judgment: (i) is for a debt or definite sum of money (not being a sum payable in respect of taxes or other charges of a like nature or in respect of a fine or other penalty); (ii) is final and conclusive; (iii) was not obtained by fraud; (iv) is not one whose enforcement would be contrary to public policy in the Isle of Man; and (v) was not obtained in proceedings which were opposed to natural justice in the Isle of Man.

No Isle of Man Licensing Requirement

It is not necessary in order to enable the Lenders to claim and enforce in the Isle of Man any right afforded by the Documents, or by reason of the execution, delivery and


SCHEDULE 5.12

 

performance of the Documents by the Lenders, that the Lenders should be licensed, qualified or otherwise entitled to carry on business in or otherwise registered with any authority of or in the Isle of Man.

No Deemed Isle of Man Residence

The Lenders will not be deemed to be resident, domiciled or carrying on business in the Isle of Man by reason only of the execution, performance and/or enforcement of any of the Documents.

No Default Proceedings Revealed

As at the Search Date, our search of the Court Indices via the General Registry website in the Isle of Man did not reveal the existence of any default proceedings in the Isle of Man to which the Borrower is a party.

No Exchange Control

No foreign exchange control regulations are in existence in the Isle of Man in relation to the exchange and remittance of sterling or any other currency from the Isle of Man and no authorisations, approvals or consents will be required from any authority in the Isle of Man in relation to the exchange and remittance of sterling and any other currency whether awarded by reason of a judgment or otherwise falling due and having been paid in the Isle of Man in relation to any obligation set out in any of the Documents.

Isle of Man Withholding Tax

All payments made by the Borrower under the Documents may be made without deduction of any Isle of Man withholding tax.

 

3. Pursuant to Section 5.12(c) and subject to the assumptions, qualifications and definitions set forth in such opinion, Cox Hallett Wilkinson, special Bermuda counsel to the Credit Parties, opines as follows (capitalized terms used in this Clause 3 have the meanings ascribed to them in such opinion):

 

  (a) Each of the Parent, Breakaway One and Breakaway Two (for the purpose of this Clause 3 of Schedule 5.12 only, the “Companies) is duly incorporated with limited liability and is existing and in good standing under the laws of Bermuda (meaning that it has not failed to make any filing with any Bermuda governmental authority or to pay any Bermuda government fee or tax which might make it liable to be struck off the Register of Companies and thereby cease to exist under the laws of Bermuda).

 

  (b) The entering into of the relevant Opinion Documents and the execution and delivery of the relevant Opinion Documents by each of the Companies and the performance by each of the Companies of its obligations thereunder:

 

  (i) are within its corporate powers and have been duly authorised; and


SCHEDULE 5.12

 

  (ii) will not conflict with the memorandum of association or bye-laws of such Company or violate or result in the breach of any Bermuda law or regulation.

 

  (c) Each of the Opinion Documents has been duly executed by the Companies party thereto and constitutes legal, valid and binding obligations of such Companies, enforceable in Bermuda in accordance with its terms.

 

  (d) Based solely on the Litigation Searches, there are no judgments against, nor legal or governmental actions or proceedings pending in Bermuda to which any of the Companies is subject.

 

  (e) Based solely on the Company Searches, there are no notices to the Registrar of the passing of a resolution of members or creditors to wind up any of the Companies and no notice appointing a liquidator or receiver has been provided to the Registrar.

 

  (f) No authorisation, consent, approval, license, qualification or formal exemption from, or any filing, declaration or registration with any court, governmental or municipal authority or other public body of Bermuda is required in connection with the execution and delivery of the Opinion Documents, the performance by each of the Companies of its obligations under the relevant Opinion Documents, the enforceability or admissibility in evidence of the Opinion Documents.

 

  (g) It is not necessary or desirable to ensure the enforceability in Bermuda of the Opinion Documents that they be registered in any register kept by, or filed with, any governmental or municipal authority or other public or regulatory body in Bermuda. However, on the basis that each of the Security Documents creates a charge over assets of the relevant Companies, it is desirable, in order to ensure the priority in Bermuda of the charge created, that such document be registered in the Register of Charges in accordance with Section 55 of the Act. On registration, to the extent that Bermuda law governs the priority of a charge, such charge will have priority in Bermuda over any unregistered charges, and over any subsequently registered charges, in respect of the property subject to such charge. A registration fee will be payable in respect of the registration.

 

  (h) The Opinion Documents will not be subject to ad valorem stamp duty, registration, recording, filing or other fees, duties or taxes in Bermuda and no such fees, duties or taxes are payable in Bermuda in connection with the execution, delivery or performance of the Opinion Documents.

 

  (i) The choice of the English Laws as the governing law of the Opinion Documents is a valid choice of law and the submission by the Companies to the exclusive jurisdiction of the English Courts is valid and binding upon the Companies and would be recognised and given effect to in any action brought before a court of competent jurisdiction in Bermuda, except for those laws:

 

  (i) which such court considers to be procedural in nature;


SCHEDULE 5.12

 

  (ii) which are revenue or penal laws; or

 

  (iii) the application of which would be inconsistent with public policy, as such term is interpreted under the laws of Bermuda.

 

  (j) The payment obligations of the Companies under the Opinion Documents are direct, general and unconditional obligations of such Company and rank at least pari passu with all other present or future unsecured and unsubordinated indebtedness of such Company other than indebtedness which is preferred by virtue of any provision of the laws of Bermuda of general application.

 

  (k) None of the Companies nor any of their respective assets are entitled to immunity from suit, execution, attachment of legal process under the laws of Bermuda, whether characterised as sovereign immunity or otherwise from any legal action or proceeding in Bermuda (which shall include, without limitation, suit, attachment prior to judgment, execution or other enforcement).

 

  (l) No Bermuda taxes are imposed by withholding or otherwise on any payment to be made by any of the Companies under the relevant Opinion Documents or are imposed on or by virtue of the execution or delivery by the Companies of the Opinion Documents or any document or instrument to be executed or delivered under the Opinion Documents.

 

  (m) The courts of Bermuda will recognise as a valid judgment any final and conclusive judgment obtained against the Companies by any party to the Opinion Documents based upon such document in the English Courts under which a sum of money is payable (other than a sum of money payable in respect of taxes or other charges of a like nature or in respect of a fine or other penalty or multiple damages as defined in the Protection of Trading Interests Act 1981) and such a judgment will be enforced by the Supreme Court of Bermuda under The Judgments (Reciprocal Enforcement) Act 1958 (the “1958 Act”) without re-examination of the merits of the case provided that:

 

  (i) the judgment is final and conclusive notwithstanding that an appeal may be pending against it or that it may still be subject to an appeal in the relevant jurisdiction;

 

  (ii) the judgment has not been given on appeal from a court which is not a superior court; and


SCHEDULE 5.12

 

  (iii) the judgment is duly registered in the Supreme Court of Bermuda in circumstances in which its registration is not liable thereafter to be set aside.

 

  (n) Under Section 3 of the 1958 Act, the registration of the judgment of the English Courts in the Supreme Court of Bermuda involves the conversion of the judgment debt into Bermuda Dollars at the date of such court’s judgment. However, the Bermuda Monetary Authority has indicated that its present policy is to give the consent necessary for the Bermuda dollar award made by the Supreme Court of Bermuda to be converted into external currency. No stamp duty or similar or other tax or duty is payable in Bermuda on the enforcement of a foreign judgment. Court fees will be payable in connection with proceedings for enforcement.

 

  (o) No party to the Opinion Documents will be deemed to be resident, domiciled, carrying on business or subject to taxation in Bermuda by reason only of the negotiation, preparation, execution, performance, enforcement of, and or receipt of any payment due from the Companies under the relevant Opinion Documents.

 

  (p) It is not necessary under the laws of Bermuda:

 

  (i) in order to enable any party to enforce its rights under the Opinion Documents; or

 

  (ii) by reason of the execution, delivery and performance of the Opinion Documents by the parties thereto,

that such persons should be licensed, qualified or otherwise entitled to carry on business in Bermuda.

 

4. Pursuant to Section 5.12(d) and subject to the assumptions, qualifications and definitions set forth in such opinion, White & Case LLP (London Office), special English counsel to the Documentation Agent for the benefit of the Joint Lead Arrangers opines as follows (capitalized terms used in this Clause 4 have the meanings ascribed to them in such opinion):

 

  (b) the obligations expressed to be assumed by each of the Borrower, the Parent and the ECF Borrowers in the Credit Documents to which it is a party constitute its valid, legally binding and enforceable obligations;

 

  (c) there is no requirement under English law for the consent or authorisation of, or the filing, recording or enrolment of any documents with, any court or other authority in England and Wales to be obtained or made in order to ensure the legality, validity, enforceability or admissibility in evidence of the Credit Documents;


SCHEDULE 5.12

 

  (d) English courts of competent jurisdiction will give effect to the choice of English law as the proper law of the Credit Documents and will regard express submission by the Borrower, the Parent and each of the ECF Borrowers to the jurisdiction contained in the Credit Documents as sufficient to confer jurisdiction upon them over proceedings within the scope of the submission;

 

  (e) no stamp duty or similar tax is payable in the United Kingdom in respect of the execution or delivery of the Credit Documents;

 

  (f) neither the Construction Contracts nor the Refund Guarantees contain any restrictions which prevent them from being assigned to, or charged in favour of, the Collateral Agent; and

 

  (g) the Assignments of Contract are effective to create valid security interests in favour of the Collateral Agent.

 

5. Pursuant to Section 5.12(e) and subject to the assumptions, qualifications and definitions set forth in such opinion, White & Case LLP (Hamburg Office) special German counsel to the Documentation Agent for the benefit of the Joint Lead Arrangers opine as follows (capitalized terms used in this Clause 5 have the meanings ascribed to them in such opinion):

The Declaration of Guarantee constitutes a valid and legally binding guarantee of the Federal Republic of Germany towards [•] subject to the specific provisions set out in the Declaration of Guarantee and subject to the applicable General Terms and Conditions and Guidelines.

 

6. Pursuant to Section 5.12(f) and subject to the assumptions, qualifications and definitions set forth in such opinion, Graham Thompson & Co., special Bahamas counsel to the Credit Parties opine as follows (capitalized terms used in this Clause 6 have the meanings ascribed to them in such opinion):

 

  (a) Under the laws of The Bahamas the Borrower is the registered owner of record of sixty-four sixty-fourth shares, being the whole thereof of the Norwegian Jade and the Norwegian Jade Mortgage constitutes the valid and legally binding act of the Borrower and the Norwegian Jade Mortgage is enforceable in accordance with its terms, and further, the Norwegian Jade Mortgage creates in favour of the Mortgagee a valid and effective fourth priority legal mortgage over the Norwegian Jade and there are no other charges, mortgages or encumbrances on record with respect thereto. It should be noted that maritime liens as set out in Section 281 of The Merchant Shipping Act of The Bahamas have priority over mortgages even if such liens are incurred after a mortgage has been registered.

 

  (b) No further registration authorization, approval or consent or other official action in The Bahamas is necessary to render any of the Documents or the security respectively created thereby valid, perfected and enforceable.


SCHEDULE 5.12

 

  (c) All filing, registration and recording fees required under the laws of The Bahamas in connection with the Norwegian Jade Mortgage and other fees necessary to ensure the validity, effectiveness and priority of any liens, charges and encumbrances created under the Norwegian Jade Mortgage have been paid.

 

  (d) The courts of The Bahamas will recognize as a valid judgment and enforce any final, conclusive and enforceable judgment obtained against a mortgagor in a United Kingdom court without re-examination of the merits of the case subject to registration of the judgment under the provisions of the Reciprocal Enforcements of Judgments Act of the Bahamas.

 

  (e) The Norwegian Jade Mortgage constitutes the legal, valid and binding obligations of the Borrower and is enforceable in accordance with their respective terms.

 

  (f) No consents, authorizations or other approvals are required from any governmental or other authority of The Bahamas for the execution, delivery or performance of any of the Documents by any of the parties thereto or the consummation of the transactions contemplated therein.

 

  (g) Neither the execution nor delivery of the Documents by the Borrower, nor the performance of its obligations under the Documents, will contravene any existing applicable law or regulation of The Bahamas.

 

  (h) The Borrower is not entitled or required under any existing applicable law or regulation of The Bahamas to make any withholding or deduction in respect of any tax or otherwise from any payment which it is or may be required to make under the Documents (or any of them) and other than the fees paid in connection with the registration of the Norwegian Jade Mortgage no tax, impost, duty or registration fee is payable on any of the Documents in The Bahamas save for registration fees on the Norwegian Jade Mortgage.

 

  (i) Other than the fees paid in connection with the registration of the Norwegian Jade Mortgage, no stamp or registration duty or similar taxes or charges are payable in The Bahamas in respect of the Documents.

 

  (j) Under the laws of The Bahamas, the Mortgagee will not be deemed to be resident, domiciled or carrying on any commercial activity in The Bahamas or subject to any tax of The Bahamas as a result of its entry into the Documents or the performance of any of the transactions contemplated thereby. It is not necessary for the Mortgagee to be authorized or qualified to carry on business in The Bahamas or establish a place of business in The Bahamas for the entry into or performance of the Documents.

 

  (k) It is not necessary or advisable to take any further action in the future in order to preserve the security interests referred to above or the priority thereof in connection with the Norwegian Jade Mortgage.


SCHEDULE 5.12

 

7. Pursuant to Section 5.12(g) and subject to the assumptions, qualifications and definitions set forth in such opinion, Holland & Knight, special Florida Counsel to the Credit Parties as follows (capitalized terms used in this Clause 7 have the meanings ascribed to them in such opinion):

To the extent that a security interest in the Collateral can be perfected by filing a UCC-1 financing statement in the State of Florida, perfection would occur by filing such financing statement with the office described in Annex 2 to the opinion. Note that, if the debtor purporting to grant such security interest changes the location of its chief executive office to another location, the effectiveness of the Financing Statements will cease on the expiration of four months after such change or, if earlier, when perfection would have otherwise ceased, unless such security interest becomes perfected under the law of such other location prior to such expiration.


SCHEDULE 6.10

MATERIAL LITIGATION

None.


SCHEDULE 8.03

EXISTING AGREEMENTS

None.


SCHEDULE 8.12

CAPITALIZATION

 

Credit Party

  

Owner

   Type of
Shares
   Number of
Shares

Owned
     Percent of
Outstanding
Shares Owned
 

Norwegian Jewel Limited

   NCL International, Ltd.    Ordinary      2         100

NCL International, Ltd.

   Arrasas Limited    Ordinary      12,000         100

Arrasas Limited

   NCL Corporation Ltd.    Common      997,218,181         100

Breakaway Two, Ltd.

   NCL International, Ltd.    Ordinary      12,000         100

Breakaway One, Ltd.

   NCL International, Ltd.    Ordinary      12,000         100


SCHEDULE 8.13

SUBSIDIARIES

 

Name of Subsidiary

  

Direct Owner(s)

   Percent(%)
Ownership
   Jurisdiction of
Organization

Arrasas Limited

   NCL Corporation Ltd.    100    Isle of Man

Breakaway One, Ltd.

   NCL International, Ltd.    100    Bermuda

Breakaway Two, Ltd.

   NCL International, Ltd.    100    Bermuda

Maritime Investment, LLC

   NCL America Holdings, LLC    100    Delaware

NCL America Holdings, LLC

   Arrasas Limited    100    Delaware

NCL America LLC

   NCL America Holdings, LLC    100    Delaware

NCL (Bahamas) Ltd.

   NCL International, Ltd.    100    Bermuda

NCL Cruises Ltd.

   NCL Holding ASA    100    Bermuda

NCL Holding ASA1

   Arrasas Limited    100    Norway

NCL International, Ltd.

   Arrasas Limited    100    Bermuda

Norwegian Dawn Limited

   NCL International, Ltd.    100    Isle of Man

Norwegian Epic, Ltd.

   NCL International, Ltd.    100    Bermuda

Norwegian Gem, Ltd.

   NCL International, Ltd.    100    Bermuda

Norwegian Jewel Limited

   NCL International, Ltd.    100    Isle of Man

Norwegian Pearl, Ltd.

   NCL International, Ltd.    100    Bermuda

Norwegian Spirit, Ltd.

   NCL International, Ltd.    100    Bermuda

Norwegian Star Limited

   NCL International, Ltd.    100    Isle of Man

Norwegian Sun Limited

   NCL International, Ltd.    100    Bermuda

PAT Tours, LLC

   NCL America Holdings, LLC    100    Delaware

Polynesian Adventure Tours, LLC

   NCL America Holdings, LLC    100    Hawaii

 

1

This company is under voluntary liquidation.


SCHEDULE 8.13

 

Name of Subsidiary

  

Direct Owner(s)

   Percent(%)
Ownership
   Jurisdiction of
Organization

Pride of America Ship Holding, LLC

   NCL America Holdings, LLC    100    Delaware

Pride of Hawaii, LLC

   NCL America Holdings, LLC    100    Delaware


SCHEDULE 8.19

COLLATERAL VESSEL

 

Vessel Name

  

Vessel Owner

   Vessel IMO Number    Flag and Registry

Norwegian Jade

   Pride of Hawaii, LLC    9304057    Bahamas


SCHEDULE 8.21

APPROVED CLASSIFICATION SOCIETIES

American Bureau of Shipping

Nippon Kaiji Kyokai

Germanischer Lloyd

Lloyd’s Register of Shipping

Bureau Veritas

Det Norske Veritas


SCHEDULE 9.03

REQUIRED INSURANCE

1. For the purpose of this Schedule 9.03, the following terms shall have the meanings ascribed to them as follows:

Compulsory Acquisition Compensation” shall mean all moneys or other compensation whatsoever payable by reason of the compulsory acquisition of the Collateral Vessel other than by requisition for hire;

Insurances” shall mean all policies and contracts of the insurance and entries of the Collateral Vessel in a protection and indemnity or war risks association which are effected in respect of the Collateral Vessel, its freight, disbursements, profits or otherwise and all benefits, including all claims and returns of premiums thereunder and shall also include all Compulsory Acquisition Compensation;

Security Period” shall mean that period from the Delivery Date until the date on which all Loans shall have been fully paid, satisfied and extinguished.

Total Loss” shall mean any actual or constructive or arranged or agreed or compromised total loss or compulsory acquisition of the Collateral Vessel (excluding any requisition for hire).

2. The Borrower shall insure the Collateral Vessel, or procure that the Collateral Vessel is insured, in its name and keep the Collateral Vessel and procure that the Collateral Vessel is kept insured on an agreed value basis for an amount in Dollars approved by the Collateral Agent, provided that:

(a) the insured value of the Collateral Vessel shall at all times be equal to or greater than its fair market value,

(b) the insured value of the Collateral Vessel shall be equal to or greater than [*] of the then applicable Total Commitment, and

(c) the hull and machinery insured value for the Collateral Vessel shall at all times be equal to no less than [*] of the total insured value of the Collateral Vessel and no more than [*] of the total insured value of the Collateral Vessel shall consist of hull interest and freight interest insurance

through internationally recognized independent first class insurance companies, underwriters, war risks and protection and indemnity associations reasonably acceptable to the Collateral Agent in each instance on terms and conditions approved by the Collateral Agent (with such approval not to be unreasonably withheld) including as to deductibles but at least in respect of:

(1) marine risks including all risks customarily and usually covered by first-class and prudent shipowners in the London insurance markets under English marine policies, or the Norwegian Plan or Collateral Agent-approved policies containing the ordinary conditions applicable to similar vessels;


SCHEDULE 9.03

 

(2) war risks including the Missing Vessel Clause terrorism, piracy and confiscation, and, should Institute War and Strike Clauses, Hulls Conditions prevail, the London Blocking and Trapping Addendum and war risks (protection and indemnity) with a separate limit and in excess of the amount for war risks (hull);

(3) excess risks that is to say the proportion of claims for general average and salvage charges and under the running down clause not recoverable in consequence of the value at which the Collateral Vessel is assessed for the purpose of such claims exceeding the insured value;

(4) protection and indemnity risks with full standard coverage and up to the highest limit of liability available (for oil pollution risk the highest limit currently available is [*] for pollution risk and this to be increased if requested by the Collateral Agent and the increase is possible in accordance with the standard protection and indemnity cover for vessels of its type and is compatible with prudent insurance practice for first class cruise shipowners or operators in waters where the Collateral Vessel trades from time to time during the Security Period;

(5) when and while the Collateral Vessel is laid-up, in lieu of hull insurance, normal port risks;

(6) such other risks as the Collateral Agent may from time to time reasonably require;

and in any event in respect of those risks and at those levels covered by first class and prudent owners and/or financiers in the international market in respect of similar tonnage, provided that if any of such insurances are also effected in the name of any other person (other than the Borrower or the Collateral Agent) such person shall if so required by the Collateral Agent execute a preferred assignment and/or transfer of its interest in such insurances in favour of the Collateral Agent in similar terms mutatis mutandis to the Assignment of Insurances, provided further that the Borrower has first obtained the consent of the First Mortgagee, the Second Mortgagee and the Third Mortgagee (as each such term is defined in the Vessel Mortgage) to such an assignment.

3. The Collateral Agent at the cost of the Borrower or the Parent shall take out, in each case, for an amount in Dollars approved by the Collateral Agent but not being, collectively, less than [*] of the then applicable Total Commitment, mortgagee interest insurance and mortgagee additional perils insurance on such conditions as the Collateral Agent may reasonably require, the Parent and the Borrower having no interest or entitlement in respect of such policies; the Collateral Agent undertakes to use its reasonable endeavors to match the premium level that the Borrower or the Parent would have paid if they had arranged such cover on such conditions (as demonstrated to the reasonable satisfaction of the Collateral Agent).

4. If the Collateral Vessel shall trade in the United States of America and/or the Exclusive Economic Zone of the United States of America (the “EEZ”) as such term is defined in the US Oil Pollution Act 1990 (“OPA”), the Borrower shall comply strictly with the requirements of OPA and any similar legislation which may from time to time be enacted in any jurisdiction in which the Collateral Vessel presently trades or may or will trade at any time during the existence of the Vessel Mortgage and in particular before such trade is commenced and during the entire period during which such trade is carried on the Borrower shall:

(i) pay any additional premiums required to maintain protection and indemnity cover for oil pollution up to the limit available to it for the Collateral Vessel in the market;


SCHEDULE 9.03

 

(ii) make all such quarterly or other voyage declarations as may from time to time be required by the Collateral Vessel’s protection and indemnity association and to comply with all obligations in order to maintain such cover, and promptly to deliver to the Collateral Agent copies of such declarations;

(iii) submit the Collateral Vessel to such additional periodic, classification, structural or other surveys which may be required by the Collateral Vessel’s protection and indemnity insurers to maintain cover for such trade and promptly to deliver to the Collateral Agent copies of reports made in respect of such surveys;

(iv) implement any recommendations contained in the reports issued following the surveys referred to in sub-clause (iii) above within the time limit specified therein and provide evidence satisfactory to the Collateral Agent that the protection and indemnity insurers are satisfied that this has been done;

(v) in particular strictly comply with the requirements of any applicable law, convention, regulation, proclamation or order with regard to financial responsibility for liabilities imposed on the Borrower or the Collateral Vessel with respect to pollution by any state or nation or political subdivision thereof, including but not limited to OPA, and provide the Collateral Agent on demand with such information or evidence as it may reasonably require of such compliance;

(vi) procure that the protection and indemnity insurances do not contain a clause excluding the Collateral Vessel from trading in waters of the United States of America and the EEZ or any other provision analogous thereto and provide the Collateral Agent with evidence that this is so; and

(vii) strictly comply with any operational or structural regulations issued from time to time by any relevant authorities under OPA so that at all times the Collateral Vessel falls within the provisions which limit strict liability under OPA for oil pollution.

5. The Borrower shall give notice forthwith of any assignment and/or transfer of its interest in the Insurances to the relevant brokers, insurance companies, underwriters and/or associations in the form reasonably approved by the Collateral Agent.

6. The Borrower shall execute and deliver all such documents and do all such things as may be necessary to confer upon the Collateral Agent legal title to the Insurances in respect of the Collateral Vessel and to procure that the interest of the Collateral Agent is at all times filed with all slips, cover notes, policies and certificates of entry and to procure (a) that a loss payable clause in the form reasonably approved by the Collateral Agent and exceeding [*] shall be filed with all the hull, machinery and equipment and war risks policies in respect of the Collateral Vessel and (b) that a loss payable clause in the form reasonably approved by the Collateral Agent and exceeding [*] shall be endorsed upon the protection and indemnity certificates of entry in respect of the Collateral Vessel.

7. At the Borrower’s expense the Borrower will cause such insurance broker and the P & I club or association providing P & I insurance to agree to advise the Collateral Agent by telex or telecopier confirmed by letter of any expiration, termination, alteration or cancellation of any policy, any default in the payment of any premium and of any other act or omission on the part of the Borrower of which it has knowledge and which might invalidate or render unenforceable, in whole or in part, any insurance on the Collateral Vessel, and to provide


SCHEDULE 9.03

 

an opportunity of paying any such unpaid premium or call, such right being exercisable by the Collateral Agent on a vessel by vessel and not on a fleet basis. In addition, the Borrower or the Parent shall promptly provide the Collateral Agent with any information which the Collateral Agent reasonably requests for the purpose of obtaining or preparing any report from an independent marine insurance consultant as to the adequacy of the insurances effected or proposed to be effected in accordance with the provisions contained herein as of the date hereof or in connection with any renewal thereof, and the Borrower or the Parent shall upon demand indemnify the Collateral Agent in respect of all reasonable fees and other expenses incurred by or for the account of the Collateral Agent in connection with any such report; provided the Collateral Agent shall be entitled to such indemnity only for one such report during any period of twelve months.

8. The Borrower shall procure that each of the relevant brokers and associations furnish the Collateral Agent with a letter of undertaking in such usual form as may be reasonably required by the Collateral Agent and waives any lien for premiums or calls except in relation to premiums or calls attributable to the Collateral Vessel.

9. The Borrower shall punctually pay all premiums, calls, contributions or other sums payable in respect of the Insurances on the Collateral Vessel and to produce all relevant receipts when so required by the Collateral Agent;

10. The Borrower shall renew each of the Insurances on the Collateral Vessel at least [*] Business Days before the expiry thereof and give immediate notice to the Collateral Agent of such renewal and procure that the relevant brokers or associations shall promptly confirm in writing to the Collateral Agent that such renewal is effected, it being understood by the Borrower that any failure to renew the Insurances on the Collateral Vessel at least [*] Business Days before the expiry thereof or to give or procure the relevant notices of such renewal shall constitute an Event of Default.

11. The Borrower shall arrange for the execution of such guarantees as may from time to time be required by any protection and indemnity and/or war risks association.

12. The Borrower shall furnish to the Collateral Agent from time to time on request with full information about all Insurances maintained on the Collateral Vessel and the names of the offices, companies, underwriters, associations or clubs with which such Insurances are placed.

13. The Borrower shall not agree to any variation in the terms of any of the Insurances on the Collateral Vessel without the prior approval of the Collateral Agent (which approval shall not be unreasonably withheld) (save in circumstances where the variation is imposed by the insurers or reinsurers without requiring the Borrower’s consent, in which case the Borrower shall notify the Collateral Agent of such variation in a timely manner) nor do any act or voluntarily suffer or permit any act to be done whereby any Insurances shall or may be rendered invalid, void, voidable, suspended, defeated or unenforceable and not to suffer or permit the Collateral Vessel to engage in any voyage nor to carry any cargo not permitted under any of the Insurances without first obtaining the consent of the insurers or reinsurers concerned and complying with such requirements as to payment of extra premiums or otherwise as the insurers or reinsurers may impose. If a variation in the terms of the Insurances is imposed as aforesaid and in the absolute opinion of the Collateral Agent its interest in the Insurances is thereby


SCHEDULE 9.03

 

materially adversely affected and/or the proceeds of the Insurances payable to the Collateral Agent would be adversely affected, the Borrower undertakes promptly to make such changes to the Insurances, or such alternative Insurance arrangements, provided that such alternative Insurance arrangements are available in the insurance market to the Borrower at that time, as the Collateral Agent shall reasonably require.

14. The Borrower shall not, without the prior written consent of the Collateral Agent, settle, compromise or abandon any claim in respect of any of the Insurances on the Collateral Vessel other than a claim of less than [*] or the equivalent in any other currency and not being a claim arising out of a Total Loss.

15. The Borrower shall promptly furnish the Collateral Agent with full information regarding any casualties or other accidents or damage to the Collateral Vessel involving an amount in excess of [*].

16. The Borrower shall apply or ensure the appliance of all such sums receivable in respect of the Insurances on the Collateral Vessel for the purpose of making good the loss and fully repairing all damage in respect whereof the insurance moneys shall have been received.

17. In the event of the Borrower defaulting in insuring and keeping insured its Collateral Vessel as hereinbefore provided then the Collateral Agent may (but shall not be bound to) insure the Collateral Vessel or enter the Collateral Vessel in such manner and to such extent as the Collateral Agent in its discretion thinks fit and in such case all the cost of effecting and maintaining such Insurance together with interest thereon shall be paid on demand by the Borrower to the Collateral Agent.


SCHEDULE 10.01

EXISTING LIENS

None.


SCHEDULE 14.03A

CREDIT PARTY ADDRESSES

If to any Credit Party:

7665 Corporation Center Drive

Miami, Florida 33126

United States of America

Attn: Chief Financial Officer and General Counsel

With copies to:

Apollo Management, L.P.

9 West 57th Street

New York, NY 10019

Attn: Steve Martinez

Tel. No.: (212) 515-3200

Fax No.: (212) 515-3288

and

O’Melveny & Myers LLP

7 Times Square

New York, NY 10036

Attn: Brad Finkelstein

Tel. No.: (212) 326-2000

Fax No.: (212) 326-2600


SCHEDULE 14.03B

LENDER ADDRESSES

 

INSTITUTIONS    ADDRESSES
DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT   

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Telephone: +49 40 3769 -9646 / -9647

Facsimile: +49 40 3769 -9649

e-mail:      marcus.weber@commerzbank.com

                 anne.randewig@commerzbank.com

DNB NOR BANK ASA   

Stranden 21

N-0021 Oslo, Norway

Attn: Amra Koluder / Solveig N. Knoff

Telephone: +47 22 94 91 17 / 22 94 96 63

Facsimile: +47 22 48 28 94

e-mail:      amra.koluder@dnbnor.no

                 solveig.knoff@dnbnor.no

HSBC BANK PLC   

8 Canada Square

London E14 5HQ

Attn: Alan P. Marshall (FC1354)

Fax no:    +44 207 992 4428

e-mail:      alan.p.marshall@hsbcib.com

KFW IPEX-BANK GMBH   

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Telephone: +49 69 7431 4649 / 4037

Fax: +49 69 7431 4466 / 2944

Attn:       Ms Claudia Wenzel /

                Mr Christian Schweiger

email:      claudia.wenzel@kfw.de /

                christian.schweiger@kfw.de

NORDEA BANK NORGE ASA   

Middelthunsgate 17, P.O. Box 1166 Sentrum

NO-0107

Oslo, Norway

Attn: Arne Berglund

Telephone: (47) 22 484193

Facsimile: (47) 22 486668

e-mail: arne.berglund@nordea.com


EXHIBIT A

FORM OF NOTICE OF BORROWING

[Date]

KfW IPEX-Bank GmbH,

  as Facility Agent for the Lenders party

    to the Credit Agreement

    referred to below

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: [                    ]

Ladies and Gentlemen:

The undersigned, PRIDE OF HAWAII, LLC, a Delaware limited liability company (the “Borrower”), refers to the Credit Agreement, dated as of [                    ], 2010 (as amended, restated, novated, modified and/or supplemented from time to time, the “Credit Agreement”, unless otherwise defined herein, capitalized terms defined therein being used herein as therein defined), among NCL CORPORATION LTD., a Bermuda company (the “Parent”), the Borrower, the Lenders from time to time party thereto, you, as Facility Agent and as Collateral Agent under the Security Documents, NORDEA BANK NORGE ASA, as Documentation Agent, COMMERZBANK AKTIENGESELLSCHAFT, as Hermes Agent for such Lenders and the other parties thereto, and hereby gives you notice, irrevocably, pursuant to Section 2.03 of the Credit Agreement, that the Borrower hereby requests a Borrowing under the Credit Agreement, and in that connection sets forth below the information relating to such Borrowing (the “Proposed Borrowing”) as required by Section 2.03 of the Credit Agreement:

(i) The Business Day of the Proposed Borrowing is                      (the “Proposed Borrowing Date”).1

(ii) The portion of the Total Commitments to be utilized on the Proposed Borrowing Date (the “Proposed Utilized Commitments’) is €                     .

(iii) The Loans to be made on the Proposed Borrowing Date shall consist of Tranche [A][B] Loans.

 

1 Shall be a Business Day at least three Business Days after the date hereof, provided that (in each case) any such notice shall be deemed to have been given on a certain day only if given before 11:00 a.m. (Frankfurt time) on such day (unless such 11:00 a.m. deadline is waived in the case of the Initial Proposed Borrowing Date).


Exhibit A

Page 2

 

(iv) The Parent and/or the Borrower and/or [Breakaway One][Breakaway Two] [have] [have not] entered into Earmarked Foreign Exchange Arrangements with respect to the amount required to be paid to Hermes and/or the Yard on the Proposed Borrowing Date [and the Dollar Equivalent of the aggregate principal amount of the Proposed Utilized Commitments is [                    ]].2 [Attached hereto as Annex A is evidence of such Earmarked Foreign Exchange Arrangements.]

(v) The initial Interest Period for the Proposed Borrowing is              [month(s)].3

(vi) The proceeds of the Proposed Borrowing shall be deposited in the following accounts:

 

Bank and Account No.

  

Account Name

  

Amount to be Disbursed

(indicate Dollars or

Euros)4

[    ]    [    ]    [    ]

(vii) The Dollar Availability on the Proposed Borrowing Date is [                    ]. Attached hereto as Annex B are calculations evidencing such Dollar Availability.

In connection with the Proposed Borrowing, the Borrower hereby certifies as follows:

(i) As of the Proposed Borrowing Date, all conditions and requirements under the [VESSEL 1] [VESSEL 2] Construction Contract required to be satisfied on such Proposed Borrowing Date have been satisfied, other than those that are not materially adverse to the Lenders.

(ii) Both on the date hereof and as of the Proposed Borrowing Date, the representations and warranties made by each Credit Party in or pursuant to the Credit Documents are true and correct in all material respects, on and as of such Proposed Borrowing Date as if made on and as of such Proposed Borrowing Date, unless stated to relate to a specific earlier date, in which case such representations and warranties were true and correct in all material respects as of such earlier date.

 

2 Dollar Equivalent to be included if the Borrower has entered into Earmarked Foreign Exchange Arrangements.
3 The initial Interest Period for any Loan shall commence on the Proposed Borrowing Date of such Loan and each Interest Period occurring thereafter in respect of such Loan shall commence on the day on which the immediately preceding Interest Period applicable thereto expires and shall be for a three or six month period.
4 Euro disbursement only available if the Parent and/or the Borrower have not entered into Earmarked Foreign Exchange Arrangements.


Exhibit A

Page 3

 

(iii) Both on the date hereof and as of the Proposed Borrowing Date after giving effect to the Proposed Borrowing, no Default or Event of Default is or will be continuing.

 

Very truly yours,
PRIDE OF HAWAII, LLC
By:  

 

  Name:
  Title:


Annex A

Evidence of Earmarked Foreign Exchange Arrangements

[See attached]


Annex B

Dollar Availability Calculation

[See attached.]


EXHIBIT B

From BankAssure Insurance Services

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

[*]


LOGO    EXHIBIT C

To:

KFW IPEX-Bank GmbH, as Collateral Agent,

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attn: Claudia Wenzel/ Christian Schweiger

Copy to:

Deutsche Schiffsbank AG

DnB Nor Bank ASA

HSBC Bank plc

Nordea Bank Norge ASA

From:

Aon Risk Services Inc., of Florida

Date: [], 20[]

Dear Sirs,

1. This Certificate is delivered pursuant to Section 5.07 of the Credit Agreement dated as of [], 2010 and made among Pride of Hawaii, LLC, as Borrower, NCL Corporation Ltd. (“NCLC”) as Parent, the Lender Creditors from time to time party thereto and KFW IPEX-Bank GmbH, as Facility Agent and Collateral Agent (as the same may be amended, restated, or otherwise modified from time to time, the “Credit Agreement”).

Capitalized terms used and not otherwise defined in this Certificate shall have the meanings assigned to such terms in the Credit Agreement.

2. We hereby certify to you that, with respect to the Vessel, on and as of the date of this Certificate:

(i) the insurance cover referred to below is placed and maintained with such insurance companies and/or underwriters and/or clubs, in such amounts, against such risks, and in such form, as are customarily insured against by similarly situated insureds for the protection of the Facility Agent, the Collateral Agent and/or the Lender Creditors as mortgagees of the Vessel; and

(ii) the insurance cover referred to in this Certificate conforms with the Required Insurances including (without limitation) hull and machinery, war risks, loss of hire (if applicable) and protection and indemnity insurance set forth in Schedule 9.03 of the Credit Agreement.

3. The insurance cover referred to in paragraph 2(i) above comprises: “NORWEGIAN JADE” ex PRIDE OF HAWAII” - Protection & Indemnity Coverage, Certificate No 259428, February 20, 2010-11, issued by The West of England Ship Owners Mutual Insurance Association

Yours truly,

For and on behalf of

Aon Risk Services Inc., of Florida

Aon Risk Solutions | Marine Practice Group

1001 Brickell Bay Drive | Suite 1100 | Miami, FL 33131

t +1.305.372.9950 | f +1.305.372.8599 | toll free: +1.800.743.3486

aon.com


EXHIBIT D

FORM OF SECRETARY’S CERTIFICATE

OF

CREDIT PARTIES

[                    ], 2010

The undersigned Secretary of each of the entities listed on Schedule I hereto (each, a “Credit Party”) does hereby certify the following to KfW IPEX-Bank GmbH (“KfW IPEX”), as Facility Agent in connection with the Credit Agreement, dated as of [            ], 2010, among NCL Corporation Ltd., Pride of Hawaii, LLC, as Borrower, the Lenders from time to time party thereto, KfW IPEX, as Facility Agent and Collateral Agent under the Security Documents, Nordea Bank Norge ASA, as Documentation Agent and Commerzbank Aktiengesellschaft, as Hermes Agent (as the same may be amended, restated, or otherwise modified from time to time, the “Credit Agreement”). All capitalized terms used in this certificate shall have the meanings assigned to them in the Credit Agreement, unless otherwise defined in this certificate.

1. Attached hereto as Exhibit A is a true and complete copy of minutes or resolutions duly adopted by the board of directors (or equivalent) of each Credit Party authorizing, among other things, the execution, delivery and performance of the Credit Documents to which such Credit Party is a party, and such minutes or resolutions (or equivalent) have not since their adoption been in any way modified, rescinded, revoked or amended in whole or in part, in any respect, and are in full force and effect on the date hereof.

2. Attached hereto as Exhibit B is a true, correct and complete copy of the certificate of incorporation or certificate of formation and by-laws or equivalent organizational documents of each Credit Party, each of which is as of the date hereof in full force and effect.

3. The persons whose names appear on Exhibit C hereto are, as of the date hereof, duly elected or appointed, as applicable, qualified, and acting officers or directors of each Credit Party, holding the offices or directorships set forth beside their names, and are authorized to execute and deliver the Credit Documents on behalf of such Credit Party, and the signature appearing next to each name is the genuine signature of such officer or director.

4. On the date hereof, the representations and warranties contained in the Credit Agreement and in the other Credit Documents are true and correct in all material respects with the same effect as though such representations and warranties had been made on the date hereof, both before and after giving effect to the incurrence of Loans on the date hereof and the application of the proceeds thereof, unless stated to relate to a specific earlier date, in which case such representations and warranties were true and correct in all material respects as of such earlier date.

5. On the date hereof, no Default or Event of Default has occurred and is continuing or would result from the Borrowing to occur on the date hereof or from the application of the proceeds thereof.

6. There is no proceeding for the dissolution or liquidation of any Credit Party or threatening any Credit Party’s existence.


IN WITNESS WHEREOF, each of the Credit Parties has caused this Secretary’s Certificate to be executed and delivered by its duly authorized representative as of the date first set forth above.

 

NCL CORPORATION LTD.
NCL AMERICA HOLDINGS, LLC
PRIDE OF HAWAII, LLC
BREAKAWAY ONE, LTD.
BREAKAWAY TWO, LTD.
By:  

 

Name:   Daniel S. Farkas
Title:   Secretary


I, Kevin M. Sheehan, President and Chief Executive Officer of NCL Corporation Ltd., NCL America Holdings, LLC, Pride of Hawaii, LLC, Breakaway One, Ltd. and Breakaway Two, Ltd. hereby certify that Daniel S. Farkas is the duly elected or appointed, as applicable, and qualified Secretary of NCL Corporation Ltd., NCL America Holdings, LLC, Pride of Hawaii, LLC, Breakaway One, Ltd. and Breakaway Two, Ltd. and that the signature appearing above is his genuine signature.

IN WITNESS WHEREOF, I have hereunto signed my name as of the date first set forth above.

 

 

Name:   Kevin M. Sheehan
Title:   President and Chief Executive Officer


Schedule I

Credit Parties

NCL Corporation Ltd.

NCL America Holdings, LLC

Pride of Hawaii, LLC

Breakaway One, Ltd.

Breakaway Two, Ltd.


Exhibit A

Resolutions


Exhibit B

Organizational Documents


Exhibit C

Incumbency

NCL Corporation Ltd.

NCL America Holdings, LLC

Pride of Hawaii, LLC

Breakaway One, Ltd.

Breakaway Two, Ltd.

 

Kevin M. Sheehan   

President

Chief Executive Officer

  

 

 

  
Daniel S. Farkas   

Senior Vice President

General Counsel

Secretary

  

 

 

 

  


EXHIBIT E

FORM OF TRANSFER CERTIFICATE

 

To: [                    ] as Facility Agent and [                    ] as Hermes Agent

 

From: [The Existing Lender] (the “Existing Lender”) and [The New Lender] (the “New Lender”)

Dated:

Pride of Hawaii, LLC – Credit Agreement

Total Commitment - €126,075,000

dated [                    ]

( the “Credit Agreement”)

 

1. We refer to the Credit Agreement and to the ECF Intercreditor Agreements. This agreement (the “Agreement”) shall take effect as a Transfer Certificate for the purpose of the Credit Agreement. Terms defined in the Credit Agreement have the same meaning in this Agreement unless given a different meaning in this Agreement.

 

2. We refer to Section 13.06 (Procedure and Conditions for Transfer) of the Credit Agreement:

 

  (a) The Existing Lender and the New Lender agree to the Existing Lender transferring to the New Lender by novation all or part of the Existing Lender’s Commitment, rights and obligations referred to in the Schedule attached hereto in accordance with Section 13.06 (Procedure and Conditions for Transfer).

 

  (b) The proposed date of transfer is [            ].

 

  (c) The Notice Office and address, fax number and attention details for notices of the New Lender for the purposes of Section 14.03 (Notices) are set out in the Schedule attached hereto.

 

3. On the date of the transfer the New Lender becomes:

 

  (a) Party to the relevant Credit Documents (other than the ECF Intercreditor Agreements and the Security Trust Deed) as a Lender; and

 

  (b) Party to each ECF Intercreditor Agreement as a Jade Lender; and

 

  (c) Party to the Security Trust Deed as a Secured Creditor.

 

4. The New Lender expressly acknowledges the limitations on the Existing Lender’s obligations set out in paragraph (c) of Section 13.04 (Limitation of responsibility of Existing Lenders).


EXHIBIT E 2

 

5. We refer to Clause 9.2 (Change to the Lenders) of each ECF Intercreditor Agreement and Clause 8.2 (Changes of Secured Creditor) of the Security Trust Deed

 

  (a) In consideration of the New Lender being accepted as a Jade Lender for the purposes of each ECF Intercreditor Agreement (and as defined therein), the New Lender confirms that, as from the date of transfer, it intends to be party to each ECF Intercreditor Agreement as a Jade Lender, and undertakes to perform all the obligations expressed in each ECF Intercreditor Agreement to be assumed by a Jade Lender and agrees that it shall be bound by all the provisions of each ECF Intercreditor Agreement, as if it had been an original party to such ECF Intercreditor Agreement.

 

  (b) In consideration of the New Lender being accepted as a Secured Creditor for the purposes of the Security Trust Deed (and as defined therein), the New Lender confirms that, as from the date of the transfer, it intends to be party to the Security Trust Deed as a Secured Creditor, and undertakes to perform all the obligations expressed in the Security Trust Deed to be assumed by a Secured Creditor and agrees that it shall be bound by all the provisions of the Security Trust Deed, as if it had been an original party to the Security Trust Deed.

 

6. We refer to Section 13.01(c) (Assignments and Transfers by the Lenders) of the Credit Agreement. Each New Lender, by executing this Assignment, confirms, for the avoidance of doubt, that the Facility Agent has authority to execute on its behalf any amendment or waiver that has been approved by or on behalf of the Required Lenders in accordance with the Credit Agreement on or prior to the date on which the transfer becomes effective in accordance with the Credit Agreement and that it is bound by that decision to the same extent as the Existing Lender would have been had it remained a Lender.

 

7. This Agreement may be executed in any number of counterparts and this has the same effect as if the signatures on the counterparts were on a single copy of this Agreement.

 

8. This Agreement takes effect as a deed.

 

9. This Agreement has been entered into on the date stated at the beginning of this Agreement.

 

10. This Agreement and any non-contractual obligations arising out of or in connection with it shall be governed by, and construed in accordance with English law.

 

Note: The execution of this Transfer Certificate may not transfer a proportionate share of the Existing Lender’s interest in the Collateral in all jurisdictions. It is the responsibility of the New Lender to ascertain whether any other documents or other formalities are required to perfect a transfer of such a share in the Existing Lender’s Collateral in any jurisdiction and, if so, to arrange for execution of those documents and completion of those formalities.


EXHIBIT E

THE SCHEDULE

Commitment/rights and obligations to be transferred

[insert relevant details]

[Notice Office address, fax number and attention details for notices and account details for payments]


EXHIBIT E

SIGNATORIES

[Existing Lender]

 

Executed as a deed by [name of Existing Lender], acting by [name of director]:    
   

 

    [Signature of Director]
    Director
   

 

    [Signature of Director]
    Director
[New Lender]Executed as a deed by [name of New Lender], acting by [name of director]:    
   

 

    [Signature of Director]
    Director
   

 

    [Signature of Director]
    Director


EXHIBIT E 5

 

This Agreement is accepted as a Transfer Certificate for the purposes of the Credit Agreement by the Facility Agent and by the Hermes Agent, and the date of the transfer is confirmed as [    ].

Signature of this Agreement by the Facility Agent constitutes confirmation by the Facility Agent of receipt of notice of the transfer referred to in this Agreement, which notice the Facility Agent receives on behalf of each Lender Creditor.

[Facility Agent]

 

Executed as a deed by [Facility Agent], acting by [name of director]:    
   

 

    [Signature of Director]
    Director
   

 

    [Signature of Director]
    Director

[Hermes Agent]

 

Executed as a deed by [Hermes Agent], acting by [name of director]:    
   

 

    [Signature of Director]
    Director
   

 

    [Signature of Director]
    Director

[NCL Corporation Ltd.]1

[Signed as a deed by [NCL Corporation Ltd.], a

company incorporated in Bermuda, by [full name(s)

 

1

To be signed by the Company only if the transfer is pursuant to section 13.01(a)(ii) of the Credit Agreement.


EXHIBIT E 6

 

of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company.    
   

 

    Signature(s)
    Authorised [signatory] [signatories]]


EXHIBIT F

DATED [    ] NOVEMBER 2010

PRIDE OF HAWAII, LLC

(as assignor)

to

KFW IPEX-BANK GMBH,

(as assignee)

 

 

FORM OF FOURTH CHARTER AND EARNINGS ASSIGNMENT

m.v. “NORWEGIAN JADE”

 

 


TABLE OF CONTENTS

 

          Page  
1    Definitions and Construction      2   
2    Covenant to Pay and Perform      3   
3    Assignment and Negative Pledge      3   
4    Notices of Assignment      4   
5    Application of Earnings      4   
6    Operation and Maintenance      4   
7    Power of Attorney      4   
8    Assignor’s Liability Unaffected by Assignment      5   
9    Continuing Security      5   
10    Further Assurance      5   
11    Enforcement Expenses      5   
12    Waivers, Remedies Cumulative      5   
13    Assignment      6   
14    Discharge of Security      6   
15    Notices      6   
16    Governing Law and Jurisdiction      7   
Schedule 1      9   
Schedule 2      13   
Schedule 3      21   
Schedule 4      26   
Schedule 5 Notice of Assignment      28   
Acknowledgement      29   

 

(i)


DEED OF ASSIGNMENT

Dated                     2010

BY:

 

(1) PRIDE OF HAWAII, LLC a Delaware corporation and having its registered office at Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Assignor”);

IN FAVOUR OF:

 

(2) KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, acting not in its own individual capacity but solely as trustee and collateral agent for the Beneficiaries (as defined below) pursuant to the Security Trust Deed (the “Assignee”).

WHEREAS:

 

(A)

The Assignor is the absolute owner of all of the sixty four sixty fourth (64/64th) shares of and in the motor vessel “NORWEGIAN JADE” (the “Vessel”) registered in the name of the Assignor under the laws and flag of the Bahamas at the port of Nassau with Official Number 9000236.

 

(B) Pursuant to a first assignment of charter and earnings dated 10 February 2008 (the “First Assignment”) the Assignor assigned the benefit of the Bareboat Charter and the Earnings, to the extent the Earnings were not assigned by way of a first assignment of earnings dated 18 October 2004 between the Assignor and the First Assignee (as defined below) as collateral to a first priority mortgage over the Vessel upon the terms and conditions contained therein to HSBC Bank Plc of 8 Canada Square, London, E14 5HQ as trustee for the parties set out in Schedule 1 (the “First Assignee”).

 

(C) Pursuant to a second assignment of charter and earnings dated 2 April 2009 (the “Second Assignment”) the Assignor assigned the benefit of the Bareboat Charter and Earnings as collateral to a second priority mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the parties set out in Schedule 2 (the “Second Assignee”).

 

(E) Pursuant to a third assignment of charter and earnings dated 2 April 2009 (the “Third Assignment”) the Assignor assigned the benefit of the Bareboat Charter and Earnings as collateral to a third priority mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the parties set out in Schedule 3 (the “Third Assignee”).

 

(F) Pursuant to the Credit Agreement, and in consideration of the obligations of the Beneficiaries under or pursuant to the Junior Finance Documents, the Assignor has executed and delivered in favour of the Assignee a fourth priority Bahamian statutory mortgage and has agreed to enter into this Deed to assign the benefit of the Bareboat Charter and Earnings to the Assignee on trust for itself and the Beneficiaries as security for the repayment of the Secured Obligations.


(G) By a deed of co-ordination dated as of the date hereof (the “Fourth Priority Security Co-ordination Deed”) made between (among others) (1) the First Assignee (2) the Second Assignee, (3) the Third Assignee and (4) the Assignee the parties have agreed (among other things) as to how the provisions of Clause 5 shall operate. Further by the Fourth Priority Security Co-ordination Deed it has been agreed that the benefit of this Deed shall be held by the Assignee on trust for itself and the Secured Creditors, including the Secured Creditors set out in Schedule 4 and its and their respective successors, assignees and transferees (together the “Beneficiaries”).

NOW THIS DEED WITNESSES:

 

1 Definitions and Construction

The headings used in this Deed are for reference only, and have no legal or other significance, and shall be ignored in the interpretation of this Deed. In this Deed the following terms shall have the meanings set out below; in addition, defined terms and expressions used but not defined herein and whose meanings are defined in the Credit Agreement shall have the same meanings when used in this Deed.

“Bareboat Charter” means the bareboat charterparty dated 10 February 2008 and made between the Assignor as owner and NCL (Bahamas) Ltd. as charterer (the “Bareboat Charterer”);

Credit Agreement” means that certain €126,075,000 credit agreement, dated November [], 2010 among NCL Corporation Ltd., as parent, (the “Parent”), the Assignor, as borrower, the lenders from time to time party thereto (the “Lenders”), the Assignee, as facility agent and as collateral agent under the Security Documents, Nordea Bank Norge ASA, as documentation agent, Commerzbank AG, as Hermes agent, and the other parties thereto, as amended, novated, and/or restated or otherwise modified from time to time

Compulsory Acquisition” means requisition for title or other compulsory acquisition of the Vessel including its capture, seizure, detention or confiscation or expropriation but excluding any requisition for hire by or on behalf of any government or governmental authority or agency or by any persons acting or purporting to act on behalf of any such government or governmental authority or agency;

“Earnings” means, in respect of the Vessel, (whether earned or to be earned) any and all freights, hire and passage monies, proceeds of requisition (other than proceeds of a Compulsory Acquisition), rebates and commissions to or for the account of the Assignor and/or the Bareboat Charterer, all earnings deriving from the Bareboat Charter, time charters, contracts of affreightment, pooling agreements, joint ventures, compensation, remuneration for salvage and towage services, damages howsoever arising and detention monies, damages for breach of any charterparty or other contract for the employment of the Vessel including, but without limitation, the Bareboat Charter, any amounts payable in consideration of the termination or variation of any charterparty or other such contract, any reduction in the Hermes Premium repaid by Hermes to the Assignor and any other earnings whatsoever due or to become due to the Assignor and/or the Bareboat Charterer;

Event of Default” has the meaning ascribed to it in the Credit Agreement;

Junior Finance Documents” means the Credit Documents as defined in the Credit Agreement;

 

2


“Lender Creditors” means the Lenders, the Assignee and each other Agent under the Credit Agreement.

Liens” has the meaning ascribed to it in the Credit Agreement;

“Other Creditors” means any Lender or any affiliate thereof and their successors, transferees and assigns if any (even if such Lender subsequently ceases to be a Lender under the Credit Agreement for any reason), together with such Lender’s or affiliate’s successors, transferees and assigns, with which the Parent and/or the Assignor enters into any Interest Rate Protection Agreements or Other Hedging Agreements from time to time.

Secured Creditors” means collectively (i) the Lender Creditors and (ii) the Other Creditors;

Secured Obligations” has the meaning ascribed to it in the Credit Agreement;

Security Documents” has the meaning ascribed to it in the Credit Agreement;

“Security Period” means the period beginning on the date of this Deed and ending on the date when the whole of the Secured Obligations have been repaid in full and the Assignor has ceased to be under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement) under or in connection with any of the Junior Finance Documents; and

“Security Trust Deed” means the Security Trust Deed executed on or about the date hereof by, inter alia, the Assignor, the Guarantor, the Assignee, the Original Secured Creditors (as defined therein) and the Original Term Hedging Creditors (as defined therein).

 

2 Covenant to Pay and Perform

The Assignor covenants with the Assignee to discharge the Secured Obligations on demand from time to time in accordance with the Credit Agreement, and to pay all other sums at any time due under or pursuant to the Junior Finance Documents in each case at the times and in the manner provided therein and to perform all its other obligations arising out of the Junior Finance Documents as and when the same shall be due for performance.

 

3 Assignment and Negative Pledge

 

  3.1 Assignment In consideration of:

 

  3.1.1 the Beneficiaries consenting to the continued chartering of the Vessel to the Bareboat Charterer pursuant to the Bareboat Charter;

 

  3.1.2 the Beneficiaries making certain facilities available to the Assignor pursuant to the Credit Agreement;

 

  3.1.3 payment by the Assignee to the Assignor of ten Dollars (USD10); and

 

  3.1.4 other good and valuable consideration from the Beneficiaries to the Assignor

 

3


(the adequacy and receipt whereof is hereby acknowledged by the Assignor) and as security for payment of the Secured Obligations, the Assignor with full title guarantee hereby assigns to, and grants a security interest in, and agrees to assign to, and grant a security interest in, the Assignee absolutely all its right and title to and interest in the Bareboat Charter and the Earnings, TO HOLD the same absolutely unto the Assignee, subject to the First Assignment, the Second Assignment and the Third Assignment.

 

  3.2 Negative pledge The Assignor undertakes that, except with the prior written consent of the Assignee, it will not at any time during the currency of this Deed create or permit to subsist any Lien save for the First Assignment, the Second Assignment and the Third Assignment (and except for Permitted Liens) on all or any part of the Assignor’s right, title and interest in and to the Bareboat Charter and the Earnings of the Vessel.

 

4 Notices of Assignment

The Assignor undertakes immediately to give notice substantially in the form of Schedule 5 to the Bareboat Charterer and the Assignor undertakes to procure that the Bareboat Charterer acknowledges and consents to such assignment by signing an endorsement of the notice in the form set out in Schedule 5.

 

5 Application of Earnings

All Earnings received by the Assignee pursuant to the assignment in this Deed shall be applied in accordance with clause 3.4 of the Fourth Priority Security Co-ordination Deed and section 4.05 of the Credit Agreement

 

6 Operation and Maintenance

The Assignor undertakes to the Assignee that it will comply with all of its obligations with respect to the operation and maintenance of the Vessel set out in the Junior Finance Documents.

 

7 Power of Attorney

The Assignor hereby irrevocably appoints and constitutes the Assignee as its true and lawful attorney with full power (in the name of the Assignor or otherwise) to demand, compound and give acquittance for any monies and claims for monies due or to become due, to endorse any cheque or other instrument or order in connection therewith and to file any claims or take any action or institute any proceedings which may seem to the Assignee to be necessary or advisable and otherwise to do any and all things which the Assignor itself could do in relation to the property hereby assigned provided that the power of attorney created by this Clause 7 shall take effect only from and after the occurrence of an Event of Default, subject to the provisions of the Fourth Priority Security Co-ordination Deed, or, in the case of the execution of notices in the form of Schedule 5, an Event of Default that is continuing. The exercise of such power by the Assignee shall not put any person dealing with the Assignee on any enquiry and the exercise by the Assignee of such power shall be conclusive evidence of its right to exercise it. The Assignor hereby ratifies and confirms and agrees to ratify and confirm whatever an attorney appointed under this Deed shall do in its capacity as such, to the extent permissible hereunder.

 

4


8 Assignor’s Liability Unaffected by Assignment

It is agreed that notwithstanding the assignments contained herein:

 

  8.1 the Assignee shall not be obliged to make any enquiries as to the nature or sufficiency of any payment received by the Assignee or its order under those assignments or to make any claim or take any other action to collect any monies or to enforce any rights and benefits assigned to the Assignee or to which the Assignee may at any time be entitled thereunder; and

 

  8.2 the Assignor shall remain liable to perform all the obligations assumed by it in relation to any charter or contract of affreightment or employment of the Vessel and the Assignee shall not be under any obligation of any kind whatsoever in respect thereof or be under any liability whatsoever in the event of any failure by the Assignor to perform its obligations in respect thereof.

 

9 Continuing Security

This Deed and the assignments herein shall be:

 

  9.1 a continuing security remaining in full force and effect until payment in full of each and every part of the Secured Obligations; and

 

  9.2 in addition to and not in substitution for or in derogation of any other security held by the Assignee, from time to time in respect of the Secured Obligations.

 

10 Further Assurance

The Assignor will, from time to time on being required to do so by the Assignee, do or procure the doing of all such acts and/or execute or procure the execution of all such documents in a form satisfactory to the Assignee as the Assignee may reasonably consider necessary for giving full effect to any of the Security Documents including this Deed or securing to the Assignee the full benefit of the rights, powers and remedies conferred upon the Assignee in any such Security Document including this Deed.

 

11 Enforcement Expenses

The Assignor shall reimburse the Assignee on demand for the charges and expenses (including the fees and expenses of legal advisors and value added tax or any similar tax thereon) incurred by it in connection with the enforcement of, or the preservation of, any rights under this Deed.

 

12 Waivers, Remedies Cumulative

 

  12.1 No waiver

No failure to exercise and no delay in exercising on the part of the Assignee any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any right or remedy preclude any other or further exercise thereof, or the exercise of any other right or remedy. No waiver by the Assignee shall be effective unless it is in writing.

 

5


  12.2 Remedies cumulative

The rights and remedies of the Assignee provided herein are cumulative and not exclusive of any rights or remedies provided by law.

 

  12.3 Severability

If any provision of this Deed or any of the other Security Documents is prohibited or unenforceable in any jurisdiction, such prohibition or unenforceability shall not invalidate the remaining provisions hereof or affect the validity or enforceability of such provision in any other jurisdiction.

 

  12.4 Time of essence

Time is of the essence in respect of all of the obligations of the Assignor under this Deed provided however that the Assignee shall not be entitled to enforce its rights under the assignments contained in this Deed otherwise than in circumstances which constitute an Event of Default, subject to the provisions of the Fourth Priority Security Co-ordination Deed.

 

13 Assignment

 

  13.1 Benefit of agreement This Deed shall be binding upon the Assignor and its successors and shall inure to the benefit of the Assignee and its successors, transferees and assigns.

 

  13.2 Disclosure of information Any of the Beneficiaries may disclose to a potential transferee or assignee or to any other person who may otherwise propose to enter into contractual relations with any of them in relation to this Deed such information about the Assignor as such Beneficiary shall consider appropriate subject always to the provisions of section 14.14 of the Credit Agreement where, for the purpose of this Deed, references to “Lender” shall be read and construed as “Beneficiary”.

 

  13.3 Contracts (Rights of Third Parties) Act 1999 (the “Act”) A person who is not a party to this Deed has no right under the Act to enforce any term of this Deed but this does not affect any right or remedy of a third party which exists or is available apart from the Act.

 

14 Discharge of Security

Following the repayment or payment to the Assignee of all the Secured Obligations the Assignee will at the Assignor’s request and expense reassign to the Assignor the property assigned to the Assignee by this Deed without recourse to any representation or warranty by or from the Assignee.

 

15 Notices

All demands and notices made or given hereunder shall be made or given in accordance with section 14.03 of the Credit Agreement.

 

6


16 Governing Law and Jurisdiction

 

  16.1 This Deed and any non-contractual obligations arising from or in connection with it shall be governed by English law.

 

  16.2 The courts of England have exclusive jurisdiction to settle any dispute:

 

  16.2.1 arising out of or in connection with this Deed (including a dispute regarding the existence, validity or termination of this Deed); or

 

  16.2.2 relating to any non-contractual obligations arising from or in connection with this Deed,

(a “Dispute”). Each party to this Deed agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no party will argue to the contrary.

This Clause 16.2 is for the benefit of the Assignee only. As a result, such party shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, such party may take concurrent proceedings in any number of jurisdictions.

The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Deed (including a dispute regarding the existence, validity or termination of this Deed) (a “Dispute”). Each party to this Deed agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no party will argue to the contrary.

This Clause 16.2 is for the benefit of the Assignee only. As a result, such party shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, such party may take concurrent proceedings in any number of jurisdictions.

 

  16.3 The Assignor may not, without the Assignee’s prior written consent, terminate the appointment of the Process Agent; if the Process Agent resigns or its appointment ceases to be effective, the Assignor shall within fourteen (14) days appoint a company which has premises in London and has been approved by the Assignee to act as the Assignor’s process agent with unconditional authority to receive and acknowledge service on behalf of the Assignor of all process or other documents connected with proceedings in the English courts which relate to this Deed.

 

  16.4 For the purpose of securing its obligations under Clause 16.2, the Assignor irrevocably agrees that, if it for any reason fails to appoint a process agent within the period specified in Clause 16.2, the Assignee may appoint any person (including a company controlled by or associated with the Assignee, the Agent or any Lender) to act as the Assignor’s process agent in England with the unconditional authority described in Clause 16.2.

 

  16.5 No neglect or default by a process agent appointed or designated under this Clause (including a failure by it to notify the Assignor of the service of any process or to forward any process to the Assignor) shall invalidate any proceedings or judgment.

 

7


  16.6 The Assignor appoints in the case of the courts of England the Process Agent to receive, for and on its behalf service of process in England of any legal proceedings with respect to this Deed.

 

  16.7 A judgment relating to this Deed which is given or would be enforced by an English court shall be conclusive and binding on the Assignor and may be enforced without review in any other jurisdiction.

 

  16.8 Nothing in this Clause shall exclude or limit any right which the Assignee may have (whether under the laws of any country, an international convention or otherwise) with regard to the bringing of proceedings, the service of process, the recognition or enforcement of a judgment or any similar or related matter in any jurisdiction.

 

  16.9 In this Clause “judgment” includes order, injunction, declaration and any other decision or relief made or granted by a court.

IN WITNESS whereof this Deed has been executed and delivered by the parties hereto as a deed on the day first written above.

 

SIGNED SEALED and DELIVERED as a DEED    )
for and on behalf of    )
PRIDE OF HAWAII, LLC    )
by    )
its duly appointed attorney-in-fact,    )
who in accordance with the laws of that territory,    )
is acting under the authority of the company    )
SIGNED SEALED and DELIVERED as a DEED    )
for and on behalf of    )
KFW IPEX-BANK GMBH    )
by    )
who in accordance with the laws of that territory,    )
is acting under the authority of the company    )

 

8


Schedule 1

Senior Security Documents

First Priority Mortgage and Collateral Deed of Covenants each dated 10 February 2008

First Assignment of Insurances dated 19 April 2006

First Charter and/or Earnings Assignments dated 18 October 2004 and 10 February 2008

Deeds of Assignment and Subordination dated 10 February 2008 and 16 June 2008

EUR308,130,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

9


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

10


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

DNB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 74221 197
Attn: Mr Stephan Bachmann
Email: stephan.bachmann@ca-cib.com

 

11


with a copy to:

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED

Fax: +852 2868 1448
Attn: Mr Terence Yuen/Ms Iris Lai
Email: terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

12


Schedule 2

Senior Security Documents

Guarantee of the Owner dated 2 April 2009

Second Priority Mortgage and Collateral Deed of Covenants dated 2 April 2009

Second Assignment of Insurances dated 2 April 2009

Second Charter and Earnings Assignment dated 2 April 2009

Second Assignment and Subordination dated 2 April 2009

Part I

EUR258,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

13


(as trustee and agent)

COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

14


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

Part II

EUR40,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

15


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

16


DVB BANK SE

Parklaan 2

3016 BB Rotterdam

The Netherlands

 

Fax: +5999 4652366
Attn: LAM/Eric Maduro
Email: lam.curacao@dvbbank.com/james.neira@dvbbank.com

Part III

USD334,050,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

17


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

18


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

OVERSEA-CHINESE BANKING

CORPORATION LIMITED

Singapore Branch

65 Chulia Street #10-00

Singapore 049513

 

Fax: +65 6536 6449/6532 5347
Attn: Ms Lee King Lan/Ms Elaine Lam
Email: LeeKingLan@ocbc.com/LamSYElaine@ocbc.com

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

 

19


CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 74221 197
Attn: Mr Stephan Bachmann
Email: stephan.bachmann@ca-cib.com

with a copy to:

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED

Fax: +852 2868 1448
Attn: Mr Terence Yuen/Ms Iris Lai
Email: terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

20


Schedule 3

Senior Security Documents

Guarantee of the Owner dated 2 April 2009

Third Priority Mortgage and Collateral Deed of Covenants dated 2 April 2009

Third Assignment of Insurances dated 2 April 2009

Third Charter and Earnings Assignment dated 2 April 2009

Third Assignment and Subordination dated 2 April 2009

EUR624,000,000 Secured Loan Agreement dated 7 October 2005 as amended

and/or restated from time to time

Non-Guaranteed Trustee

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Mrs Solveig Nuland Knoff
Email: solveig.knoff@dnbnor.no

As trustee for:

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Mrs Solveig Nuland Knoff
Email: solveig.knoff@dnbnor.no

(as security agent and agent)

 

21


and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/
   Mrs Anne Randewig
Email: shipfinance@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

22


NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

NORDEA BANK NORGE ASA

Middelthuns gate 17

Oslo

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 22 484278
Attn: Mr Arne Berglund
Email: arne.berglund@nordea.com

BANK OF SCOTLAND PLC

Marine Finance

Second Floor

New Uberior House

11 Earl Grey Street

Edinburgh EH3 9BN

Scotland

 

Fax: +44 131 659 1194
Attn: Douglas Newton/Russell Parker
Email: douglas_newton@bankofscotland.co.uk

 

23


UNICREDIT BANK AG

(formerly known as Bayerische Hypo- und

Vereinsbank AG)

Alter Wall 22

20457 Hamburg

Germany

 

Fax: +49 40 3692 3696/+49 89 378 334 2832
Attn: Mr Peter-Alexander Wunner/
   Mr Michael McCarthy
Email: peter-alexander.wunner@unicreditgroup.de/
   michael.mccarthy@unicreditgroup.de

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Bremen and Hamburg

Domshof 17

28195 Bremen

Germany

 

Fax: +49 421 3609 329
Attn: Dr Matthias Fischer
Email: matthias.fischer@schiffsbank.com

FOKUS BANK

(being the Norwegian branch of Danske Bank A/S)

Stortingsgaten 6

P O Box 1170 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 85 407990
Attn: Mr Øivind Haraldsen/Mr Tore Thorlacius Braein
Email: oivind.haraldsen@fokus.no/
     tore.braein@fokus.no

 

24


HSH NORDBANK AG

Gerhart-Hauptmann-Platz 50

20095 Hamburg

Germany

 

Fax: +49 40 3333 613741
Attn: Mr Carsten Dreyer
Email: carsten.dreyer@hsh-nordbank.com

 

Fax: +1 212 407 6008
Attn: Ms Frauke Hay
Email: frauke.hay@hsh-nordbank.com

SKANDINAVISKA ENSKILDA BANKEN AB (publ)

Kungsträdgårdsgatan 8

SE-106 40 Stockholm

Sweden

 

Fax: +44 20 7236 5144
Attn: Mr Egil Aarrestad/Mr Malcolm Stonehouse
Email: egil.aarrestad@seb.co.uk/
   malcolm.stonehouse@seb.co.uk

 

25


Schedule 4

EUR126,075,000 Credit Agreement dated November [    ] 2010 as amended and/or restated from time to time

Trustee:

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 2944
Attn: Ship Finance, X2a4
   Claudia Wenzel
Email: Claudia.wenzel@kfw.de

As Trustee for:

NORDEA BANK NORGE ASA

Middelthunsgate 17

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 22 486668
Attn: Mr Arne Berglund
Email: arne.berglund@nordea.com

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 8

D – 20095 Hamburg

Germany

 

Fax: +49 40 3769 9649
Attn: Mr Marcus Weber
   Ms Anne Randewig
Email: marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Ms Amra Koluder
   Mr Solveig N. Knoff
Email: amra.koluder@dnbnor.no
   solveig.knoff@dnbnor.no

 

26


KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 4466/ 2944
Attn: Mr Stephan Pueschel
   Mr Christian Schweiger
Email: stephan.pueschel@kfw.de
   christian.schweiger@kfw.de

HSBC BANK PLC

8 Canada Square

London E14 5HQ

 

Fax: +44 207 992 4428
Attn: Alan P. Marshall
Email: alan.p.marshall@hsbcib.com

And each other Secured Creditor under and as defined in the Credit Agreement.

 

27


Schedule 5

Notice of Assignment

 

TO:    NCL (BAHAMAS) LTD.
   Milner House
   18 Parliament Street
   Hamilton HM 12
   Bermuda

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

We hereby give you notice that by a fourth charter and earnings assignment dated November [__], 2010 (the “Assignment”) we assigned to KfW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, acting not in its own individual capacity but solely as trustee for the Beneficiaries (as defined in the Assignment) (the “Assignee”) all our right and title to and interest in (i) the bareboat charter dated 10 February 2008 made between you and us in respect of the Vessel (the “Bareboat Charter”) and (ii) all hire, freights and other earnings of the Vessel.

You are authorised to continue to pay to us the hire due under the Bareboat Charter and any other sums due to us under the Bareboat Charter unless you receive a notice from the Assignee to the contrary pursuant to an Event of Default under the said assignment.

Will you please note that these instructions are not to be revoked or varied without the prior written consent of the Assignee.

Will you please acknowledge receipt of this letter by signing and returning one (1) copy to us and one (1) copy to the Assignee with the endorsement below duly completed.

Dated                 2010

 

PRIDE OF HAWAII, LLC
By:  

 

Title:  

 

28


Acknowledgement

 

TO:    PRIDE OF HAWAII, LLC
   Corporation Trust Center
   1209 Orange Street
   Wilmington
   Delaware 19801
   United States of America

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

We, the undersigned, the bareboat charterer of the Vessel under a charterparty dated 10 February 2008, hereby acknowledge receipt of the above notice of fourth charter and earnings assignment and in consideration of the payment by you of ten United States Dollars (USD10) and other good and valuable consideration, the receipt and sufficiency of which we hereby acknowledge, we hereby (1) confirm that other than for a first assignment, second assignment and third assignment we have not previously received notice of any such assignment (2) consent to the assignment referred to in the above notice and (3) agree that we will make payment of all such monies free of any set-off, counterclaim or other deduction to the account of the Assignee referred to in the above notice if so directed by the Assignee or to such other account as the Assignee may from time to time direct.

We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the fourth charter and earnings assignment referred to in the above notice.

Dated                 2010

 

NCL (BAHAMAS) LTD.
By:  

 

Title:  

 

29


EXHIBIT G

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

Dated                                  2010

(1)        PRIDE OF HAWAII, LLC

(as assignor)

(2)        KFW IPEX-BANK GMBH

(as assignee)

 

 

FOURTH INSURANCE ASSIGNMENT

m.v. “NORWEGIAN JADE”

 

 


TABLE OF CONTENTS

 

          Page  

1

   Definitions and Construction      2   

2

   Covenant to Pay and Perform      3   

3

   Assignment and Negative Pledge      3   

4

   Notice of Assignment of Insurances      4   

5

   Application of Proceeds of Insurances      4   

6

   Power of Attorney      4   

7

   Assignor’s Liability Unaffected by Assignment      4   

8

   Continuing Security      5   

9

   Further Assurance      5   

10

   Enforcement Expenses      5   

11

   Waivers, Remedies Cumulative      5   

12

   Assignment      6   

13

   Discharge of Security      6   

14

   Notices      6   

15

   Governing Law and Jurisdiction      6   
Schedule 1      9   
Schedule 2      13   
Schedule 3      21   
Schedule 4      26   
Schedule 5      28   
Schedule 6      29   
Schedule 7      34   

 

(i)


DEED

Dated            2010

BY:

 

(1) PRIDE OF HAWAII, LLC of Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Assignor”);

IN FAVOUR OF:

 

(2) KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, acting not in its own individual capacity but solely as trustee and collateral agent for the Beneficiaries (as defined below) pursuant to the Security Trust Deed (the “Assignee”).

WHEREAS:

 

(A)

The Assignor is the absolute owner of all of the sixty four sixty fourth (64/64th) shares of and in the motor vessel “NORWEGIAN JADE” (the “Vessel”) registered in the name of the Assignor under the laws and flag of the Bahamas at the port of Nassau with Official Number 9000236.

 

(B) Pursuant to a first insurance assignment dated 19 April 2006 (the “First Assignment”) the Assignor assigned the benefit of the Insurances as collateral to a first priority Bahamian statutory mortgage over the Vessel dated 10 February 2008 upon the terms and conditions contained therein to HSBC Bank Plc of 8 Canada Square, London, E14 5HQ as trustee for the parties set out in Schedule 1 (the “First Assignee”).

 

(C) Pursuant to a second insurance assignment dated 2 April 2009 (the “Second Assignment”) the Assignor assigned the benefit of the Insurances as collateral to a second priority Bahamian statutory mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021Oslo, Norway, as trustee for itself and the parties set out in Schedule 2 (the “Second Assignee”).

 

(D) Pursuant to a third insurance assignment dated 2 April 2009 (the “Third Assignment”) the Assignor assigned the benefit of the Insurances as collateral to a third priority Bahamian statutory mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the parties set out in Schedule 3 (the “Third Assignee”).

 

(E) Pursuant to the Credit Agreement, and in consideration of the obligations of the Beneficiaries under or pursuant to the Junior Finance Documents, the Assignor has executed and delivered in favour of the Assignee a fourth priority Bahamian statutory mortgage and has agreed to enter into this Deed to assign the benefit of the Insurances to the Assignee on trust for itself and the Beneficiaries as security for the repayment of the Secured Obligations.

 

(F)

By a deed of co-ordination dated as of the date hereof (the “Fourth Priority Security Co-ordination Deed”) made between (among others) (1) the First Assignee (2) the Second Assignee, (3) the Third Assignee and (4) the Assignee, the parties have agreed (among other things) as to how the provisions of Clause 5 shall operate. Further by the


 

Fourth Priority Security Co-ordination Deed it has been agreed that the benefit of this Deed shall be held by the Assignee on trust for itself and the Secured Creditors, including the Secured Creditors set out in Schedule 4 and its and their respective successors, assignees and transferees (together the “Beneficiaries”).

NOW THIS DEED WITNESSES:

 

1 Definitions and Construction

The headings used in this Deed are for reference only, and have no legal or other significance, and shall be ignored in the interpretation of this Deed. In this Deed the following terms shall have the meanings set out below; in addition, defined terms and expressions used but not defined herein and whose meanings are defined in the Credit Agreement shall have the same meanings when used in this Deed.

Credit Agreement” means that certain €126,075,000 credit agreement, effective November 18, 2010 among NCL Corporation Ltd., as parent, (the “Parent”), the Assignor, as borrower, the lenders from time to time party thereto (the “Lenders”), the Assignee, as facility agent and as collateral agent under the Security Documents, Nordea Bank Norge ASA, as documentation agent, Commerzbank AG, as Hermes agent, and the other parties thereto, as amended, novated, and/or restated or otherwise modified from time to time;

Compulsory Acquisition” means requisition for title or other compulsory acquisition of the Vessel including its capture, seizure, detention or confiscation or expropriation but excluding any requisition for hire by or on behalf of any government or governmental authority or agency or by any persons acting or purporting to act on behalf of any such government or governmental authority or agency;

Event of Default” has the meaning ascribed to it in the Credit Agreement;

Insurances” means all policies and contracts of insurance of the Vessel and entries of the Vessel in a protection and indemnity or war risks association which are effected in respect of the Vessel, its freights, disbursements, profits or otherwise and all benefits, including all claims and returns of premiums thereunder and shall also include all compensation payable by virtue of Compulsory Acquisition of the Vessel;

Junior Finance Documents” means the Credit Documents as defined in the Credit Agreement;

Lender Creditors” means the Lenders, the Assignee and each other Agent under the Credit Agreement.

Liens” has the meaning ascribed to it in the Credit Agreement;

Other Creditors” means any Lender or any affiliate thereof and their successors, transferees and assigns if any (even if such Lender subsequently ceases to be a Lender under the Credit Agreement for any reason), together with such Lender’s or affiliate’s successors, transferees and assigns, with which the Parent and/or the Assignor enters into any Interest Rate Protection Agreements or Other Hedging Agreements from time to time.

 

2


Secured Creditors” means collectively (i) the Lender Creditors and (ii) the Other Creditors;

Secured Obligations” has the meaning ascribed to it in the Credit Agreement;

Security Documents” has the meaning ascribed to it in the Credit Agreement;

Security Period” means the period beginning on the date of this Deed and ending on the date when the whole of the Secured Obligations have been repaid in full and the Assignor has ceased to be under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement) under or in connection with any of the Junior Finance Documents; and

Security Trust Deed” means the Security Trust Deed executed on or about the date hereof by, inter alia, the Assignor, the Guarantor, the Assignee, the Original Secured Creditors (as defined therein) and the Original Term Hedging Creditors (as defined therein).

 

2 Covenant to Pay and Perform

The Assignor covenants with the Assignee to discharge the Secured Obligations on demand from time to time in accordance with the Credit Agreement, and to pay all other sums at any time due under or pursuant to the Junior Finance Documents in each case at the times and in the manner provided therein and to perform all its other obligations arising out of the Junior Finance Documents as and when the same shall be due for performance.

 

3 Assignment and Negative Pledge

 

  3.1 Assignment

In consideration of (A) the Beneficiaries making certain facilities available to the Assignor pursuant to the Credit Agreement, any Interest Rate Protection Agreements and/or any Other Hedging Agreements, (B) payment by the Assignee to the Assignor of ten Dollars (USD10) and (C) other good and valuable consideration from the Assignee to the Assignor (the adequacy and receipt whereof is hereby acknowledged by the Assignor) and as security for payment of the Secured Obligations, the Assignor with full title guarantee hereby assigns, and grants a security interest in, and agrees to assign, and grant a security interest in, to the Assignee absolutely all its right and title to and interest in the Insurances to hold the same absolutely unto the Assignee subject to the First Assignment, the Second Assignment, and the Third Assignment.

 

  3.2 Negative pledge

The Assignor undertakes that, except with the prior written consent of the Assignee, it will not at any time during the Security Period create or permit to subsist any Liens save for the First Assignment, the Second Assignment and the Third Assignment (and except for Permitted Liens) on all or any part of the Assignor’s right and title to and interest in the Insurances.

 

3


4 Notice of Assignment of Insurances

The Assignor undertakes immediately to give notice of the assignment of the Insurances contained in Clause 3 to all brokers, insurance companies, underwriters, protection and indemnity and/or war risk associations through whom any of the policies or entries relating to the Insurances are effected in the form of Schedule 5 and to obtain from such brokers, insurance companies or underwriters a letter of undertaking in the form of Schedule 6 or in such other form as the Agents may require and from such protection and indemnity or war risk associations in the form of Schedule 7 or in such other form as the Agents may agree.

 

5 Application of Proceeds of Insurances

All proceeds of the Insurances received by the Assignee pursuant to the assignment in this Deed shall be applied in accordance with the loss payable clauses endorsed on the Insurances, clause 8 of the Fourth Priority Security Co-ordination Deed and section 4.05 of the Credit Agreement.

 

6 Power of Attorney

The Assignor hereby irrevocably appoints and constitutes the Assignee as its true and lawful attorney with full power (in the name of the Assignor or otherwise) to demand, compound and give acquittance for any monies and claims for monies due or to become due, to endorse any cheque or other instrument or order in connection therewith and to file any claims or take any action or institute any proceedings which may seem to the Assignee to be necessary or advisable and otherwise to do any and all things which the Assignor itself could do in relation to the property hereby assigned provided that the power of attorney created by this Clause 6 shall take effect only from and after the occurrence of an Event of Default, subject to the provisions of the Fourth Priority Security Co-ordination Deed. The exercise of such power by the Assignee shall not put any person dealing with the Assignee on any enquiry and the exercise by the Assignee of such power shall be conclusive evidence of its right to exercise it. The Assignor hereby ratifies and confirms and agrees to ratify and confirm whatever an attorney appointed under this Deed shall do in its capacity as such, to the extent permissible hereunder.

 

7 Assignor’s Liability Unaffected by Assignment

 

  7.1 It is agreed that notwithstanding the assignment contained herein:

 

  7.1.1 the Assignee shall not be obliged to make any enquiries as to the nature or sufficiency of any payment received by the Assignee or its order under those assignments or to make any claim or take any other action to collect any monies or to enforce any rights and benefits assigned to the Assignee or to which the Assignee may at any time be entitled thereunder; and

 

  7.1.2 the Assignor shall remain liable to perform all the obligations assumed by it in relation to the Insurances and the Assignee shall not be under any obligation of any kind whatsoever in respect thereof or be under any liability whatsoever in the event of any failure by the Assignor to perform its obligations in respect thereof.

 

4


8 Continuing Security

 

  8.1 This Deed and the assignments herein shall be:

 

  8.1.1 a continuing security remaining in full force and effect until payment in full of each and every part of the Secured Obligations;

 

  8.1.2 in addition to and not in substitution for or in derogation of any other security held by the Assignee from time to time in respect of the Secured Obligations.

 

9 Further Assurance

The Assignor will, from time to time on being required to do so by the Assignee, do or procure the doing of all such acts and/or execute or procure the execution of all such documents in a form satisfactory to the Assignee as the Assignee may reasonably consider necessary for giving full effect to any of the Security Documents including this Deed or securing to the Assignee the full benefit of the rights, powers and remedies conferred upon the Assignee in any such Security Document including this Deed.

 

10 Enforcement Expenses

The Assignor shall reimburse the Assignee on demand for the charges and expenses (including the fees and expenses of legal advisors and value added tax or any similar tax thereon) incurred by it in connection with the enforcement of, or the preservation of, any rights under this Deed.

 

11 Waivers, Remedies Cumulative

 

  11.1 No waiver

No failure to exercise and no delay in exercising on the part of the Assignee any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any right or remedy preclude any other or further exercise thereof, or the exercise of any other right or remedy. No waiver by the Assignee shall be effective unless it is in writing.

 

  11.2 Remedies cumulative

The rights and remedies of the Assignee provided herein are cumulative and not exclusive of any rights or remedies provided by law.

 

  11.3 Severability

If any provision of this Deed or any of the other Security Documents is prohibited or unenforceable in any jurisdiction, such prohibition or unenforceability shall not invalidate the remaining provisions hereof or affect the validity or enforceability of such provision in any other jurisdiction.

 

  11.4 Time of essence

Time is of the essence in respect of all of the obligations of the Assignor under this Deed provided however that the Assignee shall not be entitled to enforce its rights under the assignment contained in this Deed otherwise than in circumstances which constitute an Event of Default, subject to the provisions of the Fourth Priority Security Co-ordination Deed.

 

5


12 Assignment

 

  12.1 Benefit of agreement

This Deed shall be binding upon the Assignor and its successors and assigns and shall inure to the benefit of the Assignee and their respective successors and assigns.

 

  12.2 Disclosure of information

Any of the Beneficiaries may disclose to a potential transferee or assignee or to any other person who may otherwise propose to enter into contractual relations with any of them in relation to this Deed such information about the Assignor as such Beneficiary shall consider appropriate subject always to the provisions of section 14.14 of the Credit Agreement where, for the purpose of this Deed, references to “Lender” shall be read and construed as “Beneficiary”.

12.3 Contracts (Rights of Third Parties) Act 1999 (the “Act”)

A person who is not a party to this Deed has no right under the Act to enforce any term of this Deed but this does not affect any right or remedy of a third party which exists or is available apart from the Act.

 

13 Discharge of Security

Following the repayment or payment to the Assignee of all the Secured Obligations, the Assignee will at the Assignor’s request and expense reassign to the Assignor the property assigned to the Assignee by this Deed without recourse to any representation or warranty by or from the Assignee.

 

14 Notices

All demands and notices made or given hereunder shall be made or given in accordance with section 14.03 of the Credit Agreement.

 

15 Governing Law and Jurisdiction

 

  15.1 This Deed and any non-contractual obligations arising from or in connection with it shall be governed by English law.

 

  15.2 The courts of England have exclusive jurisdiction to settle any dispute:

 

  15.2.1 arising out of or in connection with this Deed (including a dispute regarding the existence, validity or termination of this Deed); or

 

  15.2.2 relating to any non-contractual obligations arising from or in connection with this Deed,

(a “Dispute”). Each party to this Deed agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no party will argue to the contrary.

This Clause 15.2 is for the benefit of the Assignee only. As a result, such party shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, such party may take concurrent proceedings in any number of jurisdictions.

 

6


  15.3 The Assignor waives any objection which it may now or later have (whether on the ground of forum non conveniens or otherwise) to any proceedings relating to this Deed being brought in the courts of England or in any court which is covered by Clause 15.2.

 

  15.4 The Assignor agrees to comply with section 15.07 of the Credit Agreement relating to the Process Agent.

 

  15.5 A judgment relating to this Deed which is given or would be enforced by an English court shall be conclusive and binding on the Assignor and may be enforced without review in any other jurisdiction.

 

  15.6 Nothing in this Clause 15 shall exclude or limit any right which the Assignee may have (whether under the laws of any country, an international convention or otherwise) with regard to the bringing of proceedings, the service of process, the recognition or enforcement of a judgment or any similar or related matter in any jurisdiction.

 

  15.7 In this Clause “judgment” includes order, injunction, declaration and any other decision or relief made or granted by a court.

 

7


IN WITNESS whereof this Deed has been executed by the parties hereto on the day first written above.

 

SIGNED SEALED and DELIVERED as a DEED    )   
for and on behalf of    )   
PRIDE OF HAWAII, LLC    )   
by    )   
its duly appointed attorney-in-fact,    )   
who in accordance with the laws of that territory,    )   
is acting under the authority of the company    )   
SIGNED SEALED and DELIVERED as a DEED    )   
for and on behalf of    )   
KFW IPEX-BANK GMBH    )   
by    )   
who in accordance with the laws of that territory,    )   
is acting under the authority of the company    )   

 

8


Schedule 1

EUR308,130,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

9


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

10


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 74221 197
Attn: Mr Stephan Bachmann
Email: stephan.bachmann@ca-cib.com

 

11


with a copy to:

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED

Fax: +852 2868 1448
Attn: Mr Terence Yuen/Ms Iris Lai
Email: terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

12


Schedule 2

Part I

EUR258,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

13


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

14


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

Part II

EUR40,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

15


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

16


DVB BANK SE

Parklaan 2

3016 BB Rotterdam

The Netherlands

 

Fax: +5999 4652366
Attn: LAM/Eric Maduro
Email: lam.curacao@dvbbank.com/james.neira@dvbbank.com

Part III

USD334,050,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

(as trustee and agent)

 

17


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 1362 3742
Attn: Mr Klaus-Dieter Schmedding
Email: exportfinance@commerzbank.com

(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax: +44 (0)20 7992 4428
Attn: Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com

 

18


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

OVERSEA-CHINESE BANKING

CORPORATION LIMITED

Singapore Branch

65 Chulia Street #10-00

Singapore 049513

 

Fax: +65 6536 6449/6532 5347
Attn: Ms Lee King Lan/Ms Elaine Lam
Email: LeeKingLan@ocbc.com/LamSYElaine@ocbc.com

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

 

19


CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax: +49 69 74221 197
Attn: Mr Stephan Bachmann
Email: stephan.bachmann@ca-cib.com

with a copy to:

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED

Fax: +852 2868 1448
Attn: Mr Terence Yuen/Ms Iris Lai
Email: terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

20


Schedule 3

EUR624,000,000 Secured Loan Agreement dated 7 October 2005 as amended

and/or restated from time to time

Non-Guaranteed Trustee

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Mrs Solveig Nuland Knoff
Email: solveig.knoff@dnbnor.no

As trustee for:

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Mrs Solveig Nuland Knoff
Email: solveig.knoff@dnbnor.no

(as security agent and agent)

 

21


and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Germany

 

Fax: +49 40 3769 9649
Attn: Mr Stefan Kuch/Mr Marcus Weber/
     Mrs Anne Randewig
Email: shipfinance@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482020
Attn: Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email: amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 3768/2944
Attn: Mr Josef Schmid/Ms Claudia Wenzel
Email: josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

22


NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Germany

 

Fax: +49 511 361 4785
Attn: Mr Torsten Reinecke
Email: shipping@nordlb.de

NORDEA BANK NORGE ASA

Middelthuns gate 17

Oslo

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 22 484278
Attn: Mr Arne Berglund
Email: arne.berglund@nordea.com

BANK OF SCOTLAND PLC

Marine Finance

Second Floor

New Uberior House

11 Earl Grey Street

Edinburgh EH3 9BN

Scotland

 

Fax: +44 131 659 1194
Attn: Douglas Newton/Russell Parker
Email: douglas_newton@bankofscotland.co.uk

 

23


UNICREDIT BANK AG

(formerly known as Bayerische Hypo- und

Vereinsbank AG)

Alter Wall 22

20457 Hamburg

Germany

 

Fax: +49 40 3692 3696/+49 89 378 334 2832
Attn: Mr Peter-Alexander Wunner/
     Mr Michael McCarthy
Email: peter-alexander.wunner@unicreditgroup.de/
     michael.mccarthy@unicreditgroup.de

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Bremen and Hamburg

Domshof 17

28195 Bremen

Germany

 

Fax: +49 421 3609 329
Attn: Dr Matthias Fischer
Email: matthias.fischer@schiffsbank.com

FOKUS BANK

(being the Norwegian branch of Danske Bank A/S)

Stortingsgaten 6

P O Box 1170 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 85 407990
Attn: Mr Øivind Haraldsen/Mr Tore Thorlacius Braein
Email: oivind.haraldsen@fokus.no/
     tore.braein@fokus.no

 

24


HSH NORDBANK AG

Gerhart-Hauptmann-Platz 50

20095 Hamburg

Germany

 

Fax: +49 40 3333 613741
Attn: Mr Carsten Dreyer
Email: carsten.dreyer@hsh-nordbank.com

 

Fax: +1 212 407 6008
Attn: Ms Frauke Hay
Email: frauke.hay@hsh-nordbank.com

SKANDINAVISKA ENSKILDA BANKEN AB (publ)

Kungsträdgårdsgatan 8

SE-106 40 Stockholm

Sweden

 

Fax: +44 20 7236 5144
Attn: Mr Egil Aarrestad/Mr Malcolm Stonehouse
Email: egil.aarrestad@seb.co.uk/
     malcolm.stonehouse@seb.co.uk

 

25


Schedule 4

EUR126,075,000 Credit Agreement effective November 18, 2010 as amended and/or

restated from time to time

Trustee:

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 2944
Attn: Ship Finance, X2a4
     Claudia Wenzel
Email: Claudia.wenzel@kfw.de

As Trustee for:

NORDEA BANK NORGE ASA

Middelthunsgate 17

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax: +47 22 486668
Attn: Mr Arne Berglund
Email: arne.berglund@nordea.com

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 8

D – 20095 Hamburg

Germany

 

Fax: +49 40 3769 9649
Attn: Mr Marcus Weber
     Ms Anne Randewig
Email: marcus.weber@commerzbank.com
     anne.randewig@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax: +47 22 482894
Attn: Ms Amra Koluder
     Mr Solveig N. Knoff
Email: amra.koluder@dnbnor.no
     solveig.knoff@dnbnor.no

 

26


KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax: +49 69 7431 4466/ 2944
Attn: Mr Stephan Pueschel
     Mr Christian Schweiger
Email: stephan.pueschel@kfw.de
     christian.schweiger@kfw.de

HSBC BANK PLC

8 Canada Square

London E14 5HQ

 

Fax: +44 207 992 4428
Attn: Alan P. Marshall
Email: alan.p.marshall@hsbcib.com

And each other Secured Creditor under and as defined in the Credit Agreement.

 

27


Schedule 5

Notice of Assignment

(for attachment by way of endorsement to the Policy)

We, PRIDE OF HAWAII, LLC of Wilmington, Delaware, United States of America, the owners of the motor vessel “NORWEGIAN JADE” (the “Vessel”) hereby give notice that by a fourth legal assignment dated                         2010 entered into by us with KFW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for certain secured parties (the “Assignee”) and in consideration of (a) certain secured parties making certain facilities available to the Assignor pursuant to a credit agreement, any interest rate protection agreement and/or any other hedging agreement, (b) payment by the Assignee to us of ten Dollars (USD10) and (c) other good and valuable consideration from the Assignee to us (the adequacy and receipt whereof we hereby acknowledge), and as security for payment of the obligations under the credit document and related agreements, we have assigned, and granted a fourth priority security interest in and to, absolutely all our right and title to and interest in all insurances in respect of the Vessel, including the insurances constituted by the policy on which this notice is endorsed.

Please note that this Notice may not be revoked or varied without the prior written consent of the Assignee.

 

PRIDE OF HAWAII, LLC
By:  

 

Title:

Date:                     2010

 

28


Schedule 6

 

To:    []
   as Assignee

Dated:                     2010

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

PRIDE OF HAWAII, LLC (the “Assignor”)

We confirm that we have effected insurances for the account of the Assignor as set out in Appendix “A” attached.

Pursuant to instructions received from the Assignor and/or their authorised managers or agents and in consideration of your approving us as the appointed brokers in connection with the insurances covered by this letter, we hereby undertake:

 

1. to hold the insurance slips or contracts, the policies when issued, and any renewals of such policies or any policies substituted therefor with your consent as may be arranged through ourselves and the benefit of the insurances thereunder to your order in accordance with the terms of the Loss Payable Clause set out in Appendix “B” attached; and

 

2. to arrange for the said Loss Payable Clause to be included on the policies when issued; and

 

3. to have endorsed on each and every policy as and when the same is issued a Notice of Assignment in the form of Appendix “C” hereto dated and signed by the Assignor and acknowledged by underwriters in accordance with market practice; and

 

4. to advise you promptly if we cease to be the brokers for the Assignor or in the event of any material changes of which we are aware affecting the said insurance; and

 

5. following a written application received from you not later than one month before expiry of these insurances to notify you within fourteen days of the receipt of such application in the event of our not having received notice of renewal instructions from the Assignor and/or their authorised managers or agents, and in the event of our receiving instructions to renew to advise you promptly of the details thereof; and

 

6. to forward to you promptly any notices of cancellation that we receive from underwriters; and

 

7. following a written application from you to advise you promptly of the premium payment situation where such premium is paid or payable through our intermediary; and

 

29


8. not to change the effectiveness of the assignment to the assignee of the insurances constituted by this policy; and

 

9. not to revoke, modify or change the terms of the Loss Payable Clause or the undertakings made herein without the written consent of the Assignee.

If and where we are responsible for the payment of premium to underwriters, our above undertakings are given subject to our lien on the policies for premiums and subject to our right of cancellation on default in payment of such premiums but we undertake not to exercise such rights of cancellation without giving you ten days notice in writing either by letter or electronically transmitted message and a reasonable opportunity for you to pay any premiums outstanding.

It is understood and agreed that the operation of any automatic termination of cover, cancellation or amendment provisions contained in the policy conditions shall override any undertakings given by us as brokers.

Notwithstanding the terms of the said Loss Payable Clause and the said Notice of Assignment, unless and until we receive written notice from you to the contrary, we shall be empowered to arrange for a collision and/or salvage guarantee to be given in the event of bail being required in order to prevent the arrest of the Vessel or to secure the release of the Vessel from arrest following a casualty. Where a guarantee has been given as aforesaid and the guarantor has paid any sum under the guarantee in respect of such claim, there shall be payable directly to the guarantor out of the proceeds of the said policies a sum equal to the sum so paid.

This undertaking shall be governed by and construed in accordance with English law and any disputes arising out of or in any way connected with this undertaking shall be submitted to the exclusive jurisdiction of the English courts.

This undertaking is subject to all claims and returns of premiums being collected through us as brokers.

Yours faithfully

 

30


Appendix A to letter of undertaking

Details of insurances

 

31


Appendix B to letter of undertaking

Loss Payable Clause

It is noted that by a fourth assignment in writing dated                         2010 the shipowner PRIDE OF HAWAII, LLC (the “Assignor”) has assigned to KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee (the “Assignee”) all the Assignor’s right, title, benefits and interests in this policy and all benefits hereof including all claims of whatsoever nature hereunder. All claims in respect of a total or constructive total or an arranged or agreed or compromised total loss or requisition of the Vessel shall be paid to the Assignee. All other claims payable either in respect of a major casualty (that is to say any casualty in respect whereof the claim or the aggregate of the claims exceeds [*] shall be paid to the Assignor or its order, subject to the prior written consent of the Assignee. All other claims, unless and until the underwriters have received notice from the Assignee of a default under the mortgage dated                         2010, in which event all claims under this policy of Insurance shall be payable direct to the Assignee, shall be released directly for the repair, salvage or other charges involved or, if the Assignor has paid such charges, in reimbursement thereof to the Assignor. Please note that this Notice may not be revoked or varied without the prior written consent of the Assignee.

 

32


Appendix C to letter of undertaking

Notice of Assignment

(for attachment by way of endorsement to the Policy)

We, PRIDE OF HAWAII, LLC of Wilmington, Delaware, United States of America, the owners of the motor vessel “NORWEGIAN JADE” (the “Vessel”) hereby give notice that by a fourth assignment dated                     2010 entered into by us with KFW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for certain secured parties (the “Assignee”) and in consideration of (a) certain secured parties making certain facilities available to the Assignor pursuant to a credit agreement, any interest rate protection agreement and/or any other hedging agreement, (b) payment by the Assignee to us of ten Dollars (USD10) and (c) other good and valuable consideration from the Assignee to us (the adequacy and receipt whereof we hereby acknowledge), and as security for payment of the obligations under the credit document and related agreements, we have assigned, and granted a fourth priority security interest in and to, absolutely all our right and title to and interest in all insurances in respect of the Vessel, including the insurances constituted by the policy on which this notice is endorsed.

 

PRIDE OF HAWAII, LLC
By:  

 

Title:

Date:                    2010

 

33


Schedule 7

 

To:    []
   as trustees (the “Assignee”)

Dated:                             2010

Dear Sirs

m.v. “NORWEGIAN JADE” (Official Number 9000236) (the “Vessel”)

PRIDE OF HAWAII, LLC (the “Assignor”)

We acknowledge receipt of notice of an assignment to the Assignee of the insurances on the Vessel. So far as [                    ] (the ASSOCIATION”) is concerned, the managers do not consent to such assignment for the purposes of Rule [    ], other than to give efficacy to the Loss Payable Clause set out below and subject always to the Association’s right under Rule [    ].

We do confirm however that the Vessel is entered in this Association for Protection and Indemnity risks on the terms and conditions set out or to be set out in the Certificate of Entry. Furthermore, in consideration of your agreeing to the entry or continuing entry of the Vessel in this Association, the managers agree:

 

1. that the Assignor shall not cease to be insured by the Association in respect of the Vessel by reason of such assignment (see Rule [    ]); and

 

2. that, notwithstanding that the Vessel is mortgaged to the Assignee and that no undertaking or guarantee has been given to the Association to pay all contributions due in respect of the Vessel, the Assignor do not cease to be insured by reason of the operation of Rule [    ].

It is further agreed that the following Loss Payable Clause will be included in the Certificate of Entry:

“Payment of any recovery the Assignor are entitled to make out of the funds of the Association in respect of any liability, cost or expense incurred by them shall be made to the Assignor or their order unless and until the Association receives notice to the contrary from [] as trustees pursuant to an assignment of insurances over the vessel “NORWEGIAN JEWEL” dated                  2010 stating that a default has occurred under the Mortgage dated                 2010, in which event all recoveries shall thereafter be paid to the said [] as trustees or their order; provided always that no liability whatsoever shall attach to the Association, its Managers or their Agents for failure to comply with the latter obligation until after the expiry of two (2) clear business days from the receipt of such notice.”

The Association undertakes:

 

1. to inform you if the directors give the Assignor notice under Rule [    ] that their insurance in the Association in respect of the Vessel is to cease at the end of the then current policy year;

 

34


2. to give you ten (10) days’ notice of the Association’s intention to cancel the insurance of the Assignor by reason of their failure to pay when due and demanded any sum due from them to the Association.

Yours faithfully

 

35


EXHIBIT H

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

DATED                         2010

PRIDE OF HAWAII, LLC

(as owner)

to

KFW IPEX-BANK GMBH,

(as mortgagee)

 

 

FORM OF FOURTH DEED OF COVENANTS

m.v. “NORWEGIAN JADE”

 

 


TABLE OF CONTENTS

 

         Page  

1

 

Definitions

     2   

2

 

Owner’s Covenant to Pay and Perform

     4   

3

 

Mortgage

     5   

4

 

Owner’s Covenants

     5   

5

 

Owner’s Insurance Covenants

     5   

6

 

Owner’s Covenants as to Operation and Maintenance

     11   

7

 

Protection and Maintenance of Security

     18   

8

 

Mortgagee’s Powers

     18   

9

 

Ancillary Provisions

     20   

10

 

Receiver

     20   

11

 

Appropriation

     21   

12

 

Power of Attorney

     21   

13

 

Further Assurance

     22   

14

 

Discharge of Security

     22   

15

 

Notices

     22   

16

 

Governing Law and Submission to Jurisdiction

     22   

17

 

Miscellaneous

     23   

Schedule 1

     2   

Schedule 2

     6   

Schedule 3

     14   

Schedule 4

     19   

 

(i)


DEED OF COVENANTS

Dated                                             2010

BETWEEN

 

(1) PRIDE OF HAWAII, LLC a Delaware corporation and having its registered office at Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Owner”); and

 

(2) KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, acting not in its own individual capacity but solely as trustee and collateral agent for the Beneficiaries pursuant to the Security Trust Deed and the Credit Agreement (the “Mortgagee”).

WHEREAS:

 

(A)

The Owner is the absolute legal and beneficial owner of all the sixty four sixty fourth (64/64th) shares of and in the motor vessel “NORWEGIAN JADE” registered in the name of the Owner under the Bahamian flag at the port of Nassau with Official Number 9000236.

 

(B)

Pursuant to a first priority mortgage over the Vessel dated 10 February 2008 covering 64/64th of the Vessel (the “First Mortgage”) the Owner mortgaged the whole of the Vessel upon the terms and conditions contained therein to HSBC Bank Plc of 8 Canada Square, London, E14 5HQ as trustee for the parties set out in Schedule 1 (the “First Mortgagee”).

 

(C)

Pursuant to a second priority mortgage over the Vessel dated 2 April 2009 covering 64/64th of the Vessel (the “Second Mortgage”) the Owner mortgaged the whole of the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the parties set out in Schedule 2 (the “Second Mortgagee”).

 

(D)

Pursuant to a third priority mortgage over the Vessel dated 2 April 2009 covering 64/64th of the Vessel (the “Third Mortgage”) the Owner mortgaged the whole of the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and for the parties set out in Schedule 3 (the “Third Mortgagee”).

 

(E) Pursuant to the Credit Agreement, and in consideration of the obligations of the Beneficiaries (as defined below) under or pursuant to the Junior Finance Documents, the Owner has executed and delivered in favour of the Mortgagee a fourth priority Bahamian statutory mortgage and has agreed to enter into this Deed to mortgage and charge the Mortgaged Premises in favour of the Mortgagee as trustee for itself and the Beneficiaries as security for the repayment of the Secured Obligations (as defined below).

 

(F) By a deed of co-ordination dated as of the date hereof (the “Fourth Priority Security Co-ordination Deed”) made between (among others) (1) the First Mortgagee, (2) the Second Mortgagee, (3) the Third Mortgagee and (4) the Mortgagee the parties have agreed (among other things) as to how the provisions of Clause 11 shall operate. Further by the Fourth Priority Security Co-ordination Deed it has been agreed that the benefit of this Mortgage shall be held by the Mortgagee on trust for itself and the Secured Creditors, including the Secured Creditors set out in Schedule 4, and its and their respective successors, assignees and transferees (together the “Beneficiaries”).


NOW THIS DEED WITNESSETH AND IT IS HEREBY AGREED as follows:

 

1 Definitions

In this Deed the following terms shall have the meanings set out below; in addition, defined terms and expressions used but not defined herein and whose meanings are defined in the Credit Agreement shall have the same meanings when used in this Deed. The headings used in this Deed are for reference only, and have no legal or other significance, and shall be ignored in the interpretation of this Deed.

“Annex VI” means Annex VI (Regulations for the Prevention of Air Pollution from Ships) to the International Convention for the Prevention of Pollution from Ships 1973 (as modified in 1978 and 1997) (as the same may be amended from time to time);

“Assigned Property” means the Insurances, the Earnings and the Requisition Compensation;

“Compulsory Acquisition” means requisition for title or other compulsory acquisition of the Vessel including its capture, seizure, detention or confiscation or expropriation but excluding any requisition for hire by or on behalf of any government or governmental authority or agency or by any persons acting or purporting to act on behalf of any such government or governmental authority or agency;

“Compulsory Acquisition Compensation” means all moneys or other compensation whatsoever payable by reason of the Compulsory Acquisition of the Vessel (otherwise than by requisition for hire);

“Credit Agreement” means that certain €126,075,000 Credit Agreement dated November [], 2010, among NCL Corporation Ltd., as parent (the “Parent”), the Owner, as borrower, various lenders from time to time party thereto (the “Lenders”), the Mortgagee, as facility agent and collateral agent, Nordea Bank Norge ASA, as documentation agent, Commerzbank AG, as Hermes agent, and other parties thereto, as amended, novated and/or restated or otherwise modified from time to time.

“Document of Compliance” means a document issued to a vessel operator as evidence of its compliance with the requirements of the ISM Code;

“Earnings” means, in respect of the Vessel, (whether earned or to be earned) any and all freights, hire and passage monies, proceeds of requisition (other than proceeds of Compulsory Acquisition), rebates and commissions, all earnings deriving from contracts of affreightment, pooling agreements, joint ventures, compensation, remuneration for salvage and towage services, damages howsoever arising and detention monies, damages for breach of any charterparty or other contract for the employment of the Vessel, any amounts payable in consideration of the termination or variation of any charterparty or other such contract, any reduction in the Hermes Premium repaid by Hermes to the Owner and any other earnings whatsoever due or to become due to the Owner;

“Event of Default” has the meaning ascribed to it in the Credit Agreement;

 

2


“IAPPC” means an international air pollution prevention certificate issued under Annex VI;

“Insurances” means all policies and contracts of insurance of the Vessel and entries of the Vessel in a protection and indemnity or war risks association which are effected in respect of the Vessel, its freights, disbursements, profits or otherwise and all benefits, including all claims and returns of premiums thereunder and shall also include all compensation payable by virtue of Compulsory Acquisition of the Vessel;

“ISM Code” means the International Management Code for the Safe Operation of Ships and for Pollution Prevention adopted by the International Maritime Organisation;

“ISPS Code” means the International Ship and Port Facility Security Code adopted by the International Maritime Organisation;

“ISSC” means an international ship security certificate issued for a vessel under the ISPS Code;

Junior Finance Documents” means the “Credit Documents”, as such term is defined in the Credit Agreement;

“Lender Creditors means the Lenders and the Agents under the Credit Agreement, each in their respective capacities.

“the Manager” means NCL (Bahamas) Ltd.;

“the Mortgaged Premises” includes:

 

  (a) the Vessel; and

 

  (b) the Compulsory Acquisition Compensation;

Obligors” means the Credit Parties, as such term is defined in the Credit Agreement;

“Other Creditors means any Lender or any affiliate thereof and their successors, transferees and assigns if any (even if such Lender subsequently ceases to be a Lender under the Credit Agreement for any reason), together with such Lender’s or affiliate’s successors, transferees and assigns, with which the Parent and/or the Owner enters into any Interest Rate Protection Agreements or Other Hedging Agreements from time to time.

“person” includes any body of persons;

“Requisition Compensation” means all compensation or other money which may from time to time be payable to the Owner as a result of the Compulsory Acquisition of the Vessel;

“Safety Management Certificate” means a document issued to a vessel as evidence that the vessel operator and its shipboard management operate in accordance with an approved Safety Management System;

“Safety Management System” means a structured and documented system enabling the personnel of a vessel operator to implement effectively the safety and environmental protection policy of such vessel operator;

 

3


Secured Creditors” means collectively (i) the Lender Creditors and (ii) the Other Creditors;

Secured Obligations” has the meaning ascribed to such term in the Credit Agreement;

Security Documents” has the meaning ascribed to such term in the Credit Agreement;

“Security Period” means the period beginning on the date of this Deed and ending on the date when the whole of the Secured Obligations have been repaid in full and the Owner has ceased to be under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement) under or in connection with any of the Security Documents;

“Security Trust Deed” means the Security Trust Deed executed on or about the date hereof by, inter alia, the Owner, the Guarantor, the Mortgagee, the Original Secured Creditors (as defined therein) and the Original Term Hedging Creditors (as defined therein).

“Senior Loan Agreement” means the document referred to in Schedule 1;

“Senior Security Documents” means the documents listed in schedule 1, schedule 2 and schedule 3 of the Fourth Priority Security Co-ordination Deed and any other document which may at any time be executed by any person as security for the payment of all or any part of the Senior Indebtedness (as defined in the Fourth Priority Security Co-ordination Deed);

“Total Loss” means any actual or constructive or arranged or agreed or compromised total loss or Compulsory Acquisition of the Vessel; and

“Vessel” means the motor vessel more particularly described in Recital (A) hereto and includes any share or interest therein and its engines, machinery, boats, tackle, outfit, spare gear, fuel, consumable or other stores, belongings and appurtenances whether on board or ashore and whether now owned or hereafter acquired;

“war risks” includes the risks of mines and all risks excluded from the standard form of English marine policy by the free of capture and seizure clause.

 

2 Owner’s Covenant to Pay and Perform

The Owner covenants with the Mortgagee to discharge the Secured Obligations on demand from time to time in accordance with the Credit Agreement, and to pay all other sums at any time due under or pursuant to the Junior Finance Documents in each case at the times and in the manner provided therein and to perform all its other obligations arising out of the Junior Finance Documents as and when the same shall be due for performance.

 

3 Mortgage

 

  3.1

By way of security for the payment of the Secured Obligations and the performance and observance of and compliance with the covenants, terms and conditions contained in any of the Junior Finance Documents, the Owner with full title guarantee hereby mortgages and charges to and in favour of the Mortgagee all its interest, present and future, in the Mortgaged Premises (which the Owner hereby

 

4


 

warrants to be free at the date hereof from any other charge or encumbrance whatsoever other than the First Mortgage, the Second Mortgage and the Third Mortgage).

 

  3.2 It is declared and agreed that the Security Documents shall be held by the Mortgagee as a continuing security for the payment of the Secured Obligations and that the security so created shall not be satisfied by any intermediate payment or satisfaction of any part of the amount hereby and thereby secured and that the security so created shall be in addition to and shall not in any way be prejudiced or affected by any collateral or other security now or hereafter held by the Mortgagee for all or any part of the moneys hereby and thereby secured and that every power and remedy given to the Mortgagee hereunder shall be an addition to and not a limitation of any and every other power or remedy vested in the Mortgagee under any of the other Security Documents and that all the powers so vested in the Mortgagee may be exercised from time to time and as often as the Mortgagee may deem expedient.

 

4 Owner’s Covenants

 

  4.1 The Owner covenants with the Mortgagee to insure the Vessel in accordance with Clause 5 throughout the Security Period.

 

  4.2 The Owner covenants with the Mortgagee to operate and maintain the Vessel in accordance with Clause 6 and in particular but without limitation not to create or permit to subsist any Liens on the whole or any part of the Assigned Property except for the First Mortgage, the Second Mortgage and the Third Mortgage and any Liens created with the prior consent of the Mortgagee or Permitted Liens.

 

5 Owner’s Insurance Covenants

 

  5.1 The Owner covenants with the Mortgagee and undertakes throughout the Security Period:

5.1.1 to insure the Vessel, or to procure that the Vessel is insured, in its name and keep the Vessel and procure that the Vessel is kept insured on an agreed value basis for an amount in Dollars as approved by the Mortgagee provided that the insured value of the Vessel shall at all times be equal to or greater than [*] of the Total Commitment under the Credit Agreement, and the hull and machinery insured value for the Vessel to be at all times equal to no less than [*] of the total insured value of the Vessel and [*] of the total insured value of the Vessel shall consist of hull interest and freight interest insurance through internationally recognised independent first class insurance companies, underwriters, war risks and protection and indemnity associations reasonably acceptable to the Mortgagee in each instance on terms and conditions approved by the Mortgagee (with such approval not to be unreasonably withheld) including as to deductibles but at least in respect of:

 

  (1) marine risks including all risks customarily and usually covered by first-class and prudent shipowners in the London insurance markets under English marine policies or the Norwegian Plan or Mortgagee-approved policies containing the ordinary conditions applicable to similar vessels;

 

5


  (2) war risks including the Missing Vessel Clause, terrorism, piracy and confiscation, and, should Institute War and Strike Clauses, Hulls Conditions prevail, the London Blocking and Trapping Addendum and war risks (protection and indemnity) with a separate limit and in excess of the amount for war risks (hull);

 

  (3) excess risks that is to say the proportion of claims for general average and salvage charges and under the running down clause not recoverable in consequence of the value at which the Vessel is assessed for the purpose of such claims exceeding the insured value;

 

  (4) protection and indemnity risks with full standard coverage and up to the highest limit of liability available (for oil pollution risk the highest limit currently available is [*] for pollution risk and this to be increased if requested by the Mortgagee and the increase is possible in accordance with the standard protection and indemnity cover for vessels of her type and is compatible with prudent insurance practice for first class cruise shipowners or operators in waters where the Vessel trades from time to time during the Security Period);

 

  (5) when and while the Vessel is laid-up, in lieu of hull insurance, normal port risks;

 

  (6) such other risks as the Mortgagee may from time to time reasonably require;

and in any event in respect of those risks and at those levels covered by first class and prudent owners and/or financiers in the international market in respect of similar tonnage PROVIDED THAT if any of such insurances are also effected in the name of any other person (other than the Owner or the Mortgagee) such person shall if so required by the Mortgagee execute a preferred assignment of its interest in such insurances in favour of the Mortgagees in similar terms mutatis mutandis to the Assignment of Insurances (as defined in the Credit Agreement) PROVIDED FURTHER THAT the Owner has first obtained the consent of the First Mortgagee, the Second Mortgagee and the Third Mortgagee to such an assignment;

5.1.2 the Mortgagee at the cost of the Owner or the Parent shall take out, in each case, for an amount in Dollars approved by the Mortgagee but not being, collectively, less than [*] of the then applicable Total Commitment, mortgagee interest insurance and mortgagee additional perils insurance for pollution risks on such conditions as the Mortgagee may reasonably require, the Parent and the Owner having no interest or entitlement in respect of such policies; the Mortgagee undertakes to use its reasonable endeavours to match the premium level that the Parent or the Owner would have paid if they had arranged such cover on such conditions (as demonstrated to the reasonable satisfaction of the Mortgagee);

5.1.3 if the Vessel shall trade in the United States of America and/or the Exclusive Economic Zone of the United States of America (the “EEZ”) as such term is defined in the US Oil Pollution Act 1990 (“OPA”), to comply strictly with the requirements of OPA and any similar legislation which may from time to time be enacted in any jurisdiction in which the Vessel presently trades or may or will

 

6


trade at any time during the existence of this Deed and in particular before such trade is commenced and during the entire period during which such trade is carried on:

(a) to pay any additional premiums required to maintain protection and indemnity cover for oil pollution up to the limit available to it for the Vessel in the market;

(b) to make all such quarterly or other voyage declarations as may from time to time be required by the Vessel’s protection and indemnity association and to comply with all obligations in order to maintain such cover, and promptly to deliver to the Mortgagee copies of such declarations;

(c) to submit the Vessel to such additional periodic, classification, structural or other surveys which may be required by the Vessel’s protection and indemnity insurers to maintain cover for such trade and promptly to deliver to the Mortgagee copies of reports made in respect of such surveys;

(d) to implement any recommendations contained in the reports issued following the surveys referred to in sub-clause (c) above within the time limit specified therein and to provide evidence satisfactory to the Mortgagee that the protection and indemnity insurers are satisfied that this has been done;

(e) in particular strictly to comply with the requirements of any applicable law, convention, regulation, proclamation or order with regard to financial responsibility for liabilities imposed on the Owner or the Vessel with respect to pollution by any state or nation or political subdivision thereof, including but not limited to OPA, and to provide the Mortgagee on demand with such information or evidence as it may reasonably require of such compliance;

(f) to procure that the protection and indemnity insurances do not contain a clause excluding the Vessel from trading in waters of the United States of America and the EEZ or any other provision analogous thereto and to provide the Mortgagee with evidence that this is so; and

(g) strictly to comply with any operational or structural regulations issued from time to time by any relevant authorities under OPA so that at all times the Vessel falls within the provisions which limit strict liability under OPA for oil pollution;

5.1.4 to give notice forthwith of any assignment and/or transfer of its interest in the Insurances to the relevant brokers, insurance companies, underwriters and/or associations in the form reasonably approved by the Mortgagee;

5.1.5 to execute and deliver all such documents and do all such things as may be necessary to confer upon the Mortgagee legal title to the Insurances in respect of the Vessel and to procure that the interest of the Mortgagee is at all times filed with all slips, cover notes, policies and certificates of entry and to procure (a) that a loss

 

7


payable clause in the form reasonably approved by the Mortgagee and exceeding [*] shall be filed with all the hull, machinery and equipment and war risks policies in respect of the Vessel and (b) that a loss payable clause in the form reasonably approved by the Mortgagee and exceeding [*] shall be endorsed upon the protection and indemnity certificates of entry in respect of the Vessel;

5.1.6 to cause such insurance broker and the P & I club or association providing P & I insurance to agree to advise the Mortgagee by telex or telecopier confirmed by letter of any expiration, termination, alteration or cancellation of any policy, any default in the payment of any premium and of any other act or omission on the part of the Owner of which it has knowledge and which might invalidate or render unenforceable, in whole or in part, any insurance on the Vessel, and to provide an opportunity of paying any such unpaid premium or call, such right being exercisable by the Mortgagee on a vessel by vessel and not on a fleet basis. In addition, the Parent or the Owner shall promptly provide the Mortgagee with any information which the Mortgagee reasonably requests for the purpose of obtaining or preparing any report from an independent marine insurance consultant as to the adequacy of the insurances effected or proposed to be effected in accordance with the provisions contained herein and in the Credit Agreement as of the date hereof or in connection with any renewal thereof, and the Owner shall upon demand indemnify the Mortgagee in respect of all reasonable fees and other expenses incurred by or for the account of the Mortgagee in connection with any such report; provided the Mortgagee shall be entitled to such indemnity only for one such report during any period of twelve months.

5.1.7 to procure that each of the relevant brokers and associations furnish the Mortgagee with a letter of undertaking in such usual form as may be reasonably required by the Mortgagee and waives any lien for premiums or calls except in relation to premiums or calls attributable to the Vessel;

5.1.8 punctually to pay all premiums, calls, contributions or other sums payable in respect of the Insurances on the Vessel and to produce all relevant receipts when so required by the Mortgagee;

5.1.9 to renew each of the Insurances on the Vessel at least [*] days before the expiry thereof and to give immediate notice to the Mortgagee of such renewal and to procure that the relevant brokers or associations shall promptly confirm in writing to the Mortgagee that such renewal is effected it being understood by the Owner that any failure to renew the Insurances on the Vessel at least [*] days before the expiry thereof or to give or procure the relevant notices of such renewal shall constitute an Event of Default;

5.1.10 to arrange for the execution of such guarantees as may from time to time be required by any protection and indemnity and/or war risks association;

5.1.11 to furnish the Mortgagee from time to time on request with full information about all Insurances maintained on the Vessel and the names of the offices, companies, underwriters, associations or clubs with which such Insurances are placed;

 

  5.1.12

not to agree to any variation in the terms of any of the Insurances on the Vessel without the prior approval of the Mortgagee (which approval shall not be unreasonably withheld) (save in circumstances where the variation is

 

8


 

imposed by the insurers or reinsurers without requiring the Owner’s consent in which case the Owner shall notify the Mortgagee of such variation in a timely manner) nor to do any act or voluntarily suffer or permit any act to be done whereby any Insurances shall or may be rendered invalid, void, voidable, suspended, defeated or unenforceable and not to suffer or permit the Vessel to engage in any voyage nor to carry any cargo not permitted under any of the Insurances without first obtaining the consent of the insurers or reinsurers concerned and complying with such requirements as to payment of extra premiums or otherwise as the insurers or reinsurers may impose. If a variation in the terms of the Insurances is imposed as aforesaid and in the absolute opinion of the Mortgagee its interest in the Insurances is thereby materially adversely affected and/or the proceeds of the Insurances payable to the Mortgagee would be adversely affected, the Owner undertakes promptly to make such changes to the Insurances, or such alternative Insurance arrangements, provided that such alternative Insurance arrangements are available in the insurance market to the Owner at that time, as the Mortgagee shall reasonably require;

5.1.13 not without the prior written consent of the Mortgagee to settle, compromise or abandon any claim in respect of any of the Insurances on the Vessel other than a claim of less than [*] or the equivalent in any other currency and not being a claim arising out of a Total Loss;

5.1.14 promptly to furnish the Mortgagee with full information regarding any casualties or other accidents or damage to the Vessel involving an amount in excess of [*];

5.1.15 to apply or ensure the appliance of all such sums receivable in respect of the Insurances on the Vessel for the purpose of making good the loss and fully repairing all damage in respect whereof the insurance moneys shall have been received; and

5.1.16 that in the event of the Owner defaulting in insuring and keeping insured the Vessel as hereinbefore provided then the Mortgagee may (but shall not be bound to) insure the Vessel or enter the Vessel in such manner and to such extent as the Mortgagee in its discretion thinks fit and in such case all the cost of effecting and maintaining such insurance together with Interest thereon shall be paid on demand by the Owner to the Mortgagee.

 

6 Owner’s Covenants as to Operation and Maintenance

 

  6.1 The Owner covenants with the Mortgagee and undertakes throughout the Security Period at the Owner’s own expense that it will in respect of the Vessel:

 

  6.1.1

keep her in a good and efficient state of repair so as to maintain her to the highest classification available for a vessel of her age and type free of all recommendations and qualifications with Det Norske Veritas or such other classification society acceptable to the Mortgagee (acting on the instructions of the Required Lenders). On the date hereof and annually thereafter, it will furnish to the Mortgagee a statement by such classification society that such classification is maintained. It will comply with all recommendations, regulations and requirements (statutory or otherwise) from time to time applicable to the Vessel and shall have on board as and

 

9


 

when required thereby valid certificates showing compliance therewith and shall procure that all repairs to or replacements of any damaged, worn or lost parts or equipment are carried out (both as regards workmanship and quality of materials) so as not to diminish the value or class of the Vessel. It will not make any substantial modifications or alterations to the Vessel or any part thereof without the prior consent of the Mortgagee;

 

  6.1.2 submit her to continuous survey in respect of her machinery and hull and such other surveys as may be required for classification purposes and, if so required by the Mortgagee, supply to the Mortgagee copies in English of the survey reports;

 

  6.1.3 permit surveyors or agents appointed by the Mortgagee to board the Vessel at all reasonable times to inspect her condition or satisfy themselves as to repairs proposed or already carried out and afford all proper facilities for such inspections;

 

  6.1.4 comply, or procure that the Manager will comply, with the ISM Code or any replacement of the ISM Code and in particular, without prejudice to the generality of the foregoing, as and when required to do so by the ISM Code and at all times thereafter:

 

    (a) hold, or procure that the Manager holds, a valid Document of Compliance duly issued to the Owner or the Manager (as the case may be) pursuant to the ISM Code and a valid Safety Management Certificate duly issued to the Vessel pursuant to the ISM Code;

 

    (b) provide the Mortgagee with copies of any such Document of Compliance and Safety Management Certificate as soon as the same are issued; and

 

    (c) keep, or procure that there is kept, on board the Vessel a copy of any such Document of Compliance and the original of any such Safety Management Certificate;

6.1.5 comply, or procure that the Manager will comply, with the ISPS Code or any replacement of the ISPS Code and in particular, without limitation:

 

  (a) procure that the Vessel and the company responsible for the Vessel’s compliance with the ISPS Code comply with the ISPS Code;

 

  (b) maintain for the Vessel throughout the Security Period a valid and current ISSC; and

 

  (c) provide the Mortgagee with a copy of any such ISSC as soon as the same is issued;

 

  6.1.6 comply, or procure that the Manager will comply, with Annex VI or any replacement of Annex VI and in particular, without limitation, to:

 

    (a) procure that the Vessel’s master and crew are familiar with, and that the Vessel complies with, Annex VI;

 

10


    (b) maintain for the Vessel throughout the Security Period a valid and current IAPPC and provide a copy to the Mortgagee; and

 

    (c) notify the Mortgagee immediately in writing of any actual or threatened withdrawal, suspension, cancellation or modification of the IAPPC;

6.1.7 not employ the Vessel or permit her employment in any trade or business which is forbidden by any applicable law or is otherwise illicit or in carrying illicit or prohibited goods or in any manner whatsoever which may render her liable to condemnation in a prize court or to destruction, seizure or confiscation or that may expose the Vessel to penalties. In the event of hostilities in any part of the world (whether war be declared or not) it will not employ the Vessel or permit her employment in carrying any contraband goods;

6.1.8 promptly provide the Mortgagee with:

 

  (a) all information which the Mortgagee may reasonably require regarding the Vessel, her employment, earnings, position and engagements;

 

  (b) particulars of all towages and salvages; and

 

  (c) copies of all charters and other contracts for her employment and otherwise concerning her;

6.1.9 give notice to the Mortgagee promptly and in reasonable detail upon any Obligor becoming aware of:

 

  (a) accidents to the Vessel involving repairs the cost of which will or is likely to exceed [*];

 

  (b) the Vessel becoming or being likely to become a Total Loss or a Compulsory Acquisition;

 

  (c) any recommendation or requirement made by any insurer or classification society or by any competent authority which is not complied with within any time limit relating thereto;

 

  (d) any writ or claim served against or any arrest of the Vessel or the exercise of any lien or purported lien on the Vessel, her Earnings or Insurances;

 

  (e) the occurrence of any Event of Default;

 

  (f) the Vessel ceasing to be registered as a Bahamas vessel or anything which is done or not done whereby such registration may be imperilled;

 

  (g) it becoming impossible or unlawful for it to fulfil any of its obligations under the Security Documents; and

 

11


(h) anything done or permitted or not done in respect of the Vessel by any person which is likely to imperil the security created by the Security Documents;

6.1.10 promptly pay and discharge all debts, damages and liabilities, taxes, assessments, charges, fines, penalties, tolls, dues and other outgoings in respect of the Vessel and keep proper books of account in respect thereof PROVIDED ALWAYS that the Owner shall not be obliged to compromise any debts, damages and liabilities as aforesaid which are being contested in good faith subject always that full details of any such contested debt, damage or liability which, either individually or in aggregate exceeds [*] shall forthwith be provided to the Mortgagee. As and when the Mortgagee may so require it will make such books available for inspection on behalf of the Mortgagee and provide evidence satisfactory to the Mortgagee that the wages and allotments and the insurance and pension contributions of the master and crew are being regularly paid, that all deductions of crew’s wages in respect of any tax liability are being properly accounted for and that the master has no claim for disbursements other than those incurred in the ordinary course of trading on the voyage then in progress or completed prior to such inspection;

6.1.11 maintain the type of the Vessel as at the date hereof and not put the Vessel into the possession of any person without the prior consent of the Mortgagee for the purpose of work being done on her in an amount exceeding or likely to exceed [*] unless such person shall first have given to the Mortgagee a written undertaking addressed to the Mortgagee in terms satisfactory to the Mortgagee agreeing not to exercise a lien on the Vessel or her Earnings for the cost of such work or for any other reason;

6.1.12 promptly pay and discharge all liabilities which have given rise, or may give rise, to liens or claims enforceable against the Vessel under the laws of all countries to whose jurisdiction the Vessel may from time to time be subject PROVIDED ALWAYS THAT the Owner shall not be obliged to compromise any liabilities as aforesaid which are being contested in good faith subject always that full details of any such contested liabilities which, either individually or in aggregate, exceed [*] shall be forthwith provided to the Mortgagee. If the Vessel is arrested or detained for any reason it will procure the Vessel’s immediate release by providing bail or taking such other steps as the circumstances may require;

6.1.13 give to the Mortgagee at such times as it may from time to time require a certificate, duly signed on the Owner’s behalf as to the amount of any debts, damages and liabilities relating to the Vessel and, if so required by the Mortgagee, forthwith discharge such debts, damages and liabilities to the Mortgagee’s satisfaction;

 

  6.1.14 maintain the registration of the Vessel as a Bahamas vessel and not do or permit anything to be done whereby such registration may be forfeited or imperilled;

 

  6.1.15

where the Vessel trades in the territorial waters of the United States of America, take all reasonable precautions to prevent any infringements of the Anti-Drug Abuse Act of 1986 of the United States of America (as the same may be amended and/or re-enacted from time to time hereafter) or any similar legislation applicable to the Vessel in any other jurisdiction in which

 

12


 

the Vessel shall trade (a “Relevant Jurisdiction”) and, for this purpose shall (inter alia) enter into a “Carrier Initiative Agreement” with the United States’ Bureau of Customs and Border Protection (if such is possible) or into voluntary arrangements made under the Customs-Trade Partnership Against Terrorism of the United States of America (if such is possible and appropriate to cruise vessels) and procure that the same (or a similar agreement or arrangement in a Relevant Jurisdiction) is maintained in full force and effect and its obligations thereunder performed by it in respect of the Vessel throughout any period of United States of America (including coastal waters over which it claims jurisdiction) or Relevant Jurisdiction related trading;

 

  6.1.16 subject always to Permitted Chartering Arrangements under and as defined in the Credit Agreement, not enter into:

 

    (a) any pooling agreement or other arrangement for the sharing of any of the Earnings or the expenses of the Vessel; or

 

    (b) any demise or bareboat charter; or

 

    (c) any charter whereunder two (2) months’ charterhire (or the equivalent thereof) is payable in advance in respect of the Vessel; or

 

    (d) any charter of the Vessel or contract of affreightment which, with the exercise of options for extension, could be for a period longer than thirteen (13) months,

PROVIDED HOWEVER THAT the Owner may in respect of the Vessel enter into a bareboat charter on arm’s length terms and in form approved by the Mortgagee, with any company which is a member of the NCLC Group PROVIDED THAT if so requested by the Mortgagee, and without limitation:

 

    (1) any such bareboat charterer shall enter into such deeds (including but not limited to a subordination and assignment deed), agreements and indemnities as the Mortgagee shall in its absolute discretion require prior to entering into the bareboat charter with the Owner; and

 

    (2) the Owner shall assign the benefit of any such bareboat charter and its interest in the Insurances to the Mortgagee by way of further security for the Owner’s and the other Obligors’ obligations under the Security Documents;

6.1.17 subject always to clause 10.14 of the Senior Loan Agreement referred to in Schedule 1, except with the prior consent of the Mortgagee (acting on the instructions of the Required Lenders) not:

 

    (a) permit any person other than the Manager to be the manager of, including providing crewing services to, the Vessel;

 

    (b)

permit any amendment to be made to the terms of the Management Agreement in respect of the Vessel unless the amendment is advised

 

13


 

by the Owner’s tax counsel or is deemed necessary by the parties thereto but provided that the amendment does not imperil the security to be provided pursuant to the Security Documents or adversely affect the ability of any Obligor to perform its obligations under the Junior Finance Documents; or

 

    (c) permit the Vessel to be employed other than within the NCL or NCL America brand (as applicable);

6.1.18 perform its obligations under each charterparty or employment contract made in respect of the Vessel and take all necessary steps to procure the due performance of the obligations of any party under any charterparty or contract. It will not without the prior written consent of the Mortgagee rescind, cancel or otherwise terminate any charterparty or contract in respect of the Vessel PROVIDED ALWAYS THAT any determination by it of any such charterparty or contract after such consent is given shall be without responsibility on the part of the Mortgagee who shall be under no liability whatsoever in the event that such termination thereafter be adjudged to constitute a repudiation of such charterparty or contract by the Owner;

6.1.19 promptly notify the Mortgagee (a) of any default under any such charterparty or contract of which it has knowledge by it and/or by any other party under any other such charterparty or contract (b) of any such charterparty or contract being frustrated or the performance thereof becoming impossible or substantially different from that contemplated originally by the parties thereto;

6.1.20 institute and maintain all such proceedings as may be necessary or expedient to preserve or protect the interest of the Mortgagee as assignee and itself under any of its charterparties or contracts made in respect of the Vessel;

6.1.21 not take or omit to take any action the taking or omission of which might result in any material alteration or impairment of any charterparty or contract made in respect of the Vessel;

6.1.22 not substitute any other ship or ships for the Vessel under any charterparty or contract made in respect of the Vessel;

6.1.23 not without the Mortgagee’s prior consent agree to any material variation, modification or amendment in the terms of any charterparty or contract in respect of the Vessel or release any other party from any of their respective obligations thereunder or waive any breach of the obligations of any person or consent to any such act or omission of any person as would otherwise constitute such breach;

6.1.24 not without the Mortgagee’s prior consent let or employ the Vessel below approximately the market rate prevailing when the Vessel is fixed; and

 

14


6.1.25 procure that the Earnings (if any) are paid in full without set off and free and clear of and without deduction for any taxes, levies, duties, imposts, charges, fees, restrictions or conditions of any nature whatsoever.

 

7 Protection and Maintenance of Security

 

  7.1 The Mortgagee shall without prejudice to its other rights and powers hereunder be entitled (but not bound) at any time and as often as may be necessary to take any such action as it may in its absolute discretion think fit for the purpose of protecting the security created by this Deed and the other Security Documents and each and every expense or liability so incurred by the Mortgagee in or about the protection of the security shall be repayable by the Owner on demand for the charges and expenses (including the fees and expenses of legal advisers and value added tax or any similar tax thereon).

 

  7.2 Without prejudice to the generality of the foregoing:

7.2.1 if any of the provisions of Clause 5 hereof shall no longer be in full force and effect the Mortgagee shall be at liberty to effect and thereafter to maintain all such insurances upon the Vessel as it in its discretion may think fit;

7.2.2 if any of the provisions of Clause 6.1.1 and 6.1.2 hereof are not complied with the Mortgagee shall be at liberty to arrange for the carrying out of such repairs and/or surveys as it deems expedient or necessary; and

7.2.3 if any of the provisions of Clause 6.1.10 hereof are not complied with the Mortgagee shall be at liberty to pay and discharge all such debts, damages and liabilities, taxes, assessments, charges, fines, penalties, tolls, dues and other outgoings as are therein mentioned and/or take any such measures as it deems expedient or necessary for the purpose of securing the release of the Vessel and each and every expense or liability so incurred by the Mortgagee shall be recoverable from the Owner as provided in Clause 7.1.

 

8 Mortgagee’s Powers

 

  8.1 Subject always to the provisions of the Fourth Priority Security Co-ordination Deed, if an Event of Default shall occur and the Mortgagee shall demand repayment of all or any part of the Secured Obligations, the security constituted by this Deed shall become immediately enforceable and at any time thereafter whilst such event shall be continuing the Mortgagee shall be entitled to exercise all or any of the rights, powers, discretions or remedies vested in the Mortgagee by this Clause without any requirement for any court order or declaration that an Event of Default has occurred. The Mortgagee’s right to exercise those rights, powers, discretions and remedies shall be in addition to and without prejudice to all other rights, powers, discretions and remedies to which they may be entitled, whether by law or otherwise. The Mortgagee shall be entitled to exercise their rights, powers, discretions and remedies despite any rule of law or equity to the contrary, and whether or not any previous default shall have been waived, and in particular without any limitations imposed by law.

 

15


  8.2 In the circumstances described in Clause 8.1 and subject always to the provisions of the Fourth Priority Security Co-ordination Deed, the Mortgagee shall be entitled (but not obliged) to:

 

  8.2.1 take possession of the Vessel wherever she be;

 

  8.2.2 discharge the master and crew of the Vessel and employ a new master and crew;

 

  8.2.3 navigate the Vessel to such places as the Mortgagee may decide or detain or lay up the Vessel;

 

  8.2.4 in the name of the Mortgagee or the name of the Owner, demand, sue for, receive and give a good receipt for all sums due to the Owner in connection with the Vessel and, in the name of the Mortgagee or the name of the Owner or the name of the Vessel, commence such legal proceedings as they may consider appropriate, or conduct the defence of any legal proceedings commenced against the Vessel or the Owner in its capacity as owner of the Vessel;

 

  8.2.5 sell or dispose of the Vessel either by private treaty or auction, on such terms as the Mortgagee shall think fit (including deferred payment terms and with or without the benefit of any charterparty or other contract of employment), with the power to make a loan on such terms as the Mortgagee may decide to any prospective purchaser to assist in the purchase of the Vessel, and the power to postpone any sale, without being liable for any loss caused by any such sale or the postponement of any such sale;

 

  8.2.6 replace or repair any part of the Vessel or alter it to suit the Mortgagee’s requirements and put it through all appropriate surveys;

 

  8.2.7 employ agents, servants and others on such terms as the Mortgagee may in their discretion determine;

 

  8.2.8 charter or load the Vessel on such terms and for the carriage of such passengers or cargoes as the Mortgagee may in their discretion determine.

 

  8.3 Whenever any right to enter and take possession of the Vessel accrues to the Mortgagee pursuant to Clause 8.2.1, they may require the Owner to deliver, and the Owner shall on demand, at its own cost and expense, deliver to the Mortgagee the Vessel to a location designated by the Mortgagee as demanded.

 

  8.4 For the avoidance of doubt, if the Mortgagee takes any action or enters into or completes any transaction pursuant to Clause 8.2 after an Event of Default has been remedied, that action or transaction shall not be affected by the remedying of the Event of Default.

 

9 Ancillary Provisions

 

  9.1

In connection with the exercise of its rights, powers, discretions and remedies under Clause 8 or otherwise as mortgagees of the Vessel and, subject always to the provisions of the Fourth Priority Security Co-ordination Deed, the Mortgagee shall

 

16


 

have power to buy in, rescind or vary any contract for sale of the Vessel and generally to do all things in connection with the sale of the Vessel as they shall think fit.

 

  9.2 On any sale of the Vessel by the Mortgagee, the purchaser shall not be bound to enquire whether the Mortgagee’s power of sale has become exercisable or whether its exercise has become expedient, and the purchaser shall not be affected by any notice that the sale was or may have been irregular in any way. The receipt of the Mortgagee for any amounts paid to them shall be a complete discharge to the purchaser who shall not be concerned with the application of the payment or be answerable for any misapplication. As regards any purchaser, any such sale shall be deemed to be within the power of sale conferred on the Mortgagee by this Deed and at law and any remedy of the Owner in respect of any irregularity or impropriety shall be in damages only.

 

  9.3 If the Mortgagee takes possession of the Vessel, until its sale the Mortgagee shall be entitled to deal with the Vessel in all respects as if they were the owners of the Vessel.

 

10 Receiver

Subject always to the provisions of the Fourth Priority Security Co-ordination Deed:

 

  10.1 at any time after the occurrence and during the continuation of an Event of Default the Mortgagee may (but shall not be obliged to) appoint any suitably experienced and reputable person (in the opinion of the Mortgagee) to be receiver and/or manager of the Vessel and/or any of the Assigned Property;

 

  10.2 the appointment of a receiver and/or manager by the Mortgagee may be made in writing under the hand of any authorised signatory of the Mortgagee;

 

  10.3 the Mortgagee shall have the power to authorise any joint receiver and/or manager to exercise any or all of their powers independently of any other joint receiver and/or manager;

 

  10.4 the Mortgagee may at any time and from time to time remove any receiver and/or manager from office and appoint a replacement;

 

  10.5 the Mortgagee shall have the power from time to time to fix the remuneration of any receiver and/or manager on the basis of charging from time to time adopted by him or his firm and any receiver and/or manager shall not be limited to any maximum amount or rate specified by law;

 

  10.6 any receiver and/or manager appointed pursuant to this Clause shall be the agent of the Owner and the Owner shall be solely responsible for his acts and defaults and for the payment of his remuneration;

 

  10.7 any receiver and/or manager appointed pursuant to this Clause shall have all the powers conferred on receivers and/or managers or administrative receivers by law without any restriction, whether imposed by law or otherwise;

 

  10.8

without limitation, any receiver and/or manager shall have power on behalf of the Owner (and at the Owner’s expense) to do or omit to do anything which the Owner

 

17


 

could do or omit to do in relation to the Vessel or any of the Assigned Property and may exercise all or any of the rights, powers, discretions and remedies conferred on the Mortgagee by the Security Documents or at law;

 

  10.9 no receiver and/or manager shall be liable as mortgagee in possession to account or be liable for any loss on realisation of or any default of any nature in connection with the Vessel or any of the Assigned Property, or the exercise of any of the rights, powers, discretions and remedies vested in the receiver and/or manager by virtue of the Security Documents or at law.

 

11 Appropriation

All amounts received by the Mortgagee arising from the exercise by the Mortgagee of their rights, powers, discretions and remedies under or pursuant to this Mortgage (including, without limitation, all amounts received by the Mortgagee in connection with the taking possession and/or sale of the Vessel, any chartering or other use of the Vessel by the Mortgagee, and any claims for damages or claims on any insurance received by the Mortgagee while in possession of or while chartering or using the Vessel or any Compulsory Acquisition Compensation) shall be applied by the Mortgagee in accordance with clause 3 of the Fourth Priority Security Co-ordination Deed.

 

12 Power of Attorney

 

  12.1 The Owner hereby irrevocably appoints the Mortgagee as its attorney for the duration of the Security Period for the purpose of doing in its name all acts which the Owner itself could do in relation to the Vessel PROVIDED HOWEVER that such power shall not be exercisable by or on behalf of the Mortgagee until payment of the Secured Obligations shall have been demanded under Clause 8.

 

  12.2 The exercise of such power by or on behalf of the Mortgagee shall not put any person dealing with the Mortgagee upon any enquiry as to whether payment of the Secured Obligations has been demanded nor shall such person be in any way affected by notice that payment of the Secured Obligations has not been so demanded and the exercise by the Mortgagee of such power shall be conclusive evidence to such person of the Mortgagee’s right to exercise the same.

 

  12.3 The Owner hereby ratifies and confirms and agrees to ratify and confirm whatever an attorney appointed under this Clause 12 shall do in its capacity as such, to the extent permissible hereunder.

 

13 Further Assurance

The Owner agrees that from time to time on the written request of the Mortgagee it will immediately execute and deliver to the Mortgagee all further documents which the Mortgagee may reasonably require for the purpose of perfecting or protecting the security intended to be created by this Deed.

 

14 Discharge of Security

Following the repayment and termination in full of all Secured Obligations the Mortgagee will, at the cost of and on the request of the Owner, execute and deliver to the Owner a discharge of this Deed, without recourse to any representation or warranty by or from the Mortgagee.

 

18


15 Notices

The provisions of section 14.03 of the Credit Agreement shall (mutatis mutandis) apply to this Deed as if they were set out in full with references to this Deed substituted for references to the Credit Agreement.

 

16 Governing Law and Submission to Jurisdiction

 

  16.1 This Deed and any non-contractual obligations arising from or in connection with it shall be governed by English law.

 

  16.2 The courts of England have exclusive jurisdiction to settle any dispute:

 

  16.2.1 arising out of or in connection with this Deed (including a dispute regarding the existence, validity or termination of this Deed); or

 

  16.2.2 relating to any non-contractual obligations arising from or in connection with this Deed,

(a “Dispute”). Each party to this Deed agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no party will argue to the contrary.

This Clause 16.2 is for the benefit of the Mortgagee only. As a result, such party shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, such party may take concurrent proceedings in any number of jurisdictions.

This Deed shall be governed by and construed in accordance with the Laws of England and for the exclusive benefit of the Mortgagee the Owner hereby irrevocably submits to the jurisdiction of the High Courts of Justice in England. Such submission shall not limit the right of the Mortgagee to commence any proceedings relating to this Deed (in addition or alternatively) in any other jurisdiction which the Mortgagee deems fit.

 

  16.2.3 The Owner waives any objection which it may now or later have (whether on the ground of forum non conveniens or otherwise) to any proceedings relating to this Deed being brought in the courts of England or in any court which is covered by Clause 16.2.

 

  16.2.4 The Owner agrees to appoint an agent in London for the Service of Process for the duration of the Security Period.

 

  16.2.5 A judgment relating to this Deed which is given or would be enforced by an English court shall be conclusive and binding on the Owner and may be enforced without review in any other jurisdiction.

 

  16.2.6 Nothing in this Clause 16 shall exclude or limit any right which the Mortgagee may have (whether under the laws of any country, an international convention or otherwise) with regard to the bringing of proceedings, the service of process, the recognition or enforcement of a judgment or any similar or related matter in any jurisdiction.

 

19


  16.2.7 In this Clause “judgment” includes order, injunction, declaration and any other decision or relief made or granted by a court.

 

17 Miscellaneous

 

  17.1 If at any time any provision of this Deed becomes invalid, illegal or unenforceable in any respect that provision shall be severed from the remainder and the validity, legality and enforceability of the remaining provisions of this Deed shall not be affected or impaired in any way.

 

  17.2 In the event of there being any conflict between this Deed and a Junior Finance Document, that Junior Finance Document shall prevail.

 

  17.3 This Deed may be executed in any number of counterparts, each of which shall be original but which shall together constitute the same instrument.

 

  17.4 All the covenants and agreements of the Owner in this Deed shall bind the Owner and its successors and permitted assignees and shall inure to the benefit of the Beneficiaries.

 

  17.5 The headings used in this Deed are for reference only, have no legal or other significance, and shall be ignored in the interpretation of this Deed.

 

  17.6 The representations and warranties on the part of the Owner contained in this Deed shall survive the execution and registration of this Deed.

 

  17.7 The Mortgagee and/or the other Beneficiaries may at any time and from time to time waive either unconditionally or on such terms and conditions as they consider appropriate any breach of any of the Junior Finance Documents, or any of the Security Documents or the Fourth Priority Security Co-ordination Deed by any of the Obligors.

 

  17.8 Any waiver by the Mortgagee or any of the other Beneficiaries of any of their or its rights, powers, discretions or remedies pursuant to the Credit Agreement, the Security Documents or the Fourth Priority Security Co-ordination Deed or of any breach by any of the Obligors or any forbearance by the Mortgagee or any of the other Beneficiaries, or any time or other indulgence granted by the Mortgagee or any of the other Beneficiaries to any of the Obligors, shall not in any way prejudice or affect the right of the Mortgagee and the other Beneficiaries to act strictly in accordance with their rights and powers under or pursuant to the Credit Agreement, the Security Documents or the Fourth Priority Security Co-ordination Deed.

 

  17.9

The Mortgagee and/or the other Beneficiaries may, without prejudice to their rights pursuant to this Deed, at any time and from time to time, and on such terms and conditions as the Mortgagee and/or the other Beneficiaries may in their discretion determine, agree with the Obligors to vary or amend the Credit Agreement, or any of the Security Documents, or any document referred to in or related to the Credit Agreement or any of the Security Documents (including for the avoidance of doubt the Fourth Priority Security Co-ordination Deed, or without notice to the Owner grant time or other indulgence to or compound with any other person liable (actually or contingently) to the Mortgagee and/or the other Beneficiaries in respect of all or any part of the Secured Obligations, and may release or renew negotiable instruments and take and release securities and hold funds on realisation or

 

20


 

suspense account without affecting the liability of the Owner or the rights of the Mortgagee and the other Beneficiaries under or pursuant to the Credit Agreement, the Security Documents and the Fourth Priority Security Co-ordination Deed.

 

  17.10 The Mortgagee or any of the other Beneficiaries may at any time and from time to time delegate to any person all or any of their rights, powers, discretions and remedies pursuant to the Credit Agreement, the Security Documents and the Fourth Priority Security Co-ordination Deed on such terms as they may consider appropriate (including the power to sub-delegate).

 

  17.11 Every right, power, discretion and remedy conferred on the Mortgagee and the other Beneficiaries under or pursuant to the Credit Agreement, the Security Documents and the Fourth Priority Security Co-ordination Deed shall be cumulative and in addition to every other right, power, discretion or remedy to which the Mortgagee and the other Beneficiaries may at any time be entitled by law or in equity. The Mortgagee and the other Beneficiaries may exercise each of their rights, powers, discretions and remedies as often and in such order as they deem appropriate. The exercise or the beginning of the exercise of any right, power, discretion or remedy shall not be interpreted as a waiver of the right to exercise that or any other right, power, discretion or remedy either simultaneously or subsequently.

 

  17.12 No failure or delay by the Mortgagee or any of the other Beneficiaries in exercising any of their rights, powers, discretions or remedies shall impair any such right, power, discretion or remedy or be interpreted as a waiver of or acquiescence in any default on the part of the Owner, unless expressly agreed to do so by the Mortgagee in writing.

 

  17.13 Subject to the provisions of the Fourth Priority Security Co-ordination Deed, no provision of the Credit Agreement, the Security Documents or the Fourth Priority Security Co-ordination Deed shall in any way limit the rights, powers, discretions and remedies of the Mortgagee as mortgagees of the Vessel.

 

  17.14 The Mortgagee shall not be concerned to enquire into the power of the Owner or any person purporting to act on behalf of the Owner even if the Owner or such person shall have acted in excess of their powers or if their actions shall have been irregular, defective or informal, whether or not the Mortgagee had notice.

 

  17.15 The security constituted by this Deed shall be continuing and shall not be satisfied by any intermediate payment or satisfaction until the Secured Obligations shall have been repaid in full and neither the Mortgagee nor any of the other Beneficiaries shall be under any further actual or contingent liability to any third party in relation to the Vessel, the Assigned Property or any other matter referred to in the Credit Agreement, the Security Documents or the Fourth Priority Security Co-ordination Deed. The security constituted by this Deed shall be in addition to any other security now or in the future held by the Beneficiaries or by the Mortgagee for or in respect of the Secured Obligations, and shall not merge with or prejudice or be prejudiced by any such security or any other contractual or legal rights of the Mortgagee or the other Beneficiaries nor be affected by any irregularity, defect or informality or by any release, exchange or variation of any such security.

 

21


  17.16 If the Mortgagee takes any steps to exercise any of their rights, powers, remedies or discretions pursuant to this Deed and the result shall be adverse to the Mortgagee, the Owner and the Mortgagee shall be restored to their former positions as if no such steps had been taken.

 

  17.17 Neither the Mortgagee nor any agent or employee of the Mortgagee nor any receiver and/or manager appointed by the Mortgagee shall be liable for any losses which may be incurred in or about the exercise of any of the rights, powers, discretions or remedies of the Mortgagee under or pursuant to this Deed nor liable as mortgagees in possession for any loss on realisation or for any neglect or default of any nature for which mortgagees in possession might otherwise be liable, except for losses as a result of gross negligence or wilful misconduct on the part of a Trustee, its agent, employee, receiver or manager.

 

  17.18 Any discharge, release or reassignment by the Mortgagee and/or the other Beneficiaries of any of the security constituted by, or any of the obligations of the Owner contained in, the Credit Agreement or any of the Security Documents shall be (and be deemed always to have been) void if any act (including, without limitation, any payment) as a result of which such discharge, release or reassignment was given or made is subsequently wholly or partially rescinded or avoided by operation of any law.

 

  17.19 If the Mortgagee (despite Clause 4.2) receives notice of any subsequent Lien affecting the Vessel or any of the Assigned Property, the Mortgagee may open a new account in their books for the Owner and/or the Vessel. If the Mortgagee do not open such a new account, then (unless the Mortgagee give written notice to the contrary to the Owner) as from the time of receipt by the Mortgagee of notice of such subsequent Lien, all payments made to the Mortgagee shall be treated as having been credited to a new account of the Owner and not as having been applied in reduction of the Secured Obligations.

 

  17.20 The rights of the Mortgagee under this Deed shall not be affected by any change in the constitution of the Owner or by the liquidation, bankruptcy or insolvency of the Owner.

 

  17.21 No variation or amendment of this Deed shall be valid unless in writing and signed on behalf of the Owner and the Mortgagee.

 

  17.22 Notwithstanding anything to the contrary contained in this Deed, it is intended that nothing in this Deed shall waive the preferred status of this Deed and that, if any provision of this Deed shall be interpreted as waiving the preferred status of this Deed, that provision shall to such extent be void and of no effect.

 

  17.23 The exercise by the Mortgagee or by any receiver and/or manager appointed by the Mortgagee of any of their rights, powers, discretions or remedies under or arising out of this Deed shall not be interpreted as the taking by the Mortgagee or by such receiver and/or manager of the management of the Vessel nor as evidencing any intention by the Mortgagee or by any receiver and/or manager appointed by the Mortgagee to take over the management of the Vessel.

 

22


IN WITNESS whereof this Deed has been executed by the parties hereto on the day first written above.

 

SIGNED SEALED and DELIVERED as a DEED   )   
for and on behalf of   )   
PRIDE OF HAWAII, LLC   )   
by   )   
its duly appointed attorney-in-fact,   )   
who in accordance with the laws of that territory,   )   
is acting under the authority of the company   )   
SIGNED SEALED and DELIVERED as a DEED   )   
for and on behalf of   )   
KFW IPEX-BANK GMBH   )   
by   )   
who in accordance with the laws of that territory,   )   
is acting under the authority of the company   )   


Schedule 1

EUR308,130,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

Fax:

  +44 (0)20 7992 4428

Attn:

  Mr Alan Marshall

Email:

  alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

Fax:

  +44 (0)20 7992 4428

Attn:

  Mr Alan Marshall

Email:

  alan.p.marshall@hsbcib.com
(as trustee and agent)

 

2


COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 1362 3742
Attn:   Mr Klaus-Dieter Schmedding
Email:   exportfinance@commerzbank.com
(as Hermes agent)
and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:   shipfinance@commerzbank.com
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:  

          alan.p.marshall@hsbcib.com

 

3


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

Fax:

  +49 69 7431 3768/2944

Attn:

  Mr Josef Schmid/Ms Claudia Wenzel

Email:

  josef.schmid@kfw.de/claudia.wenzel@kfw.de
DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

Fax:

  +47 22 482020

Attn:

  Mrs Amra Koluder/Mrs Ursula Mack Tonjum

Email:

  amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

Fax:

  +49 511 361 4785

Attn:

  Mr Torsten Reinecke

Email:

  shipping@nordlb.de
CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

Fax:

  +49 69 74221 197

Attn:

  Mr Stephan Bachmann

Email:

  stephan.bachmann@ca-cib.com

 

4


with a copy to:
CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:   +852 2868 1448
Attn:   Mr Terence Yuen/Ms Iris Lai
Email:   terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

5


Schedule 2

Part I

EUR258,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)

 

 

6


COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 1362 3742
Attn:   Mr Klaus-Dieter Schmedding
Email:   exportfinance@commerzbank.com
(as Hermes agent)
and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:   shipfinance@commerzbank.com
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com

 

7


KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

Part II

EUR40,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
(as trustee and agent)

 

 

8


COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 1362 3742
Attn:   Mr Klaus-Dieter Schmedding
Email:   exportfinance@commerzbank.com
(as Hermes agent)
and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:   shipfinance@commerzbank.com
KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 7431 3768/2944
Attn:   Mr Josef Schmid/Ms Claudia Wenzel
Email:   josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

9


DVB BANK SE
Parklaan 2
3016 BB Rotterdam
The Netherlands
Fax:   +5999 4652366
Attn:   LAM/Eric Maduro
Email:   lam.curacao@dvbbank.com/james.neira@dvbbank.com

Part III

USD334,050,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
(as trustee and agent)

 

10


COMMERZBANK
AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 1362 3742
Attn:   Mr Klaus-Dieter Schmedding
Email:   exportfinance@commerzbank.com

(as Hermes agent)

 

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:   shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:  

          alan.p.marshall@hsbcib.com

 

11


KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 7431 3768/2944
Attn:   Mr Josef Schmid/Ms Claudia Wenzel
Email:   josef.schmid@kfw.de/claudia.wenzel@kfw.de
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482020
Attn:   Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:   amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
OVERSEA-CHINESE BANKING
CORPORATION LIMITED
Singapore Branch
65 Chulia Street #10-00
Singapore 049513
Fax:   +65 6536 6449/6532 5347
Attn:   Ms Lee King Lan/Ms Elaine Lam
Email:   LeeKingLan@ocbc.com/LamSYElaine@ocbc.com
NORDDEUTSCHE LANDESBANK GIROZENTRALE
Friedrichswall 10
30159 Hannover
Federal Republic of Germany
Fax:   +49 511 361 4785
Attn:   Mr Torsten Reinecke
Email:   shipping@nordlb.de

 

12


CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK
Taunusanlage 14
60325 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 74221 197
Attn:   Mr Stephan Bachmann
Email:   stephan.bachmann@ca-cib.com
with a copy to:
CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:   +852 2868 1448
Attn:   Mr Terence Yuen/Ms Iris Lai
Email:   terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

13


Schedule 3

EUR624,000,000 Secured Loan Agreement dated 7 October 2005 as amended

and/or restated from time to time

 

Non-Guaranteed Trustee
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482894
Attn:   Mrs Solveig Nuland Knoff
Email:   solveig.knoff@dnbnor.no
As trustee for:
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482894
Attn:   Mrs Solveig Nuland Knoff
Email:   solveig.knoff@dnbnor.no
(as security agent and agent)

 

 

14


and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Germany
Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/
  Mrs Anne Randewig
Email:   shipfinance@commerzbank.com
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482020
Attn:   Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:   amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
KFW IPEX-BANK GMBH
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Germany  
Fax:   +49 69 7431 3768/2944
Attn:   Mr Josef Schmid/Ms Claudia Wenzel
Email:   josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

15


NORDDEUTSCHE LANDESBANK GIROZENTRALE
Friedrichswall 10
30159 Hannover
Germany
Fax:   +49 511 361 4785
Attn:   Mr Torsten Reinecke
Email:   shipping@nordlb.de
NORDEA BANK NORGE ASA
Middelthuns gate 17
Oslo
P O Box 1166 Sentrum
NO-0107 Oslo
Norway
Fax:   +47 22 484278
Attn:   Mr Arne Berglund
Email:   arne.berglund@nordea.com
BANK OF SCOTLAND PLC
Marine Finance
Second Floor
New Uberior House
11 Earl Grey Street
Edinburgh EH3 9BN
Scotland
Fax:   +44 131 659 1194
Attn:   Douglas Newton/Russell Parker
Email:   douglas_newton@bankofscotland.co.uk

 

16


UNICREDIT BANK AG
(formerly known as Bayerische Hypo- und
Vereinsbank AG)
Alter Wall 22
20457 Hamburg
Germany
Fax:   +49 40 3692 3696/+49 89 378 334 2832
Attn:   Mr Peter-Alexander Wunner/
  Mr Michael McCarthy
Email:   peter-alexander.wunner@unicreditgroup.de/
  michael.mccarthy@unicreditgroup.de
DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT
Bremen and Hamburg
Domshof 17
28195 Bremen
Germany
Fax:   +49 421 3609 329
Attn:   Dr Matthias Fischer
Email:   matthias.fischer@schiffsbank.com
FOKUS BANK
(being the Norwegian branch of Danske Bank A/S)
Stortingsgaten 6
P O Box 1170 Sentrum
NO-0107 Oslo
Norway
Fax:   +47 85 407990
Attn:   Mr Øivind Haraldsen/Mr Tore Thorlacius Braein
Email:   oivind.haraldsen@fokus.no/
  tore.braein@fokus.no

 

 

17


HSH NORDBANK AG
Gerhart-Hauptmann-Platz 50
20095 Hamburg
Germany
Fax:   +49 40 3333 613741
Attn:   Mr Carsten Dreyer
Email:   carsten.dreyer@hsh-nordbank.com
Fax:   +1 212 407 6008
Attn:   Ms Frauke Hay
Email:   frauke.hay@hsh-nordbank.com
SKANDINAVISKA ENSKILDA BANKEN AB (publ)
Kungsträdgårdsgatan 8
SE-106 40 Stockholm
Sweden
Fax:   +44 20 7236 5144
Attn:   Mr Egil Aarrestad/Mr Malcolm Stonehouse
Email:   egil.aarrestad@seb.co.uk/
  malcolm.stonehouse@seb.co.uk

 

18


Schedule 4

EUR126,075,000 Credit Agreement dated November [    ] 2010 as amended and/or restated

from time to time

 

Trustee:
KFW IPEX-BANK GMBH
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Germany
Fax:   +49 69 7431 2944
Attn:   Ship Finance, X2a4
  Claudia Wenzel
Email:   Claudia.wenzel@kfw.de
As Trustee for:
NORDEA BANK NORGE ASA
Middelthunsgate 17
P O Box 1166 Sentrum
NO-0107 Oslo
Norway
Fax:   +47 22 486668
Attn:   Mr Arne Berglund
Email:   arne.berglund@nordea.com
DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 8
D – 20095 Hamburg
Germany
Fax:   +49 40 3769 9649
Attn:   Mr Marcus Weber
  Ms Anne Randewig
Email:   marcus.weber@commerzbank.com
  anne.randewig@commerzbank.com
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482894
Attn:   Ms Amra Koluder
  Mr Solveig N. Knoff
Email:   amra.koluder@dnbnor.no
  solveig.knoff@dnbnor.no

 

 

19


KFW IPEX-BANK GMBH
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Germany
Fax:   +49 69 7431 4466/ 2944
Attn:   Mr Stephan Pueschel
  Mr Christian Schweiger
Email:   stephan.pueschel@kfw.de
  christian.schweiger@kfw.de
HSBC BANK PLC
8 Canada Square
London E14 5HQ
Fax:   +44 207 992 4428
Attn:   Alan P. Marshall
Email:   alan.p.marshall@hsbcib.com

And each other Secured Creditor under and as defined in the Credit Agreement.

 

20


LOGO

 

 

EXHIBIT I-1

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

Dated [] 2010

HULL NO. S. 678

FORM OF ASSIGNMENT OF CONTRACTS

between

BREAKAWAY ONE, LTD.

as Company

and

KFW IPEX-BANK GMBH

as Collateral Agent

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


LOGO

 

 

TABLE OF CONTENTS

 

          Page  
1.    INTERPRETATION      1   
2.    COVENANT TO PAY      6   
3.    LEGAL ASSIGNMENT      6   
4.    THE CONTRACT      7   
5.    CONTINUING SECURITY      8   
6.    REPRESENTATIONS AND WARRANTIES      10   
7.    UNDERTAKINGS      12   
8.    FURTHER ASSURANCE      13   
9.    ENFORCEMENT OF SECURITY      13   
10.    RECEIVERS      14   
11.    APPLICATION OF PROCEEDS      15   
12.    POWER OF ATTORNEY      15   
13.    RELEASE OF THE SECURITY      15   
14.    PAYMENTS      15   
15.    WAIVERS AND REMEDIES      16   
16.    ADDITIONAL PROVISIONS      16   
17.    ASSIGNMENT      17   
18.    NOTICES      17   
19.    GOVERNING LAW      19   
20.    COUNTERPARTS AND EFFECTIVENESS      20   
SCHEDULE 1         FORMS OF NOTICE OF ASSIGNMENT      21   
SCHEDULE 2         FORMS OF ACKNOWLEDGMENT OF ASSIGNMENT      31   
SCHEDULE 3         DETAILS OF REFUND GUARANTEES      41   

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


THIS ASSIGNMENT is dated [] 2010

BETWEEN:

 

(1) BREAKAWAY ONE, LTD., a Bermuda company with its registered office as of the date hereof at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Company”); and

 

(2) KFW IPEX-BANK GMBH, as collateral agent under each Credit Agreement for and on behalf of the Secured Creditors under and as defined in such Credit Agreement (the “Collateral Agent”, which expression includes any person which is for the time being a collateral agent for the Secured Creditors for the purposes of this Assignment).

RECITALS

 

(A) The applicable Lenders are willing to make a loan facility available to the Borrowers on the terms and subject to the conditions set out in the Credit Agreements, on condition that the Company enters into this Assignment as security for the Borrowers’ respective obligations and Liabilities as Borrower under or in relation to the Credit Documents.

 

(B) The Board of Directors of the Company is satisfied that the Company is entering into this Assignment for the purposes of its business and that its doing so benefits the Company.

 

(C) The Company and the Collateral Agent intend this Assignment to take effect as a deed.

 

(D) The Collateral Agent holds the benefit of this Assignment on trust for itself and for the Secured Creditors on the terms of the Credit Agreements, the Security Trust Deeds and the Intercreditor Agreement.

 

1. INTERPRETATION

 

1.1 Definitions

In this Assignment the following terms have the meanings given to them in this Clause.

Acknowledgment of Assignment” means a duly completed acknowledgement of assignment in the form set out in the relevant Part of Schedule 2 (Forms of Acknowledgement of Assignment) being:

 

  (a) Part 1, in the case of the Construction Contract;

 

  (b) Part 2, in the case of the Refund Guarantees; and

 

  (c) Part 3, in the case of the Construction Risks Insurance Policies; and

or in each case in such other form as may be approved by the Collateral Agent.


Agent” means each Agent under and as defined in each Credit Agreement.

Agreed Rate” means the rate specified in section 2.06(b) and 2.06(c) (Interest) of each Credit Agreement.

Assigned Rights” means the Company’s rights, title, interest and benefits in, to and in respect of the Contracts.

Borrower” means Pride of Hawaii, LLC (“POH”) with respect to the Jade Credit Facility and Norwegian Jewel Limited (“NJL”) with respect to the Jewel Credit Facility.

Breakaway One Credit Facility” means the €529,846,154 credit facility dated on or about the date hereof among, inter alia, the Parent, the Company, as borrower, the Joint Lead Arrangers (as defined therein), the Lenders (as defined therein), the Collateral Agent (as defined therein), Nordea Bank Norge ASA, as documentation agent and Commerzbank Aktiengesellschaft, as Hermes Agent.

Construction Contract” means the construction contract dated 24 September 2010 between the Company, the Parent and the Shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the Vessel.

Construction Risks Insurance Policies” any and all insurance policies from time to time issued for the benefit of the Shipbuilder and the Company in connection with the construction of the Vessel under the Construction Contract.

Contracts” means each of the:

 

  (a) the Construction Contract;

 

  (b) the Refund Guarantees; and

 

  (c) the Construction Risks Insurance Policies.

Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Credit Agreement Obligations” means “Credit Document Obligations” as defined in the applicable Credit Agreement.

Enforcement Proceeds” means any enforcement proceeds recovered in respect of the Security.

Event of Default” means an “Event of Default” as defined in each Credit Agreement.

Intercreditor Agreement” means the intercreditor deed dated on or about the date hereof between, inter alia, the Company, the Lenders, the lenders under the Breakaway One Credit Facility, the collateral agent under the Breakaway One Credit Facility, and the Collateral Agent (in its capacity as collateral agent under each of the Jade Credit Facility and the Jewel Credit Facility).

 

2


“Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, POH, as borrower, the Parent, the Lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jade Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, POH, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

“Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, NJL, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jewel Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, NJL, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

Lender” means each Lender under and as defined in each Credit Agreement.

Lender Creditors” means the Agents and the Lenders.

Liability” means any liability for the payment of money, whether in respect of principal, interest or otherwise, whether actual or contingent, whether owed jointly or severally and whether owed as principal or surety or in any other capacity.

Notice of Assignment” means a duly completed notice of assignment in the form set out in the relevant Part of Schedule 1 (Forms of Notice of Assignment) being:

 

  (a) Part 1, in the case of the Construction Contract;

 

  (b) Part 2, in the case of each Refund Guarantees;

 

  (c) Part 3, in the case of the Construction Risks Insurance Policies;

or in each case such other form as may be approved by the Collateral Agent.

Other Creditors” means each Lender or any affiliate thereof with which the applicable Borrower and/or the Parent may at any time and from time to time after the date hereof enter into, or guaranty the obligations of one or more of its Subsidiaries under one or more Interest Rate Protection Agreements or Other Hedging Agreements (even if the respective Lender subsequently ceases to be a Lender under the applicable Credit Agreement for any reason), together with such Lender’s or affiliate’s successors and assigns, if any.

Other Vessel 1 Assignment of Contracts” means the assignment agreement dated on or about the date hereof between the Company and the Collateral Agent as security trustee on behalf of the ECF Creditors (as defined in the Intercreditor Agreement) in respect of the Refund Guarantees, the Construction Contract and the Construction Risks Insurance Policies.

Parent” means NCL Corporation Ltd., a Bermuda company.

 

3


Receiver” means a receiver and manager or any other receiver (whether appointed pursuant to this Assignment, pursuant to any statute, by a court or otherwise) of any of the Assigned Rights.

Refund Guarantees” means any and all refund guarantees from time to time issued in favour of the Company to secure certain obligations of the Shipbuilder under the Construction Contract other than any refund guarantees issued by KfW IPEX-Bank GmbH acting in its capacity as a refund guarantor.

Secured Creditors” means the Lender Creditors and the Other Creditors.

Secured Obligations” means the Credit Agreement Obligations and the Other Obligations.

Security” means the security created by this Assignment.

Security Period” means the period beginning on the date of this Assignment and ending on the date upon which the Collateral Agent is satisfied that:

 

  (a) none of the Secured Creditors is under any obligation (whether actual or contingent) to make advances or provide other financial accommodation to the Company under any of the Credit Documents; and

 

  (b) all Secured Obligations have been unconditionally and irrevocably paid and discharged in full (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement).

Security Trust Deeds” means the Jade Security Trust Deed and the Jewel Security Trust Deed.

Shipbuilder” means Meyer Werft GmbH.

Vessel” means the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.678 to be constructed by the Shipbuilder.

 

1.2 Continuing Event of Default

An Event of Default shall be regarded as continuing if (a) the circumstances constituting such event continue and (b) such Event of Default has not been waived in accordance with the terms of the Credit Documents.

 

1.3 Defined Terms

Unless this Assignment provides otherwise, a term which is defined (or expressed to be subject to a particular construction) in the Credit Agreements or in the Intercreditor Agreement shall have the same meaning (or be subject to the same construction) in this Assignment.

 

4


1.4 References to Agreements

Unless otherwise stated, any reference in this Assignment to any agreement or document (including any reference to this Assignment or any other Credit Document) shall be construed as a reference to:

 

  (a) such agreement or document as amended, varied, novated or supplemented from time to time;

 

  (b) any other agreement or document whereby such agreement or document is so amended, varied, novated or supplemented; and

 

  (c) any other agreement or document entered into pursuant to or in accordance with such agreement or document.

 

1.5 Certificates

A certificate of any Secured Creditor as to the amount of any Secured Obligation owed to it shall be prima facie evidence of the existence and amount of such Secured Obligation.

 

1.6 Statutes

Any reference in this Assignment to a statute or statutory provision shall, unless the contrary is indicated, be construed as a reference to such statute or statutory provision as the same shall have been or may be amended or re-enacted.

 

1.7 Implied Covenants

The following provisions of the Law of Property (Miscellaneous Provisions) Act 1994 will not apply to Clause 3.1 (Assignment) or Clause 3.2 (Notice of Assignment):

 

  (a) the words “other than any charges, encumbrances or rights which that person does not and could not reasonably be expected to know about” in Section 3(1);

 

  (b) the words “except to the extent that” and all the words thereafter in Section 3(2); and

 

  (c) Section 6(2).

 

1.8 Third Party Rights

It is intended that with the consent of the Collateral Agent each of the other Secured Creditors shall be able to enforce the provisions of Clause 16.4 (Currency Indemnity) (which can be amended with the consent of the Collateral Agent but without the consent of the other Secured Creditors), but otherwise a person which is not a party to this Assignment shall have no rights to enforce the provisions of this Assignment other than those it would have had if the Contracts (Rights of Third Parties) Act 1999 had not come into effect.

 

5


1.9 Clause and Schedule Headings

Clause and Schedule headings are for ease of reference only and shall not affect the construction of this Assignment.

 

1.10 Intercreditor

This Assignment is subject to the terms of the Intercreditor Agreement.

 

2. COVENANT TO PAY

 

2.1 Covenant to Pay

The Company agrees that promptly on demand of the Collateral Agent it will pay to the Collateral Agent any Secured Obligation that is due and owing by the Company provided that any recourse to the Company pursuant to this Assignment shall be limited to any Enforcement Proceeds.

 

2.2 Interest

Any amount which is owed by the Company under this Assignment and is not paid when due shall bear interest at the Agreed Rate from the due date until the date on which such amount is unconditionally and irrevocably paid in full and such interest shall accrue from day to day (after as well as before judgment) and be payable by the Company on demand of the Collateral Agent.

 

3. LEGAL ASSIGNMENT

 

3.1 Assignment

The Company hereby assigns with full title guarantee the Assigned Rights to the Collateral Agent to hold the same on behalf of the Secured Creditors on the terms set out in the Security Trust Deeds as security for the payment and discharge of the Secured Obligations.

 

3.2 Non-Assignable Rights

The Company declares that to the extent that any right, title, interest or benefit described in Clause 3.1 (Assignment) is for any reason not effectively assigned pursuant to Clause 3.1 (Assignment) for whatever reason, it shall:

 

  (a) hold the benefit of the same on trust for the Collateral Agent as security for the payment and discharge of the Secured Obligations; and

 

  (b) promptly upon becoming aware of the same, notify the Collateral Agent of the same and the reasons therefore and thereafter take such steps as the Collateral Agent may reasonably require to remove such prohibition or other reason for such incapacity.

 

6


3.3 Notice of Assignment

 

  (a) As soon as practicable after the execution of this Assignment, the Company shall deliver to each party to the Contracts as of the date hereof, a Notice of Assignment and if the Collateral Agent so requests the Company shall countersign such Notice of Assignment.

 

  (b) As soon as practicable after the execution of any Refund Guarantee or Construction Risks Insurance Policy entered into after the date of this Assignment, the Company shall deliver to each refund guarantor or broker (as applicable), a Notice of Assignment in respect of such Refund Guarantee or Construction Risks Insurance Policy (as applicable).

 

3.4 Acknowledgment of Assignment

The Company shall use commercially reasonable efforts to procure that as soon as practicable after each other party to the Contracts receives a Notice of Assignment, such other party shall deliver to the Collateral Agent an Acknowledgment of Assignment in substantially the form attached hereto or otherwise reasonably acceptable to the Collateral Agent.

 

4. THE CONTRACT

 

4.1 No Dealings with the Contract

 

  (a) The Company acknowledges that at all times during the Security Period and other than as expressly set out below, it shall not (nor shall it be entitled to):

 

  (i) receive (A) any refunds, payments or damages payable as a consequence of the repudiation or termination of the Construction Contract, (B) during the continuance of an Event of Default, any other sums from time to time payable to the Company under or in respect of the Construction Contract or (C) any payments under or in respect of the Refund Guarantees;

 

  (ii) agree to any waiver or amendment of or supplement to the terms of the Refund Guarantees other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

  (iii) agree to any waiver or amendment of or supplement to the terms of any Construction Risks Insurance Policy other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents;

 

7


  (iv) terminate, or allow to be terminated, any Refund Guarantee other than where an equivalent replacement Refund Guarantee is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination;

 

  (v) terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination; or

 

  (vi) assign, charge or dispose of the Contracts or any of the Assigned Rights (other than pursuant to the Other Vessel 1 Assignment of Contracts).

 

  (b) Notwithstanding anything to the contrary herein, the Company may make amendments, modifications or changes to any term or provision of the Construction Contract other than material amendments, modifications or changes to any term or provision of the Construction Contract that would change (i) the purpose of the Vessel or (ii) the Initial Construction Price in excess of [*] in the aggregate, in each case unless such amendment, modification or change is approved in advance by the Facility Agent and same could not reasonably be expected to be adverse to the interests of the Lenders or the Hermes Cover.

 

  (c) The Company acknowledges that at all times during the Security Period any payments under or in respect of the Construction Risks Insurance Policies shall be made in accordance with the Loss Payable Clause set out in the Annex to Part 3 (Form of Notice of Assignment to the Broker) of Schedule 1 (Forms of Notice of Assignment).

 

4.2 Performance of Obligations

The Company shall take, or cause to be taken, all steps reasonably required by the Collateral Agent to preserve or protect its interests and the interests of the Collateral Agent in the Contracts and shall diligently pursue any remedies available to it in respect of any breaches or claims of any party in connection with any of the Contracts which are necessary to preserve, protect and enforce the interests of the Collateral Agent in the Contracts.

 

5. CONTINUING SECURITY

 

5.1 Continuing and Independent Security

This Assignment shall constitute and be continuing security which shall not be released or discharged by any intermediate payment or settlement of all or any of the Secured Obligations, shall continue in full force and effect until the end of the Security Period and is in addition to and independent of, and shall not prejudice or merge with, any other security (or any right of set-off) which the Collateral Agent may have at any time for the Secured Obligations or any of them.

 

8


5.2 New Accounts

If the Collateral Agent receives notice of any security created or arising during the Security Period in respect of the Contracts or any of the Assigned Rights (other than pursuant to the Other Vessel 1 Assignment of Contracts), or following the occurrence and during the continuation of an Event of Default makes demand of the Parent or the applicable Borrower for payment of any or all of the Secured Obligations:

 

  (a) the Collateral Agent may open a new account or accounts in respect of any or all of the Secured Obligations (and if it does not do so it shall be treated as if it had done so at the time it received such notice or made such demand); and

 

  (b) thereafter any amounts paid by the Parent or the applicable Borrower to the Collateral Agent in respect of the Secured Obligations, or realised or recovered by the Collateral Agent under this Assignment, shall be credited (or be treated as having been credited) to a new account and not as having been applied in or towards payment of all or any of the Secured Obligations.

 

5.3 Avoidance of Payments

Where any release, discharge or other arrangement in respect of any Secured Obligation or any security the Collateral Agent may have for such Secured Obligation is given or made in reliance on any payment or other disposition which is avoided or must be repaid in an insolvency, liquidation or otherwise, and whether or not the Collateral Agent has conceded or compromised any claim that any such payment or other disposition will or should be avoided or repaid, this Assignment and the Security shall continue as if such release, discharge or other arrangement had not been given or made.

 

5.4 Immediate Recourse

Neither the Collateral Agent nor any other Secured Creditor shall be obliged before exercising any of the rights conferred on it or them by this Assignment or by law to seek to recover amounts due from the Parent or to exercise or enforce any other rights or security it or they may have or hold in respect of the Secured Obligations.

 

5.5 Waiver of Defences

Neither the obligations of the Company under this Assignment nor the Security and the rights, powers and remedies conferred on the Collateral Agent by this Assignment or by law, shall be discharged, impaired or otherwise affected by:

 

  (a) the winding-up, dissolution, administration or reorganisation of the Company or any other person or any change in the status, function, control or ownership of the Company or any such person;

 

  (b) any of the Secured Obligations or any other security held by the Collateral Agent in respect thereof being or becoming illegal, invalid, unenforceable or ineffective in any respect;

 

9


  (c) any time or other indulgence being granted or agreed to with the Company or any other person in respect of the Secured Obligations or any of them or in respect of any other security held by the Collateral Agent in respect thereof;

 

  (d) any amendment to, or any variation, waiver or release of, the Secured Obligations or any of them or any other security, guarantee or indemnity held by the Collateral Agent in respect thereof;

 

  (e) any total or partial failure to take or perfect any security proposed to be taken in respect of the Secured Obligations or any of them;

 

  (f) any total or partial failure to realise the value of, or any release, discharge, exchange or substitution of, any other security, guarantee or indemnity held by the Collateral Agent in respect of the Secured Obligations or any of them; or

 

  (g) any other act, event or omission which might operate to discharge, impair or otherwise affect the obligations of the Company under this Assignment, the Security or any of the rights, powers and remedies conferred on the Collateral Agent by this Assignment or by law.

 

5.6 Appropriation

Neither the Collateral Agent nor any other Secured Creditor shall be obliged to apply any sums held or received by it in respect of the Secured Obligations in or towards payment of the Secured Obligations and any such sum shall be held by or paid to the Collateral Agent for application pursuant to the terms of this Assignment, until the earlier of:

 

  (a) the date on which such monies are sufficient to satisfy the Secured Obligations in full and any money so applied could not be the subject of any clawback or similar circumstance; and

 

  (b) the date on which the Security has been enforced in full and all other remedies that the Collateral Agent may have under or in connection with the Credit Documents in all relevant jurisdictions have been exhausted.

 

6. REPRESENTATIONS AND WARRANTIES

The Company makes the representations and warranties set out in Clauses 6.1 (Entity Status) to 6.8 (Contract Terms). The Company acknowledges that the Collateral Agent has entered into this Assignment in reliance on those representations and warranties.

 

6.1 Entity Status

The Company (i) is a Person duly organized, constituted and validly existing (or the functional equivalent) under the laws of the jurisdiction of its formation, has the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted and (ii) is duly qualified and is authorized to do business and is in good standing (or the functional equivalent) in each jurisdiction where the ownership, leasing or operation of its property or the conduct of its business requires such qualifications except for failures to be so qualified or authorized or in good standing which, either individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.

 

10


6.2 Power and Authority

The Company has the power to enter into and perform this Assignment and the transactions contemplated hereby and has taken all necessary action to authorize the entry into and performance of this Assignment and such transactions. This Assignment constitutes legal, valid and binding obligations of the Company enforceable in accordance with its terms and in entering into this Assignment and borrowing the Loans, the Company is acting on its own account.

 

6.3 Form of Documentation

This Assignment is in proper legal form (under the laws of England, the Bahamas, Bermuda and each other jurisdiction where the Vessel is flagged or where the Company is domiciled) for the enforcement thereof under such laws. To ensure the legality, validity, enforceability or admissibility in evidence of this Assignment in England, the Bahamas and/or Bermuda it is not necessary that this Assignment be filed or recorded with any court or other authority in England, the Bahamas and Bermuda, except as have been made, or will be made, in accordance with Section 5, 6, 7 and 8 of the Credit Agreements, as applicable.

 

6.4 No Deductions or Withholdings

All amounts payable by the Company hereunder may be made free and clear of and without deduction or withholding for or on account of any Taxation in the Company’s jurisdiction.

 

6.5 No Filing or Stamp Taxes

It is not necessary that this Assignment be filed, recorded or enrolled with any court or other authority in England (or any other applicable jurisdiction) except as have been made or will be made in accordance with each Credit Agreement, or that any stamp, registration or similar tax be paid on or in relation to this Assignment save (i) to the extent that it may be regarded as constituting a charge over book debts and thus as registrable under the Companies Act 2006 and (ii) recording taxes which have been or will be paid as and to the extent due.

 

6.6 No Adverse Interests

Subject only to the Security and as otherwise contemplated under the Intercreditor Agreement, the Breakaway One Credit Facility and each Credit Agreement, no person other than the Company has any legal or beneficial interest (or any right to claim any such interest) in the Assigned Rights or any part thereof and the Company has not received notice of any such claim.

 

6.7 No Disposals

Save as permitted by the Breakaway One Credit Facility, each Credit Agreement, this Assignment or the Intercreditor Agreement, it has not transferred, mortgaged, charged or otherwise disposed of (or agreed to transfer, charge or otherwise dispose of), whether by way of security or otherwise, the benefit of all or any of the Assigned Rights.

 

11


6.8 Contract Terms

The terms of the Contracts do not restrict or otherwise limit its right to transfer, charge or assign any of the Assigned Rights pursuant to this Assignment.

 

6.9 Repetition

The representations and warranties set out in this Clause 6:

 

  (a) shall survive the execution of each Credit Document and each Borrowing under each Credit Agreement; and

 

  (b) are made on the date of this Assignment and are deemed to be repeated on each date during the Security Period with reference to the facts and circumstances then existing.

 

7. UNDERTAKINGS

 

7.1 Authorisations

The Company shall obtain, comply with the terms of and do all that is necessary to maintain in full force and effect all authorisations, approvals, licences and consents required in or by the laws of England and any other applicable jurisdiction to enable it lawfully to enter into and perform its obligations under this Assignment and to ensure the legality, validity, enforceability or admissibility in evidence in England and any other applicable jurisdiction of this Assignment.

 

7.2 No Action

The Company shall not take any action which would cause any of the representations made in Clause 6 (Representations and Warranties) to be untrue in any material respect at any time during the Security Period.

 

7.3 Notification of Misrepresentation

The Company shall notify the Collateral Agent of the occurrence of any event which results in or may reasonably be expected to result in any of the representations made in Clause 6 (Representations and Warranties) being untrue in any material respect when made or when deemed to be repeated.

 

7.4 Information

 

  (a) The Company shall provide the Collateral Agent with such reports and other information regarding the Contracts as the Collateral Agent may from time to time reasonably request.

 

  (b) Following the Initial Borrowing Date, the Company shall, as soon as reasonably practicable after an additional Refund Guarantee has been issued, deliver a supplement to Schedule 3 (Details of Refund Guarantees) to the Collateral Agent with updated information relating to such Refund Guarantee.

 

12


7.5 Delivery of Cash

Following the occurrence and during the continuation of an Event of Default, the Company shall promptly deliver all cash, proceeds, cheques, drafts, orders and other instruments for the payment of money received on account of any of the Contracts in the form received (properly endorsed, but without recourse, for collection where required) to the Collateral Agent and shall not commingle any such collections or proceeds with its other funds or property and shall, subject to the terms of the Intercreditor Agreement, hold the same upon an express trust for and on behalf of the Collateral Agent until delivered provided that, to the extent that the Intercreditor Agreement remains operative, the Company shall be relieved of its obligations under this clause 7.5 to the extent that it fulfils its obligations under clause 7.5 (Delivery of Cash) of the Other Vessel 1 Assignment of Contracts.

 

7.6 Delivery of Notices

The Company shall promptly deliver a copy of any notice or other correspondence received by it in connection with any of the Contracts to the Collateral Agent if such notice or correspondence has had or could reasonably be expected to have a material adverse effect on the value of such Contract.

 

8. FURTHER ASSURANCE

The Company shall from time to time and at its own expense give all such assurances and do all such things as the Collateral Agent may reasonably require or consider desirable to enable the Collateral Agent to perfect, preserve or protect the security created or intended to be created by this Assignment or to exercise any of the rights conferred on it by this Assignment or by law and to that intent the Company shall execute all such instruments, deeds and agreements and give all such notices and directions as the Collateral Agent may consider necessary.

 

9. ENFORCEMENT OF SECURITY

 

9.1 Security Enforceable

The Security shall become immediately enforceable if an Event of Default has occurred and is continuing.

 

9.2 Enforcement

Following the occurrence and during the continuation of an Event of Default, the Collateral Agent shall act in accordance with the terms of any instructions received under the Intercreditor Agreement for the purposes of exercising (or refraining from exercising) any of its rights to enforce all or any part of the Security, and in the absence of any such instructions, the Collateral Agent may in its absolute discretion enforce all or any part of the Security and exercise any of the rights conferred on it by this Assignment or by law at such times and in such manner as it thinks fit.

 

13


9.3 Power of Sale

Subject to the terms of the Intercreditor Agreement, following the occurrence and during the continuation of an Event of Default, the Collateral Agent may (without notice to the Company) sell or otherwise dispose of the Assigned Rights and shall be entitled to apply the proceeds of such sale or other disposal in paying the costs of such sale or disposal and thereafter in or towards the discharge of the Secured Obligations or otherwise as provided for in this Assignment.

 

9.4 Statutory Powers

For the purposes of all powers implied by statute the Secured Obligations shall be deemed to have become due and payable on the date of this Assignment.

 

9.5 Law of Property Act

Sections 93 and 103 of the Law of Property Act 1925 shall not apply to this Assignment or to any exercise by the Collateral Agent of its right to consolidate mortgages or its power of sale.

 

9.6 Realisation Accounts

If the Collateral Agent enforces the Security (whether by appointment of a Receiver or otherwise), the Collateral Agent may open and maintain with such financial institutions as it thinks fit one or more realisation accounts and pay any moneys it holds or receives under or pursuant to this Assignment into any such realisation account pending the application of such moneys pursuant to Clause 11 (Application of Proceeds).

 

10. RECEIVERS

 

10.1 Appointment of Receivers

At any time after the occurrence and during the continuation of an Event of Default, or if the Company requests it to do so, the Collateral Agent may by a written instrument and without notice to the Company appoint one or more persons as Receiver of all or any part of the Assigned Rights, each such person being entitled to act individually as well as jointly and being for all purposes the agent of the Company.

 

10.2 Powers of a Receiver

In addition to the powers conferred on the Collateral Agent by this Assignment, each Receiver appointed pursuant to Clause 10.1 (Appointment of Receivers) shall have in relation to the Assigned Rights in respect of which such Receiver was appointed all the powers conferred by the Law of Property Act 1925 (as extended by this Assignment) on a Receiver appointed under that Act.

 

14


11. APPLICATION OF PROCEEDS

 

11.1 Any moneys held or received by the Collateral Agent under this Assignment shall be applied by the Collateral Agent in or towards the discharge of the Secured Obligations in accordance with the provisions of the Intercreditor Agreement.

 

12. POWER OF ATTORNEY

 

12.1 Appointment

By way of security for the performance of its obligations under this Assignment, the Company hereby irrevocably appoints each of the Collateral Agent and its delegates and sub-delegates to be its attorney acting severally (or jointly with any other such attorney or attorneys) and on its behalf and in its name or otherwise to do any and every thing which the Company is obliged to do under the terms of this Assignment or which such attorney considers necessary or desirable in order to enable the Collateral Agent or such attorney to exercise the rights conferred on it by this Assignment or by law.

 

12.2 Ratification

The Company hereby ratifies and confirms and agrees to ratify and confirm whatever any attorney appointed under this Assignment shall do in its capacity as such.

 

13. RELEASE OF THE SECURITY

After the end of the Security Period or otherwise in accordance with Section 14.21 (Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer) of each Credit Agreement, the Collateral Agent shall, at the request and cost of the Company, execute all such documents and do all such other things as may be required to release the Security, in each case without recourse to or any representation or warranty by or from the Collateral Agent.

 

14. PAYMENTS

 

14.1 Grossing Up

All payments by the Company under this Assignment shall be made without any deductions and free and clear of, and without deduction for or on account of, tax except, in the latter case, to the extent that the Company is required by law to make payment subject to tax. If any tax or amounts in respect of tax must be deducted, or any other deductions must be made, from any amounts payable or paid by the Company, or paid or payable by the Collateral Agent to any Secured Creditor, under this Assignment, the Company shall pay such additional amounts as may be necessary to ensure that the relevant Secured Creditor receives a net amount equal to the full amount which it would have received had payment not been made subject to tax.

 

14.2 Payments without Set-off

Any payment made by the Company under this Assignment shall be made free and clear of and without any deduction for or on account of any set-off or counterclaim.

 

15


14.3 Manner of Payment

Each payment made by the Company under this Assignment shall be paid in the manner in which payments are to be made by the Company under each Credit Agreement.

 

15. WAIVERS AND REMEDIES

No failure by the Collateral Agent to exercise, nor any delay by the Collateral Agent in exercising, any right or remedy under this Assignment shall operate as a waiver thereof nor shall any single or partial exercise of any such right or remedy prevent any further or other exercise thereof or the exercise of any other such right or remedy.

 

16. ADDITIONAL PROVISIONS

 

16.1 Partial Invalidity

If at any time any provision of this Assignment is or becomes illegal, invalid or unenforceable in any respect or any of the Security is or becomes ineffective in any respect under the law of any jurisdiction, such illegality, invalidity, unenforceability or ineffectiveness shall not affect:

 

  (a) the legality, validity or enforceability of the remaining provisions of this Assignment or the effectiveness in any other respect of the Security under such law; or

 

  (b) the legality, validity or enforceability of such provision or the effectiveness of the Security under the law of any other jurisdiction.

 

16.2 Potentially Avoided Payments

If the Collateral Agent determines that an amount paid to a Secured Creditor under any Credit Document is being avoided or otherwise set aside on the liquidation or administration of the person by whom such amount was paid, then for the purposes of this Assignment, such amount shall be regarded as not having been paid.

 

16.3 Currency Conversion

If necessary to apply any sum held or received by the Collateral Agent in or towards payment of the Secured Obligations, the Collateral Agent may purchase an amount in another currency and the rate of exchange to be applied shall be that at which, at such time as it considers appropriate, the Collateral Agent is able to effect such purchase.

 

16.4 Currency Indemnity

If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from the Company hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Collateral Agent could purchase the specified currency with such other currency on the Business Day preceding that on which final judgment is given. The obligations of the Company in

 

16


respect of any sum due to the Collateral Agent hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by the Collateral Agent of any sum adjudged to be so due in such other currency the Collateral Agent may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to the Collateral Agent in the specified currency, the Company agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify the Collateral Agent against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to the Collateral Agent in the specified currency, the Collateral Agent agrees to remit such excess to the Company.

 

16.5 Rights Cumulative

The rights and remedies provided by this Assignment are cumulative and not exclusive of any rights or remedies provided by law.

 

16.6 Collateral Agent in Possession

The Collateral Agent shall not by reason of its taking any action permitted by this Assignment or its taking possession of all or any of the Assigned Rights be liable to account as mortgagee in possession or, other than as expressly stated in each Security Trust Deed, be liable for any loss on realisation or for any default or omission for which a mortgagee in possession might be liable.

 

17. ASSIGNMENT

 

17.1 The Company’s Rights

The rights of the Company under this Assignment are not assignable or transferable and the Company agrees that it will not purport to assign all or any such rights except as provided under the Breakaway One Credit Facility and the Credit Agreements.

 

17.2 The Collateral Agent’s Rights

 

  (a) The rights of the Collateral Agent under this Assignment are assignable in whole or in part without the consent of the Company except as provided under the Credit Agreements.

 

  (b) The Collateral Agent may not resign except in accordance with the terms of the Security Trust Deeds.

 

18. NOTICES

 

18.1 Communications in Writing

Each communication to be made under this Assignment shall be made in writing and, unless otherwise stated, may be made by fax, electronic mail or letter.

 

17


18.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 18.1 (Communications in writing) the contact details of each of the parties are as follows:

 

  (a) to the Collateral Agent:

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

  (b) to the Company:

7665 Corporation Center Drive

Miami, Florida 33126

USA

Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

        hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com

or to such other address and/or number as is notified in writing by a party to the other parties under this Assignment.

 

18.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to

 

18


the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified in Clause 18.2 (Contact Details); provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Collateral Agent and the Company agree that they (x) shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and (y) shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Collateral Agent shall not be effective until received by the Collateral Agent, or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Company to the Collateral Agent, only if it is addressed in such a manner as the Collateral Agent shall specify for this purpose.

 

19. GOVERNING LAW

 

  (a) This Assignment and any non-contractual obligations arising out of or in connection with it shall be governed by and construed in accordance with English law.

 

  (b) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Assignment (including a dispute relating to the existence, validity or termination of this Assignment or any non-contractual obligation arising out of or in connection with this Assignment ) (a “Dispute”). The parties hereto agree that the courts of England are the most appropriate and convenient courts to settle disputes and accordingly no party hereto will argue to the contrary. This Clause 19 is for the benefit of the Collateral Agent on behalf of the Secured Creditors. As a result, it shall not be prevented from taking proceedings relating to a dispute in any other courts with jurisdiction. To the extent allowed by law, the Collateral Agent may take concurrent proceedings in any number of jurisdictions.

 

  (c) Without prejudice to any other mode of service allowed under any relevant law, the Company: (i) irrevocably appoints EC3 Services Limited at 51 Eastcheap, London, England, EC3M 1JP as its agent for service of process in relation to any proceedings before the English courts in connection with any credit document and (ii) agrees that failure by an agent for service of process to notify the relevant credit party of the process will not invalidate the proceedings concerned. If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Company must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the Collateral Agent. Failing this, the Collateral Agent may appoint another agent for this purpose.

 

19


  (d) Each party to this Assignment expressly agrees and consents to the provisions of this Clause 19.

 

20. COUNTERPARTS AND EFFECTIVENESS

 

20.1 Counterparts

This Assignment may be executed in counterparts and such counterparts taken together shall constitute one and the same instrument.

 

20.2 Effectiveness

This Assignment shall take effect and be delivered as a deed on the date on which it is stated to be made.

IN WITNESS WHEREOF this Assignment has been executed as a deed by the Company and the Collateral Agent.

 

20


SCHEDULE 1

FORMS OF NOTICE OF ASSIGNMENT

Part 1

FORM OF NOTICE OF ASSIGNMENT TO THE SHIPBUILDER

 

To:   Meyer Werft GmbH
  Industriegebiet Süd
  D-26871 Papenburg
  Germany
Cc:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway One, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the construction contract dated 24 September 2010 between the Company and you, as shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the passenger cruise ship (the “Ship”) with provisional hull number 678 (the “Construction Contract”).

With effect from your receipt of this notice we hereby give you notice that:

 

(a) subject to paragraph (b), all refunds, payments or damages payable to the Company as a consequence of the repudiation or termination of the Construction Contraction should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(b)

following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, KfW IPEX-Bank

 

21


 

GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)), written notice of which Event of Default has been delivered to you by the Collateral Agent, all payments to be made to the Company under or arising from the Construction Contract should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(c) following an Event of Default, all remedies of the Company provided for in the Construction Contract or available at law or in equity shall be exercisable by the Collateral Agent;

 

(d) following an Event of Default, all rights of the Company to compel performance of the Construction Contract shall be exercisable by the Collateral Agent;

 

(e) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Contract are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(f) the Company may make amendments, modifications or changes to any term or provision of the Construction Contract other than material amendments, modifications or changes to any term or provision of the Construction Contract that would change (i) the purpose of the Vessel or (ii) the initial construction price of the Vessel (i.e., €615,000,000) in excess of [*] in the aggregate, in each case unless such amendment, modification or change is approved in advance by each of the Facility Agents (as defined in each Credit Agreement) and same could not reasonably be expected to be adverse to the interests of the Lenders or the Hermes Cover (as referenced in the Assignment);

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Contract (including without limitation, the right to superintend the construction of the Ship and to propose and agree modifications (as referred to in the Construction Contract) and to accept or reject the Ship and to take and accept delivery of and title to the Ship) unless and until the Collateral Agent notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Contract. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Contract without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Construction Contract and the Collateral Agent is under no obligation of any kind under the Construction Contract nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

 

22


You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Contract as it may from time to time reasonably request and to send copies of any notices issued by you under the Construction Contract which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Contract or the Ship, to the Collateral Agent as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

 

Yours faithfully

 

For and on behalf of
BREAKAWAY ONE, LTD.

 

23


Part 2

FORM OF NOTICE OF ASSIGNMENT TO THE REFUND GUARANTOR

 

To:   [Refund Guarantor]
Cc:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway One, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the refund guarantee dated [] and issued by you as refund guarantor in favour of the Company pursuant to which you guarantee certain refund obligations of Meyer Werft GmbH, as shipbuilder under the Construction Contract (as defined in the Assignment) (the “Refund Guarantee”), including all monies which may be payable under or in respect of the Refund Guarantee.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Refund Guarantee should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(b)

following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit

 

24


 

Agreements”)), written notice of which Event of Default has been delivered to you by the Collateral Agent, all remedies of the Company provided for in the Refund Guarantee or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Refund Guarantee shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Refund Guarantee are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(e) the Company has agreed not to agree to any waiver or amendment of or supplement to the terms of the Refund Guarantee other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Refund Guarantee other than where a replacement Refund Guarantee is issued to the Company which meets the Company’s requirements under the Construction Contract on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each Credit Agreement) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Refund Guarantee except to the extent that the Collateral Agent notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) (including, without limitation, making a demand under the Refund Guarantee) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Refund Guarantee. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Refund Guarantee without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Refund Guarantee and the Collateral Agent is under no obligation of any kind under the Refund Guarantee nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Refund Guarantee as it may from time to time reasonably request and to send copies of all notices issued by you under the Refund Guarantee which have had or would reasonably be expected to have a material adverse effect on the value of the Refund Guarantee, to the Collateral Agent as well as to the Company.

 

25


This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

 

Yours faithfully

 

For and on behalf of
BREAKAWAY ONE, LTD.

 

26


Part 3

FORM OF NOTICE OF ASSIGNMENT TO THE BROKER

(for attachment by way of endorsement to the Policy)

 

To:   [Broker]
Cc:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sir/Madam

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway One, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of construction risks insurance policy dated [] issued for the benefit of Meyer Werft GmbH (the “Yard”) and the Company in connection with the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.678 to be constructed by the Yard (the “Construction Risks Insurance Policy”), including all monies which may be payable to the Company under or in respect of the Construction Risks Insurance Policy.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Construction Risks Insurance Policy should be made in accordance with the terms of the Loss Payable Clause set out in the Annex 1 (Loss Payable Clause) to this Notice;

 

(b) following an Event of Default, all remedies of the Company provided for in the Construction Risks Insurance Policy or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Construction Risks Insurance Policy shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Risks Insurance Policy are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

27


(e) the Company has agreed that no waiver or amendment of or supplement to the terms of the Construction Risks Insurance Policy may be made other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)).

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is issued in favour of the Yard and the Company on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each of the Credit Agreements) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Risks Insurance Policy except that to the extent that the Collateral Agent notifies you in writing that an Event of Default has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Risks Insurance Policy. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Risks Insurance Policy without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations (if any) under the Construction Risks Insurance Policy and the Collateral Agent is under no obligation of any kind under the Construction Risks Insurance Policy nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Risks Insurance Policy as it may from time to time reasonably request and to send copies of

 

28


all notices issued by you under the Construction Risks Insurance Policy which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Risks Insurance Policy, to the Collateral Agent as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

 

Yours faithfully

 

For and on behalf of
BREAKAWAY ONE, LTD.

 

29


ANNEX 1

LOSS PAYABLE CLAUSE

It is noted that by a first legal assignment in writing dated 20[] BREAKAWAY ONE, LTD., the buyer (“Buyer”) of the vessel presently under construction by Meyer Werft GmBH, Papenburg Germany (“Builder”) with hull number [] has assigned to KFW IPEX-BANK GMBH of [] (“Assignee”) all the Buyer’s interests in any claims proceeds in this policy and its benefits therein including all such claims of whatsoever nature as the Buyer may have hereunder.

All sums payable to the Buyer under this policy shall be paid to the Buyer unless and until underwriters have been otherwise instructed by notice in writing from the Assignee following the occurrence and continuation of an Event of Default, as defined in the Credit Agreement dated as of [] and made among and between the Buyer, NCL Corporation Ltd., as the Buyer’s parent, the Assignee, the lenders from time to time party thereto and the other parties from time to time party thereto.

All sums payable to the Builder under this policy shall be payable to the Builder, subject to any notice of assignment of the Builder’s interests in this policy.

 

30


SCHEDULE 2

FORMS OF ACKNOWLEDGMENT OF ASSIGNMENT

Part 1

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE SHIPBUILDER

[To be printed only on copy of the Notice of Assignment given]

 

To:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Construction Contract) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Construction Contract and that we will comply with the terms of the Notice.

We also confirm that the Construction Contract is in full force and effect in accordance with its terms. We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable) with respect to the Construction Contract.

 

Yours faithfully
For and on behalf of
Meyer Werft GmbH
as Shipbuilder
By:
Date:

 

31


Part 2

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE REFUND

GUARANTOR

[To be printed only on copy of the Notice of Assignment given]

 

To:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Refund Guarantee) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Refund Guarantee and that we will comply with the terms of the Notice.

We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable).

 

Yours faithfully
For and on behalf of
[the Refund Guarantor]
as Refund Guarantor
By:
Date:

 

32


Part 3

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE BROKER

[To be printed only on copy of the Notice of Assignment given]

 

To:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

HULL NO. S. 678 (the “Vessel”)

BREAKAWAY ONE, LTD. (the “Company”)

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (i) (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Construction Risks Insurance Policy) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Construction Risks Insurance Policy, (ii) we will comply with the terms of the Notice and (iii) we have effected insurances for the benefit of Meyer Werft GmbH (the “Yard”) and the Company as set out in Annex 1 attached.

Pursuant to instructions received from the Yard and/or its authorised managers or agents and in consideration of you and the Company approving us as the appointed brokers in connection with the insurances covered by this letter, we hereby undertake:

 

1. to hold the insurance slips or contracts, the policies when issued, and any renewals of such policies or any policies substituted therefor with your consent as may be arranged through ourselves and the benefit of the insurances thereunder to your order in accordance with the terms of the Loss Payable Clause set out in Annex 2; and

 

2. to arrange for the said Loss Payable Clause to be included on the policies when issued; and

 

3. to have endorsed on each and every policy as and when the same is issued a Notice of Assignment to Underwriters in the form of Annex 3 hereto dated and signed by the Company and acknowledged by underwriters in accordance with market practice; and

 

33


4. to advise you promptly if we cease to be the appointed brokers in connection with the insurances covered by this letter or in the event of any material changes of which we are aware affecting such insurances; and

 

5. following a written application received from you not later than one month before expiry of these insurances to notify you within fourteen days of the receipt of such application in the event of our not having received notice of renewal instructions from the Yard and/or its authorised managers or agents, and in the event of our receiving instructions to renew to advise you promptly of the details thereof; and

 

6. to forward to you promptly any notices of cancellation that we receive from underwriters; and

 

7. following a written application from you to advise you promptly of the premium payment situation where such premium is paid or payable through our intermediary; and

 

8. not to challenge the effectiveness of the assignment to the Collateral Agent of the insurances constituted by this policy; and

 

9. not to revoke, modify or change the terms of the Loss Payable Clause or the undertakings made herein without the written consent of the Collateral Agent.

If and where we are responsible for the payment of premium to underwriters, our above undertakings are given subject to our lien on the policies for premiums and subject to our right of cancellation on default in payment of such premiums but we undertake not to exercise such rights of cancellation without giving you ten days notice in writing either by letter or electronically transmitted message and a reasonable opportunity for you to pay any premiums outstanding.

It is understood and agreed that the operation of any automatic termination of cover, cancellation or amendment provisions contained in the policy conditions shall override any undertakings given by us as brokers.

Notwithstanding the terms of the said Loss Payable Clause and the Notice, unless and until we receive written notice from you to the contrary, we shall be empowered to arrange for a collision and/or salvage guarantee to be given in the event of bail being required in order to prevent the arrest of the Vessel or to secure the release of the Vessel from arrest following a casualty. Where a guarantee has been given as aforesaid and the guarantor has paid any sum under the guarantee in respect of such claim, there shall be payable directly to the guarantor out of the proceeds of the said policies a sum equal to the sum so paid.

This undertaking shall be governed by and construed in accordance with English law and any disputes arising out of or in any way connected with this undertaking shall be submitted to the exclusive jurisdiction of the English courts.

This undertaking is subject to all claims and returns of premiums being collected through us as brokers.

 

34


Yours faithfully
For and on behalf of
[the Broker]
as [Broker]
By:
Date:

 

35


ANNEX 1

DETAILS OF INSURANCES

 

36


ANNEX 2

LOSS PAYABLE CLAUSE

It is noted that by a first legal assignment in writing dated 20[] BREAKAWAY ONE, LTD., the buyer (“Buyer”) of the vessel presently under construction by Meyer Werft GmBH, Papenburg Germany (“Builder”) with hull number [] has assigned to KFW IPEX-BANK GMBH of [] (“Assignee”) all the Buyer’s interests in any claims proceeds in this policy and its benefits therein including all such claims of whatsoever nature as the Buyer may have hereunder.

All sums payable to the Buyer under this policy shall be paid to the Buyer unless and until underwriters have been otherwise instructed by notice in writing from the Assignee following the occurrence and continuation of an Event of Default, as defined in the Credit Agreement dated as of [] and made among and between the Buyer, NCL Corporation Ltd., as the Buyer’s parent, the Assignee, the lenders from time to time party thereto and the other parties from time to time party thereto.

All sums payable to the Builder under this policy shall be payable to the Builder, subject to any notice of assignment of the Builder’s interests in this policy.

 

37


ANNEX 3

NOTICE OF ASSIGNMENT TO UNDERWRITERS

(for attachment by way of endorsement to the Policy)

 

To:   [Underwriter]
Cc:   KfW IPEX-Bank GmbH as Collateral Agent
  Palmengartenstrasse 5-9
  60325 Frankfurt am Main
  Germany
  Attention: Ship Finance, X2a4, Claudia Wenzel
  Fax: +49 69 7431 2944
  E-mail: claudia.wenzel@kfw.de
Date:   []

Dear Sir/Madam

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway One, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of construction risks insurance policy dated [] issued for the benefit of Meyer Werft GmbH (the “Yard”) and the Company in connection with the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.678 to be constructed by the Yard (the “Construction Risks Insurance Policy”), including all monies which may be payable to the Company under or in respect of the Construction Risks Insurance Policy.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Construction Risks Insurance Policy should be made in accordance with the terms of the Loss Payable Clause set out in the Annex 1 (Loss Payable Clause) to this Notice;

 

(b) following an Event of Default, all remedies of the Company provided for in the Construction Risks Insurance Policy or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Construction Risks Insurance Policy shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Risks Insurance Policy are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

38


(e) the Company has agreed that no waiver or amendment of or supplement to the terms of the Construction Risks Insurance Policy may be made other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, the NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, the NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)).

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is issued in favour of the Yard and the Company on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each of the Credit Agreements) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Risks Insurance Policy except that to the extent that the Collateral Agent notifies you in writing that an Event of Default has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Risks Insurance Policy. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Risks Insurance Policy without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations (if any) under the Construction Risks Insurance Policy and the Collateral Agent is under no obligation of any kind under the Construction Risks Insurance Policy nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Risks Insurance Policy as it may from time to time reasonably request and to send copies of all notices issued by you under the Construction Risks Insurance Policy which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Risks Insurance Policy, to the Collateral Agent as well as to the Company.

 

39


This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

 

Yours faithfully

 

For and on behalf of
BREAKAWAY ONE, LTD.

 

40


SCHEDULE 3

DETAILS OF REFUND GUARANTEES

 

[Name of Issuer]   [Date of Refund Guarantee]

 

41


SIGNATORIES

 

Signed as a deed on behalf of BREAKAWAY ONE, LTD, a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company  
 

 

  Authorised [signatory] [signatories]
Signed as a deed on behalf of KFW IPEX-BANK GMBH, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company  
 

 

  Authorised [signatory] [signatories]

 

42


LOGO

 

 

EXHIBIT I-2

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

Dated [] 2010

HULL NO. S. 692

FORM OF ASSIGNMENT OF CONTRACTS

between

BREAKAWAY TWO, LTD.

as Company

and

KFW IPEX-BANK GMBH

as Collateral Agent

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


LOGO

 

 

TABLE OF CONTENTS

 

          Page  
1.    INTERPRETATION      1   
2.    COVENANT TO PAY      6   
3.    LEGAL ASSIGNMENT      6   
4.    THE CONTRACT      7   
5.    CONTINUING SECURITY      8   
6.    REPRESENTATIONS AND WARRANTIES      10   
7.    UNDERTAKINGS      12   
8.    FURTHER ASSURANCE      13   
9.    ENFORCEMENT OF SECURITY      13   
10.    RECEIVERS      14   
11.    APPLICATION OF PROCEEDS      15   
12.    POWER OF ATTORNEY      15   
13.    RELEASE OF THE SECURITY      15   
14.    PAYMENTS      15   
15.    WAIVERS AND REMEDIES      16   
16.    ADDITIONAL PROVISIONS      16   
17.    ASSIGNMENT      17   
18.    NOTICES      17   
19.    GOVERNING LAW      19   
20.    COUNTERPARTS AND EFFECTIVENESS      20   
SCHEDULE 1       FORMS OF NOTICE OF ASSIGNMENT      21   
SCHEDULE 2       FORMS OF ACKNOWLEDGMENT OF ASSIGNMENT      31   
SCHEDULE 3       DETAILS OF REFUND GUARANTEES      41   

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


THIS ASSIGNMENT is dated [] 2010

BETWEEN:

 

(1) BREAKAWAY TWO, LTD., a Bermuda company with its registered office as of the date hereof at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Company”); and

 

(2) KFW IPEX-BANK GMBH, as collateral agent under each Credit Agreement for and on behalf of the Secured Creditors under and as defined in such Credit Agreement (the “Collateral Agent”, which expression includes any person which is for the time being a collateral agent for the Secured Creditors for the purposes of this Assignment).

RECITALS

 

(A) The applicable Lenders are willing to make a loan facility available to the Borrowers on the terms and subject to the conditions set out in the Credit Agreements, on condition that the Company enters into this Assignment as security for the Borrowers’ respective obligations and Liabilities as Borrower under or in relation to the Credit Documents.

 

(B) The Board of Directors of the Company is satisfied that the Company is entering into this Assignment for the purposes of its business and that its doing so benefits the Company.

 

(C) The Company and the Collateral Agent intend this Assignment to take effect as a deed.

 

(D) The Collateral Agent holds the benefit of this Assignment on trust for itself and for the Secured Creditors on the terms of the Credit Agreements, the Security Trust Deeds and the Intercreditor Agreement.

 

1. INTERPRETATION

 

1.1 Definitions

In this Assignment the following terms have the meanings given to them in this Clause.

Acknowledgment of Assignment” means a duly completed acknowledgement of assignment in the form set out in the relevant Part of Schedule 2 (Forms of Acknowledgement of Assignment) being:

 

  (a) Part 1, in the case of the Construction Contract;

 

  (b) Part 2, in the case of the Refund Guarantees; and

 

  (c) Part 3, in the case of the Construction Risks Insurance Policies; and

or in each case in such other form as may be approved by the Collateral Agent.


Agent” means each Agent under and as defined in each Credit Agreement.

Agreed Rate” means the rate specified in section 2.06(b) and 2.06(c) (Interest) of each Credit Agreement.

Assigned Rights” means the Company’s rights, title, interest and benefits in, to and in respect of the Contracts.

Borrower” means Pride of Hawaii, LLC (“POH”) with respect to the Jade Credit Facility and Norwegian Jewel Limited (“NJL”) with respect to the Jewel Credit Facility.

Breakaway Two Credit Facility” means the €529,846,154 credit facility dated on or about the date hereof among, inter alia, the Parent, the Company, as borrower, the Joint Lead Arrangers (as defined therein), the Lenders (as defined therein), the Collateral Agent (as defined therein), Nordea Bank Norge ASA, as documentation agent and Commerzbank Aktiengesellschaft, as Hermes Agent.

Construction Contract” means the construction contract dated 24 September 2010 between the Company, the Parent and the Shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the Vessel.

Construction Risks Insurance Policies” any and all insurance policies from time to time issued for the benefit of the Shipbuilder and the Company in connection with the construction of the Vessel under the Construction Contract.

Contracts” means each of the:

 

  (a) the Construction Contract;

 

  (b) the Refund Guarantees; and

 

  (c) the Construction Risks Insurance Policies.

Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Credit Agreement Obligations” means “Credit Document Obligations” as defined in the applicable Credit Agreement.

Enforcement Proceeds” means any enforcement proceeds recovered in respect of the Security.

Event of Default” means an “Event of Default” as defined in each Credit Agreement.

Intercreditor Agreement” means the intercreditor deed dated on or about the date hereof between, inter alia, the Company, the Lenders, the lenders under the Breakaway Two Credit Facility, the collateral agent under the Breakaway Two Credit Facility, and the Collateral Agent (in its capacity as collateral agent under each of the Jade Credit Facility and the Jewel Credit Facility).

 

2


“Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, POH, as borrower, the Parent, the Lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jade Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, POH, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

“Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, NJL, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jewel Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, NJL, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

Lender” means each Lender under and as defined in each Credit Agreement.

Lender Creditors” means the Agents and the Lenders.

Liability” means any liability for the payment of money, whether in respect of principal, interest or otherwise, whether actual or contingent, whether owed jointly or severally and whether owed as principal or surety or in any other capacity.

Notice of Assignment” means a duly completed notice of assignment in the form set out in the relevant Part of Schedule 1 (Forms of Notice of Assignment) being:

 

  (a) Part 1, in the case of the Construction Contract;

 

  (b) Part 2, in the case of each Refund Guarantees;

 

  (c) Part 3, in the case of the Construction Risks Insurance Policies;

or in each case such other form as may be approved by the Collateral Agent.

Other Creditors” means each Lender or any affiliate thereof with which the applicable Borrower and/or the Parent may at any time and from time to time after the date hereof enter into, or guaranty the obligations of one or more of its Subsidiaries under one or more Interest Rate Protection Agreements or Other Hedging Agreements (even if the respective Lender subsequently ceases to be a Lender under the applicable Credit Agreement for any reason), together with such Lender’s or affiliate’s successors and assigns, if any.

Other Vessel 2 Assignment of Contracts” means the assignment agreement dated on or about the date hereof between the Company and the Collateral Agent as security trustee on behalf of the ECF Creditors (as defined in the Intercreditor Agreement) in respect of the Refund Guarantees, the Construction Contract and the Construction Risks Insurance Policies.

Parent” means NCL Corporation Ltd., a Bermuda company.

 

3


Receiver” means a receiver and manager or any other receiver (whether appointed pursuant to this Assignment, pursuant to any statute, by a court or otherwise) of any of the Assigned Rights.

Refund Guarantees” means any and all refund guarantees from time to time issued in favour of the Company to secure certain obligations of the Shipbuilder under the Construction Contract other than any refund guarantees issued by KfW IPEX-Bank GmbH acting in its capacity as a refund guarantor.

Secured Creditors” means the Lender Creditors and the Other Creditors.

Secured Obligations” means the Credit Agreement Obligations and the Other Obligations.

Security” means the security created by this Assignment.

Security Period” means the period beginning on the date of this Assignment and ending on the date upon which the Collateral Agent is satisfied that:

 

  (a) none of the Secured Creditors is under any obligation (whether actual or contingent) to make advances or provide other financial accommodation to the Company under any of the Credit Documents; and

 

  (b) all Secured Obligations have been unconditionally and irrevocably paid and discharged in full (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement).

Security Trust Deeds” means the Jade Security Trust Deed and the Jewel Security Trust Deed.

Shipbuilder” means Meyer Werft GmbH.

Vessel” means the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.692 to be constructed by the Shipbuilder.

 

1.2 Continuing Event of Default

An Event of Default shall be regarded as continuing if (a) the circumstances constituting such event continue and (b) such Event of Default has not been waived in accordance with the terms of the Credit Documents.

 

1.3 Defined Terms

Unless this Assignment provides otherwise, a term which is defined (or expressed to be subject to a particular construction) in the Credit Agreements or in the Intercreditor Agreement shall have the same meaning (or be subject to the same construction) in this Assignment.

 

4


1.4 References to Agreements

Unless otherwise stated, any reference in this Assignment to any agreement or document (including any reference to this Assignment or any other Credit Document) shall be construed as a reference to:

 

  (a) such agreement or document as amended, varied, novated or supplemented from time to time;

 

  (b) any other agreement or document whereby such agreement or document is so amended, varied, novated or supplemented; and

 

  (c) any other agreement or document entered into pursuant to or in accordance with such agreement or document.

 

1.5 Certificates

A certificate of any Secured Creditor as to the amount of any Secured Obligation owed to it shall be prima facie evidence of the existence and amount of such Secured Obligation.

 

1.6 Statutes

Any reference in this Assignment to a statute or statutory provision shall, unless the contrary is indicated, be construed as a reference to such statute or statutory provision as the same shall have been or may be amended or re-enacted.

 

1.7 Implied Covenants

The following provisions of the Law of Property (Miscellaneous Provisions) Act 1994 will not apply to Clause 3.1 (Assignment) or Clause 3.2 (Notice of Assignment):

 

  (a) the words “other than any charges, encumbrances or rights which that person does not and could not reasonably be expected to know about” in Section 3(1);

 

  (b) the words “except to the extent that” and all the words thereafter in Section 3(2); and

 

  (c) Section 6(2).

 

1.8 Third Party Rights

It is intended that with the consent of the Collateral Agent each of the other Secured Creditors shall be able to enforce the provisions of Clause 16.4 (Currency Indemnity) (which can be amended with the consent of the Collateral Agent but without the consent of the other Secured Creditors), but otherwise a person which is not a party to this Assignment shall have no rights to enforce the provisions of this Assignment other than those it would have had if the Contracts (Rights of Third Parties) Act 1999 had not come into effect.

 

5


1.9 Clause and Schedule Headings

Clause and Schedule headings are for ease of reference only and shall not affect the construction of this Assignment.

 

1.10 Intercreditor

This Assignment is subject to the terms of the Intercreditor Agreement.

 

2. COVENANT TO PAY

 

2.1 Covenant to Pay

The Company agrees that promptly on demand of the Collateral Agent it will pay to the Collateral Agent any Secured Obligation that is due and owing by the Company provided that any recourse to the Company pursuant to this Assignment shall be limited to any Enforcement Proceeds.

 

2.2 Interest

Any amount which is owed by the Company under this Assignment and is not paid when due shall bear interest at the Agreed Rate from the due date until the date on which such amount is unconditionally and irrevocably paid in full and such interest shall accrue from day to day (after as well as before judgment) and be payable by the Company on demand of the Collateral Agent.

 

3. LEGAL ASSIGNMENT

 

3.1 Assignment

The Company hereby assigns with full title guarantee the Assigned Rights to the Collateral Agent to hold the same on behalf of the Secured Creditors on the terms set out in the Security Trust Deeds as security for the payment and discharge of the Secured Obligations.

 

3.2 Non-Assignable Rights

The Company declares that to the extent that any right, title, interest or benefit described in Clause 3.1 (Assignment) is for any reason not effectively assigned pursuant to Clause 3.1 (Assignment) for whatever reason, it shall:

 

  (a) hold the benefit of the same on trust for the Collateral Agent as security for the payment and discharge of the Secured Obligations; and

 

  (b) promptly upon becoming aware of the same, notify the Collateral Agent of the same and the reasons therefore and thereafter take such steps as the Collateral Agent may reasonably require to remove such prohibition or other reason for such incapacity.

 

6


3.3 Notice of Assignment

 

  (a) As soon as practicable after the execution of this Assignment, the Company shall deliver to each party to the Contracts as of the date hereof, a Notice of Assignment and if the Collateral Agent so requests the Company shall countersign such Notice of Assignment.

 

  (b) As soon as practicable after the execution of any Refund Guarantee or Construction Risks Insurance Policy entered into after the date of this Assignment, the Company shall deliver to each refund guarantor or broker (as applicable), a Notice of Assignment in respect of such Refund Guarantee or Construction Risks Insurance Policy (as applicable).

 

3.4 Acknowledgment of Assignment

The Company shall use commercially reasonable efforts to procure that as soon as practicable after each other party to the Contracts receives a Notice of Assignment, such other party shall deliver to the Collateral Agent an Acknowledgment of Assignment in substantially the form attached hereto or otherwise reasonably acceptable to the Collateral Agent.

 

4. THE CONTRACT

 

4.1 No Dealings with the Contract

 

  (a) The Company acknowledges that at all times during the Security Period and other than as expressly set out below, it shall not (nor shall it be entitled to):

 

  (i) receive (A) any refunds, payments or damages payable as a consequence of the repudiation or termination of the Construction Contract, (B) during the continuance of an Event of Default, any other sums from time to time payable to the Company under or in respect of the Construction Contract or (C) any payments under or in respect of the Refund Guarantees;

 

  (ii) agree to any waiver or amendment of or supplement to the terms of the Refund Guarantees other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

  (iii) agree to any waiver or amendment of or supplement to the terms of any Construction Risks Insurance Policy other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents;

 

7


  (iv) terminate, or allow to be terminated, any Refund Guarantee other than where an equivalent replacement Refund Guarantee is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination;

 

  (v) terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination; or

 

  (vi) assign, charge or dispose of the Contracts or any of the Assigned Rights (other than pursuant to the Other Vessel 2 Assignment of Contracts).

 

  (b) Notwithstanding anything to the contrary herein, the Company may make amendments, modifications or changes to any term or provision of the Construction Contract other than material amendments, modifications or changes to any term or provision of the Construction Contract that would change (i) the purpose of the Vessel or (ii) the Initial Construction Price in excess of [*] in the aggregate, in each case unless such amendment, modification or change is approved in advance by the Facility Agent and same could not reasonably be expected to be adverse to the interests of the Lenders or the Hermes Cover.

 

  (c) The Company acknowledges that at all times during the Security Period any payments under or in respect of the Construction Risks Insurance Policies shall be made in accordance with the Loss Payable Clause set out in the Annex to Part 3 (Form of Notice of Assignment to the Broker) of Schedule 1 (Forms of Notice of Assignment).

 

4.2 Performance of Obligations

The Company shall take, or cause to be taken, all steps reasonably required by the Collateral Agent to preserve or protect its interests and the interests of the Collateral Agent in the Contracts and shall diligently pursue any remedies available to it in respect of any breaches or claims of any party in connection with any of the Contracts which are necessary to preserve, protect and enforce the interests of the Collateral Agent in the Contracts.

 

5. CONTINUING SECURITY

 

5.1 Continuing and Independent Security

This Assignment shall constitute and be continuing security which shall not be released or discharged by any intermediate payment or settlement of all or any of the Secured Obligations, shall continue in full force and effect until the end of the Security Period and is in addition to and independent of, and shall not prejudice or merge with, any other security (or any right of set-off) which the Collateral Agent may have at any time for the Secured Obligations or any of them.

 

8


5.2 New Accounts

If the Collateral Agent receives notice of any security created or arising during the Security Period in respect of the Contracts or any of the Assigned Rights (other than pursuant to the Other Vessel 2 Assignment of Contracts), or following the occurrence and during the continuation of an Event of Default makes demand of the Parent or the applicable Borrower for payment of any or all of the Secured Obligations:

 

  (a) the Collateral Agent may open a new account or accounts in respect of any or all of the Secured Obligations (and if it does not do so it shall be treated as if it had done so at the time it received such notice or made such demand); and

 

  (b) thereafter any amounts paid by the Parent or the applicable Borrower to the Collateral Agent in respect of the Secured Obligations, or realised or recovered by the Collateral Agent under this Assignment, shall be credited (or be treated as having been credited) to a new account and not as having been applied in or towards payment of all or any of the Secured Obligations.

 

5.3 Avoidance of Payments

Where any release, discharge or other arrangement in respect of any Secured Obligation or any security the Collateral Agent may have for such Secured Obligation is given or made in reliance on any payment or other disposition which is avoided or must be repaid in an insolvency, liquidation or otherwise, and whether or not the Collateral Agent has conceded or compromised any claim that any such payment or other disposition will or should be avoided or repaid, this Assignment and the Security shall continue as if such release, discharge or other arrangement had not been given or made.

 

5.4 Immediate Recourse

Neither the Collateral Agent nor any other Secured Creditor shall be obliged before exercising any of the rights conferred on it or them by this Assignment or by law to seek to recover amounts due from the Parent or to exercise or enforce any other rights or security it or they may have or hold in respect of the Secured Obligations.

 

5.5 Waiver of Defences

Neither the obligations of the Company under this Assignment nor the Security and the rights, powers and remedies conferred on the Collateral Agent by this Assignment or by law, shall be discharged, impaired or otherwise affected by:

 

  (a) the winding-up, dissolution, administration or reorganisation of the Company or any other person or any change in the status, function, control or ownership of the Company or any such person;

 

  (b) any of the Secured Obligations or any other security held by the Collateral Agent in respect thereof being or becoming illegal, invalid, unenforceable or ineffective in any respect;

 

9


  (c) any time or other indulgence being granted or agreed to with the Company or any other person in respect of the Secured Obligations or any of them or in respect of any other security held by the Collateral Agent in respect thereof;

 

  (d) any amendment to, or any variation, waiver or release of, the Secured Obligations or any of them or any other security, guarantee or indemnity held by the Collateral Agent in respect thereof;

 

  (e) any total or partial failure to take or perfect any security proposed to be taken in respect of the Secured Obligations or any of them;

 

  (f) any total or partial failure to realise the value of, or any release, discharge, exchange or substitution of, any other security, guarantee or indemnity held by the Collateral Agent in respect of the Secured Obligations or any of them; or

 

  (g) any other act, event or omission which might operate to discharge, impair or otherwise affect the obligations of the Company under this Assignment, the Security or any of the rights, powers and remedies conferred on the Collateral Agent by this Assignment or by law.

 

5.6 Appropriation

Neither the Collateral Agent nor any other Secured Creditor shall be obliged to apply any sums held or received by it in respect of the Secured Obligations in or towards payment of the Secured Obligations and any such sum shall be held by or paid to the Collateral Agent for application pursuant to the terms of this Assignment, until the earlier of:

 

  (a) the date on which such monies are sufficient to satisfy the Secured Obligations in full and any money so applied could not be the subject of any clawback or similar circumstance; and

 

  (b) the date on which the Security has been enforced in full and all other remedies that the Collateral Agent may have under or in connection with the Credit Documents in all relevant jurisdictions have been exhausted.

 

6. REPRESENTATIONS AND WARRANTIES

The Company makes the representations and warranties set out in Clauses 6.1 (Entity Status) to 6.8 (Contract Terms). The Company acknowledges that the Collateral Agent has entered into this Assignment in reliance on those representations and warranties.

 

6.1 Entity Status

The Company (i) is a Person duly organized, constituted and validly existing (or the functional equivalent) under the laws of the jurisdiction of its formation, has the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted and (ii) is duly qualified and is authorized to do business and is in good standing (or the functional equivalent) in each jurisdiction where the ownership, leasing or operation of its property or the conduct of its business requires such qualifications except for failures to be so qualified or authorized or in good standing which, either individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.

 

10


6.2 Power and Authority

The Company has the power to enter into and perform this Assignment and the transactions contemplated hereby and has taken all necessary action to authorize the entry into and performance of this Assignment and such transactions. This Assignment constitutes legal, valid and binding obligations of the Company enforceable in accordance with its terms and in entering into this Assignment and borrowing the Loans, the Company is acting on its own account.

 

6.3 Form of Documentation

This Assignment is in proper legal form (under the laws of England, the Bahamas, Bermuda and each other jurisdiction where the Vessel is flagged or where the Company is domiciled) for the enforcement thereof under such laws. To ensure the legality, validity, enforceability or admissibility in evidence of this Assignment in England, the Bahamas and/or Bermuda it is not necessary that this Assignment be filed or recorded with any court or other authority in England, the Bahamas and Bermuda, except as have been made, or will be made, in accordance with Section 5, 6, 7 and 8 of the Credit Agreements, as applicable.

 

6.4 No Deductions or Withholdings

All amounts payable by the Company hereunder may be made free and clear of and without deduction or withholding for or on account of any Taxation in the Company’s jurisdiction.

 

6.5 No Filing or Stamp Taxes

It is not necessary that this Assignment be filed, recorded or enrolled with any court or other authority in England (or any other applicable jurisdiction) except as have been made or will be made in accordance with each Credit Agreement, or that any stamp, registration or similar tax be paid on or in relation to this Assignment save (i) to the extent that it may be regarded as constituting a charge over book debts and thus as registrable under the Companies Act 2006 and (ii) recording taxes which have been or will be paid as and to the extent due.

 

6.6 No Adverse Interests

Subject only to the Security and as otherwise contemplated under the Intercreditor Agreement, the Breakaway Two Credit Facility and each Credit Agreement, no person other than the Company has any legal or beneficial interest (or any right to claim any such interest) in the Assigned Rights or any part thereof and the Company has not received notice of any such claim.

 

6.7 No Disposals

Save as permitted by the Breakaway Two Credit Facility, each Credit Agreement, this Assignment or the Intercreditor Agreement, it has not transferred, mortgaged, charged or otherwise disposed of (or agreed to transfer, charge or otherwise dispose of), whether by way of security or otherwise, the benefit of all or any of the Assigned Rights.

 

11


6.8 Contract Terms

The terms of the Contracts do not restrict or otherwise limit its right to transfer, charge or assign any of the Assigned Rights pursuant to this Assignment.

 

6.9 Repetition

The representations and warranties set out in this Clause 6:

 

  (a) shall survive the execution of each Credit Document and each Borrowing under each Credit Agreement; and

 

  (b) are made on the date of this Assignment and are deemed to be repeated on each date during the Security Period with reference to the facts and circumstances then existing.

 

7. UNDERTAKINGS

 

7.1 Authorisations

The Company shall obtain, comply with the terms of and do all that is necessary to maintain in full force and effect all authorisations, approvals, licences and consents required in or by the laws of England and any other applicable jurisdiction to enable it lawfully to enter into and perform its obligations under this Assignment and to ensure the legality, validity, enforceability or admissibility in evidence in England and any other applicable jurisdiction of this Assignment.

 

7.2 No Action

The Company shall not take any action which would cause any of the representations made in Clause 6 (Representations and Warranties) to be untrue in any material respect at any time during the Security Period.

 

7.3 Notification of Misrepresentation

The Company shall notify the Collateral Agent of the occurrence of any event which results in or may reasonably be expected to result in any of the representations made in Clause 6 (Representations and Warranties) being untrue in any material respect when made or when deemed to be repeated.

 

7.4 Information

 

  (a) The Company shall provide the Collateral Agent with such reports and other information regarding the Contracts as the Collateral Agent may from time to time reasonably request.

 

  (b) Following the Initial Borrowing Date, the Company shall, as soon as reasonably practicable after an additional Refund Guarantee has been issued, deliver a supplement to Schedule 3 (Details of Refund Guarantees) to the Collateral Agent with updated information relating to such Refund Guarantee.

 

12


7.5 Delivery of Cash

Following the occurrence and during the continuation of an Event of Default, the Company shall promptly deliver all cash, proceeds, cheques, drafts, orders and other instruments for the payment of money received on account of any of the Contracts in the form received (properly endorsed, but without recourse, for collection where required) to the Collateral Agent and shall not commingle any such collections or proceeds with its other funds or property and shall, subject to the terms of the Intercreditor Agreement, hold the same upon an express trust for and on behalf of the Collateral Agent until delivered provided that, to the extent that the Intercreditor Agreement remains operative, the Company shall be relieved of its obligations under this clause 7.5 to the extent that it fulfils its obligations under clause 7.5 (Delivery of Cash) of the Other Vessel 2 Assignment of Contracts.

 

7.6 Delivery of Notices

The Company shall promptly deliver a copy of any notice or other correspondence received by it in connection with any of the Contracts to the Collateral Agent if such notice or correspondence has had or could reasonably be expected to have a material adverse effect on the value of such Contract.

 

8. FURTHER ASSURANCE

The Company shall from time to time and at its own expense give all such assurances and do all such things as the Collateral Agent may reasonably require or consider desirable to enable the Collateral Agent to perfect, preserve or protect the security created or intended to be created by this Assignment or to exercise any of the rights conferred on it by this Assignment or by law and to that intent the Company shall execute all such instruments, deeds and agreements and give all such notices and directions as the Collateral Agent may consider necessary.

 

9. ENFORCEMENT OF SECURITY

 

9.1 Security Enforceable

The Security shall become immediately enforceable if an Event of Default has occurred and is continuing.

 

9.2 Enforcement

Following the occurrence and during the continuation of an Event of Default, the Collateral Agent shall act in accordance with the terms of any instructions received under the Intercreditor Agreement for the purposes of exercising (or refraining from exercising) any of its rights to enforce all or any part of the Security, and in the absence of any such instructions, the Collateral Agent may in its absolute discretion enforce all or any part of the Security and exercise any of the rights conferred on it by this Assignment or by law at such times and in such manner as it thinks fit.

 

13


9.3 Power of Sale

Subject to the terms of the Intercreditor Agreement, following the occurrence and during the continuation of an Event of Default, the Collateral Agent may (without notice to the Company) sell or otherwise dispose of the Assigned Rights and shall be entitled to apply the proceeds of such sale or other disposal in paying the costs of such sale or disposal and thereafter in or towards the discharge of the Secured Obligations or otherwise as provided for in this Assignment.

 

9.4 Statutory Powers

For the purposes of all powers implied by statute the Secured Obligations shall be deemed to have become due and payable on the date of this Assignment.

 

9.5 Law of Property Act

Sections 93 and 103 of the Law of Property Act 1925 shall not apply to this Assignment or to any exercise by the Collateral Agent of its right to consolidate mortgages or its power of sale.

 

9.6 Realisation Accounts

If the Collateral Agent enforces the Security (whether by appointment of a Receiver or otherwise), the Collateral Agent may open and maintain with such financial institutions as it thinks fit one or more realisation accounts and pay any moneys it holds or receives under or pursuant to this Assignment into any such realisation account pending the application of such moneys pursuant to Clause 11 (Application of Proceeds).

 

10. RECEIVERS

 

10.1 Appointment of Receivers

At any time after the occurrence and during the continuation of an Event of Default, or if the Company requests it to do so, the Collateral Agent may by a written instrument and without notice to the Company appoint one or more persons as Receiver of all or any part of the Assigned Rights, each such person being entitled to act individually as well as jointly and being for all purposes the agent of the Company.

 

10.2 Powers of a Receiver

In addition to the powers conferred on the Collateral Agent by this Assignment, each Receiver appointed pursuant to Clause 10.1 (Appointment of Receivers) shall have in relation to the Assigned Rights in respect of which such Receiver was appointed all the powers conferred by the Law of Property Act 1925 (as extended by this Assignment) on a Receiver appointed under that Act.

 

14


11. APPLICATION OF PROCEEDS

 

11.1 Any moneys held or received by the Collateral Agent under this Assignment shall be applied by the Collateral Agent in or towards the discharge of the Secured Obligations in accordance with the provisions of the Intercreditor Agreement.

 

12. POWER OF ATTORNEY

 

12.1 Appointment

By way of security for the performance of its obligations under this Assignment, the Company hereby irrevocably appoints each of the Collateral Agent and its delegates and sub-delegates to be its attorney acting severally (or jointly with any other such attorney or attorneys) and on its behalf and in its name or otherwise to do any and every thing which the Company is obliged to do under the terms of this Assignment or which such attorney considers necessary or desirable in order to enable the Collateral Agent or such attorney to exercise the rights conferred on it by this Assignment or by law.

 

12.2 Ratification

The Company hereby ratifies and confirms and agrees to ratify and confirm whatever any attorney appointed under this Assignment shall do in its capacity as such.

 

13. RELEASE OF THE SECURITY

After the end of the Security Period or otherwise in accordance with Section 14.21 (Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer) of each Credit Agreement, the Collateral Agent shall, at the request and cost of the Company, execute all such documents and do all such other things as may be required to release the Security, in each case without recourse to or any representation or warranty by or from the Collateral Agent.

 

14. PAYMENTS

 

14.1 Grossing Up

All payments by the Company under this Assignment shall be made without any deductions and free and clear of, and without deduction for or on account of, tax except, in the latter case, to the extent that the Company is required by law to make payment subject to tax. If any tax or amounts in respect of tax must be deducted, or any other deductions must be made, from any amounts payable or paid by the Company, or paid or payable by the Collateral Agent to any Secured Creditor, under this Assignment, the Company shall pay such additional amounts as may be necessary to ensure that the relevant Secured Creditor receives a net amount equal to the full amount which it would have received had payment not been made subject to tax.

 

14.2 Payments without Set-off

Any payment made by the Company under this Assignment shall be made free and clear of and without any deduction for or on account of any set-off or counterclaim.

 

15


14.3 Manner of Payment

Each payment made by the Company under this Assignment shall be paid in the manner in which payments are to be made by the Company under each Credit Agreement.

 

15. WAIVERS AND REMEDIES

No failure by the Collateral Agent to exercise, nor any delay by the Collateral Agent in exercising, any right or remedy under this Assignment shall operate as a waiver thereof nor shall any single or partial exercise of any such right or remedy prevent any further or other exercise thereof or the exercise of any other such right or remedy.

 

16. ADDITIONAL PROVISIONS

 

16.1 Partial Invalidity

If at any time any provision of this Assignment is or becomes illegal, invalid or unenforceable in any respect or any of the Security is or becomes ineffective in any respect under the law of any jurisdiction, such illegality, invalidity, unenforceability or ineffectiveness shall not affect:

 

  (a) the legality, validity or enforceability of the remaining provisions of this Assignment or the effectiveness in any other respect of the Security under such law; or

 

  (b) the legality, validity or enforceability of such provision or the effectiveness of the Security under the law of any other jurisdiction.

 

16.2 Potentially Avoided Payments

If the Collateral Agent determines that an amount paid to a Secured Creditor under any Credit Document is being avoided or otherwise set aside on the liquidation or administration of the person by whom such amount was paid, then for the purposes of this Assignment, such amount shall be regarded as not having been paid.

 

16.3 Currency Conversion

If necessary to apply any sum held or received by the Collateral Agent in or towards payment of the Secured Obligations, the Collateral Agent may purchase an amount in another currency and the rate of exchange to be applied shall be that at which, at such time as it considers appropriate, the Collateral Agent is able to effect such purchase.

 

16.4 Currency Indemnity

If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from the Company hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Collateral Agent could purchase the specified currency with such other currency on the Business Day preceding that on which final judgment is given. The obligations of the Company in

 

16


respect of any sum due to the Collateral Agent hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by the Collateral Agent of any sum adjudged to be so due in such other currency the Collateral Agent may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to the Collateral Agent in the specified currency, the Company agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify the Collateral Agent against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to the Collateral Agent in the specified currency, the Collateral Agent agrees to remit such excess to the Company.

 

16.5 Rights Cumulative

The rights and remedies provided by this Assignment are cumulative and not exclusive of any rights or remedies provided by law.

 

16.6 Collateral Agent in Possession

The Collateral Agent shall not by reason of its taking any action permitted by this Assignment or its taking possession of all or any of the Assigned Rights be liable to account as mortgagee in possession or, other than as expressly stated in each Security Trust Deed, be liable for any loss on realisation or for any default or omission for which a mortgagee in possession might be liable.

 

17. ASSIGNMENT

 

17.1 The Company’s Rights

The rights of the Company under this Assignment are not assignable or transferable and the Company agrees that it will not purport to assign all or any such rights except as provided under the Breakaway Two Credit Facility and the Credit Agreements.

 

17.2 The Collateral Agent’s Rights

 

  (a) The rights of the Collateral Agent under this Assignment are assignable in whole or in part without the consent of the Company except as provided under the Credit Agreements.

 

  (b) The Collateral Agent may not resign except in accordance with the terms of the Security Trust Deeds.

 

18. NOTICES

 

18.1 Communications in Writing

Each communication to be made under this Assignment shall be made in writing and, unless otherwise stated, may be made by fax, electronic mail or letter.

 

17


18.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 18.1 (Communications in writing) the contact details of each of the parties are as follows:

 

  (a) to the Collateral Agent:

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

  (b) to the Company:

7665 Corporation Center Drive

Miami, Florida 33126

USA

Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

  hflanders@ncl.com

with copies to:

Apollo Management, L.P. 9

West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com

or to such other address and/or number as is notified in writing by a party to the other parties under this Assignment.

 

18.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to

 

18


the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified in Clause 18.2 (Contact Details); provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Collateral Agent and the Company agree that they (x) shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and (y) shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Collateral Agent shall not be effective until received by the Collateral Agent, or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Company to the Collateral Agent, only if it is addressed in such a manner as the Collateral Agent shall specify for this purpose.

 

19. GOVERNING LAW

 

  (a) This Assignment and any non-contractual obligations arising out of or in connection with it shall be governed by and construed in accordance with English law.

 

  (b) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Assignment (including a dispute relating to the existence, validity or termination of this Assignment or any non-contractual obligation arising out of or in connection with this Assignment ) (a “Dispute”). The parties hereto agree that the courts of England are the most appropriate and convenient courts to settle disputes and accordingly no party hereto will argue to the contrary. This Clause 19 is for the benefit of the Collateral Agent on behalf of the Secured Creditors. As a result, it shall not be prevented from taking proceedings relating to a dispute in any other courts with jurisdiction. To the extent allowed by law, the Collateral Agent may take concurrent proceedings in any number of jurisdictions.

 

  (c) Without prejudice to any other mode of service allowed under any relevant law, the Company: (i) irrevocably appoints EC3 Services Limited at 51 Eastcheap, London, England, EC3M 1JP as its agent for service of process in relation to any proceedings before the English courts in connection with any credit document and (ii) agrees that failure by an agent for service of process to notify the relevant credit party of the process will not invalidate the proceedings concerned. If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Company must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the Collateral Agent. Failing this, the Collateral Agent may appoint another agent for this purpose.

 

19


  (d) Each party to this Assignment expressly agrees and consents to the provisions of this Clause 19.

 

20. COUNTERPARTS AND EFFECTIVENESS

 

20.1 Counterparts

This Assignment may be executed in counterparts and such counterparts taken together shall constitute one and the same instrument.

 

20.2 Effectiveness

This Assignment shall take effect and be delivered as a deed on the date on which it is stated to be made.

IN WITNESS WHEREOF this Assignment has been executed as a deed by the Company and the Collateral Agent.

 

20


SCHEDULE 1

FORMS OF NOTICE OF ASSIGNMENT

Part 1

FORM OF NOTICE OF ASSIGNMENT TO THE SHIPBUILDER

 

To:  

Meyer Werft GmbH

Industriegebiet Süd

D-26871 Papenburg

Germany

Cc:  

KfW IPEX-Bank GmbH as Collateral Agent

 

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

Date:   []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway Two, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the construction contract dated 24 September 2010 between the Company and you, as shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the passenger cruise ship (the “Ship”) with provisional hull number 692 (the “Construction Contract”).

With effect from your receipt of this notice we hereby give you notice that:

 

(a) subject to paragraph (b), all refunds, payments or damages payable to the Company as a consequence of the repudiation or termination of the Construction Contraction should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(b)

following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, KfW IPEX-Bank

 

21


 

GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)), written notice of which Event of Default has been delivered to you by the Collateral Agent, all payments to be made to the Company under or arising from the Construction Contract should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(c) following an Event of Default, all remedies of the Company provided for in the Construction Contract or available at law or in equity shall be exercisable by the Collateral Agent;

 

(d) following an Event of Default, all rights of the Company to compel performance of the Construction Contract shall be exercisable by the Collateral Agent;

 

(e) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Contract are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(f) the Company may make amendments, modifications or changes to any term or provision of the Construction Contract other than material amendments, modifications or changes to any term or provision of the Construction Contract that would change (i) the purpose of the Vessel or (ii) the initial construction price of the Vessel (i.e., €615,000,000) in excess of [*] in the aggregate, in each case unless such amendment, modification or change is approved in advance by each of the Facility Agents (as defined in each Credit Agreement) and same could not reasonably be expected to be adverse to the interests of the Lenders or the Hermes Cover (as referenced in the Assignment);

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Contract (including without limitation, the right to superintend the construction of the Ship and to propose and agree modifications (as referred to in the Construction Contract) and to accept or reject the Ship and to take and accept delivery of and title to the Ship) unless and until the Collateral Agent notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Contract. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Contract without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Construction Contract and the Collateral Agent is under no obligation of any kind under the Construction Contract nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

 

22


You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Contract as it may from time to time reasonably request and to send copies of any notices issued by you under the Construction Contract which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Contract or the Ship, to the Collateral Agent as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

Yours faithfully

 

 

For and on behalf of
BREAKAWAY TWO, LTD.

 

23


Part 2

FORM OF NOTICE OF ASSIGNMENT TO THE REFUND GUARANTOR

 

To:   [Refund Guarantor]
Cc:  

KfW IPEX-Bank GmbH as Collateral Agent

 

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

Date:   []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between BREAKAWAY TWO, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the refund guarantee dated [] and issued by you as refund guarantor in favour of the Company pursuant to which you guarantee certain refund obligations of Meyer Werft GmbH, as shipbuilder under the Construction Contract (as defined in the Assignment) (the “Refund Guarantee”), including all monies which may be payable under or in respect of the Refund Guarantee.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Refund Guarantee should be made to the Collateral Agent or to its order as it may specify in writing from time to time;

 

(b)

following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit

 

24


 

Agreements”)), written notice of which Event of Default has been delivered to you by the Collateral Agent, all remedies of the Company provided for in the Refund Guarantee or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Refund Guarantee shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Refund Guarantee are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(e) the Company has agreed not to agree to any waiver or amendment of or supplement to the terms of the Refund Guarantee other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Refund Guarantee other than where a replacement Refund Guarantee is issued to the Company which meets the Company’s requirements under the Construction Contract on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each Credit Agreement) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Refund Guarantee except to the extent that the Collateral Agent notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) (including, without limitation, making a demand under the Refund Guarantee) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Refund Guarantee. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Refund Guarantee without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Refund Guarantee and the Collateral Agent is under no obligation of any kind under the Refund Guarantee nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Refund Guarantee as it may from time to time reasonably request and to send copies of all notices issued by you under the Refund Guarantee which have had or would reasonably be expected to have a material adverse effect on the value of the Refund Guarantee, to the Collateral Agent as well as to the Company.

 

25


This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

Yours faithfully

 

 

For and on behalf of
BREAKAWAY TWO, LTD.

 

26


Part 3

FORM OF NOTICE OF ASSIGNMENT TO THE BROKER

(for attachment by way of endorsement to the Policy)

 

To: [Broker]

 

Cc: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Date: []

Dear Sir/Madam

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between BREAKAWAY TWO, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of construction risks insurance policy dated [] issued for the benefit of Meyer Werft GmbH (the “Yard”) and the Company in connection with the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.692 to be constructed by the Yard (the “Construction Risks Insurance Policy”), including all monies which may be payable to the Company under or in respect of the Construction Risks Insurance Policy.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Construction Risks Insurance Policy should be made in accordance with the terms of the Loss Payable Clause set out in the Annex 1 (Loss Payable Clause) to this Notice;

 

(b) following an Event of Default, all remedies of the Company provided for in the Construction Risks Insurance Policy or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Construction Risks Insurance Policy shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Risks Insurance Policy are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

27


(e) the Company has agreed that no waiver or amendment of or supplement to the terms of the Construction Risks Insurance Policy may be made other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)).

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is issued in favour of the Yard and the Company on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each of the Credit Agreements) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Risks Insurance Policy except that to the extent that the Collateral Agent notifies you in writing that an Event of Default has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Risks Insurance Policy. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Risks Insurance Policy without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations (if any) under the Construction Risks Insurance Policy and the Collateral Agent is under no obligation of any kind under the Construction Risks Insurance Policy nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Risks Insurance Policy as it may from time to time reasonably request and to send copies of

 

28


all notices issued by you under the Construction Risks Insurance Policy which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Risks Insurance Policy, to the Collateral Agent as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

Yours faithfully

 

 

For and on behalf of
BREAKAWAY TWO, LTD.

 

29


ANNEX 1

LOSS PAYABLE CLAUSE

It is noted that by a first legal assignment in writing dated 20[] BREAKAWAY TWO, LTD., the buyer (“Buyer”) of the vessel presently under construction by Meyer Werft GmBH, Papenburg Germany (“Builder”) with hull number [] has assigned to KFW IPEX-BANK GMBH of [] (“Assignee”) all the Buyer’s interests in any claims proceeds in this policy and its benefits therein including all such claims of whatsoever nature as the Buyer may have hereunder.

All sums payable to the Buyer under this policy shall be paid to the Buyer unless and until underwriters have been otherwise instructed by notice in writing from the Assignee following the occurrence and continuation of an Event of Default, as defined in the Credit Agreement dated as of [] and made among and between the Buyer, NCL Corporation Ltd., as the Buyer’s parent, the Assignee, the lenders from time to time party thereto and the other parties from time to time party thereto.

All sums payable to the Builder under this policy shall be payable to the Builder, subject to any notice of assignment of the Builder’s interests in this policy.

 

30


SCHEDULE 2

FORMS OF ACKNOWLEDGMENT OF ASSIGNMENT

Part 1

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE SHIPBUILDER

[To be printed only on copy of the Notice of Assignment given]

 

To: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Date: []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Construction Contract) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Construction Contract and that we will comply with the terms of the Notice.

We also confirm that the Construction Contract is in full force and effect in accordance with its terms. We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable) with respect to the Construction Contract.

Yours faithfully

 

For and on behalf of

Meyer Werft GmbH

as Shipbuilder

By:
Date:

 

31


Part 2

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE REFUND

GUARANTOR

[To be printed only on copy of the Notice of Assignment given]

 

To: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Date: []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Refund Guarantee) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Refund Guarantee and that we will comply with the terms of the Notice.

We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable).

Yours faithfully

 

For and on behalf of

[the Refund Guarantor]

as Refund Guarantor

By:
Date:

 

32


Part 3

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT FROM THE BROKER

[To be printed only on copy of the Notice of Assignment given]

 

To: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Date: []

HULL NO. S. 692 (the “Vessel”)

BREAKAWAY TWO, LTD. (the “Company”)

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (i) (other than in respect of senior liens held by the Collateral Agent as security trustee on behalf of certain “ECF creditors” in respect of the Construction Risks Insurance Policy) we have not received notice of any other assignments or charges of or over any of the Company’s rights, title, interests and benefits in, to or in respect of the Construction Risks Insurance Policy, (ii) we will comply with the terms of the Notice and (iii) we have effected insurances for the benefit of Meyer Werft GmbH (the “Yard”) and the Company as set out in Annex 1 attached.

Pursuant to instructions received from the Yard and/or its authorised managers or agents and in consideration of you and the Company approving us as the appointed brokers in connection with the insurances covered by this letter, we hereby undertake:

 

1. to hold the insurance slips or contracts, the policies when issued, and any renewals of such policies or any policies substituted therefor with your consent as may be arranged through ourselves and the benefit of the insurances thereunder to your order in accordance with the terms of the Loss Payable Clause set out in Annex 2; and

 

2. to arrange for the said Loss Payable Clause to be included on the policies when issued; and

 

3. to have endorsed on each and every policy as and when the same is issued a Notice of Assignment to Underwriters in the form of Annex 3 hereto dated and signed by the Company and acknowledged by underwriters in accordance with market practice; and

 

33


4. to advise you promptly if we cease to be the appointed brokers in connection with the insurances covered by this letter or in the event of any material changes of which we are aware affecting such insurances; and

 

5. following a written application received from you not later than one month before expiry of these insurances to notify you within fourteen days of the receipt of such application in the event of our not having received notice of renewal instructions from the Yard and/or its authorised managers or agents, and in the event of our receiving instructions to renew to advise you promptly of the details thereof; and

 

6. to forward to you promptly any notices of cancellation that we receive from underwriters; and

 

7. following a written application from you to advise you promptly of the premium payment situation where such premium is paid or payable through our intermediary; and

 

8. not to challenge the effectiveness of the assignment to the Collateral Agent of the insurances constituted by this policy; and

 

9. not to revoke, modify or change the terms of the Loss Payable Clause or the undertakings made herein without the written consent of the Collateral Agent.

If and where we are responsible for the payment of premium to underwriters, our above undertakings are given subject to our lien on the policies for premiums and subject to our right of cancellation on default in payment of such premiums but we undertake not to exercise such rights of cancellation without giving you ten days notice in writing either by letter or electronically transmitted message and a reasonable opportunity for you to pay any premiums outstanding.

It is understood and agreed that the operation of any automatic termination of cover, cancellation or amendment provisions contained in the policy conditions shall override any undertakings given by us as brokers.

Notwithstanding the terms of the said Loss Payable Clause and the Notice, unless and until we receive written notice from you to the contrary, we shall be empowered to arrange for a collision and/or salvage guarantee to be given in the event of bail being required in order to prevent the arrest of the Vessel or to secure the release of the Vessel from arrest following a casualty. Where a guarantee has been given as aforesaid and the guarantor has paid any sum under the guarantee in respect of such claim, there shall be payable directly to the guarantor out of the proceeds of the said policies a sum equal to the sum so paid.

This undertaking shall be governed by and construed in accordance with English law and any disputes arising out of or in any way connected with this undertaking shall be submitted to the exclusive jurisdiction of the English courts.

This undertaking is subject to all claims and returns of premiums being collected through us as brokers.

 

34


Yours faithfully

 

For and on behalf of

[the Broker]

as [Broker]

By:
Date:

 

35


ANNEX 1

DETAILS OF INSURANCES

 

36


ANNEX 2

LOSS PAYABLE CLAUSE

It is noted that by a first legal assignment in writing dated 20[] BREAKAWAY TWO, LTD., the buyer (“Buyer”) of the vessel presently under construction by Meyer Werft GmBH, Papenburg Germany (“Builder”) with hull number [] has assigned to KFW IPEX-BANK GMBH of [] (“Assignee”) all the Buyer’s interests in any claims proceeds in this policy and its benefits therein including all such claims of whatsoever nature as the Buyer may have hereunder.

All sums payable to the Buyer under this policy shall be paid to the Buyer unless and until underwriters have been otherwise instructed by notice in writing from the Assignee following the occurrence and continuation of an Event of Default, as defined in the Credit Agreement dated as of [] and made among and between the Buyer, NCL Corporation Ltd., as the Buyer’s parent, the Assignee, the lenders from time to time party thereto and the other parties from time to time party thereto.

All sums payable to the Builder under this policy shall be payable to the Builder, subject to any notice of assignment of the Builder’s interests in this policy.

 

37


ANNEX 3

NOTICE OF ASSIGNMENT TO UNDERWRITERS

(for attachment by way of endorsement to the Policy)

 

To: [Underwriter]

 

Cc: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Date: []

Dear Sir/Madam

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway Two, Ltd. (the “Company”) and KfW IPEX-Bank GmbH as Collateral Agent (the “Collateral Agent”), the Company has assigned to the Collateral Agent a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of construction risks insurance policy dated [] issued for the benefit of Meyer Werft GmbH (the “Yard”) and the Company in connection with the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.692 to be constructed by the Yard (the “Construction Risks Insurance Policy”), including all monies which may be payable to the Company under or in respect of the Construction Risks Insurance Policy.

With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Construction Risks Insurance Policy should be made in accordance with the terms of the Loss Payable Clause set out in the Annex 1 (Loss Payable Clause) to this Notice;

 

(b) following an Event of Default, all remedies of the Company provided for in the Construction Risks Insurance Policy or available at law or in equity shall be exercisable by the Collateral Agent;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Construction Risks Insurance Policy shall be exercisable by the Collateral Agent;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Construction Risks Insurance Policy are assigned to the Collateral Agent and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

38


(e) the Company has agreed that no waiver or amendment of or supplement to the terms of the Construction Risks Insurance Policy may be made other than any waiver, amendment or supplement (A) of a technical nature or (B) agreed to be necessary by the insured parties under the Construction Risks Insurance Policy to reflect the prevailing circumstances, provided that in each case, the prior written consent of the Collateral Agent shall be required for any such amendment, waiver or supplement that (x) is materially adverse to the interests of the Collateral Agent in the Security or the Assigned Rights or (y) adversely affects the ability of the Company to perform its obligations under the Credit Documents (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, the NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, the NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)).

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Construction Risks Insurance Policy other than where an equivalent replacement Construction Risks Insurance Policy is issued in favour of the Yard and the Company on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each of the Credit Agreements) to such termination;

 

(g) the Collateral Agent has agreed that the Company may exercise all of its rights and powers under and in respect of the Construction Risks Insurance Policy except that to the extent that the Collateral Agent notifies you in writing that an Event of Default has occurred. Upon giving such notice, the Collateral Agent may exercise such rights and powers (to the exclusion of the Company) to the extent stated in that notice and without you being under any duty or obligation to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h) the Company has irrevocably appointed the Collateral Agent to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other things) things which the Company could do in relation to the Construction Risks Insurance Policy. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Collateral Agent from time to time in connection with the Construction Risks Insurance Policy without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations (if any) under the Construction Risks Insurance Policy and the Collateral Agent is under no obligation of any kind under the Construction Risks Insurance Policy nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Collateral Agent with such information relating to the Construction Risks Insurance Policy as it may from time to time reasonably request and to send copies of all notices issued by you under the Construction Risks Insurance Policy which have had or would reasonably be expected to have a material adverse effect on the value of the Construction Risks Insurance Policy, to the Collateral Agent as well as to the Company.

 

39


This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Collateral Agent).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Collateral Agent.

Yours faithfully

 

 

For and on behalf of
BREAKAWAY TWO, LTD.

 

40


SCHEDULE 3

DETAILS OF REFUND GUARANTEES

 

[Name of Issuer]   [Date of Refund Guarantee]

 

41


SIGNATORIES

 

Signed as a deed on behalf of BREAKAWAY TWO, LTD, a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company   
  

 

   Authorised [signatory] [signatories]
Signed as a deed on behalf of KFW IPEX-BANK GMBH, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company   
  

 

   Authorised [signatory] [signatories]

 

42


EXHIBIT J

FORM OF SOLVENCY CERTIFICATE

[                    ], 2010

This Solvency Certificate is delivered pursuant to Section 6.10 of the Credit Agreement, dated as of [                    ], 2010, among NCL Corporation Ltd., a Bermuda company (the “Parent”), Pride of Hawaii, LLC, a Delaware limited liability company (the “Borrower”), the Lenders from time to time party thereto, KfW IPEX-Bank GmbH, as Facility Agent and as Collateral Agent under the Security Documents, Nordea Bank Norge ASA, as Documentation Agent, Commerzbank Aktiengesellschaft, as Hermes Agent for the Lenders, and the other parties thereto (as the same may be amended, restated, novated or otherwise modified from time to time, the “Credit Agreement”). Capitalized terms used herein and not otherwise defined herein shall have the meanings assigned to such terms in the Credit Agreement.

The undersigned, a senior financial officer of the Parent, hereby certifies to the Facility Agent and each of the Lenders, solely in such capacity and on behalf of the Parent as follows:

1. I am a senior financial officer of the Parent. I am familiar with the Transaction, and have reviewed the financial statements referred to in Section 8.05 of the Credit Agreement and other such documents and made such investigations as I have deemed relevant for the purposes of this Solvency Certificate.

2. On and as of the date hereof, immediately after giving effect to the transactions under the Credit Agreement (including, without limitation, the incurrence of all the financing contemplated with respect thereto and to the purchase of each New Vessel), the Parent and its Subsidiaries taken as a whole (i) are not insolvent and will not be rendered insolvent by the Indebtedness incurred in connection with the transactions under the Credit Agreement (including, without limitation, the incurrence of all the financing contemplated with respect thereto and to the purchase of the Vessel); (ii) will not have unreasonably small capital with which to conduct the business in which they are respectively engaged as such businesses are now conducted and are proposed to be conducted following the Borrowing Date to occur on or about the date hereof; and (iii) have not incurred debts beyond their ability pay such debts and liabilities, direct, subordinated, contingent or otherwise, as such debts and liabilities become absolute, matured, or otherwise become payable.

This Solvency Certificate is being delivered by the undersigned officer only in his capacity as a senior financial officer of the Parent and not individually and the undersigned shall have no personal liability to the Agents or the Lenders with respect thereto.


IN WITNESS WHEREOF, the undersigned has executed this Solvency Certificate on the date first set forth above.

 

NCL CORPORATION LTD.
  By:  

 

    Title:
     


EXHIBIT K

FORM OF ASSIGNMENT AGREEMENT

 

To: [                    ] as Facility Agent and [                    ], [                    ] as Hermes Agent, [                    ] as Parent, for and on behalf of the Borrower

 

From: [the Existing Lender] (the “Existing Lender”) and [the New Lender] (the “New Lender”)

Dated:

Pride of Hawaii, LLC –Credit Agreement

Total Commitment - €126,075,000

dated [                    ]

(the “Credit Agreement”)

 

1. We refer to the Credit Agreement and to the ECF Intercreditor Agreements (as defined in the Credit Agreement). This agreement (the “Agreement”) shall take effect as an Assignment Agreement for the purpose of the Credit Agreement. Terms defined in the Credit Agreement have the same meaning in this Agreement unless given a different meaning in this Agreement.

 

2. We refer to section 13.07 (Procedure and Conditions for Assignment) of the Credit Agreement:

 

  (a) The Existing Lender assigns absolutely to the New Lender all the rights of the Existing Lender under the Credit Agreement, the other Credit Documents and in respect of the Collateral which correspond to that portion of the Existing Lender’s Commitments and participations in Borrowings under the Credit Agreement as specified in the Schedule attached hereto.

 

  (b) The Existing Lender is released from all the obligations of the Existing Lender which correspond to that portion of the Existing Lender’s Commitments and participations in Borrowings under the Credit Agreement specified in the Schedule attached hereto.

 

  (c) The New Lender becomes a Party as a Lender and is bound by obligations equivalent to those from which the Existing Lender is released under paragraph (b) above.

 

3. The proposed date of the assignment is [                    ].

 

4. On the date of the assignment the New Lender becomes:

 

  (a) Party to the relevant Credit Documents under the Credit Agreement (other than the ECF Intercreditor Agreements and the Security Trust Deed) as a Lender; and

 

  (b) Party to each ECF Intercreditor Agreement as a Jade Lender; and

 

  (c) Party to the Security Trust Deed as a Secured Creditor.


EXHIBIT K    2

 

5. The Notice Office and address, fax number and attention details for notices of the New Lender for the purposes of Section 14.03 (Notices) are set out in the Schedule.

 

6. The New Lender expressly acknowledges the limitations on the Existing Lender’s obligations set out in paragraph (c) of Section 13.04 (Limitation of responsibility of Existing Lenders).

 

7. We refer to Clause 9.2 (Change to the Parties) of each ECF Intercreditor Agreement and Clause 8.2 (Changes of Secured Creditor) in the Security Trust Deed.

 

  (a) In consideration of the New Lender being accepted as a Jade Lender for the purposes of each ECF Intercreditor Agreement (and as defined therein), the New Lender confirms that, as from the date of assignment, it intends to be party to each ECF Intercreditor Agreement as a Jade Lender, and undertakes to perform all the obligations expressed in each ECF Intercreditor Agreement to be assumed by a Jade Lender and agrees that it shall be bound by all the provisions of each ECF Intercreditor Agreement, as if it had been an original party to such ECF Intercreditor Agreement.

 

  (b) In consideration of the New Lender being accepted as a Secured Creditor for the purposes of the Security Trust Deed (and as defined therein), the New Lender confirms that, as from the date of the assignment, it intends to be party to the Security Trust Deed as a Secured Creditor, and undertakes to perform all the obligations expressed in the Security Trust Deed to be assumed by a Secured Creditor and agrees that it shall be bound by all the provisions of the Security Trust Deed, as if it had been an original party to the Security Trust Deed.

 

8. This Agreement acts as notice to the Facility Agent (on behalf of each Lender Creditor) and, upon delivery in accordance with section 13.08 (Copy of Transfer Certificate or Assignment Agreement to Parent), to the Parent (on behalf of the Borrower) of the assignment referred to in this Agreement.

 

9. We refer to Section 13.01(c) (Assignments and Transfers by the Lenders) of the Credit Agreement. Each New Lender, by executing this Assignment, confirms, for the avoidance of doubt, that the Facility Agent has authority to execute on its behalf any amendment or waiver that has been approved by or on behalf of the Required Lenders in accordance with the Credit Agreement on or prior to the date on which the assignment becomes effective in accordance the Credit Agreement and that it is bound by that decision to the same extent as the Existing Lender would have been had it remained a Lender.

 

10. This Agreement may be executed in any number of counterparts and this has the same effect as if the signatures on the counterparts were on a single copy of this Agreement.

 

11. This Agreement and any non-contractual obligations arising out of or in connection with it are governed by English law.


EXHIBIT K    3

 

12. This Agreement takes effect as a deed.

 

13. This Agreement has been entered into on the date stated at the beginning of this Agreement.

 

Note: The execution of this Assignment Agreement may not assign a proportionate share of the Existing Lender's interest in the Collateral in all jurisdictions. It is the responsibility of the New Lender to ascertain whether any other documents or other formalities are required to perfect an assignment of such a share in the Existing Lender's Collateral in any jurisdiction and, if so, to arrange for execution of those documents and completion of those formalities.


EXHIBIT K    4

THE SCHEDULE

Commitment/rights and obligations to be transferred by assignment, release and accession

[insert relevant details]

[Notice Office address, fax number and attention details for notices and account details for payments]


EXHIBIT K

SIGNATORIES

[Existing Lender]

 

Executed as a deed by [name of Existing Lender],

acting by [name of director]:

  
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director

[New Lender] Executed as a deed by [name of New Lender],

acting by [name of director]:

  
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director

This Agreement is accepted as an Assignment Agreement for the purposes of the Credit Agreement by the Facility Agent and by the Hermes Agent, and the date of the assignment is confirmed as [ ].


EXHIBIT K    6

Signature of this Agreement by the Facility Agent constitutes confirmation by the Facility Agent of receipt of notice of the assignment referred to in this Agreement, which notice the Facility Agent receives on behalf of each Lender Creditor.

[Facility Agent]

 

Executed as a deed by [Facility Agent], acting by

[name of director]:

  
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director
[Hermes Agent]   

Executed as a deed by [Hermes Agent], acting by

[name of director]:

  
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


EXHIBIT K    7

[NCL Corporation Ltd.]1

 

[Signed as a deed by [NCL Corporation Ltd.], a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company.  
 

 

  Signature(s)
  Authorised [signatory] [signatories]]

 

1

To be signed by the Company only if the assignment is pursuant to section 13.01(a)(ii) of the Credit Agreement.


EXHIBIT L

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION.

FORM OF COMPLIANCE CERTIFICATE

This Compliance Certificate (this “Certificate”) is delivered to you on behalf of the Company (as hereinafter defined) pursuant to Section 9.01(f) of the Credit Agreement, dated as of [                    ], 2010 (as amended, supplemented, restated, novated or modified from time to time, the “Credit Agreement”), among NCL Corporation Ltd., a Bermuda company (the “Company”) as Parent, Pride of Hawaii, LLC, a Delaware limited liability company (the “Borrower”), the Lenders from time to time party thereto, Nordea Bank Norge ASA, as Documentation Agent, KfW IPEX-Bank GmbH as Facility Agent and Collateral Agent, Commerzbank Aktiengesellschaft, as Hermes Agent, and the other parties thereto. Capitalized terms defined in the Credit Agreement and not otherwise defined herein are used herein as therein defined.

1. I am a duly elected, qualified and acting senior financial officer of the Company.

2. I have reviewed and am familiar with the contents of this Certificate. I am providing this Certificate solely in my capacity as an officer of the Company. The matters set forth herein are true to the best of my knowledge after diligent inquiry.

3. I have reviewed the terms of the Credit Agreement and the other Credit Documents and have made or caused to be made under my supervision, a review in reasonable detail of the transactions and financial condition of the Company during the accounting period covered by the financial statements true and correct copies of which are attached hereto as ANNEX 1 (the “Financial Statements”). The Financial Statements have been prepared in accordance with the requirements of the Credit Agreement.

4. Attached hereto as ANNEX 2 are the computations showing (in reasonable detail) compliance with the covenants specified therein. All such computations are true and correct.

[5. On the date hereof, no Default or Event of Default has occurred and is continuing.1

 

1 If any Default or Event of Default exists, include a description thereof, specifying the nature and extent thereof (in reasonable detail).


Exhibit L

Page 2

 

IN WITNESS WHEREOF, I have executed this Certificate on behalf of the Company this      day of         .

 

NCL CORPORATION LTD.
By  

 

  Name:
  Title:


ANNEX 1 to

Compliance Certificate

CONSOLIDATED FINANCIAL STATEMENTS


ANNEX 2 to

Compliance Certificate

COMPLIANCE WORKSHEET

The calculations described herein is as of                          ,          (the “Computation Date”) and pertains to the period from                          ,          to                          ,          (the “Test Period”).

Part A. Free Liquidity

 

1.    Aggregate Cash Balance on the Computation Date.    $                       
2.    Commitments under the Credit Agreement or other amounts available on the Computation Date for drawing under the revolving or other credit facilities of the NCLC Group, which remain undrawn, could be drawn for general working capital purposes or other general corporate purposes and would not, if drawn, be repayable within six months.    $                       
3.    Item 1 plus Item 2    $                       
4.    Is Item 3 equal to or greater than [*] pursuant to Section 10.06 of the Credit Agreement?    YES/NO   

Part B. Total Net Funded Debt to Total Capitalization

 

1.    Indebtedness for Borrowed Money of the NCLC Group on the Computation Date.    $                       
2.    The amount of any Indebtedness for Borrowed Money of any person which is not a member of the NCLC Group but which is guaranteed by a member of the NCLC Group on the Computation Date.    $                       
3.    Cash Balance on the Computation Date.    $                       
4.    Item 1 plus Item 2 minus Item 32    $                       
5.    Total Capitalization on the Computation Date    $                       
6.    Total Net Funded Debt to Total Capitalization Ratio (Item 4:Item 5) on the Computation Date.                :1.00   
7.    The maximum Total Net Funded Debt to Total Capitalization Ratio pursuant to Section 10.07 of the Credit Agreement:    [*]   

 

2 Any Commitments under the Credit Agreement and other amounts available for drawing under other revolving or other credit facilities of the NCLC Group which remain undrawn shall not be counted as cash or indebtedness for the purposes of this calculation.


Exhibit L

Page 2

 

Part C. Collateral Maintenance

 

1.    Outstanding principal amount of Loans on the Computation Date.    $                       
2.    Outstanding the principal amount of loans under the Existing Jewel Facility on the Computation Date.    $                       
3.    Item 1 plus Item 2.    $                       
4.    Vessel Value.    $                       
5.    Minimum Vessel Value for the Vessel permitted pursuant to Section 10.08 of the Credit Agreement.    Item 1 multiplied by [*]   
6.    Is Item 4 equal to or greater than Item 5 pursuant to Section 10.08 of the Credit Agreement?    YES/NO   

Part D. Consolidated EBITDA to Consolidated Debt Service

 

1.    Consolidated Net Income from the Parent’s operations for the Test Period.    $                       
2.    Aggregate amounts deducted in determining Consolidated Net Income for the Test Period in respect of gains and losses from the sale of assets or reserves relating thereto, Consolidated Interest Expense, depreciation and amortization, impairment charges and any other non-cash charges and deferred income tax expense for the Test Period.    $                       
3.    Item 1 plus Item 2    $                       
4.    Consolidated Debt Service for the Test Period.    $                       
5.    Consolidated EBITDA to Consolidated Debt Service Ratio (Item 3:Item 4) on the Computation Date.                :1.00   
6.    The minimum Consolidated EBITDA to Consolidated Debt Service Ratio pursuant to Section 10.09 of the Credit Agreement:    [*]   


Exhibit L

Page 3

 

7.    Aggregate Cash Balance on the Computation Date.    $                       
8.    Commitments under the Credit Agreement or other amounts available on the Computation Date for drawing under the revolving or other credit facilities of the NCLC Group, which remain undrawn, could be drawn for general working capital purposes or other general corporate purposes and would not, if drawn, be repayable within six months.    $                       
9.    Item 7 plus Item 8    $                       
10.    Is (x) Item 9 for the NCLC Group equal to or greater than [*] at all times during the period of four consecutive fiscal quarters ending at the end of the Test Period or (y) Item 5 greater than or equal to Item 6 pursuant to Section 10.09 of the Credit Agreement?    YES/NO   


LOGO

 

 

 

EXHIBIT M-1

Dated [] 2010

FORM OF INTERCREDITOR DEED

between

KFW IPEX-BANK GMBH

as ECF Facility Agent, the Jade Facility Agent and the Jewel Facility Agent

The ECF Lenders

The Jade Lenders

The Jewel Lenders

BREAKAWAY ONE, LTD.

as Debtor

KFW IPEX-BANK GMBH

acting as Collateral Agent

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

acting as Delegate Collateral Agent

and others

 

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


EXHIBIT M-1

TABLE OF CONTENTS

 

          Page  

1.

   DEFINITIONS AND INTERPRETATION      2   

2.

   PRIORITY AND RANKING      7   

3.

   NOTIFICATIONS      8   

4.

   RESTRICTIONS ON ENFORCEMENT      8   

5.

   MANNER OF ENFORCEMENT      9   

6.

   TURNOVER OF RECEIPTS      11   

7.

   APPLICATION OF PROCEEDS      11   

8.

   PRESERVATION      12   

9.

   CHANGES TO THE PARTIES      14   

10.

   POWER OF ATTORNEY      15   

11.

   AMENDMENTS      15   

12.

   THIRD PARTY RIGHTS      15   

13.

   COUNTERPARTS      15   

14.

   NOTICES      15   

15.

   PERPETUITY PERIOD      17   

16.

   GOVERNING LAW      17   

17.

   ENFORCEMENT      18   
SCHEDULE 1 ECF SECURITY DOCUMENTS      19   
SCHEDULE 2 TERM LOAN SECURITY DOCUMENTS      20   
SCHEDULE 3 FORM OF CREDITOR ACCESSION UNDERTAKING      21   
SCHEDULE 4 ADDRESS DETAILS      23   

 

(i)


This INTERCREDITOR DEED (the “Deed”) is dated [] 2010 and made between:

 

(1) KFW IPEX-BANK GMBH as ECF Facility Agent, as Jade Facility Agent and Jewel Facility Agent;

 

(2) THE FINANCIAL INSTITUTIONS named on the signing pages as ECF Lenders (the “Original ECF Lenders”);

 

(3) THE FINANCIAL INSTITUTIONS named on the signing pages as Jade Lenders (the “Original Jade Lenders”);

 

(4) THE FINANCIAL INSTITUTIONS named on the signing pages as Jewel Lenders (the “Original Jewel Lenders”);

 

(5) BREAKAWAY ONE, LTD. (the “Debtor”);

 

(6) KFW IPEX-BANK GMBH in its capacity as security trustee for (a) the ECF Creditors pursuant to the declaration of trust made in the ECF 1 Security Trust Deed, (b) the Jade Creditors pursuant to the declaration of trust made in the Jade Security Trust Deed and (c) the Jewel Creditors pursuant to the declaration of trust made in the Jewel Security Trust Deed (the “Collateral Agent”); and

 

(7) DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT in its capacity as security trustee for (a) the ECF Creditors pursuant to the declaration of trust made in the ECF 1 Security Trust Deed, (b) the Jade Creditors pursuant to the declaration of trust made in the Jade Security Trust Deed and (c) the Jewel Creditors pursuant to the declaration of trust made in the Jewel Security Trust Deed (the “Delegate Collateral Agent”).

NOW THIS DEED WITNESSES as follows:

 

1. DEFINITIONS AND INTERPRETATION

 

1.1 Definitions

In this Deed:

Agents” means the ECF Facility Agent and the Term Loan Facility Agents.

Business Day” shall mean any day except Saturday, Sunday and any day which shall be in New York, London, Frankfurt am Main or Norway a legal holiday or a day on which banking institutions are authorized or required by law or other government action to close.

Creditor” means the Agents, the ECF Creditors and the Term Loan Creditors.

Creditor Accession Undertaking” means an undertaking substantially in the form set out in Schedule 3 (Form of Creditor Accession Undertaking).

Debt Document” means each of this Deed, the Hedging Agreements, the ECF Credit Documents, the Term Loan Credit Documents, the ECF Security Documents, the Term Loan Security Documents and any other document designated as such by the Collateral Agent and the Parent.


Delegate” means any delegate, agent, attorney or co trustee appointed by the Collateral Agent, including the Delegate Collateral Agent.

ECF 1 Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Debtor, the Collateral Agent and the Delegate Collateral Agent as security trustees, the Facility Agent and the ECF Creditors.

ECF Credit Agreement” means the €529,846,154 credit agreement between the Parent, the Debtor, the ECF Lenders and others dated on or about the date of this Deed.

ECF Credit Documents” means the “Credit Documents” under and as defined in the ECF Credit Agreement.

ECF Creditors” means the ECF Facility Agent, the Collateral Agent in its capacity as such under the ECF Credit Documents, the Delegate Collateral Agent in its capacity as such under the ECF Credit Documents, the ECF Lenders and the ECF Hedging Creditors.

ECF Discharge Date” means the first date on which all the ECF Indebtedness and the ECF Hedging Indebtedness, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the ECF Credit Agreement), has been fully and finally discharged to the satisfaction of the ECF Facility Agent, whether or not as the result of an enforcement, and none of the ECF Creditors are under any further obligation to provide financial accommodation to either the Parent or the Debtor under the Debt Documents.

ECF Facility Agent” means the “Facility Agent” under and as defined in the ECF Credit Agreement.

ECF Hedging Agreements” means any ECF Interest Rate Protection Agreement and any ECF Other Hedging Agreement to the extent secured by the ECF Loan Collateral.

ECF Hedging Creditors” means each ECF Lender or affiliate thereof that may at any time and from time to time enter into one or more ECF Hedging Agreements and which becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking), even if the respective ECF Lender subsequently ceases to be an ECF Lender under the ECF Credit Agreement for any reason, together with such ECF Lender’s or affiliate’s successors and assigns, if any.

ECF Hedging Indebtedness” means the aggregate amount of indebtedness owed from time to time by the Debtor or the Parent to the ECF Hedging Creditors under or pursuant to the ECF Hedging Agreements, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

 

3


ECF Indebtedness” means the aggregate amount of indebtedness owed from time to time by the Debtor to the ECF Lenders under or pursuant to any of the ECF Credit Documents, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

ECF Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the ECF Credit Agreement.

ECF Lenders” means each Original ECF Lender and each other Lender (as defined under the ECF Credit Agreement) that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

ECF Loan Collateral” means the “Collateral” under and as defined in the ECF Credit Agreement.

ECF Other Hedging Agreement” means any “Other Hedging Agreement” under and as defined in the ECF Credit Agreement.

ECF Required Lenders” means the “Required Lenders” under and as defined in the ECF Credit Agreement.

ECF Security Documents” means the documents referred to in Schedule 1.

Event of Default” unless otherwise defined herein means an “Event of Default” under and as defined in the ECF Credit Agreement or either of the Term Loan Credit Agreements.

Hedging Agreements” means the Term Loan Hedging Agreements and the ECF Hedging Agreements.

Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, Pride of Hawaii, LLC, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

Jade Creditors” means the Jade Lenders and the Jade Hedging Creditors.

Jade Facility Agent” means the “Facility Agent” under and as defined in the Jade Credit Facility.

Jade Hedging Creditors” means each “Other Creditor” under and as defined in the Jade Credit Facility that becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking).

Jade Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the Jade Credit Facility.

Jade Lenders” means each Original Jade Lender and each other Lender (as defined under the Jade Credit Facility) that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

 

4


Jade Other Hedging Agreement” means any “Other Hedging Agreement” under as defined in the Jade Credit Facility.

Jade Security Trust Deed” means the “Security Trust Deed” under and as defined in the Jade Credit Facility.

Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, Norwegian Jewel Limited as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

Jewel Creditors” means the Jewel Lenders and the Jewel Hedging Creditors.

Jewel Facility Agent” means the “Facility Agent” under and as defined in the Jewel Credit Facility.

Jewel Hedging Creditors” means each “Other Creditor” under and as defined in the Jewel Credit Facility, that becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking).

Jewel Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the Jewel Credit Facility.

Jewel Lenders” means each “Original Jewel Lender” and each other “Lender” under and as defined under the Jewel Credit Facility that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

Jewel Other Hedging Agreement” means any “Other Hedging Agreement” under and as defined in the Jewel Credit Facility.

Jewel Security Trust Deed” means the “Security Trust Deed” under and as defined in the Jewel Credit Facility.

NCLC Group” means the “NCLC Group” under and as defined in the ECF Credit Agreement.

Parent” means NCL Corporation Ltd.

Party” means each party to this Deed, from time to time.

Payment” means, in respect of any liabilities or obligations of the Debtor to the Secured Parties, a payment, prepayment, repayment, redemption, defeasance or discharge of those liabilities or obligations.

Primary Creditors” means the ECF Creditors, the Term Loan Creditors, the ECF Hedging Creditors and the Term Loan Hedging Creditors.

Receiver” means a receiver or receiver and manager or administrative receiver of the whole or any part of the assets which are expressed to be the subject of the Shared Security.

 

5


Secured Parties” means the Collateral Agent, any Receiver or Delegate and each of the Agents and the Primary Creditors from time to time but, in the case of each Agent or Primary Creditor, only if it is a Party to this Deed or has become a Party pursuant to the provisions of Clause 9 (Changes to the Parties).

Security” means any mortgage, pledge, hypothecation, assignment, deposit arrangement, encumbrance, lien (statutory or other), preference, priority or other security agreement of any kind or nature whatsoever (including, without limitation, any conditional sale or other title retention agreement, any financing or similar statement or notice filed under the UCC or any other similar recording or notice statute, and any lease having substantially the same effect as any of the foregoing); provided that in no event shall an operating lease be deemed to constitute Security.

Security Documents” means the Term Loan Security Documents and the ECF Security Documents.

Shared Security” means the assets which are expressed to be the subject of the Security created or evidenced or expressed to be created or evidenced under or pursuant to the Security Documents.

Subsidiaries” means “Subsidiaries” under and as defined in the ECF Credit Agreement.

Term Loan Collateral” means (i) the “Collateral” under and as defined in the Jade Credit Facility and (ii) the “Collateral” under and as defined in the Jewel Credit Facility.

Term Loan Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Term Loan Credit Documents” means each of the “Credit Documents” under and as defined in each of the Term Loan Credit Agreements.

Term Loan Creditors” means the Term Loan Facility Agents, the Collateral Agent in its capacity as such under the Term Loan Credit Documents, the Delegate Collateral Agent in its capacity as such under the Term Loan Credit Documents, the Term Loan Lenders and the Term Loan Hedging Creditors.

Term Loan Facility Agents” means the Jewel Facility Agent and the Jade Facility Agent.

Term Loan Hedging Agreements” means any Jade Interest Rate Protection Agreement, any Jewel Interest Rate Protection Agreement, any Jade Other Hedging Agreement and any Jewel Other Hedging Agreement to the extent secured by the Term Loan Collateral.

Term Loan Hedging Creditors” means the Jade Hedging Creditors and the Jewel Hedging Creditors.

Term Loan Hedging Indebtedness” means the aggregate amount of indebtedness owed from time to time by Norwegian Jewel Limited, Pride of Hawaii, LLC or the Parent to the Term Loan Hedging Creditors under or pursuant to the Term Loan Hedging Agreements, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

 

6


Term Loan Indebtedness” means the aggregate amount of indebtedness owed from time to time by Norwegian Jewel Limited or Pride of Hawaii, LLC to the Term Loan Creditors under or pursuant to the Term Loan Credit Documents, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

Term Loan Lenders” means the Jade Lenders and the Jewel Lenders.

Term Loan Required Lenders” means in respect of each of the Term Loan Credit Agreements, the meaning given to the term “Required Lenders” in each of those Term Loan Credit Agreements.

Term Loan Security Documents” means the documents referred to in Schedule 2.

UCC” means the Uniform Commercial Code as from time to time in effect in the relevant jurisdiction.

 

1.2 References

In this Deed:

 

  (a) words denoting the plural number include the singular and vice versa;

 

  (b) words denoting persons include corporations, partnerships, associations of persons (whether incorporated or not) or governmental or quasi-governmental bodies or authorities and vice versa;

 

  (c) references to Clauses are references to clauses of this Deed;

 

  (d) the headings and contents page(s) are for the purpose of reference only, have no legal or other significance, and shall be ignored in the interpretation of this Deed;

 

  (e) references to any document are, unless the context otherwise requires, references to that document as amended, supplemented, novated or replaced from time to time; and

 

  (f) references to any party include its successors, transferees and assignees.

 

2. PRIORITY AND RANKING

The Term Loan Creditors agree that, notwithstanding (i) the date, time, method or order of grant, attachment or perfection of any of the Security Documents or (ii) the timing of delivery of any notice under any of the Security Documents, the rights, powers, discretions and remedies of the Term Loan Creditors in respect of the Term Loan Security Documents shall be subordinated to the rights, powers, discretions and remedies of any ECF Creditor in respect of the ECF Security Documents.

 

7


3. NOTIFICATIONS

 

3.1 If an Event of Default (as defined in the ECF Credit Agreement) shall occur, the ECF Facility Agent shall, as soon as is reasonably practicable after becoming aware of the same, notify the Term Loan Facility Agents of the same.

 

3.2 If an Event of Default (as defined in either of the Term Loan Credit Agreements) shall occur, the relevant Term Loan Facility Agent(s) shall, as soon as is reasonably practicable after becoming aware of the same, notify the ECF Facility Agent of the same.

 

4. RESTRICTIONS ON ENFORCEMENT

 

4.1 Each of the Term Loan Creditors undertakes that prior to the ECF Discharge Date:

 

  (a) irrespective of its legal rights, and subject to Clause 4.2, it will not take any steps to enforce or require the enforcement of any of its rights in respect of the Shared Security under or pursuant to the Term Loan Security Documents without having first either paid to the ECF Creditors the whole of the ECF Indebtedness or obtained the prior written consent of the ECF Creditors; and

 

  (b) it will not contest nor attempt to contest the security constituted by, or any of the rights of the Collateral Agent, the Delegate Collateral Agent or any ECF Creditor to, the ECF Security Documents,

PROVIDED THAT nothing in this Clause 4.1 shall prevent any Term Loan Creditor from:

 

  (i) filing any action or proceedings necessary for preserving the validity, existence or priority of its rights, or to avoid the loss of or extinction of any of its rights;

 

  (ii) from demanding payment of any of the Term Loan Indebtedness; or

 

  (iii) supporting any proceedings arising from or relating to any enforcement action taken pursuant to the ECF Security Documents by the ECF Creditors with a view (in each case) to substantiating, preserving or protecting its interests as Term Loan Creditor,

but in any such case such Term Loan Creditor shall give the earliest possible notice to the Collateral Agent of its intention to take such action and shall comply with all requirements of the Collateral Agent with respect to the preservation of the ECF Creditors’ rights in respect of the ECF Security Documents (which shall include the cessation of, or withdrawal by such Term Loan Creditor from, any proceedings in the event that the Collateral Agent so requires).

 

4.2 Each of the Term Loan Creditors undertakes to the ECF Creditors that it has not entered into, and will not at any time prior to the ECF Discharge Date enter into, any arrangement in respect of the Term Loan Security Documents, or any transactions related to or contemplated by the Term Loan Security Documents, as a result of which the ECF Security Documents or the security and other rights constituted and conferred on any ECF Creditor by the ECF Security Documents are, or may be, prejudiced.

 

8


4.3 Each of the Term Loan Creditors undertakes to the ECF Creditors that it will not at any time prior to the ECF Discharge Date give any notice to any third party inconsistent with the rights and powers of the ECF Creditors under or pursuant to the ECF Security Documents. In particular, but without limitation, any notice of the assignment by the Debtor of any assets subject to the Term Loan Security Documents shall be expressed as being subject to the provisions of this Deed.

 

5. MANNER OF ENFORCEMENT

 

5.1 Enforcement Instructions

 

  (a) Prior to the ECF Discharge Date, each of the Collateral Agent and the Delegate Collateral Agent may refrain from enforcing the Shared Security unless instructed otherwise by the ECF Required Lenders.

 

  (b) After the ECF Discharge Date, the Collateral Agent and the Delegate Collateral Agent may refrain from enforcing the Shared Security unless instructed otherwise by the Term Loan Required Lenders.

 

  (c) Prior to the ECF Discharge Date, subject to the Shared Security having become enforceable in accordance with its terms, the ECF Required Lenders may give or refrain from giving instructions to the Collateral Agent to enforce or refrain from enforcing all or any part of the Shared Security as they see fit.

 

  (d) After the ECF Discharge Date, subject to the Shared Security having become enforceable in accordance with its terms, the Term Loan Required Lenders may give or refrain from giving instructions to the Collateral Agent to enforce or refrain from enforcing all or any part of the Shared Security as they see fit.

 

  (e) Each of the Collateral Agent and the Delegate Collateral Agent are entitled to rely on and comply with instructions given in accordance with this Clause 5.1 (Enforcement instructions).

 

5.2 Co-operation

If the Collateral Agent or the Delegate Collateral Agent decide (each in its sole and absolute discretion) to exercise its rights of enforcement in relation to all or any part of the Shared Security, each of the ECF Creditors and the Term Loan Creditors agrees to co-operate fully with the Collateral Agent and/or the Delegate Collateral Agent and (where applicable) the Debtor in connection with that enforcement by (without limitation) executing all documents required by the Collateral Agent and/or the Delegate Collateral Agent.

 

5.3 Reasonable Notice

Each of the Collateral Agent and the Delegate Collateral Agent will give the Term Loan Facility Agents, the ECF Hedging Creditors and the Term Loan Hedging Creditors reasonable prior notice of any intended exercise of its rights of enforcement in relation to the Shared Security.

 

9


5.4 Manner of enforcement

If all or any part of the Shared Security is being enforced by the Collateral Agent and/or the Delegate Collateral Agent, each of the Collateral Agent and the Delegate Collateral Agent shall enforce such Shared Security in such manner (including, without limitation, the selection of any administrator of the Debtor to be appointed by either of the Collateral Agent and the Delegate Collateral Agent) as the ECF Required Lenders (or following the ECF Discharge Date, the Term Loan Required Lenders) shall instruct or, in the absence of any such instructions, as each of the Collateral Agent and the Delegate Collateral Agent sees fit.

 

5.5 Exercise of voting rights

 

  (a) Each ECF Creditor and Term Loan Creditor agrees with the Collateral Agent and the Delegate Collateral Agent that it will cast its vote in any proposal put to the vote by or under the supervision of any judicial or supervisory authority in respect of any insolvency, pre-insolvency or rehabilitation or similar proceedings relating to the Debtor as instructed by the Collateral Agent and the Delegate Collateral Agent.

 

  (b) The Collateral Agent and the Delegate Collateral Agent shall give instructions for the purposes of paragraph (a) above as directed by the ECF Required Lenders (or following the ECF Discharge Date, the Term Loan Required Lenders).

 

5.6 Waiver of rights

To the extent permitted under applicable law and subject to Clause 5.4 (Manner of enforcement) and Clause 7 (Application of proceeds), each of the Secured Parties and the Debtor waives all rights it may otherwise have to require that the Shared Security be enforced in any particular order or manner or at any particular time or that any sum received or recovered from any person, or by virtue of the enforcement of any of the Shared Security be applied in any particular manner.

 

5.7 Duties owed

Each of the Collateral Agent and the Delegate Collateral Agent and the Debtor acknowledge that, in the event that either of the Collateral Agent and the Delegate Collateral Agent enforces or is instructed to enforce the Shared Security, the duties of the Collateral Agent and the Delegate Collateral Agent and of any Receiver or Delegate owed to the Secured Parties in respect of the method, type and timing of that enforcement or of the exploitation, management or realisation of any of that Shared Security shall be no different to or greater than the duty that is owed by each of the Collateral Agent and the Delegate Collateral Agent, Receiver or Delegate to the Debtor under general law.

 

5.8 Certificates in relation to ECF Indebtedness

Any certificate provided by the ECF Facility Agent as to the amount of any ECF Indebtedness owed to the ECF Lenders shall be prima facie evidence of the existence and amount of the ECF Indebtedness.

 

10


5.9 Certificates in relation to Term Loan Indebtedness

Any certificate provided by the Term Loan Facility Agents as to the amount of any Term Loan Indebtedness owed to the relevant Term Loan Lenders under the respective Term Loan Credit Agreements shall be prima facie evidence of the existence and amount of the Term Loan Indebtedness.

 

6. TURNOVER OF RECEIPTS

If at any time any Secured Party receives or recovers the proceeds of any enforcement of any Shared Security except in accordance with Clause 7 (Application of Proceeds), that Secured Party will:

 

  (a) in relation to receipts and recoveries not received or recovered by way of set off, hold all amounts received or recovered on trust for the Collateral Agent and promptly pay that amount to the Collateral Agent for application in accordance with the terms of this Deed; and

 

  (b) in relation to receipts and recoveries received or recovered by way of set off, promptly pay an amount equal to that recovery to the Collateral Agent for application in accordance with the terms of this Deed.

 

7. APPLICATION OF PROCEEDS

 

7.1 All amounts from time to time received or recovered by the Collateral Agent in connection with the realisation or enforcement of all or any part of the Shared Security shall be held by the Collateral Agent on trust to apply them at any time as the Collateral Agent (in its discretion) sees fit, to the extent permitted by applicable law (and subject to the provisions of this Clause 7), in the following order of priority:

 

  (a) in discharging any sums (in respect of the Security Documents) owing to the Collateral Agent, the Delegate Collateral Agent, any Receiver or any Delegate (on a pro rata basis);

 

  (b) in payment of all costs and expenses incurred by any Agent or Primary Creditor in connection with any action taken at the request of the Collateral Agent (on a pro rata basis);

 

  (c) to the ECF Facility Agent in payment in or towards the ECF Indebtedness pursuant to Section 4.05 (Application of Proceeds) of the ECF Credit Agreement;

 

  (d) to each of the Term Loan Facility Agents in payment in or towards the Term Loan Indebtedness (on a pro rata basis across each of the Jewel Credit Facility and Jade Credit Facility, based on the outstanding principal amount of loans under each such facility) pursuant to Section 4.05 (Application of Proceeds) of the relevant Term Loan Credit Agreement;

 

  (e) in payment in or towards the ECF Hedging Indebtedness (on a pro rata basis in respect of the ECF Hedging Indebtedness owed to each ECF Hedging Creditor);

 

11


  (f) in payment in or towards the Term Loan Hedging Indebtedness (on a pro rata basis in respect of the Term Loan Hedging Indebtedness owed to each Term Loan Hedging Creditor);

 

  (g) if the Debtor is not under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the ECF Credit Agreement) under any ECF Credit Document, Hedging Agreement or Term Loan Credit Document, in payment to any person to whom the Collateral Agent is obliged to pay in priority to the Debtor; and

 

  (h) the balance, if any, in payment to the Debtor.

 

8. PRESERVATION

 

8.1 Partial invalidity

If, at any time, any provision of this Deed is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions nor the legality, validity or enforceability of that provision under the law of any other jurisdiction will in any way be affected or impaired.

 

8.2 Further Assurance

 

8.3 If, at any time, any provision of this Deed is or becomes invalid or unenforceable in whole or in part by reason of any present or future law or any decision of any court, then from time to time the Debtor and the Term Loan Creditors will each promptly, on demand by the Collateral Agent and at the cost of the Debtor, execute and deliver to the Collateral Agent, or procure the execution and delivery to the Collateral Agent of, such further documents as in the opinion of the Collateral Agent are necessary to give effect to the terms of this Deed.

 

8.4 No impairment

If, at any time after its date, any provision of a Debt Document (including this Deed) is not binding on or enforceable in accordance with its terms against a person expressed to be a party to that Debt Document, neither the binding nature nor the enforceability of that provision or any other provision of that Debt Document will be impaired as against the other party(ies) to that Debt Document.

 

8.5 Remedies and waivers

No failure to exercise, nor any delay in exercising, on the part of any Party, any right or remedy under this Deed shall operate as a waiver, nor shall any single or partial exercise of any right or remedy prevent any further or other exercise or the exercise of any other right or remedy. The rights and remedies provided in this Deed are cumulative and not exclusive of any rights or remedies provided by law.

 

12


8.6 Waiver of defences

The provisions of this Deed will not be affected by an act, omission, matter or thing which, but for this Clause 8.6, would reduce, release or prejudice the subordination and priorities expressed to be created by this Deed including (without limitation and whether or not known to any Party):

 

  (a) any time, waiver or consent granted to, or composition with, the Debtor or other person;

 

  (b) the release of the Debtor or any other person under the terms of any composition or arrangement with any creditor of any member of the NCLC Group;

 

  (c) the taking, variation, compromise, exchange, renewal or release of, or refusal or neglect to perfect, take up or enforce, any rights against, or security over assets of, the Debtor or other person or any non-presentation or non-observance of any formality or other requirement in respect of any instrument or any failure to realise the full value of any Security;

 

  (d) any incapacity or lack of power, authority or legal personality of or dissolution or change in the members or status of the Debtor or other person;

 

  (e) any amendment, novation, supplement, extension (whether of maturity or otherwise) or restatement (in each case, however fundamental and of whatsoever nature, and whether or not more onerous) or replacement of a Debt Document or any other document or security;

 

  (f) any unenforceability, illegality or invalidity of any obligation of any person under any Debt Document or any other document or security;

 

  (g) any intermediate Payment of any of the obligation or liabilities owed by the Debtor to the Primary Creditors in whole or in part; or

 

  (h) any insolvency or similar proceedings.

 

8.7 Priorities not affected

Except as otherwise provided in this Deed the priorities referred to in Clause 2 (Priority and Ranking) will:

 

  (a) not be affected by any reduction or increase in the principal amount secured by the Shared Security in respect of the obligations or liabilities owed by the Debtor to the Primary Creditors or by any intermediate reduction or increase in, amendment or variation to any of the Debt Documents, or by any variation or satisfaction of, any of the obligations or liabilities owed the Debtor to the Primary Creditors or any other circumstances;

 

  (b) apply regardless of the order in which or dates upon which this Deed and the other Debt Documents are executed or registered or notice of them is given to any person; and

 

  (c) secure the obligations or liabilities owed by the Debtor to the Primary Creditors in the order specified, regardless of the date upon which any of those liabilities or obligations arose or of any fluctuations in the amount of any of such outstanding liabilities or obligations.

 

13


9. CHANGES TO THE PARTIES

 

9.1 Assignments and transfers

No Party may assign any of its rights and benefits or transfer any of its rights, benefits and obligations in respect of any Debt Documents except as permitted by this Clause 9.

 

9.2 Change of Lender

Any ECF Lender and any Term Loan Lender may assign any of its rights and benefits or transfer by novation any of its rights, benefits and obligations in respect of this Deed if:

 

  (a) the assignee or transferee has executed an Assignment Agreement or Transfer Certificate (as each such term is defined in the ECF Credit Agreement or the relevant Term Loan Credit Agreement) pursuant to which, amongst other things, the assignee or transferee receives the benefit of the rights and agrees that it will perform all of the obligations which are required to be performed by a Lender under the terms of the ECF Credit Agreement or the relevant Term Loan Credit Agreement (as applicable); and

 

  (b) the ECF Lender or Term Loan Lender has complied with the requirements for such assignment or transfer under its ECF Credit Agreement or the relevant Term Loan Credit Agreement, as applicable.

 

9.3 Change of Agent

No person shall become an Agent unless at the same time, it accedes to this Deed as an Agent pursuant to Clause 9.4 (Creditor Accession Undertaking).

 

9.4 Creditor Accession Undertaking

 

  (a) Subject to Clause 9.2 (Change of Lender), any ECF Hedging Creditor, Term Loan Hedging Creditor, or Agent that wishes to become a Party to this Deed in the capacity as a Creditor may become a Party by delivering to the Collateral Agent, a duly completed and executed Creditor Accession Undertaking.

 

  (b) With effect from the date of acceptance by the Collateral Agent of a Creditor Accession Undertaking duly executed and delivered to the Collateral Agent by the relevant acceding party or, if later, the date specified in that Creditor Accession Undertaking:

 

  (i) any Party ceasing entirely to be a Creditor shall be discharged from further obligations towards the Collateral Agent and other Parties under this Deed and their respective rights against one another shall be cancelled (except in each case for those rights which arose prior to that date); and

 

14


  (ii) as from that date, the replacement or new Creditor shall assume the same obligations and become entitled to the same rights, as if it had been an original Party to this Deed in that capacity.

 

9.5 Additional parties

Each of the Parties appoints the Collateral Agent to receive on its behalf each Creditor Accession Undertaking delivered to the Collateral Agent and the Collateral Agent shall, as soon as reasonably practicable after receipt by it, sign and accept the same if it appears on its face to have been completed, executed and, where applicable, delivered in the form contemplated by this Deed.

 

10. POWER OF ATTORNEY

The Debtor and each Creditor irrevocably appoints the Collateral Agent and the Delegate Collateral Agent as its attorney to do anything which such person has authorised the Collateral Agent or the Delegate Collateral Agent to do under this Deed or which such person is required to do under this Deed but has failed to do for a period of five Business Days after receiving notice from Collateral Agent or the Delegate Collateral Agent requiring it to do so.

 

11. AMENDMENTS

 

11.1 No variation or amendment to this Deed shall be valid unless in writing and signed on behalf of each of the Parties.

 

12. THIRD PARTY RIGHTS

 

12.1 Unless expressly provided to the contrary in this Deed, a person who is not a Party has no right under the Contracts (Rights of Third Parties) Act 1999 (the “Third Parties Rights Act”) to enforce or to enjoy the benefit of any term of this Deed.

 

12.2 Notwithstanding any term of this Deed, the consent of any person who is not a Party is not required to rescind or vary this Deed at any time.

 

13. COUNTERPARTS

This Deed may be executed in any number of counterparts and all the counterparts when executed and taken together shall constitute one and the same instrument.

 

14. NOTICES

 

14.1 Communications in Writing

Any communication to be made under or in connection with this Deed shall be made in writing and, unless otherwise stated, may be made by fax or letter.

 

14.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 14.1 (Communications in writing), the contact details of each of the parties are as follows:

 

  (a) to the Collateral Agent:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany,

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

15


  (b) to the Delegate Collateral Agent:

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Fax: +49 40 3769 -9649

E-mail: marcus.weber@commerzbank.com

             anne.randewig@commerzbank.com

 

  (c) to the Agents:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

  (d) to the Credit Parties:

7665 Corporation Center Drive

Miami, Florida 33126

USA

Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

             hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

 

16


O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com,

or to such other address and/or number as is notified in writing by a party to the other parties under this Deed.

 

14.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified on Clause 14.2 (Contact Details) or in the case of the Original ECF Lenders, Original Jade Lenders and Original Jewel Lenders at the addressed identified with its name in Schedule 4 hereto; provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Parties agree that they shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and they shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Agents, the Collateral Agent and the Delegate Collateral Agent shall not be effective until received by them or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Debtor to the Agents, the Collateral Agent or the Delegate Collateral Agent, only if it is addressed in such a manner as the Agents, the Collateral Agent or the Delegate Collateral Agent shall specify for this purpose.

 

15. PERPETUITY PERIOD

 

15.1 The perpetuity period for each trust created by this Deed shall be one hundred and twenty five (125) years from the date of this Deed.

 

16. GOVERNING LAW

This Deed and any non-contractual obligations arising out of or in connection with it are governed by English law.

 

17


17. ENFORCEMENT

 

17.1 Jurisdiction

 

  (a) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Deed (including a dispute relating to the existence, validity or termination of this Deed or any non-contractual obligation arising out of or in connection with this Deed) (a “Dispute”).

 

  (b) The Parties hereto agree that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no Party will argue to the contrary.

 

  (c) This Clause 17.1 is for the benefit of the Secured Parties only. As a result, no Secured Party shall be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, the Secured Parties may take concurrent proceedings in any number of jurisdictions.

 

17.2 Service of process

 

  (a) Without prejudice to any other mode of service allowed under any relevant law the Debtor (unless incorporated in England and Wales):

 

  (i) shall appoint a process agent as its agent for service of process in relation to any proceedings before the English courts in connection with this Deed; and

 

  (ii) agrees that failure by a process agent to notify the Debtor of the process will not invalidate the proceedings concerned;

 

  (b) If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Debtor must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the ECF Facility Agent (or after the ECF Discharge Date, the Term Loan Facility Agents). Failing this, the ECF Facility Agent (or after the ECF Discharge Date, the Term Loan Facility Agents) may appoint another agent for this purpose.

 

  (c) The Debtor expressly agrees and consents to the provisions of this Clause 17 and Clause 16 (Governing Law).

IN WITNESS WHEREOF of which this Deed has been duly executed and delivered on the day and year written above.

 

18


SCHEDULE 1

ECF SECURITY DOCUMENTS

 

1. First-priority legal assignment of contracts dated on or about the date hereof in respect of the Construction Contract, certain of the Refund Guarantees and the Construction Risks Insurance (each as defined in the ECF Credit Agreement) in favour of the Collateral Agent as security trustee on behalf of the ECF Creditors (the “Vessel 1 Assignment of Contracts”).

 

2. First-priority legal assignment of the refund guarantees dated on or about the date hereof in respect of certain of the Refund Guarantees issued by KfW IPEX-Bank GmbH in favour of the Delegate Collateral Agent as security trustee on behalf of the ECF Creditors (the “Vessel 1 Assignment of KfW Refund Guarantees”).

 

3. The ECF 1 Security Trust Deed.

 

19


SCHEDULE 2

TERM LOAN SECURITY DOCUMENTS

 

1. Second-priority legal assignment of contracts dated on or about the date hereof in respect of the Construction Contract, certain of the Refund Guarantees and the Construction Risks Insurance (each as defined in each Term Loan Credit Agreement) in favour of the Collateral Agent as security trustee on behalf of the Term Loan Creditors (the “Term Loan Vessel 1 Assignment of Contracts”).

 

2. Second-priority legal assignment of the refund guarantees dated on or about the date hereof in respect of certain of the Refund Guarantees issued by KfW IPEX-Bank GmbH in favour of the Delegate Collateral Agent as security trustee on behalf of the Term Loan Creditors (the “Term Loan Vessel 1 Assignment of KfW Refund Guarantees”).

 

3. The Jade Security Trust Deed.

 

4. The Jewel Security Trust Deed.

 

20


SCHEDULE 3

FORM OF CREDITOR ACCESSION UNDERTAKING

 

To:    [Insert full name of current Collateral Agent and Delegate Collateral Agent] for themselves and each of the other parties to the Intercreditor Deed referred to below.
[To:    [Insert full name of current Agent] as Agent.]
From:    [Acceding Creditor/Agent]

THIS UNDERTAKING is made on [date] by [insert full name of new Creditor / Agent] (the “Acceding [Creditor / Agent]”) in relation to the intercreditor deed (the “Intercreditor Deed”) dated [] between KfW IPEX-Bank GmbH as ECF Facility Agent and Term Loan Facility Agents, the parties named therein as ECF Lenders, the parties named therein as the Jade Lenders, the parties named therein as the Jewel Lenders, Breakaway One, Ltd. as Debtor, KfW IPEX-Bank GmbH acting as Collateral Agent and Deutsche Schiffsbank Aktiengesellschaft as Delegate Collateral Agent.

Terms defined in the Intercreditor Deed shall, unless otherwise defined in this Undertaking, bear the same meanings when used in this Undertaking.

In consideration of the Acceding [Creditor / Agent] being accepted as a [[ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor]] for the purposes of the Intercreditor Deed, the Acceding [Creditor / Agent] confirms that, as from [date], it intends to be party to the Intercreditor Deed as a [ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor] and undertakes to perform all the obligations expressed in the Intercreditor Deed to be assumed by a [[ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor]] and agrees that it shall be bound by all the provisions of the Intercreditor Deed, as if it had been an original party to the Intercreditor Deed.

This Undertaking and any non-contractual obligations arising out of or in connection with it are governed by English law.

THIS UNDERTAKING has been entered into on the date stated above.

Acceding [Creditor / Agent]

 

[EXECUTED as a DEED]

[insert full name of Acceding Creditor / Agent]

By:
Address:
Fax:

 

21


Accepted by the Collateral Agent

 

 

for and on behalf of
KfW IPEX-Bank GmbH
Date:

 

22


SCHEDULE 4

ADDRESS DETAILS

 

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT   

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Telephone: +49 40 3769 -9646 / -9647

Facsimile: +49 40 3769 -9649

e-mail:    marcus.weber@commerzbank.com

               anne.randewig@commerzbank.com

DNB NOR BANK ASA   

Stranden 21

N-0021 Oslo, Norway

Attn: Amra Koluder / Solveig N. Knoff

Telephone: +47 22 94 91 17 / 22 94 96 63

Facsimile: +47 22 48 28 94

e-mail:    amra.koluder@dnbnor.no

               solveig.knoff@dnbnor.no

HSBC BANK PLC   

8 Canada Square

London E14 5HQ

Attn: Alan P. Marshall (FC1354)

Fax no: +44 207 992 4428

e-mail:    alan.p.marshall@hsbcib.com

KFW IPEX-BANK GMBH   

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Telephone: +49 69 7431 4649 / 4037

Fax: +49 69 7431 4466 / 2944

Attn:      Ms Claudia Wenzel /

              Mr Christian Schweiger

email:    claudia.wenzel@kfw.de /

              christian.schweiger@kfw.de

NORDEA BANK NORGE ASA   

Middelthunsgate 17, P.O. Box 1166 Sentrum

NO-0107

Oslo, Norway

Attn: Arne Berglund

Telephone: (47) 22 484193

Facsimile: (47) 22 486668

e-mail:    arne.berglund@nordea.com

 

23


SIGNATORIES

THE ECF FACILITY AGENT

 

Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director

 

24


THE JADE FACILITY AGENT

 

Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


THE JEWEL FACILITY AGENT

 

Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


THE ORIGINAL ECF LENDERS

 

Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


THE ORIGINAL JADE LENDERS

 

Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


THE ORIGINAL JEWEL LENDERS

 

Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


THE DEBTOR

 

Signed as a deed on behalf of BREAKAWAY ONE, LTD., a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company   
  

 

   Authorised [signatory] [signatories]


THE COLLATERAL AGENT

 

Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:   
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


EXHIBIT N

THE DELEGATE COLLATERAL AGENT

 

Executed as a deed by

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:

  
  

 

   [Signature of Director]
   Director
  

 

   [Signature of Director]
   Director


LOGO

 

 

 

EXHIBIT M-2

Dated [] 2010

FORM OF INTERCREDITOR DEED

between

KFW IPEX-BANK GMBH

as ECF Facility Agent, the Jade Facility Agent and the Jewel Facility Agent

The ECF Lenders

The Jade Lenders

The Jewel Lenders

BREAKAWAY TWO, LTD.

as Debtor

KFW IPEX-BANK GMBH

acting as Collateral Agent

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

acting as Delegate Collateral Agent

and others

 

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


EXHIBIT M-2

TABLE OF CONTENTS

 

         Page  
1.   DEFINITIONS AND INTERPRETATION      2   
2.   PRIORITY AND RANKING      7   
3.   NOTIFICATIONS      8   
4.   RESTRICTIONS ON ENFORCEMENT      8   
5.   MANNER OF ENFORCEMENT      9   
6.   TURNOVER OF RECEIPTS      11   
7.   APPLICATION OF PROCEEDS      11   
8.   PRESERVATION      12   
9.   CHANGES TO THE PARTIES      14   
10.   POWER OF ATTORNEY      15   
11.   AMENDMENTS      15   
12.   THIRD PARTY RIGHTS      15   
13.   COUNTERPARTS      15   
14.   NOTICES      15   
15.   PERPETUITY PERIOD      17   
16.   GOVERNING LAW      17   
17.   ENFORCEMENT      18   
SCHEDULE 1 ECF SECURITY DOCUMENTS      19   
SCHEDULE 2 TERM LOAN SECURITY DOCUMENTS      20   
SCHEDULE 3 FORM OF CREDITOR ACCESSION UNDERTAKING      21   
SCHEDULE 4 ADDRESS DETAILS      23   

 

(i)


This INTERCREDITOR DEED (the “Deed”) is dated [] 2010 and made between:

 

(1) KFW IPEX-BANK GMBH as ECF Facility Agent, as Jade Facility Agent and Jewel Facility Agent;

 

(2) THE FINANCIAL INSTITUTIONS named on the signing pages as ECF Lenders (the “Original ECF Lenders”);

 

(3) THE FINANCIAL INSTITUTIONS named on the signing pages as Jade Lenders (the “Original Jade Lenders”);

 

(4) THE FINANCIAL INSTITUTIONS named on the signing pages as Jewel Lenders (the “Original Jewel Lenders”);

 

(5) BREAKAWAY TWO, LTD. (the “Debtor”);

 

(6) KFW IPEX-BANK GMBH in its capacity as security trustee for (a) the ECF Creditors pursuant to the declaration of trust made in the ECF 2 Security Trust Deed, (b) the Jade Creditors pursuant to the declaration of trust made in the Jade Security Trust Deed and (c) the Jewel Creditors pursuant to the declaration of trust made in the Jewel Security Trust Deed (the “Collateral Agent”); and

 

(7) DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT in its capacity as security trustee for (a) the ECF Creditors pursuant to the declaration of trust made in the ECF 2 Security Trust Deed, (b) the Jade Creditors pursuant to the declaration of trust made in the Jade Security Trust Deed and (c) the Jewel Creditors pursuant to the declaration of trust made in the Jewel Security Trust Deed (the “Delegate Collateral Agent”).

NOW THIS DEED WITNESSES as follows:

 

1. DEFINITIONS AND INTERPRETATION

 

1.1 Definitions

In this Deed:

Agents” means the ECF Facility Agent and the Term Loan Facility Agents.

Business Day” shall mean any day except Saturday, Sunday and any day which shall be in New York, London, Frankfurt am Main or Norway a legal holiday or a day on which banking institutions are authorized or required by law or other government action to close.

Creditor” means the Agents, the ECF Creditors and the Term Loan Creditors.

Creditor Accession Undertaking” means an undertaking substantially in the form set out in Schedule 3 (Form of Creditor Accession Undertaking).

Debt Document” means each of this Deed, the Hedging Agreements, the ECF Credit Documents, the Term Loan Credit Documents, the ECF Security Documents, the Term Loan Security Documents and any other document designated as such by the Collateral Agent and the Parent.


Delegate” means any delegate, agent, attorney or co trustee appointed by the Collateral Agent, including the Delegate Collateral Agent.

ECF 2 Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Debtor, the Collateral Agent and the Delegate Collateral Agent as security trustees, the Facility Agent and the ECF Creditors.

ECF Credit Agreement” means the €529,846,154 credit agreement between the Parent, the Debtor, the ECF Lenders and others dated on or about the date of this Deed.

ECF Credit Documents” means the “Credit Documents” under and as defined in the ECF Credit Agreement.

ECF Creditors” means the ECF Facility Agent, the Collateral Agent in its capacity as such under the ECF Credit Documents, the Delegate Collateral Agent in its capacity as such under the ECF Credit Documents, the ECF Lenders and the ECF Hedging Creditors.

ECF Discharge Date” means the first date on which all the ECF Indebtedness and the ECF Hedging Indebtedness, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the ECF Credit Agreement), has been fully and finally discharged to the satisfaction of the ECF Facility Agent, whether or not as the result of an enforcement, and none of the ECF Creditors are under any further obligation to provide financial accommodation to either the Parent or the Debtor under the Debt Documents.

ECF Facility Agent” means the “Facility Agent” under and as defined in the ECF Credit Agreement.

ECF Hedging Agreements” means any ECF Interest Rate Protection Agreement and any ECF Other Hedging Agreement to the extent secured by the ECF Loan Collateral.

ECF Hedging Creditors” means each ECF Lender or affiliate thereof that may at any time and from time to time enter into one or more ECF Hedging Agreements and which becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking), even if the respective ECF Lender subsequently ceases to be an ECF Lender under the ECF Credit Agreement for any reason, together with such ECF Lender’s or affiliate’s successors and assigns, if any.

ECF Hedging Indebtedness” means the aggregate amount of indebtedness owed from time to time by the Debtor or the Parent to the ECF Hedging Creditors under or pursuant to the ECF Hedging Agreements, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

 

3


ECF Indebtedness” means the aggregate amount of indebtedness owed from time to time by the Debtor to the ECF Lenders under or pursuant to any of the ECF Credit Documents, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

ECF Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the ECF Credit Agreement.

ECF Lenders” means each Original ECF Lender and each other Lender (as defined under the ECF Credit Agreement) that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

ECF Loan Collateral” means the “Collateral” under and as defined in the ECF Credit Agreement.

ECF Other Hedging Agreement” means any “Other Hedging Agreement” under and as defined in the ECF Credit Agreement.

ECF Required Lenders” means the “Required Lenders” under and as defined in the ECF Credit Agreement.

ECF Security Documents” means the documents referred to in Schedule 1.

Event of Default” unless otherwise defined herein means an “Event of Default” under and as defined in the ECF Credit Agreement or either of the Term Loan Credit Agreements.

Hedging Agreements” means the Term Loan Hedging Agreements and the ECF Hedging Agreements.

Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, Pride of Hawaii, LLC, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

Jade Creditors” means the Jade Lenders and the Jade Hedging Creditors.

Jade Facility Agent” means the “Facility Agent” under and as defined in the Jade Credit Facility.

Jade Hedging Creditors” means each “Other Creditor” under and as defined in the Jade Credit Facility that becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking).

Jade Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the Jade Credit Facility.

Jade Lenders” means each Original Jade Lender and each other Lender (as defined under the Jade Credit Facility) that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

 

4


Jade Other Hedging Agreement” means any “Other Hedging Agreement” under as defined in the Jade Credit Facility.

Jade Security Trust Deed” means the “Security Trust Deed” under and as defined in the Jade Credit Facility.

Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, Norwegian Jewel Limited as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

Jewel Creditors” means the Jewel Lenders and the Jewel Hedging Creditors.

Jewel Facility Agent” means the “Facility Agent” under and as defined in the Jewel Credit Facility.

Jewel Hedging Creditors” means each “Other Creditor” under and as defined in the Jewel Credit Facility, that becomes a Party to this Deed pursuant to Clause 9.4 (Creditor Accession Undertaking).

Jewel Interest Rate Protection Agreement” means any “Interest Rate Protection Agreement” under and as defined in the Jewel Credit Facility.

Jewel Lenders” means each “Original Jewel Lender” and each other “Lender” under and as defined under the Jewel Credit Facility that becomes a Party to this Deed pursuant to Clause 9.2 (Change of Lender).

Jewel Other Hedging Agreement” means any “Other Hedging Agreement” under and as defined in the Jewel Credit Facility.

Jewel Security Trust Deed” means the “Security Trust Deed” under and as defined in the Jewel Credit Facility.

NCLC Group” means the “NCLC Group” under and as defined in the ECF Credit Agreement.

Parent” means NCL Corporation Ltd.

Party” means each party to this Deed, from time to time.

Payment” means, in respect of any liabilities or obligations of the Debtor to the Secured Parties, a payment, prepayment, repayment, redemption, defeasance or discharge of those liabilities or obligations.

Primary Creditors” means the ECF Creditors, the Term Loan Creditors, the ECF Hedging Creditors and the Term Loan Hedging Creditors.

Receiver” means a receiver or receiver and manager or administrative receiver of the whole or any part of the assets which are expressed to be the subject of the Shared Security.

 

5


Secured Parties” means the Collateral Agent, any Receiver or Delegate and each of the Agents and the Primary Creditors from time to time but, in the case of each Agent or Primary Creditor, only if it is a Party to this Deed or has become a Party pursuant to the provisions of Clause 9 (Changes to the Parties).

Security” means any mortgage, pledge, hypothecation, assignment, deposit arrangement, encumbrance, lien (statutory or other), preference, priority or other security agreement of any kind or nature whatsoever (including, without limitation, any conditional sale or other title retention agreement, any financing or similar statement or notice filed under the UCC or any other similar recording or notice statute, and any lease having substantially the same effect as any of the foregoing); provided that in no event shall an operating lease be deemed to constitute Security.

Security Documents” means the Term Loan Security Documents and the ECF Security Documents.

Shared Security” means the assets which are expressed to be the subject of the Security created or evidenced or expressed to be created or evidenced under or pursuant to the Security Documents.

Subsidiaries” means “Subsidiaries” under and as defined in the ECF Credit Agreement.

Term Loan Collateral” means (i) the “Collateral” under and as defined in the Jade Credit Facility and (ii) the “Collateral” under and as defined in the Jewel Credit Facility.

Term Loan Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Term Loan Credit Documents” means each of the “Credit Documents” under and as defined in each of the Term Loan Credit Agreements.

Term Loan Creditors” means the Term Loan Facility Agents, the Collateral Agent in its capacity as such under the Term Loan Credit Documents, the Delegate Collateral Agent in its capacity as such under the Term Loan Credit Documents, the Term Loan Lenders and the Term Loan Hedging Creditors.

Term Loan Facility Agents” means the Jewel Facility Agent and the Jade Facility Agent.

Term Loan Hedging Agreements” means any Jade Interest Rate Protection Agreement, any Jewel Interest Rate Protection Agreement, any Jade Other Hedging Agreement and any Jewel Other Hedging Agreement to the extent secured by the Term Loan Collateral.

Term Loan Hedging Creditors” means the Jade Hedging Creditors and the Jewel Hedging Creditors.

Term Loan Hedging Indebtedness” means the aggregate amount of indebtedness owed from time to time by Norwegian Jewel Limited, Pride of Hawaii, LLC or the Parent to the Term Loan Hedging Creditors under or pursuant to the Term Loan Hedging Agreements, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

 

6


Term Loan Indebtedness” means the aggregate amount of indebtedness owed from time to time by Norwegian Jewel Limited or Pride of Hawaii, LLC to the Term Loan Creditors under or pursuant to the Term Loan Credit Documents, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

Term Loan Lenders” means the Jade Lenders and the Jewel Lenders.

Term Loan Required Lenders” means in respect of each of the Term Loan Credit Agreements, the meaning given to the term “Required Lenders” in each of those Term Loan Credit Agreements.

Term Loan Security Documents” means the documents referred to in Schedule 2.

UCC” means the Uniform Commercial Code as from time to time in effect in the relevant jurisdiction.

 

1.2 References

In this Deed:

 

  (a) words denoting the plural number include the singular and vice versa;

 

  (b) words denoting persons include corporations, partnerships, associations of persons (whether incorporated or not) or governmental or quasi-governmental bodies or authorities and vice versa;

 

  (c) references to Clauses are references to clauses of this Deed;

 

  (d) the headings and contents page(s) are for the purpose of reference only, have no legal or other significance, and shall be ignored in the interpretation of this Deed;

 

  (e) references to any document are, unless the context otherwise requires, references to that document as amended, supplemented, novated or replaced from time to time; and

 

  (f) references to any party include its successors, transferees and assignees.

 

2. PRIORITY AND RANKING

The Term Loan Creditors agree that, notwithstanding (i) the date, time, method or order of grant, attachment or perfection of any of the Security Documents or (ii) the timing of delivery of any notice under any of the Security Documents, the rights, powers, discretions and remedies of the Term Loan Creditors in respect of the Term Loan Security Documents shall be subordinated to the rights, powers, discretions and remedies of any ECF Creditor in respect of the ECF Security Documents.

 

7


3. NOTIFICATIONS

 

3.1 If an Event of Default (as defined in the ECF Credit Agreement) shall occur, the ECF Facility Agent shall, as soon as is reasonably practicable after becoming aware of the same, notify the Term Loan Facility Agents of the same.

 

3.2 If an Event of Default (as defined in either of the Term Loan Credit Agreements) shall occur, the relevant Term Loan Facility Agent(s) shall, as soon as is reasonably practicable after becoming aware of the same, notify the ECF Facility Agent of the same.

 

4. RESTRICTIONS ON ENFORCEMENT

 

4.1 Each of the Term Loan Creditors undertakes that prior to the ECF Discharge Date:

 

  (a) irrespective of its legal rights, and subject to Clause 4.2, it will not take any steps to enforce or require the enforcement of any of its rights in respect of the Shared Security under or pursuant to the Term Loan Security Documents without having first either paid to the ECF Creditors the whole of the ECF Indebtedness or obtained the prior written consent of the ECF Creditors; and

 

  (b) it will not contest nor attempt to contest the security constituted by, or any of the rights of the Collateral Agent, the Delegate Collateral Agent or any ECF Creditor to, the ECF Security Documents,

PROVIDED THAT nothing in this Clause 4.1 shall prevent any Term Loan Creditor from:

 

  (i) filing any action or proceedings necessary for preserving the validity, existence or priority of its rights, or to avoid the loss of or extinction of any of its rights;

 

  (ii) from demanding payment of any of the Term Loan Indebtedness; or

 

  (iii) supporting any proceedings arising from or relating to any enforcement action taken pursuant to the ECF Security Documents by the ECF Creditors with a view (in each case) to substantiating, preserving or protecting its interests as Term Loan Creditor,

but in any such case such Term Loan Creditor shall give the earliest possible notice to the Collateral Agent of its intention to take such action and shall comply with all requirements of the Collateral Agent with respect to the preservation of the ECF Creditors’ rights in respect of the ECF Security Documents (which shall include the cessation of, or withdrawal by such Term Loan Creditor from, any proceedings in the event that the Collateral Agent so requires).

 

4.2 Each of the Term Loan Creditors undertakes to the ECF Creditors that it has not entered into, and will not at any time prior to the ECF Discharge Date enter into, any arrangement in respect of the Term Loan Security Documents, or any transactions related to or contemplated by the Term Loan Security Documents, as a result of which the ECF Security Documents or the security and other rights constituted and conferred on any ECF Creditor by the ECF Security Documents are, or may be, prejudiced.

 

8


4.3 Each of the Term Loan Creditors undertakes to the ECF Creditors that it will not at any time prior to the ECF Discharge Date give any notice to any third party inconsistent with the rights and powers of the ECF Creditors under or pursuant to the ECF Security Documents. In particular, but without limitation, any notice of the assignment by the Debtor of any assets subject to the Term Loan Security Documents shall be expressed as being subject to the provisions of this Deed.

 

5. MANNER OF ENFORCEMENT

 

5.1 Enforcement Instructions

 

  (a) Prior to the ECF Discharge Date, each of the Collateral Agent and the Delegate Collateral Agent may refrain from enforcing the Shared Security unless instructed otherwise by the ECF Required Lenders.

 

  (b) After the ECF Discharge Date, the Collateral Agent and the Delegate Collateral Agent may refrain from enforcing the Shared Security unless instructed otherwise by the Term Loan Required Lenders.

 

  (c) Prior to the ECF Discharge Date, subject to the Shared Security having become enforceable in accordance with its terms, the ECF Required Lenders may give or refrain from giving instructions to the Collateral Agent to enforce or refrain from enforcing all or any part of the Shared Security as they see fit.

 

  (d) After the ECF Discharge Date, subject to the Shared Security having become enforceable in accordance with its terms, the Term Loan Required Lenders may give or refrain from giving instructions to the Collateral Agent to enforce or refrain from enforcing all or any part of the Shared Security as they see fit.

 

  (e) Each of the Collateral Agent and the Delegate Collateral Agent are entitled to rely on and comply with instructions given in accordance with this Clause 5.1 (Enforcement instructions).

 

5.2 Co-operation

If the Collateral Agent or the Delegate Collateral Agent decide (each in its sole and absolute discretion) to exercise its rights of enforcement in relation to all or any part of the Shared Security, each of the ECF Creditors and the Term Loan Creditors agrees to co-operate fully with the Collateral Agent and/or the Delegate Collateral Agent and (where applicable) the Debtor in connection with that enforcement by (without limitation) executing all documents required by the Collateral Agent and/or the Delegate Collateral Agent.

 

5.3 Reasonable Notice

Each of the Collateral Agent and the Delegate Collateral Agent will give the Term Loan Facility Agents, the ECF Hedging Creditors and the Term Loan Hedging Creditors reasonable prior notice of any intended exercise of its rights of enforcement in relation to the Shared Security.

 

9


5.4 Manner of enforcement

If all or any part of the Shared Security is being enforced by the Collateral Agent and/or the Delegate Collateral Agent, each of the Collateral Agent and the Delegate Collateral Agent shall enforce such Shared Security in such manner (including, without limitation, the selection of any administrator of the Debtor to be appointed by either of the Collateral Agent and the Delegate Collateral Agent) as the ECF Required Lenders (or following the ECF Discharge Date, the Term Loan Required Lenders) shall instruct or, in the absence of any such instructions, as each of the Collateral Agent and the Delegate Collateral Agent sees fit.

 

5.5 Exercise of voting rights

 

  (a) Each ECF Creditor and Term Loan Creditor agrees with the Collateral Agent and the Delegate Collateral Agent that it will cast its vote in any proposal put to the vote by or under the supervision of any judicial or supervisory authority in respect of any insolvency, pre-insolvency or rehabilitation or similar proceedings relating to the Debtor as instructed by the Collateral Agent and the Delegate Collateral Agent.

 

  (b) The Collateral Agent and the Delegate Collateral Agent shall give instructions for the purposes of paragraph (a) above as directed by the ECF Required Lenders (or following the ECF Discharge Date, the Term Loan Required Lenders).

 

5.6 Waiver of rights

To the extent permitted under applicable law and subject to Clause 5.4 (Manner of enforcement) and Clause 7 (Application of proceeds), each of the Secured Parties and the Debtor waives all rights it may otherwise have to require that the Shared Security be enforced in any particular order or manner or at any particular time or that any sum received or recovered from any person, or by virtue of the enforcement of any of the Shared Security be applied in any particular manner.

 

5.7 Duties owed

Each of the Collateral Agent and the Delegate Collateral Agent and the Debtor acknowledge that, in the event that either of the Collateral Agent and the Delegate Collateral Agent enforces or is instructed to enforce the Shared Security, the duties of the Collateral Agent and the Delegate Collateral Agent and of any Receiver or Delegate owed to the Secured Parties in respect of the method, type and timing of that enforcement or of the exploitation, management or realisation of any of that Shared Security shall be no different to or greater than the duty that is owed by each of the Collateral Agent and the Delegate Collateral Agent, Receiver or Delegate to the Debtor under general law.

 

5.8 Certificates in relation to ECF Indebtedness

Any certificate provided by the ECF Facility Agent as to the amount of any ECF Indebtedness owed to the ECF Lenders shall be prima facie evidence of the existence and amount of the ECF Indebtedness.

 

10


5.9 Certificates in relation to Term Loan Indebtedness

Any certificate provided by the Term Loan Facility Agents as to the amount of any Term Loan Indebtedness owed to the relevant Term Loan Lenders under the respective Term Loan Credit Agreements shall be prima facie evidence of the existence and amount of the Term Loan Indebtedness.

 

6. TURNOVER OF RECEIPTS

If at any time any Secured Party receives or recovers the proceeds of any enforcement of any Shared Security except in accordance with Clause 7 (Application of Proceeds), that Secured Party will:

 

  (a) in relation to receipts and recoveries not received or recovered by way of set off, hold all amounts received or recovered on trust for the Collateral Agent and promptly pay that amount to the Collateral Agent for application in accordance with the terms of this Deed; and

 

  (b) in relation to receipts and recoveries received or recovered by way of set off, promptly pay an amount equal to that recovery to the Collateral Agent for application in accordance with the terms of this Deed.

 

7. APPLICATION OF PROCEEDS

 

7.1 All amounts from time to time received or recovered by the Collateral Agent in connection with the realisation or enforcement of all or any part of the Shared Security shall be held by the Collateral Agent on trust to apply them at any time as the Collateral Agent (in its discretion) sees fit, to the extent permitted by applicable law (and subject to the provisions of this Clause 7), in the following order of priority:

 

  (a) in discharging any sums (in respect of the Security Documents) owing to the Collateral Agent, the Delegate Collateral Agent, any Receiver or any Delegate (on a pro rata basis);

 

  (b) in payment of all costs and expenses incurred by any Agent or Primary Creditor in connection with any action taken at the request of the Collateral Agent (on a pro rata basis);

 

  (c) to the ECF Facility Agent in payment in or towards the ECF Indebtedness pursuant to Section 4.05 (Application of Proceeds) of the ECF Credit Agreement;

 

  (d) to each of the Term Loan Facility Agents in payment in or towards the Term Loan Indebtedness (on a pro rata basis across each of the Jewel Credit Facility and Jade Credit Facility, based on the outstanding principal amount of loans under each such facility) pursuant to Section 4.05 (Application of Proceeds) of the relevant Term Loan Credit Agreement;

 

  (e) in payment in or towards the ECF Hedging Indebtedness (on a pro rata basis in respect of the ECF Hedging Indebtedness owed to each ECF Hedging Creditor);

 

11


  (f) in payment in or towards the Term Loan Hedging Indebtedness (on a pro rata basis in respect of the Term Loan Hedging Indebtedness owed to each Term Loan Hedging Creditor);

 

  (g) if the Debtor is not under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the ECF Credit Agreement) under any ECF Credit Document, Hedging Agreement or Term Loan Credit Document, in payment to any person to whom the Collateral Agent is obliged to pay in priority to the Debtor; and

 

  (h) the balance, if any, in payment to the Debtor.

 

8. PRESERVATION

 

8.1 Partial invalidity

If, at any time, any provision of this Deed is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions nor the legality, validity or enforceability of that provision under the law of any other jurisdiction will in any way be affected or impaired.

 

8.2 Further Assurance

 

8.3 If, at any time, any provision of this Deed is or becomes invalid or unenforceable in whole or in part by reason of any present or future law or any decision of any court, then from time to time the Debtor and the Term Loan Creditors will each promptly, on demand by the Collateral Agent and at the cost of the Debtor, execute and deliver to the Collateral Agent, or procure the execution and delivery to the Collateral Agent of, such further documents as in the opinion of the Collateral Agent are necessary to give effect to the terms of this Deed.

 

8.4 No impairment

If, at any time after its date, any provision of a Debt Document (including this Deed) is not binding on or enforceable in accordance with its terms against a person expressed to be a party to that Debt Document, neither the binding nature nor the enforceability of that provision or any other provision of that Debt Document will be impaired as against the other party(ies) to that Debt Document.

 

8.5 Remedies and waivers

No failure to exercise, nor any delay in exercising, on the part of any Party, any right or remedy under this Deed shall operate as a waiver, nor shall any single or partial exercise of any right or remedy prevent any further or other exercise or the exercise of any other right or remedy. The rights and remedies provided in this Deed are cumulative and not exclusive of any rights or remedies provided by law.

 

12


8.6 Waiver of defences

The provisions of this Deed will not be affected by an act, omission, matter or thing which, but for this Clause 8.6, would reduce, release or prejudice the subordination and priorities expressed to be created by this Deed including (without limitation and whether or not known to any Party):

 

  (a) any time, waiver or consent granted to, or composition with, the Debtor or other person;

 

  (b) the release of the Debtor or any other person under the terms of any composition or arrangement with any creditor of any member of the NCLC Group;

 

  (c) the taking, variation, compromise, exchange, renewal or release of, or refusal or neglect to perfect, take up or enforce, any rights against, or security over assets of, the Debtor or other person or any non-presentation or non-observance of any formality or other requirement in respect of any instrument or any failure to realise the full value of any Security;

 

  (d) any incapacity or lack of power, authority or legal personality of or dissolution or change in the members or status of the Debtor or other person;

 

  (e) any amendment, novation, supplement, extension (whether of maturity or otherwise) or restatement (in each case, however fundamental and of whatsoever nature, and whether or not more onerous) or replacement of a Debt Document or any other document or security;

 

  (f) any unenforceability, illegality or invalidity of any obligation of any person under any Debt Document or any other document or security;

 

  (g) any intermediate Payment of any of the obligation or liabilities owed by the Debtor to the Primary Creditors in whole or in part; or

 

  (h) any insolvency or similar proceedings.

 

8.7 Priorities not affected

Except as otherwise provided in this Deed the priorities referred to in Clause 2 (Priority and Ranking) will:

 

  (a) not be affected by any reduction or increase in the principal amount secured by the Shared Security in respect of the obligations or liabilities owed by the Debtor to the Primary Creditors or by any intermediate reduction or increase in, amendment or variation to any of the Debt Documents, or by any variation or satisfaction of, any of the obligations or liabilities owed the Debtor to the Primary Creditors or any other circumstances;

 

  (b) apply regardless of the order in which or dates upon which this Deed and the other Debt Documents are executed or registered or notice of them is given to any person; and

 

  (c) secure the obligations or liabilities owed by the Debtor to the Primary Creditors in the order specified, regardless of the date upon which any of those liabilities or obligations arose or of any fluctuations in the amount of any of such outstanding liabilities or obligations.

 

13


9. CHANGES TO THE PARTIES

 

9.1 Assignments and transfers

No Party may assign any of its rights and benefits or transfer any of its rights, benefits and obligations in respect of any Debt Documents except as permitted by this Clause 9.

 

9.2 Change of Lender

Any ECF Lender and any Term Loan Lender may assign any of its rights and benefits or transfer by novation any of its rights, benefits and obligations in respect of this Deed if:

 

  (a) the assignee or transferee has executed an Assignment Agreement or Transfer Certificate (as each such term is defined in the ECF Credit Agreement or the relevant Term Loan Credit Agreement) pursuant to which, amongst other things, the assignee or transferee receives the benefit of the rights and agrees that it will perform all of the obligations which are required to be performed by a Lender under the terms of the ECF Credit Agreement or the relevant Term Loan Credit Agreement (as applicable); and

 

  (b) the ECF Lender or Term Loan Lender has complied with the requirements for such assignment or transfer under its ECF Credit Agreement or the relevant Term Loan Credit Agreement, as applicable.

 

9.3 Change of Agent

No person shall become an Agent unless at the same time, it accedes to this Deed as an Agent pursuant to Clause 9.4 (Creditor Accession Undertaking).

 

9.4 Creditor Accession Undertaking

 

  (a) Subject to Clause 9.2 (Change of Lender), any ECF Hedging Creditor, Term Loan Hedging Creditor, or Agent that wishes to become a Party to this Deed in the capacity as a Creditor may become a Party by delivering to the Collateral Agent, a duly completed and executed Creditor Accession Undertaking.

 

  (b) With effect from the date of acceptance by the Collateral Agent of a Creditor Accession Undertaking duly executed and delivered to the Collateral Agent by the relevant acceding party or, if later, the date specified in that Creditor Accession Undertaking:

 

  (i) any Party ceasing entirely to be a Creditor shall be discharged from further obligations towards the Collateral Agent and other Parties under this Deed and their respective rights against one another shall be cancelled (except in each case for those rights which arose prior to that date); and

 

14


  (ii) as from that date, the replacement or new Creditor shall assume the same obligations and become entitled to the same rights, as if it had been an original Party to this Deed in that capacity.

 

9.5 Additional parties

Each of the Parties appoints the Collateral Agent to receive on its behalf each Creditor Accession Undertaking delivered to the Collateral Agent and the Collateral Agent shall, as soon as reasonably practicable after receipt by it, sign and accept the same if it appears on its face to have been completed, executed and, where applicable, delivered in the form contemplated by this Deed.

 

10. POWER OF ATTORNEY

The Debtor and each Creditor irrevocably appoints the Collateral Agent and the Delegate Collateral Agent as its attorney to do anything which such person has authorised the Collateral Agent or the Delegate Collateral Agent to do under this Deed or which such person is required to do under this Deed but has failed to do for a period of five Business Days after receiving notice from Collateral Agent or the Delegate Collateral Agent requiring it to do so.

 

11. AMENDMENTS

 

11.1 No variation or amendment to this Deed shall be valid unless in writing and signed on behalf of each of the Parties.

 

12. THIRD PARTY RIGHTS

 

12.1 Unless expressly provided to the contrary in this Deed, a person who is not a Party has no right under the Contracts (Rights of Third Parties) Act 1999 (the “Third Parties Rights Act”) to enforce or to enjoy the benefit of any term of this Deed.

 

12.2 Notwithstanding any term of this Deed, the consent of any person who is not a Party is not required to rescind or vary this Deed at any time.

 

13. COUNTERPARTS

This Deed may be executed in any number of counterparts and all the counterparts when executed and taken together shall constitute one and the same instrument.

 

14. NOTICES

 

14.1 Communications in Writing

Any communication to be made under or in connection with this Deed shall be made in writing and, unless otherwise stated, may be made by fax or letter.

 

15


14.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 14.1 (Communications in writing), the contact details of each of the parties are as follows:

 

  (a) to the Collateral Agent:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany,

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

  (b) to the Delegate Collateral Agent:

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Fax: +49 40 3769 -9649

E-mail: marcus.weber@commerzbank.com

         anne.randewig@commerzbank.com

 

  (c) to the Agents:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

  (d) to the Credit Parties:

7665 Corporation Center Drive

Miami, Florida 33126

USA

Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

         hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

 

16


O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com,

or to such other address and/or number as is notified in writing by a party to the other parties under this Deed.

 

14.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified on Clause 14.2 (Contact Details) or in the case of the Original ECF Lenders, Original Jade Lenders and Original Jewel Lenders at the addressed identified with its name in Schedule 4 hereto; provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Parties agree that they shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and they shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Agents, the Collateral Agent and the Delegate Collateral Agent shall not be effective until received by them or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Debtor to the Agents, the Collateral Agent or the Delegate Collateral Agent, only if it is addressed in such a manner as the Agents, the Collateral Agent or the Delegate Collateral Agent shall specify for this purpose.

 

15. PERPETUITY PERIOD

 

15.1 The perpetuity period for each trust created by this Deed shall be one hundred and twenty five (125) years from the date of this Deed.

 

16. GOVERNING LAW

This Deed and any non-contractual obligations arising out of or in connection with it are governed by English law.

 

17


17. ENFORCEMENT

 

17.1 Jurisdiction

 

  (a) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Deed (including a dispute relating to the existence, validity or termination of this Deed or any non-contractual obligation arising out of or in connection with this Deed) (a “Dispute”).

 

  (b) The Parties hereto agree that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no Party will argue to the contrary.

 

  (c) This Clause 17.1 is for the benefit of the Secured Parties only. As a result, no Secured Party shall be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, the Secured Parties may take concurrent proceedings in any number of jurisdictions.

 

17.2 Service of process

 

  (a) Without prejudice to any other mode of service allowed under any relevant law the Debtor (unless incorporated in England and Wales):

 

  (i) shall appoint a process agent as its agent for service of process in relation to any proceedings before the English courts in connection with this Deed; and

 

  (ii) agrees that failure by a process agent to notify the Debtor of the process will not invalidate the proceedings concerned;

 

  (b) If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Debtor must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the ECF Facility Agent (or after the ECF Discharge Date, the Term Loan Facility Agents). Failing this, the ECF Facility Agent (or after the ECF Discharge Date, the Term Loan Facility Agents) may appoint another agent for this purpose.

 

  (c) The Debtor expressly agrees and consents to the provisions of this Clause 17 and Clause 16 (Governing Law).

IN WITNESS WHEREOF of which this Deed has been duly executed and delivered on the day and year written above.

 

18


SCHEDULE 1

ECF SECURITY DOCUMENTS

 

1. First-priority legal assignment of contracts dated on or about the date hereof in respect of the Construction Contract, certain of the Refund Guarantees and the Construction Risks Insurance (each as defined in the ECF Credit Agreement) in favour of the Collateral Agent as security trustee on behalf of the ECF Creditors (the “Vessel 2 Assignment of Contracts”).

 

2. First-priority legal assignment of the refund guarantees dated on or about the date hereof in respect of certain of the Refund Guarantees issued by KfW IPEX-Bank GmbH in favour of the Delegate Collateral Agent as security trustee on behalf of the ECF Creditors (the “Vessel 2 Assignment of KfW Refund Guarantees”).

 

3. The ECF 2 Security Trust Deed.

 

19


SCHEDULE 2

TERM LOAN SECURITY DOCUMENTS

 

1. Second-priority legal assignment of contracts dated on or about the date hereof in respect of the Construction Contract, certain of the Refund Guarantees and the Construction Risks Insurance (each as defined in each Term Loan Credit Agreement) in favour of the Collateral Agent as security trustee on behalf of the Term Loan Creditors (the “Term Loan Vessel 2 Assignment of Contracts”).

 

2. Second-priority legal assignment of the refund guarantees dated on or about the date hereof in respect of certain of the Refund Guarantees issued by KfW IPEX-Bank GmbH in favour of the Delegate Collateral Agent as security trustee on behalf of the Term Loan Creditors (the “Term Loan Vessel 2 Assignment of KfW Refund Guarantees”).

 

3. The Jade Security Trust Deed.

 

4. The Jewel Security Trust Deed.

 

20


SCHEDULE 3

FORM OF CREDITOR ACCESSION UNDERTAKING

 

To:    [Insert full name of current Collateral Agent and Delegate Collateral Agent] for
   themselves and each of the other parties to the Intercreditor Deed referred to below.
[To:    [Insert full name of current Agent] as Agent.]
From:    [Acceding Creditor/Agent]

THIS UNDERTAKING is made on [date] by [insert full name of new Creditor / Agent] (the “Acceding [Creditor / Agent]”) in relation to the intercreditor deed (the “Intercreditor Deed”) dated [] between KfW IPEX-Bank GmbH as ECF Facility Agent and Term Loan Facility Agents, the parties named therein as ECF Lenders, the parties named therein as the Jade Lenders, the parties named therein as the Jewel Lenders, Breakaway Two, Ltd. as Debtor, KfW IPEX-Bank GmbH acting as Collateral Agent and Deutsche Schiffsbank Aktiengesellschaft as Delegate Collateral Agent.

Terms defined in the Intercreditor Deed shall, unless otherwise defined in this Undertaking, bear the same meanings when used in this Undertaking.

In consideration of the Acceding [Creditor / Agent] being accepted as a [[ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor]] for the purposes of the Intercreditor Deed, the Acceding [Creditor / Agent] confirms that, as from [date], it intends to be party to the Intercreditor Deed as a [ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor] and undertakes to perform all the obligations expressed in the Intercreditor Deed to be assumed by a [[ECF Facility Agent/Term Loan Facility Agent / ECF Hedging Creditor / Term Loan Hedging Creditor]] and agrees that it shall be bound by all the provisions of the Intercreditor Deed, as if it had been an original party to the Intercreditor Deed.

This Undertaking and any non-contractual obligations arising out of or in connection with it are governed by English law.

THIS UNDERTAKING has been entered into on the date stated above.

 

Acceding [Creditor / Agent]
[EXECUTED as a DEED]
[insert full name of Acceding Creditor / Agent]
By:
Address:
Fax:

 

21


Accepted by the Collateral Agent

 

for and on behalf of
KfW IPEX-Bank GmbH
Date:

 

22


SCHEDULE 4

ADDRESS DETAILS

 

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT     

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Telephone: +49 40 3769 -9646 / -9647

Facsimile: +49 40 3769 -9649

e-mail:    marcus.weber@commerzbank.com

      anne.randewig@commerzbank.com

DNB NOR BANK ASA     

Stranden 21

N-0021 Oslo, Norway

Attn: Amra Koluder / Solveig N. Knoff

Telephone:  +47 22 94 91 17 / 22 94 96 63

Facsimile:   +47 22 48 28 94

e-mail:    amra.koluder@dnbnor.no

      solveig.knoff@dnbnor.no

HSBC BANK PLC     

8 Canada Square

London E14 5HQ

Attn: Alan P. Marshall (FC1354)

Fax no: +44 207 992 4428

e-mail:   alan.p.marshall@hsbcib.com

KFW IPEX-BANK GMBH     

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Telephone: +49 69 7431 4649 / 4037

Fax: +49 69 7431 4466 / 2944

Attn:    Ms Claudia Wenzel /

  Mr Christian Schweiger

email:  claudia.wenzel@kfw.de /

  christian.schweiger@kfw.de

NORDEA BANK NORGE ASA     

Middelthunsgate 17, P.O. Box 1166 Sentrum

NO-0107

Oslo, Norway

Attn: Arne Berglund

Telephone: (47) 22 484193

Facsimile: (47) 22 486668

e-mail:   arne.berglund@nordea.com

 

23


SIGNATORIES

THE ECF FACILITY AGENT

 

Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director

 

24


THE JADE FACILITY AGENT

 
Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


THE JEWEL FACILITY AGENT

 
Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


THE ORIGINAL ECF LENDERS

 
Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:  

 

 

[Signature of Director]

Director

 

[Signature of Director]

Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


THE ORIGINAL JADE LENDERS  
Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:  

 

 

[Signature of Director]

Director

 

[Signature of Director]

Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


THE ORIGINAL JEWEL LENDERS  
Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by DNB NOR BANK ASA, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by HSBC BANK PLC, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


Executed as a deed by NORDEA BANK NORGE ASA, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


THE DEBTOR  
Signed as a deed on behalf of BREAKAWAY TWO, LTD., a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company  

 

 

Authorised [signatory] [signatories]


THE COLLATERAL AGENT

 
Executed as a deed by KFW IPEX-BANK GMBH, acting by [name of director]:  

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


EXHIBIT N

 

THE DELEGATE COLLATERAL AGENT  

Executed as a deed by

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by [name of director]:

 

 

 

[Signature of Director]
Director

 

[Signature of Director]
Director


EXHIBIT M-3

[*]: THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE COMMISSION

DATED             NOVEMBER 2010

PRIDE OF HAWAII, LLC

(as owner)

-and-

HSBC BANK PLC

(as first mortgagee)

-and-

DnB NOR BANK ASA

(as second mortgagee)

-and-

DnB NOR BANK ASA

(as third mortgagee)

-and-

KFW IPEX-BANK GMBH

(as fourth mortgagee)

 

 

FOURTH DEED OF CO-ORDINATION

m.v. NORWEGIAN JADE

 

 

STEPHENSON HARWOOD

One, St Paul’s Churchyard

London EC4M 8SH

Tel: +44 (0)20 7329 4422

Fax: +44 (0)20 7329 7100

Ref: 1253/1647/47-02885/47-02886/47-02887/49-00640


CONTENTS

 

            Page  

1

     Definitions and Interpretation      2   

2

     Consent of Senior Mortgagees      4   

3

     Subordination      4   

4

     Priority      5   

5

     Covenants of the Fourth Mortgagee      6   

6

     Notice to Third Parties      7   

7

     Sale of Vessel      7   

8

     Insurance Proceeds      8   

9

     Payment of Junior Indebtedness      8   

10

     Senior Mortgagees’ Rights      9   

11

     Assignment      9   

12

     Consents and Approvals      9   

13

     Partial Invalidity      10   

14

     Further Assurance      10   

15

     Miscellaneous      10   

16

     Notices      10   

17

     Counterparts      11   

18

     Law and Jurisdiction      11   

SCHEDULE 1

     14   

SCHEDULE 2

     17   

SCHEDULE 3

     23   

SCHEDULE 4

     27   


DEED OF CO-ORDINATION

Dated: November 2010

BETWEEN:

 

(1) PRIDE OF HAWAII, LLC of Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America as owner (the “Owner”);

 

(2) HSBC BANK PLC of 8 Canada Square, London, E14 5HQ as trustee for the parties set out in Schedule 1 (the “First Mortgagee”);

 

(3) DnB NOR BANK ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the Guaranteed Trustees (the “Second Mortgagee”);

 

(4) DnB NOR BANK ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway as trustee for itself and the Non-Guaranteed Trustee (the “Third Mortgagee” and together with the First Mortgagee and the Second Mortgagee the “Senior Mortgagees”); and

 

(5) KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for itself and the parties set out in Schedule 4 (the “Fourth Mortgagee”).

WHEREAS:

 

(A)

The Owner is the absolute owner of all the sixty four sixty fourth (64/64th) shares of and in the motor vessel “NORWEGIAN JADE” (the “Vessel”) registered in the name of the Owner under the Bahamian flag at the port of Nassau with Official Number 9000236.

 

(B) On 10 February 2008 the Owner executed a first priority Bahamian statutory mortgage over all the shares in the Vessel (the “First Mortgage”) in favour of the First Mortgagee in its capacity as trustee for the parties set out in Schedule 1;

 

(C) On 2 April 2009 the Owner executed a second priority Bahamian statutory mortgage over all the shares in the Vessel (the “Second Mortgage”) in favour of the Second Mortgagee in its capacity as trustee for itself and the Guaranteed Trustees;

 

(D) On 2 April 2009 the Owner executed a third priority Bahamian statutory mortgage over all the shares in the Vessel (the “Third Mortgage”) in favour of the Third Mortgagee in its capacity as trustee for itself and the Non-Guaranteed Trustee;

 

(E) The Owner proposes to execute a fourth priority Bahamian statutory mortgage over all of the shares in the Vessel (the “Fourth Mortgage”) upon the terms and conditions therein in favour of the Fourth Mortgagee in its capacity as collateral agent for itself and the parties set out in Schedule 4.

 

(F) The Parties have agreed to enter into this deed of co-ordination (this “Deed”) (among other things) to regulate how the provisions of clause 11 of the collateral deed of covenants to the Fourth Mortgage shall operate.


THIS DEED WITNESSES as follows:

 

1 Definitions and Interpretation

 

  1.1 In this Deed:

Assigned Property” means the Insurances, the Charter and the Earnings.

Bareboat Charterer” means NCL (Bahamas) Ltd.

Business Day” means a day on which banks are open for the transaction of business of the nature contemplated by each Loan Agreement in New York, London, Frankfurt am Main and Oslo.

Charter” means the bareboat charter dated as of 10 February 2008 between the Owner as owner and the Bareboat Charterer as charterer in respect of the Vessel.

Earnings” means all hires, freights, pool income and other sums payable to or for the account of the Owner or the Bareboat Charterer in respect of the Vessel including (without limitation) all remuneration for salvage and towage services, demurrage and detention moneys, contributions in general average, compensation in respect of any requisition for hire, and damages and other payments (whether awarded by any court or arbitral tribunal or by agreement or otherwise) for breach, termination or variation of any contract for the operation, employment or use of the Vessel.

Guaranteed Trustees” means the so-named parties referred to in Schedule 2.

Insurances” means all policies and contracts of insurance (including all entries in protection and indemnity or war risks associations) which are from time to time taken out or entered into in respect of or in connection with the Vessel or her increased value or the Earnings and (where the context permits) all benefits under such contracts and policies, including all claims of any nature and returns of premium.

Junior Indebtedness” means the aggregate from time to time of the indebtedness of the Owner to the Fourth Mortgagee under or pursuant to the Junior Security Documents, whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent. For the avoidance of doubt, indebtedness of persons other than the Owner (including NCLC and Euler Hermes Kreditversicherungs-AG) shall not constitute Junior Indebtedness.

Junior Loan Agreement” means the loan agreement referred to in Schedule 4.

Junior Loans” means the loans made pursuant to the Junior Loan Agreement and “Junior Loan” means any one of them.

Junior Security Documents” means the documents referred to in Schedule 4 and annexed hereto.

Loan Agreement” means each Senior Loan Agreement and the Junior Loan Agreement.

Mandatory Prepayment” means the prepayment of the relevant part of the Junior Loans in full if (a) the construction contract in respect of a New Vessel is terminated prior to the delivery date of such New Vessel (b) the delivery date of the

 

2


relevant New Vessel does not occur on or before (I) in the case of the part of the Junior Loans related to the first New Vessel, 23 December 2013 and (II) in the case of the part of the Junior Loans related to the second New Vessel, 8 December 2014 (c) either new export credit facility to be entered into by the purchasers of the New Vessels shall terminate or (d) certain insolvency events occur with respect to the yard that is building the New Vessels, in each case, as more fully described in and in accordance with the terms of the Junior Loan Agreement.

NCLC” means NCL Corporation Ltd. of Milner House, 18 Parliament Street, Hamilton HM 12, Bermuda.

New Vessels” means the two (2) newbuild cruise vessels each not larger than m.v. “NORWEGIAN EPIC” (ex hull no C33 (sometimes known as D33) at STX France S.A.) in terms of number of passenger cabins or gross or net tonnage, not on order by NCLC or any of its wholly owned subsidiaries on the Effective Date (as defined in supplemental deeds dated 22 July 2010 to each of the Senior Loan Agreements).

Non-Guaranteed Trustee” means the so-named party referred to in Schedule 3.

Party” means each party to this Deed.

Prior Co-ordination Deeds” means the deed dated 2 April 2009 made between (among others) the First Mortgagee, the Second Mortgagee and the Owner in relation to the Senior Security Documents referred to in Schedule 1 and Schedule 2 and the deed dated 2 April 2009 made between (among others) the First Mortgagee, the Second Mortgagee, the Third Mortgagee and the Owner in relation to the Senior Security Documents referred to in Schedule 1, Schedule 2 and Schedule 3.

Security Period” means the period beginning on the date of this Deed and ending on the date when the whole of the Senior Indebtedness has been repaid in full.

Senior Indebtedness” means the aggregate from time to time of the indebtedness of the Owner to the Senior Mortgagees under or pursuant to any of the Senior Security Documents whether in respect of principal, interest, costs or otherwise and whether present, future, actual or contingent.

Senior Loan Agreements” means each loan agreement referred to in Schedule 1, Schedule 2 and Schedule 3 and “Senior Loan Agreement” means any one of them.

Senior Security Documents” means the documents referred to in Schedule 1, Schedule 2 and Schedule 3 and any other document which may at any time be executed by any person as security for the payment of all or any part of the Senior Indebtedness.

Supplemental Deeds” means the supplemental deeds to the Senior Loan Agreements referred to in Schedule 1 and Schedule 2 entered into on or around the date hereof.

 

  1.2 In this Deed:

 

  1.2.1 words denoting the plural number include the singular and vice versa;

 

3


  1.2.2 words denoting persons include corporations, partnerships, associations of persons (whether incorporated or not) or governmental or quasi-governmental bodies or authorities and vice versa;

 

  1.2.3 references to Clauses are references to clauses of this Deed;

 

  1.2.4 references to this Deed include the recitals to this Deed;

 

  1.2.5 the headings and contents page(s) are for the purpose of reference only, have no legal or other significance, and shall be ignored in the interpretation of this Deed;

 

  1.2.6 references to any document are, unless the context otherwise requires, references to that document as amended, supplemented, novated or replaced from time to time; and

 

  1.2.7 references to any party include its successors, transferees and assignees.

 

2 Consent of Senior Mortgagees

On the terms and subject to the conditions contained in this Deed, the Senior Mortgagees consent to the execution and, where appropriate, registration of the Junior Security Documents substantially in the form of the drafts set out in the annexes hereto.

 

3 Subordination

 

  3.1 In consideration of the consent of the Senior Mortgagees contained in Clause 2, the Fourth Mortgagee agrees with the Senior Mortgagees that, at all times during the Security Period, all rights and powers of the Fourth Mortgagee in respect of the Junior Indebtedness and all rights and powers of the Fourth Mortgagee against the Owner, the Vessel and the Assigned Property (whether pursuant to the Junior Security Documents or otherwise) shall be subordinated to all rights and powers of the Senior Mortgagees in respect of the Senior Indebtedness and all rights, powers, discretions and remedies of the Senior Mortgagees under or pursuant to the Senior Security Documents.

 

  3.2 The Owner agrees that its obligations in respect of the Junior Indebtedness are, and shall throughout the Security Period be, subordinated to its obligations in respect of the Senior Indebtedness.

 

  3.3 The Owner and the Fourth Mortgagee agree that no repayments of principal or payments of interest may be made in respect of the Junior Indebtedness during the Security Period, other than:

 

  3.3.1 in the amounts and on the dates set out in the Junior Loan Agreement provided that no repayments of principal or payments of interest may be made in respect of the Junior Indebtedness at any time after a Senior Mortgagee has given notice to the Owner and the Fourth Mortgagee of the occurrence of an event of default (howsoever described in the relevant Senior Loan Agreement); and

 

  3.3.2

a Mandatory Prepayment provided that a Mandatory Prepayment may not be made unless, at the relevant time, (x) the lenders under each of the Senior

 

4


 

Loan Agreements receive evidence satisfactory to them from NCLC that (after giving effect to any contributions from NCLC) the Owner and Norwegian Jewel Limited will be able to meet their respective obligations for the next twelve (12) months under the Senior Loan Agreement referred to in Schedule 1 and the Senior Loan Agreement referred to in Schedule 2, Part III if the Mandatory Prepayment is made and (y) the Senior Mortgagees so agree in accordance with the Supplemental Deeds (if applicable).

 

  3.4 The Fourth Mortgagee undertakes to hold all sums received by it under or pursuant to the Junior Security Documents (other than sums payable to it, or which it is permitted to receive, pursuant to this Deed) on trust for the Senior Mortgagees to be applied by the Senior Mortgagees:

 

  3.4.1 firstly in or towards payment of the Senior Indebtedness; and

 

  3.4.2 secondly by way of payment to the Fourth Mortgagee for application in or towards payment of the Junior Indebtedness as more particularly described in Clause 8.2.3.

 

  3.5 If an Event of Default (as defined in any of the Senior Loan Agreements) shall occur, the relevant Senior Mortgagee shall, as soon as is reasonably practicable after becoming aware of the same, advise the Fourth Mortgagee of the same.

 

  3.6 If an Event of Default (as defined in the Junior Loan Agreement) shall occur, the Fourth Mortgagee shall, as soon as is reasonably practicable after becoming aware of the same, advise the Senior Mortgagees of the same.

 

  3.7 Any certificate or statement signed by an authorised signatory of a Senior Mortgagee purporting to show the amount of the relevant Senior Indebtedness (or any part of the relevant Senior Indebtedness) or any other amount referred to in any of the Senior Security Documents shall, save for manifest error or on any question of law, be conclusive evidence as against the Owner and the Fourth Mortgagee of that amount.

 

  3.8 For the avoidance of doubt the application of monies received by a Senior Mortgagee in relation to the Senior Indebtedness shall be governed and regulated by the Prior Co-ordination Deeds.

 

4 Priority

 

  4.1 The Fourth Mortgagee agrees that the Senior Security Documents shall throughout the Security Period constitute a continuing security for the whole of the Senior Indebtedness, which security shall be senior in priority to the security constituted by the Junior Security Documents, notwithstanding that any of the Senior Indebtedness may have arisen after the execution and/or registration of any of the Junior Security Documents and notwithstanding any fluctuations in the amount of the Senior Indebtedness.

 

  4.2

The Fourth Mortgagee acknowledges the obligation of the Owner to satisfy the marginal security covenant contained in the Senior Loan Agreement referred to in Schedule 1 and irrevocably consents to the granting of the further security referred to in that clause and irrevocably acknowledges that any further security granted

 

5


 

pursuant to that clause will automatically form part of the Senior Security Documents and be subject to all the terms of this Deed applicable to the Senior Security Documents (including, without limitation, Clause 4.1).

 

5 Covenants of the Fourth Mortgagee

 

  5.1 The Fourth Mortgagee covenants with the Senior Mortgagees that during the Security Period:

 

  5.1.1 irrespective of its legal rights, and subject to Clause 5.2, it will not arrest, take possession of, appoint any receiver in respect of, manage or sell the Vessel with or without judicial proceedings, or take any steps to enforce any of its rights under or pursuant to the Junior Security Documents without having first either paid to the Senior Mortgagees the whole of the Senior Indebtedness or obtained the prior written consent of the Senior Mortgagees in accordance with the Supplemental Deeds (if applicable);

 

  5.1.2 it will not take any proceedings to place the Owner into liquidation, administration or receivership nor take any analogous steps without having first either paid to the Senior Mortgagees the whole of the Senior Indebtedness or obtained the prior written consent of the Senior Mortgagees in accordance with the Supplemental Deeds (if applicable); and

 

  5.1.3 it will not contest nor attempt to contest the security constituted by, or any of the rights of any Senior Mortgagee or any party for which a Senior Mortgagee is trustee under or pursuant to, the Senior Security Documents,

PROVIDED THAT nothing in this Clause 5.1 shall prevent the Fourth Mortgagee from filing any action or proceedings necessary for the preservation of its rights, or to avoid the loss of or extinction of any of its rights, nor from demanding payment of any of the Junior Indebtedness or supporting any proceedings arising from or relating to the arrest or detention of the Vessel (whether at the instigation of the Senior Mortgagees or any other person) with a view (in each case) to substantiating, preserving or protecting its interest as fourth mortgagee of the Vessel and/or fourth priority assignee of the Assigned Property, but in any such case the Fourth Mortgagee shall give the earliest possible notice to the Senior Mortgagees of its intention to take such action and shall comply with all requirements of the Senior Mortgagees with respect to the preservation of the Senior Mortgagees’ rights as first priority, second priority and third priority (respectively) mortgagee of the Vessel and as first priority, second priority and third priority (respectively) assignee of the Assigned Property (which shall include the cessation of, or withdrawal by the Fourth Mortgagee from, any proceedings in the event that the Senior Mortgagees so require).

 

  5.2 The Fourth Mortgagee covenants with the Senior Mortgagees that during the Security Period:

 

  (a)

it will procure that there are no amendments, supplements or replacements made to any of the Junior Security Documents which would increase the Euro maximum principal amount of the Junior Loans under the Junior Loan Agreement (or the Dollar equivalent thereof except as provided for by the Junior Loan Agreement as at the date of this Deed) or would increase the margin under the Junior Loan Agreement by more than [*] per annum without in either case the prior written consent of the First Mortgagee and

 

6


 

provided that if such increase were made (i) no provision of a Senior Loan Agreement would be breached and (ii) the Senior Security Documents or the security and other rights constituted and conferred on any Senior Mortgagee by the Senior Security Documents would not, or may not, be prejudiced; and

 

  (b) it will procure that no parties to the Junior Loan Agreement shall seek to secure the payment of any amount (other than an amount due pursuant to the Junior Loan Agreement) by the Junior Security Documents; and

 

  (c) subject to the proviso in Clause 5.1, it shall not take any action or refrain from taking any action as a result of which the Senior Security Documents or the security and other rights constituted and conferred on any Senior Mortgagee by the Senior Security Documents are, or may be, prejudiced.

 

6 Notice to Third Parties

The Fourth Mortgagee undertakes to the Senior Mortgagees that the Fourth Mortgagee will not at any time during the Security Period give any notice to any third party inconsistent with the rights and powers of the Senior Mortgagees under or pursuant to the Senior Security Documents. In particular, but without limitation, any notice of the assignment by the Owner to the Fourth Mortgagee of any of the Assigned Property, and any loss payable clause in favour of the Fourth Mortgagee endorsed on any of the Insurances, shall be expressed as being subject to the prior rights of the Senior Mortgagees as first, second and third assignee respectively and shall be approved by the Senior Mortgagees prior to being given to any third party or endorsed on any of the Insurances.

 

7 Sale of Vessel

 

  7.1 If the Senior Mortgagees decide (in their sole and absolute discretion) to exercise their power of sale of the Vessel, or if the Owner (with the prior consent of the Senior Mortgagees) wishes to sell the Vessel, the Fourth Mortgagee agrees to co-operate fully with the Senior Mortgagees (acting in accordance with the Prior Co-ordination Deeds) and the Owner in connection with that sale by (without limitation) executing all documents required by the Senior Mortgagees not later than the date of completion of the sale to enable the Senior Mortgagees or the Owner to transfer title in the Vessel to the purchaser free of all encumbrances, debts and liens in favour of the Fourth Mortgagee.

 

  7.2 The Senior Mortgagees will give the Fourth Mortgagee reasonable prior notice of any intended sale of the Vessel and a further notice when the price and terms of sale have been agreed in outline but before any binding agreement for the sale has been entered into. The Fourth Mortgagee will within five (5) Business Days from the date of such further notice:

 

  7.2.1 give its consent to the sale at the agreed price and on the agreed terms; or

 

  7.2.2 pay to the relevant Senior Mortgagee a sum equal to the lower of the agreed sale price of the Vessel and the amount of the Senior Indebtedness.

On receipt of payment in full of the sum referred to in Clause 7.2.2 the Senior Mortgagees will at the expense of the Fourth Mortgagee procure the assignment or transfer by the Senior Mortgagees to or to the order of the Fourth Mortgagee of their rights under the Senior Security Documents.

 

7


  7.3 If the Senior Mortgagees do not receive the consent or payment required by Clause 7.2 within the time stipulated by Clause 7.2 the Fourth Mortgagee will be deemed to have given its consent to the proposed sale.

 

  7.4 At or before the time of delivery of the Vessel to any purchaser pursuant to Clause 7.2, notwithstanding Clause 7.1, the Fourth Mortgagee will deliver to the Senior Mortgagees all other documents required by the Senior Mortgagees in recordable form for registration (if necessary) to enable the Senior Mortgagees and/or the Owner to provide the purchaser with evidence that the Vessel is free of all encumbrances, debts and liens in favour of the Fourth Mortgagee.

 

  7.5 The proceeds of any sale of the Vessel by the Senior Mortgagees or by the Owner shall be held in trust by the Senior Mortgagees to be applied as follows:

 

  7.5.1 first, in or towards reimbursement of the expenses of the Senior Mortgagees in connection with the sale, including claims ranking in priority to the claims of the Senior Mortgagees and other costs and claims necessary in the sole and absolute opinion of the Senior Mortgagees for the finalisation of the sale and collection of the sale proceeds;

 

  7.5.2 secondly, in or towards payment of the Senior Indebtedness;

 

  7.5.3 thirdly, by payment to the Fourth Mortgagee for application in or towards payment of the Junior Indebtedness; and

 

  7.5.4 fourthly, by payment to the Owner and/or to anyone else entitled to them.

 

8 Insurance Proceeds

 

  8.1 The parties to this Deed agree that the proceeds of the Insurances shall be applied in accordance with the loss payable clause(s) endorsed on the Insurances from time to time.

 

  8.2 All proceeds of the Insurances received by the Senior Mortgagees shall be held in trust by the Senior Mortgagees to be applied as follows:

 

  8.2.1 first, in or towards reimbursement of the expenses of the Senior Mortgagees in connection with the collection of the proceeds;

 

  8.2.2 secondly, by application in or towards payment of the Senior Indebtedness or otherwise in accordance with the Senior Security Documents;

 

  8.2.3 thirdly, by payment to the Fourth Mortgagee for application in or towards payment of the Junior Indebtedness or otherwise in accordance with the Junior Security Documents; and

 

  8.2.4 fourthly, by payment to the Owner and/or to anyone else entitled to them.

 

9 Payment of Junior Indebtedness

Promptly following payment to the Fourth Mortgagee of the full amount of the Junior Indebtedness the Fourth Mortgagee will do whatever is necessary to discharge the Junior Security Documents and to release the Owner from any further obligations under or pursuant to the Junior Security Documents.

 

8


10 Senior Mortgagees’ Rights

 

  10.1 Subject to the Prior Co-ordination Deeds, any Senior Mortgagee may at any time and from time to time without prejudicing its rights under or pursuant to this Deed or the Senior Security Documents and without consulting with or obtaining the consent of the Fourth Mortgagee:

 

  10.1.1 amend, supplement or replace any of the Senior Security Documents or agree to do so (other than any amendment which would increase the maximum principal amount of any loan under a Senior Loan Agreement in respect of which the consent of the Fourth Mortgagee shall be required);

 

  10.1.2 (subject to Clause 11.2), assign, novate, transfer or grant participations in the Senior Indebtedness or its rights under or pursuant to the Senior Security Documents;

 

  10.1.3 allow to the Owner or any other person time or indulgence (including, without limitation, allowing delayed repayments under the relevant Senior Loan Agreement);

 

  10.1.4 renew, vary, release or refrain from enforcing or exercising its rights under the Senior Security Documents; or

 

  10.1.5 compound with the Owner.

 

  10.2 No failure to exercise, nor delay in exercising, on the part of a Senior Mortgagee, any right or remedy under or pursuant to any of the Senior Security Documents, nor any actual or alleged course of dealing between a Senior Mortgagee and the Owner, shall operate as a waiver of, or acquiescence in, any default on the part of the Owner unless expressly agreed to in writing by the Senior Mortgagee, nor shall any single or partial exercise by a Senior Mortgagee of any right or remedy preclude any other or further exercise of that right or remedy, or the exercise by the Senior Mortgagee of any other right or remedy.

 

11 Assignment

 

  11.1 The Fourth Mortgagee shall not assign nor transfer any of its right, title or interest in any of the Junior Security Documents without, in each case, the Fourth Mortgagee having first procured that any such assignee or transferee will comply with, agree to be bound by and perform all of the obligations of the Fourth Mortgagee under this Deed.

 

  11.2 None of the Senior Mortgagees shall assign nor transfer any of its right, title or interest in any of the Senior Security Documents without that Senior Mortgagee having first procured that any such assignee or transferee will comply with, agree to be bound by and perform all of the obligations of that Senior Mortgagee under this Deed.

 

12 Consents and Approvals

Where any act requires the consent or approval of the Senior Mortgagees under the terms of any of the Senior Security Documents and the same or a similar act requires the consent or approval of the Fourth Mortgagee under any of the Junior Security Documents, the consent or approval of the Senior Mortgagees shall be deemed also to constitute the consent or approval of the Fourth Mortgagee.

 

9


13 Partial Invalidity

If, at any time, any provision of this Deed is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions nor the legality, validity or enforceability of such provision under the law of any other jurisdiction will in any way be affected or impaired.

 

14 Further Assurance

If, at any time, any provision of this Deed is or becomes invalid or unenforceable in whole or in part by reason of any present or future law or any decision of any court, then from time to time the Owner and the Fourth Mortgagee will each promptly, on demand by the Senior Mortgagees and at the cost of the Owner, execute and deliver to the Senior Mortgagees, or procure the execution and delivery to the Senior Mortgagees of, such further documents as in the opinion of the Senior Mortgagees are necessary to give effect to the terms of this Deed.

 

15 Miscellaneous

 

  15.1 The rights of the Senior Mortgagees under or pursuant to this Deed shall not be affected by any change in the constitution of the Owner or by the liquidation, bankruptcy or insolvency of the Owner.

 

  15.2 No variation or amendment of this Deed shall be valid unless in writing and signed on behalf of each of the Parties.

 

  15.3 Other than the parties set out in Schedule 1, Schedule 2, Schedule 3 and Schedule 4, a person who is not a party to this Deed has no right under the Contracts (Rights of Third Parties) Act 1999 to enforce or to enjoy the benefit of any term of this Deed.

 

16 Notices

 

  16.1 Any communication to be made under or in connection with this Deed shall be made in writing in the English language and sent by fax or letter addressed:

 

  16.1.1 in the case of a Senior Mortgagee to it at its address as set out in Schedule 1, Schedule 2 or Schedule 3 of this Deed (as the case may be); and

 

  16.1.2 in the case of the Fourth Mortgagee to it at Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany (marked for the attention of Claudia Wenzel / Mr Christian Schweiger at fax no: +49 69 7431 3768 / 2944 and email: claudia.wenzel@kfw.de / christian.schweiger@kfw.de); and

 

  16.1.3

in the case of the Owner to it at c/o 7665 Corporate Center Drive, Miami, Florida 33126, United States of America (marked for the attention of the Chief Financial Officer and the Legal Department) (but one (1) copy shall suffice) with a copy to the Investors c/o Apollo Management, LP, 9 West 57th Street, 43rd Floor, New York, NY 10019,

 

10


 

United States of America (marked for the attention of Mr Steve Martinez) (fax no: +1 305 436 4140 (marked for the attention of the Chief Financial Officer) and +1 305 436 4117 (marked for the attention of the Legal Department) with a copy to (i) the Investors c/o Apollo Management, LP at +1 212 515 3288 (marked for the attention of Mr Steve Martinez) and (ii) O’Melveny & Myers LLP at fax no. +1 212 326 2061 (marked for the attention of Mr Brad Finkelstein));

or to such other address and/or fax number as any Party may designate for itself by written notice to the others provided that if the copy of any communication is not received by the addressee, it shall not affect the deemed making or delivery of the communication.

 

  16.2 Any communication made pursuant to Clause 16.1 will only be effective:

 

  16.2.1 if by way of fax, when received in legible form; or

 

  16.2.2 if by letter, when it has been left at the relevant address or five (5) days after being deposited in the post postage prepaid in an envelope addressed to the relevant address.

 

17 Counterparts

This Deed may be executed in any number of counterparts, and this has the same effect as if the signatures on the counterparts were on a single copy of this Deed.

 

18 Law and Jurisdiction

 

  18.1 This Deed and any non-contractual obligations arising from or in connection with it shall in all respects be governed by and interpreted in accordance with English law.

 

  18.2 For the exclusive benefit of the Senior Mortgagees, the parties to this Deed irrevocably agree that the courts of England are to have exclusive jurisdiction to settle any dispute:

 

  18.2.1 arising from or in connection with this Deed; or

 

  18.2.2 relating to any non-contractual obligations arising from or in connection with this Deed and that any proceedings may be brought in those courts.

 

  18.3 Nothing contained in this Clause shall limit the right of the Senior Mortgagees to commence any proceedings under or pursuant to this Deed in any other court of competent jurisdiction nor shall the commencement of any proceedings against the Owner or the Fourth Mortgagee in one or more jurisdictions preclude the commencement of any proceedings in any other jurisdiction, whether concurrently or not.

 

  18.4 The Owner and the Fourth Mortgagee each irrevocably waives any objection which it may now or in the future have to the laying of the venue of any proceedings in any court referred to in this Clause and any claim that those proceedings have been brought in an inconvenient or inappropriate forum, and irrevocably agrees that a judgment in any proceedings commenced in any such court shall be conclusive and binding on it and may be enforced in the courts of any other jurisdiction.

 

11


  18.5 Without prejudice to any other mode of service allowed under any relevant law:

 

  18.5.1 the Owner irrevocably appoints EC3 Services Limited whose registered office is presently at 51 Eastcheap, London EC3M 1JP as its agent for service of process in relation to any proceedings before the English courts;

 

  18.5.2 the Fourth Mortgagee irrevocably appoints its London office presently at 29th Floor, Abbey Business Centre, 30 St Mary Axe, London EC3A 8EP as its agent for service of process in relation to any proceedings before the English courts; and

 

  18.5.3 the Owner and the Fourth Mortgagee each agrees that failure by a process agent to notify it of the process will not invalidate the proceedings concerned.

IN WITNESS of which this Deed has been duly executed and delivered the day and year first before written.

 

SIGNED and DELIVERED as a DEED

  )

by PRIDE OF HAWAII, LLC

  )

acting by

  )
  )

its duly authorised attorney-in-fact

  )
  )

in the presence of:

  )

SIGNED and DELIVERED as a DEED

  )

by HSBC BANK PLC

  )

as the First Mortgagee

  )

acting by Danae Zoi Mariel Ugolini

  )
  )

its duly authorised attorney-in-fact

  )
  )

in the presence of:

  )

 

12


SIGNED and DELIVERED as a DEED

  )

by DnB NOR BANK ASA

  )

as the Second Mortgagee

  )

acting by Danae Zoi Mariel Ugolini

  )
  )

its duly authorised attorney-in-fact

  )
  )

in the presence of:

  )

SIGNED and DELIVERED as a DEED

  )

by DnB NOR BANK ASA

  )

as the Third Mortgagee

  )

acting by Danae Zoi Mariel Ugolini

  )
  )

its duly authorised attorney-in-fact

  )
  )

in the presence of:

  )

SIGNED and DELIVERED as a DEED

  )

by KFW IPEX-BANK GMBH

  )

as the Fourth Mortgagee

  )

acting by

  )
  )

its duly authorised

  )
  )

in the presence of:

  )

 

13


SCHEDULE 1

Senior Security Documents

First Priority Mortgage and Collateral Deed of Covenants each dated 10 February 2008

First Assignment of Insurances dated 19 April 2006

First Charter and/or Earnings Assignments dated 18 October 2004 and 10 February 2008

Deeds of Assignment and Subordination dated 10 February 2008 and 16 June 2008

EUR308,130,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated from time to time

 

Trustee

HSBC BANK PLC

Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
(as trustee and agent)
COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 1362 3742
Attn:   Mr Klaus-Dieter Schmedding
Email:   exportfinance@commerzbank.com
(as Hermes agent)

 

14


and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:   +49 40 3769 9649
Attn:   Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:   shipfinance@commerzbank.com
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:   +44 (0)20 7992 4428
Attn:   Mr Alan Marshall
Email:   alan.p.marshall@hsbcib.com
KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 7431 3768/2944
Attn:   Mr Josef Schmid/Ms Claudia Wenzel
Email:   josef.schmid@kfw.de/claudia.wenzel@kfw.de
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:   +47 22 482020
Attn:   Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:   amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
NORDDEUTSCHE LANDESBANK GIROZENTRALE
Friedrichswall 10
30159 Hannover
Federal Republic of Germany
Fax:   +49 511 361 4785
Attn:   Mr Torsten Reinecke
Email:   shipping@nordlb.de

 

15


CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK
Taunusanlage 14
60325 Frankfurt am Main
Federal Republic of Germany
Fax:   +49 69 74221 197
Attn:   Mr Stephan Bachmann
Email:   stephan.bachmann@ca-cib.com
with a copy to:
CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:   +852 2868 1448
Attn:   Mr Terence Yuen/Ms Iris Lai
Email:   terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

16


SCHEDULE 2

Senior Security Documents

Guarantee of the Owner dated 2 April 2009

Second Priority Mortgage and Collateral Deed of Covenants each dated 2 April 2009

Second Assignment of Insurances dated 2 April 2009

Second Charter and Earnings Assignment dated 2 April 2009

Second Assignment and Subordination dated 2 April 2009

Part I

EUR258,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)
COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

 

17


and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email: shipfinance@commerzbank.com
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email: alan.p.marshall@hsbcib.com
KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

Part II

EUR40,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

 

18


As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)
COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)
and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com
KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

19


DVB BANK SE
Parklaan 2
3016 BB Rotterdam
The Netherlands
Fax:    +5999 4652366
Attn:    LAM/Eric Maduro
Email:    lam.curacao@dvbbank.com/james.neira@dvbbank.com

Part III

USD334,050,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

 

Trustee
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
As trustee for:
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)
COMMERZBANK
AKTIENGESELLSCHAFT
Corporate Banking
Structured Export and Trade Finance
Kaiserplatz
60261 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

 

20


and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Federal Republic of Germany
Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
KFW
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
OVERSEA-CHINESE BANKING
CORPORATION LIMITED
Singapore Branch
65 Chulia Street #10-00
Singapore 049513
Fax:    +65 6536 6449/6532 5347
Attn:    Ms Lee King Lan/Ms Elaine Lam
Email:    LeeKingLan@ocbc.com/LamSYElaine@ocbc.com

 

21


NORDDEUTSCHE LANDESBANK GIROZENTRALE
Friedrichswall 10
30159 Hannover
Federal Republic of Germany
Fax:    +49 511 361 4785
Attn:    Mr Torsten Reinecke
Email:    shipping@nordlb.de
CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK
Taunusanlage 14
60325 Frankfurt am Main
Federal Republic of Germany
Fax:    +49 69 74221 197
Attn:    Mr Stephan Bachmann
Email:    stephan.bachmann@ca-cib.com
with a copy to:
CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:    +852 2868 1448
Attn:    Mr Terence Yuen/Ms Iris Lai
Email:    terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

22


SCHEDULE 3

Senior Security Documents

Guarantee of the Owner dated 2 April 2009

Third Priority Mortgage and Collateral Deed of Covenants each dated 2 April 2009

Third Assignment of Insurances dated 2 April 2009

Third Charter and Earnings Assignment dated 2 April 2009

Third Assignment and Subordination dated 2 April 2009

EUR624,000,000 Secured Loan Agreement dated 7 October 2005 as amended

and/or restated from time to time

 

Non-Guaranteed Trustee
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:    +47 22 482894
Attn:    Mrs Solveig Nuland Knoff
Email:    solveig.knoff@dnbnor.no
As trustee for:
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:    +47 22 482894
Attn:    Mrs Solveig Nuland Knoff
Email:    solveig.knoff@dnbnor.no
(as security agent and agent)
and the following as lenders:
COMMERZBANK AKTIENGESELLSCHAFT
Global Shipping
Domstrasse 18
20095 Hamburg
Germany
Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/
   Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

 

23


DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
KFW IPEX-BANK GMBH
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de
NORDDEUTSCHE LANDESBANK GIROZENTRALE
Friedrichswall 10
30159 Hannover
Germany
Fax:    +49 511 361 4785
Attn:    Mr Torsten Reinecke
Email:    shipping@nordlb.de
NORDEA BANK NORGE ASA
Middelthuns gate 17
Oslo
P O Box 1166 Sentrum
NO-0107 Oslo
Norway
Fax:    +47 22 484278
Attn:    Mr Arne Berglund
Email:    arne.berglund@nordea.com
BANK OF SCOTLAND PLC
Marine Finance
Second Floor
New Uberior House
11 Earl Grey Street
Edinburgh EH3 9BN
Scotland
Fax:    +44 131 659 1194
Attn:    Douglas Newton/Russell Parker
Email:    douglas_newton@bankofscotland.co.uk

 

24


UNICREDIT BANK AG
(formerly known as Bayerische Hypo- und
Vereinsbank AG)
Alter Wall 22
20457 Hamburg
Germany
Fax:    +49 40 3692 3696/+49 89 378 334 2832
Attn:    Mr Peter-Alexander Wunner/
   Mr Michael McCarthy
Email:    peter-alexander.wunner@unicreditgroup.de/
   michael.mccarthy@unicreditgroup.de
DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT
Bremen and Hamburg
Domshof 17
28195 Bremen
Germany
Fax:    +49 421 3609 329
Attn:    Dr Matthias Fischer
Email:    matthias.fischer@schiffsbank.com
FOKUS BANK
(being the Norwegian branch of Danske Bank A/S)
Stortingsgaten 6
P O Box 1170 Sentrum
NO-0107 Oslo
Norway
Fax:    +47 85 407990
Attn:    Mr Øivind Haraldsen/Mr Tore Thorlacius Braein
Email:    oivind.haraldsen@fokus.no/
   tore.braein@fokus.no
HSH NORDBANK AG
Gerhart-Hauptmann-Platz 50
20095 Hamburg
Germany
Fax:    +49 40 3333 613741
Attn:    Mr Carsten Dreyer
Email:    carsten.dreyer@hsh-nordbank.com
Fax:    +1 212 407 6008
Attn:    Ms Frauke Hay
Email:    frauke.hay@hsh-nordbank.com

 

25


SKANDINAVISKA ENSKILDA BANKEN AB (publ)
Kungsträdgårdsgatan 8
SE-106 40 Stockholm
Sweden
Fax:    +44 20 7236 5144
Attn:    Mr Egil Aarrestad/Mr Malcolm Stonehouse
Email:    egil.aarrestad@seb.co.uk/
   malcolm.stonehouse@seb.co.uk

 

26


SCHEDULE 4

Junior Security Documents

Fourth Priority Mortgage and Collateral Deed of Covenants

Fourth Assignment of Intercompany Charters

Fourth Assignment of Insurances

Fourth Assignment of Earnings

Credit Agreement dated November 2010, among Pride of Hawaii, LLC as borrower, NCL Corporation Ltd. as guarantor, KfW IPEX-Bank GmbH as facility agent, collateral agent and CIRR agent and the lenders party thereto from time to time for the lesser of:

 

(x) the sum of:

 

  (I) 10% of the initial construction prices of the New Vessels; and

 

  (II) 100% of the total aggregate amounts payable by the Owner to Commerzbank Aktiengesellschaft (the “Hermes Agent”) in relation to the Junior Loans in respect of the Hermes cover for such loans (the “New Hermes Fees”);

 

(y) the sum of:

 

  (I) EUR123,000,000; and

 

  (II) EUR3,075,000 provided that such aggregate sum of EUR126,075,000 is subject to reduction to [*] plus the New Hermes Fees if the said Hermes cover shall so provide; and

 

(z) when aggregated with the sum to be borrowed by Norwegian Jewel Limited under a credit agreement of the same date as, and on similar terms to, the credit agreement referred to above, USD224,770,000 (or such higher Dollar cap as may be later agreed between the lead arrangers of the Junior Loans and NCLC) provided that the maximum amount of the Junior Loans available to the Owner for drawing shall not exceed USD94,576,192.83 unless the Dollar cap of USD224,770,000 is so increased,

to finance in part the acquisition of the New Vessels by two (2) wholly owned subsidiaries of NCLC and related fees.

Trustee

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

27


As trustee for:
DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT
(an affiliate of Commerzbank AG)
Global Shipping
Domstrasse 18
D - 20095 Hamburg
Germany
Telephone: +49 40 3769 9646/9647
Facsimile: +49 40 3769 9649
Attn:    Mr Marcus Weber/Mrs Anne Randewig
Email:    marcus.weber@commerzbank.com/anne.randewig@commerzbank.com
DnB NOR BANK ASA
Stranden 21
NO-0021 Oslo
Norway
Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no
HSBC BANK PLC
Project and Export Finance
8 Canada Square
London E14 5HQ
Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
KFW IPEX-BANK GMBH
Palmengartenstrasse 5-9
60325 Frankfurt am Main
Germany
Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de
NORDEA BANK NORGE ASA
Middelthuns gate 17
Oslo
P O Box 1166 Sentrum
NO-0107 Oslo
Norway
Fax:    +47 22 484278
Attn:    Mr Arne Berglund
Email:    arne.berglund@nordea.com

 

28


LOGO

 

 

EXHIBIT N

Dated [] 2010

FORM OF JADE SECURITY TRUST DEED

between

KFW IPEX-BANK GMBH

as Collateral Agent

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

as Delegate Collateral Agent

KFW IPEX-BANK GMBH

as Facility Agent

PRIDE OF HAWAII, LLC

as Company

NCL CORPORATION LTD.

as Parent

and

OTHERS

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


TABLE OF CONTENTS

 

          Page  

1.

   DEFINITIONS AND INTERPRETATION      1   

2.

   TRUSTEE FOR THE SECURED CREDITORS      6   

3.

   APPLICATION OF PROCEEDS      7   

4.

   SECURED CREDITORS’ UNDERTAKINGS      9   

5.

   CREDIT PARTIES’ UNDERTAKINGS      10   

6.

   AGENT’S RIGHTS AND DUTIES      11   

7.

   APPOINTMENT AND REMOVAL OF AGENTS      19   

8.

   CHANGE OF PARTIES      21   

9.

   FEES AND EXPENSES      21   

10.

   AMENDMENTS AND RELEASES      22   

11.

   TERMINATION OF THE TRUSTS      23   

12.

   REMEDIES AND WAIVERS      23   

13.

   ADDITIONAL PROVISIONS      23   

14.

   NOTICES      25   

15.

   GOVERNING LAW AND JURISDICTION      27   

16.

   COUNTERPARTS AND EFFECTIVENESS      28   

SCHEDULE 1 ORIGINAL SECURED CREDITORS

     29   

SCHEDULE 2 FORM OF SECURED CREDITOR ACCESSION UNDERTAKING

     30   


THIS DEED is made on                      2010

BETWEEN:

 

(1) PRIDE OF HAWAII, LLC, a Delaware limited liability company with its registered office at Corporate Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Company”);

 

(2) NCL CORPORATION LTD., a Bermuda company with its registered office at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Parent” and together with the Company, the “Credit Parties”);

 

(3) The financial institutions listed in Schedule 1 as Secured Creditors (together with the Collateral Agent and the Delegate Collateral Agent, the “Original Secured Creditors”);

 

(4) KFW IPEX-BANK GMBH as facility agent for the Lender Creditors (the “Facility Agent”);

 

(5) KFW IPEX-BANK GMBH as trustee for the Secured Creditors (the “Collateral Agent”, which expression includes any additional or successor Collateral Agent appointed pursuant to and in accordance with the terms of this Deed); and

 

(6) DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT as trustee for the Secured Creditors (the “Delegate Collateral Agent”, which expression includes any additional or successor Delegate Collateral Agent appointed pursuant to and in accordance with the terms of this Deed).

RECITALS:

 

(A) The Lenders are willing to make certain credit facilities available to the Company on the terms and subject to the conditions set out in the Credit Agreement, one of those conditions being that the Company enters into this Deed.

 

(B) The Collateral Agent holds the Transaction Security (excluding the KfW Assignments) on trust for itself and the other Secured Creditors on the terms of this Deed.

 

(C) The Delegate Collateral Agent holds the KfW Assignments on trust for itself and the other Secured Creditors on the terms of this Deed.

IT IS AGREED as follows:

 

1. DEFINITIONS AND INTERPRETATION

 

1.1 Definitions

In this Deed the following terms have the meanings given to them in this Clause 1.1.

Agents” means the Collateral Agent and the Delegate Collateral Agent.


Credit Agreement” means the €126,075,000 credit agreement made between the Parent, the Company, the Lenders and others effective 18 November 2010.

Credit Document Obligations” has the meaning given in the Credit Agreement.

Delegate” means any delegate, agent or attorney appointed by the Collateral Agent, pursuant to and in accordance with the terms of this Deed.

Discharge Date” means the date on which all the Secured Obligations have been fully discharged and none of the Lender Creditors is under any obligation (whether actual or contingent, other than (i) contingent obligations for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement) to make advances or provide other financial accommodation to any of the Credit Parties under the Credit Documents.

“ECF Vessel 1 Assignment of Contracts” means the “Assignment of Contracts” under and as defined in the Breakaway One Facility.

“ECF Vessel 1 Assignment of KfW Refund Guarantees” means the “Assignment of KfW Refund Guarantees” under and as defined in the Breakaway One Facility.

“ECF Vessel 2 Assignment of Contracts” means the “Assignment of Contracts” under and as defined in the Breakaway Two Facility.

“ECF Vessel 2 Assignment of KfW Refund Guarantees” means the “Assignment of KfW Refund Guarantees” under and as defined in the Breakaway Two Facility.

Jade Shared Security” means the assets which are expressed to be the subject of the Security created or evidenced or expressed to be created or evidenced under or pursuant to the Jade Shared Security Documents.

“Jade Shared Security Documents” means

 

  (a) the Assignment of Charter and Earnings;

 

  (b) the Charterer’s Assignment and Subordination; and

 

  (c) the Assignment of Insurances.

KfW Assignments” means (a) the Term Loan Vessel 1 Assignment of KfW Refund Guarantees and (b) the Term Loan Vessel 2 Assignment of KfW Refund Guarantees.

Other Obligations” has the meaning given in the Credit Agreement.

Party” means a party to this Deed.

Receiver” means a receiver and manager or any other receiver (whether appointed pursuant to this Deed or any statute, by a court or otherwise) of all or any of the Trust Property and the Trust Property Delegated and shall, where permitted by law, include an administrative receiver.

 

2


Secured Creditors” means (a) the Original Secured Creditors, (b) any Receiver or Delegate, (c) any additional or successor Agents appointed pursuant to and in accordance with the terms of this Deed, (d) any Term Loan Hedging Creditor that has acceded to this Deed by delivery of a Secured Creditor Accession Undertaking to the Collateral Agent and (e) any successor Facility Agent or permitted assignee, permitted transferee of a Lender or permitted transferee of a Term Loan Hedging Creditor that has acceded to this Deed by (i) delivery of a Secured Creditor Accession Undertaking to the Collateral Agent or (ii) delivery of a Transfer Certificate or Assignment Agreement to the Facility Agent.

Secured Creditor Accession Undertaking” means an undertaking substantially in the form set out in Schedule 2 (Form of Secured Creditor Accession Undertaking) of this Deed.

Secured Obligations” means the Credit Document Obligations and the Other Obligations.

Security” means a mortgage, charge, pledge, lien or other security interest securing any obligation of any person or any other agreement or arrangement having a similar effect.

Term Loan Hedging Agreements” means any Term Loan Interest Rate Protection Agreement and any Term Loan Other Hedging Agreement to the extent secured by the Term Loan Collateral.

Term Loan Hedging Creditors” means each Lender or affiliate thereof that may at any time and from time to time enter into one or more Term Loan Hedging Agreements and which becomes a Party to this Deed pursuant to Clause 8.3 (New Hedging Creditor), even if the respective Lender subsequently ceases to be a Lender under the Credit Agreement for any reason, together with such Lender’s or affiliate’s successors and assigns, if any.

Term Loan Interest Rate Protection Agreement” means Interest Rate Protection Agreement as defined in the Credit Agreement.

Term Loan Collateral” means the Collateral as defined in the Credit Agreement.

Term Loan Other Hedging Agreement” means “Other Hedging Agreement” as defined in the Credit Agreement.

Term Loan Vessel 1 Assignment of Contracts” means the “Vessel 1 Assignment of Contracts” as defined in the Credit Agreement.

Term Loan Vessel 1 Assignment of KfW Refund Guarantees” means the “Vessel 1 Assignment of KfW Refund Guarantee” as defined in the Credit Agreement.

Term Loan Vessel 2 Assignment of Contracts” means the “Vessel 2 Assignment of Contracts” as defined in the Credit Agreement.

Term Loan Vessel 2 Assignment of KfW Refund Guarantees” means the “Vessel 2 Assignment of KfW Refund Guarantee” as defined in the Credit Agreement.

 

3


Transaction Security” means the security created or expressed to be created in favour of the relevant Agent pursuant to the Term Loan Vessel 1 Assignment of Contracts, the Term Loan Vessel 2 Assignment of Contracts, the Jade Shared Security Documents, the KfW Assignments and any other agreement which is governed by the laws of England and Wales and which creates or purports to create Security in favour of the Secured Creditors.

Trust Property” means all rights, interests, benefits and other property comprised in the Transaction Security (excluding the KfW Assignments) and the proceeds thereof including without limitation:

 

  (a) any rights, interests or other property and the proceeds thereof from time to time assigned, transferred, mortgaged, charged, or pledged to or otherwise vested in the Collateral Agent under, pursuant to or in connection with this Deed or any Credit Document to which the Collateral Agent is a party;

 

  (b) any representation, obligation, covenant, warranty or other contractual provision in favour of the Collateral Agent (other than any made or granted solely for its own benefit) made or granted in or pursuant to any of the Credit Documents to which the Collateral Agent is a party;

 

  (c) any sum which is received or recovered by the Collateral Agent under, pursuant to or in connection with any of the Credit Documents or the exercise of any of the Collateral Agent’s powers under or in connection therewith (other than any sum received or recovered solely for its own account) and which is held by the Collateral Agent upon trust on the terms of this Deed or any of the Credit Documents to which the Collateral Agent is a party; and

 

  (d) all income and other sums at any time received or receivable by the Collateral Agent in respect of the other Trust Property or any part thereof.

Trust Property Delegated” means all rights, interests, benefits and other property comprised in the KfW Assignments and the proceeds thereof including without limitation:

 

  (a) any rights, interests or other property and the proceeds thereof from time to time assigned, transferred, mortgaged, charged, or pledged to or otherwise vested in the Delegate Collateral Agent under, pursuant to or in connection with this Deed or the KfW Assignments;

 

  (b) any representation, obligation, covenant, warranty or other contractual provision in favour of the Delegate Collateral Agent (other than any made or granted solely for its own benefit) made or granted in or pursuant to any of the KfW Assignments;

 

  (c) any sum which is received or recovered by the Delegate Collateral Agent under, pursuant to or in connection with any of the KfW Assignments or the exercise of any of the Delegate Collateral Agent’s powers under or in connection therewith (other than any sum received or recovered solely for its own account) and which is held by the Delegate Collateral Agent upon trust on the terms of this Deed or any the KfW Assignments; and

 

4


  (d) all income and other sums at any time received or receivable by the Delegate Collateral Agent in respect of the other Trust Property Delegated or any part thereof.

Trustee Acts” means the Trustee Act 1925 and the Trustee Act 2000.

Vessel 1 Shared Security” means the assets which are expressed to be the subject of the Security created or evidenced or expressed to be created or evidenced under or pursuant to the Vessel 1 Shared Security Documents.

Vessel 1 Shared Security Documents” means:

 

  (a) the Term Loan Vessel 1 Assignment of Contracts;

 

  (b) the Term Loan Vessel 1 Assignment of KfW Refund Guarantees;

 

  (c) the ECF Vessel 1 Assignment of Contracts; and

 

  (d) the ECF Vessel 1 Assignment of KfW Refund Guarantees.

Vessel 2 Shared Security” means the assets which are expressed to be the subject of the Security created or evidenced or expressed to be created or evidenced under or pursuant to the Vessel 2 Shared Security Documents.

Vessel 2 Shared Security Documents” means:

 

  (a) the Term Loan Vessel 2 Assignment of Contracts;

 

  (b) the Term Loan Vessel 2 Assignment of KfW Refund Guarantees;

 

  (c) the ECF Vessel 2 Assignment of Contracts; and

 

  (d) the ECF Vessel 2 Assignment of KfW Refund Guarantees.

 

1.2 Defined Terms

Unless this Deed provides otherwise, a term which is defined (or expressed to be subject to a particular construction) in the Credit Agreement shall have the same meaning (or be subject to the same construction) in this Deed.

 

1.3 References to Agreements

Unless otherwise stated, any reference in this Deed to any agreement or document (including any reference to this Deed or any other Credit Document or to any agreement or document entered into pursuant to or in accordance with such agreement or document) shall be construed as a reference to:

 

  (a) such agreement or document as amended, restated, varied, novated or supplemented from time to time; and

 

  (b) any agreement or document whereby such agreement or document is so amended, restated, varied, novated or supplemented or which is entered into pursuant to or in accordance with such agreement or document.

 

5


1.4 Certificates

A certificate of any Secured Creditor as to the amount of any Secured Obligation owed to it shall be prima facie evidence of the existence and amount of such Secured Obligation.

 

1.5 Statutes

Any reference in this Deed to a statute or statutory provision shall, unless the contrary is indicated, be construed as a reference to such statute or statutory provision as the same shall have been or may be amended or re-enacted.

 

1.6 Third Party Rights

 

  (a) A person which is not a party to this Deed (a “third party”) shall have no rights to enforce the provisions of this Deed save for those rights it would have had if the Contracts (Rights of Third Parties) Act 1999 had not come into effect provided that each of Clause 5.1 (Credit Parties’ Indemnity to Agents), Clause 9.1 (Transaction and Enforcement Expenses) and Clause 13.3 (Currency Indemnity) shall be enforceable by any third party referred to in such clause as if such third party were a party to this Deed.

 

  (b) The Parties to this Deed may vary or rescind this Deed without the consent of any third party.

 

1.7 Clause and Schedule Headings

 

  (a) Unless otherwise stated, any reference in this Deed to a Clause or a Schedule shall be construed as a reference to a clause of or a schedule to this Deed.

 

  (b) Clause and Schedule headings are for ease of reference only and shall not affect the construction of this Deed.

 

2. TRUSTEE FOR THE SECURED CREDITORS

 

2.1 Declaration of Trust by Collateral Agent

To the extent the Trust Property is not transferred, charged or granted to the Collateral Agent on trust pursuant to the Credit Documents, and subject to the provisions of Clause 2.3 (Non-Trust Jurisdictions), the Collateral Agent declares itself trustee of the Trust Property to hold the same on trust for the Secured Creditors for the purpose of securing the Secured Obligations on the terms and subject to the conditions set out in this Deed.

 

2.2 Declaration of Trust by Delegate Collateral Agent

To the extent the Trust Property Delegated is not transferred, charged or granted to the Delegate Collateral Agent on trust pursuant to the Credit Documents, and subject to the provisions of Clause 2.3 (Non-Trust Jurisdictions), the Delegate Collateral Agent declares itself trustee of the Trust Property Delegated to hold the same on trust for the Secured Creditors for the purpose of securing the Secured Obligations on the terms and subject to the conditions set out in this Deed.

 

6


2.3 Non-Trust Jurisdictions

It is hereby agreed that, in relation to any jurisdiction the courts of which would not recognise or give effect to the trusts expressed to be created by this Deed, the relationship of the Secured Creditors to the Agents shall be construed as one of principal and agent but, to the extent permissible under the laws of such jurisdiction, all the other provisions of this Deed shall have full force and effect between the Parties.

 

2.4 Covenant to Pay

Each Credit Party hereby covenants with the Agents as trustees for the Secured Creditors that on demand by either of the Agents such Credit Party shall discharge all obligations which are then due and payable and which such Credit Party may at any time owe to the Agents (whether for its own account or as trustee for the Secured Creditors) or any of the other Secured Creditors (whether for their own account or as trustee or agent of the persons who such Secured Creditors represent or for whom they act) under or pursuant to the Credit Documents including any liability in respect of any further advances made under the Credit Documents, whether present or future, actual or contingent (and whether incurred solely or jointly and whether as principal or as surety or in some other capacity) and each Credit Party shall pay to the Agents when due and payable every sum at any time owing, due or incurred by such Credit Party to the Agents (whether for its own account or as trustee for the Secured Creditors) or any of the other Secured Creditors (whether for their own account or as trustee or agent of the persons who such Secured Creditors represent or for whom they act) in respect of any such liabilities.

 

3. APPLICATION OF PROCEEDS

 

3.1 Order of Application

 

  (a) All moneys from time to time received or recovered by the Agents (after payment of any sums received by the Delegate Collateral Agent to the Collateral Agent pursuant to the Term Loan Vessel 1 Assignment of KfW Refund Guarantees) shall be applied by the Collateral Agent (a) with respect to the Vessel 1 Shared Security only (to the extent that the Tranche A Intercreditor Agreement is operative), in accordance with the order of priority set out in clause 7.1 (Application of Proceeds) of the Tranche A Intercreditor Agreement and (b) with respect to the Vessel 1 Shared Security (to the extent that the Tranche A Intercreditor Agreement is inoperative) and any other Security (other than Vessel 2 Shared Security and Jade Shared Security) to which this Deed relates, in accordance with the order of priority set out in Section 4.05 (Application of Proceeds) of the Credit Agreement.

 

  (b)

All moneys from time to time received or recovered by the Agents (after payment of any sums received by the Delegate Collateral Agent to the Collateral Agent pursuant to the Term Loan Vessel 2 Assignment of KfW Refund Guarantees) shall be applied by the Collateral Agent (a) with respect to the Vessel 2 Shared Security only (to the extent that the Tranche B Intercreditor Agreement is operative), in accordance with the order of priority set out in clause 7.1 (Application of Proceeds) of the Tranche B Intercreditor

 

7


 

Agreement and (b) with respect to the Vessel 2 Shared Security (to the extent that the Tranche B Intercreditor Agreement is inoperative) and any other Security (other than Vessel 1 Shared Security and Jade Shared Security) to which this Deed relates, in accordance with the order of priority set out in Section 4.05 (Application of Proceeds) of the Credit Agreement.

 

  (c) All moneys from time to time received or recovered by the Agents shall be applied by the Collateral Agent (a) with respect to the Jade Shared Security only (to the extent that the Jade Intercreditor Agreement is operative), in accordance with the order of priority set out in clauses 3.4, 7.5 and 8 of the Jade Intercreditor Agreement and (b) with respect to the Jade Shared Security (to the extent that the Jade Intercreditor Agreement is inoperative) and any other Security (other than Vessel 1 Shared Security and Vessel 2 Shared Security) to which this Deed relates, in accordance with the order of priority set out in Section 4.05 (Application of Proceeds) of the Credit Agreement.

 

3.2 Investment of Proceeds

 

  (a) Pending its distribution under Clause 3.1 (Order of Application) and without responsibility for any loss or any reduction in return which may result from its so doing, the Collateral Agent may credit any sum received, recovered or held by it in respect of the Trust Property and/or the Trust Property Delegated to such suspense or other account as the Collateral Agent thinks fit or invest or place on deposit such sum in the name of or under the control of the Collateral Agent in any investment for the time being authorised by English law for the investment by trustees of trust moneys or with such bank or financial institution (including the Collateral Agent) as the Collateral Agent may think fit.

 

  (b) The Collateral Agent may at any time in its absolute discretion vary, exchange, transfer or transpose any such investments or deposits for or into other such investments or deposits without being under any obligation or duty to diversify the same. Any investment made by the Collateral Agent may, at its discretion, be made or retained in the name of a nominee.

 

3.3 Currency Conversion

In order to apply any sum held or received by the Collateral Agent or a Receiver in or towards payment of the Secured Obligations, the Collateral Agent or such Receiver may purchase an amount in another currency and the rate of exchange to be used shall be that at which, at such time as it considers appropriate, the Collateral Agent or such Receiver is able to effect such purchase.

 

3.4 Permitted Deductions

The Collateral Agent shall be entitled to set aside by way of reserve amounts required to meet, and to make and pay, any deductions and withholdings (on account of taxes or otherwise) which it is or may be required by any applicable law to make from any distribution or payment made by it under this Deed, and to pay all taxes which may be assessed against it in respect of any of the Trust Property or Trust Property Delegated, as applicable, or as a consequence of performing its duties, or by virtue of its acting in

 

8


its capacity as Collateral Agent under any of the Credit Documents or otherwise (other than in connection with its remuneration for performing its duties under this Deed).

 

3.5 Discharge of Secured Obligations

 

  (a) Any payment to be made in respect of the Secured Obligations by the Collateral Agent pursuant to (i) paragraph (c) of Clause 7.1 (Application of Proceeds) of either ECF Intercreditor Agreement or (ii) paragraph (ii) of Section 4.05 (Application of Proceeds) of the Credit Agreement shall be made to the Facility Agent (on behalf of the Lenders and the other Secured Creditors (to the extent applicable)) and any payment so made shall to the extent of such payment be a good discharge to the Agents.

 

  (b) The Credit Parties hereby agree that any sums due in respect of the Secured Obligations to any Secured Creditor shall only be discharged to the extent that such Secured Creditor has received such sums in the currency in which such sums are due under the Credit Documents.

 

3.6 Clawback

 

  (a) If any Secured Creditor has received an amount as a result of the enforcement of the Transaction Security and the Collateral Agent and/or the Delegate Collateral Agent is subsequently required to pay an amount equal to that amount (a “Clawback Amount”) to a liquidator (or any other party) whether pursuant to a court order or otherwise such Secured Creditor will promptly on the request of the Collateral Agent and/or the Delegate Collateral Agent (as applicable) pay an amount equal to such Clawback Amount to the Collateral Agent and/or the Delegate Collateral Agent (as applicable) for payment to the liquidator (or such other party).

 

  (b) Each Secured Creditor that has received a Clawback Amount shall indemnify the relevant Agent against any and all costs, claims, losses, expenses (including legal fees) and liabilities together with any VAT thereon which the Collateral Agent and/or the Delegate Collateral Agent (as applicable) may incur with respect to that Clawback Amount otherwise than by reason of the Agent’s own gross negligence or wilful misconduct.

 

4. SECURED CREDITORS’ UNDERTAKINGS

Each Secured Creditor gives the undertakings set out in this Clause 4 to each of the other Secured Creditors and acknowledges that the Agents entered into this Deed in reliance on those undertakings.

 

4.1 Secured Creditors’ Information

The Secured Creditors shall furnish to the Facility Agent, for transmission to the Collateral Agent and/or the Delegate Collateral Agent, such information as the Collateral Agent and/or the Delegate Collateral Agent may reasonably specify (through the Facility Agent) as being necessary or desirable to enable the Collateral Agent and/or the Delegate Collateral Agent to perform its functions as trustee.

 

9


4.2 Independent Power

Each of the Collateral Agent and the Delegate Collateral Agent alone, in their respective capacities, to the exclusion of the Secured Creditors, shall have power to enforce or have recourse to the Transaction Security and to exercise its rights and powers pursuant to the Credit Documents.

 

4.3 Indemnity to Agents

Without prejudice to any of the provisions of any other Credit Document and to the extent that the Company does not do so on demand or is not obliged to do so, each Secured Creditor that is a Lender hereby severally agrees to indemnify, rateably in accordance with such Lender’s Commitment, the Collateral Agent and/or the Delegate Collateral Agent (as applicable) (and every Receiver and Delegate) on demand from and against any action, charge, claim, cost, damage, demand, expense (including legal fees), liability or loss which may be brought, made or preferred against or suffered, sustained or incurred by the Collateral Agent and/or the Delegate Collateral Agent (as applicable) in complying with any instructions from any of the Secured Creditors or, in the case of the Delegate Collateral Agent, the Collateral Agent or otherwise sustained or incurred by the Collateral Agent and/or the Delegate Collateral Agent (as applicable) or any Receiver or Delegate in connection with this Deed or any Credit Document except to the extent that the liability or loss arises directly from the Collateral Agent and/or the Delegate Collateral Agent (as applicable)’s (or, as the case may be, the Receiver’s or the Delegate’s) gross negligence or wilful misconduct.

 

4.4 Assignments and Transfers

Each Secured Creditor agrees with the Agents that it shall not assign or transfer any of its rights, benefits and/or obligations under the Credit Agreement unless the person to whom such assignment or transfer is made shall have acceded to this Deed by the delivery to the Agents of a duly completed Secured Creditor Accession Undertaking, Transfer Certificate or Assignment Agreement so as to ensure that such person shall be bound by the terms and conditions of this Deed as a Secured Creditor.

 

5. CREDIT PARTIES’ UNDERTAKINGS

 

5.1 Credit Parties’ Indemnity to Agents

The Credit Parties shall jointly and severally indemnify and hold harmless the Collateral Agent and the Delegate Collateral Agent and every Receiver and Delegate (“indemnified parties”) on demand from and against any and all costs, claims, losses, expenses (including legal fees) and liabilities (together with any applicable VAT), incurred by any of them in relation to or arising out of:

 

  (a) the preservation, exercise or enforcement of the Transaction Security;

 

  (b) the exercise of any of the rights, powers, discretions and remedies vested in any of the indemnified parties by the Credit Documents or by law;

 

  (c) any default by any Credit Party in the performance of any of the obligations expressed to be assumed by it in the Credit Documents; or

 

10


  (d) otherwise in relation to any of the Transaction Security or the performance of the terms of this Deed.

The Collateral Agent and the Delegate Collateral Agent may, in priority to any payment to the Secured Creditors and on its own behalf or on behalf of the other indemnified parties, indemnify itself or such other indemnified parties out of the Trust Property and Trust Property Delegated respectively and shall have a lien on the Trust Property and Trust Property Delegated respectively for all moneys payable under this Clause 5.1.

 

5.2 Counter Indemnity

To the extent that a Secured Creditor is required to indemnify the Collateral Agent and/or the Delegate Collateral Agent pursuant to Clause 4.3 (Indemnity to Agents) as a result of any action which a Credit Party is required to take but does not, the relevant Credit Party agrees to indemnify each such Secured Creditor on demand against any amount it has paid to the Collateral Agent and/or the Delegate Collateral Agent pursuant to Clause 4.3 (Indemnity to Agents).

 

5.3 Credit Parties’ Waiver

Each of the Credit Parties hereby unconditionally waives, to the extent permitted under applicable law any and all rights it may have to require that the Transaction Security be enforced in any particular order or manner or at any particular time or that any sum received or recovered from any person, or by virtue of the enforcement of any of the Transaction Security, which is capable of being applied in or towards discharge of any of the Secured Obligations is so applied.

 

5.4 Sums Received by Credit Parties

If any of the Credit Parties receives any sum which, pursuant to any of the Credit Documents, should have been paid to the Collateral Agent and/or the Delegate Collateral Agent, that sum shall be held by that Credit Party for and to the order of the Secured Creditors and shall as soon as practicable be paid to the Collateral Agent for application in accordance with Clause 3.1 (Order of Application)).

 

6. AGENT’S RIGHTS AND DUTIES

 

6.1 Powers and Remuneration

 

  (a) The Agents shall have such rights, powers, authorities and discretions as are (i) conferred on trustees by the Trustee Acts and (ii) by way of supplement to the Trustee Acts as provided for in this Deed and the Credit Documents.

 

  (b) Between itself and the other Parties, the Collateral Agent shall have full power to determine all questions and doubts arising in relation to any of the provisions of this Deed or any Credit Document and any such determination shall in the absence of manifest error, be conclusive and shall bind the Agents and the other Parties.

 

  (c) The Agents shall be entitled to such remuneration as it may from time to time agree with the Company with the approval of the Facility Agent.

 

11


6.2 Instructions for Agents to Act

The Agents shall:

 

  (a) be entitled, in their absolute discretion, to refrain from taking any (or any further) action or exercising any of the Agents’ rights under or in respect of this Deed or any Credit Document until it has received instructions from the Facility Agent, as to whether (and/or the way in which) such action, right, power, authority or discretion is to be taken or exercised;

 

  (b) except as otherwise provided in this Deed, act in accordance with any instructions given to it by the Facility Agent and shall be entitled to assume that (i) any instructions received by it from the Facility Agent are duly given by the Facility Agent itself or on behalf of the requisite Lenders and/or other Secured Creditors (if applicable), (ii) all applicable conditions under the Credit Documents for taking any action it is directed to take have been satisfied and (iii) unless it has received actual notice of their revocation, that any instructions or directions given by the Facility Agent have not been revoked;

 

  (c) be entitled to request instructions or clarification from the Facility Agent as to whether, and in what manner, it should exercise or refrain from exercising its rights, powers and discretions under this Deed and the Agents may refrain from acting unless and until it has received such instructions or clarification;

 

  (d) be entitled to refrain from acting in accordance with the instructions of the Facility Agent or any other person (including bringing any legal action or proceeding arising out of or in connection with the Credit Documents) until it has received such indemnification and/or security as it may in its absolute discretion require (whether by way of payment in advance or otherwise) for all costs, expenses, losses and liabilities which it may incur in taking such action or bringing such legal action or proceedings; and

 

  (e) be entitled to carry out all dealings with the Lenders and/or other Secured Creditors (if applicable) through the Facility Agent and may give to the Facility Agent any notice or other communication required to be given by the Agents to the Lenders and/or other Secured Creditors (if applicable).

 

6.3 Action to Protect or Enforce Transaction Security

Subject to the provisions of this Clause 6:

 

  (a) the Agents may, in the absence of any instructions from the Facility Agent to the contrary, take such action in the exercise of any of its duties under the Credit Documents and this Deed which in its absolute discretion it considers appropriate; and

 

  (b) at any time after receipt by the Agents of notice from the Facility Agent informing the Agents that the Transaction Security has become enforceable and directing the Agents to exercise all or any of its rights, remedies, powers or discretions under any of the Credit Documents or this Deed, the Agents shall take such action as in its absolute discretion it thinks fit to enforce the Transaction Security.

 

12


6.4 Agents’ Rights and Discretions

The Agents may:

 

  (a) rely on:

 

  (i) any communication, certificate, legal opinion or other document believed by it to be genuine and correct and to have been signed by, or with the authority of, the proper person;

 

  (ii) any statement made by a director, officer, partner or employee of any person regarding any matters which may reasonably be assumed to be within his knowledge or within his power to verify; and

 

  (iii) a certificate signed by any one or more persons which, or each of which, is believed by it to be a director or other duly authorised officer of the relevant Party to the effect that any particular dealing, transaction, step or thing is, in the opinion of the person so certifying, suitable or expedient or as to any other fact or matter upon which the Agents may require to be satisfied and shall not be responsible for any loss that may be occasioned by its relying on any such certificate;

 

  (b) obtain and pay for such legal or other expert advice or services as it may consider necessary or desirable;

 

  (c) retain for its own benefit, without liability to account to any other person, any fee or other sum received by it for its own account;

 

  (d) in the case of the Collateral Agent only, exercise any of its rights, powers and discretions and perform any of its obligations under this Deed or any of the Credit Documents through its employees or through paid or unpaid agents, which may be corporations, partnerships or individuals (whether or not lawyers or other professional persons). Any such agent shall be responsible for its own acts and omissions and subject to Section 12.02 of the Credit Agreement, the Collateral Agent shall not be responsible for any misconduct or omission on the part of, or be bound to supervise the proceedings or acts of, any such employee or agent (and any such agent which is engaged in any profession or business shall be entitled to charge and be paid all usual fees, expenses and other charges for its services);

 

  (e)

in the case of the Collateral Agent only, at any time and from time to time delegate, whether by power of attorney or otherwise and upon such terms and conditions (including the power to sub-delegate with the consent of the Collateral Agent) as the Collateral Agent may think fit, to any persons all or any of its rights, powers and discretions under this Deed or under any of the Credit Documents. Such delegate or sub-delegate shall be responsible for its own acts and omissions and subject to Section 12.02 of the Credit Agreement, the Collateral Agent shall not be in any way liable or responsible to any person

 

13


 

for any loss or damage arising from any act, default, omission or misconduct on the part of any such delegate or sub-delegate. Notwithstanding the above and for the avoidance of doubt, the Collateral Agent shall not be responsible for any acts or omissions, including, without limitation, any acts or omissions caused by the gross negligence or wilful misconduct of the Delegate Collateral Agent;

 

  (f) together with every Receiver, Delegate or other person appointed under this Deed or any of the Credit Documents, indemnify themselves out of the Trust Property and the Trust Property Delegated against all proceedings, claims and demands which may be made or taken against it and all costs, charges, damages, expenses and liabilities which it may suffer or incur unless suffered or incurred by reason of its own gross negligence or wilful misconduct; and

 

  (g) unless it has, in its capacity as trustee for the Secured Creditors, received actual notice to the contrary, assume that (i) no Event of Default has occurred and no Credit Party is in breach of or default under its obligations under any of the Credit Documents and (ii) any right, power, authority or discretion vested by any Credit Document in any person has not been exercised.

 

6.5 Agent’s Obligations

The Agents shall promptly inform the Facility Agent (and in the case of the Delegate Collateral Agent, inform the Collateral Agent) of:

 

  (a) the contents of any written notice or document received by it in its capacity as Collateral Agent and Delegate Collateral Agent from any Credit Party under any Credit Document; and

 

  (b) the occurrence of any Event of Default or any default by a Credit Party in the due performance of or compliance with its obligations under any Credit Document of which the Collateral Agent or Delegate Collateral Agent has received written notice from any other Party.

 

6.6 Excluded Obligations

Notwithstanding anything to the contrary expressed or implied in any Credit Document, the Agents shall not:

 

  (a) be liable to anyone where it has acted reasonably and in good faith on the opinion or advice of or any information obtained from any lawyer, accountant, architect, engineer, surveyor, broker, consultant, valuer or other expert (including any auditor), whether obtained by the Agents or otherwise whether or not the expert’s liability in respect thereof is limited by a monetary cap or otherwise and whether or not any such opinion, advice or information contains some error or is not authentic;

 

  (b) be obliged to monitor or enquire as to whether or not an Event of Default has occurred and will not be deemed to have knowledge of the occurrence of an Event Default unless it has actual knowledge or express notice thereof;

 

14


  (c) have any duty to (i) ensure that any payment or other financial benefit in respect of any of the Trust Property or the Trust Property Delegated is duly and punctually paid, received or collected as and when the same becomes due and payable or (ii) to procure that the correct amounts (if any) are paid or received or to ensure the taking up of any (or any offer of any) stocks, shares, rights, moneys or other property paid, distributed, accrued or offered at any time by way of interest, dividend, redemption, bonus, rights, preference, option, warrant or otherwise on, or in respect of or in substitution for any of the Trust Property or the Trust Property Delegated;

 

  (d) unless required by law or ordered so to do by a court of competent jurisdiction, be required to (i) disclose to any Secured Creditor any credit or other information (other than information in the Agents’ possession specifically concerning the Credit Documents) with respect to the financial condition or affairs of any member of the Group or any of their related entities whether coming into its or any of its affiliates possession before or on the entry into this Deed or at any time thereafter or (ii) request any certificates or other documents from any member of the Group unless specifically requested to do so by the Facility Agent in accordance with this Deed or any of the Credit Documents;

 

  (e) be bound to account to any other Secured Creditor for any sum or the profit element of any sum received by it for its own account;

 

  (f) be bound to disclose to any other person (including any Secured Creditor) (i) any confidential information or (ii) any other information if disclosure would or might in its reasonable opinion constitute a breach of any law or be a breach of fiduciary duty;

 

  (g) be liable to any of the Secured Creditors for any action taken or omitted to be taken under or in connection with any of the Credit Documents unless caused by its fraud, gross negligence or wilful misconduct;

 

  (h) be under any obligations other than those which are specifically provided for in the Credit Documents to which it is a party;

 

  (i) have or be deemed to have any duty, obligation or responsibility to, or relationship of trust or agency with, any Credit Party; or

 

  (j) be obliged to take any action in relation to enforcing or perfecting any charge over any shares in a company registered or incorporated with unlimited liability.

 

6.7 Responsibility of Secured Creditors

It is understood and agreed by each Secured Creditor that at all times that Secured Creditor has itself been, and will continue to be, solely responsible for making its own independent appraisal of and investigation into all risks arising under or in connection with the Credit Documents including but not limited to:

 

  (a) the financial condition, creditworthiness, condition, affairs, status and nature of each of the Credit Parties;

 

15


  (b) the legality, validity, effectiveness, adequacy and enforceability of each of the Credit Documents and the Transaction Security and any other agreement, arrangement or document entered into, made or executed in anticipation of, pursuant to or in connection with the Credit Documents;

 

  (c) whether that Secured Creditor has recourse, and the nature and extent of that recourse, against any Credit Party or any other person or any of their respective assets under or in connection with the Credit Documents or the transactions contemplated therein or any other agreement, arrangement or document entered into, made or executed in anticipation of, pursuant to or in connection with the Credit Documents;

 

  (d) the adequacy, accuracy and/or completeness of any information provided by any person in connection with the Credit Documents or the transactions contemplated therein or any other agreement, arrangement or document entered into, made or executed in anticipation of, pursuant to or in connection with the Credit Documents; and

 

  (e) the right or title of any person in or to, or the value or sufficiency of any part of the Trust Property or the Trust Property Delegated, the priority of any of the Transaction Security or the existence of any other Security affecting the Trust Property or the Trust Property Delegated,

and each Secured Creditor warrants to the Agents that it has not relied on and will not at any time rely on the Agents in respect of any of these matters.

 

6.8 No Responsibility to Perfect Security

The Agents shall not be liable for any omission or defect in, or any failure to preserve or perfect any or all of the Transaction Security including, without limitation, any failure to:

 

  (a) require the deposit with it of any deed or document certifying, representing or constituting the title of any Credit Party to any of the Trust Property or the Trust Property Delegated;

 

  (b) obtain any licence, consent or other authority for the execution, delivery, legality, validity, enforceability or admissibility in evidence of any of the Credit Documents or the Transaction Security;

 

  (c) register, file or record or otherwise protect any of the Transaction Security (or the priority of any of the Transaction Security) under any applicable laws in any jurisdiction or to give notice to any person of the execution of any of the Credit Documents or of the Transaction Security;

 

  (d) take, or to require any of the Credit Parties to take, any steps to perfect its title to any of the Trust Property or the Trust Property Delegated or to render the Transaction effective or to secure the creation of any ancillary security under the laws of any jurisdiction; or

 

16


  (e) require any further assurances in relation to any of the Transaction Security.

 

6.9 Insurance

The Agents shall not be under any obligation to insure any of the Trust Property or the Trust Property Delegated, to require any other person to maintain any insurance or to verify any obligation to arrange or maintain insurance contained in the Credit Documents. The Agents shall not be responsible for any loss which may be suffered by any person as a result of the lack of or inadequacy of any such insurance. Where the Agents are named on any insurance policy as an insured party, it shall not be responsible for any loss which may be suffered by reason of, directly or indirectly, its failure to notify the insurers of any material fact relating to the risk assumed by such insurers or any other information of any kind, unless any Secured Creditor shall have requested it to do so in writing and the Agents shall have failed to do so within 14 days after receipt of that request.

 

6.10 Safekeeping

 

  (a) Each of the Agents shall be at liberty to place (at the cost of the Credit Parties) any of the Credit Documents and any title deeds or other documents relating to the Transaction Security in any safe custody selected by the Agents or with any financial institution, any company whose business includes the safe custody of documents or any firm of lawyers of good repute and the Agents shall not be responsible for, or required to insure against, any loss incurred in connection with that deposit.

 

  (b) Each of the Agents may in its absolute discretion make any such arrangements as it thinks fit for allowing any Credit Party or its lawyers or auditors or other advisers access to or possession of any title deeds and other documents relating to the Transaction Security.

 

  (c) The Agents shall not be responsible for any loss which may result arising out of any deposit, access, possession or other matter provided for in this Clause 6.10.

 

6.11 Acceptance of Title

Each of the Agents shall be entitled to accept without enquiry, and shall not be obliged to investigate, such evidence of right and title as any Credit Party may have to any of the Trust Property or the Trust Property Delegated and shall not be liable for or bound to require any Credit Party to remedy any defect in its right or title.

 

6.12 Refrain from Illegality

Each of the Agents may refrain from doing anything which in its opinion would or might be contrary to any law of any jurisdiction or any directive or regulation binding on it which would or might otherwise render it liable to any person, and the Agents may do anything which is, in its opinion, necessary to comply with any such law, directive or regulation.

 

17


6.13 Business with the Credit Parties

Each of the Agents may accept deposits from, lend money to or provide advisory or other services to and generally engage in any kind of banking or other business with any of the Credit Parties whether or not it may or does lead to a conflict with the interests of any of the Secured Creditors and may do so without any obligation to account to or disclose any such arrangements to any person.

 

6.14 Agent Division Separate

In acting as trustee for the Secured Creditors, each of the Agents shall be regarded as acting through its trustee division which shall be treated as a separate entity from any of its other divisions or departments and any information received by any other division or department of the relevant Agent may be treated as confidential and shall not be regarded as having been given to the relevant Agent’s trustee division.

 

6.15 Exclusion of Liability

Neither the Agents nor any of their officers, employees or agents makes, or shall at any time be deemed to have made any representation or warranty (express or implied) with regard to, nor shall it be responsible or liable to any person for:

 

  (a) the adequacy, accuracy or completeness of any representation, warranty, statement or information contained in this Deed or any Credit Document, notice, report or other document, statement or information circulated, delivered or made to any Secured Creditor whether orally or otherwise and whether before, on or after the date of this Deed;

 

  (b) the execution, delivery, validity, legality, priority, ranking, adequacy, effectiveness, performance, enforceability or admissibility in evidence of this Deed or any Credit Document or any other document referred to in paragraph (a) above or of any Transaction Security created thereby or any obligations imposed thereby or assumed thereunder or any other document, agreement or arrangement entered into, made or executed in anticipation of, pursuant to or in connection therewith;

 

  (c) anything done or not done by it or any of them under or in connection with this Deed or the Credit Documents;

 

  (d) any losses to any person or any liability arising as a result of taking or refraining from taking any action in relation to any of the Credit Documents or the Transaction Security or otherwise, whether in accordance with an instruction from the Facility Agent or otherwise;

 

  (e) the exercise of, or the failure to exercise, any judgment, discretion or power given to it by or in connection with any of the Credit Documents, the Transaction Security or any other agreement, arrangement or document entered into, made or executed in anticipation of, pursuant to or in connection therewith; or

 

18


  (f) any shortfall which arises on the enforcement of the Transaction Security,

and each of the Secured Creditors agrees that it will not take any proceedings or assert or seek to assert against any officer, employee or agent of the Agents any claim it might have against any of them in respect of the matters referred to in this Clause 6.15.

 

7. APPOINTMENT AND REMOVAL OF AGENTS

 

7.1 Appointment of Additional Agents

 

  (a) The Collateral Agent shall, at any time and for any purpose or reason whatsoever, have the power to appoint any person to act either as a new or additional trustee, or as co-trustee jointly with the Collateral Agent, with (subject to the provisions of this Deed) such of the Collateral Agent’s rights (including the right to reasonable remuneration and indemnity but not exceeding those conferred on the Collateral Agent by this Deed), duties and obligations as are vested in the Collateral Agent by this Deed or any Credit Document as shall be conferred or imposed on such person by the instrument of such co-trustee’s appointment.

 

  (b) Any such appointment by the Collateral Agent shall be reasonably acceptable to the Company; provided that the Company’s consent shall not be required pursuant to this clause (b) if an Event of Default exists at the time of the appointment of the new or additional or co-trustee acting jointly with the Agents.

 

  (c) The Collateral Agent shall not be bound to supervise, or be responsible for any loss incurred by reason of any act or omission of any such person if the Collateral Agent shall have exercised reasonable care in the selection of such person.

 

  (d) So long as it continues to be a trustee under this Deed, the Collateral Agent shall have power to remove any such new or additional trustee or co-Collateral Agents with or without cause.

 

  (e) The remuneration the Collateral Agent may pay to any such person, and any costs and expenses incurred by such person in performing its functions pursuant to that appointment shall, for the purposes of this Deed, be treated as costs and expenses incurred by the Collateral Agent.

 

7.2 Delegation

The Collateral Agent may at any time delegate by power of attorney or otherwise to any person for any period, all or any of the rights, powers and discretions vested in it by any of the Credit Documents and such delegation may be made upon such terms and conditions (including the power to sub-delegate) and subject to such restrictions as the Collateral Agent may think fit. Such delegate or sub-delegate shall be responsible for its own acts and omissions and the Agents shall not be bound to supervise, or be responsible for any loss incurred by reason of any act or omission of any such person if the Collateral Agent shall have exercised reasonable care in the selection of such person.

 

19


7.3 Retirement or Removal of Agents

 

  (a) The Collateral Agent may retire at any time (without assigning any reason therefor and without being responsible for any costs occasioned by such retirement) by giving not less than 15 Business Days’ prior written notice to that effect to the Facility Agent (on behalf of the Lenders) and the Company.

 

  (b) The Delegate Collateral Agent may not resign except with the prior consent of the Collateral Agent. Only after such consent is received and subject to the other provisions of this Clause 7.3 and without being responsible for any costs occasioned by such resignation, the Delegate Collateral Agent may resign by giving not less than 15 Business Days’ prior written notice to that effect to the Facility Agent (on behalf of the Lenders) and the Company.

 

  (c) The Facility Agent (acting on the instructions of the Required Lenders), after consultation with the Parent, may remove an Agent from its role as trustee under this Deed by giving notice to that effect to the relevant Agent and each of the other Parties to this Deed.

 

  (d) The retirement or removal of a sole Collateral Agent or Delegate Collateral Agent shall not take effect until (i) the appointment of a successor Collateral Agent or Delegate Collateral Agent, as the case may be, as a co-trustee has been made and (ii) the Facility Agent is satisfied that all things required to be done in order that the relevant Credit Documents continue to provide perfected and enforceable security in favour of the successor Collateral Agent or Delegate Collateral Agent (as applicable) have been done.

 

  (e) If a notice of retirement or removal has been given under paragraph (a) or (b) above, the power to appoint new Agents shall vest in the Required Lenders. The Required Lenders shall appoint a successor Collateral Agent or Delegate Collateral Agent, as the case may be, who shall be a commercial bank or trust company reasonably acceptable to the Company; provided that the Company’s consent shall not be required if an Event of Default exists at the time of appointment of such successor Agent. If no successor Agent shall have (i) been appointed by the Required Lenders and (ii) accepted such appointment within 15 Business Days of the giving of such notice, the Facility Agent (acting on the instructions of the Required Lenders), with the consent of the Company (which shall not be unreasonably withheld or delayed), shall then appoint a commercial bank or trust company with capital and surplus of not less than $500,000,000 as successor Collateral Agent or Delegate Collateral Agent (as applicable) who shall serve as Agent until such time, if any, as the Required Lenders appoint a successor Collateral Agent or Delegate Collateral Agent (as applicable) as provided above; provided that the Company’s consent shall not be required pursuant to this clause (d) if an Event of Default exists at the time of appointment of a successor Agent.

 

  (f) If a successor to the Collateral Agent or the Delegate Collateral Agent is appointed under the provisions of this Deed (i) the retiring Agent shall be discharged from any further obligations under, but shall remain entitled to the benefits of, this Deed and (ii) the successor trustee and each of the other Parties shall have same rights and obligations amongst themselves as they would have had if such successor had been an original party to this Deed.

 

20


8. CHANGE OF PARTIES

 

8.1 Assignment

No party to this Deed may assign all or any of its rights or transfer any of its obligations under this Deed except as expressly contemplated by this Deed, by the Credit Agreement or as may be required by law.

 

8.2 Change of Secured Creditor

Any person which is (subject only to its accession to this Deed) a permitted assignee or a transferee of a Lender, a transferee of a Term Loan Hedging Creditor or a successor Facility Agent, in each case for the purposes of and in accordance with the terms of the Credit Agreement, shall be entitled to execute and deliver to the Collateral Agent a Secured Creditor Accession Undertaking, a Transfer Certificate or Assignment Agreement and, with effect from (x) the date of acceptance by, where appropriate, the Facility Agent (or, if appropriate, the outgoing Facility Agent) and the Collateral Agent or (y) if later, the date specified in that Secured Creditor Accession Undertaking, Transfer Certificate or Assignment Agreement:

 

  (a) the Secured Creditor ceasing to be a Lender and/or Facility Agent shall be discharged from further obligations towards the Collateral Agent and other Secured Creditors under this Deed and their respective rights against one another shall be cancelled (except in each case for those rights which arose prior to such date); and

 

  (b) as from that date, the new Lender or Facility Agent shall assume the same obligations, and become entitled to the same rights as it would have had if it had been an original party to this Deed in that capacity.

 

8.3 New Hedging Creditor

Any Term Loan Hedging Creditor that wishes to become a Party to this Deed in the capacity as a Secured Creditor may become a Party by delivering to the Collateral Agent, a duly completed and executed Secured Creditor Accession Undertaking. With effect from the date of acceptance by the Collateral Agent of a Secured Creditor Accession Undertaking duly executed and delivered to the Collateral Agent by such Term Loan Hedging Creditor or, if later, the date specified in that Secured Creditor Accession Undertaking, the Term Loan Hedging Creditor shall assume the same obligations and become entitled to the same rights, as if it had been an original Party to this Deed in that capacity.

 

9. FEES AND EXPENSES

 

9.1 Transaction and Enforcement Expenses

The Credit Parties shall, from time to time on demand of the Agents, reimburse the Agents:

 

  (a) for all reasonable documented out-of-pocket costs and expenses (including legal fees) properly incurred by the Agents, a Receiver or any Delegate in connection with the negotiation, preparation and execution of this Deed and the Credit Documents and the completion of the transactions and perfection of the security contemplated in the Credit Documents; and

 

21


  (b) on a full indemnity basis, for all costs and expenses (including legal fees) incurred by the Agents, a Receiver or any Delegate in connection with the exercise, preservation and/or enforcement of the Security, any of the rights, powers and remedies of the Agents and any proceedings instituted by or against the Agents as a consequence of taking or holding the Security or of enforcing those rights, powers and remedies;

in each case, together with any applicable VAT thereon.

 

9.2 Stamp Taxes

The Credit Parties shall promptly pay all stamp, registration, notarial, documentary and other taxes or fees (including any penalties fines, supplements, surcharge or interest relating to such taxes) to which this Deed, the Credit Documents, the Transaction Security or any judgment given in connection with them, is or at any time may be, subject and shall, from time to time, indemnify the Agents on demand against any liabilities, costs, claims and expenses resulting from any failure to pay or any delay in paying any such tax or fee.

 

9.3 Interest on Demands

If any Credit Party fails to pay any sum on the due date for payment of that sum the relevant Credit Party shall pay interest on any such sum (before and after any judgment and to the extent interest at a default rate is not otherwise being paid on such sum) from the date of demand until the date of payment calculated on a daily basis at the rate determined in accordance with the provisions of section 2.06(b) or (c) (Interest) (as applicable) of the Credit Agreement.

 

10. AMENDMENTS AND RELEASES

 

10.1 Amendments

The Company and the Agents, if authorised by the Facility Agent, may amend the terms of, waive any of the requirements of, or grant consents under, this Deed any such amendment, waiver or consent shall be binding on all the Parties to this Deed and the Agents shall be under no liability whatsoever in respect thereof provided that:

 

  (i) the prior consent of all of the Lenders is required to authorise any amendment to Clause 3.1 (Order of Application)), this Clause 10 or Clause 11 (Termination of the Trusts); and

 

  (ii) no new or additional obligations may be imposed upon, nor shall any amendment or waiver which relates to the rights of, the Facility Agent or of the Agents (including, without limitation, Clause 4.3 (Indemnity to Agents)) be effective without the consent of the Facility Agent or, as the case may be, the Agents.

 

22


10.2 Releases

Upon:

 

  (a) a disposal of any of the Trust Property or Trust Property Delegated pursuant to the enforcement of the Security by a Receiver or the Agents;

 

  (b) a disposal of any of the Trust Property or Trust Property Delegated in accordance with section 14.21 (Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer) of the Credit Agreement; or

 

  (c) any other disposal of any of the Trust Property or Trust Property Delegated which is otherwise permitted under the Credit Documents,

the Agents shall (at the cost of the Credit Parties) release that property from the Transaction Security to which it is subject and may execute, without the need for any further authority from the Secured Creditors, any release of the Security or other claim over that asset and to issue any certificates of non-crystallisation of floating charges that may be required or desirable.

 

10.3 Release of Credit Parties

If a Credit Party ceases to be a Credit Party under the Credit Agreement then such Credit Party shall automatically be released as a Credit Party under this Deed. Each of the Parties agrees that the Agents may release any of the Credit Parties from any guarantee or indemnity in the circumstances contemplated by the Credit Agreement. In the case of a Credit Party which is no longer a Credit Party under the Credit Agreement, the Agents shall (at the cost of that Credit Party) release the Security granted by it and the Agents are authorised, without the need for further authority from the Secured Creditors, to execute such agreements or deeds as are necessary to effect such a release.

 

11. TERMINATION OF THE TRUSTS

The trusts set out in this Deed shall terminate on the Discharge Date. At that time the Agents shall release, without recourse or warranty, all of the Transaction Security then held by it.

 

12. REMEDIES AND WAIVERS

No failure by the Agents to exercise, nor any delay by the Agents in exercising, any right or remedy under this Deed shall operate as a waiver thereof nor shall any single or partial exercise of any such right or remedy prevent any further or other exercise thereof or the exercise of any other such right or remedy.

 

13. ADDITIONAL PROVISIONS

 

13.1 Partial Invalidity

If at any time any provision of this Deed is or becomes illegal, invalid or unenforceable in any respect or any of the Transaction Security is or becomes ineffective in any respect under the law of any jurisdiction, such illegality, invalidity, unenforceability or ineffectiveness shall not affect:

 

  (a) the legality, validity or enforceability of the remaining provisions of this Deed or the effectiveness in any other respect of the Security under such law; or

 

23


  (b) the legality, validity or enforceability of such provision or the effectiveness of the Transaction Security under the law of any other jurisdiction.

 

13.2 Potentially Avoided Payments

If the Agents determine that an amount paid to the Secured Creditors under any Credit Document is being avoided or otherwise set aside on the liquidation or administration of the person by whom such amount was paid, then for the purposes of this Deed, such amount shall be regarded as not having been paid.

 

13.3 Currency Indemnity

If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from any Credit Party hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Agents could purchase the specified currency with such other currency on the Business Day preceding that on which final judgment is given. The obligations of the Credit Parties in respect of any sum due to the Agents hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by the Agents of any sum adjudged to be so due in such other currency the Agents may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to the Agents in the specified currency, each Credit Party agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify the Agents against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to the Agents in the specified currency, the Agents agree to remit such excess to the Company.

 

13.4 Rights Cumulative

The rights and remedies provided by this Deed are cumulative and not exclusive of any rights or remedies provided by law.

 

13.5 The Trustee Acts

Where there are any inconsistencies between the Trustee Acts and the provisions of this Deed, the provisions of this Deed shall, to the extent allowed by law, prevail and, in the case of any such inconsistency with the Trustee Act 2000, the provisions of this Deed shall constitute a restriction or exclusion for the purposes of that Act.

 

24


13.6 Conflicting provisions

If there is any conflict between the provisions of this Deed and any Credit Document with regard to instructions to or other matters affecting the Agents, this Deed will prevail. However, nothing in this Deed shall limit the ability of the Agents to exercise any rights, powers and discretions it may have in its capacity as a Secured Creditor.

 

13.7 Financial liability

Nothing contained in this Deed shall require the Agents to expend or risk its own funds or otherwise incur any financial liability in the performance of its duties or the exercise of any right, power, authority or discretion hereunder if it has grounds for believing the repayment of such funds or adequate indemnity against, or security for, such risk or liability is not reasonably assured to it.

 

13.8 Consents

Any consents given by the Agents for the purposes of this Deed may be given on such terms and subject to such conditions (if any) as the Agents may require.

 

14. NOTICES

 

14.1 Communications in Writing

Each communication to be made under or in connection with this Deed shall be made in writing and, unless otherwise stated, may be made by fax or letter.

 

14.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 14.1 (Communications in writing), the contact details of each of the parties are as follows:

 

  (a) to the Collateral Agent:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany,

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

  (b) to the Delegate Collateral Agent:

Domstrasse 18

D - 20095 Hamburg

Attn.: Marcus Weber / Anne Randewig

Fax: +49 40 3769 -9649

E-mail: marcus.weber@commerzbank.com

            anne.randewig@commerzbank.com

 

25


  (c) to the Facility Agent:

Palmengartenstrasse 5-9,

60325 Frankfurt am Main,

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

Email: claudia.wenzel@kfw.de

 

  (d) to the Credit Parties:

7665 Corporation Center Drive

Miami, Florida 33126

USA

Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

            hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com,

or to such other address and/or number as is notified in writing by a Party to the other Parties under this Deed.

 

14.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified on Clause 14.2 (Contact Details) or in the case of the Original Secured Creditors at the addressed identified with its name in Schedule 1 hereto; provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Agents, the Facility Agent and the Company agree that they shall notify each other in writing of their electronic mail

 

26


address and/or any other information required to enable the sending and receipt of information by that means and they shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Agents or the Facility Agent shall not be effective until received by the Agents or the Facility Agent (as applicable), or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Company to the Agents or the Facility Agent, only if it is addressed in such a manner as the Agents or the Facility Agent shall specify for this purpose.

 

15. GOVERNING LAW AND JURISDICTION

 

15.1 Governing Law

This Deed and any non-contractual obligations arising out of or in connection with it are governed by, and shall be construed in accordance with, English law.

 

15.2 Jurisdiction

Each of the parties hereto agree that the courts of England shall have exclusive jurisdiction to hear and determine any suit, action or proceedings arising our of or in connection with this Deed or any non-contractual obligations arising out of or in connection with this Deed (“Proceedings”) and, for such purposes, irrevocably submits to the jurisdiction of such courts. Nothing in this Clause 15.2 shall (or shall be construed so as to) limit the right of any Secured Creditor to take Proceedings in any other court of competent jurisdiction, nor shall the taking of Proceedings in any one or more jurisdictions preclude the taking of Proceedings by any Secured Creditor in any other jurisdiction (whether concurrently or not) if and to the extent permitted by law.

 

15.3 Appropriate Forum

For the purpose of Clause 15.2 (Jurisdiction), the parties hereto irrevocably waive any objection which they might now or hereafter have to the courts of England being nominated as the forum to hear and determine any Proceedings and agree(s) not to claim that any such court is not a convenient or appropriate forum.

 

15.4 Process Agent

The Credit Parties agree that the process by which any Proceedings in England are begun may be served on it by being delivered to EC3 Services Limited at 51 Eastcheap, London, EC3M 1JP or, if different, its registered office for the time being. If such person is not or ceases to be effectively appointed to accept service of process on behalf of the Credit Parties, the Credit Parties shall, on the written demand of any Secured Creditor, appoint a further person in England to accept service of process on its behalf and, failing such appointment within 15 days, any Secured Creditor shall be

 

27


entitled to appoint such a person by written notice to the Credit Parties. Nothing in this paragraph shall affect the right of any Secured Creditor to serve process in any other manner permitted by law.

 

16. COUNTERPARTS AND EFFECTIVENESS

 

16.1 Counterparts

This Deed may be executed in counterparts and such counterparts taken together shall constitute one and the same instrument.

 

16.2 Effectiveness

This Deed shall take effect and be delivered as a deed on the date on which it is stated to be made notwithstanding that the Agents or any other Party may have executed it under hand only.

IN WITNESS WHEREOF this Deed has been executed as a deed by the Credit Parties and has been signed on behalf of the Agents and other Parties.

 

28


SCHEDULE 1

ORIGINAL SECURED CREDITORS

 

DEUTSCHE SCHIFFSBANK    Domstrasse 18
AKTIENGESELLSCHAFT    D - 20095 Hamburg
   Attn.: Marcus Weber / Anne Randewig
   Telephone: +49 40 3769 -9646 / -9647
   Facsimile: +49 40 3769 -9649
   e-mail:    marcus.weber@commerzbank.com
      anne.randewig@commerzbank.com
DNB NOR BANK ASA    Stranden 21
   N-0021 Oslo, Norway
   Attn: Amra Koluder / Solveig N. Knoff
   Telephone: +47 22 94 91 17 / 22 94 96 63
   Facsimile: +47 22 48 28 94
   e-mail:    amra.koluder@dnbnor.no
      solveig.knoff@dnbnor.no
HSBC BANK PLC    8 Canada Square
   London E14 5HQ
   Attn: Alan P. Marshall (FC1354)
   Fax no: +44 207 992 4428
   e-mail:    alan.p.marshall@hsbcib.com
KFW IPEX-BANK GMBH    Palmengartenstrasse 5-9
   60325 Frankfurt am Main
   Germany
   Telephone: +49 69 7431 4649 / 4037
   Fax: +49 69 7431 4466 / 2944
   Attn:    Ms Claudia Wenzel /
      Mr Christian Schweiger
   email:    claudia.wenzel@kfw.de /
      christian.schweiger@kfw.de
NORDEA BANK NORGE ASA    Middelthunsgate 17, P.O. Box 1166 Sentrum
   NO-0107
   Oslo, Norway
   Attn: Arne Berglund
   Telephone: (47) 22 484193
   Facsimile: (47) 22 486668
   e-mail:    arne.berglund@nordea.com

 

29


SCHEDULE 2

FORM OF SECURED CREDITOR ACCESSION UNDERTAKING

 

To: KfW IPEX-Bank GmbH and [], for themselves and each of the other Secured Creditors to the Security Trust Deed referred to below.

THIS UNDERTAKING is made on [date] by [new Lender/Term Loan Hedging Creditor/Facility Agent/Receiver/Delegate] (the “Acceding Secured Creditor”) in relation to the Security Trust Deed (the “Security Trust Deed”) dated [] between KfW IPEX-Bank GmbH as Collateral Agent, Deutsche Schiffsbank Aktiengesellschaft as Delegate Collateral Agent, KfW IPEX-Bank GmbH as facility agent, the Secured Creditors named therein and the Credit Parties. Terms defined in the Security Trust Deed shall bear the same meanings when used in this Undertaking.

In consideration of the Acceding Secured Creditor being accepted as a Secured Creditor for the purposes of the Security Trust Deed, the Acceding Secured Creditor hereby confirms that, as from [date], it intends to be party to the Security Trust Deed as a Secured Creditor, undertakes to perform all the obligations expressed in the Security Trust Deed to be assumed by [the Facility Agent and by]/[a Secured Creditor] and agrees that it shall be bound by all the provisions of the Security Trust Deed, as if it had been an original party to the Security Trust Deed.

This Undertaking shall be governed by and construed in accordance with English law.

THIS UNDERTAKING has been entered into on the date stated above.

 

Acceding [Secured Creditor]/[Facility Agent]  
By:  
Address for Notices:  
Fax:  
For attention of:  
Accepted by the Collateral Agent:  

 

 
for and on behalf of  
KfW IPEX-Bank GmbH  
Date:  
Accepted by the [Facility Agent]/[outgoing Facility Agent]:

 

 
for and on behalf of  

[Insert name of Facility Agent or

outgoing Facility Agent as appropriate]]

 
Date:  

 

30


SIGNATORIES

 

THE COMPANY        
Signed as a deed on behalf of PRIDE OF HAWAII, LLC, a company incorporated in Delaware, by                                         , being a person who, in accordance with the laws of that territory, is acting under the authority of the company        
    

 

  
     Authorised signatory   

 

31


THE PARENT        
Signed as a deed on behalf of NCL CORPORATION LTD., a company incorporated in Bermuda, by                                         , being a person who, in accordance with the laws of that territory, is acting under the authority of the company        
    

 

  
     Authorised signatory   

 

32


THE ORIGINAL SECURED CREDITORS        
Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by                                          :        
    

 

  
     Director   
    

 

  
     Director   

 

33


Executed as a deed by DNB NOR BANK ASA, acting by                                              , in the presence of:        
    

 

  
     Director   
    

 

  
     Witness   
     Name:   
     Address:   
     Occupation:   

 

34


SIGNED and DELIVERED as a DEED by   )      
HSBC BANK PLC   )      
acting by   )      
its duly authorised attorney-in-fact   )   

 

  
in the presence of:   )    Attorney-in-Fact   
    

 

  
     Witness   
     Name:   
     Address:   
     Occupation:   

 

35


Executed as a deed by KFW IPEX-BANK GMBH, acting by                                          :        
    

 

  
     Director   
    

 

  
     Director   

 

36


Executed as a deed by NORDEA BANK NORGE ASA, acting by                                          :        
    

 

  
     Director   
    

 

  
     Director   

 

37


THE FACILITY AGENT        
Executed as a deed by KFW IPEX-BANK GMBH, acting by                                          :        
    

 

  
     Director   
    

 

  
     Director   

 

38


THE COLLATERAL AGENT        

Executed as a deed by KFW IPEX-BANK GMBH, acting

by                                          :

       
    

 

  
     Director   
    

 

  
     Director   

 

39


THE DELEGATE COLLATERAL AGENT        
Executed as a deed by DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, acting by                                          :        
    

 

  
     Director   
    

 

  
     Director   


LOGO

 

EXHIBIT O-1

Dated [] 2010

HULL NO. S. 678

FORM OF ASSIGNMENT OF KFW REFUND GUARANTEES

between

BREAKAWAY ONE, LTD.

as Company

and

KFW IPEX-BANK GMBH

as Collateral Agent

and

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

as Delegate

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


LOGO

 

TABLE OF CONTENTS

 

     Page  

1.      INTERPRETATION

     1   

2.      DELEGATION

     6   

3.      COVENANT TO PAY

     6   

4.      LEGAL ASSIGNMENT

     6   

5.      THE CONTRACT

     7   

6.      CONTINUING SECURITY

     8   

7.      REPRESENTATIONS AND WARRANTIES

     10   

8.      UNDERTAKINGS

     11   

9.      FURTHER ASSURANCE

     12   

10.    ENFORCEMENT OF SECURITY

     13   

11.    RECEIVERS

     13   

12.    APPLICATION OF PROCEEDS

     14   

13.    POWER OF ATTORNEY

     14   

14.    RELEASE OF THE SECURITY

     14   

15.    PAYMENTS

     15   

16.    WAIVERS AND REMEDIES

     15   

17.    ADDITIONAL PROVISIONS

     15   

18.    ASSIGNMENT

     16   

19.    NOTICES

     17   

20.    GOVERNING LAW

     19   

21.    COUNTERPARTS AND EFFECTIVENESS

     19   
SCHEDULE 1        FORM OF NOTICE OF ASSIGNMENT      20   
SCHEDULE 2        FORM OF ACKNOWLEDGMENT OF ASSIGNMENT      23   
SCHEDULE 3        DETAILS OF REFUND GUARANTEES      25   

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


THIS ASSIGNMENT is dated [] 2010

BETWEEN:

 

(1) BREAKAWAY ONE, LTD., a Bermuda company with its registered office as of the date hereof at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Company”); and

 

(2) KFW IPEX-BANK GMBH as collateral agent under each Credit Agreement for and on behalf of the Secured Creditors under and as defined in such Credit Agreement (the “Collateral Agent”, which expression includes any person which is for the time being a collateral agent for the Secured Creditors for the purposes of this Assignment).

 

(3) DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, the “Delegate”, which expression includes any person which is for the time being a delegate appointed by the Collateral Agent for the purposes of this Assignment.

RECITALS

 

(A) The applicable Lenders are willing to make a loan facility available to the Borrowers on the terms and subject to the conditions set out in the Credit Agreements, on condition that the Company enters into this Assignment as security for the Borrowers’ obligations and Liabilities as Borrower under or in relation to the Credit Documents.

 

(B) The Board of Directors of the Company is satisfied that the Company is entering into this Assignment for the purposes of its business and that its doing so benefits the Company.

 

(C) The Company and the Delegate intend this Assignment to take effect as a deed.

 

(D) Pursuant to the provisions of Clause 2 (Delegation) below, the Delegate holds the benefit of this Assignment on trust [for itself and] for the Secured Creditors on the terms of the Credit Agreements, the Security Trust Deeds and the Intercreditor Agreement.

 

1. INTERPRETATION

 

1.1 Definitions

In this Assignment the following terms have the meanings given to them in this Clause.

Acknowledgment of Assignment” means a duly completed acknowledgement of assignment in the form set out in Schedule 2 (Form of Acknowledgement of Assignment) or in such other form as may be approved by the Delegate.

Agent” means each Agent under and as defined in each Credit Agreement.

Agreed Rate” means the rate specified in section 2.06(b) and 2.06(c) (Interest) of each Credit Agreement.


Assigned Rights” means the Company’s rights, title, interest and benefits in, to and in respect of the Refund Guarantees.

Borrower” means Pride of Hawaii, LLC (“POH”) with respect to the Jade Credit Facility and Norwegian Jewel Limited (“NJL”) with respect to the Jewel Credit Facility.

Breakaway One Credit Facility” means the €529,846,154 credit agreement dated on or about the date hereof among, inter alia, the Parent, the Company, as borrower, the Joint Lead Arrangers (as defined therein), the Lenders (as defined therein), the Collateral Agent (as defined therein), Nordea Bank Norge ASA, as documentation agent and Commerzbank Aktiengesellschaft, as Hermes Agent.

Construction Contract” means the construction contract dated 24 September 2010 between the Company, the Parent and the Shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the Vessel.

Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Credit Agreement Obligations” means “Credit Document Obligations” as defined in the applicable Credit Agreements.

ECF Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Collateral Agent as security trustee, the Facility Agent and the Lenders under (and as defined in each of) the Export Credit Facilities.

Enforcement Proceeds” means any enforcement proceeds recovered in respect of the Security.

Event of Default” means an “Event of Default” as defined in the Credit Agreements.

Intercreditor Agreement” means the intercreditor deed dated on or about the date hereof between, inter alia, the Company, the Lenders, the lenders under the Breakaway One Credit Facility, the collateral agent under the Breakaway One Credit Facility, and the Collateral Agent (in its capacity as collateral agent under each of the Jade Credit Facility and the Jewel Credit Facility).

“Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, POH, as borrower, the Parent, the Lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jade Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, POH, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

“Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, NJL, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

 

2


“Jewel Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, NJL, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

Lender” means each Lender under and as defined in each Credit Agreement.

Lender Creditors” means the Agents and the Lenders.

Liability” means any liability for the payment of money, whether in respect of principal, interest or otherwise, whether actual or contingent, whether owed jointly or severally and whether owed as principal or surety or in any other capacity.

Notice of Assignment” means a duly completed notice of assignment in the form set out in Schedule 1 (Form of Notice of Assignment) or in such other form as may be approved by the Delegate.

Other Creditors” means each Lender or any affiliate thereof with which the applicable Borrower and/or the Parent may at any time and from time to time after the date hereof enter into, or guaranty the obligations of one or more of its Subsidiaries under one or more Interest Rate Protection Agreements or Other Hedging Agreements (even if the respective Lender subsequently ceases to be a Lender under the applicable Credit Agreement for any reason), together with such Lender’s or affiliate’s successors and assigns, if any.

Other Vessel 1 Assignment of KfW Refund Guarantees” means the assignment agreement dated on or about the date hereof between the Company, and the Delegate appointed by the Collateral Agent as its delegate pursuant to the ECF Security Trust Deeds to act as security trustee for and on behalf of the ECF Creditors (as defined in the Intercreditor Agreement) in respect of the Refund Guarantees.

Parent” means NCL Corporation Ltd., a Bermuda company.

Receiver” means a receiver and manager or any other receiver (whether appointed pursuant to this Assignment, pursuant to any statute, by a court or otherwise) of any of the Assigned Rights.

Refund Guarantees” means any and all refund guarantees from time to time issued in favour of the Company by KfW IPEX-Bank GmbH as refund guarantor to secure certain obligations of the Shipbuilder under the Construction Contract.

Secured Creditors” means the Lender Creditors and the Other Creditors.

Secured Obligations” means the Credit Agreement Obligations and the Other Obligations.

Security” means the security created by this Assignment.

 

3


Security Period” means the period beginning on the date of this Assignment and ending on the date upon which the Delegate is satisfied that:

 

  (a) none of the Secured Creditors is under any obligation (whether actual or contingent) to make advances or provide other financial accommodation to the Company under any of the Credit Documents; and

 

  (b) all Secured Obligations have been unconditionally and irrevocably paid and discharged in full (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreements).

Security Trust Deeds” means the Jade Security Trust Deed and the Jewel Security Trust Deed.

Shipbuilder” means Meyer Werft GmbH.

Vessel” means the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.678 to be constructed by the Shipbuilder.

 

1.2 Continuing Event of Default

An Event of Default shall be regarded as continuing if (a) the circumstances constituting such event continue and (b) such Event of Default has not been waived in accordance with the terms of the Credit Documents.

 

1.3 Defined Terms

Unless this Assignment provides otherwise, a term which is defined (or expressed to be subject to a particular construction) in the Credit Agreements or in the Intercreditor Agreement shall have the same meaning (or be subject to the same construction) in this Assignment.

 

1.4 References to Agreements

Unless otherwise stated, any reference in this Assignment to any agreement or document (including any reference to this Assignment or any other Credit Document) shall be construed as a reference to:

 

  (a) such agreement or document as amended, varied, novated or supplemented from time to time;

 

  (b) any other agreement or document whereby such agreement or document is so amended, varied, novated or supplemented; and

 

  (c) any other agreement or document entered into pursuant to or in accordance with such agreement or document.

 

1.5 Certificates

A certificate of any Secured Creditor as to the amount of any Secured Obligation owed to it shall be prima facie evidence of the existence and amount of such Secured Obligation.

 

4


1.6 Statutes

Any reference in this Assignment to a statute or statutory provision shall, unless the contrary is indicated, be construed as a reference to such statute or statutory provision as the same shall have been or may be amended or re-enacted.

 

1.7 Implied Covenants

The following provisions of the Law of Property (Miscellaneous Provisions) Act 1994 will not apply to Clause 4.1 (Assignment) or Clause 4.2 (Notice of Assignment):

 

  (a) the words “other than any charges, encumbrances or rights which that person does not and could not reasonably be expected to know about” in Section 3(1);

 

  (b) the words “except to the extent that” and all the words thereafter in Section 3(2); and

 

  (c) Section 6(2).

 

1.8 Third Party Rights

It is intended that with the consent of the Collateral Agent each of the other Secured Creditors shall be able to enforce the provisions of Clause 17.4 (Currency Indemnity) (which can be amended with the consent of the Collateral Agent but without the consent of the other Secured Creditors), but otherwise a person which is not a party to this Assignment shall have no rights to enforce the provisions of this Assignment other than those it would have had if the Contracts (Rights of Third Parties) Act 1999 had not come into effect.

 

1.9 Clause and Schedule Headings

Clause and Schedule headings are for ease of reference only and shall not affect the construction of this Assignment.

 

1.10 Intercreditor

This Assignment is subject to the terms of the Intercreditor Agreement.

 

5


2. DELEGATION

 

2.1 Pursuant to the Security Trust Deeds, the Collateral Agent hereby appoints the Delegate to act as trustee with respect to this Assignment and to have such rights, powers and duties as the Collateral Agent has or may have pursuant to the terms of the Security Trust Deeds including without limitation, the right to be indemnified under Clause 5.1 (Credit Parties’ Indemnity to Collateral Agent) of the Security Trust Deeds. The Delegate hereby accepts such appointment and agrees that it shall exercise all such rights, powers and duties in accordance with the instructions of the Collateral Agent, or in the absence of such instructions, in such manner as it shall reasonably determine acting in good faith and if the Collateral Agent so requires, shall appoint the Collateral Agent to exercise all and any of such rights, powers and duties in its name and on its behalf.

 

3. COVENANT TO PAY

 

3.1 Covenant to Pay

The Company agrees that promptly on demand of the Delegate it will pay to the Delegate any Secured Obligation that is due and owing by the Company provided that any recourse to the Company pursuant to this Assignment shall be limited to any Enforcement Proceeds.

 

3.2 Interest

Any amount which is owed by the Company under this Assignment and is not paid when due shall bear interest at the Agreed Rate from the due date until the date on which such amount is unconditionally and irrevocably paid in full and such interest shall accrue from day to day (after as well as before judgment) and be payable by the Company on demand of the Delegate.

 

4. LEGAL ASSIGNMENT

 

4.1 Assignment

The Company hereby assigns with full title guarantee the Assigned Rights to the Delegate to hold the same on behalf of the Secured Creditors on the terms set out in the Security Trust Deeds as security for the payment and discharge of the Secured Obligations.

 

4.2 Non-Assignable Rights

The Company declares that to the extent that any right, title, interest or benefit described in Clause 4.1 (Assignment) is for any reason not effectively assigned pursuant to Clause 4.1 (Assignment) for whatever reason, it shall:

 

  (a) hold the benefit of the same on trust for the Delegate as security for the payment and discharge of the Secured Obligations; and

 

  (b) promptly upon becoming aware of the same, notify the Delegate of the same and the reasons therefore and thereafter take such steps as the Delegate may reasonably require to remove such prohibition or other reason for such incapacity.

 

6


4.3 Notice of Assignment

 

  (a) As soon as practicable after the execution of this Assignment, the Company shall deliver to KfW IPEX-Bank GmbH, a Notice of Assignment and if the Delegate so requests the Company shall countersign such Notice of Assignment.

 

  (b) As soon as practicable after the execution of any Refund Guarantee entered into after the date of this Assignment, the Company shall deliver to KfW IPEX-Bank GmbH, a Notice of Assignment in respect of such Refund Guarantee.

 

4.4 Acknowledgment of Assignment

The Company shall use commercially reasonable efforts to procure that as soon as practicable after KfW IPEX-Bank GmbH receives a Notice of Assignment, KfW IPEX-Bank GmbH shall deliver to the Delegate an Acknowledgment of Assignment in substantially the form attached hereto or otherwise reasonably acceptable to the Delegate.

 

5. THE CONTRACT

 

5.1 No Dealings with the Refund Guarantee

 

  (a) The Company acknowledges that at all times during the Security Period and other than as expressly set out below, it shall not (nor shall it be entitled to):

 

  (i) receive any payments under or in respect of the Refund Guarantees;

 

  (ii) agree to any waiver or amendment of or supplement to the terms of the Refund Guarantees other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

  (iii) terminate, or allow to be terminated, any Refund Guarantee other than where an equivalent replacement Refund Guarantee is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination; or

 

  (iv) assign, charge or dispose of the Refund Guarantees or any of the Assigned Rights (other than pursuant to the Other Vessel 1 Assignment of KfW Refund Guarantees).

 

5.2 Performance of Obligations

The Company shall take, or cause to be taken, all steps reasonably required by the Delegate to preserve or protect its interests and the interests of the Delegate in the Refund Guarantees and shall diligently pursue any remedies available to it in respect

 

7


of any breaches or claims of any party in connection with any of the Refund Guarantees which are necessary to preserve, protect and enforce the interests of the Delegate in the Refund Guarantees.

 

6. CONTINUING SECURITY

 

6.1 Continuing and Independent Security

This Assignment shall constitute and be continuing security which shall not be released or discharged by any intermediate payment or settlement of all or any of the Secured Obligations, shall continue in full force and effect until the end of the Security Period and is in addition to and independent of, and shall not prejudice or merge with, any other security (or any right of set-off) which the Delegate may have at any time for the Secured Obligations or any of them.

 

6.2 New Accounts

If the Delegate receives notice of any security created or arising during the Security Period in respect of the Refund Guarantees or any of the Assigned Rights (other than pursuant to the Other Vessel 1 Assignment of KfW Refund Guarantees), or following the occurrence and during the continuation of an Event of Default makes demand of the Parent or the applicable Borrower for payment of any or all of the Secured Obligations:

 

  (a) the Delegate may open a new account or accounts in respect of any or all of the Secured Obligations (and if it does not do so it shall be treated as if it had done so at the time it received such notice or made such demand); and

 

  (b) thereafter any amounts paid by the Parent or the applicable Borrower to the Delegate in respect of the Secured Obligations, or realised or recovered by the Delegate under this Assignment, shall be credited (or be treated as having been credited) to a new account and not as having been applied in or towards payment of all or any of the Secured Obligations.

 

6.3 Avoidance of Payments

Where any release, discharge or other arrangement in respect of any Secured Obligation or any security the Delegate may have for such Secured Obligation is given or made in reliance on any payment or other disposition which is avoided or must be repaid in an insolvency, liquidation or otherwise, and whether or not the Delegate has conceded or compromised any claim that any such payment or other disposition will or should be avoided or repaid, this Assignment and the Security shall continue as if such release, discharge or other arrangement had not been given or made.

 

6.4 Immediate Recourse

Neither the Delegate nor any other Secured Creditor shall be obliged before exercising any of the rights conferred on it or them by this Assignment or by law to seek to recover amounts due from the Parent or to exercise or enforce any other rights or security it or they may have or hold in respect of the Secured Obligations.

 

8


6.5 Waiver of Defences

Neither the obligations of the Company under this Assignment nor the Security and the rights, powers and remedies conferred on the Delegate by this Assignment or by law, shall be discharged, impaired or otherwise affected by:

 

  (a) the winding-up, dissolution, administration or reorganisation of the Company or any other person or any change in the status, function, control or ownership of the Company or any such person;

 

  (b) any of the Secured Obligations or any other security held by the Delegate in respect thereof being or becoming illegal, invalid, unenforceable or ineffective in any respect;

 

  (c) any time or other indulgence being granted or agreed to with the Company or any other person in respect of the Secured Obligations or any of them or in respect of any other security held by the Delegate in respect thereof;

 

  (d) any amendment to, or any variation, waiver or release of, the Secured Obligations or any of them or any other security, guarantee or indemnity held by the Delegate in respect thereof;

 

  (e) any total or partial failure to take or perfect any security proposed to be taken in respect of the Secured Obligations or any of them;

 

  (f) any total or partial failure to realise the value of, or any release, discharge, exchange or substitution of, any other security, guarantee or indemnity held by the Delegate in respect of the Secured Obligations or any of them; or

 

  (g) any other act, event or omission which might operate to discharge, impair or otherwise affect the obligations of the Company under this Assignment, the Security or any of the rights, powers and remedies conferred on the Delegate by this Assignment or by law.

 

6.6 Appropriation

Neither the Collateral Agent, the Delegate nor any other Secured Creditor shall be obliged to apply any sums held or received by it in respect of the Secured Obligations in or towards payment of the Secured Obligations and any such sum shall be held by or paid to the Collateral Agent for application pursuant to the terms of this Assignment, until the earlier of:

 

  (a) the date on which such monies are sufficient to satisfy the Secured Obligations in full and any money so applied could not be the subject of any clawback or similar circumstance; and
  (b) the date on which the Security has been enforced in full and all other remedies that the Collateral Agent may have under or in connection with the Credit Documents in all relevant jurisdictions have been exhausted.

 

9


7. REPRESENTATIONS AND WARRANTIES

The Company makes the representations and warranties set out in Clauses 7.1 (Entity Status) to 7.8 (Refund Guarantee Terms). The Company acknowledges that each of the Collateral Agent and the Delegate has entered into this Assignment in reliance on those representations and warranties.

 

7.1 Entity Status

The Company (i) is a Person duly organized, constituted and validly existing (or the functional equivalent) under the laws of the jurisdiction of its formation, has the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted and (ii) is duly qualified and is authorized to do business and is in good standing (or the functional equivalent) in each jurisdiction where the ownership, leasing or operation of its property or the conduct of its business requires such qualifications except for failures to be so qualified or authorized or in good standing which, either individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.

 

7.2 Power and Authority

The Company has the power to enter into and perform this Assignment and the transactions contemplated hereby and has taken all necessary action to authorize the entry into and performance of this Assignment and such transactions. This Assignment constitutes legal, valid and binding obligations of the Company enforceable in accordance with its terms and in entering into this Assignment and borrowing the Loans, the Company is acting on its own account.

 

7.3 Form of Documentation

This Assignment is in proper legal form (under the laws of England, the Bahamas, Bermuda and each other jurisdiction where the Vessel is flagged or where the Company is domiciled) for the enforcement thereof under such laws. To ensure the legality, validity, enforceability or admissibility in evidence of this Assignment in England, the Bahamas and/or Bermuda it is not necessary that this Assignment be filed or recorded with any court or other authority in England, the Bahamas and Bermuda, except as have been made, or will be made, in accordance with Section 5, 6, 7 and 8 of the Credit Agreements, as applicable.

 

7.4 No Deductions or Withholdings

All amounts payable by the Company hereunder may be made free and clear of and without deduction or withholding for or on account of any Taxation in the Company’s jurisdiction.

 

7.5 No Filing or Stamp Taxes

It is not necessary that this Assignment be filed, recorded or enrolled with any court or other authority in England (or any other applicable jurisdiction) except as have been made or will be made in accordance with the Credit Agreements, or that any stamp, registration or similar tax be paid on or in relation to this Assignment save (i)

 

10


to the extent that it may be regarded as constituting a charge over book debts and thus as registrable under the Companies Act 2006 and (ii) recording taxes which have been or will be paid as and to the extent due.

 

7.6 No Adverse Interests

Subject only to the Security and as otherwise contemplated under the Intercreditor Agreement, the Breakaway One Credit Facility and the Credit Agreements, no person other than the Company has any legal or beneficial interest (or any right to claim any such interest) in the Assigned Rights or any part thereof and the Company has not received notice of any such claim.

 

7.7 No Disposals

Save as permitted by the Breakaway One Credit Facility, each Credit Agreement, this Assignment or the Intercreditor Agreement, it has not transferred, mortgaged, charged or otherwise disposed of (or agreed to transfer, charge or otherwise dispose of), whether by way of security or otherwise, the benefit of all or any of the Assigned Rights.

 

7.8 Refund Guarantee Terms

The terms of the Refund Guarantees do not restrict or otherwise limit its right to transfer, charge or assign any of the Assigned Rights pursuant to this Assignment.

 

7.9 Repetition

The representations and warranties set out in this Clause 7:

 

  (a) shall survive the execution of each Credit Document and each Borrowing under the Credit Agreements; and

 

  (b) are made on the date of this Assignment and are deemed to be repeated on each date during the Security Period with reference to the facts and circumstances then existing.

 

8. UNDERTAKINGS

 

8.1 Authorisations

The Company shall obtain, comply with the terms of and do all that is necessary to maintain in full force and effect all authorisations, approvals, licences and consents required in or by the laws of England and any other applicable jurisdiction to enable it lawfully to enter into and perform its obligations under this Assignment and to ensure the legality, validity, enforceability or admissibility in evidence in England and any other applicable jurisdiction of this Assignment.

 

8.2 No Action

The Company shall not take any action which would cause any of the representations made in Clause 7 (Representations and Warranties) to be untrue in any material respect at any time during the Security Period.

 

11


8.3 Notification of Misrepresentation

The Company shall notify each of the Collateral Agent and the Delegate of the occurrence of any event which results in or may reasonably be expected to result in any of the representations made in Clause 7 (Representations and Warranties) being untrue in any material respect when made or when deemed to be repeated.

 

8.4 Information

 

  (a) The Company shall provide each of the Collateral Agent and the Delegate with such reports and other information regarding the Refund Guarantees as the Collateral Agent and/or the Delegate may from time to time reasonably request.

 

  (b) Following the Initial Borrowing Date, the Company shall, as soon as reasonably practicable after an additional Refund Guarantee has been issued, deliver a supplement to Schedule 3 (Details of Refund Guarantees) to the Collateral Agent and/or the Delegate with updated information relating to such Refund Guarantee.

 

8.5 Delivery of Cash

Following the occurrence and during the continuation of an Event of Default, the Company shall promptly deliver all cash, proceeds, cheques, drafts, orders and other instruments for the payment of money received on account of any of the Refund Guarantees in the form received (properly endorsed, but without recourse, for collection where required) to the Delegate and shall not commingle any such collections or proceeds with its other funds or property and shall, subject to the terms of the Intercreditor Agreement, hold the same upon an express trust for and on behalf of the Delegate until delivered provided that, to the extent that the Intercreditor Agreement remains operative, the Company shall be relieved of its obligations under this clause 8.5 to the extent that it fulfils its obligations under clause 8.5 (Delivery of Cash) of the Other Vessel 1 Assignment of KfW Refund Guarantees.

 

8.6 Delivery of Notices

The Company shall promptly deliver a copy of any notice or other correspondence received by it in connection with any of the Refund Guarantees to each of the Collateral Agent and the Delegate if such notice or correspondence has had or could reasonably be expected to have a material adverse effect on the value of such Refund Guarantee.

 

9. FURTHER ASSURANCE

The Company shall from time to time and at its own expense give all such assurances and do all such things as the Collateral Agent and/or the Delegate may reasonably require or consider desirable to enable the Delegate to perfect, preserve or protect the security created or intended to be created by this Assignment or to exercise any of the rights conferred on it by this Assignment or by law and to that intent the Company shall execute all such instruments, deeds and agreements and give all such notices and directions as the Delegate may consider necessary.

 

12


10. ENFORCEMENT OF SECURITY

 

10.1 Security Enforceable

The Security shall become immediately enforceable if an Event of Default has occurred and is continuing.

 

10.2 Enforcement

Following the occurrence and during the continuation of an Event of Default, the Delegate shall act in accordance with the instructions of the Collateral Agent who shall act in accordance with the terms of any instructions received under the Intercreditor Agreement for the purposes of exercising (or refraining from exercising) any of its rights to enforce all or any part of the Security, and in the absence of any such instructions, the Delegate may in its absolute discretion enforce all or any part of the Security and exercise any of the rights conferred on it by this Assignment or by law at such times and in such manner as it thinks fit.

 

10.3 Power of Sale

Subject to the terms of the Intercreditor Agreement, following the occurrence and during the continuation of an Event of Default, the Delegate may (without notice to the Company) sell or otherwise dispose of the Assigned Rights and shall be entitled to apply the proceeds of such sale or other disposal in paying the costs of such sale or disposal and thereafter in or towards the discharge of the Secured Obligations or otherwise as provided for in this Assignment.

 

10.4 Statutory Powers

For the purposes of all powers implied by statute the Secured Obligations shall be deemed to have become due and payable on the date of this Assignment.

 

10.5 Law of Property Act

Sections 93 and 103 of the Law of Property Act 1925 shall not apply to this Assignment or to any exercise by the Delegate of its right to consolidate mortgages or its power of sale.

 

10.6 Realisation Accounts

If the Delegate enforces the Security (whether by appointment of a Receiver or otherwise), the Delegate may open and maintain with such financial institutions as it thinks fit one or more realisation accounts and pay any moneys it holds or receives under or pursuant to this Assignment into any such realisation account pending the application of such moneys pursuant to Clause 12 (Application of Proceeds).

 

11. RECEIVERS

 

11.1 Appointment of Receivers

At any time after the occurrence and during the continuation of an Event of Default, or if the Company requests it to do so, the Delegate may by a written instrument and

 

13


without notice to the Company appoint one or more persons as Receiver of all or any part of the Assigned Rights, each such person being entitled to act individually as well as jointly and being for all purposes the agent of the Company.

 

11.2 Powers of a Receiver

In addition to the powers conferred on the Delegate by this Assignment, each Receiver appointed pursuant to Clause 11.1 (Appointment of Receivers) shall have in relation to the Assigned Rights in respect of which such Receiver was appointed all the powers conferred by the Law of Property Act 1925 (as extended by this Assignment) on a Receiver appointed under that Act.

 

12. APPLICATION OF PROCEEDS

 

  (a) Any amounts received or recovered by the Delegate pursuant to or in connection with this Assignment shall be promptly paid to the Collateral Agent and pending such payment the Delegate shall hold such amounts on trust for the Collateral Agent.

 

  (b) Any moneys held or received by the Collateral Agent pursuant to paragraph (a) above shall be applied by the Collateral Agent in or towards the discharge of the Secured Obligations in accordance with the provisions of the Intercreditor Agreement.

 

13. POWER OF ATTORNEY

 

13.1 Appointment

By way of security for the performance of its obligations under this Assignment, the Company hereby irrevocably appoints the Delegate to be its attorney on its behalf and in its name or otherwise to do any and every thing which the Company is obliged to do under the terms of this Assignment or which the Delegate considers necessary or desirable in order to enable the Delegate to exercise the rights conferred on it by this Assignment or by law.

 

13.2 Ratification

The Company hereby ratifies and confirms and agrees to ratify and confirm whatever the Delegate shall do in its capacity as such.

 

14. RELEASE OF THE SECURITY

After the end of the Security Period or otherwise in accordance with Section 14.21 (Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer) of each Credit Agreement, the Delegate and/or the Collateral Agent shall, at the request and cost of the Company, execute all such documents and do all such other things as may be required to release the Security, in each case without recourse to or any representation or warranty by or from the Collateral Agent and/or the Delegate (as applicable).

 

14


15. PAYMENTS

 

15.1 Grossing Up

All payments by the Company under this Assignment shall be made without any deductions and free and clear of, and without deduction for or on account of, tax except, in the latter case, to the extent that the Company is required by law to make payment subject to tax. If any tax or amounts in respect of tax must be deducted, or any other deductions must be made, from any amounts payable or paid by the Company, or paid or payable by the Delegate to any Secured Creditor, under this Assignment, the Company shall pay such additional amounts as may be necessary to ensure that the relevant Secured Creditor receives a net amount equal to the full amount which it would have received had payment not been made subject to tax.

 

15.2 Payments without Set-off

Any payment made by the Company under this Assignment shall be made free and clear of and without any deduction for or on account of any set-off or counterclaim.

 

15.3 Manner of Payment

Each payment made by the Company under this Assignment shall be paid in the manner in which payments are to be made by the Company under each Credit Agreement.

 

16. WAIVERS AND REMEDIES

No failure by the Delegate to exercise, nor any delay by the Delegate in exercising, any right or remedy under this Assignment shall operate as a waiver thereof nor shall any single or partial exercise of any such right or remedy prevent any further or other exercise thereof or the exercise of any other such right or remedy.

 

17. ADDITIONAL PROVISIONS

 

17.1 Partial Invalidity

If at any time any provision of this Assignment is or becomes illegal, invalid or unenforceable in any respect or any of the Security is or becomes ineffective in any respect under the law of any jurisdiction, such illegality, invalidity, unenforceability or ineffectiveness shall not affect:

 

  (a) the legality, validity or enforceability of the remaining provisions of this Assignment or the effectiveness in any other respect of the Security under such law; or

 

  (b) the legality, validity or enforceability of such provision or the effectiveness of the Security under the law of any other jurisdiction.

 

17.2 Potentially Avoided Payments

If the Delegate determines that an amount paid to a Secured Creditor under any Credit Document is being avoided or otherwise set aside on the liquidation or administration of the person by whom such amount was paid, then for the purposes of this Assignment, such amount shall be regarded as not having been paid.

 

15


17.3 Currency Conversion

If necessary to apply any sum held or received by the Delegate in or towards payment of the Secured Obligations, the Delegate may purchase an amount in another currency and the rate of exchange to be applied shall be that at which, at such time as it considers appropriate, the Delegate is able to effect such purchase.

 

17.4 Currency Indemnity

If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from the Company hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Delegate could purchase the specified currency with such other currency on the Business Day preceding that on which final judgment is given. The obligations of the Company in respect of any sum due to the Delegate hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by the Delegate of any sum adjudged to be so due in such other currency the Delegate may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to the Delegate in the specified currency, the Company agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify the Delegate against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to the Delegate in the specified currency, the Delegate agrees to remit such excess to the Company.

 

17.5 Rights Cumulative

The rights and remedies provided by this Assignment are cumulative and not exclusive of any rights or remedies provided by law.

 

17.6 Delegate in Possession

The Delegate shall not by reason of its taking any action permitted by this Assignment or its taking possession of all or any of the Assigned Rights be liable to account as mortgagee in possession or, other than as expressly stated in each Security Trust Deed, be liable for any loss on realisation or for any default or omission for which a mortgagee in possession might be liable.

 

18. ASSIGNMENT

 

18.1 The Company’s Rights

The rights of the Company under this Assignment are not assignable or transferable and the Company agrees that it will not purport to assign all or any such rights except as provided under the Breakaway One Credit Facility and the Credit Agreements.

 

16


18.2 The Delegate’s Rights

 

  (a) The rights of the Delegate under this Assignment are assignable in whole or in part without the consent of the Company except as provided under the Credit Agreements.

 

  (b) The Delegate may not resign except with the prior consent of the Collateral Agent and otherwise, in accordance with the terms of the Security Trust Deeds.

 

19. NOTICES

 

19.1 Communications in Writing

Each communication to be made under this Assignment shall be made in writing and, unless otherwise stated, may be made by fax, electronic mail or letter.

 

19.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 19.1 (Communications in writing) the contact details of each of the parties are as follows:

 

  (a) to the Delegate:

 

Domstrasse 18
D - 20095 Hamburg
Germany
Attn.:    Marcus Weber / Anne Randewig
Telephone:    +49 40 3769 -9646 / -9647
Facsimile:    +49 40 3769 -9649
e-mail:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

 

  (b) to the Collateral Agent:

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

  (c) to the Company:

7665 Corporation Center Drive

Miami, Florida 33126

USA

 

17


Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

             hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com

or to such other address and/or number as is notified in writing by a party to the other parties under this Assignment.

 

19.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified in Clause 19.2 (Contact Details); provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Collateral Agent, the Delegate and the Company agree that they (x) shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and (y) shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Collateral Agent and the Delegate shall not be effective until received by the Collateral Agent or the Delegate (as applicable), or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Company to the Collateral Agent or the Delegate, only if it is addressed in such a manner as the Collateral Agent and/or the Delegate shall specify for this purpose.

 

18


20. GOVERNING LAW

 

  (a) This Assignment and any non-contractual obligations arising out of or in connection with it shall be governed by and construed in accordance with English law.

 

  (b) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Assignment (including a dispute relating to the existence, validity or termination of this Assignment or any non-contractual obligation arising out of or in connection with this Assignment ) (a “Dispute”). The parties hereto agree that the courts of England are the most appropriate and convenient courts to settle disputes and accordingly no party hereto will argue to the contrary. This Clause 20 is for the benefit of the Collateral Agent on behalf of Secured Creditors and the Delegate on behalf of Secured Creditors. As a result, it shall not be prevented from taking proceedings relating to a dispute in any other courts with jurisdiction. To the extent allowed by law, the Collateral Agent and the Delegate may take concurrent proceedings in any number of jurisdictions.

 

  (c) Without prejudice to any other mode of service allowed under any relevant law, the Company: (i) irrevocably appoints EC3 Services Limited at 51 Eastcheap, London, England, EC3M 1JP as its agent for service of process in relation to any proceedings before the English courts in connection with any credit document and (ii) agrees that failure by an agent for service of process to notify the relevant credit party of the process will not invalidate the proceedings concerned. If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Company must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the Collateral Agent and the Delegate. Failing this, the Collateral Agent and/or the Delegate may appoint another agent for this purpose.

 

  (d) Each party to this Assignment expressly agrees and consents to the provisions of this Clause 20.

 

21. COUNTERPARTS AND EFFECTIVENESS

 

21.1 Counterparts

This Assignment may be executed in counterparts and such counterparts taken together shall constitute one and the same instrument.

 

21.2 Effectiveness

This Assignment shall take effect and be delivered as a deed on the date on which it is stated to be made.

IN WITNESS WHEREOF this Assignment has been executed as a deed by the Company, the Collateral Agent and the Delegate.

 

19


SCHEDULE 1

FORM OF NOTICE OF ASSIGNMENT

 

To: KfW IPEX-Bank GmbH as Refund Guarantor

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: []

 

Cc: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Cc: Deutsche Schiffsbank Aktiengesellschaft as Delegate

Domstrasse 18

D - 20095 Hamburg

Germany

 

Attn.:

   Marcus Weber / Anne Randewig   

Telephone:

   +49 40 3769 -9646 / -9647   

Facsimile:

   +49 40 3769 -9649   

e-mail:

   marcus.weber@commerzbank.com   
   anne.randewig@commerzbank.com   

Date: []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway One, Ltd. (the “Company”), KfW IPEX-Bank GmbH as Collateral Agent and [] as delegate (the “Delegate”), the Company has assigned to the Delegate a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the refund guarantee dated [] and issued by you as refund guarantor in favour of the Company pursuant to which you guarantee certain refund obligations of Meyer Werft GmbH, as shipbuilder under the Construction Contract (as defined in the Assignment) (the “Refund Guarantee”), including all monies which may be payable under or in respect of the Refund Guarantee.

 

20


With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Refund Guarantee should be made to the Delegate or to its order as it may specify in writing from time to time;

 

(b) following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)), written notice of which Event of Default has been delivered to you by the Delegate, all remedies of the Company provided for in the Refund Guarantee or available at law or in equity shall be exercisable by the Delegate;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Refund Guarantee shall be exercisable by the Delegate;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Refund Guarantee are assigned to the Delegate and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(e) the Company has agreed not to agree to any waiver or amendment of or supplement to the terms of the Refund Guarantee other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Refund Guarantee other than where a replacement Refund Guarantee is issued to the Company which meets the Company’s requirements under the Construction Contract on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each Credit Agreement) to such termination;

 

(g) the Delegate has agreed that the Company may exercise all of its rights and powers under and in respect of the Refund Guarantee except that to the extent that the Delegate notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Delegate may exercise such rights and powers (to the exclusion of the Company) (including, without limitation, making a demand under the Refund Guarantee) to the extent stated in that notice and without you being under any duty to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h)

the Company has irrevocably appointed the Delegate to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other

 

21


 

things) things which the Company could do in relation to the Refund Guarantee. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Delegate from time to time in connection with the Refund Guarantee without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Refund Guarantee and the Delegate is under no obligation of any kind under the Refund Guarantee nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Delegate with such information relating to the Refund Guarantee as it may from time to time reasonably request and to send copies of all notices issued by you under the Refund Guarantee which have had or would reasonably be expected to have a material adverse effect on the value of the Refund Guarantee, to the Delegate as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Delegate).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Delegate.

Yours faithfully

 

 

For and on behalf of
BREAKAWAY ONE, LTD.

 

22


SCHEDULE 2

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT

[To be printed only on copy of the Notice of Assignment given]

 

To:    Deutsche Schiffsbank Aktiengesellschaft as Delegate
   Domstrasse 18
   D - 20095 Hamburg
   Germany

 

Attn.:    Marcus Weber / Anne Randewig
Telephone:    +49 40 3769 -9646 / -9647
Facsimile:    +49 40 3769 -9649
e-mail:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

 

Cc:    KfW IPEX-Bank GmbH as Collateral Agent
   Palmengartenstrasse 5-9
   60325 Frankfurt am Main
   Germany
   Attention: Ship Finance, X2a4, Claudia Wenzel
   Fax: +49 69 7431 2944
   E-mail: claudia.wenzel@kfw.de

Date: []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Delegate as security trustee on behalf of certain “ECF creditors” in respect of the Refund Guarantee) we have not received notice of any other assignments or charges of or over any of the rights, title, interests and benefits in, to or in respect of the Refund Guarantee and that we will comply with the terms of the Notice.

We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable).

 

23


Yours faithfully

 

For and on behalf of

KfW IPEX-Bank GmbH

as Refund Guarantor

By:
Date:

 

24


SCHEDULE 3

DETAILS OF REFUND GUARANTEES

 

[Name of Issuer]   [Date of Refund Guarantee]

 

25


SIGNATORIES

 

Signed as a deed on behalf of BREAKAWAY ONE, LTD, a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]
Signed as a deed on behalf of DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]
Signed as a deed on behalf of KFW IPEX-BANK GMBH, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]

 

26


LOGO

 

EXHIBIT O-2

Dated [] 2010

HULL NO. S. 692

FORM OF ASSIGNMENT OF KFW REFUND GUARANTEES

between

BREAKAWAY TWO, LTD.

as Company

and

KFW IPEX-BANK GMBH

as Collateral Agent

and

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

as Delegate

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


LOGO

 

TABLE OF CONTENTS

 

          Page  

1.      INTERPRETATION

     1   

2.      DELEGATION

     6   

3.      COVENANT TO PAY

     6   

4.      LEGAL ASSIGNMENT

     6   

5.      THE CONTRACT

     7   

6.      CONTINUING SECURITY

     8   

7.      REPRESENTATIONS AND WARRANTIES

     10   

8.      UNDERTAKINGS

     11   

9.      FURTHER ASSURANCE

     12   

10.    ENFORCEMENT OF SECURITY

     13   

11.    RECEIVERS

     13   

12.    APPLICATION OF PROCEEDS

     14   

13.    POWER OF ATTORNEY

     14   

14.    RELEASE OF THE SECURITY

     14   

15.    PAYMENTS

     15   

16.    WAIVERS AND REMEDIES

     15   

17.    ADDITIONAL PROVISIONS

     15   

18.    ASSIGNMENT

     16   

19.    NOTICES

     17   

20.    GOVERNING LAW

     19   

21.    COUNTERPARTS AND EFFECTIVENESS

     19   

SCHEDULE 1        FORM OF NOTICE OF ASSIGNMENT

     20   

SCHEDULE 2        FORM OF ACKNOWLEDGMENT OF ASSIGNMENT

     23   

SCHEDULE 3        DETAILS OF REFUND GUARANTEES

     25   

 

 

White & Case LLP

5 Old Broad Street

London EC2N 1DW


THIS ASSIGNMENT is dated [] 2010

BETWEEN:

 

(1) BREAKAWAY TWO, LTD., a Bermuda company with its registered office as of the date hereof at Milner House, 18 Parliament Street, Hamilton HM12, Bermuda (the “Company”); and

 

(2) KFW IPEX-BANK GMBH as collateral agent under each Credit Agreement for and on behalf of the Secured Creditors under and as defined in such Credit Agreement (the “Collateral Agent”, which expression includes any person which is for the time being a collateral agent for the Secured Creditors for the purposes of this Assignment).

 

(3) DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, the “Delegate”, which expression includes any person which is for the time being a delegate appointed by the Collateral Agent for the purposes of this Assignment.

RECITALS

 

(A) The applicable Lenders are willing to make a loan facility available to the Borrowers on the terms and subject to the conditions set out in the Credit Agreements, on condition that the Company enters into this Assignment as security for the Borrowers’ obligations and Liabilities as Borrower under or in relation to the Credit Documents.

 

(B) The Board of Directors of the Company is satisfied that the Company is entering into this Assignment for the purposes of its business and that its doing so benefits the Company.

 

(C) The Company and the Delegate intend this Assignment to take effect as a deed.

 

(D) Pursuant to the provisions of Clause 2 (Delegation) below, the Delegate holds the benefit of this Assignment on trust [for itself and] for the Secured Creditors on the terms of the Credit Agreements, the Security Trust Deeds and the Intercreditor Agreement.

 

1. INTERPRETATION

 

1.1 Definitions

In this Assignment the following terms have the meanings given to them in this Clause.

Acknowledgment of Assignment” means a duly completed acknowledgement of assignment in the form set out in Schedule 2 (Form of Acknowledgement of Assignment) or in such other form as may be approved by the Delegate.

Agent” means each Agent under and as defined in each Credit Agreement.

Agreed Rate” means the rate specified in section 2.06(b) and 2.06(c) (Interest) of each Credit Agreement.


Assigned Rights” means the Company’s rights, title, interest and benefits in, to and in respect of the Refund Guarantees.

Borrower” means Pride of Hawaii, LLC (“POH”) with respect to the Jade Credit Facility and Norwegian Jewel Limited (“NJL”) with respect to the Jewel Credit Facility.

Breakaway Two Credit Facility” means the €529,846,154 credit agreement dated on or about the date hereof among, inter alia, the Parent, the Company, as borrower, the Joint Lead Arrangers (as defined therein), the Lenders (as defined therein), the Collateral Agent (as defined therein), Nordea Bank Norge ASA, as documentation agent and Commerzbank Aktiengesellschaft, as Hermes Agent.

Construction Contract” means the construction contract dated 24 September 2010 between the Company, the Parent and the Shipbuilder in relation to the design, engineering, building, launching, equipping and outfitting of the Vessel.

Credit Agreements” means the Jade Credit Facility and the Jewel Credit Facility.

Credit Agreement Obligations” means “Credit Document Obligations” as defined in the applicable Credit Agreements.

ECF Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Collateral Agent as security trustee, the Facility Agent and the Lenders under (and as defined in each of) the Export Credit Facilities.

Enforcement Proceeds” means any enforcement proceeds recovered in respect of the Security.

Event of Default” means an “Event of Default” as defined in the Credit Agreements.

Intercreditor Agreement” means the intercreditor deed dated on or about the date hereof between, inter alia, the Company, the Lenders, the lenders under the Breakaway Two Credit Facility, the collateral agent under the Breakaway Two Credit Facility, and the Collateral Agent (in its capacity as collateral agent under each of the Jade Credit Facility and the Jewel Credit Facility).

“Jade Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, POH, as borrower, the Parent, the Lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

“Jade Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, POH, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

“Jewel Credit Facility” means the €126,075,000 delayed-draw term loan facility, dated on or about the date hereof, among inter alia, NJL, as borrower, the Parent, the lenders from time to time party thereto, KfW IPEX-Bank GmbH as facility agent and the Collateral Agent.

 

2


“Jewel Security Trust Deed” means the security trust deed dated on or about the date hereof between, inter alia, the Parent, NJL, the Collateral Agent, the Delegate Collateral Agent and the Facility Agent.

Lender” means each Lender under and as defined in each Credit Agreement.

Lender Creditors” means the Agents and the Lenders.

Liability” means any liability for the payment of money, whether in respect of principal, interest or otherwise, whether actual or contingent, whether owed jointly or severally and whether owed as principal or surety or in any other capacity.

Notice of Assignment” means a duly completed notice of assignment in the form set out in Schedule 1 (Form of Notice of Assignment) or in such other form as may be approved by the Delegate.

Other Creditors” means each Lender or any affiliate thereof with which the applicable Borrower and/or the Parent may at any time and from time to time after the date hereof enter into, or guaranty the obligations of one or more of its Subsidiaries under one or more Interest Rate Protection Agreements or Other Hedging Agreements (even if the respective Lender subsequently ceases to be a Lender under the applicable Credit Agreement for any reason), together with such Lender’s or affiliate’s successors and assigns, if any.

Other Vessel 2 Assignment of KfW Refund Guarantees” means the assignment agreement dated on or about the date hereof between the Company, and the Delegate appointed by the Collateral Agent as its delegate pursuant to the ECF Security Trust Deeds to act as security trustee for and on behalf of the ECF Creditors (as defined in the Intercreditor Agreement) in respect of the Refund Guarantees.

Parent” means NCL Corporation Ltd., a Bermuda company.

Receiver” means a receiver and manager or any other receiver (whether appointed pursuant to this Assignment, pursuant to any statute, by a court or otherwise) of any of the Assigned Rights.

Refund Guarantees” means any and all refund guarantees from time to time issued in favour of the Company by KfW IPEX-Bank GmbH as refund guarantor to secure certain obligations of the Shipbuilder under the Construction Contract.

Secured Creditors” means the Lender Creditors and the Other Creditors.

Secured Obligations” means the Credit Agreement Obligations and the Other Obligations.

Security” means the security created by this Assignment.

Security Period” means the period beginning on the date of this Assignment and ending on the date upon which the Delegate is satisfied that:

 

  (a) none of the Secured Creditors is under any obligation (whether actual or contingent) to make advances or provide other financial accommodation to the Company under any of the Credit Documents; and

 

3


  (b) all Secured Obligations have been unconditionally and irrevocably paid and discharged in full (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreements).

Security Trust Deeds” means the Jade Security Trust Deed and the Jewel Security Trust Deed.

Shipbuilder” means Meyer Werft GmbH.

Vessel” means the post-panamax luxury passenger cruise vessel with approximately 143,500 gt and the provisional hull number S.692 to be constructed by the Shipbuilder.

 

1.2 Continuing Event of Default

An Event of Default shall be regarded as continuing if (a) the circumstances constituting such event continue and (b) such Event of Default has not been waived in accordance with the terms of the Credit Documents.

 

1.3 Defined Terms

Unless this Assignment provides otherwise, a term which is defined (or expressed to be subject to a particular construction) in the Credit Agreements or in the Intercreditor Agreement shall have the same meaning (or be subject to the same construction) in this Assignment.

 

1.4 References to Agreements

Unless otherwise stated, any reference in this Assignment to any agreement or document (including any reference to this Assignment or any other Credit Document) shall be construed as a reference to:

 

  (a) such agreement or document as amended, varied, novated or supplemented from time to time;

 

  (b) any other agreement or document whereby such agreement or document is so amended, varied, novated or supplemented; and

 

  (c) any other agreement or document entered into pursuant to or in accordance with such agreement or document.

 

1.5 Certificates

A certificate of any Secured Creditor as to the amount of any Secured Obligation owed to it shall be prima facie evidence of the existence and amount of such Secured Obligation.

 

4


1.6 Statutes

Any reference in this Assignment to a statute or statutory provision shall, unless the contrary is indicated, be construed as a reference to such statute or statutory provision as the same shall have been or may be amended or re-enacted.

 

1.7 Implied Covenants

The following provisions of the Law of Property (Miscellaneous Provisions) Act 1994 will not apply to Clause 4.1 (Assignment) or Clause 4.2 (Notice of Assignment):

 

  (a) the words “other than any charges, encumbrances or rights which that person does not and could not reasonably be expected to know about” in Section 3(1);

 

  (b) the words “except to the extent that” and all the words thereafter in Section 3(2); and

 

  (c) Section 6(2).

 

1.8 Third Party Rights

It is intended that with the consent of the Collateral Agent each of the other Secured Creditors shall be able to enforce the provisions of Clause 17.4 (Currency Indemnity) (which can be amended with the consent of the Collateral Agent but without the consent of the other Secured Creditors), but otherwise a person which is not a party to this Assignment shall have no rights to enforce the provisions of this Assignment other than those it would have had if the Contracts (Rights of Third Parties) Act 1999 had not come into effect.

 

1.9 Clause and Schedule Headings

Clause and Schedule headings are for ease of reference only and shall not affect the construction of this Assignment.

 

1.10 Intercreditor

This Assignment is subject to the terms of the Intercreditor Agreement.

 

5


2. DELEGATION

 

2.1 Pursuant to the Security Trust Deeds, the Collateral Agent hereby appoints the Delegate to act as trustee with respect to this Assignment and to have such rights, powers and duties as the Collateral Agent has or may have pursuant to the terms of the Security Trust Deeds including without limitation, the right to be indemnified under Clause 5.1 (Credit Parties’ Indemnity to Collateral Agent) of the Security Trust Deeds. The Delegate hereby accepts such appointment and agrees that it shall exercise all such rights, powers and duties in accordance with the instructions of the Collateral Agent, or in the absence of such instructions, in such manner as it shall reasonably determine acting in good faith and if the Collateral Agent so requires, shall appoint the Collateral Agent to exercise all and any of such rights, powers and duties in its name and on its behalf.

 

3. COVENANT TO PAY

 

3.1 Covenant to Pay

The Company agrees that promptly on demand of the Delegate it will pay to the Delegate any Secured Obligation that is due and owing by the Company provided that any recourse to the Company pursuant to this Assignment shall be limited to any Enforcement Proceeds.

 

3.2 Interest

Any amount which is owed by the Company under this Assignment and is not paid when due shall bear interest at the Agreed Rate from the due date until the date on which such amount is unconditionally and irrevocably paid in full and such interest shall accrue from day to day (after as well as before judgment) and be payable by the Company on demand of the Delegate.

 

4. LEGAL ASSIGNMENT

 

4.1 Assignment

The Company hereby assigns with full title guarantee the Assigned Rights to the Delegate to hold the same on behalf of the Secured Creditors on the terms set out in the Security Trust Deeds as security for the payment and discharge of the Secured Obligations.

 

4.2 Non-Assignable Rights

The Company declares that to the extent that any right, title, interest or benefit described in Clause 4.1 (Assignment) is for any reason not effectively assigned pursuant to Clause 4.1 (Assignment) for whatever reason, it shall:

 

  (a) hold the benefit of the same on trust for the Delegate as security for the payment and discharge of the Secured Obligations; and

 

  (b) promptly upon becoming aware of the same, notify the Delegate of the same and the reasons therefore and thereafter take such steps as the Delegate may reasonably require to remove such prohibition or other reason for such incapacity.

 

6


4.3 Notice of Assignment

 

  (a) As soon as practicable after the execution of this Assignment, the Company shall deliver to KfW IPEX-Bank GmbH, a Notice of Assignment and if the Delegate so requests the Company shall countersign such Notice of Assignment.

 

  (b) As soon as practicable after the execution of any Refund Guarantee entered into after the date of this Assignment, the Company shall deliver to KfW IPEX-Bank GmbH, a Notice of Assignment in respect of such Refund Guarantee.

 

4.4 Acknowledgment of Assignment

The Company shall use commercially reasonable efforts to procure that as soon as practicable after KfW IPEX-Bank GmbH receives a Notice of Assignment, KfW IPEX-Bank GmbH shall deliver to the Delegate an Acknowledgment of Assignment in substantially the form attached hereto or otherwise reasonably acceptable to the Delegate.

 

5. THE CONTRACT

 

5.1 No Dealings with the Refund Guarantee

 

  (a) The Company acknowledges that at all times during the Security Period and other than as expressly set out below, it shall not (nor shall it be entitled to):

 

  (i) receive any payments under or in respect of the Refund Guarantees;

 

  (ii) agree to any waiver or amendment of or supplement to the terms of the Refund Guarantees other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

  (iii) terminate, or allow to be terminated, any Refund Guarantee other than where an equivalent replacement Refund Guarantee is entered into by the Company on or prior to such termination or where the prior written consent is given by the Facility Agent (not to be unreasonably withheld) to such termination; or

 

  (iv) assign, charge or dispose of the Refund Guarantees or any of the Assigned Rights (other than pursuant to the Other Vessel 2 Assignment of KfW Refund Guarantees).

 

5.2 Performance of Obligations

The Company shall take, or cause to be taken, all steps reasonably required by the Delegate to preserve or protect its interests and the interests of the Delegate in the Refund Guarantees and shall diligently pursue any remedies available to it in respect

 

7


of any breaches or claims of any party in connection with any of the Refund Guarantees which are necessary to preserve, protect and enforce the interests of the Delegate in the Refund Guarantees.

 

6. CONTINUING SECURITY

 

6.1 Continuing and Independent Security

This Assignment shall constitute and be continuing security which shall not be released or discharged by any intermediate payment or settlement of all or any of the Secured Obligations, shall continue in full force and effect until the end of the Security Period and is in addition to and independent of, and shall not prejudice or merge with, any other security (or any right of set-off) which the Delegate may have at any time for the Secured Obligations or any of them.

 

6.2 New Accounts

If the Delegate receives notice of any security created or arising during the Security Period in respect of the Refund Guarantees or any of the Assigned Rights (other than pursuant to the Other Vessel 2 Assignment of KfW Refund Guarantees), or following the occurrence and during the continuation of an Event of Default makes demand of the Parent or the applicable Borrower for payment of any or all of the Secured Obligations:

 

  (a) the Delegate may open a new account or accounts in respect of any or all of the Secured Obligations (and if it does not do so it shall be treated as if it had done so at the time it received such notice or made such demand); and

 

  (b) thereafter any amounts paid by the Parent or the applicable Borrower to the Delegate in respect of the Secured Obligations, or realised or recovered by the Delegate under this Assignment, shall be credited (or be treated as having been credited) to a new account and not as having been applied in or towards payment of all or any of the Secured Obligations.

 

6.3 Avoidance of Payments

Where any release, discharge or other arrangement in respect of any Secured Obligation or any security the Delegate may have for such Secured Obligation is given or made in reliance on any payment or other disposition which is avoided or must be repaid in an insolvency, liquidation or otherwise, and whether or not the Delegate has conceded or compromised any claim that any such payment or other disposition will or should be avoided or repaid, this Assignment and the Security shall continue as if such release, discharge or other arrangement had not been given or made.

 

6.4 Immediate Recourse

Neither the Delegate nor any other Secured Creditor shall be obliged before exercising any of the rights conferred on it or them by this Assignment or by law to seek to recover amounts due from the Parent or to exercise or enforce any other rights or security it or they may have or hold in respect of the Secured Obligations.

 

8


6.5 Waiver of Defences

Neither the obligations of the Company under this Assignment nor the Security and the rights, powers and remedies conferred on the Delegate by this Assignment or by law, shall be discharged, impaired or otherwise affected by:

 

  (a) the winding-up, dissolution, administration or reorganisation of the Company or any other person or any change in the status, function, control or ownership of the Company or any such person;

 

  (b) any of the Secured Obligations or any other security held by the Delegate in respect thereof being or becoming illegal, invalid, unenforceable or ineffective in any respect;

 

  (c) any time or other indulgence being granted or agreed to with the Company or any other person in respect of the Secured Obligations or any of them or in respect of any other security held by the Delegate in respect thereof;

 

  (d) any amendment to, or any variation, waiver or release of, the Secured Obligations or any of them or any other security, guarantee or indemnity held by the Delegate in respect thereof;

 

  (e) any total or partial failure to take or perfect any security proposed to be taken in respect of the Secured Obligations or any of them;

 

  (f) any total or partial failure to realise the value of, or any release, discharge, exchange or substitution of, any other security, guarantee or indemnity held by the Delegate in respect of the Secured Obligations or any of them; or

 

  (g) any other act, event or omission which might operate to discharge, impair or otherwise affect the obligations of the Company under this Assignment, the Security or any of the rights, powers and remedies conferred on the Delegate by this Assignment or by law.

 

6.6 Appropriation

Neither the Collateral Agent, the Delegate nor any other Secured Creditor shall be obliged to apply any sums held or received by it in respect of the Secured Obligations in or towards payment of the Secured Obligations and any such sum shall be held by or paid to the Collateral Agent for application pursuant to the terms of this Assignment, until the earlier of:

 

  (a) the date on which such monies are sufficient to satisfy the Secured Obligations in full and any money so applied could not be the subject of any clawback or similar circumstance; and

 

  (b) the date on which the Security has been enforced in full and all other remedies that the Collateral Agent may have under or in connection with the Credit Documents in all relevant jurisdictions have been exhausted.

 

9


7. REPRESENTATIONS AND WARRANTIES

The Company makes the representations and warranties set out in Clauses 7.1 (Entity Status) to 7.8 (Refund Guarantee Terms). The Company acknowledges that each of the Collateral Agent and the Delegate has entered into this Assignment in reliance on those representations and warranties.

 

7.1 Entity Status

The Company (i) is a Person duly organized, constituted and validly existing (or the functional equivalent) under the laws of the jurisdiction of its formation, has the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted and (ii) is duly qualified and is authorized to do business and is in good standing (or the functional equivalent) in each jurisdiction where the ownership, leasing or operation of its property or the conduct of its business requires such qualifications except for failures to be so qualified or authorized or in good standing which, either individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.

 

7.2 Power and Authority

The Company has the power to enter into and perform this Assignment and the transactions contemplated hereby and has taken all necessary action to authorize the entry into and performance of this Assignment and such transactions. This Assignment constitutes legal, valid and binding obligations of the Company enforceable in accordance with its terms and in entering into this Assignment and borrowing the Loans, the Company is acting on its own account.

 

7.3 Form of Documentation

This Assignment is in proper legal form (under the laws of England, the Bahamas, Bermuda and each other jurisdiction where the Vessel is flagged or where the Company is domiciled) for the enforcement thereof under such laws. To ensure the legality, validity, enforceability or admissibility in evidence of this Assignment in England, the Bahamas and/or Bermuda it is not necessary that this Assignment be filed or recorded with any court or other authority in England, the Bahamas and Bermuda, except as have been made, or will be made, in accordance with Section 5, 6, 7 and 8 of the Credit Agreements, as applicable.

 

7.4 No Deductions or Withholdings

All amounts payable by the Company hereunder may be made free and clear of and without deduction or withholding for or on account of any Taxation in the Company’s jurisdiction.

 

7.5 No Filing or Stamp Taxes

It is not necessary that this Assignment be filed, recorded or enrolled with any court or other authority in England (or any other applicable jurisdiction) except as have been made or will be made in accordance with the Credit Agreements, or that any stamp, registration or similar tax be paid on or in relation to this Assignment save (i)

 

10


to the extent that it may be regarded as constituting a charge over book debts and thus as registrable under the Companies Act 2006 and (ii) recording taxes which have been or will be paid as and to the extent due.

 

7.6 No Adverse Interests

Subject only to the Security and as otherwise contemplated under the Intercreditor Agreement, the Breakaway Two Credit Facility and the Credit Agreements, no person other than the Company has any legal or beneficial interest (or any right to claim any such interest) in the Assigned Rights or any part thereof and the Company has not received notice of any such claim.

 

7.7 No Disposals

Save as permitted by the Breakaway Two Credit Facility, each Credit Agreement, this Assignment or the Intercreditor Agreement, it has not transferred, mortgaged, charged or otherwise disposed of (or agreed to transfer, charge or otherwise dispose of), whether by way of security or otherwise, the benefit of all or any of the Assigned Rights.

 

7.8 Refund Guarantee Terms

The terms of the Refund Guarantees do not restrict or otherwise limit its right to transfer, charge or assign any of the Assigned Rights pursuant to this Assignment.

 

7.9 Repetition

The representations and warranties set out in this Clause 7:

 

  (a) shall survive the execution of each Credit Document and each Borrowing under the Credit Agreements; and

 

  (b) are made on the date of this Assignment and are deemed to be repeated on each date during the Security Period with reference to the facts and circumstances then existing.

 

8. UNDERTAKINGS

 

8.1 Authorisations

The Company shall obtain, comply with the terms of and do all that is necessary to maintain in full force and effect all authorisations, approvals, licences and consents required in or by the laws of England and any other applicable jurisdiction to enable it lawfully to enter into and perform its obligations under this Assignment and to ensure the legality, validity, enforceability or admissibility in evidence in England and any other applicable jurisdiction of this Assignment.

 

8.2 No Action

The Company shall not take any action which would cause any of the representations made in Clause 7 (Representations and Warranties) to be untrue in any material respect at any time during the Security Period.

 

11


8.3 Notification of Misrepresentation

The Company shall notify each of the Collateral Agent and the Delegate of the occurrence of any event which results in or may reasonably be expected to result in any of the representations made in Clause 7 (Representations and Warranties) being untrue in any material respect when made or when deemed to be repeated.

 

8.4 Information

 

  (a) The Company shall provide each of the Collateral Agent and the Delegate with such reports and other information regarding the Refund Guarantees as the Collateral Agent and/or the Delegate may from time to time reasonably request.

 

  (b) Following the Initial Borrowing Date, the Company shall, as soon as reasonably practicable after an additional Refund Guarantee has been issued, deliver a supplement to Schedule 3 (Details of Refund Guarantees) to the Collateral Agent and/or the Delegate with updated information relating to such Refund Guarantee.

 

8.5 Delivery of Cash

Following the occurrence and during the continuation of an Event of Default, the Company shall promptly deliver all cash, proceeds, cheques, drafts, orders and other instruments for the payment of money received on account of any of the Refund Guarantees in the form received (properly endorsed, but without recourse, for collection where required) to the Delegate and shall not commingle any such collections or proceeds with its other funds or property and shall, subject to the terms of the Intercreditor Agreement, hold the same upon an express trust for and on behalf of the Delegate until delivered provided that, to the extent that the Intercreditor Agreement remains operative, the Company shall be relieved of its obligations under this clause 8.5 to the extent that it fulfils its obligations under clause 8.5 (Delivery of Cash) of the Other Vessel 2 Assignment of KfW Refund Guarantees.

 

8.6 Delivery of Notices

The Company shall promptly deliver a copy of any notice or other correspondence received by it in connection with any of the Refund Guarantees to each of the Collateral Agent and the Delegate if such notice or correspondence has had or could reasonably be expected to have a material adverse effect on the value of such Refund Guarantee.

 

9. FURTHER ASSURANCE

The Company shall from time to time and at its own expense give all such assurances and do all such things as the Collateral Agent and/or the Delegate may reasonably require or consider desirable to enable the Delegate to perfect, preserve or protect the security created or intended to be created by this Assignment or to exercise any of the rights conferred on it by this Assignment or by law and to that intent the Company shall execute all such instruments, deeds and agreements and give all such notices and directions as the Delegate may consider necessary.

 

12


10. ENFORCEMENT OF SECURITY

 

10.1 Security Enforceable

The Security shall become immediately enforceable if an Event of Default has occurred and is continuing.

 

10.2 Enforcement

Following the occurrence and during the continuation of an Event of Default, the Delegate shall act in accordance with the instructions of the Collateral Agent who shall act in accordance with the terms of any instructions received under the Intercreditor Agreement for the purposes of exercising (or refraining from exercising) any of its rights to enforce all or any part of the Security, and in the absence of any such instructions, the Delegate may in its absolute discretion enforce all or any part of the Security and exercise any of the rights conferred on it by this Assignment or by law at such times and in such manner as it thinks fit.

 

10.3 Power of Sale

Subject to the terms of the Intercreditor Agreement, following the occurrence and during the continuation of an Event of Default, the Delegate may (without notice to the Company) sell or otherwise dispose of the Assigned Rights and shall be entitled to apply the proceeds of such sale or other disposal in paying the costs of such sale or disposal and thereafter in or towards the discharge of the Secured Obligations or otherwise as provided for in this Assignment.

 

10.4 Statutory Powers

For the purposes of all powers implied by statute the Secured Obligations shall be deemed to have become due and payable on the date of this Assignment.

 

10.5 Law of Property Act

Sections 93 and 103 of the Law of Property Act 1925 shall not apply to this Assignment or to any exercise by the Delegate of its right to consolidate mortgages or its power of sale.

 

10.6 Realisation Accounts

If the Delegate enforces the Security (whether by appointment of a Receiver or otherwise), the Delegate may open and maintain with such financial institutions as it thinks fit one or more realisation accounts and pay any moneys it holds or receives under or pursuant to this Assignment into any such realisation account pending the application of such moneys pursuant to Clause 12 (Application of Proceeds).

 

11. RECEIVERS

 

11.1 Appointment of Receivers

At any time after the occurrence and during the continuation of an Event of Default, or if the Company requests it to do so, the Delegate may by a written instrument and

 

13


without notice to the Company appoint one or more persons as Receiver of all or any part of the Assigned Rights, each such person being entitled to act individually as well as jointly and being for all purposes the agent of the Company.

 

11.2 Powers of a Receiver

In addition to the powers conferred on the Delegate by this Assignment, each Receiver appointed pursuant to Clause 11.1 (Appointment of Receivers) shall have in relation to the Assigned Rights in respect of which such Receiver was appointed all the powers conferred by the Law of Property Act 1925 (as extended by this Assignment) on a Receiver appointed under that Act.

 

12. APPLICATION OF PROCEEDS

 

  (a) Any amounts received or recovered by the Delegate pursuant to or in connection with this Assignment shall be promptly paid to the Collateral Agent and pending such payment the Delegate shall hold such amounts on trust for the Collateral Agent.

 

  (b) Any moneys held or received by the Collateral Agent pursuant to paragraph (a) above shall be applied by the Collateral Agent in or towards the discharge of the Secured Obligations in accordance with the provisions of the Intercreditor Agreement.

 

13. POWER OF ATTORNEY

 

13.1 Appointment

By way of security for the performance of its obligations under this Assignment, the Company hereby irrevocably appoints the Delegate to be its attorney on its behalf and in its name or otherwise to do any and every thing which the Company is obliged to do under the terms of this Assignment or which the Delegate considers necessary or desirable in order to enable the Delegate to exercise the rights conferred on it by this Assignment or by law.

 

13.2 Ratification

The Company hereby ratifies and confirms and agrees to ratify and confirm whatever the Delegate shall do in its capacity as such.

 

14. RELEASE OF THE SECURITY

After the end of the Security Period or otherwise in accordance with Section 14.21 (Release of Liens and the Parent Guaranty; Flag Jurisdiction Transfer) of each Credit Agreement, the Delegate and/or the Collateral Agent shall, at the request and cost of the Company, execute all such documents and do all such other things as may be required to release the Security, in each case without recourse to or any representation or warranty by or from the Collateral Agent and/or the Delegate (as applicable).

 

14


15. PAYMENTS

 

15.1 Grossing Up

All payments by the Company under this Assignment shall be made without any deductions and free and clear of, and without deduction for or on account of, tax except, in the latter case, to the extent that the Company is required by law to make payment subject to tax. If any tax or amounts in respect of tax must be deducted, or any other deductions must be made, from any amounts payable or paid by the Company, or paid or payable by the Delegate to any Secured Creditor, under this Assignment, the Company shall pay such additional amounts as may be necessary to ensure that the relevant Secured Creditor receives a net amount equal to the full amount which it would have received had payment not been made subject to tax.

 

15.2 Payments without Set-off

Any payment made by the Company under this Assignment shall be made free and clear of and without any deduction for or on account of any set-off or counterclaim.

 

15.3 Manner of Payment

Each payment made by the Company under this Assignment shall be paid in the manner in which payments are to be made by the Company under each Credit Agreement.

 

16. WAIVERS AND REMEDIES

No failure by the Delegate to exercise, nor any delay by the Delegate in exercising, any right or remedy under this Assignment shall operate as a waiver thereof nor shall any single or partial exercise of any such right or remedy prevent any further or other exercise thereof or the exercise of any other such right or remedy.

 

17. ADDITIONAL PROVISIONS

 

17.1 Partial Invalidity

If at any time any provision of this Assignment is or becomes illegal, invalid or unenforceable in any respect or any of the Security is or becomes ineffective in any respect under the law of any jurisdiction, such illegality, invalidity, unenforceability or ineffectiveness shall not affect:

 

  (a) the legality, validity or enforceability of the remaining provisions of this Assignment or the effectiveness in any other respect of the Security under such law; or

 

  (b) the legality, validity or enforceability of such provision or the effectiveness of the Security under the law of any other jurisdiction.

 

17.2 Potentially Avoided Payments

If the Delegate determines that an amount paid to a Secured Creditor under any Credit Document is being avoided or otherwise set aside on the liquidation or administration of the person by whom such amount was paid, then for the purposes of this Assignment, such amount shall be regarded as not having been paid.

 

15


17.3 Currency Conversion

If necessary to apply any sum held or received by the Delegate in or towards payment of the Secured Obligations, the Delegate may purchase an amount in another currency and the rate of exchange to be applied shall be that at which, at such time as it considers appropriate, the Delegate is able to effect such purchase.

 

17.4 Currency Indemnity

If for the purposes of obtaining judgment in any court it is necessary to convert a sum due from the Company hereunder in the currency expressed to be payable herein (the “specified currency”) into another currency, the parties hereto agree, to the fullest extent that they may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures the Delegate could purchase the specified currency with such other currency on the Business Day preceding that on which final judgment is given. The obligations of the Company in respect of any sum due to the Delegate hereunder shall, notwithstanding any judgment in a currency other than the specified currency, be discharged only to the extent that on the Business Day following receipt by the Delegate of any sum adjudged to be so due in such other currency the Delegate may in accordance with normal banking procedures purchase the specified currency with such other currency; if the amount of the specified currency so purchased is less than the sum originally due to the Delegate in the specified currency, the Company agrees, to the fullest extent that it may effectively do so, as a separate obligation and notwithstanding any such judgment, to indemnify the Delegate against such loss, and if the amount of the specified currency so purchased exceeds the sum originally due to the Delegate in the specified currency, the Delegate agrees to remit such excess to the Company.

 

17.5 Rights Cumulative

The rights and remedies provided by this Assignment are cumulative and not exclusive of any rights or remedies provided by law.

 

17.6 Delegate in Possession

The Delegate shall not by reason of its taking any action permitted by this Assignment or its taking possession of all or any of the Assigned Rights be liable to account as mortgagee in possession or, other than as expressly stated in each Security Trust Deed, be liable for any loss on realisation or for any default or omission for which a mortgagee in possession might be liable.

 

18. ASSIGNMENT

 

18.1 The Company’s Rights

The rights of the Company under this Assignment are not assignable or transferable and the Company agrees that it will not purport to assign all or any such rights except as provided under the Breakaway Two Credit Facility and the Credit Agreements.

 

16


18.2 The Delegate’s Rights

 

  (a) The rights of the Delegate under this Assignment are assignable in whole or in part without the consent of the Company except as provided under the Credit Agreements.

 

  (b) The Delegate may not resign except with the prior consent of the Collateral Agent and otherwise, in accordance with the terms of the Security Trust Deeds.

 

19. NOTICES

 

19.1 Communications in Writing

Each communication to be made under this Assignment shall be made in writing and, unless otherwise stated, may be made by fax, electronic mail or letter.

 

19.2 Contact Details

For the purposes of any notice, request, demand or any communication sent in accordance with Clause 19.1 (Communications in writing) the contact details of each of the parties are as follows:

 

  (a) to the Delegate:

Domstrasse 18

D - 20095 Hamburg

Germany

 

Attn.:    Marcus Weber / Anne Randewig
Telephone:    +49 40 3769 -9646 / -9647
Facsimile:    +49 40 3769 -9649
e-mail:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

 

  (b) to the Collateral Agent:

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

  (c) to the Company:

7665 Corporation Center Drive

Miami, Florida 33126

USA

 

17


Attention: Chief Financial Officer and General Counsel

Fax: +1 305-436-4117

E-mail: dfarkas@ncl.com

             hflanders@ncl.com

with copies to:

Apollo Management, L.P.

9 West 57th Street

New York, New York 10019

Attention: Steve Martinez

Fax: +1 212-515-3288

Email: martinez@apollolp.com

and

O’Melveny & Myers LLP

7 Times Square

New York, New York 10036

Attention: Brad J. Finkelstein

Fax: +1 212-326-2061

Email: bfinkelstein@omm.com

or to such other address and/or number as is notified in writing by a party to the other parties under this Assignment.

 

19.3 Delivery of Notices

All notices and other communications provided for hereunder shall be in writing (including telexed, telegraphic, telecopier or electronic (unless and until notified to the contrary) communication) and mailed, telexed, telecopied, delivered or electronic mailed at the address specified in Clause 19.2 (Contact Details); provided that, with respect to all notices and other communication made by electronic mail or other electronic means, the Collateral Agent, the Delegate and the Company agree that they (x) shall notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means and (y) shall notify each other of any change to their address or any other such information supplied by them. All such notices and communications shall, (i) when mailed, be effective three Business Days after being deposited in the mails, prepaid and properly addressed for delivery, (ii) when sent by overnight courier, be effective one Business Day after delivery to the overnight courier prepaid and properly addressed for delivery on such next Business Day, (iii) when sent by telex or telecopier, be effective when sent by telex or telecopier, except that notices and communications to the Collateral Agent and the Delegate shall not be effective until received by the Collateral Agent or the Delegate (as applicable), or (iv) when electronic mailed, be effective only when actually received in readable form and in the case of any electronic communication made by the Company to the Collateral Agent or the Delegate, only if it is addressed in such a manner as the Collateral Agent and/or the Delegate shall specify for this purpose.

 

18


20. GOVERNING LAW

 

  (a) This Assignment and any non-contractual obligations arising out of or in connection with it shall be governed by and construed in accordance with English law.

 

  (b) The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Assignment (including a dispute relating to the existence, validity or termination of this Assignment or any non-contractual obligation arising out of or in connection with this Assignment ) (a “Dispute”). The parties hereto agree that the courts of England are the most appropriate and convenient courts to settle disputes and accordingly no party hereto will argue to the contrary. This Clause 20 is for the benefit of the Collateral Agent on behalf of Secured Creditors and the Delegate on behalf of Secured Creditors. As a result, it shall not be prevented from taking proceedings relating to a dispute in any other courts with jurisdiction. To the extent allowed by law, the Collateral Agent and the Delegate may take concurrent proceedings in any number of jurisdictions.

 

  (c) Without prejudice to any other mode of service allowed under any relevant law, the Company: (i) irrevocably appoints EC3 Services Limited at 51 Eastcheap, London, England, EC3M 1JP as its agent for service of process in relation to any proceedings before the English courts in connection with any credit document and (ii) agrees that failure by an agent for service of process to notify the relevant credit party of the process will not invalidate the proceedings concerned. If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Company must immediately (and in any event within five days of such event taking place) appoint another agent on terms acceptable to the Collateral Agent and the Delegate. Failing this, the Collateral Agent and/or the Delegate may appoint another agent for this purpose.

 

  (d) Each party to this Assignment expressly agrees and consents to the provisions of this Clause 20.

 

21. COUNTERPARTS AND EFFECTIVENESS

 

21.1 Counterparts

This Assignment may be executed in counterparts and such counterparts taken together shall constitute one and the same instrument.

 

21.2 Effectiveness

This Assignment shall take effect and be delivered as a deed on the date on which it is stated to be made.

IN WITNESS WHEREOF this Assignment has been executed as a deed by the Company, the Collateral Agent and the Delegate.

 

19


SCHEDULE 1

FORM OF NOTICE OF ASSIGNMENT

 

To: KfW IPEX-Bank GmbH as Refund Guarantor

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: []

 

Cc: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

 

Cc: Deutsche Schiffsbank Aktiengesellschaft as Delegate

Domstrasse 18

D - 20095 Hamburg

Germany

 

Attn.:    Marcus Weber / Anne Randewig
Telephone:    +49 40 3769 -9646 / -9647
Facsimile:    +49 40 3769 -9649
e-mail:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

Date: []

Dear Sirs

We hereby give you notice that pursuant to an assignment agreement dated [] (the “Assignment”) and made between Breakaway Two, Ltd. (the “Company”), KfW IPEX-Bank GmbH as Collateral Agent and [] as delegate (the “Delegate”), the Company has assigned to the Delegate a second priority assignment of all of its rights, title, interests and benefits in, to or in respect of the refund guarantee dated [] and issued by you as refund guarantor in favour of the Company pursuant to which you guarantee certain refund obligations of Meyer Werft GmbH, as shipbuilder under the Construction Contract (as defined in the Assignment) (the “Refund Guarantee”), including all monies which may be payable under or in respect of the Refund Guarantee.

 

20


With effect from your receipt of this notice we hereby give you notice that:

 

(a) all payments to be made to the Company under or arising from the Refund Guarantee should be made to the Delegate or to its order as it may specify in writing from time to time;

 

(b) following an Event of Default (as defined in (i) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Pride of Hawaii, LLC, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent and (ii) the €126,075,000 delayed-draw term loan facility, dated [], among inter alia, Norwegian Jewel Limited, as borrower, NCL Corporation Ltd., the lenders from time to time party thereto, the Joint Lead Arrangers (as defined therein), KfW IPEX-Bank GmbH as facility agent and the Collateral Agent (together the “Credit Agreements”)), written notice of which Event of Default has been delivered to you by the Delegate, all remedies of the Company provided for in the Refund Guarantee or available at law or in equity shall be exercisable by the Delegate;

 

(c) following an Event of Default, all rights of the Company to compel performance of the Refund Guarantee shall be exercisable by the Delegate;

 

(d) all rights, title, interests and benefits whatsoever accruing to or for the benefit of the Company arising from the Refund Guarantee are assigned to the Delegate and are subject to the provisions of the Intercreditor Agreement (as defined in the Assignment referenced above);

 

(e) the Company has agreed not to agree to any waiver or amendment of or supplement to the terms of the Refund Guarantee other than where the prior written consent is given by the Joint Lead Arrangers (not to be unreasonably withheld) to such waiver, amendment or supplement;

 

(f) the Company has agreed not to terminate, or allow to be terminated, any Refund Guarantee other than where a replacement Refund Guarantee is issued to the Company which meets the Company’s requirements under the Construction Contract on or prior to such termination or where the prior written consent is given by each of the Facility Agents (as defined in each Credit Agreement) to such termination;

 

(g) the Delegate has agreed that the Company may exercise all of its rights and powers under and in respect of the Refund Guarantee except that to the extent that the Delegate notifies you in writing that an Event of Default (as referred to in the Assignment) has occurred. Upon giving such notice, the Delegate may exercise such rights and powers (to the exclusion of the Company) (including, without limitation, making a demand under the Refund Guarantee) to the extent stated in that notice and without you being under any duty to verify or make any enquiry as to whether such (or any) Event of Default has occurred;

 

(h)

the Company has irrevocably appointed the Delegate to be its attorney, upon the occurrence of and during the continuance of an Event of Default, to do (amongst other

 

21


 

things) things which the Company could do in relation to the Refund Guarantee. Accordingly, the Company authorises and instructs you to comply with the terms of any written notice or instructions which you may receive from the Delegate from time to time in connection with the Refund Guarantee without further authority or enquiry by you from the Company; and

 

(i) the Company remains liable to perform all its duties and obligations under the Refund Guarantee and the Delegate is under no obligation of any kind under the Refund Guarantee nor under any liability whatsoever in the event of any failure by the Company to perform its obligations.

You are hereby authorised and instructed, without requiring further approval from the Company, to provide the Delegate with such information relating to the Refund Guarantee as it may from time to time reasonably request and to send copies of all notices issued by you under the Refund Guarantee which have had or would reasonably be expected to have a material adverse effect on the value of the Refund Guarantee, to the Delegate as well as to the Company.

This notice of assignment shall terminate, and be of no further force and effect, upon termination of the Assignment (as notified to you by the Delegate).

Please acknowledge receipt of this notice by signing and dating the acknowledgment set out on the enclosed copy and returning it to the Delegate.

 

Yours faithfully

 

For and on behalf of
BREAKAWAY TWO, LTD.

 

22


SCHEDULE 2

FORM OF ACKNOWLEDGMENT OF ASSIGNMENT

[To be printed only on copy of the Notice of Assignment given]

 

To: Deutsche Schiffsbank Aktiengesellschaft as Delegate

Domstrasse 18

D - 20095 Hamburg

Germany

 

Attn.:    Marcus Weber / Anne Randewig
Telephone:    +49 40 3769 -9646 / -9647
Facsimile:    +49 40 3769 -9649
e-mail:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

 

Cc: KfW IPEX-Bank GmbH as Collateral Agent

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

Attention: Ship Finance, X2a4, Claudia Wenzel

Fax: +49 69 7431 2944

E-mail: claudia.wenzel@kfw.de

Date: []

Dear Sirs

We acknowledge receipt of a notice in the terms set out above (the “Notice”). We accept the instructions and authorisations contained in the Notice, we undertake to act in accordance with and comply with the terms of the Notice and we confirm that (other than in respect of senior liens held by the Delegate as security trustee on behalf of certain “ECF creditors” in respect of the Refund Guarantee) we have not received notice of any other assignments or charges of or over any of the rights, title, interests and benefits in, to or in respect of the Refund Guarantee and that we will comply with the terms of the Notice.

We further agree and confirm that we acknowledge that we shall not challenge the effectiveness of the Assignment (as defined in the Notice; capitalized terms used herein have the meanings ascribed thereto in the Notice or the Assignment, as applicable).

 

23


Yours faithfully

For and on behalf of

KfW IPEX-Bank GmbH

as Refund Guarantor

By:

Date:

 

24


SCHEDULE 3

DETAILS OF REFUND GUARANTEES

 

[Name of Issuer]    [Date of Refund Guarantee]

 

25


SIGNATORIES

 

Signed as a deed on behalf of BREAKAWAY TWO, LTD, a company incorporated in Bermuda, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]
Signed as a deed on behalf of DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]
Signed as a deed on behalf of KFW IPEX-BANK GMBH, a company incorporated in Germany, by [full name(s) of person(s) signing], being [a] person[s] who, in accordance with the laws of that territory, [is][are] acting under the authority of the company     
    

 

     Authorised [signatory] [signatories]

 

26


EXHIBIT P

DATED              2010

PRIDE OF HAWAII, LLC

(as owner)

and

NCL (BAHAMAS) LTD.

(as bareboat charterer)

to

KFW IPEX-BANK GMBH

(as assignee)

 

 

FORM OF FOURTH DEED OF ASSIGNMENT

AND SUBORDINATION

m.v. “NORWEGIAN JADE”

 

 


EXHIBIT P

TABLE OF CONTENTS

 

     Page  

1       Definitions and Interpretation

     2   

2       Assignment and Negative Pledge

     4   

3       Notices of Assignment of Assigned Property and Further Assignments

     4   

4       Subordination

     5   

5       Ancillary Provisions

     6   

6       Notice of Assignment under Owner’s Charter and Earnings Assignment and this Deed and Notice of Mortgage

     7   

7       Application of Moneys

     7   

8       Power of Attorney

     8   

9       Partial Invalidity

     8   

10     Further Assurance

     8   

11     Waiver of Rights as Surety

     8   

12     Enforcement Expenses

     9   

13     Waiver, Remedies Cumulative

     9   

14     Assignment

     10   

15     Re-Assignment

     10   

16     Notices

     10   

17     Counterparts

     10   

18     Governing Law and Jurisdiction

     10   

Schedule 1

     13   

Schedule 2

     17   

Schedule 3

     25   

Schedule 4

     1   

Schedule 5

     3   

Schedule 6

     4   

Schedule 7

     9   

Schedule 8

     11   

 

(i)


DEED OF ASSIGNMENT AND SUBORDINATION

Dated:                      2010

BETWEEN:

 

(1) PRIDE OF HAWAII, LLC, a Delaware corporation and having its registered office at Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Owner”); and

 

(2) NCL (BAHAMAS) LTD., a company incorporated in and existing under the laws of Bermuda and having its registered office at Milner House, 18 Parliament Street, Hamilton HM 12, Bermuda (the “Bareboat Charterer”);

IN FAVOUR OF:

 

(3) KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany, acting not in its own individual capacity but solely as trustee and collateral agent for the Beneficiaries (as defined below) pursuant to the Security Trust Deed (the “Assignee”).

WHEREAS:

 

(A) The Owner is the legal and beneficial owner of the whole of the motor vessel “NORWEGIAN JADE” (the “Vessel”) registered in the name of the Owner under the laws and flag of the Bahamas. The Bareboat Charterer is the bareboat charterer of the Vessel pursuant to a bareboat charterparty dated 10 February 2008 (the “Bareboat Charter”).

 

(B) Pursuant to first assignment and subordination deeds dated 10 February 2008 and 16 June 2008 (the “First Assignment”) the Bareboat Charterer assigned its rights, title to and interest in the Insurances and Earnings as collateral to a first priority mortgage dated 10 February 2008 over the Vessel upon the terms and conditions contained therein to HSBC Bank Plc of 8 Canada Square, London, E14 5HQ as trustee for the parties set out in Schedule 1 (the “First Assignee”).

 

(C) Pursuant to a second assignment and subordination deed dated 2 April 2009 (the “Second Assignment”) the Bareboat Charterer assigned its rights, title to and interest in the Insurances and Earnings as collateral to a second priority mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway, as trustee for itself and the parties set out in Schedule 2 (the “Second Assignee”).

 

(D) Pursuant to a third assignment and subordination deed dated 2 April 2009 (the “Third Assignment”) the Bareboat Charterer assigned its rights, title to and interest in the Insurances and Earnings as collateral to a third priority mortgage over the Vessel upon the terms and conditions contained therein to DnB NOR Bank ASA acting through its office at Stranden 21, NO-0021 Oslo, Norway, as trustee for itself and the parties set out in Schedule 3 (the “Third Assignee”).

 

(E) Pursuant to the Credit Agreement, and in consideration of the obligations of the Beneficiaries under or pursuant to the Junior Finance Documents, the Owner has executed and delivered in favour of the Assignee a fourth priority Bahamian statutory mortgage and has agreed to enter into, and to cause the Bareboat Charterer to enter into, this Deed to assign the benefit of the Insurances and Earnings to the Assignee on trust for itself and the Beneficiaries as security for the repayment of the Secured Obligations.


(F) By a deed of co-ordination dated as of the date hereof (the “Fourth Priority Security Co-ordination Deed”) made between (among others) (1) the First Assignee (2) the Second Assignee (3) the Third Assignee and (4) the Assignee, the parties have agreed (among other things) as to how the provisions of Clause 7 shall operate. Further by the Fourth Priority Security Co-ordination Deed it has been agreed that the benefit of this Deed shall be held by the Assignee on trust for itself and the Secured Creditors, including the Secured Creditors set out in Schedule 4 and its and their respective successors, assignees and transferees (together the “Beneficiaries”).

THIS DEED WITNESSES as follows:

 

1 Definitions and Interpretation

The headings used in this Deed are for reference only, and have no legal or other significance, and shall be ignored in the interpretation of this Deed. In this Deed the following terms shall have the meanings set out below; in addition, defined terms and expressions used but not defined herein and whose meanings are defined in the Credit Agreement shall have the same meanings when used in this Deed.

“Assigned Property” means the Insurances, the Earnings and the Bareboat Charter;

“Charter Period” means that part of the Security Period during which the Vessel is in the service of the Bareboat Charterer pursuant to the Bareboat Charter (whether or not off hire);

“Compulsory Acquisition” means requisition for title or other compulsory acquisition of the Vessel including its capture, seizure, detention or confiscation or expropriation but excluding any requisition for hire by or on behalf of any government or governmental authority or agency or by any persons acting or purporting to act on behalf of any such government or governmental authority or agency;

“Credit Agreement” means that certain €126,075,000 credit agreement, dated November [], 2010 among NCL Corporation Ltd., as parent, (the “Parent”), the Owner, as borrower, the lenders from time to time party thereto (the “Lenders”), the Assignee, as facility agent and as collateral agent under the Security Documents, Nordea Bank Norge ASA, as documentation agent, Commerzbank AG, as Hermes agent, and the other parties thereto, as amended, novated, and/or restated or otherwise modified from time to time;

“Default Rate” means interest at the rate calculated in accordance with section 2.06(b) of the Credit Agreement;

“Earnings” means, in respect of the Vessel, (whether earned or to be earned) any and all freights, hire and passage monies, proceeds of requisition (other than proceeds of Compulsory Acquisition), rebates and commissions to or for the account of the Owner and/or the Bareboat Charterer, all earnings deriving from the Bareboat Charter, time charters, contracts of affreightment, pooling agreements and joint ventures, compensation, remuneration for salvage and towage services, damages howsoever arising and detention monies, damages for breach of any charterparty or other contract for the employment of the Vessel including but without limitation the Bareboat Charter, any amounts payable in consideration of the termination or variation of any charterparty or other such contract including but without limitation the Bareboat Charter, any sums payable or repayable by the

 

2


Builder under the Building Contract, any reduction in the Hermes Premium repaid by Hermes to the Owner and any other earnings whatsoever due or to become due to the Owner and/or the Bareboat Charterer;

“Insurances” means all policies and contracts of insurance and entries of the Vessel in a protection and indemnity or war risks association which are effected in respect of the Vessel, its freights, disbursements, profits or otherwise and all benefits, including all claims and returns of premiums thereunder and shall also include all compensation payable by virtue of Compulsory Acquisition;

Junior Finance Documents” means the Credit Documents as such term is defined in the Credit Agreement;

Lender Creditors” means the Lenders, the Assignee and each other Agent under the Credit Agreement;

Mortgage” means that certain fourth priority statutory mortgage with respect to the Vessel together with that certain fourth priority deed of covenants dated the date hereof and made by the Owner in favour of the Assignee.

Obligors” means the Credit Parties, as such term is defined in the Credit Agreement;

Other Creditors” means any Lender or any affiliate thereof and their successors, transferees and assigns if any (even if such Lender subsequently ceases to be a Lender under the Credit Agreement for any reason), together with such Lender’s or affiliate’s successors, transferees and assigns, with which the Parent and/or the Owner enters into any Interest Rate Protection Agreements or Other Hedging Agreements from time to time;

Owner’s Charter and Earnings Assignment” means that certain fourth charter and earnings assignment dated the date hereof and made by the Owner in favour of the Assignee;

Owner’s Insurance Assignment” means that certain fourth insurance assignment dated the date hereof and made by the Owner in favour of the Assignee;

Process Agent” means EC3 Services Limited with its registered office at 51 Eastcheap, London, EC3M 1JP or any other process agent reasonably acceptable to the Owner, the Bareboat Charterer and the Assignee.

Secured Creditors” means collectively (i) the Lender Creditors and (ii) the Other Creditors;

Secured Obligations” has the meaning ascribed to it in the Credit Agreement;

Security Documents” has the meaning ascribed to it in the Credit Agreement;

Security Period” means the period beginning on the date of this Deed and ending on the date when the whole of the Secured Obligations have been repaid in full and the Assignor has ceased to be under any further actual or contingent liability (other than (i) contingent liabilities for which no claim has been made and (ii) indemnities, expense reimbursements or any other contingent liabilities that expressly survive the termination of the Credit Agreement) under or in connection with any of the Junior Finance Documents; and

 

3


Security Trust Deed” means the Security Trust Deed executed on or about the date hereof by, inter alia, the Assignor, the Guarantor, the Assignee, the Original Secured Creditors (as defined therein) and the Original Term Hedging Creditors (as defined therein).

 

2 Assignment and Negative Pledge

 

  2.1 Assignment

In consideration of:

 

  2.1.1 the Assignee consenting to the continued chartering of the Vessel to the Bareboat Charterer pursuant to the Bareboat Charter;

 

  2.1.2 the Beneficiaries making certain facilities available to the Owner pursuant to the Credit Agreement, any Interest Rate Protection Agreements and/or any Other Hedging Agreements;

 

  2.1.3 payment by the Assignee to the Bareboat Charterer of ten Dollars (USD10); and

 

  2.1.4 other good and valuable consideration from the Assignee to the Bareboat Charterer

(the adequacy and receipt whereof is hereby acknowledged by the Bareboat Charterer) and as security for payment of the Secured Obligations, the Bareboat Charterer with full title guarantee hereby assigns to, and agrees to assign to, the Assignee absolutely all its right and title to and interest in the Assigned Property to hold the same absolutely unto the Assignee subject to the First Assignment, the Second Assignment, and the Third Assignment.

 

  2.2 Negative pledge

The Bareboat Charterer undertakes that, except with the prior written consent of the Assignee, it will not at any time during the Security Period create or permit to subsist any Liens save for the First Assignment, the Second Assignment and the Third Assignment (and except for Permitted Liens) on all or any part of the Bareboat Charterer’s right and title to and interest in the Assigned Property.

 

3 Notices of Assignment of Assigned Property and Further Assignments

 

  3.1 The Bareboat Charterer undertakes:

 

  3.1.1 immediately to give notice of the assignment of the Insurances contained in this Deed to all brokers, insurance companies, underwriters, protection and indemnity and/or war risk associations through whom any of the policies or entries relating to the Insurances are effected in the form of Schedule 5 and to obtain from such brokers, insurance companies or underwriters a letter of undertaking in the form of Schedule 6 or in such other form as the Assignee may require and from such protection and indemnity or war risk associations in the form of Schedule 7 or in such other form as the Assignee may agree;

 

  3.1.2

at all times during the Charter Period to procure that, in lieu of the loss payable clause referred to in the Owner’s Insurance Assignment, a loss

 

4


 

payable clause materially in the form set out in Appendix B to Schedule 6 (or in such other form as the Assignee may approve) or, in the case of entries in a protection and indemnity association, a note of the Assignee’s interest in such form as the Assignee may approve, shall be endorsed on or attached to the policies, cover notes or certificates of entry relating to the Insurances and that letters of undertaking in such form as the Assignee may approve shall be issued to the Assignee by the brokers through whom the Insurances are placed (or, in the case of entries in protection and indemnity or war risks associations, by their managers);

 

  3.1.3 immediately to give notice of the assignment of the Bareboat Charter substantially in the form of Schedule 7 to the Owner and to procure that the Owner acknowledges and consents to such assignment by signing an endorsement of the notice in the form set out in Schedule 7;

 

  3.1.4 from time to time immediately on the written request of the Assignee (and provided, in the case of the Earnings, that an Event of Default shall have occurred and be continuing or the charter or contract of affreightment for the Vessel exceeds or is capable of exceeding six (6) months’ duration) to give such further written notice in such form as the Assignee shall require of the assignment of the Earnings and/or the proceeds of Compulsory Acquisition contained in this Deed. In the case of the Earnings, the Owner undertakes to procure that the person on whom the notice is served acknowledges and consents to such assignment if the said person is part of the NCLC Group, and otherwise to use its best endeavours to procure that such person acknowledges and consents to such assignment, by signing an endorsement of the notice in the substantially form set out in Schedule 7; and

 

  3.1.5 immediately following the execution of any charter of the Vessel or contract of affreightment which, with the exercise of options for extension, could be for a period longer than thirteen (13) months, on the request of the Assignee, to execute and deliver to the Assignee a first priority assignment of that charter or contract of affreightment in such form as the Assignee shall require but substantially in the form of this Deed.

 

4 Subordination

 

  4.1 The Bareboat Charterer acknowledges that it is aware that the Vessel is mortgaged to the Assignee pursuant to the Mortgage and that it is aware of the terms of the Mortgage.

 

  4.2 The Bareboat Charterer acknowledges that the Assignee’s rights and powers arising out of or pursuant to the Mortgage shall in all respects and at all times have precedence and priority over the rights and powers of the Bareboat Charterer arising out of or pursuant to the Bareboat Charter.

 

  4.3 The Bareboat Charterer undertakes for the duration of the Charter Period to perform all of the Owner’s obligations contained in clause 4 and clause 5 of the deed of covenants forming part of the Mortgage jointly and severally with the Owner and for this purpose the Bareboat Charterer agrees that references in those clauses to “Earnings” and “Insurances” by cross reference to the Junior Loan Agreements or otherwise shall be deemed to include the Earnings and the Insurances respectively.

 

5


  4.4 The Bareboat Charterer agrees that, for the duration of the Charter Period, the rights and powers of the Assignee in relation to the Insurances and the Earnings shall (mutatis mutandis) be the same as the rights and powers of the Assignee under or pursuant to the Mortgage in relation to the Insurances and the Earnings as respectively defined in the deed of covenants forming part of the Mortgage by cross reference to the Junior Finance Documents or otherwise.

 

  4.5 The Bareboat Charterer agrees that, should an Event of Default occur and the Assignee wishes to take and enter into possession of the Vessel pursuant to their rights under the Mortgage, the Bareboat Charterer will immediately on the demand of the Assignee surrender possession of the Vessel to or to the order of the Assignee free of the Bareboat Charter.

 

  4.6 The Bareboat Charterer agrees that, should an Event of Default occur and the Assignee wishes to sell the Vessel pursuant to their rights under the Mortgage, such sale may be made free of the Bareboat Charter and any claim for loss of the same shall be made against the Owner or the balance (if any) of the proceeds of sale in the hands of the Assignee after payment of the Secured Obgligations unless the Assignee is obliged by law to apply such balance in favour of parties other than the Bareboat Charterer.

 

5 Ancillary Provisions

 

  5.1 The Bareboat Charterer undertakes to reimburse the Assignee on demand for all sums which the Assignee may from time to time pay or become liable for in or about the protection, maintenance or enforcement of the rights created in favour of the Assignee by this Deed or in or about the exercise by the Assignee of any of the powers vested in it under or pursuant to this Deed, together in each case with interest at the Default Rate from the date when those sums were paid by the Assignee until the date of actual receipt, before or after any relevant judgment, and to keep the Assignee fully and effectually indemnified from and against all actions, losses, claims, proceedings, costs, demands and liabilities which the Assignee may suffer or incur under or in connection with the Assigned Property.

 

  5.2 Notwithstanding the assignments contained in this Deed, the Assignee shall not be obliged to make any enquiry as to the nature or sufficiency of any payment received by it under or in connection with this Deed nor to make any claim or take any other action to collect any money or to enforce any rights or benefits assigned to the Assignee by this Deed or to which the Assignee may at any time be entitled under or pursuant to this Deed.

 

  5.3 The Bareboat Charterer shall remain liable to perform all the obligations assumed by it in relation to the Assigned Property and the Assignee shall be under no obligation of any kind in respect of the Assigned Property nor under any liability in the event of any failure by the Bareboat Charterer to perform, or breach by the Bareboat Charterer of, any of those obligations.

 

  5.4 The Bareboat Charterer undertakes to hold the original copies of any and all documents in connection with any of the Assigned Property to the order of the Assignee.

 

  5.5

The Bareboat Charterer undertakes to perform the Bareboat Charter in accordance with its terms, and not without the prior written consent of the Assignee, to terminate

 

6


 

or purport to terminate the Bareboat Charter (irrespective of the terms of the Bareboat Charter), the Owner and the Bareboat Charterer acknowledging by their execution of this Deed that, if any such consent is given by the Assignee on their behalves, the Assignee shall be under no liability in the event that any termination of the Bareboat Charter is subsequently adjudged to constitute a repudiation of the Bareboat Charter.

 

  5.6 The Bareboat Charterer undertakes not without the prior written consent of the Assignee to agree to any amendment to or variation of the Bareboat Charter unless this is permitted under the Junior Finance Documents, nor to excuse the Owner from performance of any of its obligations pursuant to the Bareboat Charter.

 

6 Notice of Assignment under Owner’s Charter and Earnings Assignment and this Deed and Notice of Mortgage

 

  6.1 The Owner has agreed to send notice of the Owner’s Charter and Earnings Assignment to the Bareboat Charterer and to procure that the Bareboat Charterer acknowledges the same (in the form of schedule 1 to the Owner’s Charter and Earnings Assignment).

 

  6.2 The Bareboat Charterer has agreed to send notice of the assignment of the Bareboat Charter to the Owner and to procure that the Owner acknowledges the same (in the form of Schedule 8).

 

  6.3 For the purposes of Clause 6.1 and Clause 6.2, execution of this Deed by the Owner and the Bareboat Charterer shall constitute notice by:

 

  6.3.1 the Owner to the Bareboat Charterer of the Owner’s Charter and Earnings Assignment and shall also constitute acknowledgement of that notice by the Bareboat Charterer; and

 

  6.3.2 the Bareboat Charterer to the Owner of the assignment of the Bareboat Charter and shall also constitute acknowledgement of that notice by the Owner.

 

  6.4 For the purposes of the Bareboat Charter, the execution of this Deed by the Owner and the Bareboat Charterer shall constitute notice by the Owner to the Bareboat Charterer of the name and details of the mortgagees and shall also constitute acknowledgement of that notice by the Bareboat Charterer.

 

7 Application of Moneys

 

  7.1 The benefits and proceeds of any of the Insurances shall be distributed in accordance with the terms of any relevant loss payable clause endorsed on the Insurances, clause 8 of the Fourth Priority Security Co-Ordination Deed and section 4.05 of the Credit Agreement.

 

  7.2 Subject to Clause 7.1, the benefits and proceeds of any of the Assigned Property shall, unless otherwise agreed by the Assignee or otherwise expressly provided in the Junior Loan Agreements, be applied by the Assignee in or towards satisfaction, or by way of retention on account, of the Secured Obligations, in such manner as the Assignee may in its discretion determine.

 

7


8 Power of Attorney

So far as may be necessary to give effect to this Deed the Bareboat Charterer hereby irrevocably appoints the Assignee as its attorney (with unlimited power of substitution and delegation) for the purpose of doing in the name of the Bareboat Charterer all acts which the Bareboat Charterer could do in relation to the Assigned Property.

 

9 Partial Invalidity

If, at any time, any provision of this Deed is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions nor the legality, validity or enforceability of such provision under the law of any other jurisdiction will in any way be affected or impaired.

 

10 Further Assurance

The Bareboat Charterer agrees that from time to time on the written request of the Assignee it will immediately execute and deliver to the Assignee all further documents which the Assignee may require for the purpose of obtaining the full benefits of this Deed.

 

11 Waiver of Rights as Surety

 

  11.1 The rights of the Assignee under this Deed, the security constituted by this Deed and the warranties, covenants and obligations of the Bareboat Charterer contained in this Deed shall not in any way be discharged, impaired or otherwise affected by:

 

  11.1.1 any forbearance (whether as to payment or otherwise) or any time or other indulgence granted to any of the other Obligors under or in connection with any of the Security Documents;

 

  11.1.2 any amendment, variation, novation or replacement of any of the other Security Documents;

 

  11.1.3 any failure of any of the Security Documents to be legal, valid, binding and enforceable in relation to any of the other Obligors for any reason;

 

  11.1.4 the winding-up or dissolution of any of the other Obligors;

 

  11.1.5 the release (whether in whole or in part) of, or the entering into of any compromise or composition with, any of the other Obligors; or

 

  11.1.6 any other act, omission, thing or circumstance which would or might, but for this provision, operate to discharge, impair or otherwise affect the same.

 

  11.2 Until the Secured Obligations have been unconditionally and irrevocably paid and discharged in full, the Bareboat Charterer shall not by virtue of any payment made under this Deed on account of the Secured Obligations or by virtue of any enforcement by the Assignee of its rights under, or the security constituted by, this Deed or by virtue of any relationship between or transaction involving, the Bareboat Charterer and any of the other Obligors:

 

  11.2.1 exercise any rights of subrogation in relation to any rights, security or moneys held or received or receivable by the Assignee or any other person; or

 

8


  11.2.2 exercise any right of contribution from any of the other Obligors under any of the Security Documents; or

 

  11.2.3 exercise any right of set-off or counterclaim against any of the other Obligors; or

 

  11.2.4 receive, claim or have the benefit of any payment, distribution, security or indemnity from any of the other Obligors; or

 

  11.2.5 unless so directed by the Assignee (when the Bareboat Charterer will prove in accordance with such directions), claim as a creditor of any of the other Obligors in competition with the Assignee

and the Bareboat Charterer shall hold in trust for the Assignee and forthwith pay or transfer (as appropriate) to the Assignee any such payment (including an amount equal to any such set-off), distribution or benefit of such security, indemnity or claim in fact received by it.

 

12 Enforcement Expenses

The Bareboat Charterer shall reimburse the Assignee on demand for the charges and expenses (including the fees and expenses of legal advisors and value added tax or any similar tax thereon) incurred by it and/or the Assignee in connection with the enforcement of, or the preservation of, any rights under this Deed.

 

13 Waiver, Remedies Cumulative

 

  13.1 No waiver

No failure to exercise and no delay in exercising on the part of the Assignee any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any right or remedy preclude any other or further exercise thereof, or the exercise of any other right or remedy. No waiver by the Assignee shall be effective unless it is in writing.

 

  13.2 Remedies cumulative

The rights and remedies of the Assignee provided herein are cumulative and not exclusive of any rights or remedies provided by law.

 

  13.3 Severability

If any provision of this Deed or any of the other Security Documents is prohibited or unenforceable in any jurisdiction, such prohibition or unenforceability shall not invalidate the remaining provisions hereof or affect the validity or enforceability of such provision in any other jurisdiction.

 

  13.4 Time of essence

Time is of the essence in respect of all of the obligations of the Bareboat Charterer under this Deed provided however that the Assignee shall not be entitled to enforce its rights under the assignment contained in this Deed otherwise than in circumstances which constitute an Event of Default.

 

9


14 Assignment

 

  14.1 Benefit of Deed

This Deed shall be binding upon the Bareboat Charterer and its successors and shall inure to the benefit of the Assignee and its successors, transferees and assigns.

 

  14.2 Disclosure of information

The Assignee may disclose to a potential transferee or assignee or to any other person who may otherwise propose to enter into contractual relations with any of them in relation to this Deed such information about the Bareboat Charterer as such Assignee shall consider appropriate subject always to the provisions of section 14.14 of the Credit Agreement where, for the purpose of this Deed, references to “Lender” shall be read and construed as “Beneficiary”.

 

  14.3 Contracts (Rights of Third Parties) Act 1999 (the “Act”)

A person who is not a party to this Deed has no right under the Act to enforce any term of this Deed but this does not affect any right or remedy of a third party which exists or is available apart from the Act.

 

15 Re-Assignment

Following the expiry of the Charter Period and the satisfaction of all the Bareboat Charterer’s obligations under the Bareboat Charter and this Deed, the Assignee will, at the cost of and on the request of the Bareboat Charterer and so long as no Event of Default shall then have occurred and be continuing, execute and deliver a re-assignment to the Bareboat Charterer of the Assigned Property, to the extent then still subsisting and capable of re-assignment.

 

16 Notices

All demands and notices made or given hereunder shall be made or given in accordance with section 14.03 of the Credit Agreement (it being understood that for the purpose hereof, references to “any Credit Party” in such section 14.03 shall also apply to the Bareboat Charterer).

 

17 Counterparts

This Deed may be executed in any number of counterparts, and this has the same effect as if the signatures on the counterparts were on a single copy of this Deed.

 

18 Governing Law and Jurisdiction

 

  18.1 This Deed and any non-contractual obligations arising from or in connection with it shall be governed by English law.

 

  18.2 The courts of England have exclusive jurisdiction to settle any dispute:

 

  18.2.1 arising out of or in connection with this Deed (including a dispute regarding the existence, validity or termination of this Deed); or

 

10


  18.2.2 relating to any non-contractual obligations arising from or in connection with this Deed,

(a “Dispute”). Each party to this Deed agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no party will argue to the contrary.

This Clause 18.2 is for the benefit of the Assignee only. As a result, such party shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, such party may take concurrent proceedings in any number of jurisdictions.

 

  18.2.3 Neither the Owner nor the Bareboat Charterer may, without the Assignee’s prior written consent, terminate the appointment of the Process Agent; if the Process Agent resigns or its appointment ceases to be effective, the Owner and/or the Bareboat Charterer shall within fourteen (14) days appoint a company which has premises in London and has been approved by the Assignee to act as the Owner’s and/or the Bareboat Charterer’s process agent with unconditional authority to receive and acknowledge service on behalf of the Owner and/or the Bareboat Charterer of all process or other documents connected with proceedings in the English courts which relate to this Deed.

 

  18.2.4 For the purpose of securing their obligations under Clause 18.2, each of the Owner and the Bareboat Charterer irrevocably agrees that, if it for any reason fails to appoint a process agent within the period specified in Clause 18.2, the Assignee may appoint any person (including a company controlled by or associated with any of the Beneficiaries) to act as the Owner’s and/or the Bareboat Charterer’s process agent in England with the unconditional authority described in Clause 18.2.

 

  18.2.5 No neglect or default by a process agent appointed or designated under this Clause (including a failure by it to notify the Owner or the Bareboat Charterer (as the case may be) of the service of any process or to forward any process to the Owner and/or the Bareboat Charterer) shall invalidate any proceedings or judgment.

 

  18.2.6 Each of the Owner and the Bareboat Charterer appoints in the case of the courts of England the Process Agent to receive, for and on its behalf service of process in England of any legal proceedings with respect to this Deed.

 

  18.2.7 A judgment relating to this Deed which is given or would be enforced by an English court shall be conclusive and binding on the Owner and/or the Bareboat Charterer (as the case may be) and may be enforced without review in any other jurisdiction.

 

  18.2.8 Nothing in this Clause shall exclude or limit any right which the Assignee may have (whether under the laws of any country, an international convention or otherwise) with regard to the bringing of proceedings, the service of process, the recognition or enforcement of a judgment or any similar or related matter in any jurisdiction.

 

  18.2.9 In this Clause “judgment” includes order, injunction, declaration and any other decision or relief made or granted by a court.

 

11


IN WITNESS whereof this Deed has been executed by the parties hereto on the day first written above.

 

SIGNED SEALED and DELIVERED as a DEED    )   
for and on behalf of    )   
PRIDE OF HAWAII, LLC    )   
by    )   
its duly appointed attorney-in-fact    )   
in the presence of:    )   
SIGNED SEALED and DELIVERED as a DEED    )   
for and on behalf of    )   
NCL (BAHAMAS) LTD.    )   
by    )   
its duly appointed attorney-in-fact    )   
in the presence of:    )   
SIGNED SEALED and DELIVERED as a DEED    )   
for and on behalf of    )   
KFW IPEX-BANK GMBH    )   
by    )   
its duly appointed attorney-in-fact    )   
in the presence of:    )   

 

12


Schedule 1

EUR308,130,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)

 

13


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

 

14


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax:    +49 511 361 4785
Attn:    Mr Torsten Reinecke
Email:    shipping@nordlb.de

CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 74221 197
Attn:    Mr Stephan Bachmann
Email:    stephan.bachmann@ca-cib.com

 

15


with a copy to:

 

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:    +852 2868 1448
Attn:    Mr Terence Yuen/Ms Iris Lai
Email:    terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

16


Schedule 2

Part I

EUR258,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)

 

17


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

 

18


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

Part II

EUR40,000,000 Secured Loan Agreement dated 4 April 2003 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)

 

19


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

20


DVB BANK SE

Parklaan 2

3016 BB Rotterdam

The Netherlands

 

Fax:    +5999 4652366
Attn:    LAM/Eric Maduro
Email:    lam.curacao@dvbbank.com/james.neira@dvbbank.com

Part III

USD334,050,000 Secured Loan Agreement dated 20 April 2004 as amended and/or restated

from time to time

Trustee

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

As trustee for:

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com
(as trustee and agent)

 

21


COMMERZBANK

AKTIENGESELLSCHAFT

Corporate Banking

Structured Export and Trade Finance

Kaiserplatz

60261 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 1362 3742
Attn:    Mr Klaus-Dieter Schmedding
Email:    exportfinance@commerzbank.com
(as Hermes agent)

and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Federal Republic of Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

HSBC BANK PLC

Project and Export Finance

8 Canada Square

London E14 5HQ

 

Fax:    +44 (0)20 7992 4428
Attn:    Mr Alan Marshall
Email:    alan.p.marshall@hsbcib.com

 

22


KFW

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

OVERSEA-CHINESE BANKING

CORPORATION LIMITED

Singapore Branch

65 Chulia Street #10-00

Singapore 049513

 

Fax:    +65 6536 6449/6532 5347
Attn:    Ms Lee King Lan/Ms Elaine Lam
Email:    LeeKingLan@ocbc.com/LamSYElaine@ocbc.com

NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Federal Republic of Germany

 

Fax:    +49 511 361 4785
Attn:    Mr Torsten Reinecke
Email:    shipping@nordlb.de

 

23


CREDIT AGRICOLE CORPORATE AND INVESTMENT BANK

Taunusanlage 14

60325 Frankfurt am Main

Federal Republic of Germany

 

Fax:    +49 69 74221 197
Attn:    Mr Stephan Bachmann
Email:    stephan.bachmann@ca-cib.com

with a copy to:

 

CREDIT AGRICOLE ASIA SHIPFINANCE LIMITED
Fax:    +852 2868 1448
Attn:    Mr Terence Yuen/Ms Iris Lai
Email:    terence.yuen@ca-cib.com/iris.lai@ca-cib.com

 

24


Schedule 3

EUR624,000,000 Secured Loan Agreement dated 7 October 2005 as amended

and/or restated from time to time

Non-Guaranteed Trustee

DNB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482894
Attn:    Mrs Solveig Nuland Knoff
Email:    solveig.knoff@dnbnor.no

As trustee for:

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482894
Attn:    Mrs Solveig Nuland Knoff
Email:    solveig.knoff@dnbnor.no
(as security agent and agent)

 

25


and the following as lenders:

COMMERZBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 18

20095 Hamburg

Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Stefan Kuch/Mr Marcus Weber/
   Mrs Anne Randewig
Email:    shipfinance@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482020
Attn:    Mrs Amra Koluder/Mrs Ursula Mack Tonjum
Email:    amra.koluder@dnbnor.no/ursula.mack.tonjum@dnbnor.no

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax:    +49 69 7431 3768/2944
Attn:    Mr Josef Schmid/Ms Claudia Wenzel
Email:    josef.schmid@kfw.de/claudia.wenzel@kfw.de

 

26


NORDDEUTSCHE LANDESBANK GIROZENTRALE

Friedrichswall 10

30159 Hannover

Germany

 

Fax:    +49 511 361 4785
Attn:    Mr Torsten Reinecke
Email:    shipping@nordlb.de

NORDEA BANK NORGE ASA

Middelthuns gate 17

Oslo

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax:    +47 22 484278
Attn:    Mr Arne Berglund
Email:    arne.berglund@nordea.com

BANK OF SCOTLAND PLC

Marine Finance

Second Floor

New Uberior House

11 Earl Grey Street

Edinburgh EH3 9BN

Scotland

 

Fax:    +44 131 659 1194
Attn:    Douglas Newton/Russell Parker
Email:    douglas_newton@bankofscotland.co.uk

 

27


UNICREDIT BANK AG

(formerly known as Bayerische Hypo- und

Vereinsbank AG)

Alter Wall 22

20457 Hamburg

Germany

 

Fax:    +49 40 3692 3696/+49 89 378 334 2832
Attn:    Mr Peter-Alexander Wunner/
   Mr Michael McCarthy
Email:    peter-alexander.wunner@unicreditgroup.de/
   michael.mccarthy@unicreditgroup.de

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Bremen and Hamburg

Domshof 17

28195 Bremen

Germany

 

Fax:    +49 421 3609 329
Attn:    Dr Matthias Fischer
Email:    matthias.fischer@schiffsbank.com

FOKUS BANK

(being the Norwegian branch of Danske Bank A/S)

Stortingsgaten 6

P O Box 1170 Sentrum

NO-0107 Oslo

Norway

 

Fax:    +47 85 407990
Attn:    Mr Øivind Haraldsen/Mr Tore Thorlacius Braein
Email:    oivind.haraldsen@fokus.no/
   tore.braein@fokus.no

 

28


HSH NORDBANK AG

Gerhart-Hauptmann-Platz 50

20095 Hamburg

Germany

 

Fax:    +49 40 3333 613741
Attn:    Mr Carsten Dreyer
Email:    carsten.dreyer@hsh-nordbank.com
Fax:    +1 212 407 6008
Attn:    Ms Frauke Hay
Email:    frauke.hay@hsh-nordbank.com

SKANDINAVISKA ENSKILDA BANKEN AB (publ)

Kungsträdgårdsgatan 8

SE-106 40 Stockholm

Sweden

 

Fax:    +44 20 7236 5144
Attn:    Mr Egil Aarrestad/Mr Malcolm Stonehouse
Email:    egil.aarrestad@seb.co.uk/
   malcolm.stonehouse@seb.co.uk

 

29


Schedule 4

EUR126,075,000 Credit Agreement dated November [    ] 2010 as amended and/or restated from time to time

Trustee:

KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax:    +49 69 7431 2944
Attn:    Ship Finance, X2a4
   Claudia Wenzel
Email:    Claudia.wenzel@kfw.de

As Trustee for:

NORDEA BANK NORGE ASA

Middelthunsgate 17

P O Box 1166 Sentrum

NO-0107 Oslo

Norway

 

Fax:    +47 22 486668
Attn:    Mr Arne Berglund
Email:    arne.berglund@nordea.com

DEUTSCHE SCHIFFSBANK AKTIENGESELLSCHAFT

Global Shipping

Domstrasse 8

D – 20095 Hamburg

Germany

 

Fax:    +49 40 3769 9649
Attn:    Mr Marcus Weber
   Ms Anne Randewig
Email:    marcus.weber@commerzbank.com
   anne.randewig@commerzbank.com

DnB NOR BANK ASA

Stranden 21

NO-0021 Oslo

Norway

 

Fax:    +47 22 482894
Attn:    Ms Amra Koluder
   Mr Solveig N. Knoff
Email:    amra.koluder@dnbnor.no
   solveig.knoff@dnbnor.no


KFW IPEX-BANK GMBH

Palmengartenstrasse 5-9

60325 Frankfurt am Main

Germany

 

Fax:    +49 69 7431 2944
Attn:    Ship Finance, X2a4
   Claudia Wenzel
Email:    Claudia.wenzel@kfw.de

HSBC BANK PLC

8 Canada Square

London E14 5HQ

 

Fax:    +44 207 992 4428
Attn:    Alan P. Marshall
Email:    alan.p.marshall@hsbcib.com

And each other Secured Creditor under and as defined in the Credit Agreement.

 

2


Schedule 5

Notice of Assignment

(for attachment by way of endorsement to the Policy)

We, NCL (BAHAMAS) LTD., a company incorporated in and existing under the laws of Bermuda whose registered office is at Milner House, 18 Parliament Street, Hamilton HM 12, Bermuda, the bareboat charterer of the motor vessel “NORWEGIAN JADE” (the “Vessel”), hereby give notice that by a fourth deed of assignment and subordination dated                      2010, entered into by us with (1) PRIDE OF HAWAII, LLC and (2)KFW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for certain secured parties (the “Assignee”), and in consideration of (a) certain secured parties making certain facilities available to the Owner pursuant to a credit agreement, any interest rate protection agreement and/or any other hedging agreement, (b) payment by the Assignee to us of ten Dollars (USD10) and (c) other good and valuable consideration from the Assignee to us (the adequacy and receipt whereof we hereby acknowledge), and as security for payment of the obligations under the credit document and related agreements, we have assigned, and granted a fourth priority security interest in and to, absolutely all our right and title to and interest in all insurances in respect of the Vessel, including the insurances constituted by the policy on which this notice is endorsed.

Please note that this Notice may not be revoked or varied without the prior written consent of the Assignee.

 

NCL (BAHAMAS) LTD.
By:  

 

Title:  
Date:                      2010

 

3


Schedule 6

 

To: [ASSIGNEE]

[                                                                      ]

as trustee

Dated:                      2010

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

NCL (BAHAMAS) LTD. (the “Bareboat Charterer”)

We confirm that we have effected insurances for the account of the Bareboat Charterer as set out in Appendix “A” attached.

Pursuant to instructions received from the Bareboat Charterer and/or their authorised managers or agents and in consideration of your approving us as the appointed brokers in connection with the insurances covered by this letter, we hereby undertake:

 

1. to hold the insurance slips or contracts, the policies when issued, and any renewals of such policies or any policies substituted therefor with your consent as may be arranged through ourselves and the benefit of the insurances thereunder to your order in accordance with the terms of the Loss Payable Clause(s) set out in Appendix “B” attached; and

 

2. to arrange for the said Loss Payable Clause(s) to be included on the policies when issued; and

 

3. to have endorsed on each and every policy as and when the same is issued a Notice of Assignment in the form of Appendix “C” hereto dated and signed by the Bareboat Charterer and acknowledged by underwriters in accordance with market practice; and

 

4. to advise you promptly if we cease to be the brokers for the Bareboat Charterer or in the event of any material changes of which we are aware affecting the said insurance; and

 

5. following a written application received from you not later than one month before expiry of these insurances to notify you within fourteen days of the receipt of such application in the event of our not having received notice of renewal instructions from the Bareboat Charterer and/or their authorised managers or assignees, and in the event of our receiving instructions to renew to advise you promptly of the details thereof; and

 

6. to forward to you promptly any notices of cancellation that we receive from Underwriters; and

 

7. following a written application from you to advise you promptly of the premium payment situation where such premium is paid or payable through our intermediary.

 

4


If and where we are responsible for the payment of premium to underwriters, our above undertakings are given subject to our lien on the policies for premiums in respect of the Vessel only and subject to our right of cancellation on default in payment of such premiums but we undertake not to exercise such rights of cancellation without giving you ten days notice in writing either by letter or electronically transmitted message and a reasonable opportunity for you to pay any premiums outstanding.

It is understood and agreed that the operation of any automatic termination of cover, cancellation or amendment provisions contained in the policy conditions shall override any undertakings given by us as brokers.

Notwithstanding the terms of the said Loss Payable Clause(s) and the said Notice of Assignment, unless and until we receive written notice from you to the contrary, we shall be empowered to arrange for a collision and/or salvage guarantee to be given in the event of bail being required in order to prevent the arrest of the Vessel or to secure the release of the Vessel from arrest following a casualty. Where a guarantee has been given as aforesaid and the guarantor has paid any sum under the guarantee in respect of such claim, there shall be payable directly to the guarantor out of the proceeds of the said policies a sum equal to the sum so paid.

This undertaking shall be governed by and construed in accordance with English law and any disputes arising out of or in any way connected with this undertaking shall be submitted to the exclusive jurisdiction of the English courts.

This undertaking is subject to all claims and returns of premiums being collected through us as brokers.

Yours faithfully

 

5


Appendix A to letter of undertaking

Details of insurances

 

6


Appendix B to letter of undertaking

Loss Payable Clause

It is noted that, by a fourth deed of assignment and subordination in writing dated [] 2010 collateral to a fourth priority statutory mortgage and deed of covenants both dated [] 2010 (together the “Mortgage”), PRIDE OF HAWAII, LLC of Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801, United States of America (the “Owner”), owner of the vessel “NORWEGIAN JADE” (ex “PRIDE OF HAWAII”) (the “Vessel”), assigned to KFW IPEX-BANK GMBH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee (the “Assignee”) this policy and all benefits of this policy, including all claims of any nature (including return of premiums) under this policy.

It is also noted that, by an assignment in writing [] 2010, NCL (BAHAMAS) LTD. of Milner House, 18 Parliament Street, Hamilton HM 12, Bermuda (the “Bareboat Charterer”), the bareboat charterer of the Vessel pursuant to a bareboat charterparty dated 10 February 2008, assigned absolutely to the Assignee as fourth assignee all its interest in this policy and all benefits of this policy, including all claims of any nature (including return of premiums) under this policy.

Claims payable under this policy in respect of a total or constructive total or an arranged or agreed or compromised total loss or unrepaired damage and all claims which (in the opinion of the Assignee) are analogous thereto shall be payable to the Assignee up to the Assignee’s mortgage interest.

Subject thereto, all other claims, unless and until underwriters have received notice from the Assignee of a default under the Mortgage, in which event all claims under this policy shall be payable directly to the Assignee up to the Assignee’s mortgage interest, shall be payable as follows:

 

(i) a claim in respect of any one casualty where the aggregate claim against all insurers does not exceed twenty million United States Dollars (USD20,000,000) or the equivalent in any other currency, prior to adjustment for any franchise or deductible under the terms of the policy, shall be paid directly to the Bareboat Charterer for the repair, salvage or other charges involved or as a reimbursement if the Bareboat Charterer has fully repaired the damage and paid all of the salvage or other charges;

 

(ii) a claim in respect of any one casualty where the aggregate claim against all insurers exceeds twenty million United States Dollars (USD20,000,000) or the equivalent in any other currency prior to adjustment for any franchise or deductible under the terms of the policy, shall, subject to the prior written consent of the Assignee, be paid to the Bareboat Charterer as and when the Vessel is restored to her former state and condition and the liability in respect of which the insurance loss is payable is discharged, and provided that the insurers may with such consent make payment on account of repairs in the course of being effected, but, in the absence of such prior written consent shall be payable directly to the Assignee.

 

7


Appendix C to letter of undertaking

Notice of Assignment

(for attachment by way of endorsement to the Policy)

We, NCL (BAHAMAS) LTD., a company incorporated in and existing under the laws of Bermuda whose registered office is at Milner House, 18 Parliament Street, Hamilton HM 12, Bermuda, the bareboat charterer of the motor vessel “NORWEGIAN JADE” (the “Vessel”), hereby give notice that by a fourth deed of assignment and subordination dated [] 2010, entered into by us with (1) PRIDE OF HAWAII, LLC and (2) KFW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for certain secured parties (the “Assignee”), and in consideration of (a) certain secured parties making certain facilities available to the Owner pursuant to a credit agreement, any interest rate protection agreement and/or any other hedging agreement, (b) payment by the Assignee to us of ten Dollars (USD10) and (c) other good and valuable consideration from the Assignee to us (the adequacy and receipt whereof we hereby acknowledge), and as security for payment of the obligations under the credit document and related agreements, we have assigned, and granted a fourth priority security interest in and to, absolutely all our right and title to and interest in all insurances in respect of the Vessel, including the insurances constituted by the policy on which this notice is endorsed.

 

NCL (BAHAMAS) LTD.
By:  

 

Title:  
Date:                      2010

 

8


Schedule 7

 

To: [ASSIGNEE]

[                                                                      ]

as restructuring trustee (the “Assignee”)

Dated:                      2010

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

PRIDE OF HAWAII, LLC (the “Owners”)

NCL (BAHAMAS) LTD. (the “Bareboat Charterers”)

We acknowledge receipt of notice of an assignment to the Assignee of the insurances on the Vessel. So far as this Association is concerned, the managers do not consent to such assignment for the purposes of Rule [    ], other than to give efficacy to the Loss Payable Clause set out below and subject always to the Association’s right under Rule [    ].

We do confirm however that the Vessel is entered in this Association for Protection and Indemnity risks on the terms and conditions set out or to be set out in the Certificate of Entry. Furthermore, in consideration of your agreeing to the entry or continuing entry of the Vessel in this Association, the managers agree:

 

1. that neither the Bareboat Charterers nor the Owners shall cease to be insured by the Association in respect of the Vessel by reason of such assignment (see Rule [    ]); and

 

2. that, notwithstanding that the Vessel is mortgaged to the Assignee and that no undertaking or guarantee has been given to the Association to pay all contributions due in respect of the Vessel, neither the Bareboat Charterers nor the Owners cease to be insured by reason of the operation of Rule [    ].

It is further agreed that the following Loss Payable Clause will be included in the Certificate of Entry:

“Payment of any recovery the Bareboat Charterers are entitled to make out of the funds of the Association in respect of any liability, cost or expense incurred by them shall be made to the Bareboat Charterers or their order unless and until the Association receives notice to the contrary from [ASSIGNEE] of [                                             ] as agent for itself and others pursuant to an assignment of insurances over the vessel “NORWEGIAN JADE” dated                      2010 stating that a default has occurred under the Mortgage dated 2010, in which event all recoveries shall thereafter be paid to the said [ASSIGNEE] as agent or its order; provided always that no liability whatsoever shall attach to the Association, its Managers or their Assignees for failure to comply with the latter obligation until after the expiry of two (2) clear business days from the receipt of such notice.”

 

9


The Association undertakes:

 

1. to inform you if the Directors give the Bareboat Charterers notice under Rule [    ] that their insurance in the Association in respect of the Vessel is to cease at the end of the then current policy year; and

 

2. to give you fourteen (14) days’ notice of the Association’s intention to cancel the insurance of the Bareboat Charterers by reason of their failure to pay when due and demanded any sum due from them to the Association.

Yours faithfully

 

10


Schedule 8

Notice of Assignment

 

TO: PRIDE OF HAWAII, LLC

Corporation Trust Center

1209 Orange Street

Wilmington

Delaware 19801

United States of America

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

We, the bareboat charterer of the Vessel under the bareboat charter dated 10 February 2008 made between you and us in respect of the Vessel (the “Bareboat Charter”), hereby give you notice that by a fourth deed of assignment and subordination dated                      2010 we assigned to KFW IPEX-Bank GmbH of Palmengartenstrasse 5-9, 60325 Frankfurt am Main, Germany as trustee for certain secured parties (the “Assignee”) all our right and title to and interest in the Bareboat Charter.

Will you please acknowledge receipt of this letter by signing and returning one (1) copy to us and one (1) copy to the Assignee with the endorsement below duly completed.

Dated                      2010

 

NCL (BAHAMAS) LTD.
By:  
Title:  

 

11


Acknowledgement

 

TO: NCL (BAHAMAS) LTD.

Milner House

18 Parliament Street

Hamilton HM 12

Bermuda

Dear Sirs

m.v. “NORWEGIAN JADE” (the “Vessel”)

We, the undersigned, the owner of the Vessel under a charterparty dated 10 February 2008, hereby acknowledge receipt of the above notice and in consideration of the payment by you of ten United States Dollars (USD10) and other good and valuable consideration, the receipt and sufficiency of which we hereby acknowledge, we hereby (1) confirm that we have not previously received notice of any such assignment other than a first assignment, second assignment and third assignment and (2) consent to the assignment referred to in the above notice.

Dated                      2010

 

PRIDE OF HAWAII, LLC

By:

 

 

Title:

 

 

12