-----BEGIN PRIVACY-ENHANCED MESSAGE----- Proc-Type: 2001,MIC-CLEAR Originator-Name: webmaster@www.sec.gov Originator-Key-Asymmetric: MFgwCgYEVQgBAQICAf8DSgAwRwJAW2sNKK9AVtBzYZmr6aGjlWyK3XmZv3dTINen TWSM7vrzLADbmYQaionwg5sDW3P6oaM5D3tdezXMm7z1T+B+twIDAQAB MIC-Info: RSA-MD5,RSA, IkHLZQX2V23331fkoGMPaeME7mxbFO2/SFCT8VqJIuZKIggXxkI06sAnmfP3L5sY nPIPmQ92n9eyqAqY0qaGyw== 0000919574-08-002611.txt : 20080424 0000919574-08-002611.hdr.sgml : 20080424 20080424123042 ACCESSION NUMBER: 0000919574-08-002611 CONFORMED SUBMISSION TYPE: 20-F PUBLIC DOCUMENT COUNT: 7 CONFORMED PERIOD OF REPORT: 20080418 FILED AS OF DATE: 20080424 DATE AS OF CHANGE: 20080424 FILER: COMPANY DATA: COMPANY CONFORMED NAME: KNIGHTSBRIDGE TANKERS LTD CENTRAL INDEX KEY: 0001029145 STANDARD INDUSTRIAL CLASSIFICATION: WATER TRANSPORTATION [4400] IRS NUMBER: 000000000 FISCAL YEAR END: 1231 FILING VALUES: FORM TYPE: 20-F SEC ACT: 1934 Act SEC FILE NUMBER: 000-29106 FILM NUMBER: 08773713 BUSINESS ADDRESS: STREET 1: PAR LA VILLE PLACE, 4TH FLOOR STREET 2: 14 PAR LA VILLE ROAD CITY: HAMILTON HM 08 STATE: D0 ZIP: 00000 BUSINESS PHONE: 4412956935 MAIL ADDRESS: STREET 1: PAR LA VILLE PLACE, 4TH FLOOR STREET 2: 14 PAR LA VILLE ROAD CITY: HAMILTON HM 08 STATE: D0 ZIP: 00000 20-F 1 d875784_20-f.htm KNIGHTSBRIDGE 20-F d875784_20-f.htm

 
UNITED STATES
 
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549

FORM 20-F
(Mark One)
[   ]                    REGISTRATION STATEMENT PURSUANT TO SECTION 12(b) OR (g)
                OF THE SECURITIES EXCHANGE ACT OF 1934
 
OR
 
[X]                                ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d)
                OF THE SECURITIES EXCHANGE ACT OF 1934

For the fiscal year ended
December 31, 2007
 
OR
 
[   ]                            TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d)
                    OF THE SECURITIES EXCHANGE ACT OF 1934
 
OR

[   ]                    SHELL COMPANY REPORT PURSUANT TO SECTION 13 OR 15(d) OF
    THE SECURITIES EXCHANGE ACT OF 1934

Date of event requiring this shell company report
 

For the transition period from
 
Commission file number
0-22704
 
KNIGHTSBRIDGE TANKERS LIMITED
(Exact name of Registrant as specified in its charter)
 
KNIGHTSBRIDGE TANKERS LIMITED
(Translation of Registrant’s name into English)
Bermuda
(Jurisdiction of incorporation or organization)
Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton, HM 08, Bermuda
(Address of principal executive offices)
Georgina Sousa, (1) 441 295 3494, Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton, HM 08, Bermuda
(Name, Telephone, E-mail and/or Facsimile number and Address of Company Contact Person )


Securities registered or to be registered pursuant to section 12(b) of the Act

Title of each class
 
Name of each exchange
Common Shares,  $0.01 Par Value
 
NASDAQ National Market


Securities registered or to be registered pursuant to section 12(g) of the Act.

None
(Title of Class)


Securities for which there is a reporting obligation pursuant to Section 15(d) of the Act.

Common Shares,  $0.01 Par Value
 (Title of Class)

Indicate the number of outstanding shares of each of the issuer’s classes of capital or common stock as of the close of the period covered by the annual report.

17,100,000 Common Shares, $0.01 Par Value
 
 
 
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act.
 
[    ] Yes     [ X] No
   
If this report is an annual or transition report, indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934.
 
[    ] Yes     [ X] No
   
Note – Checking the box above will not relieve any registrant required to file reports pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 from their obligations under those Sections.
 
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.
 
[ X] Yes    [    ] No
   
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, or a non-accelerated filer. See definition of “accelerated filer and large accelerated filer” in Rule 12b-2 of the Exchange Act. (Check one):
 
Large accelerated filer [    ]                         Accelerated filer  [  X  ]                            Non-accelerated filer [   ]
 
Indicate by check mark which financial statement the registrant has elected to follow:
 
 
[    ] Item 17   [ X ] Item 18
Indicate by check mark which basis of accounting the registrant has used to prepare the financial statements included in this filing:
 
U.S. GAAP x                                 International Financial Reporting Standards o                     Other o
 
 
If this is an annual report, indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).
 
[    ] Yes     [ X ] No

 
(i)
 

INDEX TO REPORT ON FORM 20-F


   
PAGE
PART I
   
Item 1.
Identity of Directors, Senior Management and Advisers ……………………....
1
Item 2.
Offer Statistics and Expected Timetable ………………………………………
1
Item 3.
Key Information………………………………………………………………
1
Item 4.
Information on the Company…………………………………………………..
10
Item 4A.
Unresolved Staff Comments…………………………………………………..
24
Item 5.
Operating and Financial Review and Prospects………………………………..
24
Item 6.
Directors, Senior Management and Employees………………………………..
32
Item 7.
Major Shareholders and Related Party Transactions…………………………..
35
Item 8.
Financial Information………………………………………………………….
35
Item 9.
The Offer and Listing………………………………………………………….
36
Item 10.
Additional Information………………………………………………………...
37
Item 11.
Quantitative and Qualitative Disclosures about Market Risk…………………....
42
Item 12.
Description of Securities other than Equity Securities…………………………..
42
 
PART II
 
   
Item 13.
Defaults, Dividend Arrearages and Delinquencies……………………………...
43
Item 14.
Material Modifications to the Rights of Security Holders and Use of Proceeds……………………………………………………………………..
 
43
Item 15.
Controls and Procedures……………………………………………………...
43
Item 16A.
Audit Committee Financial Expert……………………………………………..
44
Item 16B.
Code of Ethics………………………………………………………………..
44
Item 16C.
Principal Accountant Fees and Services……………………………………….
44
Item 16D.
Exemptions from the Listing Standards for Audit Committees………………….
45
Item 16E.
Purchase of Equity Securities by the Issuer and Affiliated Purchasers…………..
45
 
PART III
 
   
Item 17.
Financial Statements…………………………………………………………..
46
Item 18.
Financial Statements…………………………………………………………..
46
Item 19.
Exhibits……………………………………………………………………….
46
 
 

 
(ii)

 

 
 
 
CAUTIONARY STATEMENT REGARDING FORWARD-LOOKING STATEMENTS

Matters discussed in this report may constitute forward-looking statements.  The Private Securities Litigation Reform Act of 1995 provides safe harbor protections for forward-looking statements in order to encourage companies to provide prospective information about their business.  Forward-looking statements include statements concerning plans, objectives, goals, strategies, future events or performance, and underlying assumptions and other statements, which are other than statements of historical facts.

Knightsbridge Tankers Limited, or the Company desires to take advantage of the safe harbor provisions of the Private Securities Litigation Reform Act of 1995 and is including this cautionary statement in connection with this safe harbor legislation.  This report and any other written or oral statements made by us or on our behalf may include forward-looking statements, which reflect our current views with respect to future events and financial performance. When used in this report, the words “believe,” “anticipate,” “intend,” “estimate,” “forecast,” “project,” “plan,” “potential,” “will,” “may,” “should,” “expect” and similar expressions identify forward-looking statements.

The forward-looking statements in this report are based upon various assumptions, many of which are based, in turn, upon further assumptions, including without limitation, management's examination of historical operating trends, data contained in our records and other data available from third parties.  Although we believe that these assumptions were reasonable when made, because these assumptions are inherently subject to significant uncertainties and contingencies which are difficult or impossible to predict and are beyond our control, we cannot assure you that we will achieve or accomplish these expectations, beliefs or projections.

In addition to these important factors and matters discussed elsewhere herein and in the documents incorporated by reference herein, important factors that, in our view, could cause actual results to differ materially from those discussed in the forward-looking statements include the strength of world economies, fluctuations in currencies and interest rates, general market conditions, including fluctuations in charterhire rates and vessel values, changes in demand in the tanker market, including changes in demand resulting from changes in OPEC's petroleum production levels and world wide oil consumption and storage, changes in the Company's operating expenses, including bunker prices, drydocking and insurance costs, changes in governmental rules and regulations or actions taken by regulatory authorities, potential liability from pending or future litigation, general domestic and international political conditions, potential disruption of shipping routes due to accidents,  political events or acts by terrorists and other important factors described from time to time in the reports filed by the Company with the Securities and Exchange Commission.

 
(iii)

 

PART I

ITEM 1.                      IDENTITY OF DIRECTORS, SENIOR MANAGEMENT AND ADVISERS

Not Applicable

ITEM 2.                      OFFER STATISTICS AND EXPECTED TIMETABLE

Not Applicable

ITEM 3.                      KEY INFORMATION

Throughout this report, the “Company,” “Knightsbridge,” “we,” “us” and “our” all refer to Knightsbridge Tankers Limited and its subsidiaries. We use the term deadweight ton, or dwt, in describing the size of vessels. Dwt, expressed in metric tons, each of which is equivalent to 1,000 kilograms, refers to the maximum weight of cargo and supplies that a vessel can carry. Unless otherwise indicated, all references to “USD,”“US$” and “$” in this report are to, and amounts are presented in, U.S. dollars.

A. SELECTED FINANCIAL DATA

The selected consolidated income statement data of Knightsbridge Tankers Limited and its subsidiaries, with respect to the fiscal years ended December 31, 2007, 2006 and 2005, and the selected consolidated balance sheet data of the Company with respect to December 31, 2007 and 2006 have been derived from the Company's Consolidated Financial Statements included herein and should be read in conjunction with such statements and the notes thereto.  The selected consolidated income statement data with respect to the fiscal years ended December 31, 2004 and 2003 and the selected consolidated balance sheet data with respect December 31, 2005, 2004 and 2003 have been derived from consolidated financial statements of the Company not included herein. The following table should also be read in conjunction with Item 5 “Operating and Financial Review and Prospects” and the Company's Consolidated Financial Statements and Notes thereto included herein.

   
Fiscal year ended December 31,
 
   
2007
   
2006
   
2005
   
2004
   
2003
 
(in thousands of $, except shares, per share data and ratios)
 
Income Statement Data:
                             
Total operating revenues
    88,160       105,728       100,179       135,695       75,246  
Total operating expenses
    46,913       54,463       51,778       42,441       18,457  
Net operating income
    90,366       51,265       48,401       93,254       56,789  
Net income
    84,836       45,717       43,967       85,839       47,461  
Earnings per common share
                                       
- basic and diluted
    4.96       2.67       2.57       5.02       2.78  
Cash dividend declared per share
    2.50       3.60       4.55       4.55       2.74  
                                         
Balance Sheet Data (at end of year):
                                       
Cash and cash equivalents
    82,143       8,538       12,634       31,653       6,312  
Restricted cash
    10,000       10,000       10,000       10,000       -  
Newbuildings
    33,459       -       -       -       -  
Vessels, net
    201,072       267,949       285,070       301,500       -  
Vessels under capital lease, net
    -       -       -       -       319,408  
Total assets
    342,166       301,499       323,159       365,554       348,443  
Credit facilities and current portion of long-term debt
    8,960       11,211       11,200       11,309       8,400  
Long-term debt
    103,040       98,000       109,200       120,400       116,997  
Share capital
    171       171       171       171       171  
Stockholders’ equity
    221,276       179,190       195,033       228,871       215,527  
Common shares outstanding
    17,100,000       17,100,000       17,100,000       17,100,000       17,100,000  
                                         

 
1

 


Other Financial Data:
                             
Equity to assets ratio (percentage) (1)
    64.7 %     59.4 %     60.4 %     62.6 %     61.9 %
Debt to equity ratio (2)
    0.5       0.6       0.6       0.6       0.6  
Price earnings ratio (3)
    4.9       8.9       9.4       6.7       4.5  
Time charter equivalent revenue (4)
    75,288       85,713       83,720       121,455       75,246  
                                         

1.
Equity to assets ratio is calculated as total stockholders’ equity divided by total assets.
2.
Debt to equity ratio is calculated as total interest bearing current and long-term liabilities, including obligations under capital leases, divided by stockholders’ equity.
3.
Price earnings ratio is calculated using the year end share price divided by basic earnings per share.
4.
A reconciliation of time charter equivalent revenues to total operating revenues as reflected in the consolidated statements of operation is as follows:

   
2007
   
2006
   
2005
   
2004
   
2003
 
(in thousands of $)
                             
Total operating revenues
    88,160       105,728       100,179       135,695       75,246  
Less: Voyage expense
    (12,872 )     (20,015 )     (16,459 )     (14,240 )     -  
Time charter equivalent revenue
    75,288       85,713       83,720       121,455       75,246  

In 2003, no voyage expenses were incurred due to the bareboat charters with Shell International. The charters ended during 2003.
 
Our vessels may operate under time charters, bareboat charters, voyage charters, pool arrangements and contracts of affreightment, or COAs. Under a time charter, the charterer pays substantially all of the vessel voyage costs which are primarily fuel and port charges. Under a bareboat charter the charterer pays substantially all of the vessel voyage and operating costs which are primarily crewing and insurance costs. Under a voyage charter, the vessel owner pays such costs. Under contracts of affreightment, the owner carries an agreed upon quantity of cargo over a specified route and time period. Accordingly, charter income from a voyage charter would be greater than that from an equally profitable time charter to take account of the owner’s payment of vessel voyage costs, and charter income from a bareboat charter would be lower than that from an equally profitable time charter, to take account of the charterer’s payment of vessel operating costs. In order to compare vessels trading under different types of charters, it is standard industry practice to measure the revenue performance of a vessel in terms of time charter equivalent revenue, or TCE. Total TCE is the sum of time charter, voyage charter and bareboat charter revenues, less voyage expenses. Total TCE, which is not covered by generally accepted accounting principles, or GAAP, provides more meaningful information to us than total operating revenues, the most directly comparable GAAP measure. Average daily TCEs are also widely used by investors and analysts in the tanker shipping industry for comparing financial performance between companies and to industry averages. In order to calculate the daily TCE figures disclosed in Item 5, TCEs for bareboat charters include an allowance for estimated operating costs that would be paid by us under an equivalently profitable time charter. Other companies may calculate TCE using a different method.
 

B. CAPITALIZATION AND INDEBTEDNESS

Not Applicable

C. REASONS FOR THE OFFER AND USE OF PROCEEDS

Not Applicable


 
2

 
D. RISK FACTORS

We are engaged primarily in transporting crude oil and oil products and expect, with the acquisition of two Capesize bulk carriers in 2009, to operate in the dry bulk market. The following summarizes some of the risks that may materially affect our business, financial condition or results of operations.

Risks Related to Our Industry
 
The cyclical nature of the tanker industry may lead to volatile changes in charter rates and vessel values which may adversely affect our earnings
 
Historically, the tanker industry has been highly cyclical, with volatility in profitability and asset values resulting from changes in the supply of and demand for tanker capacity. If the tanker market is depressed in the future, our earnings and available cash flow may decrease. Our ability to re-charter our vessels on the expiration or termination of their current spot, time and bareboat charters and the charter rates payable under any renewal or replacement  charters will depend upon, among other things, economic conditions in the tanker market.  Fluctuations in charter rates and vessel values result from changes in the supply and demand for tanker capacity and changes in the supply and demand for oil and oil products.

The factors affecting the supply and demand for oil tankers are outside of our control, and the nature, timing and degree of changes in industry conditions are unpredictable.  The factors that influence demand for tanker capacity include:

 
demand for oil and products;
 
global and regional economic and political conditions;
 
changes in oil production and refining capacity;
 
environmental and other regulatory developments;
 
the distance oil and oil products are to be moved by sea; and
 
changes in seaborne and other transportation patterns.

The factors that influence the supply of tanker capacity include:

 
the number of newbuilding deliveries;
 
the scrapping rate of older vessels;
 
port or canal congestion;
 
vessel casualties;
 
price of steel;
 
potential conversion of vessels to alternative use;
 
the number of vessels that are out of service; and
 
changes in environmental and other regulations that may effectively cause reductions in the carrying capacity of vessels or early obsolescence of tonnage.

The international tanker industry has experienced historically high charter rates and vessel values in the recent past and there can be no assurance that these historically high charter rates and vessel values will be sustained

Charter rates in the tanker industry are volatile. We anticipate that future demand for our vessels, and in turn our future charter rates, will be dependent upon continued economic growth in the world’s economy as well as seasonal and regional changes in demand and changes in the capacity of the world’s fleet. We believe that these charter rates are the result of continued economic growth in the world economy that exceeds growth in global vessel capacity. There can be no assurance that economic growth will not stagnate or decline leading to a decrease in vessel values and charter rates. A decline in charter rates could have an adverse effect on our business, financial condition, results of operation and ability to pay dividend.

Any decrease in shipments of crude oil may adversely affect our financial performance

The demand for our very large crude carrier, or VLCC, oil tankers derives primarily from demand for Arabian Gulf and West African crude oil, along with crude oil from the former Soviet Union, or the FSU, which, in turn, primarily depends on the economies of the world's industrial countries and competition from alternative energy sources.  A wide range of economic, social and other factors can significantly affect the strength of the world's industrial economies and their demand for Arabian Gulf crude oil.  One such factor is the price of worldwide crude oil.  The world's oil markets have experienced high levels of volatility in the last 25 years.  If oil prices were to rise dramatically, the economies of the world's industrial countries may experience a significant downturn.
 
3

 

Any decrease in shipments of crude oil from the above mentioned geographical areas would have a material adverse effect on our financial performance.  Among the factors which could lead to such a decrease are:

 
·
increased crude oil production from other areas;
 
·
increased refining capacity in the Arabian Gulf area;
 
·
increased use of existing and future crude oil pipelines in the Arabian Gulf area;
 
·
a decision by Arabian Gulf, West African and FSU oil-producing nations to increase their crude oil prices or to further decrease or limit their crude oil production;
 
·
armed conflict in the Arabian Gulf and West Africa and and political or other factors; and
 
·
the development and the relative costs of nuclear power, natural gas, coal and other alternative sources of energy.

An increase in the supply of vessel capacity without an increase in demand for vessel capacity would likely cause charter rates and vessel values to decline, which could have a material adverse effect on our results of operations and financial condition
 
The supply of vessels generally increases with deliveries of new vessels and decreases with the scrapping of older vessels, conversion of vessels to other uses, such as floating production and storage facilities, and loss of tonnage as a result of casualties. Currently there is significant newbuilding activity with respect to virtually all sizes and classes of vessels. If the amount of tonnage delivered exceeds the number of vessels being scrapped, vessel capacity will increase. If the supply of vessel capacity increases and the demand for vessel capacity does not, the charter rates paid for our vessels as well as the value of our vessels could materially decline. Such a decline in charter rates and vessel values would likely have an adverse effect on our revenues and profitability.
 
Risks involved with operating ocean-going vessels could affect our business and reputation, which could have a material adverse effect on our results of operations and financial condition
 
The operation of an ocean-going vessel carries inherent risks.  These risks include the possibility of:
 
·
a marine disaster;
 
·
piracy;
 
·
environmental accidents;
 
·
cargo and property losses or damage; and
 
·
business interruptions caused by mechanical failure, human error, war, terrorism, piracy, political action in various countries, labor strikes, or adverse weather conditions.

Any of these circumstances or events could increase our costs or lower our revenues.  The involvement of our vessels in an oil spill or other environmental disaster may harm our reputation as a safe and reliable tanker operator.
 
Safety, environmental and other governmental and other requirements expose us to liability, and compliance with current and future regulations could require significant additional expenditures, which could have a material adverse affect on our business and financial results
 
Our operations are affected by extensive and changing international, national, state and local laws, regulations, treaties, conventions and standards in force in international waters, the jurisdictions in which our tankers and other vessels operate and the country or countries in which such vessels are registered, including those governing the management and disposal of hazardous substances and wastes, the cleanup of oil spills and other contamination, air emissions, and water discharges and ballast water management.  These regulations include the U.S. Oil Pollution Act of 1990, or OPA, the International Convention on Civil Liability for Oil Pollution Damage of 1969, or CLC; International Convention for the Prevention of Pollution from Ships, the IMO International Convention for the Safety of Life at Sea of 1974, or SOLAS, the International Convention on Load Lines of 1966, and the U.S. Marine Transportation Security Act of 2002.  In addition, vessel classification societies also impose significant safety and other requirements on our vessels.  In complying with current and future environmental requirements, vessel owners and operators may also incur significant additional costs in meeting new maintenance and inspection requirements, in developing contingency arrangements for potential spills and in obtaining insurance coverage.  Government regulation of vessels, particularly in the areas of safety and environmental requirements, can be expected to become stricter in the future and require us to incur significant capital expenditures on our vessels to keep them in compliance, or even to scrap or sell certain vessels altogether.

 
4

 


Many of these requirements are designed to reduce the risk of oil spills and other pollution, and our compliance with these requirements can be costly.  These requirements can also affect the resale value or useful lives of our vessels, require a reduction in cargo-capacity, ship modifications or operational changes or restrictions, lead to decreased availability of insurance coverage for environmental matters or result in the denial of access to certain jurisdictional waters or ports, or detention in, certain ports.

Under local, national and foreign laws, as well as international treaties and conventions, we could incur material liabilities, including cleanup obligations, natural resource damages and third-party claims for personal injury or property damages, in the event that there is a release of petroleum or other hazardous substances from our vessels or otherwise in connection with our current or historic operations.  We could also incur substantial penalties, fines and other civil or criminal sanctions, including in certain instances seizure or detention of our vessels, as a result of violations of or liabilities under environmental laws, regulations and other requirements.

For example, OPA affects all vessel owners shipping oil to, from or within the United States.  OPA allows for potentially unlimited liability without regard to fault for owners, operators and bareboat charterers of vessels for oil pollution in United States waters.  Similarly, CLC, which has been adopted by most countries outside of the United States, imposes liability for oil pollution in international waters.  OPA expressly permits individual states to impose their own liability regimes with regard to hazardous materials and oil pollution incidents occurring within their boundaries.  Coastal states in the United States have enacted pollution prevention liability and response laws, many providing for unlimited liability.
 
Maritime claimants could arrest our tankers, which could have a material adverse effect on our results of operations and financial condition
 
Crew members, suppliers of goods and services to a vessel, shippers of cargo and other parties may be entitled to a maritime lien against that vessel for unsatisfied debts, claims or damages. In many jurisdictions, a maritime lien holder may enforce its lien by arresting a vessel through foreclosure proceedings. The arrest or attachment of one or more of our vessels could interrupt our cash flow and require us to pay a significant amount of money to have the arrest lifted.

In addition, in some jurisdictions, such as South Africa, under the “sister ship” theory of liability, a claimant may arrest both the vessel which is subject to the claimant's maritime lien and any “associated” vessel, which is any vessel owned or controlled by the same owner.  Claimants could try to assert “sister ship” liability against one vessel in our fleet for claims relating to another of our ships.
 
Governments could requisition our vessels during a period of war or emergency, which could have a material adverse effect on our results of operations and financial condition
 
A government could requisition for title or seize our vessels.  Requisition for title occurs when a government takes control of a vessel and becomes her owner.  Also, a government could requisition our vessels for hire.  Requisition for hire occurs when a government takes control of a vessel and effectively becomes her charterer at dictated charter rates. Generally, requisitions occur during a period of war or emergency. This amount could be materially less than the charterhire that would have been payable otherwise.  In addition, we would bear all risk of loss or damage to a vessel under requisition for hire.  Government requisition of one or more of our vessels would negatively impact our revenues.
 
Risks Related to Our Business
 
Our revenues experience seasonal variations that may affect our income

We operate our tankers in markets that have historically exhibited seasonal variations in demand and, therefore, charter rates.  Historically, oil trade and therefore charter rates increased in the winter months and eased in the summer months as demand for oil in the Northern Hemisphere rose in colder weather and fell in warmer weather.  In addition, unpredictable weather patterns in the winter months tend to disrupt vessel scheduling.  The tanker industry in general is less dependent on the seasonal transport of heating oil than a decade ago as new uses for oil and oil products have developed, spreading consumption more evenly over the year.  Most apparent is a higher seasonal demand during the summer months due to energy requirements for air conditioning and motor vehicles.  The oil price volatility resulting from these factors has historically led to increased oil trading activities and demand for vessels.  The change in demand for vessels may affect the charter rates that we receive.

 
5

 

Because the market value of our vessels may fluctuate significantly, we may incur losses when we sell vessels which may adversely affect our earnings
 
The fair market value of vessels may increase and decrease depending on but not limited to the following factors:

 
general economic and market conditions affecting the shipping industry;
 
competition from other shipping companies;
 
types and sizes of vessels;
 
other modes of transportation;
 
cost of newbuildings;
 
shipyard capacity;
 
governmental or other regulations;
 
age of vessels;
 
prevailing level of charter rates; and
 
technological advances.

If we sell a vessel at a time when ship prices have fallen, the sale may be at less than the vessel’s carrying amount on our financial statements, with the result that we could incur a loss and a reduction in earnings.  In addition, if we determine at any time that a 'vessel’s future limited useful life and earnings require us to impair its value on our financial statements, that could result in a charge against our earnings and a reduction of our shareholders’ equity. It is possible that the market value of our vessels will decline in the future.

We operate in the highly competitive international tanker market and we may not be able to effectively compete which would negatively affect our results of operations
 
The operation of tanker vessels and transportation of crude and petroleum products and the other businesses in which we operate are extremely competitive.  Competition arises primarily from other tanker owners, including major oil companies as well as independent tanker companies, some of whom have substantially greater resources than we do.  Competition for the transportation of oil and oil products can be intense and depends on price, location, size, age, condition and the acceptability of the tanker and its operators to the charterers.  We compete with other tanker owners, including major oil companies as well as independent tanker companies for charterers.  Due in part to the fragmented tanker market, competitors with greater resources could enter and operate larger fleets through acquisitions or consolidations and may be able to offer better prices and fleets, which could result in our achieving lower revenues from our VLCC oil tankers.

We receive a portion of our charterhire revenue from a limited number of customers including Frontline Ltd.
 
We will derive a significant portion of our revenues from two charters with Frontline Ltd, or Frontline, a Bermuda corporation.  If we were to lose one or both of our charters with Frontline, or any of our other customers, we may be unable to find a suitable replacement charter for the related vessel on terms as favorable to us as under our current charters. The loss of any of our customers could have a material adverse effect on our revenues and results of operations.
 
Our revenues may be adversely affected if we do not successfully employ our tankers
 
Currently, all four of our tankers are contractually committed to time charters, with the remaining terms of these charters expiring on dates between 2009 and 2012. Although these time charters generally provide reliable revenues, they also limit the portion of our fleet available for spot market voyages during an upswing in the tanker industry cycle, when spot market voyages might be more profitable. We also cannot assure you that we will be able to successfully employ our tankers in the future or renew our existing charters at rates sufficient to allow us to operate our business profitably or meet our obligations. A decline in charter or spot rates or a failure to successfully charter our tankers could have a material adverse effect on our business, financial condition, results of operation and ability to pay dividends.

 
6

 

Delays or defaults by the shipyard in the construction of our new vessels could increase our expenses and diminish our net income and cash flows

We have entered into newbuilding contracts for the construction of two Capesize bulk carriers with Daehan Shipbuilding Co. Ltd in the Republic of Korea.  We have also entered into related long-term time charters for employment of these vessels upon their expected delivery in 2009. The newbuilding projects are subject to the risk of delay or defaults by the shipyard caused by, among other things, the financial condition of the shipyard, unforeseen quality or engineering problems, work stoppages, weather interference, unanticipated cost increases, delays in receipt of necessary equipment, and inability to obtain the requisite permits or approvals. In accordance with industry practice, in the event the shipyard is unable or unwilling to deliver the vessels, we may not have substantial remedies. In addition, if the delivery of any of the newbuildings is cancelled or significantly delayed, we might be unable to perform under the related long-term time charters, which may be cancelled. Failure to construct or deliver the ships by the shipyard or any significant delays could increase our expenses and result in cancellation of the related long-term time charters diminishing our net income and cash flows.

We have no history of operating dry bulk carriers and we may not be able to enter, or effectively manage our entry into dry bulk market, which could negatively impact our results of operations, financial condition and our ability to pay dividend
 
We have entered into newbuilding contracts for the construction of two Capesize bulk carriers and expect to take delivery of these in 2009.  Acquisition and management of these vessels will impose significant responsibilities on our management and staff.  We do not have any experience transporting dry bulk products nor do we have any history of operating or competing in that business.  As we have no history of operating dry bulk carriers, it is difficult to predict our needs when entering into the dry bulk market.  We will also have to market our services to a new customer base so that we can provide continued deployment of our vessels.  We may not be successful in executing our growth plans and may incur significant expenses and losses in connection with our future line of business which could negatively impact our results of operations, financial condition and our ability to pay dividends.
 
As we expand our fleet, we may not be able to recruit suitable employees and crew for our vessels which may limit our growth and cause our financial performance to suffer
 
As we expand our fleet, we will need to recruit suitable crew, shoreside, administrative and management personnel.  We may not be able to continue to hire suitable employees as we expand our fleet of vessels.  If we are unable to recruit suitable employees and crews, we may not be able to provide our services to customers, our growth may be limited and our financial performance may suffer.
 
We may not be able to renew time charters when they expire or enter into new time charters for newbuildings
 
Currently, all of our vessels are employed on time charters. We have also entered into long-term charters for the employment of our two Capesize bulk carriers upon their expected delivery in 2009. There can be no assurance that any of our existing time charters will be renewed or that we will be successful in entering into new time charters on the newbuildings that will be delivered to the Company or if renewed or entered into, that they will be at favorable rates. If, upon expiration of the existing time charters or delivery of newbuildings, we are unable to obtain time charters or voyage charters at desirable rates, the Company’s profitability may be adversely affected.

Rising fuel prices may adversely affect our profits
 
Fuel is a significant, if not the largest, operating expense for many of our shipping operations when our vessels are not under time charter. The price and supply of fuel is unpredictable and fluctuates based on events outside our control, including geopolitical developments, supply and demand for oil and gas, actions by OPEC and other oil and gas producers, war and unrest in oil producing countries and regions, regional production patterns and environmental concerns. As a result, an increase in the price of fuel may adversely affect our profitability.

 
7

 


Our vessels may suffer damage and we may face unexpected drydocking costs, which could affect our cash flow and financial condition
 
If our vessels suffer damage, they may need to be repaired at a drydocking facility. The costs of drydock repairs are unpredictable and can be substantial. We may have to pay drydocking costs that our insurance does not cover. The inactivity of these vessels while they are being repaired and repositioned, as well as the actual cost of these repairs, would decrease our earnings. In addition, space at drydocking facilities is sometimes limited and not all drydocking facilities are conveniently located. We may be unable to find space at a suitable drydocking facility or we may be forced to move to a drydocking facility that is not conveniently located to our vessels’ positions. The loss of earnings while our vessels are forced to wait for space or to relocate to drydocking facilities that are farther away from the routes on which our vessels trade would decrease our earnings.

Incurrence of expenses or liabilities may reduce or eliminate distributions
 
Our policy is to make distributions to shareholders based on the Company's earnings and cash flow. The amount and timing of dividends will depend on the Company's earnings, financial condition, cash position, Bermuda law affecting the payment of distributions and other factors. However, we could incur other expenses or contingent liabilities that would reduce or eliminate the cash available for distribution by us as dividends. Our loan agreement prohibits the declaration and payment of dividends if we are in default under such loan agreement.  In addition, the declaration and payment of dividends is subject at all times to the discretion of our Board.  We cannot assure you that we will pay dividends.
 
Increased inspection procedures and tighter import and export controls could increase costs and disrupt our business
 
International shipping is subject to various security and customs inspection and related procedures in countries of origin and destination. Inspection procedures can result in the seizure of contents of our vessels, delays in the loading, offloading or delivery and the levying of customs duties, fines or other penalties against us.

It is possible that changes to inspection procedures could impose additional financial and legal obligations on us. Furthermore, changes to inspection procedures could also impose additional costs and obligations on our customers and may, in certain cases, render the shipment of certain types of cargo uneconomical or impractical. Any such changes or developments may have an adverse effect on our business, financial condition, results of operations and ability to pay dividends.
 
Our debt service obligations could affect our ability to incur additional indebtedness or engage in certain transactions
 
Our existing financing agreements impose operational and financing restrictions on us which may significantly limit or prohibit, among other things, our ability to incur additional indebtedness, create liens, sell capital shares of subsidiaries, make certain investments, engage in mergers and acquisitions, purchase and sell vessels, enter into time or consecutive voyage charters or pay dividends without the consent of our lenders. In addition, our lenders may accelerate the maturity of indebtedness under our financing agreements and foreclose on the collateral securing the indebtedness upon the occurrence of certain events of default, including our failure to comply with any of the covenants contained in our financing agreements, not rectified within the permitted time. For instance, declining vessel values could lead to a breach of covenants under our financing agreements. If we are unable to pledge additional collateral or obtain waivers from our lenders, our lenders could accelerate our debt and foreclose on our vessels. In addition, if the lenders accelerate the debt outstanding under one facility in default, it could result in a default on our other facilities.
 
We may not be able to finance our newbuilding program

As of December 31, 2007 we had outstanding commitments of approximately $129.6 million with respect to our contracted newbuildings. We intend to fund this from existing cash resources and new bank financing, which may contain terms and covenants that restrict our financial and operating flexibility. Our liquidity position will be adversely impacted if we are unable to attract bank financing for our newbuilding program.

 
8

 

We may not have adequate insurance to compensate us if our vessels are damaged or lost

We procure insurance for our fleet against those risks that we believe the shipping industry commonly insures against.  These insurances include hull and machinery insurance, protection and indemnity insurance, which include environmental damage and pollution insurance coverage, and war risk insurance.  We can give no assurance that we are adequately insured against all risks.  We may not be able to obtain adequate insurance coverage at reasonable rates for our fleet in the future.  Additionally, our insurers may not pay particular claims.  Our insurance policies contain deductibles for which we will be responsible, limitations and exclusions which, although we believe are standard in the shipping industry, may nevertheless increase our costs or lower our revenue.
 
Our operations outside the United States expose us to global risks that may interfere with the operation of our vessels
 
We are an international company and primarily conduct our operations outside the United States. Changing economic, regulatory, political and governmental conditions in the countries where we are engaged in business or where our vessels are registered affect us. Hostilities or other political instability in regions where our vessels trade could affect our trade patterns and adversely affect our operations and performance.  The terrorist attacks against targets in the United States on September 11, 2001 and the military response by the United States has increased the likelihood of acts of terrorism worldwide.  Acts of terrorism, regional hostilities or other political instability, as shown by the attack on the Limburg in Yemen in October 2002, attacks on oil pipelines during and subsequent to the Iraq war in 2003 and attacks on expatriate workers in the Middle East could adversely affect the oil trade and reduce our revenue or increase our expenses.

Because we are a foreign corporation, you may not have the same rights that a shareholder in a U.S. corporation may have
 
We are a Bermuda company. Our memorandum of association and bye-laws and the Bermuda Companies Act 1981, as amended, govern our affairs. Investors may have more difficulty in protecting their interests in the face of actions by management, directors or controlling shareholders than would shareholders of a corporation incorporated in a United States jurisdiction. Under Bermuda law a director generally owes a fiduciary duty only to the company; not to the company’s shareholder.  Our shareholders may not have a direct course of action against our directors.  In addition, Bermuda law does not provide a mechanism for our shareholders to bring a class action lawsuit under Bermuda law.  Further, our Bye-laws provide for the indemnification of our directors or officers against any liability arising out of any act or omission except for an act or omission constituting fraud, dishonesty or illegality.

Because our offices and most of our assets are outside the United States, you may not be able to bring suit against us, or enforce a judgment obtained against us in the United States
 
Our executive offices, administrative activities and assets are located outside the United States. As a result, it may be more difficult for investors to effect service of process within the United States upon us, or to enforce both in the United States and outside the United States judgments against us in any action, including actions predicated upon the civil liability provisions of the federal securities laws of the United States.
 
We may have to pay tax on United States source income, which would reduce our earnings
 
Under the United States Internal Revenue Code of 1986, or the Code, 50% of the gross shipping income of a vessel owning or chartering corporation, such as us and our subsidiaries, that is attributable to transportation that begins or ends, but that does not both begin and end, in the United States, may be subject to a 4% United States federal income tax without allowance for deduction, unless that corporation qualifies for exemption from tax under Section 883 of the Code and the applicable Treasury Regulations recently promulgated thereunder.

We expect that we and each of our subsidiaries will qualify for this statutory tax exemption and we will take this position for United States federal income tax return reporting purposes. However, there are factual circumstances beyond our control that could cause us to lose the benefit of this tax exemption and thereby become subject to United States federal income tax on our United States source income. Therefore, we can give no assurances on our tax-exempt status or that of any of our subsidiaries.

 
 
9

 
If we or our subsidiaries are not entitled to exemption under Section 883 of the code for any taxable year, we or our subsidiaries could be subject for those years to an effective 4% United States federal income tax on the gross shipping income these companies derive during the year that are attributable to the transport or cargoes to or from the United States.  The imposition of this tax would have a negative effect on our business and would result in decreased earnings available for distribution to our shareholders.

Our Liberian subsidiaries may not be exempt from Liberian taxation, which would materially reduce our Liberian subsidiaries’, and consequently our, net income and cash flow by the amount of the applicable tax

The Republic of Liberia enacted an income tax law generally effective as of January 1, 2001, or the New Act, which repealed, in its entirety, the prior income tax law in effect since 1977, pursuant to which our Liberian subsidiaries, as non-resident domestic corporations, were wholly exempt from Liberian tax.

In 2004, the Liberian Ministry of Finance issued regulations, or the New Regulations, pursuant to which a non-resident domestic corporation engaged in international shipping, such as our Liberian subsidiaries, will not be subject to tax under the New Act retroactive to January 1, 2001. In addition, the Liberian Ministry of Justice issued an opinion that the New Regulations were a valid exercise of the regulatory authority of the Ministry of Finance. Therefore, assuming that the New Regulations are valid, our Liberian subsidiaries will be wholly exempt from tax as under prior law.

If our Liberian subsidiaries were subject to Liberian income tax under the New Act, our Liberian subsidiaries would be subject to tax at a rate of 35% on their worldwide income. As a result, their, and subsequently our, net income and cash flow would be materially reduced by the amount of the applicable tax. In addition, we, as a shareholder of the Liberian subsidiaries, would be subject to Liberian withholding tax on dividends paid by the Liberian subsidiaries at rates ranging from 15% to 20%.

Investor confidence and the market price of our common stock may be adversely impacted if we are unable to comply with Section 404 of the Sarbanes-Oxley Act of 2002
 
We are subject to Section 404 of the Sarbanes-Oxley Act of 2002, which requires us to include in our annual report on Form 20-F our management’s report on, and assessment of the effectiveness of, our internal controls over financial reporting. In addition, our independent registered public accounting firm is required to attest to and report on management’s assessment of the effectiveness of our internal controls over financial reporting. If we fail to achieve and maintain the adequacy of our internal controls over financial reporting, we will not be in compliance with all of the requirements imposed by Section 404. Any failure to comply with Section 404 could result in an adverse reaction in the financial marketplace due to a loss of investor confidence in the reliability of our financial statements, which ultimately could harm our business and could negatively impact the market price of our common stock. We believe that future ongoing costs of complying with these requirements may be substantial.



ITEM 4. INFORMATION ON THE COMPANY

A.  HISTORY AND DEVELOPMENT OF THE COMPANY

Knightsbridge Tankers Limited was incorporated in Bermuda on September 18, 1996. The Company's registered and principal executive offices are located at Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton, HM 08, Bermuda, and its telephone number is +1 (441) 295-0182. References herein to the Company include the Company and all of its subsidiaries, unless otherwise indicated. The Company was incorporated for the purpose of the acquisition, disposition, ownership, leasing and chartering of, through wholly-owned subsidiaries (the “Original Subsidiaries”), five very large crude oil carriers (the “Vessels”). The Company used the net proceeds of its initial public offering and bank debt to fund the purchase by the Original Subsidiaries of the Vessels. Upon their purchase from their previous owners on February 27, 1997 until March 2004, the Company chartered its Vessels to Shell International on long-term bareboat charters (the “Charters”). The term of each of these Charters was a minimum of seven years, with options for Shell International to extend the period for each Vessel's Charter. Shell International did not extend the bareboat charters for any of the Vessels.  Consequently, the Charters expired for all five Vessels, in accordance with their terms, during March 2004 and the Vessels were redelivered to the Company.

 
 
10

 
Following the redelivery, the Company entered into a five year time charter, due to expire in 2009, for one of its vessels while two of the Company's vessels were time chartered for a period of three years, which expired in May 2007. The Company entered into four and five year time charter agreements with Frontline, a Bermuda based publicly listed tanker owner and operator, to replace the charters which expired in May 2007. The Company's remaining two vessels had been trading on the spot market and from April 2005, participated in a pooling arrangement with Frontline. During March 2007, the pooling arrangement with Frontline was terminated, and the Company commenced a three year time charter for one of the vessels leaving one vessel trading in the spot market. The Vessel trading in the spot market was sold in December 2007. We currently own and operate four Vessels, all of which are employed on time charters.

In May 2007, the Company agreed to purchase two newbuilding contracts each for the construction of a Capesize bulk carrier with a cargo-carrying capacity of approximately 170,000 dwt. The ships are being built by Daehan Shipbuilding Co Ltd in the Republic of Korea and are due for delivery in 2009. The Company has secured employment for both of the newbuildings under five year time charters commencing upon their respective deliveries.


B.  BUSINESS OVERVIEW

We are an international tanker company and our primary business activity is currently the international seaborne transportation of crude oil. Our current fleet consists of four double-hull VLCCs, one of which was built in 1996 and three of which were built in 1995. Each of the Vessels is owned by a subsidiary and has been named and flagged in the Marshall Islands and is currently deployed on time charters operating worldwide.  In addition to the VLCCs, the Company has contracted to acquire two Capesize bulk carriers currently under construction. The Company expects to take delivery of these vessels in 2009 and employ them under five-year time charters. The following chart provides information on the deployment of our Vessels and the newbuildings as of December 31, 2007:
                                                            
Vessel Name
Type
Employment
Expiration Date
Camden     VLCC Time charter March, 2009
Mayfair             VLCC Time charter March, 2010
Hampstead
VLCC
Time charter
May, 2012
Kensington
VLCC
Time charter
May, 2011
Belgravia (1)
Capesize
Time charter
5 years (2)
Battersea (1)
Capesize
Time charter
5 years (2)
       

(1)  Vessel under construction for delivery in 2009
(2)  Commencing upon the vessel’s delivery.

Strategy

Our strategy is to maintain our position as an operator and charterer of VLCC oil tankers with flexibility to adjust our exposure to the tanker market depending on existing factors such as charter rates, newbuilding costs, vessel resale and scrap values and vessel operating expenses resulting from, among other things, changes in the supply of and demand for tanker capacity. We may adjust our exposure through time charters, bareboat charters, sale and leasebacks, straight sales and purchases of vessels, newbuilding contracts and acquisitions. We also intend to limit our exposure to the tanker market by expanding our activities in shipping transportation to sectors other than oil transportation. The Company has contracted to acquire two Capesize bulk carriers, currently under construction, and upon their delivery in 2009, they will operate in the dry bulk market. The Company believes that the dry bulk market has good underlying dynamics with a strong growth in the main commodity trades (coal and iron ore) and approximately 40% of the dry bulk fleet greater than 20,000 dwt is older than 20 years. We believe that expanding into the dry bulk market will be incremental to the Company’s long-term earning per share and dividend capacity.
 
Our goal is to generate competitive returns for our shareholders with quarterly dividend payments. The level of dividend will be guided by present earnings, market prospects, current capital expenditure programs as well as investment opportunities.
 
11

Management Structure
 
The Company has four tanker vessels of which two are currently on time charters which expire in 2009 and 2010. The remaining two tanker vessels have been chartered to a subsidiary of Frontline on four and five year time charter agreements. The terms of these charters were negotiated on an arm's length basis in 2006 and reflect the prevailing market terms at the time. Two of the Company's subsidiaries have ordered capesize bulk vessels at Daehan Shipbuilding Co. Ltd. in Korea. The construction process is expected to commence in August 2008. The vessels are expected to be delivered in 2009. To the extent these vessels are not delivered within the deadline set by the charter, the charterer will have the right to cancel the charter. The Company's board of directors (the “Board”) decided, at the incorporation of the Company, to contract the day-to-day management services of the Company and its subsidiaries, rather than to establish a proprietary management organization. This policy was based on the availability of such services in the market on terms which are more cost efficient to the Company than the alternative. The Board has not seen any reason to change this policy since it was formulated. All of the management services contracted in by the Company and its subsidiaries are subject to the Board's or, as the case may be, the board of the relevant subsidiary's, sole right to determine the overall objectives and policies of the Company and its subsidiaries. Further, all matters of material importance to or of an extraordinary nature in respect of the business of the Company and its subsidiaries shall be decided by the Board.

 
General Management Agreement
 
The Company and its subsidiaries are provided with general administrative services by ICB Shipping (Bermuda) Limited (the “Manager) on the terms set forth in a management agreement dated February 12, 1997, as subsequently amended by an amendment no. 1 thereto dated March 1,  2004 (the “Management Agreement”). The Manager is a wholly owned subsidiary of Frontline. The Manager subcontracts all the services delivered to the Company and its subsidiaries to Frontline Management (Bermuda) Limited, another wholly owned subsidiary of Frontline. The fee payable to the Manager pursuant to the terms of the Management Agreement was $1.15 million in 2007. The Company and its subsidiaries are responsible for paying all administrative expenses incurred from third parties such as audit, legal and other professional fees, registration fees and directors' and officers' fees and expenses. The Board regularly benchmark the fee due to the Manager and believes that the fee level (and other terms of the Management Agreement) are substantially similar to those that can be obtained in the market. The Company may terminate the Management Agreement at any time upon 30 days notice to the Manager provided such termination has been approved by the affirmative vote of shareholders holding at least 66 2/3 per cent of the Company's outstanding common shares in a shareholders meeting. The Company may, furthermore, terminate the Management Agreement subject to five business days prior written notice to the Manager in the event:
 
of a material breach of the terms thereof by the Manager occurs and remains unremedied for 30 days;
     
any material consent, authorization, license, approval or similar requirement for the Manager's activities as such is modified, terminated, revoked or expires;
     
the Manager becomes subject to an insolvency event;
     
it becomes unlawful for the Manager to perform the services to be provided there under; or
     
the Manager ceases to be a wholly owned subsidiary of Frontline.
 
 
The Manager may terminate the Management Agreement upon 10 business days notice in the event the Company undergoes “a change of control” (which shall mean the election of a director to the Board who is not recommended by the then current Board). The Management Agreement terminates automatically in 2012 unless earlier terminated as per the above. The Board believes that, in the case of any termination of the Management Agreement, the Company and its subsidiaries can obtain an appropriate alternative arrangement for its management requirements although there can be no assurance that such alternative arrangement would not cause the Company to incur additional expenses.

The Company has agreed with the Manager and Frontline Management (Bermuda) Ltd that, during 2008, the Management Agreement shall be novated and restated directly between the Company and its subsidiaries as service recipients and Frontline Management (Bermuda) Ltd as service provider.
 
 
12

 
Technical Management of vessel

Technical Management is provided by ship mangers subcontracted by the Manager to oversee the technical elements of running the vessels.
 
Building Supervision – Newbuildings
 
The Company's subsidiaries, KTL Belgravia I Inc. and KTL Belgravia II Inc., have entered into building supervision agreements with Frontline Management (Bermuda) Ltd (the “Building Supervisor”) setting forth the terms upon which the Building Supervisor shall supervise the construction of their respective newbuildings at Daehan Shipbuilding Co. Ltd. on their behalf.  The fee payable to the Building Supervisor has been agreed at $40,110 per month, commencing in the month in which the construction process commences. Each party to these agreements can terminate the same subject to one month's written notice to the other party.
 
Commercial Management of Newbuildings
 
KTL Belgravia I Inc. and KTL Belgravia II Inc. and Golden Ocean Management AS (the “Commercial Manager”) have negotiated the terms of a commercial management agreement in respect of the Company’s dry bulk newbuildings. These services shall commence on delivery of the newbuildings and shall, subject to the overall authority of the boards of the two subsidiaries, include the authority to charter out the newbuildings. The remuneration of the Commercial Manager shall be 1.25 % of all gross freights earned by the vessels. The agreement can be terminated by either party thereto subject to one month's written notice. The Commercial Manager is a wholly owned subsidiary of Golden Ocean Group Limited., a Bermuda company listed on the Oslo Stock Exchange.
 
Seasonality

Historically, oil trade and therefore charter rates, increased in the winter months and eased in the summer months as demand for oil in the Northern Hemisphere rose in colder weather and fell in warmer weather. In addition, unpredictable weather patterns in the winter months tend to disrupt vessel scheduling. The tanker industry in general is less dependent on the seasonal transport of heating oil than a decade ago as new uses for oil and oil products have developed, spreading consumption more evenly over the year. Most apparent is a higher seasonal demand during the summer months due to energy requirements for air conditioning and motor vehicles. The oil price volatility resulting from these factors has historically led to increased oil trading activities and demand for vessels. The change in demand for vessels may effect charter rates that we receive.
 
Competition

The market for international seaborne crude oil transportation services is highly fragmented and competitive. Seaborne crude oil transportation services generally are provided by two main types of operators: major oil company captive fleets (both private and state-owned) and independent ship owner fleets. In addition, several owners and operators pool their vessels together on an ongoing basis, and such pools are available to customers to the same extent as independently owned and operated fleets. Many major oil companies and other oil trading companies, the primary charterers of the vessels owned by the Company, also operate their own vessels and use such vessels not only to transport their own crude oil but also to transport crude oil for third party charterers in direct competition with independent owners and operators in the tanker charter market. Competition for charters is intense and is based upon price, location, size, age, condition and acceptability of the vessel and its manager. Competition is also affected by the availability of other size vessels to compete in the trades in which the Company engages. Charters are to a large extent brokered through international independent brokerage houses that specialize in finding the optimal ship for any particular cargo based on the aforementioned criteria. Brokers may be appointed by the cargo shipper or the ship owner.
 


 
13

 
Environmental Regulation and Other Regulations


Government regulations and laws significantly affect the ownership and operation of our tankers.  We are subject to various international conventions, laws and regulations in force in the countries in which our vessels may operate or are registered.

Our tankers are subject to both scheduled and unscheduled inspections by a variety of government, quasi-governmental and private organizations, each of which may have unique requirements.  These organizations include the local port authorities, national authorities, harbor masters or equivalent, classification societies, flag state and charterers, particularly terminal operators and oil companies.  Some of these entities require us to obtain permits, licenses and certificates for the operation of our tankers.  Our failure to maintain necessary permits or approvals could require us to incur substantial costs or temporarily suspend operation of one or more of the vessels in our fleet.

We believe that the heightened levels of environmental and quality concerns among insurance underwriters, regulators and charterers have led to greater inspection and safety requirements on all tankers and may accelerate the scrapping of older vessels throughout the industry.  Increasing environmental concerns have created a demand for tankers that conform to the stricter environmental standards.  We are required to maintain operating standards for all of our vessels emphasizing operational safety, quality maintenance, continuous training of our officers and crews and compliance with applicable local, national and international environmental laws and regulations.  We believe that the operation of our vessels will be in substantial compliance with applicable environmental laws and regulations and that our vessels have all material permits, licenses, certificates or other authorizations necessary for the conduct of our operations; however, because such laws and regulations are frequently changed and may impose increasingly stricter requirements, we cannot predict the ultimate cost of complying with these requirements, or the impact of these requirements on the resale value or useful lives of our tankers.  In addition, a future serious marine incident that results in significant oil pollution or otherwise causes significant adverse environmental impact could result in additional legislation or regulation that could negatively affect our profitability.

International Maritime Organization

The International Maritime Organization, or IMO (the United Nations agency for maritime safety and the prevention of pollution by ships), has adopted the International Convention for the Prevention of Marine Pollution from Ships, 1973, as modified by the Protocol of 1978 relating thereto, which has been updated through various amendments, or the MARPOL Convention. The MARPOL Convention implements environmental standards including oil leakage or spilling, garbage management, as well as the handling and disposal of noxious liquids, harmful substances in packaged forms, sewage and air emissions. These regulations, which have been implemented in many jurisdictions in which our vessels operate, provide, in part, that:

 
25-year old tankers must be of double hull construction or of a mid-deck design with double-sided construction, unless:
 
 
(1)
they have wing tanks or double-bottom spaces not used for the carriage of oil which cover at least 30% of the length of the cargo tank section of the hull or bottom; or
 
 
(2)
they are capable of hydrostatically balanced loading (loading less cargo into a tanker so that in the event of a breach of the hull, water flows into the tanker, displacing oil upwards instead of into the sea);
 
 
30-year old tankers must be of double hull construction or mid-deck design with double-sided construction; and
 
 
all tankers will be subject to enhanced inspections.
 
Also, under IMO regulations, a tanker must be of double hull construction or a mid-deck design with double-sided construction or be of another approved design ensuring the same level of protection against oil pollution if the tanker:
 
 
is the subject of a contract for a major conversion or original construction on or after July 6, 1993;
 
 
commences a major conversion or has its keel laid on or after January 6, 1994; or
 
 
completes a major conversion or is a newbuilding delivered on or after July 6, 1996.
 
 

 
14

 
Our vessels are also subject to regulatory requirements, including the phase-out of single hull tankers, imposed by the IMO. Effective September 2002, the IMO accelerated its existing timetable for the phase-out of single hull oil tankers. At that time, these regulations required the phase-out of most single hull oil tankers by 2015 or earlier, depending on the age of the tanker and whether it has segregated ballast tanks. We do not currently own any single hull vessels.

Under regulation 13G, the flag state may allow for some newer single hull ships registered in its country that conform to certain technical specifications to continue operating until the 25th anniversary of their delivery. Any port state, however, may deny entry of those single hull tankers that are allowed to operate until their 25th anniversary to ports or offshore terminals. These regulations have been adopted by over 150 nations, including many of the jurisdictions in which our tankers operate.

As a result of the oil spill in November 2002 relating to the loss of the MT Prestige, which was owned by a company not affiliated with us, in December 2003, the Marine Environmental Protection Committee of the IMO, or MEPC, adopted an amendment to the MARPOL Convention, which became effective in April 2005. The amendment revised an existing regulation 13G accelerating the phase-out of single hull oil tankers and adopted a new regulation 13H on the prevention of oil pollution from oil tankers when carrying heavy grade oil. Under the revised regulation, single hull oil tankers were required to be phased out no later than April 5, 2005 or the anniversary of the date of delivery of the ship on the date or in the year specified in the following table:



Category of Oil Tankers
 
Date or Year for Phase Out
Category 1 - oil tankers of 20,000 dwt and above carrying crude oil, fuel oil, heavy diesel oil or lubricating oil as cargo, and of 30,000 dwt and above carrying other oils, which do not comply with the requirements for protectively located segregated ballast tanks
 
April 5, 2005 for ships delivered on April 5, 1982 or earlier; or
2005 for ships delivered after April 5, 1982
Category 2 - oil tankers of 20,000 dwt and above carrying crude oil, fuel oil, heavy diesel oil or lubricating oil as cargo, and of 30,000 dwt and above carrying other oils, which do comply with the protectively located segregated ballast tank requirements
 
and
 
Category 3 - oil tankers of 5,000 dwt and above but less than the tonnage specified for Category 1 and 2 tankers.
 
April 5, 2005 for ships delivered on April 5, 1977 or earlier
2005 for ships delivered after April 5, 1977 but before January 1, 1978
2006 for ships delivered in 1978 and 1979
2007 for ships delivered in 1980 and 1981
2008 for ships delivered in 1982
2009 for ships delivered in 1983
2010 for ships delivered in 1984 or later

Under the revised regulations, a flag state may permit continued operation of certain Category 2 or 3 tankers beyond their phase in accordance with the above schedule. Under regulation 13G, the flag state may allow for some newer single hull oil tankers registered in its country that conform to certain technical specifications to continue operating until the earlier of the anniversary of the date of delivery of the vessel in 2015 or the 25th anniversary of their delivery.  Under regulations 13G and 13H, as described below, certain Category 2 and 3 tankers fitted only with double bottoms or double sides may be allowed by the flag state to continue operations until their 25th anniversary of delivery. Any port state, however, may deny entry of those single hull oil tankers that are allowed to operate under any of the flag state exemptions.

The MEPC in October 2004, adopted a unified interpretation to regulation 13G that clarified the date of delivery for  tankers that have been converted.  Under the interpretation, where an oil tanker has undergone a major conversion that has resulted in the replacement of the fore-body, including the entire cargo carrying section, the major conversion completion date of the oil tanker shall be deemed to be the date of delivery of the ship, provided that:
 
15


 
the oil tanker conversion was completed before July 6, 1996;
 
 
the conversion included the replacement of the entire cargo section and fore-body and the tanker complies with all the relevant provisions of MARPOL Convention applicable at the date of completion of the major conversion; and
 
 
the original delivery date of the oil tanker will apply when considering the 15 years of age threshold relating to the first technical specifications survey to be completed in accordance with MARPOL Convention.
 
In December 2003, the MEPC adopted a new regulation 13H on the prevention of oil pollution from oil tankers when carrying heavy grade oil, or HGO, which includes most of the grades of marine fuel.  The new regulation bans the carriage of HGO in single hull oil tankers of 5,000 dwt and above after April 5, 2005, and in single hull oil tankers of 600 dwt and above but less than 5,000 dwt, no later than the anniversary of their delivery in 2008.
 
Under regulation 13H, HGO means any of the following:
 
 
crude oils having a density at 15ºC higher than 900 kg/m3;
 
 
fuel oils having either a density at 15ºC higher than 900 kg/m3 or a kinematic viscosity at 50ºC higher than 180 mm2/s; or
 
 
bitumen, tar and their emulsions.
 
Under the regulation 13H, the flag state may allow continued operation of oil tankers of 5,000 dwt and above, carrying crude oil with a density at 15ºC higher than 900 kg/m3 but lower than 945 kg/m3, that conform to certain technical specifications and, in the opinion of the such flag state, the ship is fit to continue such operation, having regard to the size, age, operational area and structural conditions of the ship and provided that the continued operation shall not go beyond the date on which the ship reaches 25 years after the date of its delivery.  The flag state may also allow continued operation of a single hull oil tanker of 600 dwt and above but less than 5,000 dwt, carrying HGO as cargo, if, in the opinion of the such flag state, the ship is fit to continue such operation, having regard to the size, age, operational area and structural conditions of the ship, provided that the operation shall not go beyond the date on which the ship reaches 25 years after the date of its delivery.

The flag state may also exempt an oil tanker of 600 dwt and above carrying HGO as cargo if the ship is either engaged in voyages exclusively within an area under its jurisdiction, or is engaged in voyages exclusively within an area under the jurisdiction of another party, provided the party within whose jurisdiction the ship will be operating agrees.  The same applies to vessels operating as floating storage units of HGO.

Any port state, however, can deny entry of single hull tankers carrying HGO which have been allowed to continue operation under the exemptions mentioned above, into the ports or offshore terminals under its jurisdiction, or deny ship-to-ship transfer of HGO in areas under its jurisdiction except when this is necessary for the purpose of securing the safety of a ship or saving life at sea.

Revised Annex I to the MARPOL Convention entered into force in January 2007.  Revised Annex I incorporates various amendments adopted since the MARPOL Convention entered into force in 1983, including the amendments to regulation 13G (regulation 20 in the revised Annex) and regulation 13H (regulation 21 in the revised Annex).  Revised Annex I also impose construction requirements for oil tankers delivered on or after January 1, 2010.  A further amendment to revised Annex I includes an amendment to the definition of heavy grade oil that will broaden the scope of regulation 21. On August 1, 2007, regulation 12A (an amendment to Annex I) came into force requiring oil fuel tanks to be located inside the double hull in all ships with an aggregate oil fuel capacity of 600 m3 and above, which are delivered on or after August 1, 2010 including ships for which the building contract is entered into on or after August 1, 2007, or in the absence of a contract, which keel is laid on or after February 1, 2008.

Air Emissions
 
In September 1997, the IMO adopted Annex VI to the International Convention for the Prevention of Pollution from Ships to address air pollution from ships. Annex VI was ratified in May 2004, and became effective May 19, 2005. Annex VI sets limits on sulfur oxide and nitrogen oxide emissions from ship exhausts and prohibits deliberate emissions of ozone depleting substances, such as chlorofluorocarbons. Annex VI also includes a global cap on the sulfur content of fuel oil and allows for special areas to be established with more stringent controls on sulfur emissions. We believe that all our vessels are currently compliant in all material respects with these regulations.

 
16

 

Additional or new conventions, laws and regulations may be adopted that could adversely affect our business, cash flows, results of operations and financial condition.

In February 2007, the United States proposed a series of amendments to Annex VI regarding particulate matter, NOx and SOx emission standards.  The proposed emission program would reduce air pollution from ships by establishing a new tier of performance-based standards for diesel engines on all vessels and stringent emission requirements for ships that operate in coastal areas with air-quality problems. If these amendments are implemented, we may incur costs to comply with the proposed standards.

Recent scientific studies have suggested that emissions of certain gases, commonly referred to as “greenhouse gases,” may be contributing to warming of the Earth’s atmosphere.  According to the IMO’s study of greenhouse gases emissions from the global shipping fleet, greenhouse emissions from ships are predicted to rise by 38% to 72% due to increased bunker consumption by 2020 if corrective measures are not implemented.  Any passage of climate control legislation or other regulatory initiatives by the IMO or individual countries where we operate that restrict emissions of greenhouse gases could require us to make significant financial expenditures we cannot predict with certainty at this time.

Safety Requirements
 
The IMO has also adopted the International Convention for the Safety of Life at Sea, or SOLAS Convention, and the International Convention on Load Lines, 1966, or LL Convention, which impose a variety of standards to regulate design and operational features of ships. SOLAS Convention and LL Convention standards are revised periodically. We believe that all our vessels are in substantial compliance with SOLAS Convention and LL Convention standards.

Under Chapter IX of SOLAS, the requirements contained in the International Safety Management Code for the Safe Operation of Ships and for Pollution Prevention,  or ISM Code, promulgated by the IMO, also affect our operations. The ISM Code requires the party with operational control of a vessel to develop an extensive safety management system that includes, among other things, the adoption of a safety and environmental protection policy setting forth instructions and procedures for operating its vessels safely and describing procedures for responding to emergencies. We intend to rely upon the safety management system that the appointed ship managers have developed.

The ISM Code requires that vessel ship manager or operators obtain a safety management certificate for each vessel they operate. This certificate evidences compliance by a vessel’s management with the ISM code requirements for a safety management system. No vessel can obtain a safety management certificate unless its manager has been awarded a document of compliance, issued by each flag state, under the ISM Code. The appointed ship managers have obtained documents of compliance for their offices and safety management certificates for all of our vessels for which the certificates are required by the IMO.

Noncompliance with the ISM Code and other IMO regulations may subject the shipowner or bareboat charterer to increased liability, may lead to decreases in available insurance coverage for affected vessels and may result in the denial of access to, or detention in, some ports. The U.S. Coast Guard and European Union authorities have indicated that vessels not in compliance with the ISM Code by the applicable deadlines will be prohibited from trading in U.S. and European Union ports, as the case may be.

The IMO has negotiated international conventions that impose liability for oil pollution in international waters and a signatory’s territorial waters. Additional or new conventions, laws and regulations may be adopted which could limit our ability to do business and which could have a material adverse effect on our business and results of operations.

Ballast Water Requirements
 
The IMO adopted an International Convention for the Control and Management of Ships’ Ballast Water and Sediments, or the BWM Convention, in February 2004. The BWM Convention’s implementing regulations call for a phased introduction of mandatory ballast water exchange requirements (beginning in 2009), to be replaced in time with mandatory concentration limits. The BWM Convention will not enter into force until 12 months after it has been adopted by 30 states, the combined merchant fleets of which represent not less than 35% of the gross tonnage of the world’s merchant shipping.

 
17

 

The flag state, as defined by the United Nations Convention on Law of the Sea, has overall responsibility for the implementation and enforcement of international maritime regulations for all ships granted the right to fly its flag. The “Shipping Industry Guidelines on Flag State Performance” evaluates flag states based on factors such as sufficiency of infrastructure, ratification of international maritime treaties, implementation and enforcement of international maritime regulations, supervision of surveys, casualty investigations and participation at IMO meetings. Our vessels are flagged in the Marshall Islands. Marshall Islands-flagged vessels generally receive a good assessment in the shipping industry.

Oil Pollution Liability
 
Although the United States is not a party to these conventions, many countries have ratified and follow the liability plan adopted by the IMO and set out in the International Convention on Civil Liability for Oil Pollution Damage of 1969, as amended in 2000, or the CLC. Under this convention and depending on whether the country in which the damage results is a party to the 1992 Protocol to the CLC, a vessel’s registered owner is strictly liable for pollution damage caused in the territorial waters of a contracting state by discharge of persistent oil, subject to certain complete defenses.  The limits on liability outlined in the 1992 Protocol use the International Monetary Fund currency unit of Special Drawing Rights, or SDR. Under an amendment to the 1992 Protocol that became effective on November 1, 2003, for vessels of 5,000 to 140,000 gross tons (a unit of measurement for the total enclosed spaces within a vessel), liability will be limited to approximately 4.51 million SDR plus 631 SDR for each additional gross ton over 5,000. For vessels of over 140,000 gross tons, liability will be limited to 89.77 million SDR.  The exchange rate between SDRs and U.S. dollars was 0.613863 SDR per U.S. dollar on March 20, 2008. As the convention calculates liability in terms of a basket of currencies, these figures are based on currency exchange rates on March 13, 2007. The right to limit liability is forfeited under the CLC where the spill is caused by the owner’s actual fault and under the 1992 Protocol where the spill is caused by the owner’s intentional or reckless conduct. Vessels trading to states that are parties to these conventions must provide evidence of insurance covering the liability of the owner. In jurisdictions where the International Convention on Civil Liability for Oil Pollution Damage has not been adopted, various legislative schemes or common law govern, and liability is imposed either on the basis of fault or in a manner similar to that convention. We believe that our P&I insurance will cover the liability under the plan adopted by the IMO.

United States

In 1990, the United States Congress enacted OPA to establish an extensive regulatory and liability regime for environmental protection and cleanup of oil spills. OPA affects all owners and operators whose vessels trade with the United States or its territories or possessions, or whose vessels operate in the waters of the United States, which include the U.S. territorial sea and the 200 nautical mile exclusive economic zone around the United States. The Comprehensive Environmental Response, Compensation and Liability Act, or CERCLA, imposes liability for cleanup and natural resource damage from the release of hazardous substances (other than oil) whether on land or at sea. Both OPA and CERCLA impact our operations.

Under OPA, vessel owners, operators and bareboat charterers are responsible parties who are jointly, severally and strictly liable (unless the spill results solely from the act or omission of a third party, an act of God or an act of war) for all containment and clean-up costs and other damages arising from oil spills from their vessels. These other damages are defined broadly to include:

 
natural resource damages and related assessment costs;
 
 
real and personal property damages;
 
 
net loss of taxes, royalties, rents, profits or earnings capacity;
 
 
net cost of public services necessitated by a spill response, such as protection from fire, safety or health hazards; and
 
loss of subsistence use of natural resources.
 
OPA previously limited the liability of responsible parties to the greater of $1,200 per gross ton or $10.0 million per tanker that is over 3,000 gross tons (subject to possible adjustment for inflation). Amendments to OPA signed into law in July 2006 increased these limits on the liability of responsible parties to the greater of $1,900 per gross ton or $16.0 million per double hull tanker that is over 3,000 gross tons.  The act specifically permits individual states to impose their own liability regimes with regard to oil pollution incidents occurring within their boundaries, and some states have enacted legislation providing for unlimited liability for discharge of pollutants within their waters. In some cases, states which have enacted this type of legislation have not yet issued implementing regulations defining tanker owners’ responsibilities under these laws. CERCLA, which applies to owners and operators of vessels, contains a similar liability regime and provides for cleanup, removal and natural resource damages. Liability under CERCLA is limited to the greater of $300 per gross ton or $5.0 million.

 
18

 

 
These limits of liability do not apply, however, where the incident is caused by violation of applicable U.S. federal safety, construction or operating regulations, or by the responsible party’s gross negligence or willful misconduct. These limits do not apply if the responsible party fails or refuses to report the incident or to cooperate and assist in connection with the substance removal activities. OPA and CERCLA each preserve the right to recover damages under existing law, including maritime tort law. We believe that we are in substantial compliance with OPA, CERCLA and all applicable state regulations in the ports where our vessels call.

OPA requires owners and operators of vessels to establish and maintain with the U.S. Coast Guard evidence of financial responsibility sufficient to meet the limit of their potential strict liability under the act. The U.S. Coast Guard has enacted regulations requiring evidence of financial responsibility in the amount of $1,500 per gross ton for tankers, coupling the former OPA limitation on liability of $1,200 per gross ton with the CERCLA liability limit of $300 per gross ton. The U.S. Coast Guard has indicated that it expects to adopt regulations requiring evidence of financial responsibility in amounts that reflect the higher limits of liability imposed by the July 2006 amendments to OPA, as described above.  Under the regulations, evidence of financial responsibility may be demonstrated by insurance, surety bond, self-insurance or guaranty. Under OPA regulations, an owner or operator of more than one tanker is required to demonstrate evidence of financial responsibility for the entire fleet in an amount equal only to the financial responsibility requirement of the tanker having the greatest maximum strict liability under OPA and CERCLA. We have provided such evidence and received certificates of financial responsibility from the U.S. Coast Guard for each of our vessels required to have one.

We insure each of our vessels with pollution liability insurance in the maximum commercially available amount of $1.0 billion. A catastrophic spill could exceed the insurance coverage available, which could have a material adverse effect on our business.

Under OPA, with certain limited exceptions, all newly-built or converted vessels operating in U.S. waters must be built with double hulls, and existing vessels that do not comply with the double hull requirement will be prohibited from trading in U.S. waters over a 20-year period (1995-2015) based on size, age and place of discharge, unless retrofitted with double hulls. Notwithstanding the prohibition to trade schedule, the act currently permits existing single hull and double-sided tankers to operate until the year 2015 if their operations within U.S. waters are limited to discharging at the Louisiana Offshore Oil Port or off-loading by lightering within authorized lightering zones more than 60 miles off-shore. Lightering is the process by which vessels at sea off-load their cargo to smaller vessels for ultimate delivery to the discharge port.

All of our vessels are of double hull construction.

Owners or operators of tankers operating in the waters of the United States must file vessel response plans with the U.S. Coast Guard, and their tankers are required to operate in compliance with their U.S. Coast Guard approved plans. These response plans must, among other things:

 
address a worst case scenario and identify and ensure, through contract or other approved means, the availability of necessary private response resources to respond to a worst case discharge;
 
 
describe crew training and drills; and
 
 
identify a qualified individual with full authority to implement removal actions.
 
We have obtained vessel response plans approved by the U.S. Coast Guard for our vessels operating in the waters of the United States. In addition, the U.S. Coast Guard has announced it intends to propose similar regulations requiring certain vessels to prepare response plans for the release of hazardous substances.

In addition, the Clean Water Act prohibits the discharge of oil or hazardous substances in navigable waters and imposes strict liability in the form of penalties for unauthorized discharges.  The Clean Water Act also imposes substantial liability for the costs of removal, remediation and damages and complements the remedies available under OPA and CERCLA, discussed above.  The Environmental Protection Agency, or EPA, has exempted the discharge of ballast water and other substances incidental to the normal operation of vessels in U.S. ports from

 
19

 

Clean Water Act permitting requirements.  However, on March 31, 2005, a U.S. District Court ruled that the EPA exceeded its authority in creating an exemption for ballast water.  On September 18, 2006, the court issued an order invalidating the exemption in EPA’s regulations for all discharges incidental to the normal operation of a vessel as of September 30, 2008, and directing EPA to develop a system for regulating all discharges from vessels by that date.  EPA filed a notice of appeal of this decision and, if EPA’s appeals are unsuccessful and the exemption is repealed, we may be subject to Clean Water Act permit requirements that could include ballast water treatment obligations that could increase the cost of operating in the United States.  For example, this could require the installation of equipment on our vessels to treat ballast water before it is discharged or the implementation of other port facility disposal arrangements or procedures at potentially substantial cost, and/or otherwise restrict our vessels from entering waters.

On June 21, 2007, the EPA provided notice of its intention to develop a permit program for discharge of ballast water incidental to the normal operations of vessels and solicited comments.
 
In addition, most U.S. states that border a navigable waterway have enacted environmental pollution laws that impose strict liability on a person for removal costs and damages resulting from a discharge of oil or a release of a hazardous substance. These laws may be more stringent than U.S. federal law.

The U.S. Clean Air Act of 1970, as amended by the Clean Air Act Amendments of 1977 and 1990, or the CAA, requires EPA, to promulgate standards applicable to emissions of volatile organic compounds and other air contaminants. Our vessels are subject to vapor control and recovery requirements for certain cargoes when loading, unloading, ballasting, cleaning and conducting other operations in regulated port areas.  Our vessels that operate in such port areas with restricted cargoes are equipped with vapor recovery systems that satisfy these requirements.  The CAA also requires states to draft State Implementation Plans, or SIPs, designed to attain national health-based air quality standards in primarily major metropolitan and/or industrial areas. Several SIPs regulate emissions resulting from vessel loading and unloading operations by requiring the installation of vapor control equipment. As indicated above, our vessels operating in covered port areas are already equipped with vapor recovery systems that satisfy these requirements. Although a risk exists that new regulations could require significant capital expenditures and otherwise increase our costs, based on the regulations that have been proposed to date, we believe that no material capital expenditures beyond those currently contemplated and no material increase in costs are likely to be required.

The U.S. National Invasive Species Act, or NISA, was enacted in 1996 in response to growing reports of harmful organisms being released into U.S. ports through ballast water taken on by ships in foreign ports.  The United States Coast Guard adopted regulations under NISA in July 2004 that impose mandatory ballast water management practices for all vessels equipped with ballast water tanks entering U.S. waters.  These requirements can be met by performing mid-ocean ballast exchange, by retaining ballast water on board the ship, or by using environmentally sound alternative ballast water management methods approved by the United States Coast Guard. (However, mid-ocean ballast exchange is mandatory for ships heading to the Great Lakes or Hudson Bay, or vessels engaged in the foreign export of Alaskan North Slope crude oil.) Mid-ocean ballast exchange is the primary method for compliance with the United States Coast Guard regulations, since holding ballast water can prevent ships from performing cargo operations upon arrival in the United States, and alternative methods are still under development. Vessels that are unable to conduct mid-ocean ballast exchange due to voyage or safety concerns may discharge minimum amounts of ballast water (in areas other than the Great Lakes and the Hudson River), provided that they comply with recordkeeping requirements and document the reasons they could not follow the required ballast water management requirements. The United States Coast Guard is developing a proposal to establish ballast water discharge standards, which could set maximum acceptable discharge limits for various invasive species, and/or lead to requirements for active treatment of ballast water.

Our operations occasionally generate and require the transportation, treatment and disposal of both hazardous and non-hazardous solid wastes that are subject to the requirements of the U.S. Resource Conservation and Recovery Act, or RCRA, or comparable state, local or foreign requirements. In addition, from time to time we arrange for the disposal of hazardous waste or hazardous substances at offsite disposal facilities. If such materials are improperly disposed of by third parties, we may still be held liable for clean up costs under applicable laws.

 
20

 

Other Regulations
 
European Union
 
In July 2003, in response to the MT Prestige oil spill in November 2002, the European Union adopted legislation that prohibits all single hull tankers from entering into its ports or offshore terminals by 2010. The European Union has also banned all single hull tankers carrying heavy grades of oil from entering or leaving its ports or offshore terminals or anchoring in areas under its jurisdiction. Commencing in 2005, certain single hull tankers above 15 years of age will also be restricted from entering or leaving European Union ports or offshore terminals and anchoring in areas under European Union jurisdiction. The European Union has also adopted legislation that would: (1) ban manifestly sub-standard vessels (defined as those over 15 years old that have been detained by port authorities at least twice in a six month period) from European waters and create an obligation of port states to inspect vessels posing a high risk to maritime safety or the marine environment; and (2) provide the European Union with greater authority and control over classification societies, including the ability to seek to suspend or revoke the authority of negligent societies. The sinking of the MT Prestige and resulting oil spill in November 2002 has led to the adoption of other environmental regulations by certain European Union nations, which could adversely affect the remaining useful lives of all of our vessels and our ability to generate income from them. It is impossible to predict what legislation or additional regulations, if any, may be promulgated by the European Union or any other country or authority.

In 2005, the European Union adopted a directive on ship-source pollution, imposing criminal sanctions for intentional, reckless or negligent pollution discharges by ships.  The directive could result in criminal liability for pollution from vessels in waters of European countries that adopt implementing legislation.  Criminal liability for pollution may result in substantial penalties or fines and increased civil liability claims.

Vessel Security Regulations

Since the terrorist attacks of September 11, 2001, there have been a variety of initiatives intended to enhance vessel security. On November 25, 2002, the U.S. Maritime Transportation Security Act of 2002, or MTSA, came into effect. To implement certain portions of the MTSA, in July 2003, the U.S. Coast Guard issued regulations requiring the implementation of certain security requirements aboard vessels operating in waters subject to the jurisdiction of the United States. Similarly, in December 2002, amendments to SOLAS created a new chapter of the convention dealing specifically with maritime security. The new chapter became effective in July 2004 and imposes various detailed security obligations on vessels and port authorities, most of which are contained in the International Ship and Port Facility Security Code, or the ISPS Code. The ISPS Code is designed to protect ports and international shipping against terrorism. After July 1, 2004, to trade internationally, a vessel must attain an International Ship Security Certificate, or ISSC from a recognized security organization approved by the vessel’s flag state. Among the various requirements are:

 
on-board installation of automatic identification systems to provide a means for the automatic transmission of safety-related information from among similarly equipped ships and shore stations, including information on a ship’s identity, position, course, speed and navigational status;
 
 
on-board installation of ship security alert systems, which do not sound on the vessel but only alerts the authorities on shore;
 
 
the development of vessel security plans;
 
 
ship identification number to be permanently marked on a vessel’s hull;
 
 
a continuous synopsis record kept onboard showing a vessel’s history including, name of the ship and of the state whose flag the ship is entitled to fly, the date on which the ship was registered with that state, the ship’s identification number, the port at which the ship is registered and the name of the registered owner(s) and their registered address; and
 
 
compliance with flag state security certification requirements.
 
The U.S. Coast Guard regulations, intended to align with international maritime security standards, exempt from MTSA vessel security measures non-U.S. vessels that have on board, as of July 1, 2004, a valid ISSC attesting to the vessel’s compliance with SOLAS security requirements and the ISPS Code. We have implemented the various security measures addressed by MTSA, SOLAS and the ISPS Code, and our fleet is in compliance with applicable security requirements.

 
21

 


Inspection by Classification Societies

The classification society certifies that the vessel is “in-class,” signifying that the vessel has been built and maintained in accordance with the rules of the classification society and complies with applicable rules and regulations of the vessel’s country of registry and the international conventions of which that country is a member. In addition, where surveys are required by international conventions and corresponding laws and ordinances of a flag state, the classification society will undertake them on application or by official order, acting on behalf of the authorities concerned.

The classification society also undertakes on request other surveys and checks that are required by regulations and requirements of the flag state. These surveys are subject to agreements made in each individual case and/or to the regulations of the country concerned.

For maintenance of the class, regular and extraordinary surveys of hull, machinery, including the electrical plant, and any special equipment classed are required to be performed as follows:

 
Annual Surveys. For seagoing ships, annual surveys are conducted for the hull and the machinery, including the electrical plant and where applicable for special equipment classed, at intervals of 12 months from the date of commencement of the class period indicated in the certificate.

 
Intermediate Surveys. Extended annual surveys are referred to as intermediate surveys and typically are conducted two and one-half years after commissioning and each class renewal. Intermediate surveys may be carried out on the occasion of the second or third annual survey.

 
Class Renewal Surveys. Class renewal surveys, also known as special surveys, are carried out for the ship’s hull, machinery, including the electrical plant and for any special equipment classed, at the intervals indicated by the character of classification for the hull. At the special survey the vessel is thoroughly examined, including audio-gauging to determine the thickness of the steel structures. Should the thickness be found to be less than class requirements, the classification society would prescribe steel renewals. The classification society may grant a one year grace period for completion of the special survey. Substantial amounts of money may have to be spent for steel renewals to pass a special survey if the vessel experiences excessive wear and tear. In lieu of the special survey every four or five years, depending on whether a grace period was granted, a ship owner has the option of arranging with the classification society for the vessel’s hull or machinery to be on a continuous survey cycle, in which every part of the vessel would be surveyed within a five year cycle. At an owner’s application, the surveys required for class renewal may be split according to an agreed schedule to extend over the entire period of class. This process is referred to as continuous class renewal.

All areas subject to survey as defined by the classification society are required to be surveyed at least once per class period, unless shorter intervals between surveys are prescribed elsewhere. The period between two subsequent surveys of each area must not exceed five years.

Our vessels, which are less than 15 years old are drydocked every 60 months, while vessels which are more than 15 years old are drydocked every 30 to 36 months for inspection of the underwater parts and for repairs related to inspections. If any defects are found, the classification surveyor will issue a recommendation which must be rectified by the ship owner within prescribed time limits.
 
Most insurance underwriters make it a condition for insurance coverage that a vessel be certified as “in-class” by a classification society which is a member of the International Association of Classification Societies. All our vessels are certified as being “in-class” by Det Norske Veritas. All new and secondhand vessels that we purchase must be certified prior to their delivery under our standard purchase contracts and memoranda of agreement. If the vessel is not certified on the scheduled date of closing, we have no obligation to take delivery of the vessel.

In addition to the classification inspections, many of our customers regularly inspect our vessels as a precondition to chartering them for voyages. We believe that our well-maintained, high-quality vessels provide us with a competitive advantage in the current environment of increasing regulation and customer emphasis on quality.

 
22

 


Risk of loss and insurance
 
Our business is affected by a number of risks, including mechanical failure of the vessels, collisions, property loss to the vessels, cargo loss or damage and business interruption due to political circumstances in foreign countries, hostilities and labor strikes. In addition, the operation of any ocean-going vessel is subject to the inherent possibility of catastrophic marine disaster, including oil spills and other environmental mishaps, and the liabilities arising from owning and operating vessels in international trade.  OPA, which imposes virtually unlimited liability upon owners, operators and demise charterers of any vessel trading in the United States exclusive economic zone for certain oil pollution accidents in the United States, has made liability insurance more expensive for ship owners and operators trading in the United States market.
 
Our Manager is responsible for arranging the insurance of our vessels in line with standard industry practice. In accordance with that practice, we maintain marine hull and machinery and war risks insurance, which include the risk of actual or constructive total loss, and protection and indemnity insurance with mutual assurance associations. From time to time we carry insurance covering the loss of hire resulting from marine casualties in respect of some of our vessels. Currently, the amount of coverage for liability for pollution, spillage and leakage available to us on commercially reasonable terms through protection and indemnity associations and providers of excess coverage is $1.05 billion per vessel per occurrence. Protection and indemnity associations are mutual marine indemnity associations formed by shipowners to provide protection from large financial loss to one member by contribution towards that loss by all members.
 
We believe that our current insurance coverage is adequate to protect us against the accident-related risks involved  in the conduct of our business and that we maintain appropriate levels of environmental damage and pollution insurance coverage, consistent with standard industry practice. However, there is no assurance that all risks are adequately insured against, that any particular claims will be paid or that we will be able to procure adequate insurance coverage at commercially reasonable rates in the future.
 

 

 
23

 

C.  ORGANIZATIONAL STRUCTURE

See Exhibit 8.1 for a list of our principle subsidiaries.

D.  PROPERTY, PLANT AND EQUIPMENT

We operate a modern fleet of four tankers and have contracts to acquire two Capesize bulk carriers under construction. The name, dwt, flag and date of original delivery from the Builder's yard are set forth below.

 
Vessel name
Type
Approx. dwt
Flag
Year Built
         
Camden
VLCC
298,000
Marshall Islands
1995
Mayfair
VLCC
298,000
Marshall Islands
1995
Kensington
VLCC
298,000
Marshall Islands
1995
Hampstead
VLCC
298,000
Marshall Islands
1996
Belgravia
Capesize
170,500
Marshall Islands
under construction
Battersea
Capesize
170,500
Marshall Islands
under construction

The Vessels are of double hull construction designed for enhanced safety and reliability.

Other than its interests in the vessels and the newbuilding contracts, the Company has no interest in any other property.

ITEM 4A. UNRESOLVED STAFF COMMENTS

None


ITEM 5.  OPERATING AND FINANCIAL REVIEW AND PROSPECTS

Overview

The following discussion should be read in conjunction with Item 3 “Selected Financial Data” and the Company’s audited Consolidated Financial Statements and Notes thereto included herein.

In February 1997, the Company's five Original Subsidiaries each purchased one VLCC. From their purchase in February 1997 until March 2004, the Company chartered the Vessels to Shell International on long-term bareboat charters (the “Charters”). The Charters expired for all five Vessels, in accordance with their terms, in March 2004 and the Vessels were redelivered to the Company and subsequently chartered out on time and spot markets

The Company’s vessels are currently operating under the following time charter agreements:

 
Time Charter Terms
Length of Charter
Expiration date
Hampstead
$37,750 per day plus profit share*
5 year
May, 2012
Kensington
$37,750 per day plus profit share*
4 year
May, 2011
Camden
$31,000 per day
5 year
March, 2009
Mayfair
$45,000 per day
3 year
March, 2010
 
* Profit share is calculated and settled on a quarterly basis for earnings in excess of $37,750 per vessel per day calculated by reference to the Baltic International Trading Route (BITR) Index.
 
In addition, the Company has secured time charter agreements for its two newbuildings, which are currently under construction for $40,000 and $53,000 per day. The length of both charters are five years and are due to commence upon delivery in 2009.


 
24

 

Market Overview and Trend Information

In the beginning of 2007, the daily TCE was approximately $47,000 per day for VLCCs. The VLCC segment strengthened in the first quarter of 2007 from weakness at the end of 2006. A strike at Lavera, France, in late March delayed a large number of Suezmaxes from discharging their respective cargoes which caused Suezmax earnings to spike. VLCC earnings increased but not to the same extent as the Suezmaxes. Ultimately the earnings for both VLCCs and Suezmaxes gradually declined throughout the second and third quarters of 2007 The primary reasons for the decline can be attributed to reduced global oil production in the summer months, the price structure on oil turning from contango to backwardation, which initiated a significant draw on crude stocks worldwide. Volatility, a trademark of the VLCC segment, disappeared until the sharp increase in VLCC rates in mid November.

The sharp increase in VLCC rates was created in part by the discounting of crude prices by Saudi Aramco in late November to mainly U.S. refiners. This resulted in the increased demand for VLCCs between the last week in November and the third week in December and had the effect of upsetting the balance of supply and demand in the owners’ favor, which resulted in increased rates which shipowners successfully exploited. Additionally, the market was not hurt by the December oil spill caused by a Chinese owned single hull vessel off the coast of South Korea. Another important factor, which contributed to the increase in rates was the joint decision by several major owners to reduce laden and ballast speeds in order to save bunkers and reduce costs. In a low demand market, when bunkers cost as much as an additional $50,000 per day, the reduction of speed from 15 to 12 knots saved an estimated $20,000 per day and reduced the overall ”market capacity” by approximately 10%.

The increased number of VLCCs marked for conversions also contributed to the increase in rates. At the end of 2007, it is estimated that somewhere between 10 and 15 units had been removed from the market, reducing single hull availability in locations such as the Arabian Gulf.

Vessels have, in connection with the increased rates and volatility towards the end of the year been fixed on more speculative short term time charters than we have seen in the past. According to Clarkson’s, the average TCE for the year was approximately $57,000 per day for a double hulled VLCC.

The current trend is for oil majors to avoid employing single hull tonnage when transporting persistent oils because non-single hull vessels are less likely to be inspected. Oil traders with crude or fuel oil cargoes often require double hull tonnage in order to have full flexibility regarding cargo delivery. Thus, single hull ships are no longer able to trade to their full capacity compared to the double hull vessels. This implies a further gap in the already existing “two tier market” between the double and the single hull vessels.

Bunker prices followed the price fluctuations in the oil market closely in 2007 with Fujairah’s lowest bunker quote for the year set early January at $256 per metric ton and the high set in early November at $513 per metric ton. The average bunker price in 2007 was estimated to be approximately $374 per metric ton.

It was reported by the International Energy Agency, or IEA, in March 2008 that average OPEC oil production, including Iraq but not Angola, was approximately 29.1 million barrels per day during 2007, a 0.7 million barrel per day decrease from 2006. Saudi Arabia and Venezuela contributed the most to the reduced crude oil production by approximately 0.65 million barrels per day while Iran and Iraq offset this to a certain degree with increased production by approximately 0.26 million barrels per day. The balance stems from minor changes in all remaining OPEC countries. On December 1, 2007, the Republic of Ecuador became the thirteenth member of OPEC and thereby rejoined the Organization after an absence of a decade and a half. The inclusion of the Republic of Ecuador could strengthen the capability of OPEC in fulfilling its objectives and help to further stabilize the market.

OPEC-12 and Iraq are expected to reach a production capacity of 35.8 million barrels per day in 2008 according to IEA. Production could therefore accelerate in 2008 as capacity at the start of the year was at 32 million barrels per day. The growth is expected to be heavily skewed towards Saudi Arabia, Nigeria and UAE together accounting for approximately 75% of the net increase.

The IEA further estimates that the average world oil demand was 85.8 million barrels per day in 2007, a 1.1% increase from 2006. For 2008, a 2.0% or 1.7 million barrels per day growth is forecasted in world oil demand with China, Latin America and the Middle East as the main drivers.

 
25

 

The International Monetary Fund, or IMF, expects global growth to moderate to 4.1% in 2008, 0.8 % lower than in 2007, according to their February 2008 update. In the United States, growth is expected to come down to 1.5% this year, from 2.2% in 2007. Growth is also expected to ease in Europe, Japan and in emerging markets and developing countries. China’s growth is projected to remain rapid in 2008, albeit a little below the torrid pace in 2007 of 11.4%.

The total VLCC fleet increased by 1.9% in 2007 to 489 vessels with a total of 28 new vessels delivered to owners during 2007 with 28 new orders made. The total order book amounted to 176 vessels at the end of the year, which represented approximately 36% of the existing fleet.

Industry sources expect 40 VLCCs to be delivered from shipyards during 2008.

We believe it is likely that more tankers will be either converted or scrapped compared to recent years. Frontline estimates that approximately 40 VLCCs will be converted for non-trading purposes in 2008, approximately 90% to VLOC and the balance to FSO/FPSO. It is also likely that parts of the order book will be delayed as a function of the uncertainty of the delivery schedule for several yards due to financing issues. It is expected that these elements together will cushion the fleet growth.

Critical Accounting Policies and Estimates

The preparation of our financial statements in accordance with accounting principles generally accepted in the United States requires that management make estimates and assumptions affecting the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of revenues and expenses during the reporting period. The following is a discussion of the accounting policies applied by us that are considered to involve a higher degree of judgment in their application. See Note 2 to our audited Consolidated Financial Statements included herein for details of all of our significant accounting policies.

Revenue Recognition
 
Revenues are generated from freight billings, time charter and bareboat charter hires. Time charter and bareboat charter revenues are recorded over the term of the charter as service is provided. Under a voyage charter the revenues and associated voyage costs are recognized ratably over the estimated duration of the voyage, which is measured from completion of discharge to completion of discharge. Voyage revenues and expenses are recognized ratably over the estimated length of each voyage and, therefore, are allocated between reporting periods based on the relative transit time in each period. The impact of recognizing voyage expenses ratably over the length of each voyage is not materially different on a quarterly and annual basis from a method of recognizing such costs as incurred. Probable losses on voyages are accrued in full at the time such losses can be estimated. Amounts receivable from profit sharing arrangements are accrued based on the time charter equivalent rates achieved through vessel deployment over the preceding quarter in the market for certain key routes and are not contingent on the performance of the Company. Each quarterly settlement is final and does not get carried forward to the next quarter. There is no consideration of future performance in the recording of profit sharing revenue.

Vessels, Depreciation and Impairment
 
Management estimates the useful life of the Company's Vessels to be 25 years. This is a common life expectancy applied in the shipping industry. If the estimated economic useful life is incorrect, or circumstances change and the estimated economic useful life has to be revised, an impairment loss could result in future periods and/or annual depreciation expense could be increased. Our Vessels are reviewed for impairment whenever events or changes in circumstances indicate that their carrying amount may not be recoverable. Factors we consider important that could affect recoverability and trigger impairment include significant underperformance relative to expected operating results, new regulations that change the estimated useful economic lives of our Vessels and significant negative industry or economic trends.  In assessing the recoverability of the Vessels' carrying amounts when an indicator of impairment is present, we must make assumptions regarding estimated future cash flows. These assumptions include assumptions about the spot market rates for Vessels, the revenues the Vessel could earn under time charter, voyage charter or bareboat charter, the operating costs of our Vessels and the estimated economic useful life of our Vessels. In making these assumptions, the Company refers to historical trends and performance as well as any known future factors. If our review indicates impairment, an impairment charge is recognized based on the difference between carrying value and fair value. Fair value is typically established using an average of three independent valuations.

 
26

 


Factors Affecting Our Results

The principal factors which affect our results of operations and financial position include:

 
the earnings of our vessels in the charter market;
 
 
the delivery of newbuildings in 2009;
 
 
the earnings from the sale of assets;
 
 
vessel operating expenses;
 
 
administrative expenses;
 
 
depreciation; and
 
 
interest expense.
 

Operating costs are the direct costs associated with running a vessel and include crew costs, vessel supplies, repairs and maintenance, drydockings, lubricating oils and insurance. We bear the operating costs for our vessels which operate under time charter.

Administrative expenses are composed of general corporate overhead expenses, including audit fees, directors’ fees and expenses, registrar fees, investor relations and publication expenses, legal and professional fees and other general administrative expenses.

Depreciation, or the periodic cost charged to our income for the reduction in usefulness and long-term value of our vessels, is also related to the number of vessels we own. We depreciate the cost of our vessels, less their estimated residual value, over their estimated useful life on a straight-line basis.

Interest expense depends on our overall borrowing levels and will change with prevailing interest rates, although the effect of these changes may be reduced by interest rate swaps or other derivative instruments. At December 31, 2007, all of our debt was floating rate debt. We may enter into interest rate swap arrangements if we believe it is advantageous to do so.

Inflation
 
Although inflation has had a moderate impact on our vessel operating expenses and corporate overheads, management does not consider inflation to be a significant risk to direct costs in the current and foreseeable economic environment other than potentially in relation to insurance costs and crew costs. It is anticipated that insurance costs, which have risen considerably over the last three years, may well continue to rise over the next few years. Oil transportation is a specialized area and the number of vessels is increasing. There will therefore be an increased demand for qualified crew and this has and will continue to put inflationary pressure on crew costs. However, in a shipping downturn, costs subject to inflation can usually be controlled because shipping companies typically monitor costs to preserve liquidity and encourage suppliers and service providers to lower rates and prices in the event of a downturn.
 
Results of Operations

Year ended December 31, 2007 compared with year ended December 31, 2006

Operating revenues

(in thousands of $)
 
2007
   
2006
   
Change
 
Time charter revenues
    53,814       42,445       26.8 %
Voyage charter revenues
    34,346       63,283       (45.7 )%
Total operating revenues
    88,160       105,728       (16.6 )%


 
27

 

Time charter revenues have increased primarily due to one vessel switching to a time charter from the spot market during the first quarter of 2007.

Voyage charter revenues have decreased due to the lower market in 2007 compared to 2006. We had two vessels operating in the spot market during 2006 at average TCE rates of approximately $63,000 and $60,000 compared with rates of approximately $52,000 and $46,000 for 2007. In addition, one of the vessels operating in the spot market switched to a time charter in the first quarter of 2007.

Operating expenses

(in thousands of $)
 
2007
   
2006
   
Change
 
Voyage expenses and commission
    12,872       20,015       (35.7 )%
Ship operating expenses
    15,544       15,835       (1.8 )%
Administrative expenses
    1,481       1,492       (0.7 )%
Depreciation
    17,016       17,121       (0.6 )%
Total operating expenses
    46,913       54,463       (13.8 )%

91.9% (2006: 93.3%) of voyage expenses and commission relate to the two vessels that operated in the spot market. The decrease in voyage expenses and commission in 2007 is due primarily to the switch by one vessel in the first quarter of 2007 from the spot market to time charter.

The decrease in ship operating expenses in 2007 is a result of lower repairs and maintenance work compared with 2006. No vessels drydocked during 2007. Drydocking costs in 2006 were $0.6 million. This decrease was largely offset by an increase in operating expenses due to increased crew costs.

Gain on sale of assets

(in thousands of $)
 
2007
   
2006
   
Change
 
Gain on sale of assets
    49,119       -       -  

The gain on sale of assets in 2007 relates to the sale of the VLCC Chelsea in December 2007, which was sold for net proceeds of $99.0 million.

Interest income and expenses

(in thousands of $)
 
2007
   
2006
   
Change
 
Interest income
    1,026       1,383       (25.8 )%
Interest expense
    (6,373 )     (6,881 )     (7.4 )%
Net interest expense
    (5,347 )     (5,498 )     (2.7 )%

The decrease in interest income during 2007 is a result of lower interest rates received on short term deposits.

Interest expense consists of interest paid in relation to the $140.0 million loan facility and the amortization of deferred financing charges incurred in connection with the debt. The decrease in interest expense in 2007 is primarily due to the decrease in the three month LIBOR since the beginning of the year from 5.4% to 5.2% and the lower principal amount outstanding. The interest expense on the newbuilding financing of $1.0 million has been capitalized (2006: nil).

Year ended December 31, 2006 compared with year ended December 31, 2005

Operating revenues

(in thousands of $)
 
2006
   
2005
   
Change
 
Time charter revenues
    42,445       42,325       (0.3 )%
Voyage charter revenues
    63,283       57,854       9.4 %
Total operating revenues
    105,728       100,179       5.5 %


 
28

 

The increase in total operating revenues was a result of higher voyage charter revenues in 2006 while time charter revenues were stable. Voyage charter revenues are generated from our vessels trading on the spot market in 2006 and 2005; these vessels participated in a pooling arrangement with two similar vessels since the second quarter of 2005. Under the pooling agreement revenues and voyage expenses of the vessels operating in pooling arrangements are pooled and the resulting net pool revenues, calculated on a time charter equivalent basis, are allocated to the pool participants according to an agreed formula.  Pool revenues of $63.1 million are included in voyage charter revenues for the year ended December 31, 2006 (2005: $36.8 million).  Subsequent to the year end this arrangement was terminated and only one vessel continues to trade in the spot market.

Operating expenses

(in thousands of $)
 
2006
   
2005
   
Change
 
Voyage expenses and commission
    20,015       16,459       21.6 %
Ship operating expenses
    15,835       17,211       (8.0 )%
Administrative expenses
    1,492       988       51.0 %
Depreciation
    17,121       17,120       0.0 %
Total operating expenses
    54,463       51,778       5.2 %

The two vessels that traded in the spot market generated 93.3% in 2006 (2005: 94.1%) of the voyage expenses and commission as substantially all voyage costs associated with time charters are covered by the charterer. The increased voyage expenses in 2006 correlate to the increase in voyage charter revenues. The decrease in ship operating expenses in 2006 is a result of only one vessel drydocking in 2006, whereas four of the five Vessels drydocked in 2005.  The vessels have scheduled drydockings approximately every five years.

The increase in administration costs in 2006 relates primarily to higher fees payable to the Manager for administration services provided of $645,000 (2005: $245,000). The remainder of administration costs for the Company are directors’ fees, directors and officers insurance, shareholder and public relations, management fees and audit fees.

Interest income and expenses

(in thousands of $)
 
2006
   
2005
   
Change
 
Interest income
    1,383       959       44.2 %
Interest expense
    (6,881 )     (5,310 )     29.6 %
Net interest expense
    (5,498 )     (4,351 )     26.4 %

The significant increase in interest income during 2006 is a result of higher interest rates received on short term deposits.

Interest expense consists of interest paid in relation to the $140.0 million loan facility and the amortization of deferred financing charges incurred in connection with the debt. The increase in interest expense in 2006 is primarily due to the rise in the three month LIBOR since the beginning of the year from 4.5% to 5.4%.  Since March 2005, the interest rate is calculated at LIBOR plus 0.7%, previously LIBOR plus 1.0%.


Recently Issued Accounting Standards

In September 2006, the FASB issued SFAS No. 157 “Fair Value Measurements” (“FAS 157”). FAS 157 defines fair value, establishes a framework for measuring fair value in generally accepted accounting principles and expands disclosures about fair value measurements. FAS 157 applies under most other accounting pronouncements that require or permit fair value measurements and does not require any new fair value measurements. FAS 157 is effective for fiscal years beginning after November 15, 2007.

In February 2008, the FASB issued FSP No. FAS157-1 “Application of FASB Statement No. 157 to FASB Statement No. 13 and Other Accounting Pronouncements That Address Fair Value Measurements for Purposes of Lease Classification or Measurement under Statement 13” (“FSP FAS157-1”). FSP FAS157-1 amends FAS 157 to exclude FASB Statement No. 13 “Accounting for Leases” (“FAS 13”) and its related interpretive accounting pronouncements that address leasing transactions. The FASB decided to exclude leasing transactions covered by FAS 13 in order to

 
29

 

allow it to more broadly consider the use of fair value measurements for these transactions as part of its project to comprehensively reconsider the accounting for leasing transactions. The Company does not expect the adoption of FAS 157 and FSP FAS157-1 to have a material impact on its financial statements.

In February 2007, the FASB issued SFAS No. 159 “The Fair Value Option for Financial Assets and Financial Liabilities – including an amendment of FASB  Statement No. 115” (SFAS 159). SFAS 159 permits entities to choose to measure many financial instruments and certain other items at fair value. The objective is to improve financial reporting by providing entities with the opportunity to mitigate volatility in reported earnings caused by measuring related assets and liabilities differently without having to apply complex hedge accounting provisions. SFAS 159 is effective for fiscal years beginning after November 15 2007. The Company does not expect the adoption of SFAS 159 to have a material impact on its financial statements.

In December 2007, the FASB issued SFAS No. 160 “Noncontrolling Interests in Consolidated Financial Statements – an amendment of ARB No. 51” (SFAS 160). SFAS 160 is intended to improve the relevance, comparability and transparency of financial information that a reporting entity provides in its consolidated financial statements with reference to a noncontrolling interest in a subsidiary. Such a noncontrolling interest, sometimes called a minority interest, is the portion of equity in a subsidiary not attributable, directly or indirectly, to the parent entity. SFAS 160 is effective for fiscal years beginning on or after December 15, 2008. The Company does not expect the adoption of SFAS 160 to have a material impact on its financial statements.

In December 2007, the FASB issued SFAS No. 141 (revised 2007) “Business Combinations” (“FAS 141R”). The objective of FAS 141R is to improve the relevance, representational faithfulness and comparability of the information that a reporting entity provides in its financial reports about a business combination and its effects. To accomplish this, FAS 141R establishes principles and requirements for how the acquirer a) recognizes and measures in its financial statements the identifiable assets acquired, the liabilities assumed and any non-controlling interest in the acquiree, b) recognizes and measures the goodwill acquired in the business combination or a gain from a bargain price, and c) determines what information to disclose to enable users of the financial statements to evaluate the nature and financial effects of the business combination. FAS 141R is effective for fiscal years beginning on or after December 15, 2008. The Company does not expect the adoption of FAS 141R to have a material impact on its financial statements.


Liquidity and Capital Resources

The Company operates in a capital intensive industry and has historically financed its purchase of tankers through a combination of equity capital and borrowings from commercial banks. Our ability to generate adequate cash flows on a short and medium term basis depends substantially on the trading performance of our Vessels in the market.  Market rates for charters of our Vessels have historically been volatile.  Periodic adjustments to the supply of and demand for oil tankers cause the industry to be cyclical in nature.

The Company’s funding and treasury activities are conducted within corporate policies to maximize investment returns while maintaining appropriate liquidity for the Company’s requirements. Cash and cash equivalents are held primarily in United States dollars.

Short-term liquidity requirements of the Company relate to servicing our debt, payment of operating costs, funding working capital requirements and maintaining cash reserves against fluctuations in operating cash flows. Sources of short-term liquidity include cash balances, restricted cash balances, short-term investments and receipts from our customers. Revenues from time charters are generally received monthly or bi-weekly in advance while revenues from voyage charters are received upon completion of the voyage.

We estimated the cash breakeven average daily TCE rate in February 2008 for our VLCCs to be $19,410. This represents the daily rate our Vessels must earn to cover payment of budgeted operating costs (including corporate overheads), estimated interest and scheduled loan principal repayments.  These rates do not take into account loan balloon repayments at maturity, which we expect to refinance with new loans. Based on the current strength of the tanker market and the employment status of our Vessels, the Company believes that working capital is sufficient for the Company’s present requirements.


 
30

 

Medium and long-term liquidity requirements of the Company include funding the replacement of vessels through the acquisition of second hand vessels or newbuilding vessels, and the repayment of long-term debt balances.  The Company's sources of capital have been the proceeds of its initial public offering, bank loans and charterhire income. The Company expects that charterhire paid from time charters or voyage charter income in the spot market will be sufficient sources of income for the Company to continue to pay ordinary recurring expenses including installments due on outstanding borrowings under the Loan Agreement. However, there can be no assurance that the Company will be able to pay or refinance its borrowings when the debt becomes due, or that it will not incur extraordinary expenses.

As of December 31, 2007, 2006, and 2005, the Company had cash and cash equivalents of $82.1 million, $8.5 million and $12.6 million, respectively. As of December 31, 2007, 2006, and 2005, the Company had restricted cash of $10.0 million.  The restricted cash balance is a result of a minimum liquidity balance which we are required to maintain at all times in conjunction with the $140.0 million loan facility with the Royal Bank of Scotland.  The cash position at the end of 2007 was significantly higher than the amount usually maintained by us due to the sale in December of one of the Company’s vessels, the Chelsea, which generated net proceeds of $99.0 million. $20.1 million of these proceeds was used in December to partially repay the $140.0 million loan facility.

During the year ended December 31, 2007, we paid total cash dividends of $42.8 million.

Borrowing activities

In March 2004, the Company refinanced its prior debt facility with a $140.0 million credit facility (“Loan”), incurring expenses of $0.01 million on the debt extinguishment. The original repayment schedule was twenty-eight quarterly installments of $2.8 million and a final settlement of $61.6 million. Following the $20.1 million repayment in December 2007, the Company is obligated to repay the Loan in fourteen quarterly installments of $2.2 million and a final installment of $49.3 million.  The Loan provides for payment of interest on the outstanding principal balance of the Loan, quarterly in arrears at the annual rate of LIBOR plus a margin.  The Company has not entered into any interest rate swap agreements in respect to the variable rate on the Loan Agreement. The original credit facility did not have principal installments and was due for repayment in its entirety in August 2004. At the time of entering into the credit facility, the Company entered into an interest rate swap agreement that provided for a fixed rate payment of 6.74% on notional principal of $125.4 million, which matured in August 2004.

During 2007, the Company obtained extension on the Loan with two tranches of $16.8 million each in order to fund the first installments on the two Capesize newbuildings. The tranches are repayable in 2009 and are subject to the same covenants as the original Loan. As of December 31, 2007, the remaining commitments on the newbuilding contracts are $129.6 million, which the Company intends to finance through borrowing against existing assets and its contract back log as well as existing cash resources. Such a financing will not materially affect the Company's dividend capacity during the newbuildings’ construction period. For long-term financing of the assets normal mortgage financing as well as lease financing will be considered. It is not intended that the purchase of the two newbuildings will require any new equity issues.

Although the Company's activities are conducted worldwide, the international shipping industry's functional currency is the United States Dollar and virtually all of the Company's operating revenues and most of its anticipated cash expenses are expected to be denominated in United States Dollars. Accordingly, the Company's operating revenues are not expected to be adversely affected by movements in currency exchange rates or the imposition of currency controls in the jurisdictions in which the vessels operate.

Off-balance sheet arrangements

None

Tabular disclosure of contractual obligations

At December 31 2007, the Company had the following contractual obligations:

   
Payment due by period
 
   
Total
   
Less than one year
   
1-3 years
   
3-5 yearss
   
More than 5 years
 
(In thousands of $)
                             
Long-term debt obligations
    112,000       8,960       51,520       51,520       -  
Newbuilding commitments
    129,600       32,400       97,200       -          
Total contractual cash obligations
    241,600       41,360       148,720       51,520       -  
 
31

Safe Harbor

Matters discussed in this Item 5 include assumptions, expectations, projections, intentions and beliefs about future events. These statements are intended as “forward-looking statements”. We caution that assumptions, expectations, projections, intentions and beliefs about future events may and often do vary from actual results and the differences can be material. Please see “Cautionary Statement Regarding Forward-Looking Statements” in this Report.

ITEM 6.  DIRECTORS, SENIOR MANAGEMENT AND EMPLOYEES

A.  DIRECTORS AND SENIOR MANAGEMENT

Set forth below are the names and positions of the directors and executive officers of the Company.

The Company
 
Name
 
Age
 
Position
Ola Lorentzon
 
58
 
Director and Chairman
Douglas C. Wolcott
 
76
 
Director and Audit Committee member
David M. White
 
67
 
Director and Audit Committee Chairman
Bjørn Sjaastad
 
50
 
Director and Chief Executive Officer
Inger M. Klemp
 
45
 
Chief Financial Officer
Georgina Sousa
 
58
 
Company Secretary

Pursuant to the management agreement with the Company, the Manager provides management and advisory services to the Company.  Set forth below are the names and positions of the directors, executive officers and officers of the Manager.

Name
 
Age
 
Position
Inger M. Klemp
 
45
 
Director and President
Kate Blankenship
 
43
 
Director
Graham Baker
 
48
 
Director
 
Directors of both the Company and the Manager are elected annually, and each director elected holds office until a successor is elected.  Officers of both the Company and the Manager are elected from time to time by vote of the respective board of directors and hold office until a successor is elected.  Certain biographical information with respect to each director and executive officer of the Company and the Manager is set forth below.

Ola Lorentzon has been a director of the Company since September 18, 1996 and Chairman since May 26, 2000.  Mr. Lorentzon is also a director of Erik Thun AB, Crew Chart Ship Management AB, Remedial (Cyprus) PLC and is the Chairman of Consafe MSV AB.  Mr. Lorentzon was the Managing Director of Frontline Management AS, a subsidiary of Frontline, from April 2000 until September 2003.

Douglas C. Wolcott has been a director of the Company since September 18, 1996.  Mr. Wolcott has also served as President of Chevron Shipping Corporation until 1994.  Mr. Wolcott previously served as Deputy Chairman and director of the United Kingdom Protection and Indemnity Club and as a director of London & Overseas Freighters Limited.  He is currently a director of the American Bureau of Shipping.

David M. White has been a director of the Company since September 18, 1996.  Mr. White was Chairman of Dan White Investment Limited which is now closed.  Mr. White has also served as a director of NatWest Equity Primary

 
32

 

Markets Limited from January 1992 to March 1996, and was previously a director of both NatWest Markets Corporate Finance Limited and NatWest Markets Securities Limited until December 1991.

Bjørn Sjaastad has been a director of the Company since September 2007 and has served as our Chief Executive Officer since September 2007. Mr. Sjaastad has served as Chief Executive Officer of Frontline Management A.S. since October 2006.  From 2004 to 2006 Mr. Sjaastad ran his own consultancy business.  From 1990 to 2004, Mr. Sjaastad was the Chief Executive Officer of Odfjell ASA, a Norwegian based, stock listed, international chemical tanker operator.  From 1981 to 1989 Mr. Sjaastad served as a lending officer of DnB NOR ASA (previously Bergen Bank AS), heading up the banks shipping and offshore department in Bergen.  Mr. Sjaastad has, over the years, been a member of the boards of a range of companies and has also been the President of the Norwegian Shipowners Association. Mr. Sjaastad resigned as Chief Executive Officer on Frontline Management AS on April 2, 2008 and is expected to leave the company before the end of June 2008.

Inger M. Klemp has served as Chief Financial Officer of the Company since September 2007. Mrs. Klemp has served as Chief Financial Officer of Frontline Management AS and has been a director of the Manager since June 1, 2006. Mrs. Klemp served as Vice President Finance from August 2001 until she was promoted in May 2006. Mrs. Klemp graduated as MSc in Business and Economics from the Norwegian School of Management (BI) in 1986. Mrs. Klemp served as Assistant Director Finance in Color Group ASA from 1998 to 2001 and as Group Financial Manager in Color Line ASA from 1992 to 1998, a Norwegian based cruise operator which was stock exchange listed until October 1999. From 1989 to 1992 Mrs. Klemp served as Assistant Vice President in Nordea Bank Norge ASA handling structuring and syndication of loan facilities in the international banking market. From 1986 to 1989, Mrs. Klemp served as a lending officer of Fokus Bank ASA.

Kate Blankenship was Chief Financial Officer of the Company from April 2000 to September 2007 and served as Secretary of the Company from December 2000 to March 2007. Mrs. Blankenship has been a director of the Manager since March 2000. Mrs. Blankenship served as the Chief Accounting Officer and Secretary of Frontline between 1994 and October 2005. Mrs. Blankenship also serves as a director of Golar LNG Limited, Ship Finance International Limited, Seadrill Limited and Golden Ocean Group Limited.

Graham Baker has been a director of the Manager since December 6, 2006. Mr Baker is Chief Accounting Officer of Frontline having joined the company in July 2006. Mr Baker has worked in various senior financial roles and most recently was the Head of Group Reporting at NTL Inc., a large NASDAQ quoted company and before that the European Chief Financial Officer of DVI Inc., a NYSE listed group. He is a member of the Institute of Chartered Accountants in England and Wales and the Association of Corporate Treasurers.

Georgina E. Sousa has served as Secretary of the Company since March 15, 2007 and has been employed by Frontline since February 2007.  Prior to joining Frontline, Mrs. Sousa was Vice-President-Corporate Services of Consolidated Services Limited, a Bermuda management company having joined that firm in 1993 as Manager of Corporate Administration.  From 1976 to 1982 she was employed by the Bermuda law firm of Appleby, Spurling & Kempe as a Company Secretary and from 1982 to 1993 she was employed by the Bermuda law firm of Cox & Wilkinson as Senior Company Secretary.


B.  COMPENSATION

The Company incurred directors’ fees of $256,000 in 2007. No separate compensation was paid to the Company's officers.

C.  BOARD PRACTICES

As provided in the Company's bye-laws, each Director shall hold office until the next Annual General Meeting following his election or until his successor is elected.  The Officers of the Company are elected by the Board of Directors as soon as possible following each Annual General Meeting and shall hold office for such period and on such terms as the Board may determine.

The Company has established an audit committee comprised of Messrs. White and Wolcott, independent directors of the Company.

 
33

 

Board practices and exemptions from NASDAQ corporate governance rules

We have certified to NASDAQ that our corporate governance practices are in compliance with, and are not prohibited by, the laws of Bermuda. Therefore, we are exempt from many of NASDAQ's corporate governance practices other than the requirements regarding the disclosure of a going concern audit opinion, submission of a listing agreement, notification of material non-compliance with NASDAQ corporate governance practices and the establishment and composition of an audit committee and a formal written audit committee charter. The practices that we follow in lieu of NASDAQ's corporate governance rules are as follows:

 
Our board of directors is currently comprised by a majority of independent directors.  Under Bermuda law, we are not required to have a majority of independent directors and cannot assure you that we will continue to do so.

 
In lieu of holding regular meetings at which only independent directors are present, our entire board of directors may hold regular meetings as is consistent with Bermuda law.

 
In lieu of an audit committee comprised of three independent directors, our audit committee has two members, which is consistent with Bermuda law.  Both members of the audit committee currently meet the NASDAQ requirement of independence.

 
In lieu of a nomination committee comprised of independent directors, our board of directors is responsible for identifying and recommending potential candidates to become board members and recommending directors for appointment to board committees. There is nothing to prohibit Shareholders identifying and recommending potential candidates to become board members, but pursuant to the bye-laws, directors are elected by the shareholders in duly convened annual or special general meetings.

 
In lieu of a compensation committee comprised of independent directors, our board of directors is responsible for establishing the executive officers’ compensation and benefits. Under Bermuda law, compensation of the executive officers is not required to be determined by an independent committee.

 
In lieu of obtaining an independent review of related party transactions for conflicts of interests, consistent with Bermuda law requirements, our bye-laws do not prohibit any director from being a party to, or otherwise interested in, any transaction or arrangement with the Company or in which the Company is otherwise interested, provided that the director makes proper disclosure of same as required by the bye-laws and Bermuda law.

 
Prior to the issuance of securities, we are required to obtain the consent of the Bermuda Monetary Authority as required by law. We have obtained blanket consent from the Bermuda Monetary Authority for the issue and transfer of the Company’s securities provided that such securities remain listed.

 
Pursuant to NASDAQ corporate governance rules and as a foreign private issuer, we are not required to solicit proxies or provide proxy statements to NASDAQ. Bermuda law does not require that we solicit proxies or provide proxy statements to NASDAQ. Consistent with Bermuda law and as provided in our bye-laws, we are also required to notify our shareholders of meetings no less than 5 days before the meeting.  Our bye-laws also provide that shareholders may designate a proxy to act on their behalf.

Other than as noted above, we are in full compliance with all other applicable NASDAQ corporate governance standards.

D.  EMPLOYEES

The Company has not had any employees since inception as the Manager is responsible for the management and administration of the Company.

E.  SHARE OWNERSHIP

As of March 31, 2008, none of the directors or officers of the Company owned any Common Shares of the Company.

 
34

 
ITEM 7.  MAJOR SHAREHOLDERS AND RELATED PARTY TRANSACTIONS

A.  MAJOR SHAREHOLDERS

The Company is not directly or indirectly controlled by another corporation, by a foreign government or by any other natural or legal person. We are not aware of any arrangements, the operation of which may at a subsequent date result in a change in control of the Company.

The Company is not aware of any person who owns more than five percent of the Company’s outstanding common shares as of March 31, 2008.

B.  RELATED PARTY TRANSACTIONS

None

C.  INTERESTS OF EXPERTS AND COUNSEL

Not Applicable

ITEM 8. FINANCIAL INFORMATION

A.  CONSOLIDATED STATEMENTS AND OTHER FINANCIAL INFORMATION

See Item 18.

Legal Proceedings

To the best of the Company's knowledge, there are no legal or arbitration proceedings existing or pending which have had or may have significant effects on the Company's financial position or profitability and no such proceedings are pending or known to be contemplated by governmental authorities.

Dividend Policy

The Company's policy is to make distributions to shareholders based on the Company's earnings and cash flow. The amount and timing of dividends will depend on the Company's earnings, financial condition, cash position, Bermuda law affecting the payment of distributions and other factors. There will be no guaranteed minimum and the Company may not be able to make distributions in quarters where the earnings are low and where cash flow is insufficient. The Company's financing may also restrict distributions in certain circumstances.

In 2007, 2006 and 2005, the Company paid the following distributions to shareholders.

Record Date
Payment Date
Amount per share
2007
   
February 26, 2007
March  9, 2007
$0.80
May 26, 2007
June 11, 2007
$0.60
August 23, 2007
September 7, 2007
$0.60
November 23, 2007
December 7, 2007
$0.50
     
2006
   
February 23, 2006
March  9, 2006
$0.80
May 29, 2006
June 12, 2006
$1.00
August 25, 2006
September 8, 2006
$0.80
November 27, 2006
December 7, 2006
$1.00
     
2005
   
February 25, 2005
March 11, 2005
$1.75
May 19, 2005
June 1, 2005
$1.50
August 26, 2005
September 6, 2005
$0.80
November 21, 2005
December 5, 2005
$0.50
 
On February 13, 2008 the Board declared a cash dividend of $0.75 per share for the fourth quarter of 2007 that was paid on March 6, 2008.
 
35

 

B.  SIGNIFICANT CHANGES

Not applicable

ITEM 9.  THE OFFER AND LISTING

Not applicable except for Item 9.A.4 and Item 9.C.

The following table sets forth, for the five most recent fiscal years during which the Company's Common Shares were traded on the NASDAQ National Market, the annual high and low closing prices for the Common Shares as reported by the NASDAQ National Market.

Fiscal year ended December 31
 
 
High
   
Low
 
2007
 
$
34.00    
$
23.01  
2006
 
$
30.78    
$
20.42  
2005
 
$
47.50    
$
23.76  
2004
 
$
39.25    
$
12.52  
2003
 
$
17.56    
$
8.45  
2002
 
$
18.85    
$
11.51  

The following table sets forth, for the two most recent fiscal years, the high and low closing prices for the Common Shares as reported by the NASDAQ National Market.

Fiscal year ended December 31, 2007
 
 
High
   
Low
 
First quarter
 
$
27.94    
$
23.01  
Second quarter
 
$
34.00    
$
27.00  
Third quarter
 
$
33.00    
$
23.25  
Fourth quarter
 
$
27.75    
$
23.01  

Fiscal year ended December 31, 2006
 
 
High
   
Low
 
First quarter
 
$
27.87    
$
24.03  
Second quarter
 
$
28.23    
$
20.42  
Third quarter
 
$
30.78    
$
24.53  
Fourth quarter
 
$
28.57    
$
22.48  


The following table sets forth, for the most recent six months, the high and low closing prices for the Common Shares as reported by the NASDAQ National Market.

Month
 
 
High
   
Low
 
March 2008
 
$
27.20    
$
23.64  
February 2008
 
$
28.79    
$
25.00  
January 2008
 
$
26.49    
$
20.25  
December 2007
 
$
27.25    
$
23.54  
November 2007
 
$
26.00    
$
23.01  
October 2007
 
$
27.75    
$
24.50  


The Company's Common Shares have been quoted on the NASDAQ National Market under the symbol “VLCCF” since its initial public offering in February 1997.

 
36

 

ITEM 10.  ADDITIONAL INFORMATION

A.  SHARE CAPITAL

Not Applicable

B.  MEMORANDUM AND ARTICLES OF ASSOCIATION

Incorporated by reference to “Description of Capital Stock” in the prospectus contained in the Company's Registration Statement on Form F-1, filed December 13, 1996 (File No. 333-6170).

At the 2005 Annual General Meeting of the Company the shareholders voted to amend the Company’s bye-laws 83 and 85 by removing the restrictions that limited the Company’s business activities.  The changes to the bye-laws removed restrictions on the Company’s activities such as rechartering the Vessels, refinancing or replacing the credit facility, acting in connection with the management agreement, offering Common Shares and listing them, enforcing its rights in connection with the Charters, the Credit Facility, the UK Finance Leases, the management agreement and other agreements into which the Company and its subsidiaries entered at the time of its initial public offering, and leasing, selling or otherwise disposing of the Vessels (or Vessel owning subsidiaries) on termination of the Charters or subsequent charters. The amended bye-laws of the Company as adopted on June 27, 2005, have been filed as Exhibit 4.2 to the Company’s Annual Report on Form 20-F for the fiscal year ended December 31, 2005, filed with Securities and Exchange Commission on June 15, 2006, and are hereby incorporated by reference into this Annual Report.

C.  MATERIAL CONTRACTS

The Company announced in May 2007, that it had agreed to purchase two newbuilding contracts, each for a Capesize bulk carrier of approximately 170,000 dwt. The ships will be built at Daehan Shipbuilding Co. Ltd in the Republic of Korea with delivery scheduled for 2009. The newbuilding contracts have been acquired from Golden Ocean Group Limited (“GOGL”) which company has ordered a series of sister ships at the same yard. The contract price for the two vessels is $81 million per vessel. In addition, the Company will pay a 1% commission to GOGL for arranging the deal. GOGL is listed on the Oslo Stock Exchange and is an affiliate of Frontline, the parent company of the Manager. The supervision of the ships' construction will be carried out by Frontline Management (Bermuda) Ltd. and the commercial operation will be contracted to Golden Ocean Management AS, a subsidiary of GOGL that operates the GOGL fleet.

D.  EXCHANGE CONTROLS

The Company is classified by the Bermuda Monetary Authority as a non-resident of Bermuda for exchange control purposes.

The transfer of Ordinary Shares between persons regarded as resident outside Bermuda for exchange control purposes may be effected without specific consent under the Exchange Control Act of 1972 and regulations there under and the issuance of Ordinary Shares to persons regarded as resident outside Bermuda for exchange control purposes may be effected without specific consent under the Exchange Control Act of 1972 and regulations there under. Issues and transfers of Ordinary Shares involving any person regarded as resident in Bermuda for exchange control purposes require specific prior approval under the Exchange Control Act of 1972.

The owners of Ordinary Shares who are ordinarily resident outside Bermuda are not subject to any restrictions on their rights to hold or vote their shares. Because the Company has been designated as a non-resident for Bermuda exchange control purposes, there are no restrictions on its ability to transfer funds in and out of Bermuda or to pay dividends to U.S. residents who are holders of Ordinary Shares, other than in respect of local Bermuda currency.

E.  TAXATION

United States Taxation

The following discussion is based upon the provisions of the U.S. Internal Revenue Code of 1986, as amended (the “Code”), existing and proposed U.S. Treasury Department regulations, administrative rulings, pronouncements and

 
37

 

judicial decisions, all as of the date of this Annual Report.  Unless otherwise noted, references to the “Company” include the Company’s Subsidiaries.  This discussion assumes that we do not have an office or other fixed place of business in the United States.

Taxation of the Company’s Shipping Income: In General
The Company anticipates that it will derive substantially all of its gross income from the use and operation of vessels in international commerce and that this income will principally consist of freights from the transportation of cargoes, hire or lease from time or voyage charters and the performance of services directly related thereto, which the Company refers to as “shipping income.”

Shipping income that is attributable to transportation that begins or ends, but that does not both begin and end, in the United States will be considered to be 50% derived from sources within the United States.  Shipping income attributable to transportation that both begins and ends in the United States will be considered to be 100% derived from sources within the United States.  The Company is not permitted by law to engage in transportation that gives rise to 100 percent United States source income.

Shipping income attributable to transportation exclusively between non-U.S. ports will be considered to be 100% derived from sources outside the United States.  Shipping income derived from sources outside the United States will not be subject to U.S. federal income tax.

Based upon the Company’s anticipated shipping operations, the Company’s vessels will operate in various parts of the world, including to or from U.S. ports.  Unless exempt from U.S. taxation under Section 883 of the Code (“Section 883”), the Company will be subject to U.S. federal income taxation, in the manner discussed below, to the extent its shipping income is considered derived from sources within the United States.
 
Application of Code Section 883

Under the relevant provisions of Section 883, the Company will be exempt from U.S. taxation on its U.S. source shipping income if:
 
 
(i)
 
It is organized in a qualified foreign country which is one that grants an equivalent exemption from tax to corporations organized in the United States in respect of the shipping income for which exemption is being claimed under Section 883 (a “qualified foreign country”) and which the Company refers to as the “country of organization requirement”; and
 
 
(ii)
It can satisfy any one of the following two stock ownership requirements for more than half the days during the taxable year:
 
 
the Company’s stock is “primarily and regularly” traded on an established securities market located in the United States or a qualified foreign country, which the Company refers to as the “Publicly-Traded Test”; or
 
 
more than 50% of the Company’s stock, in terms of value, is beneficially owned by any combination of one or more individuals who are residents of a qualified foreign country or foreign corporations that satisfy the country of organization requirement and the Publicly-Traded Test, which the Company refers to as the “50% Ownership Test.”

The U.S. Treasury Department has recognized Bermuda, the country of incorporation of the Company and certain of its subsidiaries, as a qualified foreign country.  In addition, the U.S. Treasury Department has recognized Liberia, the country of incorporation of the Company’s subsidiaries, as qualified foreign countries.  Accordingly, the Company and its vessel owning subsidiaries satisfy the country of organization requirement.

Therefore, the Company’s eligibility to qualify for exemption under Section 883 is wholly dependent upon being able to satisfy one of the stock ownership requirements.

For the 2007 tax year, the Company satisfied the Publicly-Traded Test since, on more than half the days of the taxable year, the Company’s stock was primarily and regularly traded on the NASDAQ National Market.
 

 
38

 
Taxation in Absence of Internal Revenue Code Section 883 Exemption

To the extent the benefits of Section 883 are unavailable with respect to any item of U.S. source income, the Company’s U.S. source shipping income, would be subject to a 4% tax imposed by Section 887 of the Code on a gross basis, without the benefit of deductions.  Since under the sourcing rules described above, no more than 50% of the Company’s shipping income would be treated as being derived from U.S. sources, the maximum effective rate of U.S. federal income tax on the Company’s shipping income would never exceed 2% under the 4% gross basis tax regime.

Gain on Sale of Vessels

Regardless of whether the Company qualifies for exemption under Section 883, the Company will not be subject to United States federal income taxation with respect to gain realized on a sale of a vessel, provided the sale is considered to occur outside of the United States under United States federal income tax principles.  In general, a sale of a vessel will be considered to occur outside of the United States for this purpose if title to the vessel, and risk of loss with respect to the vessel, pass to the buyer outside of the United States.  It is expected that any sale of a vessel by the Company will be considered to occur outside of the United States.

Taxation of U.S. Holders
 
The following is a discussion of the material United States federal income tax considerations relevant to an investment decision by a U.S. Holder, as defined below, with respect to the common stock.  This discussion does not purport to deal with the tax consequences of owning common stock to all categories of investors, some of which may be subject to special rules.  You are encouraged to consult your own tax advisors concerning the overall tax consequences arising in your own particular situation under United States federal, state, local or foreign law of the ownership of common stock.
 
As used herein, the term “U.S. Holder” means a beneficial owner of the Company’s common stock that (i) is a U.S. citizen or resident, a U.S. corporation or other U.S. entity taxable as a corporation, an estate, the income of which is subject to U.S. federal income taxation regardless of its source, or a trust if a court within the United States is able to exercise primary jurisdiction over the administration of the trust and one or more U.S. persons have the authority to control all substantial decisions of the trust and (ii) owns the common stock as a capital asset, generally, for investment purposes.
 
If a partnership holds the common stock, the tax treatment of a partner will generally depend upon the status of the partner and upon the activities of the partnership.  If you are a partner in a partnership holding the common stock, you are encouraged consult your own tax advisor on this issue.
 
Distributions
 
Subject to the discussion of passive foreign investment companies below, any distributions made by the Company with respect to the common stock to a U.S. Holder will generally constitute dividends, which may be taxable as ordinary income or “qualified dividend income” as described in more detail below, to the extent of the Company’s current or accumulated earnings and profits, as determined under United States federal income tax principles.  Distributions in excess of the Company’s earnings and profits will be treated first as a non-taxable return of capital to the extent of the U.S. Holder’s tax basis in his common stock on a dollar-for-dollar basis and thereafter as capital gain.  Because the Company is not a United States corporation, U.S. Holders that are corporations will not be entitled to claim a dividends-received deduction with respect to any distributions they receive from the Company.
 
Dividends paid by the Company to a United States Holder which is an individual, trust, or estate (a “U.S. Non-Corporate Holder”) will generally be treated as “qualified dividend income” that is taxable to such shareholders at preferential United States federal income tax rates (currently through 2010) provided that (1) the common stock is readily tradable on an established securities market in the United States (such as the NASDAQ National Market on which the common stock is traded); (2) the Company not a passive foreign investment company (a “PFIC”) for the taxable year during which the dividend is paid or the immediately preceding taxable year (as discussed in more detail below); and (3) the U.S. Non-Corporate Holder has owned the common stock for more than 60 days in the 121-day period beginning 60 days before the date on which the common stock becomes ex-dividend.  The Company was a PFIC for United States federal income tax purposes through its 2003 taxable year.  Beginning with its 2004 taxable year, the Company ceased to be a PFIC as a result of the expiration of the Shell International charters on

 
39

 

February 27, 2004.  The Company was not a PFIC for United States federal income tax purposes in the 2007 taxable year and does not anticipate being a PFIC in future years, although there is no assurance that this will be the case.

Legislation has been recently introduced in the United States Congress which, if enacted, would preclude dividends paid by the Company from qualifying for such preferential rates prospectively from the date of the enactment. Any dividends paid by the Company which are not eligible for these preferential rates will be taxed as ordinary income to a United States shareholder.

 
Sale, Exchange or other Disposition of Common Stock
 
Subject to the discussion of PFIC status below, a U.S. Holder generally will recognize taxable gain or loss upon a sale, exchange or other disposition of the common stock in an amount equal to the difference between the amount realized by the U.S. Holder from such sale, exchange or other disposition and the U.S. Holder’s tax basis in such stock.  Such gain or loss will be treated as long-term capital gain or loss if the U.S. Holder’s holding period in the common stock is greater than one year at the time of the sale, exchange or other disposition.  A U.S. Holder’s ability to deduct capital losses is subject to certain limitations.
 
Passive Foreign Investment Company Status and Significant Tax Consequences
 
Special United States federal income tax rules apply to a U.S. Holder that holds stock in a foreign corporation classified as a passive foreign investment company, or a PFIC, for United States federal income tax purposes.  In general, the Company will be treated as a PFIC with respect to a U.S. Holder if, for any taxable year in which such holder held the common stock, either
 
 
at least 75% of the Company’s gross income for such taxable year consists of passive income (e.g., dividends, interest, capital gains and rents derived other than in the active conduct of a rental business), or
 
 
at least 50% of the average value of the assets held by the Company during such taxable year produce, or are held for the production of, passive income.
 
For purposes of determining whether the Company is treated as a PFIC, the Company will be treated as earning and owning its proportionate share of the income and assets, respectively, of any of its subsidiary corporations in which it owns at least 25% of the value of the subsidiary’s stock.  Income earned, or deemed earned, by the Company in connection with the performance of services would not constitute passive income.  By contrast, rental income would generally constitute “passive income” unless the Company were treated under specific rules as deriving its rental income in the active conduct of a trade or business.
 
Based on the Company’s current operations and future projections, the Company does not believe that it is, nor does it expect to become, a PFIC with respect to any taxable year.  Although there is no legal authority directly on point and therefore the IRS or a court could disagree with the Company’s position, the Company’s belief is based principally on the position that, for purposes of determining whether the Company is a PFIC, the gross income the Company derives or is deemed to derive from the time chartering and voyage chartering activities of its wholly-owned subsidiaries should constitute services income, rather than rental income.  Correspondingly, the Company believes that such income does not constitute passive income, and the assets that the Company or its wholly-owned subsidiaries own and operate in connection with the production of such income, in particular, the vessels, do not constitute passive assets for purposes of determining whether the Company is a PFIC.
 
If the Company were to be treated as a PFIC, special and adverse United States federal income tax rules would apply to a U.S. Holder of the common stock.  Among other things, the distributions a U.S. Holder received with respect to the Common Stock and the gain, if any, a U.S. Holder derived from his sale or other disposition of the common stock would be taxable as ordinary income (rather than as qualified dividend income or capital gain, as the case may be), would be treated as realized ratably over his holding period in the common stock, and would be subject to an additional interest charge.  However, a U.S. Holder may be able to make certain tax elections which ameliorate these consequences.
 
As described above, the Company was a PFIC for United States federal income tax purposes through its 2003 taxable year.  The Company has not been a PFIC beginning with its 2004 taxable year.  Shareholders who held the
 

 
40

 
Company’s common stock prior to the 2004 taxable year are encouraged to consult their tax advisors regarding the proper tax treatment of any dispositions of common stock and any distributions by the Company.
 
Bermuda Taxation
 
Bermuda currently imposes no tax  (including a tax in the nature of an income, estate  duty,  inheritance,  capital  transfer or  withholding  tax) on profits, income,  capital  gains or  appreciations  derived  by,  or  dividends  or other distributions paid to U.S. Shareholders of common shares. Bermuda has undertaken not to impose any such Bermuda taxes on U.S. Shareholders of common chares prior to the year 2016 except in so far as such tax applies to persons ordinarily resident in Bermuda.
 
Liberian Taxation
 
The Republic of Liberia enacted a new income tax act effective as of January 1, 2001 (the “New Act”).  In contrast to the income tax law previously in effect since 1977 (the “Prior Law”), which the New Act repealed in its entirety, the New Act does not distinguish between the taxation of a non-resident Liberian corporation, such as the Company’s Liberian subsidiaries, which conduct no business in Liberia and were wholly exempted from tax under the Prior Law, and the taxation of ordinary resident Liberian corporations.
 
In 2004, the Liberian Ministry of Finance issued regulations pursuant to which a non-resident domestic corporation engaged in international shipping, such as the Company’s Liberian subsidiaries, will not be subject to tax under the New Act retroactive to January 1, 2001 (the “New Regulations”).  In addition, the Liberian Ministry of Justice issued an opinion that the New Regulations were a valid exercise of the regulatory authority of the Ministry of Finance.  Therefore, assuming that the New Regulations are valid, the Company’s Liberian subsidiaries will be wholly exempt from Liberian income tax as under the Prior Law.
 
If the Company’s Liberian subsidiaries were subject to Liberian income tax under the New Act, the Company’s Liberian subsidiaries would be subject to tax at a rate of 35% on their worldwide income.  As a result, their, and subsequently the Company’s, net income and cash flow would be materially reduced by the amount of the applicable tax.  In addition, the Company, as shareholder of the Liberian subsidiaries, would be subject to Liberian withholding tax on dividends paid by the Liberian subsidiaries at rates ranging from 15% to 20%.
 
F.  DIVIDENDS AND PAYING AGENTS

Not Applicable

G.  STATEMENT BY EXPERTS

Not Applicable

H.  DOCUMENTS ON DISPLAY

The Company is subject to the informational requirements of the Securities Exchange Act of 1934, as amended. In accordance with these requirements we file reports and other information with the Securities and Exchange Commission. These materials, including this annual report and the accompanying exhibits may be inspected and copied at the public reference facilities maintained by the Commission at 100 F Street, N.E., Room 1580, Washington, D.C. 20549 and at 500 West Madison Street, Suite 1400, Northwestern Atrium Center, Chicago, Illinois 60661 and are also available on our website located at www.knightsbridgetankers.com.  You may obtain information on the operation of the public reference room by calling 1 (800) SEC-0330, and you may obtain copies at prescribed rates from the Public Reference Section of the Commission at its principal office in Washington, D.C. 20549.  The SEC maintains a website (http://www.sec.gov.) that contains reports, proxy and information statements and other information regarding registrants that file electronically with the SEC.  In addition, documents referred to in this annual report may be inspected at the Company's headquarters at Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton, Bermuda.

 
41

 

I.  SUBSIDIARY INFORMATION

Not Applicable

ITEM 11.  QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

The Company is exposed to market risk from changes in interest rates primarily resulting from the floating rate of the Company's borrowings.  The Company does not currently utilise interest rate swaps to manage such interest rate risk.  The Company has not entered into any financial instruments for speculative or trading purposes.

The Company's borrowings under its loan facility at December 31, 2007 of $112.0 million (December 31, 2006: $109.2 million) bear interest at an annual rate of LIBOR plus a margin of 0.7%. A one percent change in interest rates would increase or decrease interest expense by $1.1 million per year as of December 31, 2007. The fair value of the loan facility at December 31, 2007 was equal to the carrying amount of the facility at the same date.

ITEM 12.  DESCRIPTION OF SECURITIES OTHER THAN EQUITY SECURITIES

Not Applicable

 
42

 

PART II

ITEM 13.  DEFAULTS, DIVIDEND ARREARAGES AND DELINQUENCIES

Neither we nor any of our subsidiaries have been subject to a material default in the payment of principal, interest, a sinking fund or purchase fund installment or any other material default that was not cured within 30 days. In addition, the payment of our dividends is not, and has not been in arrears or has not been subject to a material delinquency that was not cured within 30 days.

ITEM 14.  MATERIAL MODIFICATIONS TO THE RIGHTS OF SECURITY HOLDERS AND USE OF PROCEEDS

Not Applicable

ITEM 15.  CONTROLS AND PROCEDURES

a)           Disclosure Controls and Procedures
 
Management assessed the effectiveness of the design and operation of the Company’s disclosure controls and procedures pursuant to Rule 13a-15(e) of the Securities Exchange Act of 1934, as of the end of the period covered by this annual report as of December 31, 2007. Based upon that evaluation, the Principal Executive Officer and Principal Financial Officer concluded that the Company’s disclosure controls and procedures are effective as of the evaluation date.
 
b)           Management’s annual report on internal controls over financial reporting
 
Our management is responsible for establishing and maintaining adequate internal control over financial reporting as defined in Rules 13a-15(f) promulgated under the Securities Exchange Act of 1934.
 
Internal control over financial reporting is defined in Rule 13a-15(f) or 15d-15(f) promulgated under the Securities Exchange Act of 1934 as a process designed by, or under the supervision of, the Company’s principal executive and principal financial officers and effected by the Company’s board of directors, management and other personnel, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles and includes those policies and procedures that:
 
 
Pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the Company;
 
 
Provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that our receipts and expenditures are being made only in accordance with authorizations of Company’s management and directors; and
 
 
Provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of our assets that could have a material effect on the financial statements.
 
Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree or compliance with the policies or procedures may deteriorate.
 
Management conducted the evaluation of the effectiveness of the internal controls over financial reporting using the control criteria framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO) published in its report entitled Internal Control-Integrated Framework.
 
Our management with the participation of our Principal Executive Officer and Principal Financial Officer assessed the effectiveness of the design and operation of the Company’s internal controls over financial reporting pursuant to Rule 13a-15 of the Securities Exchange Act of 1934, as of December 31, 2007. Based upon that evaluation, the Principal Executive Officer and Principal Financial Officer concluded that the Company’s internal controls over financial reporting are effective as of December 31, 2007.

 
43

 
The effectiveness of the Company’s internal control over financial reporting as of December 31 2007 has been audited by Moore Stephens, P.C., an independent registered public accounting firm, as stated in their report which appears herein.
 
c)           Changes in internal control over financial reporting
 
There were no changes in our internal controls over financial reporting that occurred during the period covered by this annual report that have materially effected or are reasonably likely to materially affect, the Company’s internal control over financial reporting

ITEM 16 A. AUDIT COMMITTEE FINANCIAL EXPERT

The Company’s Board of Directors has determined that the Company’s Audit Committee has one Audit Committee Financial Expert. Mr. David White is an independent director and is the Audit Committee Financial Expert.

ITEM 16 B. CODE OF ETHICS

The Company has adopted a Code of Ethics that applies to all entities controlled by the Company and all employees, directors, officers and agents of the Company, including representatives and agents of the Company’s manager, ICB Shipping (Bermuda) Limited. The Code of Ethics has previously been filed as Exhibit 11.1 to the Company’s Annual Report on Form 20-F for the fiscal year ended December 31 2003, filed with the Securities and Exchange Commission on June 2, 2004, and is hereby incorporated by reference into this Annual Report.

The Company has posted a copy of its Code of Ethics on its website at www.knightsbridgetankers.com. The Company will provide any person, free of charge, a copy of its Code of Ethics upon written request to the Company’s registered office.

ITEM 16 C. PRINCIPAL ACCOUNTANT FEES AND SERVICES

Our independent registered public accounting firm for 2007 and 2006 was Moore Stephens, P.C. The following table sets forth for the two most recent fiscal years the fees paid or accrued for audit and services provided by Moore Stephens, P.C.

(in $)
 
2007
   
2006
 
             
Audit Fees (a)
    200,000       120,000  
Audit-Related Fees (b)
    -       -  
Tax Fees (c)
    -       2,900  
All Other Fees (d)
    4,600       3,000  
Total
    204,600       125,900  

(a)
Audit Fees
Audit fees represent professional services rendered for the audit of the Company’s annual financial statements and services provided by our independent registered public accounting firm in connection with statutory and regulatory filings or engagements.

(b)
Audit Related Fees
Audit-related fees consisted of assurance and related services rendered by our independent registered public accounting firm related to the performance of the audit or review of the Company’s financial statements which have not been reported under Audit Fees above.

 
44

 

(c)
Tax Fees
Tax fees represent fees for professional services rendered by our independent registered public accounting firm for tax compliance, tax advice and tax planning.

(d)
All Other Fees
All other fees include services other than audit fees, audit-related fees and tax fees set forth above.

The Company’s Audit Committee has adopted pre-approval policies and procedures in compliance with paragraph (c) (7)(i) of Rule 2-01 of Regulation S-X that require the Audit Committee to approve the appointment of the independent auditor of the Company before such auditor is engaged and approve each of the audit and non-audit related services to be provided by such auditor under such engagement by the Company.   All services provided by our independent registered public accounting firm in 2007 were approved by the Audit Committee pursuant to the pre-approval policy.

ITEM 16 D. EXEMPTIONS FROM THE LISTING STANDARDS FOR AUDIT COMMITTEES

Not applicable

ITEM 16 E. PURCHASE OF EQUITY SECURITIES BY THE ISSUER AND AFFILIATED PURCHASERS

Not Applicable

 
45

 
PART III

ITEM 17.  FINANCIAL STATEMENTS

Not Applicable
 
ITEM 18.  FINANCIAL STATEMENTS

The following financial statements listed below and set forth on pages F-1 through F-12 are filed as part of this annual report:

Consolidated Financial Statements of Knightsbridge Tankers Limited

Index to Consolidated Financial Statements of Knightsbridge Tankers Limited
 
F-1
     
Report of Independent Registered Public Accounting Firm
 
F-2
     
Consolidated Statements of Operations for the years ended December 31, 2007, 2006 and 2005
 
F-3
     
Consolidated Balance Sheets as of December 31, 2007 and 2006
 
F-4
     
Consolidated Statements of Cash Flows for the years ended December 31, 2007, 2006 and 2005
 
F-5
     
Consolidated Statements of Changes in Stockholders' Equity for the years ended
 
F-6
December 31, 2007, 2006 and 2005
   
     
Notes to Consolidated Financial Statements
 
F-7
     

ITEM 19.  EXHIBITS

Number
 Description of Exhibit

1.1
Memorandum of Association of the Company. *
 
1.2
Amended Bye-Laws of the Company. **
 
4.1
Form of Shipbuilding Contract.
 
8.1
List of subsidiaries of the Company.
 
11.1
Code of Ethics.***
 
12.1
Certification of the Principal Executive Officer.
 
12.2
Certification of the Principal Financial Officer.
 
13.1
Principal Executive Officer Certifications pursuant to 18 U.S.C. Section 1350.
 
13.2
Principal Financial Officer Certifications pursuant to 18 U.S.C. Section 1350.
 
*
Incorporated by reference to Exhibit No. 4.1 in the Company's Registration Statement on Form F-1, filed December 13, 1996.
**
Incorporated by reference to Exhibit No. 4.2 in the Company’s Annual report on Form 20F for the fiscal year ended December 31, 2005.
***
Incorporated by reference to the same Exhibit No. of the Company’s Annual Report on Form 20-F for the fiscal year ended December 31, 2003.

 
46

 


SIGNATURES

The registrant hereby certifies that it meets all of the requirements for filing on Form 20-F and has duly caused and authorized the undersigned to sign this annual report on its behalf.

KNIGHTSBRIDGE TANKERS LIMITED

By: /s/ Inger M. Klemp

_____________________
Inger M. Klemp
Chief Financial Officer
Dated:  April 23, 2008

 

 
47

 

 
 
Index to Consolidated Financial Statements of Knightsbridge Tankers Limited
 
   
Report of Independent Registered Public Accounting Firm
 
F-2
Consolidated Statements of Operations for the years ended December 31, 2007, 2006 and 2005
 
F-3
Consolidated Balance Sheets as of December 31, 2007 and 2006
 
F-4
Consolidated Statements of Cash Flows for the years ended December 31, 2007, 2006 and 2005
 
F-5
Consolidated Statements of Changes in Stockholders' Equity for the years ended
F-6
December 31, 2007, 2006 and 2005
 
 
Notes to Consolidated Financial Statements
F-7

 
F-1 

 

 REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Board of Directors and Stockholders
Knightsbridge Tankers Limited
 
We have audited the accompanying consolidated balance sheets of Knightsbridge Tankers Limited as of December 31, 2007 and 2006, and the related consolidated statements of operations, changes in stockholders' equity, and cash flows for each of the years in the three-year period ended December 31, 2007.  We also have audited Knightsbridge Tankers Limited’s internal control over financial reporting as of December 31, 2007, based on criteria established in Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission.  Knightsbridge Tankers Limited's management is responsible for these consolidated financial statements, for maintaining effective internal control over financial reporting, and for its assessment of the effectiveness of internal control over financial reporting included in the accompanying Management’s annual report on internal controls over financial reporting.  Our responsibility is to express an opinion on these consolidated financial statements and an opinion on the Company's internal control over financial reporting based on our audits.
 
We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States).  Those standards require that we plan and perform the audits to obtain reasonable assurance about whether the consolidated financial statements are free of material misstatement and whether effective internal control over financial reporting was maintained in all material respects.  Our audits of the consolidated financial statements included examining, on a test basis, evidence supporting the amounts and disclosures in the consolidated financial statements, assessing the accounting principles used and significant estimates made by management, and evaluating the overall consolidated financial statement presentation.  Our audit of internal control over financial reporting included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, and testing and evaluating the design and operating effectiveness of internal control based on the assessed risk.  Our audits also included performing such other procedures as we considered necessary in the circumstances.  We believe that our audits provide a reasonable basis for our opinions.
 
A company's internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of consolidated financial statements for external purposes in accordance with generally accepted accounting principles.  A company's internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of consolidated financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company's assets that could have a material effect on the consolidated financial statements.
 
Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements.  Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.
 
In our opinion, the consolidated financial statements referred to above present fairly, in all material respects, the financial position of Knightsbridge Tankers Limited as of December 31, 2007 and 2006, and the results of operations and cash flows for each of the years in the three-year period ended December 31, 2007, in conformity with accounting principles generally accepted in the United States of America.  Also in our opinion, Knightsbridge Tankers Limited maintained, in all material respects, effective internal control over financial reporting as of December 31, 2007, based on criteria established in Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission.
 
.
New York, New York                                                                                                           Moore Stephens, P.C.
April 18, 2008                                                                                                           Certified Public Accountants

F-2
 
 

 

Knightsbridge Tankers Limited
Consolidated Statements of Operations for the years ended
December 31, 2007, 2006 and 2005
(in thousands of $, except per share data)

   
2007
   
2006
   
2005
 
Operating revenues
 
Time charter revenues
    53,814       42,445       42,325  
Voyage charter revenues
    34,346       63,283       57,854  
Total operating revenues
    88,160       105,728       100,179  
Gain on sale of assets
    49,119       -       -  
Operating expenses
 
Voyage expenses and commission
    12,872       20,015       16,459  
Ship operating expenses
    15,544       15,835       17,211  
Administrative expenses
    1,481       1,492       988  
Depreciation
    17,016       17,121       17,120  
Total operating expenses
    46,913       54,463       51,778  
Net operating income
    90,366       51,265       48,401  
Other income (expenses)
                       
Interest income
    1,026       1,383       959  
Interest expense
    (6,373 )     (6,881 )     (5,310 )
Other financial items, net
    (183 )     (50 )     (83 )
Net other expenses
    (5,530 )     (5,548 )     (4,434 )
Net income
    84,836       45,717       43,967  
Per share information:
                       
Earnings per share: basic and diluted   $
4.96
    $ 2.67     $ 2.57  
Cash dividends per share declared
  $ 2.50     $ 3.60     $ 4.55  

 

The accompanying notes are an integral part of these consolidated financial statements.

 
F-3 

 

Knightsbridge Tankers Limited
Consolidated Balance Sheets as of December 31, 2007 and 2006
(in thousands of $)

   
2007
   
2006
 
ASSETS
           
Current Assets
           
Cash and cash equivalents
    82,143       8,538  
Restricted cash
    10,000       10,000  
Trade accounts receivable, net
    4,843       8,535  
Other receivables
    5,836       666  
Inventories
    3,923       2,621  
Voyages in progress
    -       2,273  
Prepaid expenses and accrued income
    608       628  
Total current assets
    107,353       33,261  
     Vessels, net
    201,072       267,949  
     Newbuildings
    33,459       -  
     Deferred charges
    282       289  
Total assets
    342,166       301,499  
                 
LIABILITIES AND STOCKHOLDERS’ EQUITY
               
Current liabilities
               
Credit facilities and current portion of long-term debt
    8,960       11,211  
Trade accounts payable
    620       8,094  
Accrued expenses
    5,861       3,072  
Other current liabilities
    2,409       1,932  
Total current liabilities
    17,850       24,309  
Long-term liabilities
               
Long-term debt
    103,040       98,000  
Total liabilities
    120,890       122,309  
Commitments and contingencies
               
Stockholders’ equity
               
Share capital
    171       171  
Contributed capital surplus account
    179,019       179,019  
Retained earnings
    42,086       -  
Total stockholders’ equity
    221,276       179,190  
Total liabilities and stockholders’ equity
    342,166       301,499  

 
The accompanying notes are an integral part of these consolidated financial statements.

 
F-4 

 

Knightsbridge Tankers Limited
Consolidated Statements of Cash Flows for the years ended
December 31, 2007, 2006 and 2005
(in thousands of $)

 
   
2007
   
2006
   
2005
 
                   
Net income
    84,836       45,717       43,967  
Adjustments to reconcile net income to net cash
                       
provided by operating activities:
                       
Depreciation
    17,016       17,121       17,120  
Amortization of deferred charges
    148       70       66  
Gain on sale of assets
    (49,119 )     -       -  
Changes in operating assets and liabilities:
                       
  Trade accounts receivable, net
    3,330       (902 )     5,599  
  Other receivables
    (5,170 )     473       (531 )
  Inventories
    (1,302 )     (609 )     (381 )
  Voyages in progress
    2,273       1,394       2,455  
  Prepaid expenses and accrued income
    20       17       (229 )
  Trade accounts payable
    (7,112 )     6,120       1,509  
  Accrued expenses
    2,789       (228 )     570  
  Other current liabilities
    477       (520 )     (17 )
Net cash provided by operating activities
    48,186       68,653       70,128  
Investing activities
                       
Additions to newbuildings
    (33,459 )     -       -  
Proceeds from sale of asset
    98,980       -       -  
Net cash provided by investing activities
    65,521       -       -  
Financing activities
                       
Proceeds from long-term debt
    33,600       87       -  
Repayments of long-term debt and credit facilities
    (30,811 )     (11,276 )     (11,309 )
Debt fees paid
    (141 )     -       (33 )
Dividends paid
    (42,750 )     (61,560 )     (77,805 )
Net cash used in financing activities
    (40,102 )     (72,749 )     (89,147 )
Net increase (decrease) in cash and cash equivalents
    73,605       (4,096 )     (19,019 )
Cash and cash equivalents at beginning of year
    8,538       12,634       31,653  
Cash and cash equivalents at end of year
    82,143       8,538       12,634  
                         
Supplemental disclosure of cash flow information:
                       
Interest paid, net of capitalized interest
    6,416       6,791       5,235  
                         
                         

 
The accompanying notes are an integral part of these consolidated financial statements.

F-5 
 

 

Knightsbridge Tankers Limited
Consolidated Statements of Changes in Stockholders’ Equity for the years ended
December 31, 2007, 2006 and 2005
(in thousands of $, except number of shares)

   
2007
   
2006
   
2005
 
NUMBER OF SHARES OUTSTANDING
                 
Balance at beginning and end of year
    17,100,000       17,100,000       17,100,000  
                         
SHARE CAPITAL
                       
Balance at beginning and end of year
    171       171       171  
                         
CONTRIBUTED CAPITAL SURPLUS ACCOUNT
                       
Balance at beginning of year
    179,019       194,862       220,059  
Distributions to shareholders
    -       (15,843 )     (25,197 )
Balance at end of year
    179,019       179,019       194,862  
                         
RETAINED EARNINGS
                       
Balance at beginning of year
    -       -       8,641  
Net income
    84,836       45,717       43,967  
Dividends paid
    (42,750 )     (45,717 )     (52,608 )
Balance at end of year
    42,086       -       -  
Total Stockholders’ Equity
    221,276       179,190       195,033  

 
The accompanying notes are an integral part of these consolidated financial statements.

 
F-6 

 


Knightsbridge Tankers Limited
Notes to Consolidated Financial Statements


 
1.
DESCRIPTION OF BUSINESS

Knightsbridge Tankers Limited (the “Company”) was incorporated in Bermuda in September, 1996, for the purpose of the acquisition, disposition, ownership, leasing and chartering of five very large crude oil carriers, or VLCCs and certain related activities. The Company’s shares are listed on the NASDAQ National Market.

During 2007, a vessel was sold and the remainder of the fleet is now operating in the time charter market. Two of the vessels are on charter for four and five years respectively, both earning a rate of $37,750 per day plus a market-based profit sharing payment computed as 50% of the difference between the related spot market index rate and the base rate. These charters commenced during the year. Another vessel moved from the spot market to a three year time charter during the year earning a rate of $45,000 per day. The remaining vessel charter expires in 2009. This is a five year charter earning a rate of $31,000 a day. In addition, the Company currently has two newbuildings under construction, both Capesize bulk carriers of approximately 170,000 dwt, which are scheduled for delivery in 2009. One of the newbuildings will commence a five year time charter upon delivery in 2009, earning a rate of $40,000 per day.

The business of the Company is managed by ICB Shipping (Bermuda) Limited (the “Manager”), an indirect wholly-owned subsidiary of Frontline Ltd.


 
2.
SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Basis of presentation
The consolidated financial statements are prepared in accordance with accounting principles generally accepted in the United States of America. The consolidated financial statements include the assets and liabilities of Knightsbridge Tankers Limited and its wholly-owned subsidiaries. All intercompany balances and transactions have been eliminated upon consolidation.

The preparation of financial statements in accordance with generally accepted accounting principles requires that management make estimates and assumptions affecting the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates.

Reporting currency
The Company's functional currency is the United States dollar as all revenues are received in United States dollars and a majority of the Company's expenditures are made in United States dollars. The Company and its subsidiaries report in United States dollars.

Transactions in foreign currencies during the year are translated into United States dollars at the rates of exchange in effect at the date of the transaction. Foreign currency monetary assets and liabilities are translated using rates of exchange at the balance sheet date. Foreign currency non-monetary assets and liabilities are translated using historical rates of exchange. Foreign currency transaction gains or losses are included in the consolidated statements of operations.

Revenue and expense recognition
Revenues are generated from freight billings, time charter and bareboat charter hires. Time charter and bareboat charter revenues are recorded over the term of the charter as service is provided. Under a voyage charter the revenues and associated voyage costs are recognized ratably over the estimated duration of the voyage, which is measured from completion of discharge to completion of discharge. Voyage revenues and expenses are recognized ratably over the estimated length of each voyage and, therefore, are allocated between reporting periods based on the relative transit time in each period. The impact of recognizing voyage expenses ratably over the length of each voyage is not materially different on a quarterly and annual basis from a method of recognizing such costs as incurred. Probable losses on voyages are accrued in full at the time such losses can be estimated. Amounts receivable from profit sharing arrangements are accrued based on the time charter equivalent rates

F- 7

 
 

 

achieved through vessel deployment over the preceding quarter in the market for certain key routes and are not contingent on the performance of the Company. This amount is calculated and accounted for on a quarterly basis and is received on a quarterly basis. Each quarterly settlement is final and does not get carried forward to the next quarter. There is no consideration of future performance in the recording of profit sharing revenue.

Leases
The current time charters for the Company’s four vessels are classified as operating leases by the Company.

Cash and cash equivalents
All demand and time deposits and highly liquid, low risk investments with maturities of three months or less at the date of purchase are considered equivalent to cash.

 
Restricted cash
Restricted cash consists of bank deposits maintained in accordance with contractual loan arrangements.

 
Inventories
Inventories, which are comprised principally of fuel and lubricating oils, are stated at the lower of cost and market value. Cost is determined on a first-in, first-out basis.

Newbuildings
The carrying value of the vessels under construction or newbuildings, represents the accumulated costs through the balance sheet date including capitalized loan interest and associated finance costs. No charge for depreciation is made until a vessel is put into operation.

Vessel purchase expenditures are capitalized at the time vessel purchase contracts are acquired or entered into. The Company reviews expected future cash flows, which would result from each contract on a contract by contract basis to determine whether the carrying value is recoverable. If the expected future cash flows are less than the carrying value of the contract plus further costs to delivery, impairment is recorded to write down the carrying value to the recoverable amount. Capitalized amounts are transferred to cost of vessels, upon delivery of a vessel to the Company.

Vessels and depreciation
Vessels are stated at cost less accumulated deprecation. Depreciation is calculated based on cost less estimated residual value, using the straight-line method, over the useful life of each vessel. The useful life of each vessel is deemed to be 25 years.

Deferred charges
Loan costs, including debt arrangement fees, are capitalized and amortized on a straight-line basis over the term of the loan. Amortization of loan costs is included in interest expense.  If the loan is repaid early, any unamortized portion of the related deferred charges is charged against income in the period in which the loan is repaid.

Earnings per share
Earnings per share are based on the weighted average number of common shares outstanding for the period presented. For all periods presented, the Company had no potentially dilutive securities outstanding and therefore basic and diluted earnings per share are the same.

Impairment of long-lived assets
Long-lived assets that are held and used by the Company are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. If such a review indicates impairment, an impairment charge is recognized based on the difference between carrying value and fair value. Fair value is typically established using an average of three independent valuations. In addition, long-lived assets to be disposed of by sale are reported at the lower of their carrying amount or fair value less estimated costs to sell.

Distributions to shareholders
Distributions to shareholders are applied first to retained earnings. When retained earnings are not sufficient, distributions are applied to the contributed capital surplus account.


F-8

 
 

 
Drydocking

Normal vessel repair and maintenance costs are expensed when incurred. The Company recognises the cost of a drydocking at the time the drydocking takes place, that is, it applies the “expense as incurred” method.

 
3.
RECENTLY ISSUED ACCOUNTING STANDARDS

In September 2006, the FASB issued SFAS No. 157 “Fair Value Measurements” (“FAS 157”). FAS 157 defines fair value, establishes a framework for measuring fair value in generally accepted accounting principles and expands disclosures about fair value measurements. FAS 157 applies under most other accounting pronouncements that require or permit fair value measurements and does not require any new fair value measurements. FAS 157 is effective for fiscal years beginning after November 15, 2007.

In February 2008 the FASB issued FSP No. FAS157-1 “Application of FASB Statement No. 157 to FASB Statement No. 13 and Other Accounting Pronouncements That Address Fair Value Measurements for Purposes of Lease Classification or Measurement under Statement 13” (“FSP FAS157-1”). FSP FAS157-1 amends FAS 157 to exclude FASB Statement No. 13 “Accounting for Leases” (“FAS 13”) and its related interpretive accounting pronouncements that address leasing transactions. The FASB decided to exclude leasing transactions covered by FAS 13 in order to allow it to more broadly consider the use of fair value measurements for these transactions as part of its project to comprehensively reconsider the accounting for leasing transactions. The Company does not expect the adoption of FAS 157 and FSP FAS157-1 to have a material impact on its financial statements.

In February 2007 the FASB issued SFAS No. 159 “The Fair Value Option for Financial Assets and Financial Liabilities – including an amendment of FASB  Statement No. 115” (SFAS 159). SFAS 159 permits entities to choose to measure many financial instruments and certain other items at fair value. The objective is to improve financial reporting by providing entities with the opportunity to mitigate volatility in reported earnings caused by measuring related assets and liabilities differently without having to apply complex hedge accounting provisions. SFAS 159 is effective for fiscal years beginning after November 15 2007. The Company does not expect the adoption of SFAS 159 to have a material impact on its financial statements.

In December 2007 the FASB issued SFAS No. 160 “Noncontrolling Interests in Consolidated Financial Statements – an amendment of ARB No.51” (SFAS 160). SFAS 160 is intended to improve the relevance, comparability and transparency of financial information that a reporting entity provides in its consolidated financial statements with reference to a noncontrolling interest in a subsidiary. Such a noncontrolling interest, sometimes called a minority interest, is the portion of equity in a subsidiary not attributable, directly or indirectly, to the parent entity. SFAS 160 is effective for fiscal years beginning on or after December 15 2008. The Company does not expect the adoption of SFAS 160 to have a material impact on its financial statements.

In December 2007 the FASB issued SFAS No. 141 (revised 2007) “Business Combinations” (“FAS 141R”). The objective of FAS 141R is to improve the relevance, representational faithfulness and comparability of the information that a reporting entity provides in its financial reports about a business combination and its effects. To accomplish this, FAS 141R establishes principles and requirements for how the acquirer a) recognizes and measures in its financial statements the identifiable assets acquired, the liabilities assumed and any non-controlling interest in the acquiree, b) recognizes and measures the goodwill acquired in the business combination or a gain from a bargain price, and c) determines what information to disclose to enable users of the financial statements to evaluate the nature and financial effects of the business combination. FAS 141R is effective for fiscal years beginning on or after December 15, 2008. The Company does not expect the adoption of FAS 141R to have a material impact on its financial statements.


 
4.
TAXATION

The Company is incorporated in Bermuda. Under current Bermuda law, the Company is not required to pay taxes in Bermuda on either income or capital gains. The Company has received written assurance from the Minister of Finance in Bermuda that, in the event of any such taxes being imposed, the Company will be exempted from taxation until the year 2016. Based upon review of applicable laws and regulations, and after consultation with counsel, the Company does not believe it is subject to material income taxes in any jurisdiction.


F-9

 
 

 
 
 
 
 
5.
LEASES
The minimum future revenues to be received on time charters which are accounted for as operating leases as of December 31, 2007 are as follows:

Year ending December 31,
     
(in thousands of $)
     
2008
    55,418  
2009
    46,184  
2010
    31,428  
2011
    20,687  
2012
    5,926  
Total minimum lease revenues
    159,643  

The cost and accumulated depreciation of vessels leased to third parties at December 31, 2007 was $352.3 million and $151.2 million respectively and at December 31, 2006 were $264.4 million and $103.3 million respectively.


 
6.
TRADE ACCOUNTS RECEIVABLE, NET

Trade accounts receivable are presented net of allowance for doubtful accounts amounting to $0.2 million (2006: $0.2 million).


 
7.
NEWBUILDINGS

(in thousands of $)
 
2007
   
2006
 
Newbuildings
    33,459       -  

The carrying value of newbuildings represents accumulated costs paid in purchase installments, other capital expenditures and capitalized loan interest.  Interest capitalized in the cost of newbuildings totaled $1.0 million in 2007 (2006: $nil).


 
8.
VESSELS

(in thousands of $)
 
2007
   
2006
 
Cost
    352,308       439,822  
Accumulated depreciation
    (151,236 )     (171,873 )
Net book value at end of year
    201,072       267,949  

Depreciation expense was $17.0 million, $17.1 million and $17.1 million for the years ended December 31, 2007, 2006 and 2005, respectively. During December 2007, a vessel was sold to a third-party for net proceeds of $99.0 million.


 
9.
DEFERRED CHARGES

Deferred charges represent debt arrangement fees that are capitalized and amortized on a straight-line basis to interest expense over the life of the debt instrument. The deferred charges are comprised of the following amounts:

(in thousands of $)
 
2007
   
2006
 
Capitalized financing fees and expenses
    523       477  
Accumulated amortization
    (241 )     (188 )
Net book value at end of year
    282       289  


F-10

 
 

 

10. 
DEBT
     
(in thousands of $)
 
2007
   
2006
 
US dollar denominated floating rate debt
    112,000       109,200  
Other
    -       11  
Total debt
    112,000       109,211  
Less: Credit facilities and current portion of debt
    (8,960 )     (11,211 )
      103,040       98,000  

The average interest rate for the floating rate debt was 6.1% for the year ended December 31, 2007 and 5.87% for the year ended December 31, 2006.

Credit Facility Loan
In March 2004, the Company refinanced a prior debt facility with a $140.0 million credit facility in the form of five tranches of $28.0 million, each in respect to a vessel. The credit facility is secured by, among other things, a mortgage on each vessel and an assignment of any charter in respect to that vessel. An amount of $20.1 million was repaid following the sale of a vessel in December 2007. The repayment terms of the facility is seven years so that the facility is due to be repaid in 2011.

The credit facility bears interest at LIBOR plus a margin and contains a minimum market value covenant on the vessels and a covenant requiring us to maintain a certain minimum level of cash.

Newbuilding Loan Extension
In May 2007, the Company took out an extension of the credit facility and drew two tranches of $16.8 million each to fund instalment payments on two newbuilding contracts. This is repayable in 2009 and is subject to the same covenants as the original loan.

The outstanding debt as of December 31, 2007 is repayable as follows:

Year ending December 31,
     
(in thousands of $)
     
2008
    8,960  
2009
    42,560  
2010
    8,960  
2011
    51,520  
Total debt
    112,000  

11. 
SHARE CAPITAL

Authorized, issued and fully paid share capital:

(in thousands of $)
 
2007
   
2006
 
17,100,000 ordinary shares of $0.01 each
    171       171  

12. 
FINANCIAL INSTRUMENTS

Interest rate risk management
In certain situations, the Company may enter into financial instruments to reduce the risk associated with fluctuations in interest rates. The Company does not hold or issue instruments for speculative or trading purposes. As at December 31, 2007, the Company is not party to any interest rate swaps to hedge interest rate exposure.

Foreign currency risk
The majority of the Company’s transactions, assets and liabilities are denominated in United States dollars, the functional currency of the Company. There is no significant risk that currency fluctuations will have a negative effect of the value of the Company’s cash flows.

F- 11

 
 

 


Fair values
The carrying value and estimated fair value of the Company’s financial instruments at December 31, 2007 and 2006 are as follows:

   
2007
   
2007
   
2006
   
2006
 
 
(in thousands of $)
 
Fair
Value
   
Carrying Value
   
Fair
Value
   
Carrying Value
 
Cash and cash equivalents
    82,143       82,143       8,538       8,538  
Restricted cash
    10,000       10,000       10,000       10,000  
Floating rate debt and credit facilities
    112,000       112,000       109,211       109,211  

The carrying value of cash and cash equivalents, and restricted cash, is a reasonable estimate of fair value.

The estimated fair value for floating rate long-term debt is considered to be equal to the carrying value since it bears variable interest rates, which are reset on a quarterly basis.

Concentrations of risk
There is a concentration of credit risk with respect to cash and cash equivalents to the extent that substantially all of the amounts are carried with Skandinaviska Enskilda Banken and The Royal Bank of Scotland plc. However, the Company believes this risk is remote as these banks are high credit quality financial institutions. The Company does not require collateral or other security to support financial instruments subject to credit risk.

In 2007, four customers accounted for $81.0 million, or 92% of gross revenue, while in 2006 four customers accounted for $71.1 million or 67% of gross revenue. In 2005 two customers accounted for $42.6 million or 42% of gross revenues. Below is a list of customers who have revenue of more than 10% of total revenue in 2007.

 
Customer
 
Revenue (in thousands of $)
   
Percentage
of revenue
Malaysia International Shipping Corporation
    11,481       13 %
Frontline Ltd
    29,881       34 %
Great Elephant Corporation
    13,855       16 %
Shell International
    25,807       29 %
      81,024       92 %

13. 
MANAGEMENT OF COMPANY

On February 12, 1997, the Company entered into a management agreement with the Manager under which the Manager provided certain administrative, management and advisory services to the Company for an amount of $750,000 per year. Effective February 2004, the Company entered into an amendment to the agreement with the Manager. The management fee has been amended to $630,000 per year, in addition to a commission of 1.25 per cent on gross freight revenues. Pursuant to the terms of the amendment, the Company is now responsible for paying its own administrative expenses. In February 2006 the management fee was increased to $1,150,000 per annum.


14. 
COMMITMENTS AND CONTINGENCIES

The Company has contracts for the construction of two Capesize newbuildings at Daehan Shipbuilding Co. Ltd in the Republic of Korea. These vessels are scheduled for delivery in 2009. As of December 31, 2007 the Company was committed to make further instalments of $129.6 million under these contracts.
 
15. 
SUBSEQUENT EVENTS
 
The Company announced in March 2008 that it has agreed to fix out on time charter one of its two newbuilding Capesize bulk carriers. The charter is for a period of five years from the delivery scheduled for July 2009 and is at a net rate of $53,000 per day.


F- 12

 
 
 
EX-4.1 2 d873547_ex4-1.htm FORM OF SHIPBUILDING CONTRACT d873547_ex4-1.htm
Exhibit 4.1
 

FORM OF
 
SHIPBUILDING CONTRACT
 

 
FOR
 
 
THE CONSTRUCTION
 

 
OF
 

 
ONE (1) 170,500 DWT CLASS BULK CARRIER
 

 
(HULL NO. HN-101[  ])
 

 
BETWEEN
 
 
GOLDEN OCEAN GROUP LIMITED
OR ITS NOMINEE
 
(AS BUYER)
 
 
AND
 
 
 
DAEHAN SHIPBUILDING CO., LTD.
(AS BUILDER)
 

 
 

 

INDEX
 

ARTICLE   PAGE  
PREAMBLE
1
ARTICLE I - DESCRIPTION AND CLASS
2
 
1.
Description
2
 
2.
Basic Dimensions And Principal Particulars Of The Vessel
2
 
3.
Classification, Rules And Regulations
3
 
4.
Subcontracting
3
 
5.
Nationality Of The Vessel
3
ARTICLE II - CONTRACT PRICE
4
ARTICLE III - ADJUSTMENT OF THE CONTRACT PRICE
5
 
1.
Delayed Delivery
5
 
2.
Insufficient Speed
5
 
3.
Excessive Fuel Consumption
6
 
4.
Deadweight Below Contract Requirements
6
 
5.
Effect Of Cancellation
8
ARTICLE IV - INSPECTION AND APPROVAL
9
 
1.
Appointment Of The Buyer’s Representative
9
 
2.
Authority Of The Buyer’s Representative
9
 
3.
Approval Of Drawings
10
 
4.
Salaries And Expenses
11
 
5.
Responsibility Of The Builder
11
 
6.
Responsibility Of The Buyer
11
ARTICLE V - MODIFICATIONS, CHANGES AND EXTRAS
13
 
1.
How Effected
13
 
2.
Substitution Of Material
13
 
3.
Changes In Rules And Regulations
13
ARTICLE VI - TRIALS AND COMPLETION
15
 
1.
Notice
15
 
2.
Weather Condition
15
 
3.
How Conducted
15
 
4.
Consumable Stores
15
 
5.
Acceptance Or Rejection
16
 
6.
Effect Of Acceptance
17
ARTICLE VII - DELIVERY
18
 
1.
Time And Place
18
 
2.
When And How Effected
18
 
 

 
 
3.
Documents To Be Delivered To The Buyer
18
 
4.
Tender Of The Vessel
19
 
5.
Title And Risk
19
 
6.
Removal Of The Vessel
19
ARTICLE VIII - DELAYS AND EXTENSIONS OF TIME (FORCE MAJEURE)
21
 
1.
Causes Of Delay
21
 
2.
Notice Of Delays
21
 
3.
Right To Cancel For Excessive Delay
21
 
4.
Definition Of Permissible Delays
22
ARTICLE IX - WARRANTY OF QUALITY
23
 
1.
Guarantee Of Material And Workmanship
23
 
2.
Notice Of Defects
23
 
3.
Remedy Of Defects
23
 
4.
Extent Of The Builder’s Liability
24
ARTICLE X - PAYMENT
27
 
1.
Currency
27
 
2.
Terms Of Payment
27
 
3.
Demand For Payment
28
 
4.
Method Of Payment
28
 
5.
Refund By The Builder
29
 
6.
Total Loss
29
 
7.
Discharge Of Obligations
29
 
8.
Refund Guarantee
30
 
9.
Performance Guarantee
30
ARTICLE XI - BUYER’S DEFAULT
31
 
1.
Definition Of Default
31
 
2.
Effect Of The Buyer’s Default On Or Before The Delivery Of The Vessel
31
ARTICLE XII - BUYER’S SUPPLIES
34
 
1.
Responsibility Of The Buyer
34
 
2.
Responsibility Of The Builder
34
ARTICLE XIII - ARBITRATION
36
 
1.
Appointment Of The Arbitrator
36
 
2.
Laws Applicable
36
 
3.
Proceedings
36
 
4.
Alteration Of Delivery Of The Vessel
37
ARTICLE XIV - SUCCESSORS AND ASSIGNS
38
ARTICLE XV - TAXES AND DUTIES
39
 
1.
Taxes
39
 
2.
Duties
39
ARTICLE XVI - PATENTS, TRADEMARKS AND COPYRIGHTS
40
 
1.
Patents, Trademarks And Copyrights
40
 
2.
Rights to the Specifications, Plans, etc.
40
ARTICLE XVII - INTERPRETATION AND GOVERNING LAW
41
ARTICLE XVIII - NOTICE
42
ARTICLE XIX - EFFECTIVENESS OF THIS CONTRACT
43
ARTICLE XX - EXCLUSIVENESS
44
EXHIBIT “A”
A-1
EXHIBIT “B”
B-1



 
 

 

SHIPBUILDING CONTRACT
 
THIS CONTRACT, made on this 30th day of November, 2006 by and between GOLDEN OCEAN GROUP LIMITED or its nominee, a corporation organized and existing under the laws of Bermuda with its principal office at Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton HM 08, Bermuda (hereinafter called the “BUYER”), the party of the first part and DAEHAN SHIPBUILDING CO., LTD., a corporation organized and existing under the laws of the Republic of Korea, having its principal office at 748, Woodoo-Ri, Dolsan-Up, Yeosu City, Jeonnam, Korea (hereinafter called the “BUILDER”), the party of the second part,
 
WITNESSETH:
 
In consideration of the mutual covenants contained herein, the BUILDER agrees to design, build, launch, equip and complete one (1) 170,500 DWT Class Bulk Carrier as described in Article I hereof (hereinafter called the “VESSEL”) at the BUILDER’s shipyard in Haenam, Korea (hereinafter called the “SHIPYARD”) and to deliver and sell the VESSEL to the BUYER, and the BUYER agrees to accept delivery of and purchase from the BUILDER the VESSEL, according to the terms and conditions hereinafter set forth :
 
(End of Preamble)

 
1

 

ARTICLE I - DESCRIPTION AND CLASS
 

1.  
DESCRIPTION
 
The VESSEL shall have the BUILDER’s Hull No, HN-101[  ] and shall be constructed, equipped and completed in accordance with the Specifications for Hull Nos. HN-1015/1016, dated 30th November, 2006 and General Arrangement Plan attached thereto (hereinafter called respectively the “SPECIFICATIONS” and the “PLAN”) signed by both parties, which shall constitute an integral part of this CONTRACT although not attached hereto.
 
The SPECIFICATIONS and the PLAN are intended to explain each other and anything shown on the PLAN and not stipulated in the SPECIFICATIONS or anything stipulated in the SPECIFICATIONS and not shown on the PLAN shall be deemed and considered as if included in both. Should there be any inconsistencies or contradictions between the SPECIFICATIONS and the PLAN, the SPECIFICATIONS shall prevail. Should there be any inconsistencies or contradictions between this CONTRACT and the SPECIFICATIONS, this CONTRACT shall prevail.
 
2.  
BASIC DIMENSIONS AND PRINCIPAL PARTICULARS OF THE VESSEL
 
 
(a)  
The basic dimensions and principal particulars of the VESSEL shall be
 
 
Length, overall
about
289.0 M
       
 
Length, between perpendiculars
about
279.0 M
       
 
Breadth, moulded
about
45.0 M
       
 
Depth to Upper Deck, moulded
about
24.2 M
       
 
Design draft, moulded, in seawater
of specific gravity of 1.025
about
16.5 M
       
 
Scantling draft, moulded, in
seawater of specific gravity of 1.025
about
17.8 M
       
 
Deadweight on the above moulded design draft of 16.5 M
 
155,000 M/T
       
 
Deadweight on the above moulded scantling draft of 17.8 M
about
170,500 M/T
       
 
Cubic capacity of cargo hold (incl. hatch coaming)
about
191,500 M3
 
 
Main propulsion engine
 
MAN B&W 6S70MC-C
MCR:  18,660KW x 91.0 RPM
NCR:  16,794KW x 87.9 RPM
       
 
Service speed at 16.5 meters design draft at the condition of clean bottom and in calm and deep sea with main engine developing a NCR of 16,794 KW with 15.0 per cent (15.0%) sea margin.
 
 
15.4 Knots
 
       
 
Specific fuel consumption of the main engine with tolerance of +5% applying I.S.O. reference conditions to the result of official shop test at a MCR of 18,660 KW using marine diesel oil having lower calorific value of 10,200 Kcal per Kg.
 
 
169.0 gr/KW.HR
 
 
 
2

 
The details of the above particulars as well as the definitions and method of measurements and calculations are as indicated in the SPECIFICATIONS.
 
 
(b)  
The dimensions may be slightly modified by the BUILDER, who also reserves the right to make changes to the SPECIFICATIONS and the PLAN if found necessary to suit the local conditions and facilities of the SHIPYARD, the availability of materials and equipment, the introduction of improved production methods or otherwise, subject to the approval of the BUYER which the BUYER shall not withhold unreasonably.
 
3.  
CLASSIFICATION, RULES AND REGULATIONS
 
 
(a)  
The VESSEL shall be built in compliance with the rules and regulations of Det Norske Veritas (hereinafter called the “CLASSIFICATION SOCIETY”), in force as of the date of this CONTRACT, to be classed and registered as +1A1, Bulk Carrier ESP, CSR, BC-A, Holds 2, 4, 6 and 8 may be empty, E0, BIS, GRAB(20), ES(S) and also to comply with the rules and regulations, in force as of the date of this CONTRACT, as described in the SPECIFICATIONS,
 
 
(b)  
The BUILDER shall arrange with the CLASSIFICATION SOCIETY for the assignment by the CLASSIFICATION SOCIETY of representative(s) to the VESSEL during construction. All fees and charges incidental to classification of the VESSEL in compliance with the above specified rules, regulations and requirements of this CONTRACT shall be for the account of the BUILDER.
 
 
(c)  
The decision of the CLASSIFICATION SOCIETY as to whether the VESSEL complies with the regulations of the CLASSIFICATION SOCIETY shall be final and binding upon the BUILDER and the BUYER.
 
4.  
SUBCONTRACTING
 
The BUILDER may, at its sole discretion and responsibility, subcontract any portion of the construction work of the VESSEL.
 
5.  
NATIONALITY OF THE VESSEL
 
The VESSEL shall be registered by the BUYER at its own cost and expense under the laws of the Republic of the Marshall Islands with its home port of Majuro at the time of its delivery and acceptance hereunder.
 
 
(End of Article)
 

 
3

 

ARTICLE II - CONTRACT PRICE
 

The contract price of the VESSEL delivered to the BUYER at the SHIPYARD shall be United States Dollars Eighty One Million only (US$81,000,000.-) (hereinafter called the “CONTRACT PRICE”) which shall be paid plus any increases or less any decreases due to adjustment or modifications, if any, as set forth in this CONTRACT. The above CONTRACT PRICE shall include payment for services in the inspection, tests, survey and classification of the VESSEL which will be rendered by the CLASSIFICATION SOCIETY and shall not include the cost of the BUYER’s supplies as stipulated in Article XII.
 
The CONTRACT PRICE also includes all costs and expenses for supplying all necessary drawings as stipulated in the SPECIFICATIONS except those to be furnished by the BUYER for the VESSEL in accordance with the SPECIFICATIONS.
 
(End of Article)
 

 
4

 

ARTICLE III - ADJUSTMENT OF THE CONTRACT PRICE
 

 
The CONTRACT PRICE of the VESSEL shall be adjusted as hereinafter set forth in the event of the following contingencies. It is hereby understood by both parties that any adjustment of the CONTRACT PRICE as provided for in this Article is by way of liquidated damages and not by way of penalty.
 

1.  
DELAYED DELIVERY
 
 
(a)  
No adjustment shall be made and the CONTRACT PRICE shall remain unchanged for the first thirty (30) days of the delay in delivery of the VESSEL [ending as of 12 o’clock midnight Korean Standard Time on the thirtieth (30th) day of delay] beyond the Delivery Date calculated as provided in Article VII.1. hereof.
 
 
(b)  
If delivery of the VESSEL is delayed more than thirty (30) days beyond the date upon which the delivery is due from the BUILDER under the terms of this CONTRACT, then, beginning at midnight of the thirtieth (30th) day after such due date, the CONTRACT PRICE of the VESSEL shall be reduced by U.S. Dollars Twenty Five Thousand (US$25,000.-) for each full day of delay.
 
      However, unless the parties agree otherwise, the total amount of deduction from the CONTRACT PRICE shall not exceed the amount due to cover the delay of one hundred and eighty (180) days after thirty (30) days of the delay in delivery of the VESSEL at the rate of deduction as specified hereinabove. 
 
 
(c)  
But, if the delay in delivery of the VESSEL continues for a period of more than two hundred and ten (210) days beyond the date upon which the delivery is due from the BUILDER under the terms of this CONTRACT then, in such event, and after such period has expired, the BUYER may, at its option, cancel this CONTRACT by serving upon the BUILDER a notice of cancellation by facsimile to be confirmed by a registered letter via airmail directed to the BUILDER at the address given in this CONTRACT. Such cancellation shall be effective as of the date the notice thereof is received by the BUILDER. If the BUYER has not served the notice of cancellation after the aforementioned two hundred and ten (210) days delay in delivery, the BUILDER may demand the BUYER to make an election in accordance with Article VIII.3. hereof,
 
 
(d)  
For the purpose of this Article, the delivery of the VESSEL shall be deemed to be delayed when and if the VESSEL, after taking into full account extension of the Delivery Date or permissible delays as provided in Article V-3, VI-2, VIII-1, XI-2 or elsewhere in this CONTRACT, is delivered beyond the date upon which delivery would then be due under the terms of this CONTRACT.
 
2.  
INSUFFICIENT SPEED
 
 
(a)  
The CONTRACT PRICE of the VESSEL shall not be affected or changed, if the actual speed, as determined by trial runs more fully described in Article VI hereof, is less than the speed required under the terms of this CONTRACT and the SPECIFICATIONS provided such deficiency in actual speed is not more than three-tenths (3/10) of a knot below the guaranteed speed.
 
 
(b)  
However, commencing with and including a deficiency of more than three-tenths (3/10) of a knot in actual speed below the speed guaranteed under this CONTRACT, the CONTRACT PRICE shall be reduced for each full one tenth (1/10) of a knot in excess of the said three tenths (3/10) of a knot of deficiency in speed [fractions of less than one-tenth (1/10) of a knot shall be regarded as a full one-tenth (1/10) of a knot] as follows.
 
 
5

 
 
For three tenths (3/10) of a knot
a total sum of US$60,000.-
 
For four tenths (4/10) of a knot
a total sum of US$120,000.-
 
For five tenths (5/10) of a knot
a total sum of US$180,000.-
 
For six tenths (6/10) of a knot
a total sum of US$240,000.-
 
For seven tenths (7/10) of a knot
a total sum of US$300,000.-
 
For eight tenths (8/10) of a knot
a total sum of US$360,000.-
 
For nine tenths (9/10) of a knot
a total sum of US$420,000.-
 
For one (1) knot
a total sum of US$480,000.-
     
  The above figures are not cumulative.   
 
  However, unless the parties agree otherwise, the total amount of reduction from the CONTRACT PRICE shall not exceed the amount due to cover the deficiency of one (1) full knot below the guaranteed speed at the rate of reduction as specified above. 
 
 
(c)  
If the deficiency in actual speed of the VESSEL is more than one (1) full knot below the speed guaranteed under this CONTRACT, then the BUYER, at its option, may, subject to the BUILDER’s right to effect alterations or corrections as provided in Article VI.5. hereof, cancel this CONTRACT or may accept the VESSEL at a reduction in the CONTRACT PRICE as above provided for one (1) full knot of deficiency only.
 
3.  
EXCESSIVE FUEL CONSUMPTION
 
 
(a)  
The CONTRACT PRICE shall not be affected or changed by reason of the fuel consumption of the VESSEL’s main engine, as determined by the engine manufacturer’s shop trial as per the SPECIFICATIONS being more than the guaranteed fuel consumption of the VESSEL’s main engine, if such excess is not more than five per cent (5%) over the guaranteed fuel consumption.
 
 
(b)  
However, as for the excess of more than five per cent (5%) in the actual fuel consumption over the guaranteed fuel consumption of the VESSEL’s main engine, the CONTRACT PRICE shall be reduced by U.S. Dollars Seventy Thousand (US$70,000.-) for each full one per cent (1%) increase in fuel consumption in excess of the said five per cent (5%) increase in fuel consumption [fractions of less than one per cent (1%) shall be regarded as a full one per cent (1%)]. However, unless the parties agree otherwise, the total amount of reduction from the CONTRACT PRICE shall not exceed the amount due to cover the excess of ten per cent (10%) over the guaranteed fuel consumption of the VESSEL’s main engine at the rate of reduction as specified above.
 
 
(c)  
If such actual fuel consumption exceeds the guaranteed fuel consumption of the VESSEL’s main engine by more than ten per cent (10%), the BUYER, at its option, may, subject to the BUILDER’s right to effect alterations or corrections as specified in Article VI.5. hereof, cancel this CONTRACT or may accept the VESSEL at a reduction in the CONTRACT PRICE as above provided for the ten per cent (10%) increase only.
 
4.  
DEADWEIGHT BELOW CONTRACT REQUIREMENTS
 
 
(a)  
The CONTRACT PRICE of the VESSEL shall not be affected or changed, if actual deadweight, determined as provided in this CONTRACT and the SPECIFICATIONS, is below the deadweight of 170,500 metric tons on the moulded scantling draft of 17.8 meters required by this CONTRACT and the SPECIFICATIONS by an amount of 1,500 metric tons or less. However, should the deficiency in the actual deadweight of the VESSEL be more than 1,500 metric tons below the said required deadweight, then the CONTRACT PRICE of the VESSEL shall be reduced for each full one (1) metric ton [fractions of less than one (1) metric ton shall be disregarded] of decreased deadweight in excess of 1,500 metric tons by the sum of U.S. Dollars Five Hundred (US$500.-) per metric ton.
 
 
6

 
 
    However, unless the parties agree otherwise, the total amount of deduction from the CONTRACT PRICE shall not exceed the amount due to cover the deficiency of 3,500 metric tons below the said required deadweight hereinabove. 
 
 
(b)  
If the deficiency in the deadweight of the VESSEL is more than 3,500 metric tons below the said required deadweight, then the BUYER, at its option, may, subject to the BUILDER’s right to effect alterations or corrections without the BUYER’s prior consent as specified in Article VI.5. hereof, cancel this CONTRACT or may accept the VESSEL at a reduction in the CONTRACT PRICE as above provided for 3,500 metric tons of deficiency only.
 

 
7

 

EFFECT OF CANCELLATION
 
It is expressly understood and agreed by the parties hereto that in any case, if the BUYER cancels this CONTRACT under this Article, the BUYER shall not be entitled to any liquidated damages.
 
 
(End of Article)

 
8

 

 

ARTICLE IV — INSPECTION AND APPROVAL
 

1.  
APPOINTMENT OF THE BUYER’S REPRESENTATIVE
 
The BUYER shall timely despatch to and maintain at the SHIPYARD, at its own cost, expense and risk, one or more representatives (hereinafter called the “BUYER’S REPRESENTATIVE”), who shall be duly accredited in writing by the BUYER to supervise adequately the construction by the BUILDER of the VESSEL, her equipment and all accessories. Before the commencement of any item of work under this CONTRACT, the BUILDER shall, whenever reasonably required, previously exhibit, furnish to, and within the limits of the BUYER’S REPRESENTATIVE’s authority, secure the approval from the BUYER’S REPRESENTATIVE of any and all plans and drawings prepared in connection therewith. Upon appointment of the BUYER’S REPRESENTATIVE, the BUYER shall notify the BUILDER in writing of the name and the scope of the authority of the BUYER’S REPRESENTATIVE.
 
2.  
AUTHORITY OF THE BUYER’S REPRESENTATIVE
 
Such BUYER’S REPRESENTATIVE shall, at all times during working hours of the construction until delivery of the VESSEL, have the right to inspect the VESSEL, her equipment and all accessories, and work in progress, or materials utilized in connection with the construction of the VESSEL, wherever such work is being done or such materials are stored, for the purpose of determining that the VESSEL, her equipment and accessories are being constructed in accordance with the terms of this CONTRACT and/or the SPECIFICATIONS and the PLAN.
 
The BUILDER will endeavor to arrange for the inspection by the BUYER’S REPRESENTATIVE during working hours of the BUILDER. However, such inspection may be arranged beyond the BUILDER’s normal working hours, including weekend and/or holiday if this is considered necessary by the BUILDER in order to meet the BUILDER’s construction schedule, on the condition that the BUILDER will inform the BUYER’S REPRESENTATIVE at least three (3) days in advance of such inspection.
 
The BUYER’S REPRESENTATIVE shall, within the limits of the authority conferred upon him by the BUYER, make decisions or give advice to the BUILDER on behalf of the BUYER promptly on all problems arising out of, or in connection with, the construction of the VESSEL and generally act in a reasonable manner with a view to cooperating to the utmost with the BUILDER in the construction process of the VESSEL.
 
The decision, approval or advice of the BUYER’S REPRESENTATIVE shall be deemed to have been given by the BUYER and once given shall not be withdrawn, revoked or modified except with consent of the BUILDER. Provided that the BUYER’S REPRESENTATIVE or his assistants shall comply with the foregoing obligations, no act or omission of the BUYER’S REPRESENTATIVE or his assistants shall, in any way, diminish the liability of the BUILDER under Article IX (WARRANTY OF QUALITY). The BUYER’S REPRESENTATIVE shall notify the BUILDER promptly in writing of his discovery of any construction or materials, which he believes do not or will not conform to the requirements of the CONTRACT and the SPECIFICATIONS or the PLAN and likewise advise and consult with the BUILDER on all matters pertaining to the construction of the VESSEL, as may be required by the BUILDER, or as he may deem necessary.
 
However, if the BUYER’S REPRESENTATIVE fails to submit to the BUILDER without delay any such demand concerning alterations or changes with respect to the construction, arrangement or outfit of the VESSEL, which the BUYER’S REPRESENTATIVE has examined, inspected or attended at the test thereof under this CONTRACT or the SPECIFICATIONS, the BUYER’S REPRESENTATIVE shall be deemed to have approved the same and shall be precluded from making any demand for alterations, changes, or complaints with respect thereto at a later date,
 
 
9

 
The BUILDER shall comply with any such demand which is not contradictory to this CONTRACT and the SPECIFICATIONS or the PLAN, provided that any and all such demands by the BUYER’S REPRESENTATIVE with regard to construction, arrangement and outfit of the VESSEL shall be submitted in writing to the authorised representative of the BUILDER. The BUILDER shall notify the BUYER’S REPRESENTATIVE of the names of the persons who are from time to time authorised by the BUILDER for this purpose.
 
It is agreed upon between the BUYER and the BUILDER that the modifications, alterations or changes and other measures necessary to comply with such demand may be effected at a convenient time and place at the BUILDER’s reasonable discretion in view of the construction schedule of the VESSEL.
 
In the event that the BUYER’S REPRESENTATIVE shall advise the BUILDER that he has discovered or believes the construction or materials do not or will not conform to the requirements of this CONTRACT and the SPECIFICATIONS or the PLAN, and the BUILDER shall not agree with the views of the BUYER’S REPRESENTATIVE in such respect, either the BUYER or the BUILDER may, with the agreement of the other party, seek an opinion of the CLASSIFICATION SOCIETY or failing such agreement, request an arbitration in accordance with the provisions of Article XIII hereof. The CLASSIFICATION SOCIETY or the arbitration tribunal, as the case may be, shall determine whether or not a nonconformity with the provisions of this CONTRACT, the SPECIFICATIONS and the PLAN exists. If the CLASSIFICATION SOCIETY or the arbitration tribunal, as the case may be, enters a determination in favour of the BUYER, then in such case the BUILDER shall make the necessary alterations or changes, or if such alterations or changes cannot be made in time to meet the construction schedule for the VESSEL, the BUILDER shall make fair and reasonable adjustment of the CONTRACT PRICE in lieu of such alterations and changes. If the CLASSIFICATION SOCIETY or the arbitration tribunal, as the case may be, enters a determination in favour of the BUILDER, then the time for delivery of the VESSEL shall be extended for the period of delay in construction, if any, occasioned by such proceedings, and the BUYER shall compensate the BUILDER for the proven loss and damages incurred by the BUILDER as a result of the dispute herein referred to.
 
3.  
APPROVAL OF DRAWINGS
 
 
(a)  
The BUILDER shall submit to the BUYER three (3) copies of each of the plans and drawings to be submitted to the BUYER for its approval at its address as set forth in Article XVIII hereof. The BUYER shall, within fourteen (14) days after receipt thereof return to the BUILDER one (1) copy of such plans and drawings with the approval or comments, if any, of the BUYER. A list of the plans and drawings to be so submitted to the BUYER shall be mutually agreed upon between the parties hereto.
 
 
(b)  
When and if the BUYER’S REPRESENTATIVE shall have been sent by the BUYER to the SHIPYARD in accordance with Paragraph 1 of this Article, the BUILDER may submit the remainder, if any, of the plans and drawings in the agreed list, to the BUYER’S REPRESENTATIVE for his approval, unless otherwise agreed upon between the parties hereto.
 
    The BUYER’S REPRESENTATIVE shall, within seven (7) days after receipt thereof, return to the BUILDER one (1) copy of such plans and drawings with his approval or comments written thereon, if any. Approval by the BUYER’S REPRESENTATIVE of the plans and drawings duly submitted to him shall be deemed to be the approval by the BUYER for all purposes of this CONTRACT, 
 
 
(c)  
In the event that the BUYER or the BUYER’S REPRESENTATIVE shall fail to return the plans and drawings to the BUILDER within the time limit as hereinabove provided, such plans and drawings shall be deemed to have been automatically approved without any comment. In the event the plans and drawings submitted by the BUILDER to the BUYER or the BUYER’S REPRESENTATIVE in accordance with this Article do not meet with the BUYER’s or the BUYER’S REPRESENTATIVE’s approval, the matter may be submitted by either party hereto for determination pursuant to Article XIII hereof. If the BUYER’s comments on the plans and drawings that are returned to the BUILDER by the BUYER within the said time limit are not clearly specified or detailed, the BUILDER shall be entitled to place its own interpretation on such comments in implementing them.
 
 
10

 
4.  
SALARIES AND EXPENSES
 
All salaries and expenses of the BUYER’S REPRESENTATIVE or any other person or persons employed by the BUYER hereunder shall be for the BUYER’s account.
 
5.  
RESPONSIBILITY OF THE BUILDER
 
 
(a)  
The BUILDER shall provide the BUYER’S REPRESENTATIVE and his assistants free of charge with suitably furnished office space at, or in the immediate vicinity of, the SHIPYARD together with access to telephone and facsimile facilities as may be necessary to enable the BUYER’S REPRESENTATIVE and his assistants to carry out their work under this CONTRACT. However, the BUYER shall pay for the telephone or facsimile facilities used by the BUYER’S REPRESENTATIVE or his assistants.
 
    The BUILDER, its employees, agents and subcontractors, during its working hours until delivery of the VESSEL, shall arrange for them to have free and ready access to the VESSEL, her equipment and accessories, and to any other place (except the areas controlled for the purpose of national security) where work is being done, or materials arc being processed or stored in connection with the construction of the VESSEL including the premises of sub-contractors. 
 
    The BUYER’S REPRESENTATIVE or his assistants or employees shall observe the work’s rules, regulations and the guidances prevailing at the BUILDER’s and its sub-contractor’s premises. The BUILDER shall promptly provide to the BUYER’S REPRESENTATIVE and/or his assistants and shall ensure that its sub-contractors shall promptly provide all such information as he or they may reasonably request in connection with the construction of the VESSEL and her engines, equipment and machinery. 
 
 
(b)  
The BUYER’S REPRESENTATIVE and his assistants shall at all times remain the employees of the BUYER. The BUILDER shall not be liable to the BUYER or the BUYER’S REPRESENTATIVE or to his assistants or to the BUYER’s employees or agents for personal injuries, including death, during the time they, or any of them, are on the VESSEL, or within the premises of either the BUILDER or its sub-contractors, or are otherwise engaged in and about the construction of the VESSEL, unless, however, such personal injuries, including death, are caused by the gross negligence of the BUILDER, its sub-contractors, or its or their employees or agents. The BUILDER shall not be liable to the BUYER for damages to, or destruction of property of the BUYER or of the BUYER’S REPRESENTATIVE or his assistants or the BUYER’s employees or agents, unless such damages, loss or destruction is caused by the gross negligence of the BUILDER, its sub-contractors, or its or their employees or agents.
 
6.  
RESPONSIBILITY OF THE BUYER
 
The BUYER shall undertake and assure that the BUYER’S REPRESENTATIVE and his assistants shall carry out their duties hereunder in accordance with the normal shipbuilding practice and SHIPYARD quality standard and in such a way as to avoid any unnecessary increase in building cost, delay in the construction of the VESSEL, and/or any disturbance in the construction schedule of the BUILDER.
 

 
11

 

The BUILDER has the right to request the BUYER to replace any of the BUYER’S REPRESENTATIVE and/or his assistants who are deemed unsuitable and unsatisfactory for the proper progress of the VESSEL’s construction.
 
 
(End of Article)

 
12

 

 

ARTICLE V - MODIFICATIONS, CHANGES AND EXTRAS
 

1.  
HOW EFFECTED
 
Minor modifications or changes to the SPECIFICATIONS and the PLAN under which the VESSEL is to be constructed may be made at any time hereafter by written agreement of the parties hereto. Any modification or change requested by the BUYER which does not affect the frame-work of the SPECIFICATIONS shall be agreed to by the BUILDER if the BUYER agrees to adjustment of the CONTRACT PRICE, deadweight and/or cubic capacity, speed requirements, the Delivery Date and other terms and conditions of this CONTRACT reasonably required as a result of such modification or change. The BUILDER has the right to continue construction of the VESSEL on the basis of the SPECIFICATIONS and the PLAN until the BUYER has agreed to such adjustments. The BUILDER shall be entitled to refuse to make any alteration, change or modification of the SPECIFICATIONS and/or the PLAN requested by the BUYER, if the BUYER does not agree to the aforesaid adjustments within seven (7) days of the BUILDER’s notification of the same to the BUYER, or, if, in the BUILDER’s judgement, the compliance with such request of the BUYER would cause an unreasonable disruption of the normal working schedule of the SHIPYARD.
 
The BUILDER, however, agrees to exert its efforts to accommodate such reasonable request by the BUYER so that the said change and modification shall be made at a reasonable cost and within the shortest period of time reasonably possible. The aforementioned agreement to modify and change the SPECIFICATIONS and the PLAN may be effected by exchange of letters or facsimiles manifesting the agreement.
 
The letters and facsimiles exchanged by the parties pursuant to the foregoing shall constitute an amendment to this CONTRACT and the SPECIFICATIONS or the PLAN under which the VESSEL shall be built. Upon consummation of such an agreement to modify and change the SPECIFICATIONS or the PLAN, the BUILDER shall alter the construction of the VESSEL in accordance therewith including any addition to, or deduction from, the work to be performed in connection with such construction.
 
2.  
SUBSTITUTION OF MATERIAL
 
If any materials, machinery or equipment required for the construction of the VESSEL by the SPECIFICATIONS and the PLAN or otherwise under this CONTRACT can not be procured in time to meet the BUILDER’s construction schedule for the VESSEL, or are in short supply, or are unreasonably high in price compared with the prevailing international market price, the BUILDER may supply, subject to the BUYER’s prior approval, other materials, machinery or equipment of equal quality and effect capable of meeting the requirements of the CLASSIFICATION SOCIETY and the rules, regulations and requirements with which the construction of the VESSEL must comply.
 
3.  
CHANGES IN RULES AND REGULATIONS
 
If the specified rules and regulations with which the construction of the VESSEL is required to comply are altered or changed by the CLASSIFICATION SOCIETY or bodies authorised to make such alterations or changes after the CONTRACT date, either the BUYER or the BUILDER, upon receipt of due notice thereof, shall forthwith give notice thereof to the other party in writing. Thereupon, within ten (10) days after giving the notice to the BUILDER or receiving the notice from the BUILDER, the BUYER shall advise the BUILDER as to the alterations and changes, if any, to be made on the VESSEL which the BUYER, in its sole discretion, shall decide. The BUILDER shall not be obliged to comply with such alterations and/or changes if the BUYER fails to notify the BUILDER of its decision within the time limit stated above,
 
The BUILDER shall comply promptly with the said request of the BUYER, provided that the BUILDER and the BUYER shall first agree to :
 
 
13

 
 
(a)  
any increase or decrease in the CONTRACT PRICE of the VESSEL that is occasioned by such compliance ;
 
 
(b)  
any extension or advancement in the Delivery Date of the VESSEL that is occasioned by such compliance ;
 
 
(c)  
any increase or decrease in the deadweight and/or cubic capacity of the VESSEL, if such compliance results in any increase or reduction in the deadweight and/or cubic capacity ;
 
 
(d)  
adjustment of the speed requirements if such compliance results in any increase or reduction in the speed ; and
 
 
(e)  
any other alterations in the terms of this CONTRACT or of the SPECIFICATIONS or the PLAN or both, if such compliance makes such alterations of the terms necessary.
 
Any delay in the construction of the VESSEL caused by the BUYER’s delay in making a decision or agreement as above shall constitute a permissible delay under this CONTRACT. Such agreement by the BUYER shall be effected in the same manner as provided above for modification and change of the SPECIFICATIONS and the PLAN.
 
 
(End of Article)

 
14

 

 

ARTICLE VI - TRIALS AND COMPLETION
 

1.  
NOTICE
 
The BUILDER shall notify the BUYER in writing or by facsimile at least fourteen (14) days in advance of the time and place of the trial run of the VESSEL. Such notice shall specify the place from which the VESSEL will commence her trial run and approximate date upon which the trial run is expected to take place. Such date shall be further confirmed by the BUILDER five (5) days in advance of the trial run in writing or by facsimile.
 
The BUYER’S REPRESENTATIVE, who is to witness the performance of the VESSEL during such trial run, shall be present at such place on the date specified in such notice. Should the BUYER’S REPRESENTATIVE fail to be present after the BUILDER’s due notice to the BUYER as provided above, the BUILDER shall be entitled to conduct such trial run with the presence of the representative(s) of the CLASSIFICATION SOCIETY only without the BUYER’S REPRESENTATIVE being present. In such case, the BUYER shall be obliged to accept the VESSEL on the basis of a certificate issued by the BUILDER that the VESSEL, after the trial run, subject to alterations and corrections, if necessary, has been found to conform with the SPECIFICATIONS and this CONTRACT and is satisfactory in all respects, provided the BUILDER first makes such corrections and alterations promptly.
 
2.  
WEATHER CONDITION
 
In the event of unfavourable weather on the date specified for the trial run, the trial run shall take place on the first available day that weather conditions permit. The parties hereto recognize that the weather conditions in Korean waters, in which the trial run is to take place, are such that great changes in weather may arise momentarily and without warning and therefore, it is agreed that if, during the trial run, the weather should become so unfavourable that the trial run cannot be continued, then the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent to the acceptance of the VESSEL by notification in writing on the basis of such trial run so far made prior to such change in weather conditions. Any delay of the trial run caused by such unfavourable weather conditions shall also operate to extend the Delivery Date of the VESSEL for the period of delay occasioned by such unfavourable weather conditions.
 
3.  
HOW CONDUCTED
 
All expenses in connection with the trials of the VESSEL are to be for the account of the BUILDER, which, during the trials, is to provide at its own expense the necessary crew to comply with conditions of safe navigation. The trials shall be conducted in the manner prescribed in this CONTRACT and the SPECIFICATIONS, and shall prove fulfilment of the performance requirements for the trials as set forth in the SPECIFICATIONS.
 
The BUILDER shall be entitled to conduct preliminary sea trials, during which the propulsion plant and/or its appurtenance shall be adjusted according to the BUILDER’s judgement. The BUILDER shall have the right to repeat any trial whatsoever as it deems necessary.
 
4.  
CONSUMABLE STORES
 
The BUILDER shall load the VESSEL with the required quantity of fuel oil, lubricating oil, hydraulic oil and greases, fresh water, and other stores necessary to conduct the trials as set forth in the SPECIFICATIONS. The necessary ballast (fuel oil, fresh water and such other ballast as may be required) to bring the VESSEL to the trial load draft, as specified in the SPECIFICATIONS, shall be supplied and paid for by the BUILDER whilst lubricating oil and greases shall be supplied and paid for by the BUYER within the time advised by the BUILDER for the conduct of sea trials as well as for use before the delivery of the VESSEL to the BUYER. The fuel oil as well as lubricating oil and greases shall be in accordance with the specifications of the main engine and other machinery and the BUYER shall decide and advise the BUILDER of the supplier’s name for lubricating oil, hydraulic oil and greases before the work-commencement of the VESSEL, provided that the supplier shall be acceptable to the BUILDER and/or the makers of all the machinery,
 
 
15

 
Any fuel oil, fresh water or other consumable stores furnished and paid for by the BUILDER for trial runs remaining on board the VESSEL, at the time of acceptance of the VESSEL by the BUYER, shall be bought by the BUYER from the BUILDER at the BUILDER’s purchase price for such supply in Korea and payment by the BUYER thereof shall be made at the time of delivery of the VESSEL. The BUILDER shall pay the BUYER at the time of delivery of the VESSEL for the consumed quantity of any lubricating oil, hydraulic oil and greases which were furnished and paid for by the BUYER at the BUYER’s purchase price thereof. The consumed quantity of lubricating oils, hydraulic oil and greases shall be calculated on the basis of the difference between the remaining amount, including the same remaining in the main engine, other machinery and their pipes, stern tube and the like, and the supplied amount.
 
5.  
ACCEPTANCE OR REJECTION
 
 
(a)  
If, during any sea trial, any breakdown occurs entailing interruption or irregular performance which can be repaired on board, the trial shall be continued after such repairs and be valid in all respects.
 
 
(b)  
However, if, during or after the trial run, it becomes apparent that the VESSEL or any part of her equipment requires alterations or corrections which but for this provision would or might entitle the BUYER to cancel this CONTRACT, the BUILDER shall notify the BUYER promptly in writing or by facsimile to such effect and shall simultaneously advise the BUYER of the estimated additional time required for the necessary alterations or corrections to be made.
 
    The BUYER shall, within three (3) days of receipt from the BUILDER of notice of completion of such alterations or corrections and after such further trials or tests as necessary, notify the BUILDER in writing or by facsimile confirmed in writing of its acceptance, qualified acceptance or rejection of the VESSEL, all in accordance with the SPECIFICATIONS, the PLAN and this CONTRACT, and shall not be entitled to reject the VESSEL on such grounds until such time. 
 
 
(c)  
Save as above provided, the BUYER shall, within two (2) days after completion of the trial run, notify the BUILDER in writing or by facsimile confirmed in writing of its acceptance of the VESSEL or of the details in respect of which the VESSEL does not conform to the SPECIFICATIONS or this CONTRACT.
 
    If the BUILDER is in agreement with the BUYER’s determinations as to non-conformity, the BUILDER shall make such alterations or changes as may be necessary to correct such non-conformity and shall prove the fulfilment of this CONTRACT and the SPECIFICATIONS by such tests or trials as may be necessary. 
 
    The BUYER shall, within two (2) days after completion of such tests and/or trials, notify the BUILDER in writing or by facsimile confirmed in writing of its acceptance or rejection of the VESSEL. 
 
 
(d)  
However, the BUYER shall not be entitled to reject the VESSEL by reason of any minor or insubstantial items judged from the point of view of standard shipbuilding and shipping practice as not being in conformity with the SPECIFICATIONS, but, in that case, the BUILDER shall not be released from the obligation to correct and/or remedy such minor or insubstantial items as soon as practicable after the delivery of the VESSEL.
 
 
16

 
6.  
EFFECT OF ACCEPTANCE
 
The BUYER’s written or facsimiled notification of acceptance delivered to the BUILDER as above provided, shall be final and binding insofar as conformity of the VESSEL with the SPECIFICATIONS is concerned and shall preclude the BUYER from refusing formal delivery of the VESSEL as hereinafter provided, if the BUILDER complies with all conditions of delivery, as herein set forth and provided that, in the case of qualified acceptance, any matters which were mentioned in the notice of the qualified acceptance by the BUYER as requiring correction have been corrected satisfactorily.
 
If the BUYER fails to notify the BUILDER of its acceptance or rejection of the VESSEL as hereinabove provided, the BUYER shall be deemed to have accepted the VESSEL. Nothing contained in this Article shall preclude the BUILDER from exercising any and all rights which the BUILDER has under this CONTRACT if the BUILDER disagrees with the BUYER’s rejection of the VESSEL or any reasons given for such rejection, including arbitration provided in Article XIII hereof.
 
 
(End of Article)

 
17

 

 

ARTICLE VII – DELIVERY
 

1.  
TIME AND PLACE
 
The VESSEL shall be delivered by the BUILDER to the BUYER at the SHIPYARD, safely afloat on or before 30th September, 2009 (hereinafter called the “DELIVERY DATE”) after completion of satisfactory trials and acceptance by the BUYER in accordance with the terms of Article VI, except that, in the event of delays in delivery of the VESSEL by the BUILDER due to causes which under the terms of this CONTRACT permit extensions of the time for delivery of the VESSEL, the aforementioned DELIVERY DATE shall be extended accordingly.
 
2.  
WHEN AND HOW EFFECTED
 
Provided that the BUYER shall concurrently with delivery of the VESSEL release to the BUILDER the fifth instalment as set forth in Article X.2 hereof and shall have fulfilled all of its obligations provided for in this CONTRACT, delivery of the VESSEL shall be forthwith effected upon acceptance thereof by the BUYER, as hereinabove provided, by the concurrent delivery by each of the parties hereto to the other of a PROTOCOL OF DELIVERY AND ACCEPTANCE acknowledging delivery of the VESSEL by the BUILDER and acceptance thereof by the BUYER, which PROTOCOL shall be prepared in duplicate and signed by each of the parties hereto.
 
3.  
DOCUMENTS TO BE DELIVERED TO THE BUYER
 
Upon delivery and acceptance of the VESSEL, the BUILDER shall deliver to the BUYER the following documents, which shall accompany the aforementioned PROTOCOL OF DELIVERY AND ACCEPTANCE :
 
 
(a)  
PROTOCOL OF TRIALS of the VESSEL made pursuant to this CONTRACT and the SPECIFICATIONS,
 
 
(b)  
PROTOCOL OF INVENTORY of the equipment of the VESSEL, including spare parts, all as specified in the SPECIFICATIONS,
 
 
(c)  
PROTOCOL OF DEADWEIGHT DETERMINATION AND INCLINING EXPERIMENT.
 
 
(d)  
PROTOCOL OF STORES OF CONSUMABLE NATURE, such as all fuel oil and fresh water remaining in tanks if its cost is charged to the BUYER under Article VI.4. hereof,
 
 
(e)  
DRAWINGS AND PLANS pertaining to the VESSEL as stipulated in the SPECIFICATIONS, which shall be furnished to the BUYER at no additional cost,
 
 
(f)  
ALL CERTIFICATES required to be furnished upon delivery of the VESSEL pursuant to this CONTRACT, the SPECIFICATIONS and the customary shipbuilding practice, including
 
 
(i)  
Classification Certificate
 
 
(ii)  
Safety Construction Certificate
 
 
(iii)  
Safety Equipment Certificate
 
 
(iv)  
Safety Radio Certificate
 
 
18

 
 
(v)  
International Loadline Certificate
 
 
(vi)  
International Tonnage Certificate
 
 
(vii)  
BUILDER’s Certificate
 
 
(viii)  
De-ratting Exemption Certificate
 
 
(ix)  
International Oil Pollution Prevention Certificate
 
 
(x)  
Deadweight Certificate
 
 
(xi)  
Certificate for Life Boats and Life Saving Equipments
 
    However, it is agreed by the parties that if the Classification Certificate and/or other certificates are not available at the time of delivery of the VESSEL, provisional certificates shall be accepted by the BUYER, provided that the BUILDER shall furnish the BUYER with formal certificates as promptly as possible after such formal certificates have been issued. 
 
 
(g)  
DECLARATION OF WARRANTY of the BUILDER that the VESSEL is delivered to the BUYER free and clear of any liens, claims, mortgages, or other encumbrances upon the BUYER’S title thereto, and in particular, that the VESSEL is absolutely free of all burdens in the nature of imposts, taxes, or charges imposed by the prefecture or country of the port of delivery, as well as of all liabilities of the BUILDER to its sub-contractors and employees and of all liabilities arising from the operation of the VESSEL in trial runs, or otherwise, prior to delivery except as otherwise provided under this CONTRACT.
 
 
(h)  
COMMERCIAL INVOICE.
 
 
(i)  
BILL OF SALE.
 
4.  
TENDER OF THE VESSEL
 
If the BUYER fails to take delivery of the VESSEL after completion thereof according to this CONTRACT and the SPECIFICATIONS, the BUILDER shall have the right to tender delivery of the VESSEL after compliance with all procedural requirements as provided above.
 
5.  
TITLE AND RISK
 
Title and risk shall pass to the BUYER upon delivery of the VESSEL being effected as stated above and the BUILDER shall be free of all responsibility or liability whatsoever related with this CONTRACT except for the warranty of quality contained in Article IX and the obligation to correct and/or remedy, as provided in Article VI. 5. (d), if any, it being expressly understood that, until such delivery is effected, the VESSEL and equipment thereof are at the entire risk of the BUILDER including but not confined to, risks of war, insurrection and seizure by Governments or Authorities, whether Korean or foreign, and whether at war or at peace. The title to the BUYER’s supplies as provided in Article XII shall remain with the BUYER and the BUILDER’s responsibility for such BUYER’s supplies shall be as described in Article XII.2.
 
6.  
REMOVAL OF THE VESSEL
 
The BUYER shall take possession of the VESSEL immediately upon delivery thereof and shall remove the VESSEL from the SHIPYARD within three (3) days after delivery thereof is effected. Port dues and other charges levied by the Korean Government Authorities after delivery of the VESSEL and any other costs related to the removal of the VESSEL shall be borne by the BUYER.
 
 
19

 

(End of Article)

 
20

 


ARTICLE VIII - DELAYS AND EXTENSIONS OF TIME (FORCE MAJEURE)
 

1.  
CAUSES OF DELAY
 
If at any time after signing this CONTRACT, either the construction or delivery of the VESSEL or any performance required hereunder as a prerequisite to the delivery thereof is delayed by any of the following events; namely war involving Korea, acts of state or government, blockade, revolution, insurrections, mobilization, civil commotion, riots, strikes, sabotage, lockouts, Acts of God or the public enemy, plague or other epidemics, quarantines, shortage or prolonged failure of electric current, freight embargoes, or delays in delivery of materials, machinery or equipment or hull blocks or outfitting works , provided that at the time of ordering the same could reasonably be expected by the BUILDER to be delivered in time or defects in materials, machinery or equipment which could not have been detected by the BUILDER using reasonable care or earthquakes, tidal waves, typhoons, hurricanes, prolonged or unusually severe weather conditions or destruction of the premises or works of the BUILDER or its sub-contractors, or of the VESSEL, or any part thereof, by fire, landslides, flood, lightning, explosion which in turn delay the construction of the VESSEL or the BUILDER’s performance under the CONTRACT, or delays caused by the CLASSIFICATION SOCIETY or the BUYER’s faulty action or omission, or for any other causes which, under the terms of this CONTRACT, authorise and permit extension of the time for delivery of the VESSEL, then, in the event of delays due to the happening of any of the aforementioned contingencies, the DELIVERY DATE of the VESSEL under this CONTRACT shall be extended for a period of time which shall not exceed the total accumulated time of all such delays.
 
2.  
NOTICE OF DELAYS
 
As soon as practicably possible after commencement of any delay on account of which the BUILDER claims that it is entitled under this CONTRACT to an extension of the DELIVERY DATE of the VESSEL, excluding delays due to arbitration, the BUILDER shall advise the BUYER in writing or by facsimile of the date such delay commenced, the reasons thereof and, if possible, its estimated duration of the probable delay in the delivery of the VESSEL, and shall supply the BUYER if reasonably available with relevant information or evidence to justify the delay claimed, Within one (1) week after such delay ends, the BUILDER shall likewise advise the BUYER in writing or by facsimile of the date that such delay ended, and also, shall specify the period of time by which the BUILDER claims the DELIVERY DATE should be extended by reason of such delay. Failure of the BUYER to object to the BUILDER’s notification of any claim for extension of the date for delivery of the VESSEL within one (1) week after receipt by the BUYER of such notification shall be deemed to be a waiver by the BUYER of its right to object to such extension.
 
3.  
RIGHT TO CANCEL FOR EXCESSIVE DELAY
 
If the total accumulated time of all permissible and non-permissible delays, excluding delays due to (i) arbitration under Article XIII, (ii) the BUYER’s defaults under Article XI, (iii) modifications and changes under Article V or (iv) delays or defects in the BUYER’s supplies as stipulated in Article XII, aggregates three hundred and sixty-five (365) days or more, then, the BUYER may, at any time thereafter, cancel this CONTRACT by giving a written notice of cancellation to the BUILDER. Such cancellation shall be effective as of the date the notice thereof is received by the BUILDER.
 
If the BUYER has not served the notice of cancellation as provided in the above or Article III.1 hereof, the BUILDER may, at any time after expiration of the accumulated time of the delay in delivery, either three hundred and sixty-five (365) days in case of the delay in this Paragraph or two hundred and ten (210) days in case of the delay in Article III.1, notify the BUYER of the future date upon which the BUILDER estimates the VESSEL will be ready for delivery and demand in writing or by facsimile that the BUYER make an election either to cancel this CONTRACT or to consent to the delivery of the VESSEL at such future date, in which case the BUYER shall, within seven (7) days after receipt of such demand, make and notify the BUILDER of such election. If the BUYER elects to consent to the delivery of the VESSEL at such future date (or other future date as the parties may agree):
 
 
21

 
 
(a)  
Such future date shall become the contractual delivery date for the purposes of this CONTRACT and shall be subject to extension by reason of permissible delays as herein provided, and
 
 
(b)  
If the VESSEL is not delivered by such revised contractual delivery date (as extended by reason of permissible delays), the BUYER shall have the same right of cancellation upon the same terms as provided in the above and Article III. 1.
 
If the BUYER shall not make an election within seven (7) days as provided hereinabove, the BUYER shall be deemed to have accepted such extension of the DELIVERY DATE to the future delivery date indicated by the BUILDER.
 
4.  
DEFINITION OF PERMISSIBLE DELAYS
 
Delays on account of the foregoing causes shall be understood to be permissible delays, and are to be distinguished from non-permissible unauthorised delays on account of which the CONTRACT PRICE of the VESSEL is subject to adjustment as provided in Article III hereof.
 
 
(End of Article)

 
22

 

 

ARTICLE IX - WARRANTY OF QUALITY
 

1.  
GUARANTEE OF MATERIAL AND WORKMANSHIP
 
The BUILDER, for the period of twelve (12) months from the date of delivery of the VESSEL to the BUYER, guarantees the VESSEL and all parts and equipment thereof that are manufactured or furnished by the BUILDER under this CONTRACT against all defects which are directly due to defective materials, construction miscalculation and/or poor workmanship, provided such defects have not been caused by perils of the sea, rivers or navigations, or by normal wear and tear, overloading, improper loading or stowage, corrosion of the materials, fire, accidents at sea or elsewhere, or by incompetence, mismanagement, negligence or wilful neglect or any alteration or addition to the VESSEL which has not previously been approved by the BUILDER and provided that the cost of repairs of such defects is not recoverable from insurers.
 
The BUILDER will be responsible for all machinery or parts of machinery and all constructions which are supplied by sub-contractors and will guarantee the above mentioned for a period of twelve (12) months on the basis as laid down in this Paragraph.
 
The BUILDER further guarantee any repairs or replacements to the VESSEL made within the Guarantee Period of twelve (12) months by it pursuant to this Article IX for an independent period of twelve (12) months from the date of completion of such repairs or replacements provided that the total accumulated period of guarantee shall not exceed eighteen (18) months from the date of delivery of the VESSEL.
 
2.  
NOTICE OF DEFECTS
 
The BUYER or its duly authorized representative will notify the BUILDER in writing or by e-mail or facsimile promptly after discovery of any defect for which a claim is to be made under this guarantee.
 
The BUYER’s written notice shall include full particulars as to the nature of the defect and the extent of the damage caused thereby, but excluding consequential damage as hereinafter provided. The BUILDER will be under no obligation with respect to this guarantee in respect of any claim for defects discovered prior to the expiry date of the guarantee, unless notice of such defects is received by the BUILDER before the expiry date. However, e-mail or facsimile advice received by the BUILDER within three (3) days after such expiry date that a claim is forthcoming will be sufficient compliance with the requirement as to time, provided that such e-mail or facsimile advice shall include at least a brief description of the defect including the identity of the equipment, extent of damage, name and number of any replacement part and description of any remedial work required, and that full particulars are given to the BUILDER not later than seven (7) days after the expiry date.
 
3.  
REMEDY OF DEFECTS
 
 
(a)  
The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary and reasonably practicable repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow.
 
    In such case, the VESSEL shall be taken at the BUYER’s cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER’s getting and keeping the VESSEL ready for such repairing or replacing. 
 
 
23

 
 
(b)  
However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice in writing or by e-mail or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by e-mail or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER’s acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD.
 
 
(c)  
In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the terms of F.O.B. port of the country where they are to be purchased.
 
 
(d)  
The BUILDER reserves the option to retrieve, at the BUILDER’s cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article.
 
 
(e)  
Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
 
4.  
EXTENT OF THE BUILDER’S LIABILITY
 
 
(a)  
After delivery of the VESSEL the responsibility of the BUILDER in respect of and/or in connection with the VESSEL and/or this CONTRACT shall be limited to the extent expressly provided in the Paragraph of this Article. Except as expressly provided in the foregoing Paragraph, in no circumstances and on no ground whatsoever shall the BUILDER have any responsibility or liability whatsoever or howsoever arising in respect of or in connection with the VESSEL or this CONTRACT after the delivery of the VESSEL. Further, but without in any way limiting the generality of the foregoing, the BUILDER shall have no liability or responsibility whatsoever or howsoever arising for or in connection with any consequential or special losses, damages or expenses (including but not limited to loss of time, loss of profit or earnings or demurrage directly or indirectly caused), any pecuniary loss or expense, any liability to any third party or any fine, compensation, penalty or other payment or sanction incurred by or imposed upon the BUYER or any other party whatsoever in relation to or in connection with this CONTRACT or the VESSEL.
 
 
(b)  
The BUILDER shall be under no obligation with respect to defects in respect of which the BUILDER has not received notice in accordance with Paragraph 2 of this Article by the expiry date of the guarantee specified in Paragraph 1, nor in any event shall the BUILDER be liable for any worsening of the defects after the expiry date of the guarantee.
 
 
(c)  
The BUILDER shall under no circumstances be liable for defects in the VESSEL or any part of equipment thereof caused by perils of the sea, rivers or navigations, or by normal wear and tear, overloading, improper loading or stowage, corrosion of the materials, fire, accidents at sea or elsewhere, or by incompetence, mismanagement, negligence or wilful neglect or any alteration or addition on the part of the BUYER, its employees or agents or any other person on or doing work on the VESSEL, including the VESSEL’s officers, crew and passengers. Likewise, the BUILDER shall not be liable for defects in the VESSEL or any part of equipment thereof that are due to
 
 
24

 
 
    repairs carried out by any other than the BUILDER or which have not been carried out in accordance with the procedure set out in Paragraph 3 (b) of this Article, 
 
 
 
25

 
 
(d)  
The BUILDER shall not be obliged to repair, not be liable for, damage to the VESSEL or any part of the equipment thereof, which after delivery of the VESSEL, is caused other than by the defects of the nature specified in this Article. The guarantees contained as hereinabove in this Article replace and exclude any other liability, guarantee, warranty and/or condition imposed or implied by statute, common law, custom, contract (including this CONTRACT) or otherwise on the part of the BUILDER by reason of the construction and sale of the VESSEL for and to the BUYER or for any other reason whatsoever.
 
(End of Article)

 
26

 


ARTICLE X - PAYMENT
 

1.  
CURRENCY
 
All payments under this CONTRACT shall be made in United States Dollars.
 
2.  
TERMS OF PAYMENT
 
The payments of the CONTRACT PRICE shall be made as follows :
 
 
(a)  
First Instalment
 
    Twenty per cent (20%) of the CONTRACT PRICE amounting to U.S. Dollars Sixteen Million Two Hundred Thousand (US$16,200,000.-) shall be paid within five (5) business days after receipt by the BUYER’s bank of a tested telex or a SWIFT confirmation of the refund guarantor that the Refund Guarantee mentioned in Paragraph 8 of this Article has been issued. 
 
    Under this CONTRACT, in counting the business days, only Saturdays and Sundays are excepted. When a due date falls on a day when banks are not open for business in New York, N.Y., U.S.A. or Oslo, Norway, such due date shall fall due upon the first business day next following. 
 
 
(b)  
Second Instalment
 
    Twenty per cent (20%) of the CONTRACT PRICE amounting to U.S. Dollars Sixteen Million Two Hundred Thousand (US$16,200,000.-) shall be paid within five (5) business days of receipt by the BUYER of an e-mail or a facsimile advice from the BUILDER that the steel cutting of the VESSEL has been commenced. 
 
 
(c)  
Third Instalment
 
    Twenty per cent (20%) of the CONTRACT PRICE amounting to U.S. Dollars Sixteen Million Two Hundred Thousand (US$16,200,000.-) shall be paid within five (5) business days of receipt by the BUYER of an e-mail or facsimile advice from the BUILDER that the first block of the keel has been laid. 
 
 
(d)  
Fourth Instalment
 
    Twenty per cent (20%) of the CONTRACT PRICE amounting to U.S. Dollars Sixteen Million Two Hundred Thousand (US$16,200,000,-) shall be paid within five (5) business days of receipt by the BUYER of an e-mail or a facsimiled advice from the BUILDER that the launching of the VESSEL has been completed. 
 
 
(e)  
Fifth Instalment
 
    Twenty per cent (20%) of the CONTRACT PRICE amounting to U.S. Dollars Sixteen Million Two Hundred Thousand (US$16,200,000.-) plus or minus any increase or decrease due to modifications and/or adjustment, if any, arising prior to delivery of the VESSEL of the CONTRACT PRICE under Articles III and V of this CONTRACT shall be paid to the BUILDER concurrently with the delivery of the VESSEL. (The date stipulated for payment of each of the five instalments mentioned above is hereinafter in this Article and in Article XI referred to as the “DUE DATE” of that instalment). 
 
 
27

 
 
 
It is understood and agreed upon by the BUILDER and the BUYER that all payments under the provisions of this Article shall not be delayed or withheld by the BUYER due to any dispute or disagreement of whatsoever nature arising between the BUILDER and the BUYER. Should there be any dispute in this connection, the matter shall be dealt with in accordance with the provisions of arbitration in Article XIII hereof. Expenses for remitting payments and any other expenses connected with such payments shall be for the account of the BUYER.
 
3.  
DEMAND FOR PAYMENT
 
At least fourteen (14) days prior to the date of each event provided in Paragraph 2 of this Article on which any payment shall fall due hereunder, with the exception of the payment of the first instalment, the BUILDER shall notify the BUYER by e-mail or facsimile of the date such payment shall become due.
 
The BUYER shall immediately acknowledge receipt of such notification by e-mail or facsimile to the BUILDER, and make payment as set forth in this Article. If the BUILDER fails to receive the BUYER’s said acknowledgement within three (3) days after sending the aforementioned notification, the BUILDER shall promptly e-mail or facsimile to the BUYER a second notification of similar import. The BUYER shall immediately acknowledge by e-mail or facsimile receipt of the foregoing second notification regardless of whether or not the first notification was acknowledged as aforesaid.
 
4.  
METHOD OF PAYMENT
 
 
(a)  
All the pre-delivery payments and the payment due on delivery in settlement of the CONTRACT PRICE as provided for in Paragraph 2 of this Article shall be made in U.S. Dollars on or before the DUE DATE thereof by telegraphic transfer as follows;
 
 
(i)  
The payment of the first, second, third and fourth instalments shall be made to the account of XXXXXX Bank (hereinafter called the “BUILDER’s Bank”) (Account No.: XXX-XXXXXX) with XXXXXX Bank as described in the following reference in favor of the BUILDER, as designated and notified by the BUILDER at least three (3) business days prior to the DUE DATE.
 
 
Reference to the BUILDER’s Bank
 
     
 
Name : XXXXXX Bank
Address : XXXXXXXXXX
Telex Number:  XXXXXXXXX
Telefax Number:  XXXXXXXX
Swift Code:  XXXXXXXXXXX
Account Number:  XXX-XXXXXX
Through Bank:  XXXXXX  Bank
 
 
 
(ii)  
The fifth instalment as provided for in Paragraph 2.(e) of this Article shall be deposited at the account of the BUILDER’s Bank or, if the BUILDER requires, at the account of the BUILDER with any other bank by telegraphic transfer remittance at least three (3) business days prior to the scheduled delivery date of the VESSEL notified by the BUILDER, with instructions that the said instalment is payable to the BUILDER against presentation by the BUILDER to the BUILDER’s Bank or any other bank, as the case may be, of a duplicate original copy of the PROTOCOL OF DELIVERY AND ACCEPTANCE of the VESSEL signed by the BUILDER and the BUYER.
 
 
(b)  
Simultaneously with each of such payments, the BUYER shall advise the BUILDER of the details of the payments by e-mail or facsimile and at the same time, the BUYER shall cause the BUYER’s remitting Bank to advise the BUILDER’s Bank of the details of such payments by authenticated bank cable or telex.
 
 
28

 
5.  
REFUND BY THE BUILDER
 
The payments made by the BUYER to the BUILDER prior to delivery of the VESSEL shall constitute advances to the BUILDER. If the VESSEL is rejected by the BUYER in accordance with the terms of this CONTRACT, or except in the case of rescission or cancellation of this CONTRACT by the BUILDER under the provisions of Article XI hereof, if the BUYER terminates, cancels or rescinds this CONTRACT pursuant to any of the provisions of this CONTRACT specifically permitting the BUYER to do so, the BUILDER shall forthwith refund to the BUYER, in U.S. Dollars, the full amount of total sums paid by the BUYER to the BUILDER in advance of delivery together with interest thereon as herein provided.
 
The transfer and other bank charges of such refund shall be for the BUILDER’s account. The interest rate of the refund, as above provided, shall be six per cent (6%) per annum from the date following the date of receipt by the BUILDER of the pre-delivery instalment(s) to the date of remittance by telegraphic transfer of such refund.
 
It is hereby understood by both parties that payment of any interest provided herein is by way of liquidated damages due to cancellation of this CONTRACT and not by way of compensation for use of money.
 
If the BUILDER is required to refund to the BUYER the instalments paid by the BUYER to the BUILDER as provided in this Paragraph, the BUILDER shall return to the BUYER all of the BUYER’s supplies as stipulated in Article XII which were not incorporated into the VESSEL and pay to the BUYER an amount equal to the cost to the BUYER of those supplies incorporated into the VESSEL.
 
6.  
TOTAL LOSS
 
If there is a total loss or a constructive total loss of the VESSEL prior to delivery thereof, the BUILDER shall proceed according to the mutual agreement of the parties hereto either:
 
 
(a)  
to build another vessel in place of the VESSEL so lost and deliver it under this CONTRACT to the BUYER, provided that the parties hereto shall have agreed in writing to a reasonable cost and time for the construction of such vessel in place of the lost VESSEL; or
 
 
(b)  
to refund to the BUYER the full amount of the total sums paid by the BUYER to the BUILDER under the provisions of Paragraph 2 of this Article together with interest thereon at the rate of six per cent (6%) per annum from the date following the date of receipt by the BUILDER of such pre-delivery instalment(s) to the date of payment by the BUILDER to the BUYER of the refund.
 
    If the parties hereto fail to reach such agreement within one (1) month after the VESSEL is determined to be a total loss or constructive total loss, the provisions of (b) hereinabove shall be applied. 
 
7.  
DISCHARGE OF OBLIGATIONS
 
Such refund as provided in the foregoing Paragraphs 5 and 6 by the BUILDER to the BUYER shall forthwith discharge all the obligations, duties and liabilities of each of the parties hereto to the other except the claims of the BUILDER against the BUYER, if any, under this CONTRACT. Any and all refunds or payments due to the BUYER under this CONTRACT shall be effected by telegraphic transfer to the account specified by the BUYER.
 
 
29

 
8.  
REFUND GUARANTEE
 
The BUILDER shall furnish to the BUYER by a tested telex or SWIFT through the BUYER’s bank an assignable letter of guarantee issued by the BUILDER’s Bank for the refund of the pre-delivery instalments plus interest as aforesaid to the BUYER under or pursuant to Paragraph 5 above in the form annexed hereto as Exhibit “A”. All expenses in issuing and maintaining the letter of guarantee described in this Paragraph shall be borne by the BUILDER. In case of SWIFT, the BUYER shall advise the BUILDER of the details of the BUYER’s bank including the SWIFT address upon execution of this CONTRACT.
 
9.  
PERFORMANCE GUARANTEE
 
Upon signing this CONTRACT, the BUYER shall provide the BUILDER with an irrevocable and unconditional Corporate Guarantee issued by a Corporate Guarantor acceptable to the BUILDER for the due and faithful performance by the BUYER of all its liabilities and responsibilities under the CONTRACT including, but not limited to, the payment of the CONTRACT PRICE and taking delivery of the VESSEL, in the form annexed hereto as Exhibit “B”.
 
 
(End of Article)

 
30

 

 

ARTICLE XI - BUYER’S DEFAULT
 

1.  
DEFINITION OF DEFAULT
 
The BUYER shall be deemed to be in default under this CONTRACT in the following cases:
 
 
(a)  
If the first, second, third, or fourth instalment is not paid to the BUILDER within respective DUE DATE of such instalments; or
 
 
(b)  
If the fifth instalment is not deposited at the account of the BUILDER’s Bank or at the account of the BUILDER with any other bank designated by the BUILDER in accordance with Article X.4. (a)(ii) hereof or if the said fifth instalment deposit is not released to the BUILDER against presentation by the BUILDER of a duplicate original copy of the PROTOCOL OF DELIVERY AND ACCEPTANCE; or
 
 
(c)  
If the BUYER fails to take delivery of the VESSEL when the VESSEL is duly tendered for delivery by the BUILDER under the provisions of Article VII hereof; or
 
 
(d)  
If an order or an effective resolution shall be passed for winding up of the BUYER (except for the purpose of reorganization, merger or amalgamation); or
 
 
(e)  
If the BUYER fails to be in punctual, due and full compliance with any of its obligations under this CONTRACT.
 
In case the BUYER is in default of any of its obligations under this CONTRACT, the BUILDER is entitled to and shall have the following rights, powers and remedies in addition to such other rights, powers and remedies as the BUILDER may have elsewhere in this CONTRACT and/or at law, at equity or otherwise.
 
2.  
EFFECT OF THE BUYER’S DEFAULT ON OR BEFORE THE DELIVERY OF THE VESSEL
 
If the BUYER shall be in default as provided in Paragraph 1 above of its obligations under this CONTRACT, then;
 
 
(a)  
The DELIVERY DATE of the VESSEL shall be extended automatically for the actual period of such default and the BUILDER shall not be obliged to pay any liquidated damages for the delay in delivery of the VESSEL caused thereby.
 
 
(b)  
The BUYER shall pay to the BUILDER interest at the rate of six per cent (6%) per annum in respect of the instalment(s) in default from the respective DUE DATE to the date of actual receipt by the BUILDER of the full amount of such instalment(s).
 
 
(c)  
If the BUYER is in default in payment of any of the instalment(s) due and payable prior to or simultaneously with the delivery of the VESSEL, the BUILDER shall, in writing or by facsimile, notify the BUYER to that effect, and the BUYER shall, upon receipt of such notification, forthwith acknowledge in writing or by facsimile to the BUILDER that such notification has been received.
 
 
(d)  
If any of the BUYER’s default continues for a period of seven (7) days after the BUILDER’s notification to the BUYER of such default, the BUILDER may, at its option, rescind this CONTRACT by serving upon the BUYER a written notice or a facsimile notice of rescission confirmed in writing.
 
 
31

 
 
(e)  
In the event of such cancellation by the BUILDER of this CONTRACT due to the BUYER’s default as provided for in paragraph 1 above, the BUILDER shall be entitled to retain and apply the instalments already paid by the BUYER to the recovery of the BUILDER’s loss and damage including, but not being limited to, reasonable estimated profit due to the BUYER’s default and the cancellation of this CONTRACT and at the same time the BUILDER shall have the full right and power either to complete or not to complete the VESSEL which is the sole property of the BUILDER as it deems fit, and to sell the VESSEL at a public or private sale on such terms and conditions as the BUILDER thinks fit without being answerable for any loss or damage.
 
The proceeds received by the BUILDER from the sale shall be applied in addition to the instalment(s) retained by the BUILDER as mentioned hereinabove as follows:
 
First,
in payment of all reasonable costs and expenses of the sale of the VESSEL, including interest thereon at six per cent (6%) per annum from the respective date of payment of such costs and expenses aforesaid to the date of sale on account of the BUYER’s default.
 
Second,
if the VESSEL has been completed, in or towards satisfaction of the unpaid balance of the CONTRACT PRICE, to which shall be added the cost of all additional work and extras agreed by the BUYER including interest thereon at six per cent (6%) per annum from the respective DUE DATE of the instalment in default to the date of sale, or if the VESSEL has not been completed, in or towards satisfaction of the unpaid amount of the cost incurred by the BUILDER prior to the date of sale on account of construction of the VESSEL, including work, labour, materials and reasonably estimated profit which the BUILDER would have been entitled to receive if the VESSEL had been completed and delivered plus interest thereon at six per cent (6%) per annum from the respective DUE DATE of the instalment in default to the date of sale.
 
Third,
the balance of the proceeds, if any, shall belong to the BUYER, and shall forthwith be paid over to the BUYER by the BUILDER.

 
 
32

 

In the event of the proceeds from the sale together with instalment(s) retained by the BUILDER being insufficient to pay the BUILDER, the BUYER shall be liable for the deficiency and shall pay the same to the BUILDER upon its demand.
 
(End of Article)

 
33

 


ARTICLE XII - BUYER’S SUPPLIES
 

1.  
RESPONSIBILITY OF THE BUYER
 
The BUYER shall, at its cost and expense, supply all the BUYER’s supplies as specified in Paragraph 1.7.2 of the SPECIFICATIONS (hereinafter called the “BUYER’S SUPPLIES”), to the BUILDER at the SHIPYARD in perfect condition ready for installation and in accordance with the time schedule to be furnished by the BUILDER to meet the building schedule of the VESSEL.
 
In order to facilitate the installation of the BUYER’S SUPPLIES by the BUILDER, the BUYER shall furnish the BUILDER with the necessary plans, instruction books, test report and all test certificates required by the BUILDER and shall cause the representative(s) of the makers of the BUYER’S SUPPLIES to give the BUILDER any advice, instructions or assistance which the BUILDER may reasonably require in the installation or adjustment thereof at the SHIPYARD, all without cost or expense to the BUILDER.
 
The BUYER shall be liable for any expense incurred by the BUILDER for repair of the BUYER’S SUPPLIES due to defective design or materials, poor workmanship or performance or due to damage in transit and the DELIVERY DATE of the VESSEL shall be extended for the period of such repair if such repair shall affect the delivery of the VESSEL.
 
Commissioning into good order of the BUYER’S SUPPLIES during and after installation on board shall be made at the BUYER’s expense by the representative of respective maker or the person designated by the BUYER in accordance with the BUILDER’s building schedule.
 
Should the BUYER fail to deliver to the BUILDER the BUYER’S SUPPLIES and the necessary document or advice for such supplies within the time specified by the BUILDER, the DELIVERY DATE of the VESSEL shall automatically be extended for the period of such delay if such delay in delivery shall affect the delivery of the VESSEL. In such event, the BUYER shall pay to the BUILDER all losses and damages sustained by the BUILDER due to such delay in the delivery of the BUYER’S SUPPLIES and such payment shall be made upon delivery of the VESSEL, provided, however, that the BUILDER shall have:
 
 
(a)  
furnished the BUYER with the time schedule referred to above, two (2) months prior to installation of the BUYER’S SUPPLIES and
 
 
(b)  
given the BUYER written notice of any delay in delivery of the BUYER’S SUPPLIES and the necessary document or advice for such supplies as soon as the delay occurs which might give rise to a claim by the BUILDER under this Paragraph.
 
Furthermore, if the delay in delivery of the BUYER’S SUPPLIES and the necessary document or advice for such supplies should exceed ten (10) days from the date specified by the BUILDER, the BUILDER shall be entitled to proceed with construction of the VESSEL without installation of such items (regardless of their nature or importance to the BUYER or the VESSEL) in or on the VESSEL without prejudice to the BUILDER’s right hereinabove provided, and the BUYER shall accept the VESSEL so completed.
 
2.  
RESPONSIBILITY OF THE BUILDER
 
The BUILDER shall be responsible for storing, safekeeping and handling the BUYER’S SUPPLIES which the BUILDER is required to install on board the VESSEL under the SPECIFICATIONS after delivery of such supplies to the SHIPYARD, and shall install such supplies on board the VESSEL at the BUILDER’s expense unless otherwise specified in the SPECIFICATIONS.
 
 
34

 
However, the BUILDER shall not be responsible for the quality, performance or efficiency of any equipment included in the BUYER’S SUPPLIES and is under no obligation with respect to the guarantee of such equipment against any defects caused by poor quality, performance or efficiency of the BUYER’S SUPPLIES. If any of the BUYER’S SUPPLIES is lost or damaged while in the custody of the BUILDER, the BUILDER shall, if the loss or damage is due to wilful default or negligence on its part, be responsible for such loss or damage.
 
(End of Article)

 
35

 


ARTICLE XIII – ARBITRATION
 

1.  
APPOINTMENT OF THE ARBITRATOR
 
If any dispute or difference shall arise between the parties hereto concerning any matter or thing herein contained, or the operation or construction thereof, or any matter or thing in any way connected with this CONTRACT or the rights, duties or liabilities of either party under or in connection with this CONTRACT, then, in every such case, the dispute or difference shall be referred to arbitration in London by a sole arbitrator. The arbitrator shall be appointed by agreement within fourteen (14) days of first written notification of either party to the other of intention to arbitrate such dispute or difference, or in default of such agreement, upon the application of either of the parties, by the President for the time being of the London Maritime Arbitrators Association who shall in making any such appointment have due regard to the requirement for an expeditious resolution of the dispute and in particular the availability of any arbitrator so appointed for an early hearing date.
 
2.  
LAWS APPLICABLE
 
Any arbitration arising hereunder shall be governed by and construed in accordance with the Arbitration Act 1996 of England or any statutory modification or re-enactments thereof for the time being in force. The award of the arbitrator shall be final and binding upon parties hereto.
 
3.  
PROCEEDINGS
 
In the event of any dispute or difference arising or occurring prior to delivery to or acceptance by, the BUYER of the VESSEL being referred to arbitration, the parties hereby acknowledge that time is of the essence in obtaining an award from the arbitrator on such dispute or difference and the parties hereby agree that the arbitration shall be conducted according to the following timetable:
 
 
(a)  
The claimant in the arbitration to serve points of claim within fourteen (14) days of the appointment of the arbitrator.
 
 
(b)  
The respondent in the arbitration to serve points of defence and points of counterclaim, if any, within fourteen (14) days thereafter.
 
 
(c)  
The claimant to serve points of reply and defence to counterclaim, if any, within seven (7) days thereafter and the hearing of the arbitration to commence within twelve (12) weeks of the appointment of the arbitrator.
 

 
36

 


4.  
ALTERATION OF DELIVERY OF THE VESSEL
 
In the event of the arbitration of any dispute or difference arising or occurring prior to delivery to, or acceptance by the BUYER of the VESSEL, the award by the arbitrator shall include a finding as to whether or not the contractual delivery date of the VESSEL should, as a result of such dispute, be in any way altered thereby.
 
 
(End of Article)

 
37

 

 

ARTICLE XIV - SUCCESSORS AND ASSIGNS
 

The BUILDER agrees that, prior to delivery of the VESSEL, this CONTRACT may, with the prior written approval of the BUILDER, which the BUILDER shall not unreasonably withhold, be transferred to and the title thereof may be taken by another company. In the event of any assignment pursuant to the terms of this CONTRACT, the assignee, its successors and assigns shall succeed to all the rights and obligations of the BUYER under this CONTRACT. However, the BUYER shall remain responsible for performance by the assignee, its successors and assigns of all the BUYER’s obligations, liabilities and responsibilities under this CONTRACT. It is understood that any expenses or charges incurred due to the transfer of this CONTRACT shall be for the account of the BUYER.
 
The BUILDER shall have the right to assign this CONTRACT at any time after the effective date hereof, provided that prior written agreement is obtained from the BUYER.
 
 
(End of Article)

 
38

 

 

ARTICLE XV - TAXES AND DUTIES
 

1.  
TAXES
 
Unless otherwise expressly provided for in this CONTRACT, all costs and taxes including stamp duties, if any, incurred in or levied by any country except Korea in connection with this CONTRACT shall be borne by the BUYER and corresponding costs and taxes in Korea, before delivery of the VESSEL, if any, shall be borne by the BUILDER.
 
2.  
DUTIES
 
The BUILDER shall hold the BUYER harmless from any payment of duty imposed in Korea upon materials or supplies which, under the terms of this CONTRACT, or amendments thereto, may be supplied by the BUYER from abroad for the construction of the VESSEL.
 
The BUILDER shall likewise hold the BUYER harmless from any payment of duty imposed in Korea in connection with materials or supplies for operation of the VESSEL, including running stores, provisions and supplies necessary to stock the VESSEL for its operation. This indemnity does not, however, extend to any items purchased by the BUYER for use in connection with the VESSEL which are not absolutely required for the construction or operation of the VESSEL.
 
 
(End of Article)

 
39

 

 

ARTICLE XVI - PATENTS, TRADEMARKS AND COPYRIGHTS
 

1.  
PATENTS, TRADEMARKS AND COPYRIGHTS
 
Machinery and equipment of the VESSEL, whether made or furnished by the BUILDER under this CONTRACT, may bear the patent numbers, trademarks, or trade names of the manufacturers. The BUILDER shall defend and save harmless the BUYER from all liabilities or claims for or on account of the use of any patents, copyrights or design of any nature or kind, or for the infringement thereof including any unpatented invention made or used in the performance of this CONTRACT and also for any costs and expenses of litigation, if any in connection therewith. No such liability or responsibility shall be with the BUILDER with regard to components and/or equipment and/or design supplied by the BUYER.
 
Nothing contained herein shall be construed as transferring any patent or trademark rights or copyrights in equipment covered by this CONTRACT, and all such rights are hereby expressly reserved to the true and lawful owners thereof.
 
2.  
RIGHTS TO THE SPECIFICATIONS, PLANS, ETC.
 
The BUILDER retains all rights with respect to the SPECIFICATIONS, plans and working drawings, technical descriptions, calculations, test results and other data, information and documents concerning the design and construction of the VESSEL and the BUYER shall not disclose the same or divulge any information contained therein to any third parties, including but not limited to any other shipbuilders, without the prior written consent of the BUILDER, excepting where it is necessary for usual operation, repair and maintenance of the VESSEL. In case the BUYER is in breach of its obligation under this Article, the BUILDER shall be entitled to any rights, powers and remedies in this CONTRACT and/or at law, at equity or otherwise to recover any damages caused by the breach of the BUYER.
 
 
(End of Article)

 
40

 


 
ARTICLE XVII - INTERPRETATION AND GOVERNING LAW
 

This CONTRACT has been prepared in English and shall be executed in duplicate and in such number of additional copies as may be required by either party respectively. The parties hereto agree that the validity and interpretation of this CONTRACT and of each Article and part thereof shall be governed by the laws of England.
 
 
(End of Article)

 
41

 

 

ARTICLE XVIII – NOTICE
 

Any and all notices, requests, demands, instructions, advices and communications in connection with this CONTRACT shall be written in English, sent by registered air mail or e-mail or facsimile and shall be deemed to be given when first received whether by registered mail or facsimile. They shall be addressed as follows, unless and until otherwise advised :
 
 
To the BUILDER:
DAEHAN SHIPBUILDING CO., LTD.
   
748, Woodoo-Ri, Dolsan-Up, Yeosu City, Jeonnam, Korea
c/o 3rd Floor, Moodeung Building, 20-2, 2-Ga, Gumnam-Ro,
Dong-Gu, Gwangju, Korea
 
Attn:  [                     ]
 
Tel :  [                     ] 
Facsimile :  [                     ] 
E-mail :  [                     ] 
     
 
To the BUYER :
GOLDEN OCEAN GROUP LIMITED
   
Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton HM 08,
Bermuda
c/o GOLDEN OCEAN MANAGEMENT ASIA PTE LTD.
168 Robinson Road, #24-01 Capital Tower, Singapore 068912
 
Attn:  [                     ]
 
Tel :  [                     ]
Facsimile:  [                     ]
E-mail:  [                     ]
 
The said notices shall become effective upon receipt of the letter or e-mail or facsimile communication by the receiver thereof. Where a notice by e-mail or facsimile is concerned which is required to be confirmed by letter, then, unless the CONTRACT or the relevant Article thereof otherwise requires, the notice shall become effective upon receipt of the e-mail or facsimile.
 
(End of Article)

 
42

 


 
ARTICLE XIX - EFFECTIVENESS OF THIS CONTRACT
 

This CONTRACT shall become effective upon signing by the parties hereto.
 
 
(End of Article)

 
43

 

 

ARTICLE XX – EXCLUSIVENESS
 

This CONTRACT shall constitute the only and entire agreement between the parties hereto, and unless otherwise expressly provided for in this CONTRACT, all other agreements, oral or written, made and entered into between the parties prior to the execution of this CONTRACT shall be null and void.
 
 
(End of Article)

 
44

 

 

IN WITNESS WHEREOF, the parties hereto have caused this CONTRACT to be duly executed on the date and year first above written.

BUYER
 
BUILDER
 
       
For and on behalf of
 
For and on behalf of
 
       
GOLDEN OCEAN GROUP LIMITED
DAEHAN SHIPBUILDING CO., LTD.
 
By:
                                                                                 
By:
                                                                                       
Name:
Anders Zorn
Name:
Min Ho Song
Title:
Attorney-in-fact
Title:
Attorney-in-fact
       
 
 
WITNESS:                                                                                   WITNESS:                                                                        
 
 
 


 
45

 

EXHIBIT “A”
 
 
LETTER OF GUARANTEE
 
Date :_______________
 
Gentlemen:

We hereby open our irrevocable letter of guarantee number ______________ in favor of GOLDEN OCEAN GROUP LIMITED or its nominee (hereinafter called the “BUYER”) for account of DAEHAN SHIPBUILDING CO., LTD., Korea (hereinafter called the “BUILDER”) as follows in connection with the shipbuilding contract dated 30th November, 2006 (hereinafter called the “CONTRACT”) made by and between the BUYER and the BUILDER for the construction of one (1) 170,500 DWT Class Bulk Carrier having the BUILDER’s Hull No. HN-101[  ] (hereinafter called the “VESSEL”).

If, in connection with the terms of the CONTRACT, the BUYER shall become entitled to a refund of the advance payments made to the BUILDER prior to the delivery of the VESSEL, we hereby irrevocably guarantee the repayment of the same to the BUYER within thirty (30) days after demand not exceeding US$16,200,000.- (Say U.S. Dollars Sixteen Million Two Hundred Thousand only) together with interest thereon at the rate of six per cent (6%) per annum from the date following the date of receipt by the BUILDER to the date of remittance by telegraphic transfer of such refund.

The amount of this guarantee will be automatically increased upon the BUILDER’s receipt of the second, third and fourth instalments plus interest thereon as provided in the CONTRACT, but in any eventuality the amount of this guarantee shall not exceed the total sum of US$64,800,000.- (Say U.S. Dollars Sixty Four Million Eight Hundred Thousand only) plus interest thereon at the rate of six per cent (6%) per annum from the date following the date of the BUILDER’s receipt of each instalment to the date of remittance by telegraphic transfer of the refund.

The payment by the undersigned under this guarantee (subject to the second and third paragraph hereof) shall be made upon simple receipt by us of written demand from you including a signed statement certifying that the BUYER’s demand for refund has been made in conformity with Article X of the CONTRACT and the BUILDER has failed to make the refund.

Notwithstanding the provisions hereinabove, in the event that within thirty (30) days from the date of your claim to the BUILDER referred to above, we receive notification from you or the BUILDER accompanied by written confirmation to the effect that your claim to cancel the CONTRACT or your claim for refundment thereunder has been disputed and referred to arbitration in accordance with the provisions of the CONTRACT, we shall under this guarantee, refund to you the sum adjudged to be due to you by the BUILDER pursuant to the award made under such arbitration immediately upon receipt from you of a demand for the sums so adjudged and a copy of the award. And in any case the sum will not exceed US$64,800,000.- (Say U.S. Dollars Sixty Four Million Eight Hundred Thousand only) together with interest thereon at the rate of six per cent (6%) per annum from the date following the date of receipt by the BUILDER to the date of remittance by telegraphic transfer of such refund.

This letter of guarantee shall become null and void upon receipt by the BUYER of the sum guaranteed hereby or upon acceptance by the BUYER of the delivery of the VESSEL in accordance with the terms of the CONTRACT and, in either case, the BUYER shall return this letter of guarantee to us or shall arrange with their bank to confirm us by SWIFT (our SWIFT address : ______________________ ) that this letter of guarantee has been null and void.

This letter of guarantee is assignable and valid from the date of this Letter of Guarantee until such time as the VESSEL is delivered by the BUILDER to the BUYER in accordance with the provisions of the CONTRACT.

This guarantee shall be governed by and construed in accordance with the laws of England and the undersigned hereby submits to the non-exclusive jurisdiction of the Courts of England.



 
Very truly yours,
 
For and on behalf of
XXXXXX Bank
 
By:__________________________
Name:
Title:
 

 


A-1
 
 

 

EXHIBIT “B”
 
 
DAEHAN SHIPBUILDING CO., LTD.
748, Woodoo-Ri, Dolsan-Up, Yeosu City
Jeonnam, Korea
 
Date :___________________
 
PERFORMANCE GUARANTEE
 
Gentlemen,

In consideration of your executing a shipbuilding contract (hereinafter called the “CONTRACT”) dated 30th November, 2006 with GOLDEN OCEAN GROUP LIMITED or its nominee (hereinafter called the “BUYER”) providing for the construction of one (1) 170,500 DWT Class Bulk Carrier haying the BUILDER’s Hull No. HN-101[  ] (hereinafter called the “VESSEL”), and providing, among other things, for payment of the contract price amounting to United States Dollars Eighty One Million only (US$81,000,000.-) for the VESSEL, prior to, upon and after the delivery of the VESSEL, the undersigned, as a primary obligor and not as a surety merely, hereby unconditionally and irrevocably guarantees to you, your successors and assigns, the due and faithful performance by the BUYER of all its liabilities and responsibilities under the CONTRACT and any supplements, amendments, changes or modifications hereinafter made thereto including but not limited to, due and prompt payment of the contract price (whether on account of principal, interest or otherwise) by the BUYER to you, your successors and assigns under the CONTRACT, notwithstanding any obligation of the BUYER being or becoming unenforceable by defect in or want of its powers, (hereby expressly waiving notice of any such supplement, amendment, change or modification as may be agreed to by the BUYER) and confirms that this guarantee shall be fully applicable to the CONTRACT whether so supplemented, amended, changed or modified and if it shall be assigned by the BUYER in accordance with the terms of the CONTRACT. This guarantee will expire on delivery of the VESSEL to the BUYER.

The undersigned hereby certifies, represents and warrants that all acts, conditions and things required to be done and performed and to have occurred precedent to the creation and issuance of this guarantee, and to constitute the guarantee the valid and legally binding obligation of the undersigned enforceable in accordance with its terms have been done and performed and have occurred in due and strict compliance with applicable laws.

The payment by the undersigned under this guarantee shall be made forthwith upon receipt by us of written demand from you including a statement that the BUYER is in default of payment of the amounts (including, but not limited to, the instalment(s) payable prior to or upon delivery of the VESSEL) that were due under the CONTRACT, without requesting you to take any or further procedure or step against the BUYER. In the event that any withholding or deduction is imposed by any law, the undersigned will pay such additional amount as may be necessary in order that the actual amount received after deduction or withholding shall equal to the amount that would have been received if such deduction or withholding were not required.
 
This guarantee shall be governed by and interpreted in accordance with the laws of England and the undersigned hereby submits to the non-exclusive jurisdiction of the Courts of England and appoints __________________________________ to receive service of proceedings in such courts on its behalf.



 
Very truly yours,
 
For and on behalf of BUYER
 
By:__________________________
Name:
Title:



B-1
 
 

 
 
FORM OF
 
NOVATION AGREEMENT
 
 
THIS AGREEMENT is dated 21 June, 2007 and is made BETWEEN:
 
(I)
Golden Ocean Group Ltd., a corporation incorporated and existing under the laws of Bermuda having its registered office at Par-la-Ville Place, 14 Par-la-Ville Road, Hamilton HM 08, Bermuda (the “BUYER”), and
 
(II)
Daehan Shipbuilding Co. Ltd. a corporation incorporated and existing under the laws of the Republic of Korea (the “BUILDER”) having its registered office at 748, Woodoo-Ri, Dolsand-Up, Yeosu City, Jeonnam, Korea, and
 
(III)
KTL Belgravia [  ] Inc, a corporation incorporated and existing under the laws of Liberia having its registered office at 80 Broad Street, Monrovia, Liberia (the “SUBSTITUTED BUYER”).
 
WHEREAS:
 
1.1
Under an agreement made on 30 November 2006 between the Buyer and the Builder the Builder has agreed to construct a 170,500 dwt class bulk carrier vessel for the Buyer with hull no. HN-101[  ] (the “Shipbuilding Contract”).
 
1.2
Under Article XIV of the Shipbuilding Contract the Buyer is permitted to transfer the Shipbuilding Contract, with the consent of the Builder.
 
1.3
The Buyer wishes to transfer its rights and obligations under the Shipbuilding Contract to the Substituted Buyer which is a company in the same group as the Buyer, and the Builder has agreed to this on the condition that the Buyer provides the Builder with a performance guarantee pursuant to Article X, clause 9, guaranteeing the performance of the Substituted Buyer under the Shipbuilding Contract.
 
1.4
In accordance with recital (C) herein, the terms of Article XIV of the Shipbuilding Contract and the terms hereof the Builder has agreed to release and discharge the Buyer of its rights and obligations under the Shipbuilding Contract. The Substituted Buyer has agreed to assume, the obligations of the Buyer to the Builder under the Shipbuilding Contract, and the Buyer has agreed to release and discharge the Builder from its rights and obligations to the Buyer under the Shipbuilding Contract, in each case on the terms and subject to the conditions contained in this Agreement.
 
1.5
Pursuant to Article X, Clause 8 of the Shipbuilding Contract a refund guarantee has been issued by XXXXXX Bank (the “Refund Guarantor”) in favour of the Buyer or its nominee (the “Refund Guarantee”). The nomination and novation under the Shipbuilding Contract is subject to all rights of the Buyer under a new refund guarantee on the same terms as the Refund Guarantee (the “Substituted Refund Guarantee”) is issued to the Substituted Buyer as set out below as soon as the existing Refund Guarantee has been discharged by the Substituted Buyer’s bank by SWIFT as set out below.
 
AGREEMENT
 
1.1     Novation
 
With effect from 21 June 2007 (“Novation Date”):
 
(i)
The Substituted Buyer agrees with the Builder to assume all the rights and obligations of the Buyer to the Builder under or arising from the Shipbuilding Contract, (except any rights or obligations that have been fully and properly performed prior to the Novation Date);
 
(ii)
the Buyer releases and discharges the Builder from all its rights and obligations and liability to the Buyer under the Shipbuilding Contract and from all (if any) liability to the Buyer arising from any act or omission of the Builder in the performance of all or any of the Builder’s obligations to the Buyer under the Shipbuilding Contract;
 
(iii)
on the condition that the Buyer has issued a performance guarantee in favour of the Builder as set out in Article X, Clause 9 of the Shipbuilding Contract prior to the entering into of this Novation Agreement, the Builder releases and discharges the Buyer from all its rights and obligations and liability to the Builder under the Shipbuilding Contract and from all (if any) liability to the Builder arising from any act or omission of the Buyer in the performance of all or any of the Buyer’s obligations to the Builder under the Shipbuilding Contract;
 
 

 
(iv)
the Builder agrees to ensure that the Substituted Refund Guarantee is issued in writing to the Substituted Buyer as soon as possible after the Substituted Buyer’s bank, the XXXXXX, having confirmed by swift message to the Builder’s bank, XXXXXX Bank (swift address XXXXXXXXXXX) that the existing Refund Guarantee is considered null and void; and
 
(iv)
the Builder agrees with the Substituted Buyer to be bound by its rights and obligations under the Shipbuilding Contract (to the extent that they have not been fully and properly performed prior to the Novation Date) in every way as if the Substituted Buyer had been a party to the Contract in place of the Buyer.
 
1.2     Obligations
The parties acknowledge and agree that:
 
(i)
any obligations of the Buyer to the Builder pursuant to the terms of the Shipbuilding Contract which are not performed as at the Novation Date shall not be deemed to be waived by the Builder by virtue of the novation of the Shipbuilding Contract pursuant to the terms of this Agreement, but shall be performed by the Substituted Buyer;
 
(ii)
any obligations of the Builder pursuant to the terms of the Shipbuilding Contract which are not performed as at the Novation Date shall not be deemed to be waived by the Substituted Buyer by virtue of the novation of the Shipbuilding Contract pursuant to the terms of this Agreement, but shall be performed by the Builder.
 
2        AMENDMENTS
 
The Builder and the Substituted Buyer hereby agree that, with effect from the Novation Date, the Shipbuilding Contract shall be amended so that all references to the Buyer shall be interpreted as references to the Substituted Buyer.
 
3        GOVERNING LAW AND DISPUTES
 
This Agreement shall be governed and interpreted in accordance with the laws of England. The terns relating to disputes and arbitration as contained In Article XIII of the Shipbuilding Contract shall apply to this Agreement.
The parties have entered into this Agreement the day and year first above written.
 
Signed by Anders Zorn
For and on behalf of the Buyer
 
______________________________
 
 
Signed by [name]
For and on behalf of the Builder
 
______________________________
 
Signed by Anders Zorn
For and on behalf of the Substituted Buyer

______________________________
 
Novation agreement hull 101[  ]
EX-8.1 3 d875784_ex8-1.htm LIST OF SUBSIDIARIES OF THE COMPANY d875784_ex8-1.htm
Exhibit 8.1
 
NAME
COUNTRY OF INCORPORATION
OWNERSHIP INTEREST
     
KTL Camden, Inc.
Republic of Liberia
100%
KTL Kensington, Inc.
Republic of Liberia
100%
KTL Hampstead, Inc.
Republic of Liberia
100%
KTL Mayfair, Inc.
Republic of Liberia
100%
KTL Belgravia I, Inc.
Republic of Liberia
100%
KTL Belgravia II, Inc.
Republic of Liberia
100%

EX-12.1 4 d875784_ex12-1.htm CERTIFICATION d875784_ex12-1.htm
 
Exhibit 12.1

CERTIFICATION OF THE PRINCIPAL EXECUTIVE OFFICER
PURSUANT TO RULE 13a-14(a) AND 15d-14(a), AS AMENDED

 
I, Bjørn Sjaastad, certify that:
 
1. I have reviewed this annual report on Form 20-F of Knightsbridge Tankers Limited;
 
2. Based on my knowledge, this annual report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this annual report;
 
3. Based on my knowledge, the financial statements, and other financial information included in this annual report, fairly present in all material respects the financial condition, results of operations and cash flows of the company as of, and for, the periods presented in this annual report;
 
4. The company’s other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in the Exchange Act Rules 13a-15(f) and 15d-15(f)) for the company and have:
 
a) designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the company, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this annual report is being prepared;
 
b) designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
 
c) evaluated the effectiveness of the company’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
d) disclosed in this report any change in the company’s internal control over financial reporting that occurred during the period covered by the annual report that has materially affected, or is reasonably likely to materially affect, the company’s internal control over financial reporting; and
 
5. The company's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the company’s auditors and the audit committee of the company’s board of directors (or persons performing the equivalent functions):
 
a) all significant deficiencies and material weaknesses in the design or operation of internal controls over financial reporting which are reasonably likely to adversely affect the company’s ability to record, process, summarize and report financial information; and
 
b) any fraud, whether or not material, that involves management or other employees who have a significant role in the company’s internal control over financial reporting.
 
Date: April 23, 2008
 
 /s/ Bjørn Sjaastad
 
Bjørn Sjaastad
Principal Executive Officer

EX-12.2 5 d875784_ex12-2.htm CERTIFICATION d875784_ex12-2.htm
Exhibit 12.2


CERTIFICATION OF THE PRINCIPAL FINANCIAL OFFICER
PURSUANT TO RULE 13a-14(a) AND 15d-14(a), AS AMENDED
 
I, Inger M. Klemp, certify that:
 
1. I have reviewed this annual report on Form 20-F of Knightsbridge Tankers Limited;
 
2. Based on my knowledge, this annual report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this annual report;
 
3. Based on my knowledge, the financial statements, and other financial information included in this annual report, fairly present in all material respects the financial condition, results of operations and cash flows of the company as of, and for, the periods presented in this annual report;
 
4. The registrant's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in the Exchange Act Rules 13a-15(f) and 15d-15(f))  for the company and have:
 
a) designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the company, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this annual report is being prepared;
 
b) designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
 
c) evaluated the effectiveness of the company’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
d) disclosed in this report any change in the company’s internal control over financial reporting that occurred during the period covered by the annual report that has materially affected, or is reasonably likely to materially affect, the company’s internal control over financial reporting; and
 
5. The company's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the company’s auditors and the audit committee of the company’s board of directors (or persons performing the equivalent functions):
 
a) all significant deficiencies and material weaknesses in the design or operation of internal controls over financial reporting which are reasonably likely to adversely affect the company’s ability to record, process, summarize and report financial information; and
 
b) any fraud, whether or not material, that involves management or other employees who have a significant role in the company’s internal control over financial reporting.
 
Date: April 23, 2008
 
/s/ Inger M. Klemp
 
Inger M. Klemp
Principal Financial Officer

EX-13.1 6 d875784_13-1.htm PRINCIPAL EXECUTIVE OFFICER CERTIFICATION d875784_13-1.htm
Exhibit 13.1
 

PRINCIPAL EXECUTIVE OFFICER CERTIFICATION
PURSUANT TO 18 U.S.C. SECTION 1350

In connection with this Annual Report of Knightsbridge Tankers Limited (the “Company”) on Form 20-F for the annual period ended December 31, 2007, as filed with the Securities and Exchange Commission (the “SEC”) on or about the date hereof (the “Report”), I, Bjørn Sjaastad, the Principal Executive Officer of the Company, certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that:

 
(1)
The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

 
(2)
The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

A signed original of this written statement has been provided to the Company and will be retained by the Company and furnished to the SEC or its staff upon request.

Date: April 23, 2008
 
/s/ Bjørn Sjaastad
 
Bjørn Sjaastad
Principal Executive Officer

 
 

 
EX-13.2 7 d875784_13-2.htm PRINCIPAL EXECUTIVE OFFICER CERTIFICATION d875784_13-2.htm
Exhibit 13.2
 

PRINCIPAL FINANCIAL OFFICER CERTIFICATION
PURSUANT TO 18 U.S.C. SECTION 1350

In connection with this Annual Report of Knightsbridge Tankers Limited (the “Company”) on Form 20-F for the annual period ended December 31, 2007, as filed with the Securities and Exchange Commission (the “SEC”) on or about the date hereof (the “Report”), I, Inger M. Klemp, the Principal Financial Officer of the Company, certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that:

 
(1)
The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

 
(2)
The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

A signed original of this written statement has been provided to the Company and will be retained by the Company and furnished to the SEC or its staff upon request.

Date: April 23, 2008

/s/ Inger M. Klemp

Inger M. Klemp
Principal Financial Officer

 
 
 

 

-----END PRIVACY-ENHANCED MESSAGE-----