10-Q

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-Q

(Mark One)

☑ QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT OF 1934

For the Quarterly Period Ended April 30, 2021

or

☐ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT

For the Transition Period from                      to                     

Commission File Number 001-31756

(Exact Name of Registrant as Specified in Its Charter)

Delaware	13-1947195
(State or Other Jurisdiction of Incorporation)	(I.R.S. Employer Identification No.)

One Church Street, Suite 201, Rockville, Maryland 20850

(Address of Principal Executive Offices) (Zip Code)

(301) 315-0027

(Registrant’s Telephone Number, Including Area Code)

(Former Name, Former Address and Former Fiscal Year, if Changed since Last Report)

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15 (d) of the Securities Exchange Act of 1934 (the “Exchange Act”) during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.    Yes   þ    No  ☐

Indicate by check mark whether the Registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the Registrant was required to submit such files).    Yes  þ    No  ☐

Indicate by check mark whether the Registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer ”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer ☐  Accelerated filer þ  Non-accelerated filer ☐  Smaller reporting company ☐  Emerging growth company ☐

If an emerging growth company, indicate by check mark if the Registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).    Yes  ☐    No  ☑

Title of Each Class	Trading Symbol(s)	Name of Each Exchange on Which Registered
Common Stock, $.15 par value	AGX	New York Stock Exchange

Indicate the number of shares outstanding of each of the Registrant’s classes of common stock, as of the latest practicable date.

Common stock, $0.15 par value: 15,769,440 shares as of June 4, 2021.

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS

(In thousands, except per share data)

(Unaudited)

	Three Months Ended
	April 30,
	2021		2020
REVENUES	$	126,341	$	60,148
Cost of revenues		102,627		56,139
GROSS PROFIT		23,714		4,009
Selling, general and administrative expenses		9,892		10,344
INCOME (LOSS) FROM OPERATIONS		13,822		(6,335)
Other income, net		712		1,088
INCOME (LOSS) BEFORE INCOME TAXES		14,534		(5,247)
Income tax (expense) benefit		(3,768)		4,454
NET INCOME (LOSS)		10,766		(793)
Net loss attributable to non-controlling interests		—		(30)
NET INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.		10,766		(763)
Foreign currency translation adjustments		(118)		(246)
COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	$	10,648	$	(1,009)
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.
Basic	$	0.68	$	(0.05)
Diluted	$	0.67	$	(0.05)
WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING
Basic		15,726		15,643
Diluted		15,961		15,643
CASH DIVIDENDS PER SHARE	$	0.25	$	0.25

The accompanying notes are an integral part of these condensed consolidated financial statements.

2

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED BALANCE SHEETS

(Dollars in thousands, except per share data)

	April 30,		January 31,
	2021		2021
	(Unaudited)		(Note 1)
ASSETS
CURRENT ASSETS
Cash and cash equivalents	$	396,675	$	366,671
Short-term investments		70,075		90,055
Accounts receivable		32,379		28,713
Contract assets		26,158		26,635
Other current assets (Note 10)		33,744		34,146
TOTAL CURRENT ASSETS		559,031		546,220
Property, plant and equipment, net		19,944		20,361
Goodwill		27,943		27,943
Other purchased intangible assets, net		3,869		4,097
Deferred taxes		—		249
Right-of-use and other assets		7,185		3,760
TOTAL ASSETS	$	617,972	$	602,630
LIABILITIES AND EQUITY
CURRENT LIABILITIES
Accounts payable	$	41,467	$	53,295
Accrued expenses		42,050		50,750
Contract liabilities		199,548		172,042
TOTAL CURRENT LIABILITIES		283,065		276,087
Deferred taxes		350		—
Other noncurrent liabilities		3,741		4,135
TOTAL LIABILITIES		287,156		280,222
COMMITMENTS AND CONTINGENCIES (Notes 7 and 8)
STOCKHOLDERS’ EQUITY
Preferred stock, par value $0.10 per share – 500,000 shares authorized; no shares issued and outstanding		—		—
Common stock, par value $0.15 per share – 30,000,000 shares authorized; 15,772,673 and 15,706,202 shares issued at April 30, 2021 and January 31, 2021, respectively; 15,769,440 and 15,702,969 shares outstanding at April 30, 2021 and January 31, 2021, respectively		2,366		2,356
Additional paid-in capital		154,974		153,282
Retained earnings		172,934		166,110
Accumulated other comprehensive loss		(1,199)		(1,081)
TOTAL STOCKHOLDERS’ EQUITY		329,075		320,667
Non-controlling interests		1,741		1,741
TOTAL EQUITY		330,816		322,408
TOTAL LIABILITIES AND EQUITY	$	617,972	$	602,630

The accompanying notes are an integral part of these condensed consolidated financial statements.

3

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

FOR THE THREE MONTHS ENDED APRIL 30, 2021 AND 2020

(Dollars in thousands)

(Unaudited)

	Common Stock			Additional				Accumulated
	Outstanding	Par		Paid-in		Retained		Other Comprehensive		Non-controlling		Total
	Shares	Value		Capital		Earnings		Loss		Interests		Equity
Balances, February 1, 2021	15,702,969	$	2,356	$	153,282	$	166,110	$	(1,081)	$	1,741	$	322,408
Net income	—		—		—		10,766		—		—		10,766
Foreign currency translation loss	—		—		—		—		(118)		—		(118)
Stock compensation expense	—		—		679		—		—		—		679
Stock option exercises and other share-based award settlements	66,471		10		1,013		—		—		—		1,023
Cash dividends	—		—		—		(3,942)		—		—		(3,942)
Balances, April 30, 2021	15,769,440	$	2,366	$	154,974	$	172,934	$	(1,199)	$	1,741	$	330,816
Balances, February 1, 2020	15,634,969	$	2,346	$	148,713	$	189,306	$	(1,116)	$	1,781	$	341,030
Net losses	—		—		—		(763)		—		(30)		(793)
Foreign currency translation loss	—		—		—		—		(246)		—		(246)
Stock compensation expense	—		—		642		—		—		—		642
Stock option exercises	10,000		1		176		—		—		—		177
Cash dividends	—		—		—		(3,910)		—		—		(3,910)
Balances, April 30, 2020	15,644,969	$	2,347	$	149,531	$	184,633	$	(1,362)	$	1,751	$	336,900

The accompanying notes are an integral part of these condensed consolidated financial statements.

4

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

(In thousands)

(Unaudited)

	Three Months Ended April 30,
	2021		2020
CASH FLOWS FROM OPERATING ACTIVITIES
Net income (loss)	$	10,766	$	(793)
Adjustments to reconcile net income (loss) to net cash provided by operating activities
Deferred income tax expense		599		8,214
Depreciation		882		937
Stock compensation expense		679		642
Lease expense		776		379
Amortization of purchased intangible assets		228		225
Other		(114)		328
Changes in operating assets and liabilities
Accounts receivable		(3,666)		14,980
Contract assets		477		344
Other assets		765		(13,600)
Accounts payable and accrued expenses		(21,552)		(8,609)
Contract liabilities		27,506		37,140
Net cash provided by operating activities		17,346		40,187
CASH FLOWS FROM INVESTING ACTIVITIES
Maturities of short-term investments		20,000		70,000
Purchase of short-term investment		—		(10,000)
Investment in solar energy project		(3,520)		—
Purchases of property, plant and equipment		(844)		(684)
Net cash provided by investing activities		15,636		59,316
CASH FLOWS FROM FINANCING ACTIVITIES
Payments of cash dividends		(3,942)		(3,910)
Proceeds from the exercise of stock options		1,023		177
Net cash used in financing activities		(2,919)		(3,733)
EFFECTS OF EXCHANGE RATE CHANGES ON CASH		(59)		(206)
NET INCREASE IN CASH AND CASH EQUIVALENTS		30,004		95,564
CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD		366,671		167,363
CASH AND CASH EQUIVALENTS, END OF PERIOD	$	396,675	$	262,927
SUPPLEMENTAL CASH FLOW INFORMATION (Notes 7 and 10)

The accompanying notes are an integral part of these condensed consolidated financial statements.

5

ARGAN, INC. AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

April 30, 2021

(Tabular dollar amounts in thousands, except per share data)

(Unaudited)

NOTE 1 – DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Description of the Business

Argan, Inc. (“Argan”) conducts operations through its wholly owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the United States (the “US”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “UK”). Including consolidated variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeastern region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIE. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 of each year.

The condensed consolidated balance sheet as of April 30, 2021, the condensed consolidated statements of earnings and stockholders’ equity for the three months ended April 30, 2021 and 2020, and the condensed consolidated statements of cash flows for the three months ended April 30, 2021 and 2020 are unaudited. The condensed consolidated balance sheet as of January 31, 2021 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2021 (“Fiscal 2021”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of April 30, 2021, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

6

Accounting Policies

Income Taxes

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. Adoption of this new guidance, which was effective for the Company on February 1, 2021, did not alter the Company’s accounting for income taxes.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

Fair Values

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three-month periods ended April 30, 2021 and 2020. The total amounts of the project development costs included in the balances for property, plant and equipment as of April 30, 2021 and January 31, 2021 were $7.7 million and $7.5 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

NOTE 2 – REVENUES FROM CONTRACTS WITH CUSTOMERS

The Company’s accounting for revenues on contracts with customers is based on a single comprehensive five-step model that requires reporting entities to:

1. Identify the contract,

2. Identify the performance obligations of the contract,

3. Determine the transaction price of the contract,

4. Allocate the transaction price to the performance obligations, and

5. Recognize revenue.

The Company focuses on the transfer of the contractor’s control of the goods and/or services to the customer, as opposed to the transfer of risk and rewards. Major provisions of the current guidance cover the determination of which goods and services are distinct and represent separate performance obligations, the appropriate treatments for variable consideration, and the evaluation of whether revenues should be recognized at a point in time or over time.

When a performance obligation is satisfied over time, the related revenues are recognized over time. The Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed-price or a time-and-materials basis, and primarily over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer.

7

Revenues from fixed-price contracts, including portions of estimated gross profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the cost-to-cost approach. If, at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period that it is identified and an amount is estimable. Revenues from time-and-materials contracts are recognized when the related services are provided to the customer.

Almost all of the Company’s fixed-price contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of such contracts because contract promises included therein are interrelated or the contracts require the Company to perform critical integration so that the customer receives a completed project. Warranties provided under the Company’s contracts with customers are assurance-type and are recorded as the corresponding contract work is performed.

The transaction price for a contract represents the value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration, which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as changes in the scope and price of contracts, claims, incentives and liquidated damages.

Contract assets include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities include amounts that reflect obligations to provide goods or services for which payment has been received. Contract retentions are billed amounts which, pursuant to the terms of the applicable contract, are not paid by project owners until a defined phase of a contract or project has been completed and accepted. These retained amounts are reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retainage amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at April 30, 2021 and January 31, 2021 were $42.1 million and $36.8 million, respectively.

Variable Consideration

Amounts for contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. The aggregate amount of such contract variations included in the transaction prices that were used to determine project-to-date revenues at April 30, 2021 and January 31, 2021 were $17.6 million and $16.6 million, respectively. Variations related to the Company’s contracts typically represent modifications to the existing contracts and performance obligations, and do not represent new performance obligations. Actual costs related to any changes in the scope of the corresponding contract are expensed as they are incurred. Changes to total estimated contract costs and losses, if any, are reflected in operating results for the period in which they are determined.

The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. These contract requirements generally relate to specified activities that must be completed by an established date or by the achievement of a specified level of output or efficiency. Each applicable contract defines the conditions under which a project owner may be entitled to any liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not subtracted from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract. The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved. The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects.

8

In other cases, the Company may have the grounds to assert liquidated damages against subcontractors, suppliers, project owners or other parties related to a project. Such circumstances may arise when the Company’s activities and progress are adversely affected by delayed or damaged materials, challenges with equipment performance or other events out of the Company’s control where the Company has rights to recourse, typically in the form of liquidated damages. In general, the Company does not adjust the corresponding contract accounting until it is probable that the favorable cost relief will be realized. Such adjustments have been and could be material.

The Company records adjustments to revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.

Accounting for the Subcontract Loss

For the year ended January 31, 2019 (“Fiscal 2019”), the Company disclosed that APC was completing the mechanical installation of the boiler for a biomass-fired power plant under construction in Teesside, England, which is referred to as the Tees Renewable Energy Plant (“TeesREP”), that had encountered significant operational and contractual challenges. Subsequently, APC’s estimates of the costs of the unfavorable financial impacts of the difficulties on the TeesREP project escalated substantially. For the fiscal year ended January 31, 2020 (“Fiscal 2020”), the Company recorded a loss related to this project in the amount of $33.6 million and reversed profit in the amount of $0.7 million that had been recorded in prior fiscal years.

Construction activities on the TeesREP project were suspended on March 24, 2020 due to the COVID-19 pandemic, pending preparations being made by the contractors and subcontractors to comply with new and evolving government guidance concerning public health protocols, leaving only a small number of critical maintenance staff remaining on site. At the time of the suspension of work on the TeesREP project, APC had completed approximately 90% of its subcontracted work. However, as of April 30, 2020 and based on an updated forecast of subcontract costs, management expected that such costs for the TeesREP project at completion would exceed forecasted revenues by approximately $36.2 million. The additional subcontract loss in the amount of approximately $2.7 million was reflected in the consolidated amount of gross profit for the three months ended April 30, 2020.

Negotiated changes to the contractual arrangements for the TeesREP project and the redirected efforts of the top management of APC and the project team resulted in the reduction of the final amount of the loss incurred on the fixed-price portion of the TeesREP project to $29.5 million. Final closeout adjustments may result in future changes in the amount of this loss; however, APC has included an estimate of these costs in accrued expenses in the accompanying consolidated balance sheet as of April 30, 2021 and January 31, 2021. Project activities conducted by APC during the three-month period ended April 30, 2021, which were performed under a time and materials arrangement, were profitable.

Prior to April 30, 2021, APC completed its on-site activities at the TeesREP project location and commenced the process of resolving certain remaining contractual matters, collecting final amounts owed and confirming its commitment to perform the necessary services under its assurance warranty. The total amounts of accounts receivable and contract assets related to the TeesREP Project and included in the condensed consolidated balance sheets were $1.6 million as of April 30, 2021 and $4.7 million as of January 31, 2021.

Remaining Unsatisfied Performance Obligations (“RUPO”)

The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under the revenue recognition rules of US GAAP. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations.

9

At April 30, 2021, the Company had RUPO of $478.7 million. The largest portion of RUPO at any date usually relates to EPC service contracts with typical performance durations of one to three years. However, the length of certain significant construction projects may exceed three years. The Company estimates that approximately 58% of the RUPO amount at April 30, 2021 will be included in the amount of consolidated revenues that will be recognized during the latter three quarters of the fiscal year ending January 31, 2022. Most of the remaining amount of RUPO at April 30, 2021 is expected to be recognized in revenues during the fiscal year ending January 31, 2023.

Revenues for future periods will also include amounts related to customer contracts started or awarded subsequent to April 30, 2021. It is important to note that estimates may be changed in the future and that cancellations, deferrals or scope adjustments may occur related to work included in the amount of RUPO at April 30, 2021. Accordingly, RUPO may be adjusted to reflect project delays and cancellations, revisions to project scope and cost and foreign currency exchange fluctuations, or to revise estimates, as effects become known. Such adjustments may materially reduce future revenues below Company estimates.

Disaggregation of Revenues

The following table presents consolidated revenues for the three months ended April 30, 2021 and 2020, disaggregated by the geographic area where the corresponding projects were located:

	Three Months Ended April 30,
	2021		2020
United States	$	115,491	$	48,865
United Kingdom		6,157		10,296
Republic of Ireland		4,693		987
Consolidated Revenues	$	126,341	$	60,148

The major portion of the Company’s consolidated revenues are recognized pursuant to fixed-price contracts with most of the remaining portions earned pursuant to time-and-material contracts. Consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements.

NOTE 3 – CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

At April 30, 2021 and January 31, 2021, significant amounts of cash and cash equivalents were invested in government and prime money market funds with net assets invested in high-quality money market instruments. Such investments include US Treasury obligations; obligations of US government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by US government obligations. Due to market conditions, returns on money market instruments are currently minimal. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

Short-term investments as of April 30, 2021 and January 31, 2021 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of less than one year. The Company has the intent and ability to hold the CDs until they mature, and they are carried at cost plus accrued interest which approximates fair value. Interest income is recorded when earned and is included in other income. At April 30, 2021 and January 31, 2021, the weighted average annual interest rate of the outstanding CDs was 0.2% at each period end.

In addition, the Company has a substantial portion of its cash on deposit in the US at the Bank in excess of federally insured limits. Management does not believe that the combined amount of the CD investments and the cash deposited with the Bank represents a material risk. The Company also maintains certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

NOTE 4 – ACCOUNTS AND NOTES RECEIVABLE

The Company generally extends credit to a customer based on an evaluation of the customer’s financial condition without requiring tangible collateral. Exposure to losses on accounts and notes receivable is expected to differ due to the varying financial condition of each customer. The Company monitors its exposure to credit losses and may establish an allowance

10

for credit losses based on management’s estimate of the loss that is expected to occur over the remaining life of the particular financial asset.

At April 30, 2021 and January 31, 2021, the amounts of credit losses expected by management were insignificant. The amounts of the provision for credit losses for the three months ended April 30, 2021 and 2020 were insignificant.

As of April 30, 2021, there were outstanding invoices billed to a former customer and unbilled costs incurred on the related project, with balances included in both accounts receivable and contract assets in the aggregate amount of $24.5 million. The recovery time related to this amount will most likely depend on the resolution of the outstanding legal dispute between the parties (see Note 8).

As of April 30, 2021, there were past due notes receivable from project developers in the aggregate amount of $1.8 million, for which full receipt will most likely depend on the successful financing of the related projects. The Company placed these notes receivable on a non-accrual status during Fiscal 2021.

NOTE 5 – PURCHASED INTANGIBLE ASSETS

At both April 30, 2021 and January 31, 2021, the goodwill balances related to the acquisitions of GPS and TRC were $18.5 million and $9.5 million, respectively. Management does not believe that any events or circumstances that have occurred or arisen since January 31, 2021 require an updated assessment of the goodwill balances of either GPS or TRC.

The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of April 30, 2021 and January 31, 2021:

		April 30, 2021						January 31,
	Estimated	Gross		Accumulated		Net		2021, (net
	Useful Life	Amounts		Amortization		Amounts		amounts)
Trade names
TRC	15 years	$	4,499	$	1,625	$	2,874	$	2,949
GPS	15 years		3,643		3,497		146		208
Process certifications	7 years		1,897		1,468		429		497
Customer relationships	10 years		916		496		420		443
Totals		$	10,955	$	7,086	$	3,869	$	4,097

NOTE 6 – FINANCING ARRANGEMENTS

The original term of the Company’s Amended and Restated Replacement Credit Agreement with the Bank (the “Credit Agreement”) was scheduled to expire on May 31, 2021. During April 2021, negotiations with the Bank were completed which, among other items, extended the expiration date of the Credit Agreement, as amended, to May 31, 2024 and reduced the borrowing rate. The Credit Agreement, as amended, includes the following features, among others: a lending commitment of $50.0 million including a revolving loan with interest at the 30-day LIBOR plus 1.6% (reduced from 2.0%), and an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions. The Company may use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business as defined by the Bank. At April 30, 2021, the Company had $1.8 million of outstanding letters of credit issued under the Credit Agreement. Additionally, in connection with the current project development activities of the VIE that is described in Note 1, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the approximate amount of $3.4 million as of April 30, 2021 and January 31, 2021 for which the Company has provided cash collateral.

The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement, as amended, also includes other terms, covenants and events of default that are customary for a credit facility of its size and nature, including a requirement to achieve positive adjusted earnings before interest, taxes, depreciation and amortization, as defined, over each rolling twelve-month measurement period. As of April 30, 2021 and January 31, 2021, the Company was in compliance with the covenants of the Credit Agreement.

11

NOTE 7 – COMMITMENTS

Leases

The Company’s operating leases primarily cover office space that expire on various dates through January 2025 and certain equipment used by the Company in the performance of its construction services contracts. Some of these equipment leases are embedded in broader agreements with subcontractors or construction equipment suppliers. The Company has no material finance leases. None of the operating leases includes significant amounts for incentives, rent holidays or price escalations. Under certain lease agreements, the Company is obligated to pay property taxes, insurance, and maintenance costs.

Operating lease right-of-use assets and associated lease liabilities are recorded in the balance sheet at the lease commencement date based on the present value of future minimum lease payments to be made over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate (historically, LIBOR plus 2.0%) at the commencement date in determining the present value of future payments. The expected lease term includes any option to extend or to terminate the lease when it is reasonably certain the Company will exercise such option.

Operating lease expense amounts are recorded on a straight-line basis over the expected lease terms and were $0.8 million and $0.4 million for the three months ended April 30, 2021 and 2020, respectively. Operating lease payments for the three months ended April 30, 2021 and 2020 were $0.8 million and $0.4 million, respectively. For operating leases as of April 30, 2021, the weighted average lease term is 32 months and the weighted average discount rate is 3.0%.

The Company also uses equipment and occupies other facilities under short-term rental agreements. Rent expense amounts incurred under operating leases and short-term rental agreements (including portions of the lease expense amounts disclosed above) and included in costs of revenues for the three months ended April 30, 2021 and 2020 were $3.0 million and $0.6 million, respectively. Rent expense incurred under these types of arrangements (including portions of the lease expense amounts disclosed above) and included in selling, general and administrative expenses for the three months ended April 30, 2021 and 2020 was $0.2 million for both periods.

The aggregate amounts of operating leases added during the three months ended April 30, 2021 and 2020 were $0.5 million and $0.4 million, respectively. The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of April 30, 2021.

Years Ending January 31,
Remainder of 2022	$	1,925
2023		967
2024		283
2025		132
2026		20
Total lease payments		3,327
Less interest portion		90
Present value of lease payments		3,237
Less current portion (included in accrued expenses)		1,997
Non-current portion	$	1,240

The future minimum lease payments presented above include amounts due under a long-term lease covering the primary offices and plant for TRC with the founder and current chief executive officer of TRC at an annual rate of $0.3 million with a term extending through April 30, 2022.

Performance Bonds and Guarantees

In the normal course of business and for certain major projects, the Company may be required to obtain surety or performance bonding, to cause the issuance of letters of credit, or to provide parent company guarantees (or some combination thereof) in order to provide performance assurances to clients on behalf of its contractor subsidiaries. As these subsidiaries are wholly-owned, any actual liability is ordinarily reflected in the financial statement account balances

12

determined pursuant to the Company’s accounting for contracts with customers. When sufficient information about claims on guaranteed or bonded projects would be available and monetary damages or other costs or losses would be determined to be probable, the Company would record such losses. Any amounts that may be required to be paid in excess of the estimated costs to complete contracts in progress as of April 30, 2021 are not estimable.

As of April 30, 2021, the value of the Company’s unsatisfied bonded performance obligations, covering all of its subsidiaries, was approximately $372 million. In addition, as of April 30, 2021, there were bonds outstanding in the aggregate amount of approximately $6.6 million covering other risks including warranty obligations related to projects completed by GPS; these bonds expire at various dates over the next twelve months. Not all of our projects require bonding.

On behalf of APC, Argan provided a parent company performance guarantee to APC’s customer, the EPC services contractor on the TeesREP project, which was supported by a performance bond issued on behalf of the customer which, in connection with the completion of subcontract construction activities, will be replaced by a warranty bond in the amount of approximately $4.2 million.

As of April 30, 2021, the Company has also provided a financial guarantee, subject to certain terms and conditions, on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million in support of business development efforts. The Company believes that the fair value of this guarantee as of April 30, 2021 is not material.

Warranties

The Company generally provides assurance-type warranties for work performed under its construction contracts. The warranties cover defects in equipment, materials, design or workmanship, and most warranty periods typically run from nine to twenty-four months after the completion of construction on a particular project. Because of the nature of the Company’s projects, including project owner inspections of the work both during construction and prior to substantial completion, the Company has not experienced material unexpected warranty costs in the past. Warranty costs are estimated based on experience with the type of work and any known risks relative to each completed project. The accruals of liabilities, which are established to cover estimated future warranty costs, are recorded as the contracted work is performed, and they are included in the amounts of accrued expenses in the condensed consolidated balances sheets. The liability amounts may be periodically adjusted to reflect changes in the estimated size and number of expected warranty claims.

Solar Energy Projects

The Company has made equity investments in several solar energy projects which are accounted for using the equity method of accounting. Other than the Company making initial investment payments to a new solar energy fund in the amount of approximately $3.5 million during the three-month period ended April 30, 2021, the activities related to these projects during the period were not meaningful.  As of April 30, 2021, the Company has a remaining $1.5 million cash investment commitment to the new fund.

NOTE 8 – LEGAL CONTINGENCIES

In the normal course of business, the Company may have pending claims and legal proceedings. In the opinion of management, based on information available at this time, there are no current claims and proceedings that could have a material adverse effect on the condensed consolidated financial statements except for the outstanding matter described below.

In January 2019, GPS filed a lawsuit against Exelon West Medway II, LLC and Exelon Generation Company, LLC (together referred to as “Exelon”) in the US District Court for the Southern District of New York for Exelon’s breach of contract and failure to remedy various conditions which negatively impacted the schedule and the costs associated with the construction by GPS of a gas-fired power plant for Exelon in Massachusetts. As a result, the Company believes that Exelon has received the benefits of the construction efforts of GPS and the corresponding progress made on the project without making payments to GPS for the value received (see Note 4). In March 2019, Exelon provided GPS with a notice intending to terminate the EPC contract under which GPS had been providing services to Exelon. At that time, the construction project was nearly complete and both of the power generation units included in the plant had successfully reached first fire. The completion of various prescribed performance tests and the clearance of punch-list items were the primary tasks necessary to be accomplished by GPS in order to achieve substantial completion of the power plant.

13

Nevertheless, and among other actions, Exelon provided contractual notice requiring GPS to vacate the construction site. Exelon has asserted that GPS failed to fulfill certain obligations under the contract and was in default, withholding payments from GPS on invoices rendered to Exelon in accordance with the terms of the contract between the parties.

With vigor, GPS intends to continue to assert its rights under the EPC contract with Exelon, to pursue the collection of amounts owed under the EPC contract and to defend itself against the allegations that GPS did not perform in accordance with the contract. The discovery period related to this litigation is now closed for both parties. No trial date has yet to be set for this lawsuit. Mediation on this matter has been set to occur in September 2021.

NOTE 9 – STOCK-BASED COMPENSATION

The Company’s board of directors may make share-based awards under the 2011 Stock Plan (the “2011 Plan”) or the 2020 Stock Plan (the “2020 Plan”) to officers, directors and key employees (together, the “Stock Plans”). On June 23, 2020, the Company’s stockholders approved the adoption of the 2020 Plan, and the allocation of 500,000 shares of the Company’s common stock for issuance thereunder. The 2020 Plan will serve to replace the 2011 Plan; the Company’s authority to make awards pursuant to the 2011 Plan will expire on July 19, 2021.

The features of the 2020 Plan are similar to those included in the 2011 Plan. Awards may include nonqualified stock options, incentive stock options,  and restricted or unrestricted stock. The specific provisions for each award made pursuant to the terms of the Stock Plans are documented in a written agreement between the Company and the awardee. All stock options awarded under the Stock Plans shall have an exercise price per share at least equal to the common stock’s market value on the date of grant. Stock options shall have terms no longer than ten years. Typically, stock options are awarded with one-third of each stock option vesting on each of the first three anniversaries of the corresponding award date.

As of April 30, 2021, there were approximately 2,090,929 shares of the Company’s common stock reserved for issuance under the Stock Plans; this number includes 493,528 shares of common stock available for future awards.

Stock Options

A summary of stock option activity under the Company’s approved Stock Plans for the three months ended April 30, 2021, along with corresponding weighted average per share amounts, is presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2021	1,405	$	44.17	6.90	$	10.39
Granted	32	$	54.60
Exercised	(26)	$	39.37
Forfeited	(3)	$	42.31
Outstanding, April 30, 2021	1,408	$	44.50	6.77	$	10.44
Exercisable, April 30, 2021	1,029	$	45.47	6.01	$	11.24
Outstanding, April 30, 2020	1,431	$	43.69	7.33	$	10.45
Exercisable, April 30, 2020	874	$	45.78	6.17	$	11.74

The change in the number of non-vested options to purchase shares of common stock for the three months ended April 30, 2021, and the weighted average fair value per share for each number, is presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2021	467	$	8.01
Granted	32	$	11.12
Vested	(117)	$	8.06
Forfeitures	(3)	$	8.67
Non-vested, April 30, 2021	379	$	8.25
Non-vested, April 30, 2020	557	$	8.42

14

The total intrinsic value amount of the stock options exercised during the three-month period ended April 30, 2021 and 2020 was $0.3 million for both periods. At April 30, 2021, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $12.5 million and $9.2 million, respectively.

Restricted Stock Units

The changes in the maximum number of restricted stock units for the three months ended April 30, 2021, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Outstanding, February 1, 2021	117	$	17.71
Awarded	113	$	38.91
Issued	(40)	$	20.64
Outstanding, April 30, 2021	190	$	29.73
Outstanding, April 30, 2020	117	$	17.71

Performance-Based Restricted Stock Units

Pursuant to the terms of the Stock Plans and as described in the corresponding agreements with the executives, the Company awarded performance-based restricted stock units to four senior executives in April 2021 and two senior executives in 2020, covering up to 49,000 and 45,000 maximum total numbers of shares of common stock, respectively, plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards. The issuance of the number of shares earned under the agreements, free of related restrictions, depends on the total return performance of the Company’s common stock measured against the performance of a peer-group of common stocks over three-year periods.

During the three months ended April 30, 2021, the three-year vesting period for the restricted stock units awarded in April 2018 concluded and it was determined that 40,471 shares of common stock, including shares attributable to cash dividends, were earned pursuant to the performance criteria and other terms of the 2011 Plan and the applicable award agreements. These shares were issued to the awardees in April 2021.

Renewable Performance-Based Restricted Stock Units

In April 2021, the Company awarded renewable performance-based restricted stock units to two senior executives at GPS pursuant to the terms of the Stock Plans and as described in the corresponding agreements with the executives. Each award covers 5,000 shares of the Company’s common stock plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards.

The issuance of the shares, free of restrictions, shall be based on the success of GPS in increasing the amount of RUPO related to renewable energy projects, as defined, during certain periods within the three-year term of each award. The awards establish RUPO hurdle amounts for separate periods of time defined in the awards, and assign a certain portion of the award shares to each hurdle. If a RUPO hurdle is exceeded (each is mutually exclusive), the number of shares earned based on the achievement of the applicable hurdle will be issued to the executives at the end of the corresponding period. If a RUPO hurdle amount is not achieved within the period of time defined in the awards, the award shares assigned to the hurdle are forfeited. 

Time-Based Restricted Stock Units

In April 2021, the Company also awarded time-based restricted stock units covering 49,500 shares of common stock to senior executives and other employees pursuant to the terms of the Stock Plans and as described in the corresponding agreements with each awardee. The shares will vest in equal installments on each of the first three anniversaries of the award date. Accordingly, at each vesting date, one-third of the award shares plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards will be issued to each awardee.

15

Fair Value

The fair values of stock options and restricted stock units are recorded as stock compensation expense over the terms of the corresponding awards. Expense amounts related to stock awards were $0.7 million and $0.6 million for the three months ended April 30, 2021 and 2020, respectively. At April 30, 2021, there was $7.4 million in unrecognized compensation cost related to outstanding stock awards that the Company expects to expense over the next three years.

The Company estimates the weighted average fair value of stock options on the date of award using a Black-Scholes option pricing model. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. Risk-free interest rates are determined by blending the rates for three to five year US Treasury notes. The dividend yield is based on the Company’s current annual regular dividend amount. The calculations of the expected volatility factors are based on the monthly closing prices of the Company’s common stock for the five-year periods preceding the dates of the corresponding awards.

The fair value amounts for the performance-based restricted stock units have been determined by using the per share market price of the Company’s common stock on the dates of award and the target number of shares for the awards (50% of the maximum number), by assigning equal probabilities to the thirteen possible payout outcomes at the end of each three-year term, and by computing the weighted average of the outcome amounts. For each award, the estimated fair value amount was calculated to be 88.5% of the aggregate market value of the target number of shares on the award date. For the renewable performance-based restricted stock units, which were awarded for the first time in April 2021, the fair value of each award was determined to be 50% of the aggregate market value of the shares of common stock covered by the award on the date of the award. For the time-based restricted stock units, the fair value of each award equals the aggregate market price for the number of shares covered by each award on the date of award.

NOTE 10 – INCOME TAXES

Income Tax Expense Reconciliation

The Company’s income tax amounts for the three months ended April 30, 2021 and 2020 differed from corresponding amounts computed by applying the federal corporate income tax rate of 21% to the income (loss) before income taxes for the periods as presented below:

	Three Months Ended April 30,
	2021		2020
Computed expected income tax (expense) benefit	$	(3,052)	$	1,102
Difference resulting from:
State income taxes, net of federal tax effect		(334)		—
Deferred tax asset adjustments		(284)		—
Net operating loss carryback benefit (see discussion below)		—		4,175
Net operating losses deemed unrealizable (UK)		—		(695)
Adjustments and other differences		(98)		(128)
Income tax (expense) benefit	$	(3,768)	$	4,454

Foreign income tax expense amounts for the three months ended April 30, 2021 and 2020 were not material except that for the three months ended April 30, 2020, the valuation allowance established against the unrealizable net operating loss benefits of the subsidiary located in the UK was increased by $0.7 million.

During the quarter ended April 30, 2021, the Company wrote-off previously established deferred tax assets in the amount of $0.3 million based on the estimated non-deductible portion of stock option compensation.    

16

Net Operating Loss (“NOL”) Carryback

In an effort to combat the adverse economic impacts of the COVID-19 crisis, the US Congress passed the Coronavirus, Aid, Relief, and Economic Security Act ( the “CARES Act”) that was signed into law on March 27, 2020. This wide-ranging legislation was an emergency economic stimulus package that included spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19.

The tax changes of the CARES Act included a temporary suspension of the limitations on the future utilization of certain NOLs and re-established a carryback period for certain losses to five years. The NOLs eligible for carryback under the CARES Act include the Company’s domestic NOL for the year ended January 31, 2020, which was approximately $39.5 million. The Company made the appropriate filing with the Internal Revenue Service (the “IRS”) requesting carryback refunds of income taxes paid for the years ended January 31, 2017, 2016 and 2015.

A deferred tax asset in the amount of $8.3 million was recorded as of January 31, 2020 associated with the income tax benefit of the NOL for the year then ended. With the enactment of the CARES Act, the asset was moved to income taxes receivable (included in other current assets in the condensed consolidated balance sheets as of April 30, 2021 and January 31, 2021) where the value was increased to approximately $12.7 million. The carryback provided a favorable rate benefit for the Company as the loss, which was incurred in a year where the statutory federal tax rate was 21%, has been carried back to tax years where the tax rate was higher. The substantial portion of the net amount of this additional income tax benefit, estimated at the time to be approximately $4.2 million, was recorded in the three-month period ended April 30, 2020.

Research and Development Tax Credits

During Fiscal 2019, the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development tax credits that may have been available to reduce prior year income taxes. This study focused on project costs incurred during the three-year period ended January 31, 2018. Based on the results of the study, management identified and estimated significant amounts of income tax benefits that were not previously recognized in the Company’s operating results for any prior year reporting period.

The amount of research and development tax credit benefit recognized in Fiscal 2019 was $16.6 million. During Fiscal 2020, deferred tax assets related to the research and development tax credits were reduced by $0.4 million. As described below, the IRS has concluded examinations of the Company’s consolidated federal income tax returns for the years ended January 31, 2016 (“Fiscal 2016”) and 2017 (“Fiscal 2017”), as amended to include research and development tax credits, and has commenced an examination of the Company’s consolidated federal income tax return for the year ended January 31, 2018 (“Fiscal 2018”) with an expressed intent to focus on the research and development tax credit included therein. All of the aforementioned filings were made prior to January 31, 2019.

The amount of identified but unrecognized income tax benefits related to research and development tax credits as of April 30, 2021 is $5.0 million, for which the Company has established a liability for uncertain income tax return positions, most of which is included in accrued expenses as of April 30, 2021 and January 31, 2021. The final outcome of these uncertain tax positions is not yet determinable. However, the Company does not expect that the amount of unrecognized tax benefits will significantly change due to any expiration of statutes of limitation over the next 12 months. However, it is possible that the disputes with the IRS related to the Company’s federal research and development tax credits (see discussion of income tax returns below) could be resolved within the next twelve months depending on the scheduling of an appeals hearing and/or the results of negotiations with the IRS. If resolution of the disputes occurs, it would result in the Company’s elimination of at least a substantial portion of the amount of the liability for uncertain income tax positions discussed above. As of April 30, 2021, the Company does not believe that it has any other material uncertain income tax positions reflected in its accounts.

As of April 30, 2021 and January 31, 2021, the balances of other current assets in the condensed consolidated balance sheet included income tax refunds and prepaid income taxes in the total amount of approximately $26.9 million at each date. The income tax refunds include the amounts expected to be received from the IRS upon completion of the tax return examination appeals process identified below and the amount expected to be received from the IRS upon its processing of the Company’s NOL carryback refund request discussed above.

17

Income Tax Returns

The Company is subject to federal and state income taxes in the US, and income taxes in Ireland and the UK. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2017 except for several notable exceptions including Ireland, the UK and several states where the open periods are one year longer.

The IRS conducted an examination of the Company’s original federal consolidated income tax return for Fiscal 2016. The IRS reported to the Company that no unfavorable adjustment items were noted during this examination. However, the Company consented to an extension of the audit timeline which enabled the IRS to also examine the amendment to the income tax return, which included the research and development credit for the year. In addition, the IRS opened an examination of the Company’s amended consolidated income tax return for Fiscal 2017. In substance, these efforts evolved into simultaneously conducted examinations of the research and development credits claimed in each year.

In January 2021, the IRS issued its final revenue agents report that documents its understanding of the facts, attempts to summarize the Company’s arguments in support of the research and development claims and states its position which disagrees with the Company’s treatment of a substantial amount of the costs that support the Company’s claims for Fiscal 2016 and Fiscal 2017. The Company believes that its arguments are sound and that the report does not present any new facts relating to the issues or make any new arguments that would cause it to make any adjustments to its accounting for the research and development claims as of April 30, 2021. In March 2021, the Company submitted a formal protest of the findings of the IRS examiner and intends to pursue its income tax position with the IRS through the established protest and appeals process. The Company expects that the ultimate settlement of the income tax dispute will be resolved on a basis favorable to the Company.

In November 2020, the Company was notified by the IRS that it intends to examine the consolidated income tax return for Fiscal 2018, with an expressed focus on the research and development tax credit claimed therein. The Company expects that by the time the appeals process commences, its protest will dispute the results of the examinations of the tax returns for all three years.

Supplemental Cash Flow Information

The Company was not required to make any income tax payments during the three months ended April 30, 2021 or 2020. During the three months ended April 30, 2021, the Company did not receive any income tax refunds that were material. During the three months ended April 30, 2020, the Company received cash refunds of previously paid income taxes from various taxing authorities in the total amount of $0.8 million.

NOTE 11 – NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in the notes):

	Three Months Ended April 30,
	2021		2020
Net income (loss) attributable to the stockholders of Argan	$	10,766	$	(763)
Weighted average number of shares outstanding – basic		15,726		15,643
Effect of stock awards (1)(2)		235		—
Weighted average number of shares outstanding – diluted		15,961		15,643
Net income (loss) per share attributable to the stockholders of Argan
Basic	$	0.68	$	(0.05)
Diluted	$	0.67	$	(0.05)

(1) For the three months ended April 30, 2021, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 279,500 shares of common stock.

(2) For the three months ended April 30, 2020, all common stock equivalents, which covered 1,483,151 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

18

NOTE 12 – CASH DIVIDENDS

On April 14, 2021, the Company’s board of directors declared a regular quarterly cash dividend in the amount of $0.25 per share of common stock, which was paid on April 30, 2021 to stockholders of record at the close of business on April 22, 2021. Last year, the board of directors declared a regular quarterly cash dividend of $0.25 per share of common stock, which was paid to stockholders on April 30, 2020.

NOTE 13 – CUSTOMER CONCENTRATIONS

The majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided 77% and 81% of consolidated revenues for the three months ended April 30, 2021 and 2020, respectively. The industrial services segment represented 21% and 16% of consolidated revenues for the three months ended April 30, 2021 and 2020, respectively.

The Company’s most significant customer relationships for the three months ended April 30, 2021 included one power industry service customer, which accounted for 68% of consolidated revenues. The Company’s most significant customer relationships for the three months ended April 30, 2020 included two power industry service customers, which accounted for 61% and 17% of consolidated revenues, respectively.

The accounts receivable balances from two major customers each represented 23% of the corresponding consolidated balance as of April 30, 2021. Accounts receivable balances from three major customers represented 26%, 11% and 11% of the corresponding consolidated balance as of January 31, 2021. The contract asset balance from one major customer represented 65% of the corresponding consolidated balance as of April 30, 2021. Contract asset balances from two major customers represented 64% and 12% of the corresponding consolidated balance as of January 31, 2021.

NOTE 14 – SEGMENT REPORTING

Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than one operating segment. Intersegment revenues and the related cost of revenues are netted against the corresponding amounts of the segment receiving the intersegment services. For the three months ended April 30, 2021 and 2020, intersegment revenues totaled approximately $2.0 million and $0.6 million, respectively. Intersegment revenues for the aforementioned periods primarily related to services provided by the industrial fabrication and field services segment to the power industry services segment and were based on prices negotiated by the parties.

19

Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three months ended April 30, 2021 and 2020. The “Other” column in each summary includes the Company’s corporate expenses.

Three Months Ended	Power		Industrial		Telecom
April 30, 2021	Services		Services		Services		Other		Totals
Revenues	$	97,172	$	26,658	$	2,511	$	—	$	126,341
Cost of revenues		78,669		21,969		1,989		—		102,627
Gross profit		18,503		4,689		522		—		23,714
Selling, general and administrative expenses		5,455		1,882		486		2,069		9,892
Income (loss) from operations		13,048		2,807		36		(2,069)		13,822
Other income, net		710		—		—		2		712
Income (loss) before income taxes	$	13,758	$	2,807	$	36	$	(2,067)		14,534
Income tax expense										(3,768)
Net income									$	10,766
Amortization of intangibles	$	61	$	167	$	—	$	—	$	228
Depreciation		166		607		108		1		882
Property, plant and equipment additions		602		9		232		1		844
Current assets	$	371,827	$	27,422	$	2,433	$	157,349	$	559,031
Current liabilities		265,471		14,796		1,212		1,586		283,065
Goodwill		18,476		9,467		—		—		27,943
Total assets		408,442		47,840		3,974		157,716		617,972

Three Months Ended	Power		Industrial		Telecom
April 30, 2020	Services		Services		Services		Other		Totals
Revenues	$	48,612	$	9,744	$	1,792	$	—	$	60,148
Cost of revenues		45,710		8,982		1,447		—		56,139
Gross profit		2,902		762		345		—		4,009
Selling, general and administrative expenses		5,928		2,123		488		1,805		10,344
Loss from operations		(3,026)		(1,361)		(143)		(1,805)		(6,335)
Other income, net		1,024		—		—		64		1,088
Loss before income taxes	$	(2,002)	$	(1,361)	$	(143)	$	(1,741)		(5,247)
Income tax benefit										4,454
Net loss									$	(793)
Amortization of intangibles	$	60	$	165	$	—	$	—	$	225
Depreciation		170		667		99		1		937
Property, plant and equipment additions		380		210		94		—		684
Current assets	$	316,753	$	22,916	$	2,434	$	113,633	$	455,736
Current liabilities		163,674		8,184		793		455		173,106
Goodwill		18,476		9,467		—		—		27,943
Total assets		348,577		46,411		4,013		113,963		512,964

20

ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS.

The following discussion summarizes the financial position of Argan, Inc. and its subsidiaries as of April 30, 2021, and the results of their operations for the three-month periods ended April 30, 2021 and 2020, and should be read in conjunction with (i) the unaudited condensed consolidated financial statements and notes thereto included elsewhere in this Quarterly Report on Form 10-Q and (ii) the consolidated financial statements and accompanying notes included in our Annual Report on Form 10-K for Fiscal 2021 that was filed with the SEC on April 14, 2021 (the “Annual Report”).  

Cautionary Statement Regarding Forward Looking Statements

The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for certain forward-looking statements. We have made statements in this Item 2 and elsewhere in this Quarterly Report on Form 10-Q that may constitute “forward-looking statements.” The words “believe,” “expect,” “anticipate,” “plan,” “intend,” “foresee,” “should,” “would,” “could,” or other similar expressions are intended to identify forward-looking statements. Our forward-looking statements, including those relating to the potential effects of the COVID-19 pandemic on our business, financial position and results of operations, are based on our current expectations and beliefs concerning future developments and their potential effects on us.

There can be no assurance that future developments affecting us will be those that we anticipate. All comments concerning our expectations for future revenues and operating results are based on our forecasts for existing operations and do not include the potential impact of any future acquisitions.

Our forward-looking statements, by their nature, involve significant risks and uncertainties (some of which are beyond our control) and assumptions. They are subject to change based upon various factors including, but not limited to, the risks and uncertainties described in this Quarterly Report on Form 10-Q and our Annual Report. Should one or more of these risks or uncertainties materialize, or should any of our assumptions prove to be incorrect, actual results may vary in material respects from those projected in the forward-looking statements. We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise.

Business Description

Argan is a holding company that conducts operations through its wholly-owned subsidiaries, GPS, APC, SMC and TRC. Through GPS and APC, we provide a full range of engineering, procurement, construction, commissioning, operations management, maintenance, development, technical and consulting services to the power generation market, including the renewable energy sector, for a wide range of customers, including independent power project owners, public utilities, equipment suppliers and global energy plant construction firms. GPS and APC represent our power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeastern region of the US and that are based on its expertise in producing, delivering and installing fabricated steel components such as piping systems and pressure vessels. Through SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

We intend to make additional opportunistic acquisitions and/or investments by identifying companies with significant potential for profitable growth and realizable synergies with one or more of our existing businesses. However, we may have more than one industrial focus depending on the opportunity. We expect that acquired companies will be maintained in separate subsidiaries that will be operated in a manner that best provides cash flows for the Company and value for our stockholders.

Overview

Operating Results

Consolidated revenues for the three months ended April 30, 2021 were $126.3 million, which represented an increase of $66.2 million, or 110.1%, from consolidated revenues of $60.1 million reported for the three months ended April 30, 2020.

21

The revenues of the power industry services segment increased by $48.6 million to $97.2 million for the three months ended April 30, 2021, from $48.6 million reported for the three months ended April 30, 2020. The revenues of this reportable segment of our business represented 76.9% of consolidated revenues for the three months ended April 30, 2021. For the three months ended April 30, 2020, the percentage share of consolidated revenues represented by this reportable segment was 80.8%. The industrial services business of TRC reported revenues of $26.7 million for the three months ended April 30, 2021. This amount represented an increase of $16.9 million, or 173.6%, from revenues of $9.7 million reported by TRC for the three months ended April 30, 2020. Revenues provided by this reportable business segment represented 21.1% and 16.2% of corresponding consolidated revenues for the three months ended April 30, 2021 and 2020, respectively.

Consolidated gross profit for the three-month period ended April 30, 2021 was $23.7 million, or 18.8% of the corresponding consolidated revenues, which reflected primarily the favorable impacts of the higher amount of consolidated revenues and favorable contributions from all three reportable business segments. For the three-month period ended April 30, 2020, the consolidated gross profit was $4.0 million, which represented approximately 6.7% of the corresponding amount of consolidated revenues and reflected $2.7 million of subcontract loss related to APC’s TeesREP project.

Selling, general and administrative expenses for the three months ended April 30, 2021 and 2020 were $9.9 million, or 7.8% of corresponding consolidated revenues, and $10.3 million, or 17.2% of corresponding consolidated revenues, respectively.

Due primarily to the consolidated pre-tax book income reported for the three-month period ended April 30, 2021 in the amount of $14.5 million, we reported income tax expense in the amount of $3.8 million for the period. For the three-month period ended April 30, 2020, we recorded an income tax benefit in the amount of $4.5 million which amount included primarily $4.2 million of the carryback benefit related to the net operating loss incurred by us for the year ended January 31, 2020.

For the three months ended April 30, 2021, our improved overall operating performance resulted in net income attributable to our stockholders in the amount of $10.8 million, or $0.67 per diluted share. Last year, despite the favorable effect of the net operating loss carryback benefit identified above, we reported a net loss attributable to our stockholders in the amount of $0.8 million, or $0.05 per dilutive share.

The primary drivers of our improved financial performance for the three-month period ended April 30, 2021 were the increasing revenues and steady gross margin contributions associated with the construction of the Guernsey Power Station by GPS. This project represented the major portion of our business for the period.

Engineering, Procurement and Construction Service Contracts

At April 30, 2021, the project backlog for the power industry services reporting segment was approximately $0.7 billion. The comparable backlog amount as of January 31, 2021 was approximately $0.8 billion. Our reported amount of project backlog at a point in time represents the total value of projects awarded to us that we consider to be firm as of that date less the amounts of revenues recognized to date on the corresponding projects (project backlog is larger than the value of remaining unsatisfied performance obligations, or RUPO, on active contracts; see Note 2 to the accompanying consolidated financial statements). Cancellations or reductions may occur that would reduce project backlog and our expected future revenues.

Typically, we include the total value of EPC services and other major construction contracts in project backlog when we receive a corresponding notice to proceed from the project owner. However, we may include the value of an EPC services contract prior to the receipt of a notice to proceed if we believe that it is probable that the project will commence within a reasonable timeframe, among other factors. Projects that are awarded to us may remain included in our backlog for extended periods of time as customers experience project delays.

A substantial amount of the project backlog amount at April 30, 2021 was represented by the Guernsey Power Station. The ramp-up of activity on this project since August 2019 has favorably impacted our consolidated operating results since then with its increasing revenues. Substantial completion of this project is currently scheduled to occur during the second half of the fiscal year ending January 31, 2023.

22

In January 2020, GPS entered into an EPC services contract with Harrison Power, LLC (“Harrison Power”) to construct a 1,085 MW natural gas-fired power plant in the Village of Cadiz, Harrison County, Ohio. The project is being developed by EmberClear, the parent company of Harrison Power. On March 12, 2020, we announced that GPS had entered into an EPC services contract with NTE Connecticut, LLC to construct the Killingly Energy Center, a 650 MW natural gas-fired power plant, in Killingly, Connecticut. The facility is being developed by NTE Energy, LLC. We anticipate adding the value of each of these new contracts to project backlog at times closer to their financial close and expected start dates. We are cautiously optimistic that the start of construction activities for these projects will occur before the end of our fiscal year ending January 31, 2022. However, we cannot predict with certainty when the projects will commence. The start dates for construction are generally controlled by the project owners.

In May 2019, GPS entered into an EPC services contract to construct a 625 MW power plant in Harrison County, West Virginia. Caithness is partnered with ESC Harrison County Power, LLC to develop this project. As a limited notice to proceed with certain preliminary activities was received from the owner of this project at the time, the value of the contract was added to our project backlog. However, meaningful construction activities for the facility are not likely to begin until financial close is achieved which will probably not occur before January 31, 2022.

As announced in Fiscal 2019, GPS entered into an EPC services contract to construct the Chickahominy Power Station, a 1,740 MW natural gas-fired power plant, in Charles City County, Virginia. Even though we have been providing financial and technical support to the project development effort through a consolidated VIE and significant project development milestones have been achieved, we have not included the value of this contract in our project backlog. Due to several factors that have interrupted the pace of the development of this project, including additional costs and time being required to secure the natural gas supply for the plant and to obtain the necessary equity financing, we currently cannot predict when construction will commence, if at all.

The aggregate rated electrical output amount for the natural gas-fired power plants for which we have signed EPC services contracts, including the Guernsey Power Station, is approximately 6.4 gigawatts with an aggregate initial contract value of approximately $3.0 billion and an aggregate unrealized contract value of approximately $2.6 billion as of April 30, 2021.

Despite our commitment to the construction of state-of-the-art, natural gas-fired power plants as important elements of our country’s electricity-generation mix in the future, we have been directing certain business development efforts to winning projects for the erection of utility-scale wind farms and solar fields and for the construction of hydrogen-based and other renewable energy projects. We have successfully completed these types of projects in the past and we renewed efforts to obtain new work in the renewable power sector that will complement our natural gas-fired EPC services projects going forward. During the year ended January 31, 2021, GPS began exclusive negotiations with the owners of several significant renewable projects for which we expect to begin EPC services contract activities during the fiscal year ending January 31, 2022 (“Fiscal 2022”). During the quarter ended April 30, 2021, GPS continued to provide pre-construction contract assistance, that commenced late last year, to one of these customers under a consulting services agreement.

Our efforts led to our announcement in May 2021 that GPS has entered into an EPC services contract with CPV Maple Hill Solar, LLC, an affiliate of Competitive Power Ventures, Inc. (“CPV”), to construct the Maple Hill Solar facility, which we believe will be among the largest solar-powered energy plants in Pennsylvania. Gemma also received notice to proceed with project activities immediately. Project completion is scheduled to occur during the second half of 2022. The unique Maple Hill Solar project, which is located in Cambria County, will be constructed using over 235,000 photovoltaic modules to generate approximately 100 megawatts of electrical power.

We have maintained that the delays in new business awards to GPS and the project construction starts of certain previously awarded projects relate to a variety of factors, especially in the northeastern and mid-Atlantic regions of the US. Currently, we believe that the ability of the owners of fully developed gas-fired power plant projects to close on equity and permanent debt financing was challenged by uncertainty in the capital markets caused by multiple factors including delayed capacity auctions and mounting public and political opposition to fossil-fuel energy projects.  

23

The recent announcement by the PJM of a new capacity auction schedule may remove a certain amount of uncertainty for project developers in forecasting future streams of revenues. In fact, the results of the first capacity auction conducted by PJM in over 3 years were announced on May 2, 2021. Even though it may be disappointing for potential power plant owners to see pricing significantly lower than in prior years, over 5.6 GW of new combined cycle, gas-fired power plants cleared the auction, representing over 75% of all new capacity units. The remaining new capacity was comprised of solar and wind powered energy plants. These mixed results may result in new gas-fired power plant EPC projects continuing to be delayed until the visibility regarding future capacity revenue streams is further restored with the results of the upcoming December 2021 capacity auction for the PJM region.

However, other headwinds for future gas-fired power plant developments remain. Besides the downturn in the demand for electric power during the COVID-19 outbreak in the US that is referenced in the discussion below, factors to consider include an increase in the amount of power generating capacity provided by renewable energy assets, improvements and decreasing prices in renewable energy storage solutions including battery resources, increased environmental activism and the results of the recent presidential election in the US.

Protests against fossil-fuel related energy projects continue to garner media attention and stir public skepticism about new projects resulting in delays due to onsite protest demonstrations, indecision by local officials and lawsuits. Currently, we have a pending project for the construction of a gas-fired power plant project in Killingly, Connecticut. Although substantially all of the permits, approvals and other items necessary for the commencement of the project have been obtained by the project owner, including the securing of capacity auction payments, a financial close on project financing has not yet occurred. During this delay, opposition to the project has been voiced by various government officials and clean air advocates. We currently believe that the start of this project will occur before the end of Fiscal 2022.

In the New England and mid-Atlantic regions of the US, power plant operators are challenged by the requirements of the Regional Greenhouse Gas Initiative, or “RGGI,” which is a cooperative effort by states in these regions to cap and reduce power sector carbon dioxide emissions. In addition, various cities, counties and states have adopted clean energy and carbon-free goals or objectives with achievement expected by a certain future date, typically 10 to 30 years out. These aspirational goals may increase the risk of a new power plant becoming a stranded asset long before the end of its otherwise useful economic life, which is a risk that potential equity capital providers may be unwilling to take. The difficulty in obtaining project equity financing and the other factors identified above may be adversely impacting the planning and initial phases for the construction of new natural gas-fired power plants which continue to be deferred by project owners.

Perhaps the most significant uncertainty relates to the ambitious policies of President Biden who is proposing to make the electricity production in the US carbon free by 2035 and to put the country on the path to achieve net zero carbon emissions by 2050. As he pledged during his presidential campaign, Mr. Biden caused the US to re-join the Paris Climate Agreement and he has cancelled the permit allowing the Keystone XL Pipeline to cross the border from Canada into the US. In addition, Mr. Biden ordered a pause on the US government entering into new oil and natural gas leases on public lands or offshore waters to the extent possible, the launch of a rigorous review of all existing leasing and permitting practices related to fossil fuel development on public lands and waters, and the identification of steps that can be taken to double renewable energy production from offshore wind by 2030. 

Market Outlook

The overall growth of our power business has been substantially based on the number of combined cycle gas-fired power plants built by us, as many coal-fired plants have been shut down. In 2010, coal-fired power plants accounted for about 45% of total electricity generation. By 2020, coal accounted for less than 20% of total electricity generation. On the other hand, natural-gas fired power plants provided approximately 39% of the electricity generated by utility-scale power plants in the US in 2020, representing an increase of 64% from the amount of electrical power generated by natural gas-fired power plants in 2010, which provided approximately 24% of net electricity generation for 2010. In the reference case of its Annual Energy Outlook 2021, the Energy Information Administration (“EIA”) projects that coal-fired generation will continue to decline through 2050, and will represent only 11% of the electricity generation mix by 2050. The projection for natural gas-fired plants is that they will supply 36% of the net electricity generation in the US for 2050. Undoubtedly, the long-term historic decline in the use of coal as a power source in the US has been caused, to a significant extent, by the plentiful supply of inexpensive natural gas which made it the fuel of choice for power plant developers over this period.

24

The share of electricity generation provided by natural gas is particularly reactive in the short term to changing natural gas prices. In recent publications, the EIA explains that natural gas prices have risen recently because of reduced supplies and higher winter heating demand. The increased natural gas prices in the US prompted firms controlling electricity generation facilities to switch fuel sources from gas to coal. The EIA states that coal-fired electrical power generation increased by nearly 40% in the US during the first four months of calendar year 2021 compared with the same period in 2020 and now accounts for 23% of total generation. However, natural gas electric power prices for 2020 were about 18% lower than prices in 2019, and they were approximately 33% lower than they were in 2018.

Nonetheless, a long-term rise in natural gas prices and the resulting reduction in the demand for natural gas-fired electricity generation, could have adverse effects on the ability of independent power producers to obtain construction and permanent financing for new natural gas-fired power plants.  

The pace of the ten-year increase in the preference for natural gas as an electricity generating fuel source was energized by environmental activism and restrictive regulations targeting coal-fired power plants. Now, the environmentalist opposition against coal-fired power generation has expanded meaningfully and effectively to target all fossil fuel energy projects, including power plants and pipelines, and has evolved into powerful support for renewable energy sources.

The share of electricity generation in the US provided by utility-scale wind and solar photovoltaic facilities continues to rise meaningfully. Together, such power facilities provided approximately 8.8% and 10.6% of the total amount of electricity generated by utility-scale power facilities in 2019 and 2020, respectively. In EIA’s 2021 reference case, net electricity generation from all renewable power sources is expected to increase by more than 175%, representing over 42% of such generation, by 2050. Impetus for this growth is provided by public concerns about climate change and favorable economic factors. Environmental activism has resulted in the passage of laws and the establishment of regulations that discourage new fossil-fuel burning power plants and provide income tax advantages that promote the growth of wind and solar power. Declines in the amount of renewable power plant component and power storage costs and an increase in the scale of energy storage capacity (i.e., battery farms) have also occurred. Should the pace of development for renewable energy facilities, including wind and solar power plants, accelerate at faster rates than projected, the number of future natural gas-fired construction project opportunities may fall.

Over the next few years, EIA projects that new wind and photovoltaic solar capacity will continue to be added to the utility-scale power fleet in the US at a brisk pace substantially attributable to declining equipment costs and the availability of valuable tax credits. As these credits decline and then expire early in the next decade as currently scheduled, the wind capacity additions are expected to slow. Although the special tax incentives related to solar power also expire, the continuing decline in the cost of solar power equipment is predicted to sustain the growth of photovoltaic solar power generation facilities.

Nonetheless, we believe that persistently low natural gas prices over the long-term, lower power plant operating costs, higher energy generating efficiencies and the maintenance of grid resiliency should sustain the demand for modern combined cycle gas-fired power plants in the future. Natural gas is relatively clean burning, cost-effective and reliable; we believe that its benefits as a source of power are compelling. We continue to believe that the future long-term prospects for natural gas-fired power plant construction remain generally favorable as natural gas continues to be the primary source for power generation in our country. New gas-fired power plants incorporate major advances in gas-fired turbine technologies that have provided increased power plant efficiencies while providing the quick starting capabilities and the reliability that  are necessary to balance the inherent intermittencies of wind and solar powered energy plants.

It has been reported that renewables currently provide approximately 36% of electricity generation in California. Yet, last summer’s experience is that the increasing dependence on intermittent renewable energy sources, especially solar, is making it harder to ensure reliable power in California as millions of its residents lost power during a late summer heat wave. Analysis of the causes of the recent widespread power outages in Texas during a frigid stretch of winter weather is complex. The residents of Texas suffered as the severe cold froze wind turbines and the lack of sun diminished the power contributions of solar powered facilities. However, natural gas-fired power plants in Texas were forced offline as well primarily due to frozen well-site equipment and the decisions by regulators to prioritize natural gas for residential use, which caused interruptions to the supply of natural gas to the plants. However, in both states, the significant amount of renewable power capacity failed to rise to the occasion.

25

A diversity lesson from both power crises may be that fossil-fuel electricity generation sources remain critical elements of the power generation mix in order to assure grid reliability and the avoidance of power outages.

The North American Electric Corp. (“NERC”), the designated electric reliability organization in the US, issued its 2021 Summer Reliability Assessment on May 26, 2021 that indicated that parts of North America are at elevated or high risk of energy shortfalls during peak summer conditions. NERC noted that the events of this past year and the outlook for summer are stark reminders that in the nation’s hurry to develop a cleaner resource base, reliability and energy adequacy have to be considered.

Additionally, solar and wind energy plant developers continue to confront the problems caused by grid congestion, often unsuccessfully. Many of these projects have been canceled because renewable plants need to be sited where the resources are optimal, often in remote locations where the transmission systems are not robust. The costs associated with the necessary grid upgrades may be prohibitive. US offshore wind projects progress inconsistently, facing challenges in the areas of environmental and fishery impacts, grid connection and capability and federal permitting processes. Further, projects are confronted by shipping regulations in the US that may limit the ability of developers to replicate successful European construction and installation models.  

Major advances in the safe combination of horizontal drilling techniques and hydraulic fracturing led to the boom in natural gas supplies which have been available generally at consistently low prices. The abundant availability of cheap, less carbon-intense and higher efficiency natural gas should continue to be a significant factor in the economic assessment of future power generation capacity additions although the pace of new opportunities emerging may be restrained and the starts of awarded EPC projects may be delayed. We believe that it is also important to note that the plans for two of our contracted natural gas-fired power plant projects include the adoption of integrated green hydrogen solution packages developed by a major gas turbine manufacturer. While the plants will initially burn natural gas alone, it is planned by the respective project owners that the plants will eventually burn a mixture of natural gas and green hydrogen, thereby establishing power-generation flexibility for these plants.

We believe this is a winning combination that provides inexpensive and efficient power, enhances grid reliability and addresses the clean-air concerns of environmentalists. The building of state-of-the-art power plants with flex-fuel capability replaces coal-fired power plants in the short term with relatively clean gas-fired electricity generation. Further, such additions to the power generation fleet provide the potential for the plants to burn 100% green hydrogen gas, which would provide both base load power and long duration backup power, when the sun is not shining and the wind is not blowing, for extended periods of time and without certain harmful air emissions.

We are committed to the rational pursuit of new construction projects and the future growth of our revenues. This may result in our decision to make investments in the development and/or ownership of new projects. Because we believe in the strength of our balance sheet, we are willing to consider certain opportunities that include reasonable and manageable risks in order to assure the award of the related EPC services contracts to us. The competitive landscape in the EPC services market for natural gas-fired power plant construction has changed significantly over the last several years. While the market remains dynamic, we are moving into an era where there may be fewer competitors for new gas-fired power plant EPC services project opportunities. Several major competitors have exited the market for a variety of reasons or have been acquired. Others have announced intentions to avoid entering into fixed-price contracts. Nonetheless, the competition for new utility-scale gas-fired power plant construction opportunities is fierce and still includes multiple global firms.  

We believe that the Company has a reputation as an accomplished and cost-effective provider of EPC and other large project construction contracting services. We are convinced that the latest series of new EPC projects awarded to us confirms the soundness of our belief. With the proven ability to deliver completed power facilities, particularly combined cycle, natural gas-fired power plants, we are focused on expanding our position in the power markets where we expect investments to be made based on forecasts of electricity demand covering decades into the future. We believe that our expectations are valid and that our plans for the future continue to be based on reasonable assumptions. 

Confidence in our financial strength and the prospects for our business going forward prompted our board of directors to declare and to pay two special cash dividends during Fiscal 2021 in the amount of $1.00 per share each, to continue to pay regular cash dividends in the amount of $0.25 per share and to authorize the use of $25.0 million to repurchase shares of our common stock.

26

Comparison of the Results of Operations for the Three Months Ended April 30, 2021 and 2020

We reported net income attributable to our stockholders of $10.8 million, or $0.67 per diluted share, for the three months ended April 30, 2021. For the comparable period of the prior year, we reported a net loss attributable to our stockholders of approximately $0.8 million, or $0.05 per diluted share.

The following schedule compares our operating results for the three months ended April 30, 2021 and 2020 (dollars in thousands):

	Three Months Ended April 30,
	2021		2020		$ Change		% Change
REVENUES
Power industry services	$	97,172	$	48,612	$	48,560	99.9	%
Industrial fabrication and field services		26,658		9,744		16,914	173.6
Telecommunications infrastructure services		2,511		1,792		719	40.1
Revenues		126,341		60,148		66,193	110.1
COST OF REVENUES
Power industry services		78,669		45,710		32,959	72.1
Industrial fabrication and field services		21,969		8,982		12,987	144.6
Telecommunications infrastructure services		1,989		1,447		542	37.5
Cost of revenues		102,627		56,139		46,488	82.8
GROSS PROFIT		23,714		4,009		19,705	491.5
Selling, general and administrative expenses		9,892		10,344		(452)	(4.4)
INCOME (LOSS) FROM OPERATIONS		13,822		(6,335)		20,157	NM
Other income, net		712		1,088		(376)	(34.6)
INCOME (LOSS) BEFORE INCOME TAXES		14,534		(5,247)		19,781	NM
Income tax (expense) benefit		(3,768)		4,454		(8,222)	NM
NET INCOME (LOSS)		10,766		(793)		11,559	NM
Net loss attributable to non-controlling interests		—		(30)		30	(100.0)
NET INCOME (LOSS) ATTRIBUTABLE TO
THE STOCKHOLDERS OF ARGAN, INC.	$	10,766	$	(763)	$	11,529	NM

NM – Not meaningful.

Revenues

Power Industry Services

The revenues of the power industry services business increased by 99.9%, or $48.6 million, to $97.2 million for the three months ended April 30, 2021 compared with revenues of $48.6 million for the three months ended April 30, 2020. The revenues of this business represented approximately 76.9% of consolidated revenues for the quarter ended April 30, 2021 and 80.8% of consolidated revenues for the prior year quarter. The primary driver for the improved performance by this reportable segment for the three months ended April 30, 2021 was the increased revenues associated with the construction of the Guernsey Power Station as this project has reached its peak level of construction activity. The revenues associated with this project represented 67.8% of consolidated revenues for the three months ended April 30, 2021.

Last year, the revenues earned by GPS on the Guernsey Power Station project represented 60.6% of consolidated revenues as activities on this project were ramping up from its start in August 2019. Results for the three-month period ended April 30, 2020 also included a meaningful contribution from APC’s TeesREP project as its revenues represented 17.0% of consolidated revenues for the period. Activities on this project have diminished considerably as APC completed its subcontracted efforts during the three-month period ended April 30, 2021. Before the end of the first quarter, APC and its customer on the TeesREP subcontract executed an agreement that documents the termination of the subcontract. Future meaningful activities should be limited to  the performance of the necessary services under its assurance-type warranty.  

27

Industrial Fabrication and Field Services

The revenues of our industrial fabrication and field services segment (representing the business of TRC) provided 21.1% of consolidated revenues for the three-month period ended April 30, 2021, which reflected an increase in revenues of $16.9 million, or 173.6%, to $26.7 million for the period compared to revenues of $9.7 million for the three months ended April 30, 2020. TRC’s strong performance for the three-month period ended April 30, 2021 reflected a significant rise in revenues earned on field services activities during the period from the amount of revenues reported for the quarter ended April 30, 2020, as well as increases in revenues associated with pipe and vessel fabrication works. New project awards have increased TRC’s project backlog to approximately $67.1 million as of April 30, 2021 from $38.3 million as of April 30, 2020. The major customers of TRC include some of North America’s largest fertilizer producers, as well as other chemical, mining, forest products, construction and energy companies with plants, facilities and other sites located primarily in the southeastern region of the US.

Telecommunications Infrastructure Services

The revenue results of this business segment (representing the business of SMC) were $2.5 million for the three-month period ended April 30, 2021, increasing by 40.1% from $1.8 million for the three months ended April 30, 2020. Most of the increase in revenues between the quarters related to increased activities for inside-premises customers, an indication that concerns of project sponsors regarding the spread of COVID-19 threatening works performed indoors may be abating.

Cost of Revenues

With the increase in consolidated revenues for the three months ended April 30, 2021 compared with last year’s first quarter ended April 30, 2020, the consolidated cost of revenues also increased between the quarters. These costs were $102.6 million and $56.1 million for the three-month periods ended April 30, 2021 and 2020, respectively, representing an increase of approximately 82.8%.

For the three-month period ended April 30, 2021, we reported a consolidated gross profit of approximately $23.7 million, which represented a gross profit percentage of approximately 18.8% of corresponding consolidated revenues. The gross profit for the period reflected the consistent profit contribution of the construction activities related to the Guernsey Power Station project; it was also favorably impacted by the profit contributions of APC as the TeesREP project wound down towards completion. Works for this project performed during the quarter ended April 30, 2021 were profitable as they were completed pursuant to the time and materials arrangement of the subcontract, as amended. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 19.0%, 17.6% and 20.8%, respectively, for the quarter ended April 30, 2021.

Our consolidated gross profit reported for the three-month period ended April 30, 2020 was $4.0 million, which represented a gross profit percentage of approximately 6.7% of corresponding consolidated revenues. Last year, the gross profit percentage for the first quarter period was adversely affected by the continuation of challenges that confronted the management of the TeesREP project, including a suspension of construction activities due to the COVID-19 outbreak, which resulted in our recording additional loss for this project in the amount of $2.7 million during the quarter.

Selling, General and Administrative Expenses

These costs were $9.9 million and $10.3 million for the three months ended April 30, 2021 and 2020, respectively, representing 7.8% and 17.2% of consolidated revenues for the corresponding periods, respectively. We expected these costs, expressed as a percentage of corresponding revenues, to trend favorably based on a quarter-to-quarter comparison  due to the expected increase in consolidated revenues over the same periods. The reduction in actual costs between the quarters was due primarily to the increased utilization of staff by GPS on the Guernsey Power Station project. The amount for the three months ended April 30, 2020 included the costs of maintaining core members of the operations staff at GPS whose time is typically charged to active projects to a greater degree, and the costs of maintaining intact the key staff organizations at corporate headquarters, GPS, TRC and SMC.

28

Other Income

In April 2021 APC received a research and development credit payment from the government of the UK related to certain qualifying works performed on the TeesREP project during Fiscal 2019. Net of associated costs, the payment amount of $0.7 million, much like a grant, was included in other income for the three months ended April 30, 2021.

Typically, the amounts reported on this line include primarily income earned on funds maintained in money market accounts and interest income earned on CDs. Adverse economic reactions to the uncertainties of the COVID-19 pandemic commenced during the middle of last year’s first quarter ended April 30, 2020, including sharp reductions in investment interest rates. For the three months ended April 30, 2020, the net amount of other income was $1.1 million, including approximately $0.9 million in earnings on our temporary investments of excess cash. Other income for the three months ended April 30, 2021 was insignificant although the aggregate amount of invested funds increased between the quarters.  

Income Taxes

We reported income tax expense for the three months ended April 30, 2021 in the amount of approximately $3.8 million. We estimate that our annual effective income tax rate for Fiscal 2022, before discrete items, will approximate 25.1%. This tax rate differs from the statutory federal tax rate of 21% due primarily to the unfavorable effects of state income taxes and permanent differences, including certain nondeductible executive compensation and the non-deductible portions of the out-of-pocket travel and living expenses incurred by the large numbers of our project and craft employees currently working offsite, and a write-off of certain deferred tax assets in the amount of $0.3 million. For the three months ended April 30, 2020, we recorded an income tax benefit in the amount of approximately $4.5 million, which reflected primarily the net operating loss carryback benefit amount of $4.2 million discussed above.

The wide-ranging CARES Act legislation was enacted in March 2020 as an emergency economic stimulus package including spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19. The tax changes of the CARES Act temporarily suspended the limitations on the future utilization of certain NOLs and re-established a carryback period for certain losses to five years. The losses eligible for carryback under the CARES Act include our consolidated NOL for the Fiscal 2020, which was approximately $39.5 million. With the filing of our consolidated federal income tax return for the year, we elected to apply the NOL against our taxable income for the years ended January 31, 2015, 2016 and 2017. The carryback provides a favorable rate benefit for us as the loss, which was incurred in a year where the statutory federal tax rate was 21%, will be carried back to tax years where the tax rate was higher.

Liquidity and Capital Resources as of April 30, 2021

At April 30, 2021 and January 31, 2021, our balances of cash and cash equivalents were $396.7 million and $366.7 million, respectively. During the three months between these dates, our working capital increased by $5.8 million to $276.0 million as of April 30, 2021 from $270.1 million as of January 31, 2021.

The net amount of cash provided by operating activities for the three months ended April 30, 2021 was $17.3 million. Our net income for the three months ended April 30, 2021, adjusted favorably by the net amount of non-cash income and expense items, represented a source of cash in the total amount of $13.8 million. The sources of cash from operations for the three months ended April 30, 2021 also included the temporary increase in the balance of contract liabilities  associated with projects at GPS and TRC in the amount of $27.5 million. A reduction in the combined level of accounts payable and accrued expenses and an increase in the amount of accounts receivable during the three-month period ended April 30, 2021, in the respective amounts of $21.6 million and $3.7 million, represented uses of cash for the period.

Other primary sources of cash for the three months ended April 30, 2021 were the net maturities of short-term investments, certificates of deposit issued by the Bank, and the proceeds associated with the exercise of stock options in the amounts of $20.0 million and $1.0 million, respectively. Non-operating activities used cash during the three months ended April 30, 2021, including the payment of a regular cash dividend in the amount of $3.9 million, investment payments made to a solar energy fund in the amount of $3.5 million and capital expenditures in the amount of $0.8 million. As of April 30, 2021, there were no restrictions with respect to inter-company payments between GPS, TRC, APC, SMC and the holding company. However, certain loans made by Argan to APC have been determined to be uncollectible.

29

Last year, the net amount of cash provided by operating activities for the three months ended April 30, 2020 was $40.2 million. The sources of cash for the period included a temporary increase in the balance of contract liabilities, primarily associated with the early phases of a major construction project at GPS, and a reduction in the balances of accounts receivable, primarily at the TRC and APC operations, in the amounts of $37.1 million and $15.0 million, respectively. In addition, our net loss for the quarter ended April 30, 2020 was more than offset by the favorable adjustments related to non-cash income and expense items, which represented a net source of cash in the total amount of $9.9 million.

As described above, our income tax accounting for the quarter ended April 30, 2020 included an entry to record the carryback benefit related to our NOL incurred for Fiscal 2020 to previous tax years. The loss carryback should result in a refund of federal income taxes in the amount of $12.3 million. This tax refund receivable was included in the balance of other current assets as of April 30, 2020, which was the primary cause of the increase in this balance of $13.6 million during the quarter then ended, a use of cash.

The Company also used cash in operations during the three months ended April 30, 2020 in the amount of $8.6 million to reduce the level of accounts payable and accrued expenses.

Another primary source of cash for the three months ended April 30, 2020 was represented by the net maturities of short-term investments in the amount of $60.0 million. Non-operating activities used cash during the three months ended April 30, 2020, including the payment of a quarterly cash dividend in the total amount of $3.9 million and capital expenditures in the amount of $0.7 million.

At April 30, 2021, most of our balance of cash and cash equivalents was invested in government and prime money market funds with most of their total assets invested in cash, US Treasury obligations and repurchase agreements secured by US Treasury obligations. The major portion of our domestic operating bank account balances are maintained with the Bank. We do maintain certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

The original term of our Credit Agreement was scheduled to expire on May 31, 2021. During April 2021, negotiations with the Bank were completed which, among other items, extended the expiration date of the Credit Agreement, as amended, to May 31, 2024 and reduced the borrowing rate. The Credit Agreement, as amended, includes the following features, among others: a lending commitment of $50.0 million including a revolving loan with interest at the 30-day LIBOR plus 1.6% (reduced from 2.0%), and an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions. We may use the borrowing ability to cover other credit instruments issued by the Bank for our use in the ordinary course of business as defined by the Bank. At April 30, 2021, we had $1.8 million of outstanding letters of credit issued under the Credit Agreement. Additionally, in connection with the current project development activities of the VIE, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the approximate amount of $3.4 million for which we have provided cash collateral.

We have pledged the majority of our assets to secure the financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Credit Agreement, as amended, requires that we comply with certain financial covenants at our fiscal year-end and at each fiscal quarter-end, and includes other terms, covenants and events of default that are customary for a credit facility of its size and nature, including a requirement to achieve positive adjusted earnings before interest, taxes, depreciation and amortization, as defined, over each rolling twelve-month measurement period. At April 30, 2021 and January 31, 2021, we were compliant with the covenants of the Credit Agreement.

In the normal course of business and for certain major projects, we may be required to obtain surety or performance bonding, to provide parent company guarantees, or to cause the issuance of letters of credit (or some combination thereof) in order to provide performance assurances to clients on behalf of one of our contractor subsidiaries.

If our services under a guaranteed project would not be completed or would be determined to have resulted in a material defect or other material deficiency, then we could be responsible for monetary damages or other legal remedies. As is typically required by any surety bond, we would be obligated to reimburse the issuer of any surety bond issued on behalf of a subsidiary for any cash payments made thereunder. The commitments under performance bonds generally end concurrently with the expiration of the related contractual obligation. Not all of our projects require bonding.

30

As of April 30, 2021, the value of the Company’s unsatisfied bonded performance obligations, covering all of its subsidiaries, was approximately $372 million. In addition, as of April 30, 2021, there were bonds outstanding in the aggregate amount of approximately $6.6 million covering other risks including warranty obligations related to projects completed by GPS; these bonds expire at various dates over the next twelve months.

On behalf of APC, Argan has provided a parent company performance guarantee to its customer, the EPC services contractor on the TeesREP project which was supported by a performance bond issued on behalf of the customer. In connection with the completion of the subcontract construction work, we expect the issuance of a warranty bond in the approximate amount of $4.2 million to replace the performance bond.

We have also provided a financial guarantee on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million to support project developmental efforts.

When sufficient information about claims related to our performance on projects would be available and monetary damages or other costs or losses would be determined to be probable, we would record such guaranteed losses. As our subsidiaries are wholly-owned, any actual liability related to contract performance is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. Any amounts that we may be required to pay in excess of the estimated costs to complete contracts in progress as of April 30, 2021 are not estimable.

We believe that cash on hand, cash that will be provided from the maturities of short-term investments and cash generated from our future operations, with or without funds available under our Credit Agreement, as amended, will be adequate to meet our general business needs in the foreseeable future. Since the beginning of the COVID-19 pandemic, to assure an optimum level of liquidity during this period of uncertainty and to mitigate the market risks represented by the COVID-19 pandemic, management decided to temporarily maintain larger balances of cash and cash equivalents relative to short-term investments with minimal opportunity cost.

In general, we maintain significant liquid capital in our balance sheet to ensure the maintenance of our bonding capacity and to provide parent company performance guarantees for EPC and other construction projects. Any future acquisitions, or other significant unplanned cost or cash requirement, may require us to raise additional funds through the issuance of debt and/or equity securities. There can be no assurance that such financing will be available on terms acceptable to us, or at all.

Earnings before Interest, Taxes, Depreciation and Amortization (“EBITDA”)

We believe that EBITDA is a meaningful presentation that enables us to assess and compare our operating cash flow performance on a consistent basis by removing from our operating results the impacts of our capital structure, the effects of the accounting methods used to compute depreciation and amortization and the effects of operating in different income tax jurisdictions. Further, we believe that EBITDA is widely used by investors and analysts as a measure of performance.

The table following immediately below presents the determinations of EBITDA for the three months ended April 30, 2021 and 2020, respectively (amounts in thousands).

	Three Months Ended
	April 30,
	2021		2020
Net income (loss), as reported	$	10,766	$	(793)
Income tax expense (benefit)		3,768		(4,454)
Depreciation		882		937
Amortization of purchased intangible assets		228		225
EBITDA		15,644		(4,085)
EBITDA of non-controlling interests		—		(30)
EBITDA attributable to the stockholders of Argan, Inc.	$	15,644	$	(4,055)

31

However, as EBITDA is not a measure of performance calculated in accordance with US GAAP, we do not believe that this measure should be considered in isolation from, or as a substitute for, the results of our operations presented in accordance with US GAAP that are included in our condensed consolidated financial statements. In addition, our EBITDA does not necessarily represent funds available for discretionary use and is not necessarily a measure of our ability to fund our cash needs.

As we believe that our net cash flow provided by operations is the most directly comparable performance measure determined in accordance with US GAAP, the table below reconciles the amounts of EBITDA for the applicable three-month periods to the corresponding amounts of net cash flows provided by operating activities that are presented in our condensed consolidated statements of cash flows for the three months ended April 30, 2021 and 2020 (amounts in thousands).

	Three Months Ended
	April 30,
	2021		2020
EBITDA	$	15,644	$	(4,085)
Current income tax (expense) benefit		(3,169)		12,668
Stock compensation expense		679		642
Other non-cash items		662		707
(Increase) decrease in accounts receivable		(3,666)		14,980
Decrease (increase) in other assets		765		(13,600)
Decrease in accounts payable and accrued expenses		(21,552)		(8,609)
Change in contracts in progress, net		27,983		37,484
Net cash provided by operating activities	$	17,346	$	40,187

Critical Accounting Policies

Critical accounting policies are those related to the areas where we have made what we consider to be particularly subjective or complex judgments in arriving at estimates and where these estimates can significantly impact our financial results under different assumptions and conditions. These estimates, judgments, and assumptions affect the reported amounts of assets, liabilities and equity, the disclosure of contingent assets and liabilities at the date of financial statements and the reported amounts of revenues and expenses during the reporting periods. We base our estimates on historical experience and various other assumptions that we believe are reasonable under the circumstances, the results of which form the basis for making judgments about the carrying value of assets, liabilities and equity that are not readily apparent from other sources. Actual results and outcomes could differ from these estimates and assumptions.

We consider the accounting policies related to revenue recognition on long-term construction contracts; income tax reporting; the accounting for business combinations; the subsequent valuation of goodwill, other indefinite-lived assets and long-lived assets; the valuation of employee common stock-based awards; and the financial reporting associated with any significant claims or legal matters to be most critical to the understanding of our financial position and results of operations, as well as the accounting and reporting for special purpose entities including joint ventures and variable interest entities. An expanded discussion of our critical accounting policies is included in Item 7 of Part II of our Annual Report. During the three months ended April 30, 2021, there have been no material changes in the way we apply the critical accounting policies described therein.

Recently Issued Accounting Pronouncements

In December 2019, the FASB issued ASU 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by us as a non-income based tax. We do not expect that the requirements of this new guidance, effective for us on February 1, 2021, will alter our accounting for income taxes.

32

There are no other recently issued accounting pronouncements that have not yet been adopted that we consider material to our consolidated financial statements.

ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

In the normal course of business, our results of operations may be subject to risks related to fluctuations in interest rates. As of April 30, 2021, we had no outstanding borrowings under our financing arrangements with the Bank, as amended (see Note 6 to the accompanying condensed consolidated financial statements), which provide a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2024 with interest at 30-day LIBOR plus 1.6% going forward. During the three months ended April 30, 2021 and 2020, we did not enter into derivative financial instruments for trading, speculation or other purposes that would expose us to market risk.

Financial markets around the globe are preparing for the discontinuation of LIBOR at the end of 2021, which is the widely used indicator of basis for short-term lending rates. The transition from LIBOR is market-driven, not a change required by regulation. The US and other countries are currently working to replace LIBOR with alternative reference rates. We do not expect that the replacement of LIBOR as the basis for the determination of our short-term borrowing rate will have significant effects on the financial arrangements with the Bank, as amended, or our financial reporting.

We maintain a substantial amount of our temporarily investable cash in government and prime money market funds (see Note 3 of the accompanying condensed consolidated financial statements). The balance of these funds, which was included in cash and cash equivalents in our condensed consolidated balance sheet as of April 30, 2021, was $277.4 million with earnings based on a blended annual yield of 0.04%. The significant drop in interest rates during Fiscal 2021 has caused a substantial reduction in the investment returns earned on these funds by us.

As of April 30, 2021, the weighted average annual interest rate of our short-term investments of $70.0 million and money market funds of $277.4 million was 0.07%. To illustrate the potential impact of changes in interest rates on our results of operations, we present the following hypothetical analysis, which assumes that our condensed consolidated balance sheet as of April 30, 2021 remains constant, and no further actions are taken to alter our existing interest rate sensitivity, including reinvestments. The weighted average number of days until maturity for the short-term investments and money market funds is 356 days. As the blended weighted average interest rate on our short-term investments and money market funds was 0.07% at April 30, 2021, the largest decrease in the interest rates presented below is 7 basis points (dollars in thousands).

	Increase (Decrease) in		Increase (Decrease) in		Net Increase (Decrease) in
Basis Point Change	Interest Income		Interest Expense		Income (pre-tax)
Up 300 basis points	$	8,888	$	—	$	8,888
Up 200 basis points		5,925		—		5,925
Up 100 basis points		2,963		—		2,963
Down 7 basis points		(122)		—		(122)

With the consolidation of APC, we are subject to the effects of translating the financial statements of APC from its functional currency (Euros) into our reporting currency (US dollars). Such effects are recognized in accumulated other comprehensive loss, which is net of tax when applicable. APC remeasures transactions and subsidiary financial statements denominated in local currencies to Euros. Gains and losses on the remeasurements are recorded in the other income line of our condensed consolidated statement of earnings.

In addition, we are subject to fluctuations in prices for commodities including copper, concrete, steel products and fuel. Although we attempt to secure firm quotes from our suppliers, we generally do not hedge against increases in prices for these commodities. Commodity price risks may have an impact on our results of operations due to the fixed-price nature of many of our contracts. We attempt to include the anticipated amounts of price increases or decreases in the costs of our bids. In times of increased supply cost volatility similar to those being experienced currently, we may take other steps to reduce our risks. For example, we may hold quotes related to materials in our industrial fabrication and field services segment for only three days. For major fixed price contracts in our power industry services segment, we may mitigate material cost risks by procuring the majority of the equipment and construction supplies during the early phases of a project. During the year ended April 30, 2021, the profitability of our active jobs did not suffer meaningfully from the global surge in construction material costs.  

33

ITEM 4. CONTROLS AND PROCEDURES

Evaluation of disclosure controls and procedures. Our management, with the participation of our chief executive officer and chief financial officer, evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934 (the “Exchange Act”)) as of April 30, 2021. Management recognizes that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving their objectives, and management necessarily applies its judgment in evaluating the cost-benefit relationship of possible controls and procedures. Based on the evaluation of our disclosure controls and procedures as of April 30, 2021, our chief executive officer and chief financial officer concluded that, as of such date, our disclosure controls and procedures were effective to provide reasonable assurance that information required to be disclosed in our Exchange Act reports is recorded, processed, summarized, and reported within the time periods specified by the SEC, and the material information related to the Company and its consolidated subsidiaries is made known to management, including the chief executive officer and chief financial officer, to allow timely decisions regarding required disclosure in the reports.

Changes in internal controls over financial reporting. There have been no significant changes in our internal control over financial reporting (as defined in Rules 13a-15 and 15d-15 under the Exchange Act) during the fiscal quarter ended April 30, 2021 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

PART II

ITEM 1. LEGAL PROCEEDINGS

Included in Note 8 to the condensed consolidated financial statements that are included in Item 1 of Part I of this Quarterly Report on Form 10-Q is the discussion of the status of a specific legal proceeding as of April 30, 2021. In the normal course of business, we may have other pending claims and legal proceedings. It is our opinion, based on information available at this time, that any other current claim or proceeding will not have a material effect on our condensed consolidated financial statements.

ITEM 1A. RISK FACTORS

There have been no material changes to the risk factors disclosed in our Annual Report.

ITEM 2. UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS

On June 24, 2020, we made a filing on Current Report Form 8-K announcing that our board of directors authorized the repurchase of up to $25.0 million of our issued and outstanding common stock through June 2022 (the “Repurchase Plan”). The repurchases may occur in the open market or through investment banking institutions, privately-negotiated transactions, or direct purchases, and the timing and amount of stock repurchased will depend on market and business conditions, applicable legal and credit requirements and other corporate considerations. To date, there have not been any purchases made under the Repurchase Plan.

In accordance with the SEC’s Rule 10b5-1, we have allowed, and may in the future allow, the repurchase of our common stock during trading blackout periods by an investment banking firm or other institution agent acting on our behalf pursuant to predetermined parameters.

ITEM 3. DEFAULTS UPON SENIOR SECURITIES

None

ITEM 4. MINE SAFETY DISCLOSURES (not applicable)

ITEM 5. OTHER INFORMATION

None

34

ITEM 6. EXHIBITS

Exhibit No.	Title
Exhibit 31.1	Certification of Chief Executive Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934.
Exhibit 31.2	Certification of Chief Financial Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934.
Exhibit 32.1	Certification of Chief Executive Officer, pursuant to 18 U.S.C. Section 1350. *
Exhibit 32.2	Certification of Chief Financial Officer, pursuant to 18 U.S.C. Section 1350. *
Exhibit 101: Exhibit 101.INS	XBRL Instance Document – the instance document does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document.
Exhibit 101.SCH	Inline XBRL Taxonomy Extension Schema.
Exhibit 101.CAL	Inline XBRL Taxonomy Extension Calculation Linkbase.
Exhibit 101.LAB	Inline XBRL Taxonomy Label Linkbase.
Exhibit 101.PRE	Inline XBRL Taxonomy Presentation Linkbase.
Exhibit 101.DEF	Inline XBRLTaxonomy Extension Definition Document.
Exhibit 104	Cover Page Interactive Data File – the cover page interactive data file does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document.

* The certification is being furnished and shall not be considered filed as part of this report.

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

	ARGAN, INC.
June 8, 2021	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
June 8, 2021	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer,
		Treasurer and Secretary

35

EX-31.1

Exhibit 31.1

SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION

I, Rainer H. Bosselmann, certify that:

1.    I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended April 30, 2021;

2.    Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.    Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.    The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:

a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)    Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)    Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and

d)    Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.    The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):

a)    All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and

b)    Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

Date: June 8, 2021	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
		(Principal Executive Officer)

EX-31.2

Exhibit 31.2

SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION

I, David H. Watson, certify that:

1.    I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended April 30, 2021;

2.    Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.    Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.    The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:

a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)    Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)    Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and

d)    Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.    The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):

a)    All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and

b)    Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

Date: June 8, 2021	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer, Treasurer and Secretary
		(Principal Financial Officer)

EX-32.1

Exhibit 32.1

CERTIFICATION PURSUANT TO

18 U.S.C. SECTION 1350,

AS ADOPTED PURSUANT TO

SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended April 30, 2021, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, Rainer H. Bosselmann, Chairman and Chief Executive Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:

1.     The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

2.     Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

Date: June 8, 2021	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
		(Principal Executive Officer)

EX-32.2

Exhibit 32.2

CERTIFICATION PURSUANT TO

18 U.S.C. SECTION 1350,

AS ADOPTED PURSUANT TO

SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended April 30, 2021, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, David H. Watson, Senior Vice President and Chief Financial Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:

1.     The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

2.     Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

Date: June 8, 2021	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer, Treasurer and Secretary
		(Principal Financial Officer)

XML

Document and Entity Information - shares	3 Months Ended
	Apr. 30, 2021	Jun. 04, 2021
Document And Entity Information
Document Type	10-Q
Document Quarterly Report	true
Document Period End Date	Apr. 30, 2021
Document Transition Report	false
Entity File Number	001-31756
Entity Registrant Name	ARGAN INC
Entity Incorporation, State or Country Code	DE
Entity Tax Identification Number	13-1947195
Entity Address, Address Line One	One Church Street, Suite 201
Entity Address, City or Town	Rockville
Entity Address, State or Province	MD
Entity Address, Postal Zip Code	20850
City Area Code	301
Local Phone Number	315-0027
Title of 12(b) Security	Common Stock, $.15 par value
Trading Symbol	AGX
Security Exchange Name	NYSE
Entity Current Reporting Status	Yes
Entity Interactive Data Current	Yes
Entity Filer Category	Accelerated Filer
Entity Small Business	false
Entity Emerging Growth Company	false
Entity Shell Company	false
Entity Common Stock, Shares Outstanding		15,769,440
Entity Central Index Key	0000100591
Document Fiscal Year Focus	2022
Current Fiscal Year End Date	--01-31
Document Fiscal Period Focus	Q1
Amendment Flag	false

XML

CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS - USD ($) shares in Thousands, $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS
REVENUES	$ 126,341	$ 60,148
Cost of revenues	102,627	56,139
GROSS PROFIT	23,714	4,009
Selling, general and administrative expenses	9,892	10,344
INCOME (LOSS) FROM OPERATIONS	13,822	(6,335)
Other income, net	712	1,088
INCOME (LOSS) BEFORE INCOME TAXES	14,534	(5,247)
Income tax (expense) benefit	(3,768)	4,454
NET INCOME (LOSS)	10,766	(793)
Net loss attributable to non-controlling interests		(30)
NET INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	10,766	(763)
Foreign currency translation adjustments	(118)	(246)
COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	$ 10,648	$ (1,009)
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.
Basic	$ 0.68	$ (0.05)
Diluted	$ 0.67	$ (0.05)
WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING
Basic	15,726	15,643
Diluted	15,961	15,643
CASH DIVIDENDS PER SHARE	$ 0.25	$ 0.25

XML

CONDENSED CONSOLIDATED BALANCE SHEETS - USD ($) $ in Thousands	Apr. 30, 2021	Jan. 31, 2021
CURRENT ASSETS
Cash and cash equivalents	$ 396,675	$ 366,671
Short-term investments	70,075	90,055
Accounts receivable	32,379	28,713
Contract assets	26,158	26,635
Other current assets (Note 10)	33,744	34,146
TOTAL CURRENT ASSETS	559,031	546,220
Property, plant and equipment, net	19,944	20,361
Goodwill	27,943	27,943
Other purchased intangible assets, net	3,869	4,097
Deferred taxes		249
Right-of-use and other assets	7,185	3,760
TOTAL ASSETS	617,972	602,630
LIABILITIES AND EQUITY CURRENT LIABILITIES
Accounts payable	41,467	53,295
Accrued expenses	42,050	50,750
Contract liabilities	199,548	172,042
TOTAL CURRENT LIABILITIES	283,065	276,087
Deferred taxes	350
Other noncurrent liabilities	3,741	4,135
TOTAL LIABILITIES	287,156	280,222
COMMITMENTS AND CONTINGENCIES (Notes 7 and 8)
STOCKHOLDERS' EQUITY
Preferred stock, par value $0.10 per share - 500,000 shares authorized; no shares issued and outstanding
Common stock, par value $0.15 per share - 30,000,000 shares authorized; 15,772,673 and 15,706,202 shares issued at April 30, 2021 and January 31, 2021 respectively; 15,769,440 and 15,702,969 shares outstanding at April 30, 2021 and January 31, 2021, respectively	2,366	2,356
Additional paid-in capital	154,974	153,282
Retained earnings	172,934	166,110
Accumulated other comprehensive loss	(1,199)	(1,081)
TOTAL STOCKHOLDERS' EQUITY	329,075	320,667
Non-controlling interests	1,741	1,741
TOTAL EQUITY	330,816	322,408
TOTAL STOCKHOLDERS' EQUITY	$ 617,972	$ 602,630

XML

CONDENSED CONSOLIDATED BALANCE SHEETS (Parenthetical) - $ / shares	Apr. 30, 2021	Jan. 31, 2021
CONDENSED CONSOLIDATED BALANCE SHEETS
Preferred stock, par value	$ 0.10	$ 0.10
Preferred stock, shares authorized	500,000	500,000
Preferred stock, shares issued	0	0
Preferred stock, shares outstanding	0	0
Common stock, par value	$ 0.15	$ 0.15
Common stock, shares authorized	30,000,000	30,000,000
Common stock, shares issued	15,772,673	15,706,202
Common stock, shares outstanding	15,769,440	15,702,969

XML

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS' EQUITY - USD ($) $ in Thousands	Common Stock	Additional Paid-in Capital	Retained Earnings	Accumulated Other Comprehensive Loss	Non-controlling Interests	Total
Balances at Jan. 31, 2020	$ 2,346	$ 148,713	$ 189,306	$ (1,116)	$ 1,781	$ 341,030
Balances (in shares) at Jan. 31, 2020	15,634,969
Net income (loss)			(763)		(30)	(793)
Foreign currency translation loss				(246)		(246)
Stock compensation expense		642				642
Stock option exercises and other share-based award settlements	$ 1	176				177
Stock option exercises and other share-based award settlements (in shares)	10,000
Cash dividends			(3,910)			(3,910)
Balances at Apr. 30, 2020	$ 2,347	149,531	184,633	(1,362)	1,751	336,900
Balances (in shares) at Apr. 30, 2020	15,644,969
Balances at Jan. 31, 2021	$ 2,356	153,282	166,110	(1,081)	1,741	322,408
Balances (in shares) at Jan. 31, 2021	15,702,969
Net income (loss)			10,766			10,766
Foreign currency translation loss				(118)		(118)
Stock compensation expense		679				679
Stock option exercises and other share-based award settlements	$ 10	1,013				$ 1,023
Stock option exercises and other share-based award settlements (in shares)	66,471					26,000
Cash dividends			(3,942)			$ (3,942)
Balances at Apr. 30, 2021	$ 2,366	$ 154,974	$ 172,934	$ (1,199)	$ 1,741	$ 330,816
Balances (in shares) at Apr. 30, 2021	15,769,440

XML

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS - USD ($) $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
CASH FLOWS FROM OPERATING ACTIVITIES
Net income (loss)	$ 10,766	$ (793)
Adjustments to reconcile net income (loss) to net cash provided by operating activities
Deferred income tax expense	599	8,214
Depreciation	882	937
Stock compensation expense	679	642
Lease expense	776	379
Amortization of purchased intangible assets	228	225
Other	(114)	328
Changes in operating assets and liabilities
Accounts receivable	(3,666)	14,980
Contract assets	477	344
Other assets	765	(13,600)
Accounts payable and accrued expenses	(21,552)	(8,609)
Contract liabilities	27,506	37,140
Net cash provided by operating activities	17,346	40,187
CASH FLOWS FROM INVESTING ACTIVITIES
Maturities of short-term investments	20,000	70,000
Purchases of short-term investments		(10,000)
Investment in solar energy projects	(3,520)
Purchases of property, plant and equipment	(844)	(684)
Net cash provided by investing activities	15,636	59,316
CASH FLOWS FROM FINANCING ACTIVITIES
Payments of cash dividends	(3,942)	(3,910)
Proceeds from the exercise of stock options	1,023	177
Net cash used in financing activities	(2,919)	(3,733)
EFFECTS OF EXCHANGE RATE CHANGES ON CASH	(59)	(206)
NET INCREASE IN CASH AND CASH EQUIVALENTS	30,004	95,564
CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD	366,671	167,363
CASH AND CASH EQUIVALENTS, END OF PERIOD	$ 396,675	$ 262,927

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

3 Months Ended

Apr. 30, 2021

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

NOTE 1 – DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Description of the Business

Argan, Inc. (“Argan”) conducts operations through its wholly owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the United States (the “US”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “UK”). Including consolidated variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeastern region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIE. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 of each year.

The condensed consolidated balance sheet as of April 30, 2021, the condensed consolidated statements of earnings and stockholders’ equity for the three months ended April 30, 2021 and 2020, and the condensed consolidated statements of cash flows for the three months ended April 30, 2021 and 2020 are unaudited. The condensed consolidated balance sheet as of January 31, 2021 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2021 (“Fiscal 2021”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of April 30, 2021, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

Accounting Policies

Income Taxes

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. Adoption of this new guidance, which was effective for the Company on February 1, 2021, did not alter the Company’s accounting for income taxes.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

Fair Values

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three-month periods ended April 30, 2021 and 2020. The total amounts of the project development costs included in the balances for property, plant and equipment as of April 30, 2021 and January 31, 2021 were $7.7 million and $7.5 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS

3 Months Ended

Apr. 30, 2021

REVENUES FROM CONTRACTS WITH CUSTOMERS

REVENUES FROM CONTRACTS WITH CUSTOMERS

NOTE 2 – REVENUES FROM CONTRACTS WITH CUSTOMERS

The Company’s accounting for revenues on contracts with customers is based on a single comprehensive five-step model that requires reporting entities to:

1. Identify the contract,

2. Identify the performance obligations of the contract,

3. Determine the transaction price of the contract,

4. Allocate the transaction price to the performance obligations, and

5. Recognize revenue.

The Company focuses on the transfer of the contractor’s control of the goods and/or services to the customer, as opposed to the transfer of risk and rewards. Major provisions of the current guidance cover the determination of which goods and services are distinct and represent separate performance obligations, the appropriate treatments for variable consideration, and the evaluation of whether revenues should be recognized at a point in time or over time.

When a performance obligation is satisfied over time, the related revenues are recognized over time. The Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed-price or a time-and-materials basis, and primarily over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer.

Revenues from fixed-price contracts, including portions of estimated gross profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the cost-to-cost approach. If, at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period that it is identified and an amount is estimable. Revenues from time-and-materials contracts are recognized when the related services are provided to the customer.

Almost all of the Company’s fixed-price contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of such contracts because contract promises included therein are interrelated or the contracts require the Company to perform critical integration so that the customer receives a completed project. Warranties provided under the Company’s contracts with customers are assurance-type and are recorded as the corresponding contract work is performed.

The transaction price for a contract represents the value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration, which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as changes in the scope and price of contracts, claims, incentives and liquidated damages.

Contract assets include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities include amounts that reflect obligations to provide goods or services for which payment has been received. Contract retentions are billed amounts which, pursuant to the terms of the applicable contract, are not paid by project owners until a defined phase of a contract or project has been completed and accepted. These retained amounts are reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retainage amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at April 30, 2021 and January 31, 2021 were $42.1 million and $36.8 million, respectively.

Variable Consideration

Amounts for contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. The aggregate amount of such contract variations included in the transaction prices that were used to determine project-to-date revenues at April 30, 2021 and January 31, 2021 were $17.6 million and $16.6 million, respectively. Variations related to the Company’s contracts typically represent modifications to the existing contracts and performance obligations, and do not represent new performance obligations. Actual costs related to any changes in the scope of the corresponding contract are expensed as they are incurred. Changes to total estimated contract costs and losses, if any, are reflected in operating results for the period in which they are determined.

The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. These contract requirements generally relate to specified activities that must be completed by an established date or by the achievement of a specified level of output or efficiency. Each applicable contract defines the conditions under which a project owner may be entitled to any liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not subtracted from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract. The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved. The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects.

In other cases, the Company may have the grounds to assert liquidated damages against subcontractors, suppliers, project owners or other parties related to a project. Such circumstances may arise when the Company’s activities and progress are adversely affected by delayed or damaged materials, challenges with equipment performance or other events out of the Company’s control where the Company has rights to recourse, typically in the form of liquidated damages. In general, the Company does not adjust the corresponding contract accounting until it is probable that the favorable cost relief will be realized. Such adjustments have been and could be material.

The Company records adjustments to revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.

Accounting for the Subcontract Loss

For the year ended January 31, 2019 (“Fiscal 2019”), the Company disclosed that APC was completing the mechanical installation of the boiler for a biomass-fired power plant under construction in Teesside, England, which is referred to as the Tees Renewable Energy Plant (“TeesREP”), that had encountered significant operational and contractual challenges. Subsequently, APC’s estimates of the costs of the unfavorable financial impacts of the difficulties on the TeesREP project escalated substantially. For the fiscal year ended January 31, 2020 (“Fiscal 2020”), the Company recorded a loss related to this project in the amount of $33.6 million and reversed profit in the amount of $0.7 million that had been recorded in prior fiscal years.

Construction activities on the TeesREP project were suspended on March 24, 2020 due to the COVID-19 pandemic, pending preparations being made by the contractors and subcontractors to comply with new and evolving government guidance concerning public health protocols, leaving only a small number of critical maintenance staff remaining on site. At the time of the suspension of work on the TeesREP project, APC had completed approximately 90% of its subcontracted work. However, as of April 30, 2020 and based on an updated forecast of subcontract costs, management expected that such costs for the TeesREP project at completion would exceed forecasted revenues by approximately $36.2 million. The additional subcontract loss in the amount of approximately $2.7 million was reflected in the consolidated amount of gross profit for the three months ended April 30, 2020.

Negotiated changes to the contractual arrangements for the TeesREP project and the redirected efforts of the top management of APC and the project team resulted in the reduction of the final amount of the loss incurred on the fixed-price portion of the TeesREP project to $29.5 million. Final closeout adjustments may result in future changes in the amount of this loss; however, APC has included an estimate of these costs in accrued expenses in the accompanying consolidated balance sheet as of April 30, 2021 and January 31, 2021. Project activities conducted by APC during the three-month period ended April 30, 2021, which were performed under a time and materials arrangement, were profitable.

Prior to April 30, 2021, APC completed its on-site activities at the TeesREP project location and commenced the process of resolving certain remaining contractual matters, collecting final amounts owed and confirming its commitment to perform the necessary services under its assurance warranty. The total amounts of accounts receivable and contract assets related to the TeesREP Project and included in the condensed consolidated balance sheets were $1.6 million as of April 30, 2021 and $4.7 million as of January 31, 2021.

Remaining Unsatisfied Performance Obligations (“RUPO”)

The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under the revenue recognition rules of US GAAP. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations.

At April 30, 2021, the Company had RUPO of $478.7 million. The largest portion of RUPO at any date usually relates to EPC service contracts with typical performance durations of one to three years. However, the length of certain significant construction projects may exceed three years. The Company estimates that approximately 58% of the RUPO amount at April 30, 2021 will be included in the amount of consolidated revenues that will be recognized during the latter three quarters of the fiscal year ending January 31, 2022. Most of the remaining amount of RUPO at April 30, 2021 is expected to be recognized in revenues during the fiscal year ending January 31, 2023.

Revenues for future periods will also include amounts related to customer contracts started or awarded subsequent to April 30, 2021. It is important to note that estimates may be changed in the future and that cancellations, deferrals or scope adjustments may occur related to work included in the amount of RUPO at April 30, 2021. Accordingly, RUPO may be adjusted to reflect project delays and cancellations, revisions to project scope and cost and foreign currency exchange fluctuations, or to revise estimates, as effects become known. Such adjustments may materially reduce future revenues below Company estimates.

Disaggregation of Revenues

The following table presents consolidated revenues for the three months ended April 30, 2021 and 2020, disaggregated by the geographic area where the corresponding projects were located:

	Three Months Ended April 30,
	2021		2020
United States	$	115,491	$	48,865
United Kingdom		6,157		10,296
Republic of Ireland		4,693		987
Consolidated Revenues	$	126,341	$	60,148

The major portion of the Company’s consolidated revenues are recognized pursuant to fixed-price contracts with most of the remaining portions earned pursuant to time-and-material contracts. Consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements.

XML

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

3 Months Ended

Apr. 30, 2021

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

NOTE 3 – CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

At April 30, 2021 and January 31, 2021, significant amounts of cash and cash equivalents were invested in government and prime money market funds with net assets invested in high-quality money market instruments. Such investments include US Treasury obligations; obligations of US government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by US government obligations. Due to market conditions, returns on money market instruments are currently minimal. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

Short-term investments as of April 30, 2021 and January 31, 2021 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of less than one year. The Company has the intent and ability to hold the CDs until they mature, and they are carried at cost plus accrued interest which approximates fair value. Interest income is recorded when earned and is included in other income. At April 30, 2021 and January 31, 2021, the weighted average annual interest rate of the outstanding CDs was 0.2% at each period end.

In addition, the Company has a substantial portion of its cash on deposit in the US at the Bank in excess of federally insured limits. Management does not believe that the combined amount of the CD investments and the cash deposited with the Bank represents a material risk. The Company also maintains certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

XML

ACCOUNTS AND NOTES RECEIVABLE

3 Months Ended

Apr. 30, 2021

ACCOUNTS AND NOTES RECEIVABLE

ACCOUNTS AND NOTES RECEIVABLE

NOTE 4 – ACCOUNTS AND NOTES RECEIVABLE

The Company generally extends credit to a customer based on an evaluation of the customer’s financial condition without requiring tangible collateral. Exposure to losses on accounts and notes receivable is expected to differ due to the varying financial condition of each customer. The Company monitors its exposure to credit losses and may establish an allowance

for credit losses based on management’s estimate of the loss that is expected to occur over the remaining life of the particular financial asset.

At April 30, 2021 and January 31, 2021, the amounts of credit losses expected by management were insignificant. The amounts of the provision for credit losses for the three months ended April 30, 2021 and 2020 were insignificant.

As of April 30, 2021, there were outstanding invoices billed to a former customer and unbilled costs incurred on the related project, with balances included in both accounts receivable and contract assets in the aggregate amount of $24.5 million. The recovery time related to this amount will most likely depend on the resolution of the outstanding legal dispute between the parties (see Note 8).

As of April 30, 2021, there were past due notes receivable from project developers in the aggregate amount of $1.8 million, for which full receipt will most likely depend on the successful financing of the related projects. The Company placed these notes receivable on a non-accrual status during Fiscal 2021.

XML

PURCHASED INTANGIBLE ASSETS

3 Months Ended

Apr. 30, 2021

PURCHASED INTANGIBLE ASSETS

PURCHASED INTANGIBLE ASSETS

NOTE 5 – PURCHASED INTANGIBLE ASSETS

At both April 30, 2021 and January 31, 2021, the goodwill balances related to the acquisitions of GPS and TRC were $18.5 million and $9.5 million, respectively. Management does not believe that any events or circumstances that have occurred or arisen since January 31, 2021 require an updated assessment of the goodwill balances of either GPS or TRC.

The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of April 30, 2021 and January 31, 2021:

		April 30, 2021						January 31,
	Estimated	Gross		Accumulated		Net		2021, (net
	Useful Life	Amounts		Amortization		Amounts		amounts)
Trade names
TRC	15 years	$	4,499	$	1,625	$	2,874	$	2,949
GPS	15 years		3,643		3,497		146		208
Process certifications	7 years		1,897		1,468		429		497
Customer relationships	10 years		916		496		420		443
Totals		$	10,955	$	7,086	$	3,869	$	4,097

XML

FINANCING ARRANGEMENTS

3 Months Ended

Apr. 30, 2021

FINANCING ARRANGEMENTS

FINANCING ARRANGEMENTS

NOTE 6 – FINANCING ARRANGEMENTS

The original term of the Company’s Amended and Restated Replacement Credit Agreement with the Bank (the “Credit Agreement”) was scheduled to expire on May 31, 2021. During April 2021, negotiations with the Bank were completed which, among other items, extended the expiration date of the Credit Agreement, as amended, to May 31, 2024 and reduced the borrowing rate. The Credit Agreement, as amended, includes the following features, among others: a lending commitment of $50.0 million including a revolving loan with interest at the 30-day LIBOR plus 1.6% (reduced from 2.0%), and an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions. The Company may use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business as defined by the Bank. At April 30, 2021, the Company had $1.8 million of outstanding letters of credit issued under the Credit Agreement. Additionally, in connection with the current project development activities of the VIE that is described in Note 1, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the approximate amount of $3.4 million as of April 30, 2021 and January 31, 2021 for which the Company has provided cash collateral.

The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement, as amended, also includes other terms, covenants and events of default that are customary for a credit facility of its size and nature, including a requirement to achieve positive adjusted earnings before interest, taxes, depreciation and amortization, as defined, over each rolling twelve-month measurement period. As of April 30, 2021 and January 31, 2021, the Company was in compliance with the covenants of the Credit Agreement.

XML

COMMITMENTS

3 Months Ended

Apr. 30, 2021

COMMITMENTS

COMMITMENTS

NOTE 7 – COMMITMENTS

Leases

The Company’s operating leases primarily cover office space that expire on various dates through January 2025 and certain equipment used by the Company in the performance of its construction services contracts. Some of these equipment leases are embedded in broader agreements with subcontractors or construction equipment suppliers. The Company has no material finance leases. None of the operating leases includes significant amounts for incentives, rent holidays or price escalations. Under certain lease agreements, the Company is obligated to pay property taxes, insurance, and maintenance costs.

Operating lease right-of-use assets and associated lease liabilities are recorded in the balance sheet at the lease commencement date based on the present value of future minimum lease payments to be made over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate (historically, LIBOR plus 2.0%) at the commencement date in determining the present value of future payments. The expected lease term includes any option to extend or to terminate the lease when it is reasonably certain the Company will exercise such option.

Operating lease expense amounts are recorded on a straight-line basis over the expected lease terms and were $0.8 million and $0.4 million for the three months ended April 30, 2021 and 2020, respectively. Operating lease payments for the three months ended April 30, 2021 and 2020 were $0.8 million and $0.4 million, respectively. For operating leases as of April 30, 2021, the weighted average lease term is 32 months and the weighted average discount rate is 3.0%.

The Company also uses equipment and occupies other facilities under short-term rental agreements. Rent expense amounts incurred under operating leases and short-term rental agreements (including portions of the lease expense amounts disclosed above) and included in costs of revenues for the three months ended April 30, 2021 and 2020 were $3.0 million and $0.6 million, respectively. Rent expense incurred under these types of arrangements (including portions of the lease expense amounts disclosed above) and included in selling, general and administrative expenses for the three months ended April 30, 2021 and 2020 was $0.2 million for both periods.

The aggregate amounts of operating leases added during the three months ended April 30, 2021 and 2020 were $0.5 million and $0.4 million, respectively. The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of April 30, 2021.

Years Ending January 31,
Remainder of 2022	$	1,925
2023		967
2024		283
2025		132
2026		20
Total lease payments		3,327
Less interest portion		90
Present value of lease payments		3,237
Less current portion (included in accrued expenses)		1,997
Non-current portion	$	1,240

The future minimum lease payments presented above include amounts due under a long-term lease covering the primary offices and plant for TRC with the founder and current chief executive officer of TRC at an annual rate of $0.3 million with a term extending through April 30, 2022.

Performance Bonds and Guarantees

In the normal course of business and for certain major projects, the Company may be required to obtain surety or performance bonding, to cause the issuance of letters of credit, or to provide parent company guarantees (or some combination thereof) in order to provide performance assurances to clients on behalf of its contractor subsidiaries. As these subsidiaries are wholly-owned, any actual liability is ordinarily reflected in the financial statement account balances

determined pursuant to the Company’s accounting for contracts with customers. When sufficient information about claims on guaranteed or bonded projects would be available and monetary damages or other costs or losses would be determined to be probable, the Company would record such losses. Any amounts that may be required to be paid in excess of the estimated costs to complete contracts in progress as of April 30, 2021 are not estimable.

As of April 30, 2021, the value of the Company’s unsatisfied bonded performance obligations, covering all of its subsidiaries, was approximately $372 million. In addition, as of April 30, 2021, there were bonds outstanding in the aggregate amount of approximately $6.6 million covering other risks including warranty obligations related to projects completed by GPS; these bonds expire at various dates over the next twelve months. Not all of our projects require bonding.

On behalf of APC, Argan provided a parent company performance guarantee to APC’s customer, the EPC services contractor on the TeesREP project, which was supported by a performance bond issued on behalf of the customer which, in connection with the completion of subcontract construction activities, will be replaced by a warranty bond in the amount of approximately $4.2 million.

As of April 30, 2021, the Company has also provided a financial guarantee, subject to certain terms and conditions, on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million in support of business development efforts. The Company believes that the fair value of this guarantee as of April 30, 2021 is not material.

Warranties

The Company generally provides assurance-type warranties for work performed under its construction contracts. The warranties cover defects in equipment, materials, design or workmanship, and most warranty periods typically run from nine to twenty-four months after the completion of construction on a particular project. Because of the nature of the Company’s projects, including project owner inspections of the work both during construction and prior to substantial completion, the Company has not experienced material unexpected warranty costs in the past. Warranty costs are estimated based on experience with the type of work and any known risks relative to each completed project. The accruals of liabilities, which are established to cover estimated future warranty costs, are recorded as the contracted work is performed, and they are included in the amounts of accrued expenses in the condensed consolidated balances sheets. The liability amounts may be periodically adjusted to reflect changes in the estimated size and number of expected warranty claims.

Solar Energy Projects

The Company has made equity investments in several solar energy projects which are accounted for using the equity method of accounting. Other than the Company making initial investment payments to a new solar energy fund in the amount of approximately $3.5 million during the three-month period ended April 30, 2021, the activities related to these projects during the period were not meaningful.  As of April 30, 2021, the Company has a remaining $1.5 million cash investment commitment to the new fund.

XML

LEGAL CONTINGENCIES

3 Months Ended

Apr. 30, 2021

LEGAL CONTINGENCIES

LEGAL CONTINGENCIES

NOTE 8 – LEGAL CONTINGENCIES

In the normal course of business, the Company may have pending claims and legal proceedings. In the opinion of management, based on information available at this time, there are no current claims and proceedings that could have a material adverse effect on the condensed consolidated financial statements except for the outstanding matter described below.

In January 2019, GPS filed a lawsuit against Exelon West Medway II, LLC and Exelon Generation Company, LLC (together referred to as “Exelon”) in the US District Court for the Southern District of New York for Exelon’s breach of contract and failure to remedy various conditions which negatively impacted the schedule and the costs associated with the construction by GPS of a gas-fired power plant for Exelon in Massachusetts. As a result, the Company believes that Exelon has received the benefits of the construction efforts of GPS and the corresponding progress made on the project without making payments to GPS for the value received (see Note 4). In March 2019, Exelon provided GPS with a notice intending to terminate the EPC contract under which GPS had been providing services to Exelon. At that time, the construction project was nearly complete and both of the power generation units included in the plant had successfully reached first fire. The completion of various prescribed performance tests and the clearance of punch-list items were the primary tasks necessary to be accomplished by GPS in order to achieve substantial completion of the power plant.

Nevertheless, and among other actions, Exelon provided contractual notice requiring GPS to vacate the construction site. Exelon has asserted that GPS failed to fulfill certain obligations under the contract and was in default, withholding payments from GPS on invoices rendered to Exelon in accordance with the terms of the contract between the parties.

With vigor, GPS intends to continue to assert its rights under the EPC contract with Exelon, to pursue the collection of amounts owed under the EPC contract and to defend itself against the allegations that GPS did not perform in accordance with the contract. The discovery period related to this litigation is now closed for both parties. No trial date has yet to be set for this lawsuit. Mediation on this matter has been set to occur in September 2021.

XML

STOCK-BASED COMPENSATION

3 Months Ended

Apr. 30, 2021

STOCK-BASED COMPENSATION

STOCK-BASED COMPENSATION

NOTE 9 – STOCK-BASED COMPENSATION

The Company’s board of directors may make share-based awards under the 2011 Stock Plan (the “2011 Plan”) or the 2020 Stock Plan (the “2020 Plan”) to officers, directors and key employees (together, the “Stock Plans”). On June 23, 2020, the Company’s stockholders approved the adoption of the 2020 Plan, and the allocation of 500,000 shares of the Company’s common stock for issuance thereunder. The 2020 Plan will serve to replace the 2011 Plan; the Company’s authority to make awards pursuant to the 2011 Plan will expire on July 19, 2021.

The features of the 2020 Plan are similar to those included in the 2011 Plan. Awards may include nonqualified stock options, incentive stock options,  and restricted or unrestricted stock. The specific provisions for each award made pursuant to the terms of the Stock Plans are documented in a written agreement between the Company and the awardee. All stock options awarded under the Stock Plans shall have an exercise price per share at least equal to the common stock’s market value on the date of grant. Stock options shall have terms no longer than ten years. Typically, stock options are awarded with one-third of each stock option vesting on each of the first three anniversaries of the corresponding award date.

As of April 30, 2021, there were approximately 2,090,929 shares of the Company’s common stock reserved for issuance under the Stock Plans; this number includes 493,528 shares of common stock available for future awards.

Stock Options

A summary of stock option activity under the Company’s approved Stock Plans for the three months ended April 30, 2021, along with corresponding weighted average per share amounts, is presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2021	1,405	$	44.17	6.90	$	10.39
Granted	32	$	54.60
Exercised	(26)	$	39.37
Forfeited	(3)	$	42.31
Outstanding, April 30, 2021	1,408	$	44.50	6.77	$	10.44
Exercisable, April 30, 2021	1,029	$	45.47	6.01	$	11.24
Outstanding, April 30, 2020	1,431	$	43.69	7.33	$	10.45
Exercisable, April 30, 2020	874	$	45.78	6.17	$	11.74

The change in the number of non-vested options to purchase shares of common stock for the three months ended April 30, 2021, and the weighted average fair value per share for each number, is presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2021	467	$	8.01
Granted	32	$	11.12
Vested	(117)	$	8.06
Forfeitures	(3)	$	8.67
Non-vested, April 30, 2021	379	$	8.25
Non-vested, April 30, 2020	557	$	8.42

The total intrinsic value amount of the stock options exercised during the three-month period ended April 30, 2021 and 2020 was $0.3 million for both periods. At April 30, 2021, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $12.5 million and $9.2 million, respectively.

Restricted Stock Units

The changes in the maximum number of restricted stock units for the three months ended April 30, 2021, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Outstanding, February 1, 2021	117	$	17.71
Awarded	113	$	38.91
Issued	(40)	$	20.64
Outstanding, April 30, 2021	190	$	29.73
Outstanding, April 30, 2020	117	$	17.71

Performance-Based Restricted Stock Units

Pursuant to the terms of the Stock Plans and as described in the corresponding agreements with the executives, the Company awarded performance-based restricted stock units to four senior executives in April 2021 and two senior executives in 2020, covering up to 49,000 and 45,000 maximum total numbers of shares of common stock, respectively, plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards. The issuance of the number of shares earned under the agreements, free of related restrictions, depends on the total return performance of the Company’s common stock measured against the performance of a peer-group of common stocks over three-year periods.

During the three months ended April 30, 2021, the three-year vesting period for the restricted stock units awarded in April 2018 concluded and it was determined that 40,471 shares of common stock, including shares attributable to cash dividends, were earned pursuant to the performance criteria and other terms of the 2011 Plan and the applicable award agreements. These shares were issued to the awardees in April 2021.

Renewable Performance-Based Restricted Stock Units

In April 2021, the Company awarded renewable performance-based restricted stock units to two senior executives at GPS pursuant to the terms of the Stock Plans and as described in the corresponding agreements with the executives. Each award covers 5,000 shares of the Company’s common stock plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards.

The issuance of the shares, free of restrictions, shall be based on the success of GPS in increasing the amount of RUPO related to renewable energy projects, as defined, during certain periods within the three-year term of each award. The awards establish RUPO hurdle amounts for separate periods of time defined in the awards, and assign a certain portion of the award shares to each hurdle. If a RUPO hurdle is exceeded (each is mutually exclusive), the number of shares earned based on the achievement of the applicable hurdle will be issued to the executives at the end of the corresponding period. If a RUPO hurdle amount is not achieved within the period of time defined in the awards, the award shares assigned to the hurdle are forfeited. 

Time-Based Restricted Stock Units

In April 2021, the Company also awarded time-based restricted stock units covering 49,500 shares of common stock to senior executives and other employees pursuant to the terms of the Stock Plans and as described in the corresponding agreements with each awardee. The shares will vest in equal installments on each of the first three anniversaries of the award date. Accordingly, at each vesting date, one-third of the award shares plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards will be issued to each awardee.

Fair Value

The fair values of stock options and restricted stock units are recorded as stock compensation expense over the terms of the corresponding awards. Expense amounts related to stock awards were $0.7 million and $0.6 million for the three months ended April 30, 2021 and 2020, respectively. At April 30, 2021, there was $7.4 million in unrecognized compensation cost related to outstanding stock awards that the Company expects to expense over the next three years.

The Company estimates the weighted average fair value of stock options on the date of award using a Black-Scholes option pricing model. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. Risk-free interest rates are determined by blending the rates for three to five year US Treasury notes. The dividend yield is based on the Company’s current annual regular dividend amount. The calculations of the expected volatility factors are based on the monthly closing prices of the Company’s common stock for the five-year periods preceding the dates of the corresponding awards.

The fair value amounts for the performance-based restricted stock units have been determined by using the per share market price of the Company’s common stock on the dates of award and the target number of shares for the awards (50% of the maximum number), by assigning equal probabilities to the thirteen possible payout outcomes at the end of each three-year term, and by computing the weighted average of the outcome amounts. For each award, the estimated fair value amount was calculated to be 88.5% of the aggregate market value of the target number of shares on the award date. For the renewable performance-based restricted stock units, which were awarded for the first time in April 2021, the fair value of each award was determined to be 50% of the aggregate market value of the shares of common stock covered by the award on the date of the award. For the time-based restricted stock units, the fair value of each award equals the aggregate market price for the number of shares covered by each award on the date of award.

XML

INCOME TAXES

3 Months Ended

Apr. 30, 2021

INCOME TAXES

INCOME TAXES

NOTE 10 – INCOME TAXES

Income Tax Expense Reconciliation

The Company’s income tax amounts for the three months ended April 30, 2021 and 2020 differed from corresponding amounts computed by applying the federal corporate income tax rate of 21% to the income (loss) before income taxes for the periods as presented below:

	Three Months Ended April 30,
	2021		2020
Computed expected income tax (expense) benefit	$	(3,052)	$	1,102
Difference resulting from:
State income taxes, net of federal tax effect		(334)		—
Deferred tax asset adjustments		(284)		—
Net operating loss carryback benefit (see discussion below)		—		4,175
Net operating losses deemed unrealizable (UK)		—		(695)
Adjustments and other differences		(98)		(128)
Income tax (expense) benefit	$	(3,768)	$	4,454

Foreign income tax expense amounts for the three months ended April 30, 2021 and 2020 were not material except that for the three months ended April 30, 2020, the valuation allowance established against the unrealizable net operating loss benefits of the subsidiary located in the UK was increased by $0.7 million.

During the quarter ended April 30, 2021, the Company wrote-off previously established deferred tax assets in the amount of $0.3 million based on the estimated non-deductible portion of stock option compensation.    

Net Operating Loss (“NOL”) Carryback

In an effort to combat the adverse economic impacts of the COVID-19 crisis, the US Congress passed the Coronavirus, Aid, Relief, and Economic Security Act ( the “CARES Act”) that was signed into law on March 27, 2020. This wide-ranging legislation was an emergency economic stimulus package that included spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19.

The tax changes of the CARES Act included a temporary suspension of the limitations on the future utilization of certain NOLs and re-established a carryback period for certain losses to five years. The NOLs eligible for carryback under the CARES Act include the Company’s domestic NOL for the year ended January 31, 2020, which was approximately $39.5 million. The Company made the appropriate filing with the Internal Revenue Service (the “IRS”) requesting carryback refunds of income taxes paid for the years ended January 31, 2017, 2016 and 2015.

A deferred tax asset in the amount of $8.3 million was recorded as of January 31, 2020 associated with the income tax benefit of the NOL for the year then ended. With the enactment of the CARES Act, the asset was moved to income taxes receivable (included in other current assets in the condensed consolidated balance sheets as of April 30, 2021 and January 31, 2021) where the value was increased to approximately $12.7 million. The carryback provided a favorable rate benefit for the Company as the loss, which was incurred in a year where the statutory federal tax rate was 21%, has been carried back to tax years where the tax rate was higher. The substantial portion of the net amount of this additional income tax benefit, estimated at the time to be approximately $4.2 million, was recorded in the three-month period ended April 30, 2020.

Research and Development Tax Credits

During Fiscal 2019, the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development tax credits that may have been available to reduce prior year income taxes. This study focused on project costs incurred during the three-year period ended January 31, 2018. Based on the results of the study, management identified and estimated significant amounts of income tax benefits that were not previously recognized in the Company’s operating results for any prior year reporting period.

The amount of research and development tax credit benefit recognized in Fiscal 2019 was $16.6 million. During Fiscal 2020, deferred tax assets related to the research and development tax credits were reduced by $0.4 million. As described below, the IRS has concluded examinations of the Company’s consolidated federal income tax returns for the years ended January 31, 2016 (“Fiscal 2016”) and 2017 (“Fiscal 2017”), as amended to include research and development tax credits, and has commenced an examination of the Company’s consolidated federal income tax return for the year ended January 31, 2018 (“Fiscal 2018”) with an expressed intent to focus on the research and development tax credit included therein. All of the aforementioned filings were made prior to January 31, 2019.

The amount of identified but unrecognized income tax benefits related to research and development tax credits as of April 30, 2021 is $5.0 million, for which the Company has established a liability for uncertain income tax return positions, most of which is included in accrued expenses as of April 30, 2021 and January 31, 2021. The final outcome of these uncertain tax positions is not yet determinable. However, the Company does not expect that the amount of unrecognized tax benefits will significantly change due to any expiration of statutes of limitation over the next 12 months. However, it is possible that the disputes with the IRS related to the Company’s federal research and development tax credits (see discussion of income tax returns below) could be resolved within the next twelve months depending on the scheduling of an appeals hearing and/or the results of negotiations with the IRS. If resolution of the disputes occurs, it would result in the Company’s elimination of at least a substantial portion of the amount of the liability for uncertain income tax positions discussed above. As of April 30, 2021, the Company does not believe that it has any other material uncertain income tax positions reflected in its accounts.

As of April 30, 2021 and January 31, 2021, the balances of other current assets in the condensed consolidated balance sheet included income tax refunds and prepaid income taxes in the total amount of approximately $26.9 million at each date. The income tax refunds include the amounts expected to be received from the IRS upon completion of the tax return examination appeals process identified below and the amount expected to be received from the IRS upon its processing of the Company’s NOL carryback refund request discussed above.

Income Tax Returns

The Company is subject to federal and state income taxes in the US, and income taxes in Ireland and the UK. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2017 except for several notable exceptions including Ireland, the UK and several states where the open periods are one year longer.

The IRS conducted an examination of the Company’s original federal consolidated income tax return for Fiscal 2016. The IRS reported to the Company that no unfavorable adjustment items were noted during this examination. However, the Company consented to an extension of the audit timeline which enabled the IRS to also examine the amendment to the income tax return, which included the research and development credit for the year. In addition, the IRS opened an examination of the Company’s amended consolidated income tax return for Fiscal 2017. In substance, these efforts evolved into simultaneously conducted examinations of the research and development credits claimed in each year.

In January 2021, the IRS issued its final revenue agents report that documents its understanding of the facts, attempts to summarize the Company’s arguments in support of the research and development claims and states its position which disagrees with the Company’s treatment of a substantial amount of the costs that support the Company’s claims for Fiscal 2016 and Fiscal 2017. The Company believes that its arguments are sound and that the report does not present any new facts relating to the issues or make any new arguments that would cause it to make any adjustments to its accounting for the research and development claims as of April 30, 2021. In March 2021, the Company submitted a formal protest of the findings of the IRS examiner and intends to pursue its income tax position with the IRS through the established protest and appeals process. The Company expects that the ultimate settlement of the income tax dispute will be resolved on a basis favorable to the Company.

In November 2020, the Company was notified by the IRS that it intends to examine the consolidated income tax return for Fiscal 2018, with an expressed focus on the research and development tax credit claimed therein. The Company expects that by the time the appeals process commences, its protest will dispute the results of the examinations of the tax returns for all three years.

Supplemental Cash Flow Information

The Company was not required to make any income tax payments during the three months ended April 30, 2021 or 2020. During the three months ended April 30, 2021, the Company did not receive any income tax refunds that were material. During the three months ended April 30, 2020, the Company received cash refunds of previously paid income taxes from various taxing authorities in the total amount of $0.8 million.

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

3 Months Ended

Apr. 30, 2021

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

NOTE 11 – NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in the notes):

	Three Months Ended April 30,
	2021		2020
Net income (loss) attributable to the stockholders of Argan	$	10,766	$	(763)
Weighted average number of shares outstanding – basic		15,726		15,643
Effect of stock awards (1)(2)		235		—
Weighted average number of shares outstanding – diluted		15,961		15,643
Net income (loss) per share attributable to the stockholders of Argan
Basic	$	0.68	$	(0.05)
Diluted	$	0.67	$	(0.05)

(1) For the three months ended April 30, 2021, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 279,500 shares of common stock.

(2) For the three months ended April 30, 2020, all common stock equivalents, which covered 1,483,151 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

XML

CASH DIVIDENDS

3 Months Ended

Apr. 30, 2021

CASH DIVIDENDS

CASH DIVIDENDS

NOTE 12 – CASH DIVIDENDS

On April 14, 2021, the Company’s board of directors declared a regular quarterly cash dividend in the amount of $0.25 per share of common stock, which was paid on April 30, 2021 to stockholders of record at the close of business on April 22, 2021. Last year, the board of directors declared a regular quarterly cash dividend of $0.25 per share of common stock, which was paid to stockholders on April 30, 2020.

XML

CUSTOMER CONCENTRATIONS

3 Months Ended

Apr. 30, 2021

CUSTOMER CONCENTRATIONS

CUSTOMER CONCENTRATIONS

NOTE 13 – CUSTOMER CONCENTRATIONS

The majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided 77% and 81% of consolidated revenues for the three months ended April 30, 2021 and 2020, respectively. The industrial services segment represented 21% and 16% of consolidated revenues for the three months ended April 30, 2021 and 2020, respectively.

The Company’s most significant customer relationships for the three months ended April 30, 2021 included one power industry service customer, which accounted for 68% of consolidated revenues. The Company’s most significant customer relationships for the three months ended April 30, 2020 included two power industry service customers, which accounted for 61% and 17% of consolidated revenues, respectively.

The accounts receivable balances from two major customers each represented 23% of the corresponding consolidated balance as of April 30, 2021. Accounts receivable balances from three major customers represented 26%, 11% and 11% of the corresponding consolidated balance as of January 31, 2021. The contract asset balance from one major customer represented 65% of the corresponding consolidated balance as of April 30, 2021. Contract asset balances from two major customers represented 64% and 12% of the corresponding consolidated balance as of January 31, 2021.

XML

SEGMENT REPORTING

3 Months Ended

Apr. 30, 2021

SEGMENT REPORTING

SEGMENT REPORTING

NOTE 14 – SEGMENT REPORTING

Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than one operating segment. Intersegment revenues and the related cost of revenues are netted against the corresponding amounts of the segment receiving the intersegment services. For the three months ended April 30, 2021 and 2020, intersegment revenues totaled approximately $2.0 million and $0.6 million, respectively. Intersegment revenues for the aforementioned periods primarily related to services provided by the industrial fabrication and field services segment to the power industry services segment and were based on prices negotiated by the parties.

Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three months ended April 30, 2021 and 2020. The “Other” column in each summary includes the Company’s corporate expenses.

Three Months Ended	Power		Industrial		Telecom
April 30, 2021	Services		Services		Services		Other		Totals
Revenues	$	97,172	$	26,658	$	2,511	$	—	$	126,341
Cost of revenues		78,669		21,969		1,989		—		102,627
Gross profit		18,503		4,689		522		—		23,714
Selling, general and administrative expenses		5,455		1,882		486		2,069		9,892
Income (loss) from operations		13,048		2,807		36		(2,069)		13,822
Other income, net		710		—		—		2		712
Income (loss) before income taxes	$	13,758	$	2,807	$	36	$	(2,067)		14,534
Income tax expense										(3,768)
Net income									$	10,766
Amortization of intangibles	$	61	$	167	$	—	$	—	$	228
Depreciation		166		607		108		1		882
Property, plant and equipment additions		602		9		232		1		844
Current assets	$	371,827	$	27,422	$	2,433	$	157,349	$	559,031
Current liabilities		265,471		14,796		1,212		1,586		283,065
Goodwill		18,476		9,467		—		—		27,943
Total assets		408,442		47,840		3,974		157,716		617,972

Three Months Ended	Power		Industrial		Telecom
April 30, 2020	Services		Services		Services		Other		Totals
Revenues	$	48,612	$	9,744	$	1,792	$	—	$	60,148
Cost of revenues		45,710		8,982		1,447		—		56,139
Gross profit		2,902		762		345		—		4,009
Selling, general and administrative expenses		5,928		2,123		488		1,805		10,344
Loss from operations		(3,026)		(1,361)		(143)		(1,805)		(6,335)
Other income, net		1,024		—		—		64		1,088
Loss before income taxes	$	(2,002)	$	(1,361)	$	(143)	$	(1,741)		(5,247)
Income tax benefit										4,454
Net loss									$	(793)
Amortization of intangibles	$	60	$	165	$	—	$	—	$	225
Depreciation		170		667		99		1		937
Property, plant and equipment additions		380		210		94		—		684
Current assets	$	316,753	$	22,916	$	2,434	$	113,633	$	455,736
Current liabilities		163,674		8,184		793		455		173,106
Goodwill		18,476		9,467		—		—		27,943
Total assets		348,577		46,411		4,013		113,963		512,964

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION (Policies)

3 Months Ended

Apr. 30, 2021

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Basis of Presentation and Significant Accounting Policies

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIE. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 of each year.

The condensed consolidated balance sheet as of April 30, 2021, the condensed consolidated statements of earnings and stockholders’ equity for the three months ended April 30, 2021 and 2020, and the condensed consolidated statements of cash flows for the three months ended April 30, 2021 and 2020 are unaudited. The condensed consolidated balance sheet as of January 31, 2021 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2021 (“Fiscal 2021”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of April 30, 2021, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

Accounting Policies

Income Taxes

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. Adoption of this new guidance, which was effective for the Company on February 1, 2021, did not alter the Company’s accounting for income taxes.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

Fair Values

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three-month periods ended April 30, 2021 and 2020. The total amounts of the project development costs included in the balances for property, plant and equipment as of April 30, 2021 and January 31, 2021 were $7.7 million and $7.5 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS (Tables)

3 Months Ended

Apr. 30, 2021

REVENUES FROM CONTRACTS WITH CUSTOMERS

Schedule of consolidated revenues disaggregated by geographical area

	Three Months Ended April 30,
	2021		2020
United States	$	115,491	$	48,865
United Kingdom		6,157		10,296
Republic of Ireland		4,693		987
Consolidated Revenues	$	126,341	$	60,148

XML

PURCHASED INTANGIBLE ASSETS (Tables)

3 Months Ended

Apr. 30, 2021

PURCHASED INTANGIBLE ASSETS

Schedule of company's purchased intangible assets, other than goodwill

		April 30, 2021						January 31,
	Estimated	Gross		Accumulated		Net		2021, (net
	Useful Life	Amounts		Amortization		Amounts		amounts)
Trade names
TRC	15 years	$	4,499	$	1,625	$	2,874	$	2,949
GPS	15 years		3,643		3,497		146		208
Process certifications	7 years		1,897		1,468		429		497
Customer relationships	10 years		916		496		420		443
Totals		$	10,955	$	7,086	$	3,869	$	4,097

XML

COMMITMENTS (Tables)

3 Months Ended

Apr. 30, 2021

COMMITMENTS

Schedule of future minimum lease payments for the operating leases

Years Ending January 31,
Remainder of 2022	$	1,925
2023		967
2024		283
2025		132
2026		20
Total lease payments		3,327
Less interest portion		90
Present value of lease payments		3,237
Less current portion (included in accrued expenses)		1,997
Non-current portion	$	1,240

XML

STOCK-BASED COMPENSATION (Tables)

3 Months Ended

Apr. 30, 2021

Apr. 30, 2020

STOCK-BASED COMPENSATION

Schedule of stock option activity under the Company's stock plans

Stock Options

A summary of stock option activity under the Company’s approved Stock Plans for the three months ended April 30, 2021, along with corresponding weighted average per share amounts, is presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2021	1,405	$	44.17	6.90	$	10.39
Granted	32	$	54.60
Exercised	(26)	$	39.37
Forfeited	(3)	$	42.31
Outstanding, April 30, 2021	1,408	$	44.50	6.77	$	10.44
Exercisable, April 30, 2021	1,029	$	45.47	6.01	$	11.24
Outstanding, April 30, 2020	1,431	$	43.69	7.33	$	10.45
Exercisable, April 30, 2020	874	$	45.78	6.17	$	11.74

Schedule of changes in the number of non-vested options to purchase shares of common stock

The change in the number of non-vested options to purchase shares of common stock for the three months ended April 30, 2021, and the weighted average fair value per share for each number, is presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2021	467	$	8.01
Granted	32	$	11.12
Vested	(117)	$	8.06
Forfeitures	(3)	$	8.67
Non-vested, April 30, 2021	379	$	8.25
Non-vested, April 30, 2020	557	$	8.42

Schedule of changes in restricted stock units

The changes in the maximum number of restricted stock units for the three months ended April 30, 2021, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Outstanding, February 1, 2021	117	$	17.71
Awarded	113	$	38.91
Issued	(40)	$	20.64
Outstanding, April 30, 2021	190	$	29.73
Outstanding, April 30, 2020	117	$	17.71

XML

INCOME TAXES (Tables)

3 Months Ended

Apr. 30, 2021

INCOME TAXES

Schedule of actual income tax expense amounts

	Three Months Ended April 30,
	2021		2020
Computed expected income tax (expense) benefit	$	(3,052)	$	1,102
Difference resulting from:
State income taxes, net of federal tax effect		(334)		—
Deferred tax asset adjustments		(284)		—
Net operating loss carryback benefit (see discussion below)		—		4,175
Net operating losses deemed unrealizable (UK)		—		(695)
Adjustments and other differences		(98)		(128)
Income tax (expense) benefit	$	(3,768)	$	4,454

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN (Tables)

3 Months Ended

Apr. 30, 2021

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN

Schedule of computations of basic and diluted net income (loss) per share

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in the notes):

	Three Months Ended April 30,
	2021		2020
Net income (loss) attributable to the stockholders of Argan	$	10,766	$	(763)
Weighted average number of shares outstanding – basic		15,726		15,643
Effect of stock awards (1)(2)		235		—
Weighted average number of shares outstanding – diluted		15,961		15,643
Net income (loss) per share attributable to the stockholders of Argan
Basic	$	0.68	$	(0.05)
Diluted	$	0.67	$	(0.05)

(1) For the three months ended April 30, 2021, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 279,500 shares of common stock.

(2) For the three months ended April 30, 2020, all common stock equivalents, which covered 1,483,151 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

XML

SEGMENT REPORTING (Tables)

3 Months Ended

Apr. 30, 2021

SEGMENT REPORTING

Schedule of operating results and certain financial position data of the Company's reportable business segments

Three Months Ended	Power		Industrial		Telecom
April 30, 2021	Services		Services		Services		Other		Totals
Revenues	$	97,172	$	26,658	$	2,511	$	—	$	126,341
Cost of revenues		78,669		21,969		1,989		—		102,627
Gross profit		18,503		4,689		522		—		23,714
Selling, general and administrative expenses		5,455		1,882		486		2,069		9,892
Income (loss) from operations		13,048		2,807		36		(2,069)		13,822
Other income, net		710		—		—		2		712
Income (loss) before income taxes	$	13,758	$	2,807	$	36	$	(2,067)		14,534
Income tax expense										(3,768)
Net income									$	10,766
Amortization of intangibles	$	61	$	167	$	—	$	—	$	228
Depreciation		166		607		108		1		882
Property, plant and equipment additions		602		9		232		1		844
Current assets	$	371,827	$	27,422	$	2,433	$	157,349	$	559,031
Current liabilities		265,471		14,796		1,212		1,586		283,065
Goodwill		18,476		9,467		—		—		27,943
Total assets		408,442		47,840		3,974		157,716		617,972

Three Months Ended	Power		Industrial		Telecom
April 30, 2020	Services		Services		Services		Other		Totals
Revenues	$	48,612	$	9,744	$	1,792	$	—	$	60,148
Cost of revenues		45,710		8,982		1,447		—		56,139
Gross profit		2,902		762		345		—		4,009
Selling, general and administrative expenses		5,928		2,123		488		1,805		10,344
Loss from operations		(3,026)		(1,361)		(143)		(1,805)		(6,335)
Other income, net		1,024		—		—		64		1,088
Loss before income taxes	$	(2,002)	$	(1,361)	$	(143)	$	(1,741)		(5,247)
Income tax benefit										4,454
Net loss									$	(793)
Amortization of intangibles	$	60	$	165	$	—	$	—	$	225
Depreciation		170		667		99		1		937
Property, plant and equipment additions		380		210		94		—		684
Current assets	$	316,753	$	22,916	$	2,434	$	113,633	$	455,736
Current liabilities		163,674		8,184		793		455		173,106
Goodwill		18,476		9,467		—		—		27,943
Total assets		348,577		46,411		4,013		113,963		512,964

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION (Details) - USD ($) $ in Millions	3 Months Ended	12 Months Ended
	Apr. 30, 2021	Jan. 31, 2021
DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION
Cost of property, plant and equipment	$ 7.7	$ 7.5

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS (Details) - USD ($) $ in Millions	Apr. 30, 2021	Jan. 31, 2021
REVENUES FROM CONTRACTS WITH CUSTOMERS
Retained amounts by project owners	$ 42.1	$ 36.8
Amounts of unpriced change orders included in transaction prices	17.6	16.6

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS - Accounting for the Loss Subcontract (Details) - TeesREPProject - USD ($) $ in Millions	3 Months Ended		12 Months Ended
	Apr. 30, 2021	Apr. 30, 2020	Jan. 31, 2021	Jan. 31, 2020	Mar. 24, 2020
REVENUES FROM CONTRACTS WITH CUSTOMERS
Loss recorded		$ 2.7		$ 33.6
Reversal of profit				$ 0.7
Excess of projected project costs over projected project revenues		$ 36.2
Percentage of completion of subcontracted work					90.00%
Subcontract loss	$ 29.5
The total amounts of accounts receivable and contract assets with the customer	$ 1.6		$ 4.7

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS - Remaining Unsatisfied Performance Obligations (Details) - Revenue, Remaining Performance Obligation, Expected Timing of Satisfaction, Start Date [Axis]: 2021-05-01 $ in Millions	Apr. 30, 2021 USD ($)
REVENUES FROM CONTRACTS WITH CUSTOMERS
Contract backlog amount	$ 478.7
Contract backlog (as percent)	58.00%
Revenue, Remaining Performance Obligation, Expected Timing of Satisfaction, Period	21 months

XML

REVENUES FROM CONTRACTS WITH CUSTOMERS - Disaggregation of Revenues (Details) - USD ($) $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
Disaggregation of Revenues
Totals	$ 126,341	$ 60,148
United States
Disaggregation of Revenues
Totals	115,491	48,865
United Kingdom
Disaggregation of Revenues
Totals	6,157	10,296
Republic of Ireland
Disaggregation of Revenues
Totals	$ 4,693	$ 987

XML

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS (Details) - Held-to-maturity Securities	3 Months Ended	12 Months Ended
	Apr. 30, 2021	Jan. 31, 2021
Cash and Cash Equivalents
Maturity period	1 year	1 year
Weighted average annual interest rates of CDs (as a percent)	0.20%	0.20%

XML

ACCOUNTS AND NOTES RECEIVABLE (Details) $ in Millions	Apr. 30, 2021 USD ($)
ACCOUNTS AND NOTES RECEIVABLE
Outstanding balances of accounts receivable and contract assets	$ 24.5
Past due notes receivable	$ 1.8

XML

PURCHASED INTANGIBLE ASSETS - Goodwill and Finite Lived Intangible Assets (Details) - USD ($) $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020	Jan. 31, 2021
Indefinite-Lived Intangible Assets
Goodwill	$ 27,943	$ 27,943	$ 27,943
Intangible Assets - Gross Carrying Amount	10,955
Accumulated Amortization	7,086
Intangible Assets, Net (Excluding Goodwill)	3,869		4,097
Amortization of intangibles	228	$ 225
TRC
Indefinite-Lived Intangible Assets
Goodwill	9,500		9,500
GPS
Indefinite-Lived Intangible Assets
Goodwill	$ 18,500		18,500
Trade names | TRC
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life	15 years
Finite Lived Intangible Assets - Gross Carrying Amount	$ 4,499
Accumulated Amortization	1,625
Finite Lived Intangible Assets - Net Amount	$ 2,874		2,949
Trade names | GPS
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life	15 years
Finite Lived Intangible Assets - Gross Carrying Amount	$ 3,643
Accumulated Amortization	3,497
Finite Lived Intangible Assets - Net Amount	$ 146		208
Process certifications
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life	7 years
Finite Lived Intangible Assets - Gross Carrying Amount	$ 1,897
Accumulated Amortization	1,468
Finite Lived Intangible Assets - Net Amount	$ 429		497
Customer relationships
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life	10 years
Finite Lived Intangible Assets - Gross Carrying Amount	$ 916
Accumulated Amortization	496
Finite Lived Intangible Assets - Net Amount	$ 420		$ 443

XML

FINANCING ARRANGEMENTS (Details) - USD ($) $ in Millions	1 Months Ended	3 Months Ended	12 Months Ended
	Apr. 30, 2021	Apr. 30, 2021	Jan. 31, 2021
Financing Arrangements
Amount of an outstanding letter of credit issued by Bank in support of project development activities and deposited with the Bank as collateral	$ 3.4	$ 3.4	$ 3.4
London Interbank Offered Rate (LIBOR)
Financing Arrangements
Interest rate margin on referred rate		2.00%
Revolving Credit Facility
Financing Arrangements
Additional commitment amount	$ 10.0
Revolving Credit Facility | London Interbank Offered Rate (LIBOR)
Financing Arrangements
Variable rate	30-day LIBOR
Interest rate margin on referred rate	1.60%		2.00%
Revolving Credit Facility | Expires on May 31, 2024
Financing Arrangements
Borrowing available under financing arrangements	$ 50.0	$ 50.0
Letter of Credit
Financing Arrangements
Letters of credit outstanding amount	$ 1.8	$ 1.8

XML

COMMITMENTS - Leases (Details) - USD ($) $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
Operating leases, options to extend	true
Operating leases, options to terminate	true
Operating lease expense	$ 776	$ 379
Operating lease payments	$ 800	400
Weighted average lease term	32 months
Weighted average discount rate	3.00%
Future minimum lease payment	$ 500	400
Unsatisfied bonded performance obligations	372,000
Bonds outstanding, covering other risks	6,600
Warranty bond	$ 4,200
London Interbank Offered Rate (LIBOR)
Interest rate margin on referred rate	2.00%
TRC
April 30, 2022	$ 300
GPS | Financial guarantee
Guarantor obligation maximum exposure	3,600
Costs of Revenues
Rent expense	3,000	600
Selling, General and Administrative Expenses
Rent expense	$ 200	$ 200

XML

COMMITMENTS - Future minimum lease payments (Details) $ in Thousands	Apr. 30, 2021 USD ($)
Operating Leases
Remainder of 2022	$ 1,925
2023	967
2024	283
2025	132
2026	20
Total lease payments	3,327
Less interest portion	90
Present value of lease payments	3,237
Less current portion (included in accrued expenses)	$ 1,997
Less current portion (included in accrued expenses)	Accrued expenses
Non-current portion	$ 1,240
Non-current portion	Non-current portion

XML

COMMITMENTS - Warranties (Details)	3 Months Ended
	Apr. 30, 2021
Minimum
Warranty period	9 months
Maximum
Warranty period	24 months

XML

COMMITMENTS - Solar Energy Projects (Details) $ in Thousands	3 Months Ended
	Apr. 30, 2021 USD ($)
COMMITMENTS
Initial investment payments	$ 3,520
Remaining cash investment commitments	$ 1,500

XML

STOCK-BASED COMPENSATION - Summary of Activity under Company's Stock Option Plans (Details) - $ / shares shares in Thousands	3 Months Ended		12 Months Ended
	Apr. 30, 2021	Apr. 30, 2020	Jan. 31, 2021
STOCK-BASED COMPENSATION
Shares, Outstanding, Beginning balance	1,405
Shares, Granted	32
Shares, Exercised	(26)
Shares, Forfeited	(3)
Shares, Outstanding, Ending balance	1,408	1,431	1,405
Shares, Exercisable	1,029	874
Weighted Average Exercise Price, Outstanding, Beginning balance	$ 44.17
Weighted Average Exercise Price, Granted	54.60
Weighted Average Exercise Price, Exercised	39.37
Weighted Average Exercise Price, Forfeited	42.31
Weighted Average Exercise Price, Outstanding, Ending balance	44.50	$ 43.69	$ 44.17
Weighted Average Exercise Price, Exercisable	$ 45.47	$ 45.78
Weighted Average Remaining Term (Years), Outstanding	6 years 9 months 7 days	7 years 3 months 29 days	6 years 10 months 24 days
Weighted Average Remaining Term (Years), Exercisable	6 years 3 days	6 years 2 months 1 day
Weighted Average Fair Value, Outstanding	$ 10.44	$ 10.45	$ 10.39
Weighted Average Fair Value, Exercisable	$ 11.24	$ 11.74

XML

STOCK-BASED COMPENSATION - Summary of Change in Number of Non-Vested Options to Purchase Shares of Common Stock (Details) - $ / shares shares in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
STOCK-BASED COMPENSATION
Shares, Non-vested, Beginning balance	467
Shares, Granted	32
Shares, Vested	(117)
Shares, Forfeitures	(3)
Shares, Non-vested, Ending balance	379
Shares, Non-vested	379	557
Weighted Average Fair Value, Non-vested, Beginning balance	$ 8.01
Weighted Average Fair Value, Granted	11.12
Weighted Average Fair Value, Vested	8.06
Weighted Average Fair Value, Forfeitures	8.67
Weighted Average Fair Value, Non-vested, Ending balance	8.25
Weighted Average Fair Value, Non-vested	$ 8.25	$ 8.42

XML

STOCK-BASED COMPENSATION - Summary of Change in restricted stock units (Details) - Restricted Stock Units - $ / shares shares in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
Share-based Compensation Arrangement by Share-based Payment Award, Equity Instruments Other than Options, Nonvested, Number of Shares [Roll Forward]
Outstanding, Beginning balance (in shares)	117
Awarded (in shares)	113
Issued (in shares)	(40)
Outstanding, Ending balance (in shares)	190
Outstanding (in shares)	190	117
Share-based Compensation Arrangement by Share-based Payment Award, Equity Instruments Other than Options, Nonvested, Weighted Average Grant Date Fair Value [Abstract]
Outstanding, Beginning balance Fair value (Per share)	$ 17.71
Awarded, Fair value (Per share)	38.91
Issued, Fair value (Per share)	20.64
Outstanding, Ending balance Fair value (Per share)	29.73
Outstanding, Fair value (per share)	$ 29.73	$ 17.71

XML

STOCK-BASED COMPENSATION - Additional Information (Details) $ in Thousands	1 Months Ended		3 Months Ended
	Apr. 30, 2021 USD ($) person item shares	Apr. 30, 2020 person shares	Apr. 30, 2021 USD ($) item shares	Apr. 30, 2020 USD ($)	Jun. 23, 2020 shares
Share-based Compensation Arrangement by Share-based Payment Award
Percentage Reduction In The Aggregate Fair Value Of Stock Option			88.50%
Stock compensation expense | $			$ 679	$ 642
Unrecognized compensation cost | $	$ 7,400		$ 7,400
Compensation expense recognize, period			3 years
Intrinsic value of outstanding stock options | $	12,500		$ 12,500
Intrinsic value of exercisable stock options | $	$ 9,200		$ 9,200
Period used for calculations			5 years
Fair value of award as a percentage of market value			50.00%
Minimum
Share-based Compensation Arrangement by Share-based Payment Award
Period used for calculations			3 years
Maximum
Share-based Compensation Arrangement by Share-based Payment Award
Period used for calculations			5 years
2020 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Number of shares of common stock reserved for issuance					500,000
Stock Options Plans
Share-based Compensation Arrangement by Share-based Payment Award
Initial vesting percentage			33.33%
Period to become exercisable			3 years
Number of shares of common stock available for award	493,528		493,528
Number of shares of common stock reserved for issuance	2,090,929		2,090,929
Intrinsic value of the stock options exercised | $			$ 300	$ 300
Performance-based restricted stock units | 2011 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Number of executives | person	4	2
ISOs/NSOs
Share-based Compensation Arrangement by Share-based Payment Award
Incentive stock option award maximum expiration period			10 years
Restricted Stock Units
Share-based Compensation Arrangement by Share-based Payment Award
Number of shares earned and issue under the restricted stock unit			40,000
Restricted Stock Units | 2011 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Period to become exercisable			3 years
Number of shares earned and issue under the restricted stock unit			40,471
Renewable Performance-Based Restricted Stock Units
Share-based Compensation Arrangement by Share-based Payment Award
Awards authorized	5,000		5,000
Share-based Compensation Arrangement by Share-based Payment Award, Terms of Award	three-year
Time Based Restricted Stock Units
Share-based Compensation Arrangement by Share-based Payment Award
Initial vesting percentage	33.33%
Awards authorized	49,500		49,500
Number of anniversaries | item	3		3
Senior executives | Performance-based restricted stock units | 2011 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Period to become exercisable			3 years
Percentage of the maximum shares for the target number of shares awarded			50.00%
Senior executives | Performance-based restricted stock units | 2011 Plan | Maximum
Share-based Compensation Arrangement by Share-based Payment Award
Number of shares awarded		45,000	49,000
Senior executives | Renewable Performance-Based Restricted Stock Units
Share-based Compensation Arrangement by Share-based Payment Award
Number of executives | person	2

XML

INCOME TAXES - Income Tax Expense Reconciliation (Details) - USD ($) $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
INCOME TAXES
Computed expected income tax (expense) benefit	$ (3,052)	$ 1,102
State income taxes, net of federal tax effect	(334)
Stock award valuation allowances	(284)
Net operating loss carryback benefit		4,175
Net operating losses deemed unrealizable (UK)		(695)
Adjustments and other differences	(98)	(128)
Income tax (expense) benefit	$ (3,768)	$ 4,454

XML

INCOME TAXES - Net Operating Loss Carryback (Details) - USD ($) $ in Thousands	3 Months Ended		12 Months Ended
	Apr. 30, 2021	Apr. 30, 2020	Jan. 31, 2021	Jan. 31, 2020
Operating Loss Carryforwards [Line Items]
Federal corporate income tax rate (as percent)	21.00%	21.00%	21.00%
Increase in loss carryback period for certain losses	5 years
Domestic net operating loss carryback			$ 39,500
Deferred tax asset				$ 8,300
Amount of rate difference tax benefit		$ 4,175
Other current assets
Operating Loss Carryforwards [Line Items]
Income tax receivable	$ 12,700

XML

INCOME TAXES - Research and Development Tax Credits (Details) - USD ($) $ in Millions	12 Months Ended
	Jan. 31, 2018	Apr. 30, 2021	Jan. 31, 2021	Jan. 31, 2020	Jan. 31, 2019
INCOME TAXES
Prior period for identify and quantify the amounts of research and development credits	3 years
Research and development tax credit benefit				$ 0.4	$ 16.6
Unrecognized income tax benefits related to research and development credits		$ 5.0
Income tax refunds and prepaid income taxes			$ 26.9

XML

INCOME TAXES - Equity Method Investments And Supplemental Cash Flow Information (Details) - USD ($)	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
INCOME TAXES
Payment for equity method investment	$ 3,520,000
Income Taxes Paid, Net	0	$ 0
Proceeds from Income Tax Refunds	$ 0	$ 800,000

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN (Details) - USD ($) $ / shares in Units, shares in Thousands, $ in Thousands	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN
Net income (loss) attributable to the stockholders of Argan, Inc.	$ 10,766	$ (763)
Weighted average number of shares outstanding - basic	15,726	15,643
Effects of stock awards	235
Weighted average number of shares outstanding - diluted	15,961	15,643
Basic	$ 0.68	$ (0.05)
Diluted	$ 0.67	$ (0.05)

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN - Additional information (Details) - shares	3 Months Ended
	Apr. 30, 2021	Apr. 30, 2020
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN
Antidilutive common stock	279,500	1,483,151

XML

CASH DIVIDENDS (Details) - $ / shares				3 Months Ended
	Apr. 30, 2021	Apr. 14, 2021	Apr. 30, 2020	Apr. 30, 2021	Apr. 30, 2020
CASH DIVIDENDS
Regular cash dividend declared per common stock		$ 0.25	$ 0.25	$ 0.25	$ 0.25
Regular cash dividend paid per common stock	$ 0.25		$ 0.25

XML

CUSTOMER CONCENTRATIONS (Details) - customer	3 Months Ended		12 Months Ended
	Apr. 30, 2021	Apr. 30, 2020	Jan. 31, 2021
Major Customer One | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer	23.00%
Customer Concentration Risk | Accounts Receivable
Customer Concentrations
Number of customers	2		3
Customer Concentration Risk | Contract Asset
Customer Concentrations
Number of customers	1		2
Customer Concentration Risk | Major Customer One | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			26.00%
Customer Concentration Risk | Major Customer One | Contract Asset
Customer Concentrations
Percentage of major customers or segments	65.00%		64.00%
Customer Concentration Risk | Major Customer Two | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			11.00%
Customer Concentration Risk | Major Customer Two | Contract Asset
Customer Concentrations
Percentage of major customers or segments			12.00%
Customer Concentration Risk | Major Customer Three | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			11.00%
Power Services | Product Concentration Risk | Revenue
Customer Concentrations
Percentage of major customers or segments	77.00%	81.00%
Power Services | Customer Concentration Risk | Revenue
Customer Concentrations
Number of customers	1	2
Power Services | Customer Concentration Risk | Major Customer One | Revenue
Customer Concentrations
Percentage of major customers or segments	68.00%	61.00%
Power Services | Customer Concentration Risk | Major Customer Two | Revenue
Customer Concentrations
Percentage of major customers or segments		17.00%
Industry services | Product Concentration Risk | Revenue
Customer Concentrations
Percentage of major customers or segments	21.00%	16.00%

XML

SEGMENT REPORTING (Details) $ in Thousands	3 Months Ended
	Apr. 30, 2021 USD ($) segment	Apr. 30, 2020 USD ($)	Jan. 31, 2021 USD ($)
Segment Reporting Information
Operating segment | segment	1
Revenues	$ 126,341	$ 60,148
Cost of revenues	102,627	56,139
Gross (loss) profit	23,714	4,009
Selling, general and administrative expenses	9,892	10,344
Income (loss) from operations	13,822	(6,335)
Other income, net	712	1,088
Income (loss) before income taxes	14,534	(5,247)
Income tax expense	(3,768)	4,454
Net income (loss)	10,766	(793)
Amortization of intangibles	228	225
Depreciation	882	937
Property, plant and equipment additions	844	684
Current assets	559,031	455,736	$ 546,220
Current liabilities	283,065	173,106	276,087
Goodwill	27,943	27,943	27,943
Total assets	617,972	512,964	$ 602,630
Other
Segment Reporting Information
Selling, general and administrative expenses	2,069	1,805
Income (loss) from operations	(2,069)	(1,805)
Other income, net	2	64
Income (loss) before income taxes	(2,067)	(1,741)
Depreciation	1	1
Property, plant and equipment additions	1
Current assets	157,349	113,633
Current liabilities	1,586	455
Total assets	157,716	113,963
Intercompany Eliminations
Segment Reporting Information
Revenues	2,000	600
Power Services
Segment Reporting Information
Revenues	97,172	48,612
Cost of revenues	78,669	45,710
Gross (loss) profit	18,503	2,902
Selling, general and administrative expenses	5,455	5,928
Income (loss) from operations	13,048	(3,026)
Other income, net	710	1,024
Income (loss) before income taxes	13,758	(2,002)
Amortization of intangibles	61	60
Depreciation	166	170
Property, plant and equipment additions	602	380
Current assets	371,827	316,753
Current liabilities	265,471	163,674
Goodwill	18,476	18,476
Total assets	408,442	348,577
Industrial Services
Segment Reporting Information
Revenues	26,658	9,744
Cost of revenues	21,969	8,982
Gross (loss) profit	4,689	762
Selling, general and administrative expenses	1,882	2,123
Income (loss) from operations	2,807	(1,361)
Income (loss) before income taxes	2,807	(1,361)
Amortization of intangibles	167	165
Depreciation	607	667
Property, plant and equipment additions	9	210
Current assets	27,422	22,916
Current liabilities	14,796	8,184
Goodwill	9,467	9,467
Total assets	47,840	46,411
Telecom Services
Segment Reporting Information
Revenues	2,511	1,792
Cost of revenues	1,989	1,447
Gross (loss) profit	522	345
Selling, general and administrative expenses	486	488
Income (loss) from operations	36	(143)
Income (loss) before income taxes	36	(143)
Depreciation	108	99
Property, plant and equipment additions	232	94
Current assets	2,433	2,434
Current liabilities	1,212	793
Total assets	$ 3,974	$ 4,013