10-Q 1 a19-10006_110q.htm 10-Q

Table of Contents

 

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

 

FORM 10-Q

 

(Mark One)

 

x      QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the Quarterly Period Ended April 30, 2019

 

or

 

o         TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT

 

For the Transition Period from              to            

 

Commission File Number 001-31756

 

(Exact Name of Registrant as Specified in Its Charter)

 

Delaware

 

13-1947195

(State or Other Jurisdiction of Incorporation)

 

(I.R.S. Employer Identification No.)

 

 

One Church Street, Suite 201, Rockville, Maryland 20850

(Address of Principal Executive Offices) (Zip Code)

 

(301) 315-0027

(Registrant’s Telephone Number, Including Area Code)

 

 

(Former Name, Former Address and Former Fiscal Year, if Changed since Last Report)

 

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15 (d) of the Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes x No o

 

Indicate by check mark whether the Registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the Registrant was required to submit such files).  Yes x No o

 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

 

Large accelerated filer o Accelerated filer x Non-accelerated filer o Smaller reporting company o Emerging growth company o

 

If an emerging growth company, indicate by check mark if the Registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. o

 

Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes o No x

 

Title of Each Class

 

Trading Symbol(s)

 

Name of Each Exchange on Which Registered

Common Stock, $.15 par value

 

AGX

 

New York Stock Exchange

 

Indicate the number of shares outstanding of each of the Registrant’s classes of common stock, as of the latest practicable date.

 

Common stock, $0.15 par value: 15,633,302 shares as of June 6, 2019.

 

 

 


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

FORM 10-Q QUARTERLY REPORT

APRIL 30, 2019

INDEX

 

 

 

Page
No.

 

 

 

PART I.

FINANCIAL INFORMATION

3

 

 

 

Item 1.

Financial Statements

3

 

 

 

 

Condensed Consolidated Statements of Earnings for the Three Months Ended April 30, 2019 and 2018

3

 

 

 

 

Condensed Consolidated Balance Sheets as of April 30, 2019 and January 31, 2019

4

 

 

 

 

Condensed Consolidated Statements of Stockholders’ Equity for the Three Months Ended April 30, 2019 and 2018

5

 

 

 

 

Condensed Consolidated Statements of Cash Flows for the Three Months Ended April 30, 2019 and 2018

6

 

 

 

 

Notes to Condensed Consolidated Financial Statements

7

 

 

 

Item 2.

Management’s Discussion and Analysis of Financial Condition and Results of Operations

18

 

 

 

Item 3.

Quantitative and Qualitative Disclosures about Market Risk

26

 

 

 

Item 4.

Controls and Procedures

27

 

 

 

PART II.

OTHER INFORMATION

27

 

 

 

Item 1.

Legal Proceedings

27

 

 

 

Item 1A.

Risk Factors

27

 

 

 

Item 2.

Unregistered Sales of Equity Securities and Use of Proceeds

27

 

 

 

Item 3.

Defaults upon Senior Securities

27

 

 

 

Item 4.

Mine Safety Disclosures (not applicable to the Registrant)

27

 

 

 

Item 5.

Other Information

27

 

 

 

Item 6.

Exhibits

28

 

 

 

SIGNATURES

28

 

 

CERTIFICATIONS

 

 

2


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS

(In thousands, except per share data)

(Unaudited)

 

 

 

Three Months Ended
April 30,

 

 

 

2019

 

2018

 

REVENUES

 

$

49,544

 

$

141,366

 

Cost of revenues

 

70,570

 

125,914

 

GROSS (LOSS) PROFIT (Note 2)

 

(21,026

)

15,452

 

Selling, general and administrative expenses

 

9,588

 

9,637

 

Impairment loss (Note 5)

 

2,072

 

 

(LOSS) INCOME FROM OPERATIONS

 

(32,686

)

5,815

 

Other income, net

 

2,252

 

764

 

(LOSS) INCOME BEFORE INCOME TAXES

 

(30,434

)

6,579

 

Income tax benefit (expense)

 

521

 

(1,737

)

NET (LOSS) INCOME

 

(29,913

)

4,842

 

Net (loss) income attributable to non-controlling interests

 

(113

)

5

 

NET (LOSS) INCOME ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

 

(29,800

)

4,837

 

 

 

 

 

 

 

Foreign currency translation adjustments

 

(1,054

)

(579

)

COMPREHENSIVE (LOSS) INCOME ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

 

$

(30,854

)

$

4,258

 

 

 

 

 

 

 

(LOSS) EARNINGS PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. (Note 12)

 

 

 

 

 

Basic

 

$

(1.91

)

$

0.31

 

Diluted

 

$

(1.91

)

$

0.31

 

 

 

 

 

 

 

WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING

 

 

 

 

 

Basic

 

15,583

 

15,568

 

Diluted

 

15,583

 

15,656

 

 

 

 

 

 

 

CASH DIVIDENDS PER SHARE (Note 10)

 

$

0.25

 

$

0.25

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

3


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED BALANCE SHEETS

(Dollars in thousands, except per share data)

 

 

 

April 30, 2019

 

January 31, 2019

 

 

 

(Unaudited)

 

(Note 1)

 

ASSETS

 

 

 

 

 

 

 

 

 

 

 

CURRENT ASSETS

 

 

 

 

 

Cash and cash equivalents

 

$

132,388

 

$

164,318

 

Short-term investments

 

123,376

 

132,213

 

Accounts receivable, net

 

48,203

 

36,174

 

Contract assets

 

48,536

 

58,357

 

Other current assets

 

20,658

 

25,286

 

TOTAL CURRENT ASSETS

 

373,161

 

416,348

 

Property, plant and equipment, net

 

20,850

 

19,778

 

Goodwill

 

30,766

 

32,838

 

Other purchased intangible assets, net

 

5,838

 

6,137

 

Rights-of-use assets (Note 7)

 

1,186

 

 

Deferred taxes

 

998

 

1,257

 

Other assets

 

362

 

290

 

TOTAL ASSETS

 

$

433,161

 

$

476,648

 

 

 

 

 

 

 

LIABILITIES AND EQUITY

 

 

 

 

 

 

 

 

 

 

 

CURRENT LIABILITIES

 

 

 

 

 

Accounts payable

 

$

34,426

 

$

44,427

 

Accrued expenses (Notes 2, 7 and 11)

 

29,700

 

29,500

 

Contract liabilities

 

6,900

 

8,349

 

TOTAL CURRENT LIABILITIES

 

71,026

 

82,276

 

Lease liabilities (Note 7)

 

645

 

 

TOTAL LIABILITIES

 

71,671

 

82,276

 

 

 

 

 

 

 

COMMITMENTS AND CONTINGENCIES (Notes 7 and 8)

 

 

 

 

 

 

 

 

 

 

 

STOCKHOLDERS’ EQUITY

 

 

 

 

 

Preferred stock, par value $0.10 per share — 500,000 shares authorized; no shares issued and outstanding

 

 

 

Common stock, par value $0.15 per share — 30,000,000 shares authorized; 15,636,535 and 15,577,102 shares issued at April 30 and January 31, 2019, respectively; 15,633,302 and 15,573,869 shares outstanding at April 30 and January 31, 2019, respectively

 

2,346

 

2,337

 

Additional paid-in capital

 

146,932

 

144,961

 

Retained earnings

 

213,921

 

247,616

 

Accumulated other comprehensive loss

 

(1,400

)

(346

)

TOTAL STOCKHOLDERS’ EQUITY

 

361,799

 

394,568

 

Non-controlling interests

 

(309

)

(196

)

TOTAL EQUITY

 

361,490

 

394,372

 

TOTAL LIABILITIES AND EQUITY

 

$

433,161

 

$

476,648

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

4


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

FOR THE THREE MONTHS ENDED APRIL 30, 2019 AND 2018

(Dollars in thousands)

(Unaudited)

 

 

 

Common Stock

 

 

 

 

 

 

 

 

 

 

 

 

 

Outstanding
Shares

 

Par
Value

 

Additional
Paid-in
Capital

 

Retained
Earnings

 

Accumulated
Other Comprehensive
(Loss) Gain

 

Non-controlling
Interests

 

Total
Equity

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balances, February 1, 2018

 

15,567,719

 

$

2,336

 

$

143,215

 

$

211,112

 

$

1,422

 

$

43

 

$

358,128

 

Adoption of ASC Topic 606 (Note 2)

 

 

 

 

38

 

 

 

38

 

Net income

 

 

 

 

4,837

 

 

5

 

4,842

 

Foreign currency translation loss

 

 

 

 

 

(579

)

 

(579

)

Stock compensation expense

 

 

 

568

 

 

 

 

568

 

Cash dividends

 

 

 

 

(3,892

)

 

 

(3,892

)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balances, April 30, 2018

 

15,567,719

 

$

2,336

 

$

143,783

 

$

212,095

 

$

843

 

$

48

 

$

359,105

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balances, February 1, 2019

 

15,573,869

 

$

2,337

 

$

144,961

 

$

247,616

 

$

(346

)

$

(196

)

$

394,372

 

Net loss

 

 

 

 

(29,800

)

 

(113

)

(29,913

)

Foreign currency translation loss

 

 

 

 

 

(1,054

)

 

(1,054

)

Stock compensation expense

 

 

 

413

 

 

 

 

413

 

Exercise of stock options

 

59,433

 

9

 

1,558

 

 

 

 

1,567

 

Cash dividends

 

 

 

 

(3,895

)

 

 

(3,895

)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balances, April 30, 2019

 

15,633,302

 

$

2,346

 

$

146,932

 

$

213,921

 

$

(1,400

)

$

(309

)

$

361,490

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

5


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

(In thousands)

(Unaudited)

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

CASH FLOWS FROM OPERATING ACTIVITIES

 

 

 

 

 

Net (loss) income

 

$

(29,913

)

$

4,842

 

Adjustments to reconcile net (loss) income to net cash used in operating activities

 

 

 

 

 

Impairment loss

 

2,072

 

 

Depreciation

 

829

 

771

 

Stock compensation expense

 

413

 

568

 

Amortization of purchased intangible assets

 

299

 

253

 

Deferred income tax expense

 

259

 

162

 

Other

 

(129

)

(412

)

Changes in operating assets and liabilities

 

 

 

 

 

Accounts receivable

 

(12,049

)

(9,522

)

Contract assets

 

9,821

 

(36,732

)

Other assets

 

3,962

 

(2,970

)

Accounts payable and accrued expenses

 

(10,497

)

(745

)

Contract liabilities

 

(1,449

)

(17,150

)

Net cash used in operating activities

 

(36,382

)

(60,935

)

 

 

 

 

 

 

CASH FLOWS FROM INVESTING ACTIVITIES

 

 

 

 

 

Maturities of short-term investments

 

44,000

 

103,000

 

Purchases of short-term investments

 

(35,000

)

(5,000

)

Purchases of property, plant and equipment

 

(1,985

)

(3,691

)

Changes in notes receivable

 

 

225

 

Net cash provided by investing activities

 

7,015

 

94,534

 

 

 

 

 

 

 

CASH FLOWS FROM FINANCING ACTIVITIES

 

 

 

 

 

Cash dividends paid

 

(3,895

)

(3,892

)

Proceeds from the exercise of stock options

 

1,567

 

 

Net cash used in financing activities

 

(2,328

)

(3,892

)

 

 

 

 

 

 

EFFECTS OF EXCHANGE RATE CHANGES ON CASH

 

(235

)

(291

)

NET (DECREASE) INCREASE IN CASH AND CASH EQUIVALENTS

 

(31,930

)

29,416

 

CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD

 

164,318

 

122,107

 

CASH AND CASH EQUIVALENTS, END OF PERIOD

 

$

132,388

 

$

151,523

 

 

 

 

 

 

 

SUPPLEMENTAL CASH FLOW INFORMATION

 

 

 

 

 

Cash paid for income taxes

 

$

454

 

$

967

 

Cash received from income tax refunds

 

$

6,143

 

$

 

Operating lease payments made (Note 7)

 

$

141

 

 

 

Adoption of ASC Topic 842 (non-cash transaction, see Note 7)

 

$

1,341

 

$

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

6


Table of Contents

 

ARGAN, INC. AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

APRIL 30, 2019

(Tabular dollar amounts in thousands, except per share data)

(Unaudited)

 

NOTE 1 — DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

 

Description of the Business

 

Argan, Inc. (“Argan”) conducts operations through its wholly owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”); and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

 

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and consulting services to the power generation and renewable energy markets. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms. Including consolidated joint ventures and variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southern United States and that are based on its expertise in producing, delivering and installing fabricated steel components such as piping systems, pressure vessels and heat exchangers. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the United States.

 

Basis of Presentation

 

The condensed consolidated financial statements include the accounts of Argan, its wholly owned subsidiaries and any variable interest entities for which the Company is deemed to be the primary beneficiary. All significant inter-company balances and transactions have been eliminated in consolidation. In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. In Note 13, the Company has provided certain financial information related to concentrations of businesses and customers. The Company’s fiscal year ends on January 31 of each year.

 

These condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) and pursuant to the rules and regulations of the Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with U.S. GAAP have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2019.

 

The condensed consolidated balance sheet as of April 30, 2019, the condensed consolidated statements of earnings for the three months ended April 30, 2019 and 2018, and the condensed consolidated statements of cash flows for the three months ended April 30, 2019 and 2018 are unaudited. The condensed consolidated balance sheet as of January 31, 2019 has been derived from audited financial statements. In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of April 30, 2019, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

 

7


Table of Contents

 

Accounting Policies

 

Effective February 1, 2019, the Company adopted Accounting Standards Update (“ASU”) 2016-02, “Leases,” as amended, which herein is referred to as “ASC Topic 842.” Accordingly, operating leases with lease terms of more than twelve months have been presented in the condensed consolidated balance sheet as of April 30, 2019 by adding assets for the rights and liabilities for the obligations that are created by these leases (see Note 7). The Company elected to apply the transition requirements at the adoption date rather than at the beginning of the earliest comparative period presented herein. There was no cumulative effect adjustment that had to be made to retained earnings at the adoption date, and prior year consolidated financial statements were not restated. The new accounting for leases did not have a material effect on the Company’s operating results for the three months ended April 30, 2019.

 

Effective February 1, 2018, the Company adopted ASU 2014-09, “Revenue from Contracts with Customers,” as amended, which herein is referred to as “ASC Topic 606”, using the permitted modified retrospective method. Accordingly, the new guidance was applied retrospectively to contracts that were not completed as of the adoption date. Financial results for the reporting periods which are included herein have been presented in accordance with the new guidance of ASC Topic 606 (see Note 2). The effect of the adoption on retained earnings as of February 1, 2018 was an income tax-effected increase of less than $0.1 million. The differences between the Company’s reported operating results for the three months ended April 30, 2019 and 2018, which reflect the application of the new standard on the Company’s contracts, and the results that would have been reported if the accounting was performed pursuant to the accounting standards previously in effect, were not material.

 

In 2016, the Financial Accounting Standards Board (the “FASB”) issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments. The scope of this new standard covers, among other provisions, the methods that businesses shall use to estimate amounts of uncollectible accounts receivable. As subsequently amended, the Company does not expect that the requirements of this new guidance, which becomes effective for the Company on February 1, 2020, will materially affect our consolidated financial statements. There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its consolidated financial statements.

 

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

 

Variable Interest Entity

 

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities for the construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three-month periods ended April 30, 2019 and 2018. The total amounts of project development costs included in the balances for property, plant and equipment as of April 30 and January 31, 2019 were $3.2 and $2.1 million, respectively. At April 30 and January 31, 2019, the total amounts of notes receivable from the VIE and related accrued interest, which amounts are eliminated in consolidation, were $3.4 million and $2.1 million, respectively.

 

NOTE 2 — REVENUES FROM CONTRACT WITH CUSTOMERS

 

The new standard outlines a single comprehensive model for entities to use in accounting for revenues arising from contracts with customers. Central to the new revenue recognition framework is a five-step revenue recognition model that requires reporting entities to:

 

1.        Identify the contract,

2.   Identify the performance obligations of the contract,

3.   Determine the transaction price of the contract,

4.   Allocate the transaction price to the performance obligations, and

5.   Recognize revenue.

 

The Company focuses on the transfer of the contractor’s control of the goods and/or services to the customer, as opposed to the transfer of risk and rewards. Major provisions of the new standard cover the determination of which goods and services are distinct and represent separate performance obligations, the appropriate treatments for variable consideration, and the

 

8


Table of Contents

 

evaluation of whether revenues should be recognized at a point in time or over time. Where a performance obligation is satisfied over time, the related revenues are also recognized over time. Most of the Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed price or a time and materials basis, and primarily over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer. Revenues from fixed price contracts, including a portion of estimated profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the percentage-of-completion method. If at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period that it is identified and an amount is estimable. Revenues from time and materials contracts are recognized when the related services are provided to the customer.

 

Most of the Company’s long-term contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of our contracts because our contract promises are interrelated or they require the Company to perform critical integration so that the customer receives a completed project. Warranties provided under the Company’s contracts with customers are assurance-type and do not represent separate performance obligations.

 

The transaction price for a contract represents the value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration, which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as variations in the scope and price of contracts, claims, incentives and liquidated damages.

 

Contract assets are defined in the new standard to include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities are defined in the new standard to include the amounts that reflect obligations to provide goods or services for which payment has been received. In addition, the definition of accounts receivable has been restated to effectively exclude billed amounts retained by project owners until a defined phase of a contract or project has been completed and accepted. Retentions were historically included in accounts receivable, but are now reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retainage amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at April 30 and January 31, 2019 were $15.9 million and $15.3 million, respectively.

 

Variable Consideration

 

Contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price and are reflected in revenues when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The aggregate amount of such contract variations included in the transaction prices that were used to determine project-to-date revenues at April 30 and January 31, 2019, were $21.7 million and $18.8 million, respectively. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. Variations related to the Company’s contracts typically represent modifications to the existing contracts and performance obligations, and do not represent new performance obligations. Actual costs related to any changes in the scope of the corresponding contract are expensed as they are incurred. Changes to total estimated contract costs and losses, if any, are reflected in operating results for the period in which they are determined.

 

The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. These contract requirements generally relate to specified activities that must be completed by an established date or by the achievement of a specified level of output or efficiency. Each applicable contract defines the conditions under which a project owner may be entitled to liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not constrained, or subtracted, from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract. The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved.

 

9


Table of Contents

 

The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects. In other cases, the Company may have the grounds to assert liquidated damages against subcontractors, suppliers, project owners or other parties related to a project. Such circumstances may arise when the Company’s activities and progress are adversely affected by delayed or damaged materials, challenges with equipment performance or other events out of the Company’s control where the Company has rights to recourse, typically in the form of liquidated damages. In general, the Company does not adjust the corresponding contract accounting until it is probable that the favorable cost relief will be realized. Such adjustments have been and could be material.

 

The Company records adjustments in revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.

 

In its Form 10-K Annual Report for the year ended January 31, 2019, the Company disclosed that APC is completing a power-plant construction project in the United Kingdom that has encountered significant operational and contractual challenges, and that the consolidated operating results for the year ended January 31, 2019 reflected unfavorable gross profit adjustments related to this project. The disclosure explained that the project progress was behind the schedule originally established for the job and warned that the project may continue to impact consolidated operating results negatively until it reaches completion.

 

Subsequent to the release of the Company’s consolidated financial statements for the fiscal year ended January 31, 2019, APC’s estimates of the unfavorable financial impacts of the difficulties on this particular project, including work stoppages due to labor strikes, escalated substantially. APC conducted a comprehensive review of the remaining contract work, prepared a new timeline for the completion of the project and assessed other factors. With the completion of its analysis, management concluded that the costs for APC to complete the work that remains for the project will exceed projected revenues by approximately $27.6 million.

 

The total amount of the expected loss on this project has been reflected in the condensed consolidated financial statements for the three months ended April 30, 2019, including a provision for contract loss in the amount of $9.8 million that was recorded as an addition to the cost of revenues for the quarter. The amount of the loss provision has been included in accrued expenses as of April 30, 2019. For the three months ended April 30, 2019, the reversal of revenues recorded in prior periods related to the changes that the Company made to transaction prices and to estimates of the costs-to-complete active contracts, including those changes related to the loss contract of APC, was a net amount of approximately $1.4 million.

 

Remaining Unsatisfied Performance Obligations (“RUPO”)

 

The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under ASC Topic 606. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations. At April 30, 2019, the Company had RUPO of $97.9 million, most of which is expected to be recognized as revenues during the year ending January 31, 2020. Although the amount of reported RUPO represents business that is considered to be firm, it is important to note that cancellations, deferrals or scope adjustments may occur. RUPO may be adjusted to reflect any known project cancellations, revisions to project scope and cost, foreign currency exchange fluctuations and project deferrals, as applicable.

 

Disaggregation of Revenues

 

The consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements. The amounts of revenues earned under fixed-price contracts during the three-month periods ended April 30, 2019 and 2018, were approximately 76% and 92%, respectively, of the corresponding consolidated revenues for the periods.

 

10


Table of Contents

 

The following table presents consolidated revenues for the three months ended April 30, 2019 and 2018, disaggregated by the geographic area where the work was performed:

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

United States

 

$

39,766

 

$

124,154

 

United Kingdom

 

5,664

 

14,468

 

Republic of Ireland

 

4,003

 

2,744

 

Other

 

111

 

 

 

 

 

 

 

 

Consolidated Revenues

 

$

49,544

 

$

141,366

 

 

NOTE 3 — CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

 

At April 30 and January 31, 2019, a significant amount of cash and cash equivalents was invested in a money market fund with net assets invested in high-quality money market instruments. Such investments include U.S. Treasury obligations; obligations of U.S. Government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by U.S. Government obligations. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

 

Short-term investments as of April 30 and January 31, 2019 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of 250 days (the “CDs”) at both dates. The Company has the intent and ability to hold the CDs until they mature, and they are carried at cost plus accrued interest which approximates fair value. The total carrying value amounts as of April 30 and January 31, 2019 included accrued interest of $1.4 million and $1.2 million, respectively. Interest income is recorded when earned and is included in other income. At April 30 and January 31, 2019, the weighted average annual interest rates of the CDs were 2.7% and 2.6%, respectively. In addition, the Company has cash on deposit in excess of federally insured limits at the Bank. Management does not believe that maintaining substantially all such assets with the Bank represents a material risk.

 

NOTE 4 — ACCOUNTS AND NOTES RECEIVABLE

 

At April 30 and January 31, 2019, there were outstanding invoices, with balances included in accounts receivable and contract assets in the aggregate amount of $19.6 million and $17.1 million, respectively, for which the collection time may be extended and depend on the resolution of the outstanding legal dispute between the parties (see Note 8). At both April 30 and January 31, 2019, Company’s allowance for uncollectible accounts was insignificant. The amounts of the provision for uncollectible accounts and notes receivable for the three months ended April 30, 2019 and 2018 were also not significant.

 

NOTE 5 — PURCHASED INTANGIBLE ASSETS

 

Primarily due to the significant reduction of the fair value of the business of APC deemed to have occurred in connection with the substantial contract loss identified during the three-month period ended April 30, 2019, the Company recorded an impairment loss in the amount of $2.1 million for the amount of goodwill included in the condensed consolidated balance sheet as of January 31, 2019 associated with APC. At both April 30 and January 31, 2019, the goodwill balances related to the acquisitions of GPS and TRC were $18.5 million and $12.3 million, respectively. The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of April 30 and January 31, 2019:

 

 

 

 

 

April 30, 2019

 

January 31,

 

 

 

Estimated
Useful Life

 

Gross
Amount

 

Accumulated
Amortization

 

Net
Amount

 

2019 (net
amount)

 

Trade names

 

15 years

 

$

8,323

 

$

4,080

 

$

4,243

 

$

4,424

 

Process certifications

 

7 years

 

1,897

 

926

 

971

 

1,039

 

Customer relationships

 

4-10 years

 

1,346

 

722

 

624

 

674

 

Totals

 

 

 

$

11,566

 

$

5,728

 

$

5,838

 

$

6,137

 

 

11


Table of Contents

 

NOTE 6 — FINANCING ARRANGEMENTS

 

The Company maintains financing arrangements with the Bank that are described in an Amended and Restated Replacement Credit Agreement (the “Credit Agreement”), dated May 15, 2017. The Credit Agreement provides a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2021 with interest at the 30-day LIBOR plus 2.0%. The Company may also use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business. At April 30 and January 31, 2019, the Company had credit outstanding under the Credit Agreement, but no borrowings, in the approximate amounts of $15.5 million and $15.2 million, respectively. The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement includes other terms, covenants and events of default that are customary for a credit facility of its size and nature. As of April 30 and January 31, 2019, the Company was compliant with the financial covenants of the Credit Agreement.

 

NOTE 7 — LEASES

 

Management determines if a contract is or contains a lease at inception or modification of the contract. A contract is or contains a lease if the contract conveys the right to control the use of an identified asset for a period in exchange for consideration. Control over the use of the identified asset means the lessee has both (a) the right to obtain substantially all of the economic benefits from the use of the asset and (b) the right to direct the use of the asset. The Company has made the election, as permitted by the new standard, not to apply the new accounting to those leases with terms of twelve (12) months or less and that do not include options to purchase the underlying assets that the Company is reasonably certain to exercise. In addition, the Company has chosen not to separate non-lease components from their related lease components. Finally, the Company elected to utilize the package of permitted practical expedients that, upon adoption of ASC Topic 842, allows entities to not reassess whether any existing contracts are or contain leases.

 

The Company has operating leases primarily for office space that expire on various dates through May 2024; it has no finance leases. Certain leases contain renewal options. Renewal periods are included in the expected lease term if they are reasonably certain of being exercised by the Company. None of the Company’s operating leases include significant amounts for incentives, rent holidays, penalties, or price escalations. Under certain lease agreements, the Company is obligated to pay property taxes, insurance, and maintenance costs.

 

Operating lease right-of-use assets and associated lease liabilities are recognized in the balance sheet at the lease commencement date based on the present value of future minimum lease payments over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate based on the information available at commencement date in determining the present value of future payments. The expected lease term includes options to extend or terminate the lease when it is reasonably certain the Company will exercise such option. Lease expense for minimum lease payments is recognized on a straight-line basis over the expected lease term. Operating lease expense for the three months ended April 30, 2019 was $0.2 million. For operating leases as of April 30, 2019, the weighted average lease term was 42 months and the weighted average discount rate was 4.5%.

 

The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of April 30, 2019:

 

Year ending January 31,

 

Remainder of 2020

 

$

467

 

2021

 

283

 

2022

 

210

 

2023

 

185

 

2024

 

121

 

Thereafter

 

22

 

Total lease payments

 

1,288

 

Less interest portion

 

94

 

Present value of lease payments

 

1,194

 

Less current portion (included in accrued expenses)

 

549

 

Non-current portion

 

$

645

 

 

12


Table of Contents

 

The Company also uses equipment and occupies other facilities under cancelable or short-term rental agreements. Rent expense related to all lease and rental arrangements incurred on construction projects and included in the costs of revenues for the three months ended April 30, 2018 was approximately $4.8 million. Rent expense for such arrangements included in selling, general and administrative expenses for the three-month period ended April 30, 2018 was $0.2 million. Rent expense amounts incurred under operating leases and short-term rental agreements (including the lease expense amount disclosed above) and included in costs of revenues and in selling, general and administrative expenses for the three months ended April 30, 2019 were $1.0 million and $0.2 million, respectively.

 

NOTE 8 — LEGAL MATTERS

 

In the normal course of business, the Company may have pending claims and legal proceedings. It is the opinion of management, based on information available at this time, that there are no current claims and proceedings that could have a material adverse effect on the Company’s condensed consolidated financial statements except for the matter described below.

 

In January 2019, GPS filed a lawsuit against Exelon West Medway II, LLC and Exelon Generation Company, LLC (together referred to as “Exelon”) for Exelon’s breach of contract and failure to remedy various conditions which negatively impacted the schedule and the costs associated with the construction by GPS of a gas-fired power plant for Exelon in Massachusetts. On March 7, 2019, Exelon provided GPS with a notice intending to terminate the EPC contract under which GPS had been providing services to Exelon. At that time, the construction project was nearly complete and both of the power generation units included in the plant had successfully reached first fire. The completion of various prescribed performance tests and the clearance of punch-list items were the primary tasks necessary to be accomplished by GPS in order to achieve substantial completion of the power plant.

 

Nevertheless, and among other actions, Exelon provided contractual notice requiring GPS to vacate the construction site, made claims against GPS and has withheld payments from GPS on invoices rendered to Exelon in accordance with the terms of the EPC contract between the parties. In summary, the Company’s position is that Exelon has received the benefits of the construction without making payments to GPS for the value received. With vigor, GPS intends to assert its rights under the EPC contract, to pursue the collection from Exelon of amounts owed under the contract and to defend itself against the allegations that GPS has not performed in accordance with the contract.

 

NOTE 9 — STOCK-BASED COMPENSATION

 

The Company’s board of directors may make awards under the 2011 Stock Plan (the “Stock Plan”) to officers, directors and key employees. Awards may include incentive stock options (“ISOs”), nonqualified stock options (“NSOs”), and restricted or unrestricted stock. All stock options awarded under the Stock Plan shall have an exercise price per share at least equal to the common stock’s market value per share at the date of grant. ISOs shall have a term no longer than ten years; NSOs may have up to a ten-year term. In the past, stock options typically became exercisable one year from the date of award. Commencing in January 2018, stock options were awarded with three-year vesting schedules. As of April 30, 2019, there were approximately 1.7 million shares of the Company’s common stock reserved for issuance under the Company’s stock plans. This number includes 496,000 shares of the Company’s common stock available for future awards.

 

Summaries of stock option activity under the Company’s stock option plans for the three months ended April 30, 2019 and 2018, along with corresponding weighted average per share amounts, are presented below (shares in thousands):

 

 

 

Shares

 

Exercise
Price

 

Remaining
Term (years)

 

Fair Value

 

Outstanding, February 1, 2019

 

1,140

 

$

44.01

 

7.54

 

$

11.22

 

Granted

 

92

 

$

50.30

 

 

 

 

 

Exercised

 

(59

)

$

26.36

 

 

 

 

 

Forfeited

 

(14

)

$

51.13

 

 

 

 

 

Outstanding, April 30, 2019

 

1,159

 

$

45.34

 

7.64

 

$

11.42

 

Exercisable, April 30, 2019

 

729

 

$

45.90

 

6.67

 

$

11.97

 

 

13


Table of Contents

 

 

 

Shares

 

Exercise
Price

 

Remaining
Term (years)

 

Fair Value

 

Outstanding, February 1, 2018

 

889

 

$

44.83

 

7.91

 

$

11.74

 

Granted

 

97

 

$

37.60

 

 

 

 

 

Outstanding, April 30, 2018

 

986

 

$

44.12

 

7.90

 

$

11.44

 

Exercisable, April 30, 2018

 

692

 

$

44.01

 

7.11

 

$

11.65

 

 

The changes in the number of non-vested options to purchase shares of common stock for the three months ended April 30, 2019 and 2018, and the weighted average fair value per share for each number, are presented below (shares in thousands):

 

 

 

Shares

 

Fair Value

 

Non-vested, February 1, 2019

 

375

 

$

10.05

 

Granted

 

92

 

$

11.68

 

Vested

 

(33

)

$

8.74

 

Forfeited

 

(4

)

$

11.68

 

Non-vested, April 30, 2019

 

430

 

$

10.48

 

 

 

 

Shares

 

Fair Value

 

Non-vested, February 1, 2018

 

302

 

$

13.55

 

Granted

 

97

 

$

8.74

 

Vested

 

(105

)

$

16.37

 

Non-vested, April 30, 2018

 

294

 

$

10.95

 

 

In April 2019 and 2018, and pursuant to terms of the Stock Plan, the Company awarded performance-based restricted stock units to two senior executives covering up to 36,000 shares of common stock at each date plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards. The release of the stock restrictions depends on the total shareholder return performance of the Company’s common stock measured against the performance of a peer-group of common stocks over three-year periods.

 

The Company estimates the weighted average fair value of stock options on the date of award using the Black-Scholes pricing model, which was developed for use in estimating the fair value of traded options that have no vesting restrictions and are fully transferable. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. The fair values of stock options granted during the periods presented herein were estimated on the corresponding dates of award based on the following weighted average assumptions:

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

Dividend yield

 

2.0

%

2.7

%

Expected volatility

 

34.0

%

36.0

%

Risk-free interest rate

 

2.4

%

2.0

%

Expected life (in years)

 

3.3

 

3.3

 

 

The award-date fair value amounts for restricted stock units are determined by using the per share market price of a share of the Company’s common stock on the corresponding dates of award and the target number of shares for the award, by assigning equal probabilities to the thirteen possible payout outcomes at the ends of the three-year vesting periods, and by computing the weighted average of the outcome amounts. For each case, the estimated fair value amount was calculated to be 88.5% of the aggregate market value of the target number of shares on the award date.

 

The fair values of stock options and restricted stock units are recorded as stock compensation expense over the vesting periods of the corresponding awards. Expense amounts related to stock awards were $0.4 million and $0.6 million for the three months ended April 30, 2019 and 2018, respectively. At April 30, 2019, there was $5.2 million in unrecognized compensation cost related to outstanding stock awards that the Company expects to expense over the next three years.

 

14


Table of Contents

 

The total intrinsic value of the stock options exercised during the three months ended April 30, 2019 was $1.4 million. There were no stock options exercises during the three months ended April 30, 2018. At April 30, 2019, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $8.7 million and $7.0 million, respectively.

 

NOTE 10 — CASH DIVIDENDS

 

The Company’s board of directors declared a regular quarterly cash dividend of $0.25 per share of common stock on April 9, 2019, which was paid on April 30, 2019 to stockholders of record on April 22, 2019. The board declared the Company’s first regular quarterly cash dividend of $0.25 per share of common stock on April 10, 2018, which was paid on April 30, 2018.

 

NOTE 11 — INCOME TAXES

 

Income Tax Expense Reconciliation

 

The Company’s income tax amounts for the three months ended April 30, 2019 and 2018 differed from corresponding amounts computed by applying the new federal corporate income tax rate of 21% to loss or income before income taxes for the periods as shown in the table below.

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

Computed expected income tax benefit (expense)

 

$

6,391

 

$

(1,382

)

Differences resulting from:

 

 

 

 

 

Foreign tax rate differential

 

(754

)

13

 

State income taxes, net of federal tax effect

 

78

 

(158

)

Stock options

 

205

 

 

Net operating loss deemed unrealizable

 

(5,316

)

 

Adjustments and other permanent differences

 

(83

)

(210

)

Income tax benefit (expense)

 

$

521

 

$

(1,737

)

 

Foreign income tax expense amounts for the three months ended April 30, 2019 and 2018 were not material. A valuation allowance in the amount of $5.3 million was established against the deferred tax asset amount created by the net operation loss of APC’s subsidiary in the United Kingdom for the three months ended April 30, 2019.

 

Research and Development Tax Credits

 

During the year ended January 31, 2019, the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development credits that may be available to reduce prior year income taxes. This study focused on project costs incurred during the three-year period ended January 31, 2018. Based on the results of the study, management identified and estimated significant amounts of income tax benefits that were not previously recognized in the Company’s operating results for any prior year reporting period. The amount of research and development tax credit benefit recognized in the consolidated financial statements, which was recorded in the third quarter last year, was $16.6 million.

 

As described below, the Internal Revenue Service (the “IRS”) intends to review the research and development credits that were included in the amendments of the Company’s consolidated federal income tax return for the years ended January 31, 2016 and 2017 that were filed in January 2019. The Company does not anticipate any significant unfavorable changes to its income taxes to arise from the completion of these examinations.

 

The amount of identified but unrecognized income tax benefits related to research and development credits as of April 30, 2019 was $5.2 million, for which the Company has established a liability for uncertain income tax return positions that is included in accrued expenses. The amount of the liability was $5.1 million as of January 31, 2019. The final outcome of these uncertain tax positions is not yet determinable. However, the Company does not expect that the amount of unrecognized tax benefits will significantly change due to any settlement and/or expiration of statutes of limitation over the next 12 months. As of April 30, 2019, the Company does not believe that it has any other material uncertain income tax positions reflected in its accounts.

 

15


Table of Contents

 

Income Tax Returns

 

The Company is subject to income taxes in the United States, the Republic of Ireland, the United Kingdom and various other state and foreign jurisdictions. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2015 except for several notable exceptions including the Republic of Ireland, the United Kingdom and several states where the open periods are one year longer. The IRS conducted an examination of the Company’s original federal consolidated income tax return for the year ended January 31, 2016. The IRS represented to the Company that no unfavorable adjustment items were noted during the examination. However, with the filing of the amended tax return for the year ended January 31, 2016, the audit timeline has been extended which will enable the IRS to examine the amendment to the income tax return, which includes the research and development credit for the year. In addition, the IRS has notified the Company of its plan to examine the Company’s consolidated income tax return for the year ended January 31, 2017.

 

At April 30 and January 31, 2019, the amounts of other current assets presented in the condensed consolidated balance sheets included income tax refunds and prepaid income taxes in the combined amounts of $15.3 million and $19.5 million, respectively. The income tax refunds are amounts expected to be received from taxing authorities based on amended tax returns claiming research and development tax credits in prior years.

 

NOTE 12 — (LOSS) EARNINGS PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

 

Basic and diluted (loss) earnings per share are computed as follows (shares in thousands except in the footnote below):

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

Net (loss) income attributable to the stockholders of Argan, Inc.

 

$

(29,800

)

$

4,837

 

 

 

 

 

 

 

Weighted average number of shares outstanding - basic

 

15,583

 

15,568

 

Effects of stock awards (1)

 

 

88

 

Weighted average number of shares outstanding - diluted

 

15,583

 

15,656

 

Net (loss) income per share attributable to the stockholders of Argan, Inc.

 

 

 

 

 

Basic

 

$

(1.91

)

$

0.31

 

Diluted

 

$

(1.91

)

$

0.31

 

 


(1)   For the three months ended April 30, 2019, all common stock equivalents are considered to be antidilutive as the Company incurred a net loss for the period. The number for the three months ended April 30, 2018 excludes the effect of antidilutive stock options which covered 487,000 shares, which had exercise prices per share in excess of the average market price per share for the period.

 

NOTE 13 — CUSTOMER CONCENTRATIONS

 

Historically, the majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided 87% of consolidated revenues for the three months ended April 30, 2018. For the three months ended April 30, 2019, this reporting segment represented 41% of consolidated revenues. The industrial services reporting segment represented 55% and 12% of consolidated revenues for the three-month periods ended April 30, 2019 and 2018, respectively.

 

The Company’s most significant customer relationships for the three months ended April 30, 2019 included two power industry service customers which accounted for approximately 17% and 14% of consolidated revenues, respectively. The Company’s most significant customer relationships for the three months ended April 30, 2018 included four power industry service customers which accounted for approximately 22%, 19%, 12% and 12% of consolidated revenues, respectively.

 

The accounts receivable balance from two customers represented 15% and 12% of the corresponding consolidated balance as of April 30, 2019. Accounts receivable balances from two customers represented 25% and 15% of the corresponding consolidated balance as of January 31, 2019.

 

16


Table of Contents

 

NOTE 14 — SEGMENT REPORTING

 

Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than one operating segment.

 

Intersegment revenues and the related cost of revenues are netted against the corresponding amounts of the segment receiving the intersegment services. For the three months ended April 30, 2019, intersegment revenues totaled approximately $0.5 million. For the three months ended April 30, 2018, intersegment revenues were not significant.

 

Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three months ended April 30, 2019 and 2018. The “Other” column in each summary includes the Company’s corporate expenses:

 

Three Months Ended
April 30, 2019

 

Power
Services

 

Industrial
Services

 

Telecom
Services

 

Other

 

Totals

 

Revenues

 

$

20,203

 

$

27,069

 

$

2,272

 

$

 

$

49,544

 

Cost of revenues

 

44,526

 

24,271

 

1,773

 

 

70,570

 

Gross (loss) profit

 

(24,323

)

2,798

 

499

 

 

(21,026

)

Selling, general and administrative expenses

 

5,646

 

1,861

 

511

 

1,570

 

9,588

 

Impairment loss

 

2,072

 

 

 

 

2,072

 

(Loss) income from operations

 

(32,041

)

937

 

(12

)

(1,570

)

(32,686

)

Other income, net

 

2,100

 

 

 

152

 

2,252

 

(Loss) income loss before income taxes

 

$

(29,941

)

$

937

 

$

(12

)

$

(1,418

)

(30,434

)

Income tax benefit

 

 

 

 

 

 

 

 

 

521

 

Net loss

 

 

 

 

 

 

 

 

 

$

(29,913

)

 

 

 

 

 

 

 

 

 

 

 

 

Amortization of purchased intangible assets

 

$

87

 

$

166

 

$

46

 

$

 

$

299

 

Depreciation

 

168

 

560

 

100

 

1

 

829

 

Property, plant and equipment additions

 

1,062

 

815

 

97

 

11

 

1,985

 

 

 

 

 

 

 

 

 

 

 

 

 

Current assets

 

$

281,759

 

$

33,315

 

$

2,893

 

$

55,194

 

$

373,161

 

Current liabilities

 

52,829

 

16,909

 

619

 

669

 

71,026

 

Goodwill

 

18,476

 

12,290

 

 

 

30,766

 

Total assets

 

310,354

 

61,893

 

4,569

 

56,345

 

433,161

 

 

Three Months Ended
April 30, 2018

 

Power
Services

 

Industrial
Services

 

Telecom
Services

 

Other

 

Totals

 

Revenues

 

$

122,487

 

$

16,449

 

$

2,430

 

$

 

$

141,366

 

Cost of revenues

 

108,296

 

15,649

 

1,969

 

 

125,914

 

Gross profit

 

14,191

 

800

 

461

 

 

15,452

 

Selling, general and administrative expenses

 

5,232

 

1,835

 

462

 

2,108

 

9,637

 

Income (loss) from operations

 

8,959

 

(1,035

)

(1

)

(2,108

)

5,815

 

Other income, net

 

675

 

 

 

89

 

764

 

Income (loss) before income taxes

 

$

9,634

 

$

(1,035

)

$

(1

)

$

(2,019

)

6,579

 

Income tax expense

 

 

 

 

 

 

 

 

 

1,737

 

Net income

 

 

 

 

 

 

 

 

 

$

4,842

 

 

17


Table of Contents

 

Three Months Ended

 

Power

 

Industrial

 

Telecom

 

 

 

 

 

April 30, 2018

 

Services

 

Services

 

Services

 

Other

 

Totals

 

Amortization of purchased intangible assets

 

$

87

 

$

166

 

$

 

$

 

$

253

 

Depreciation

 

176

 

513

 

79

 

3

 

771

 

Property, plant and equipment additions

 

826

 

2,564

 

300

 

1

 

3,691

 

 

 

 

 

 

 

 

 

 

 

 

 

Current assets

 

$

365,569

 

$

23,598

 

$

3,380

 

$

73,085

 

$

465,632

 

Current liabilities

 

147,694

 

15,989

 

1,115

 

515

 

165,313

 

Goodwill

 

20,548

 

13,781

 

 

 

34,329

 

Total assets

 

393,932

 

53,698

 

4,862

 

73,386

 

525,878

 

 

ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

 

The following discussion summarizes the financial position of Argan, Inc. and its subsidiaries as of April 30, 2019, and the results of their operations for the three months ended April 30, 2019 and 2018, and should be read in conjunction with (i) the unaudited condensed consolidated financial statements and notes thereto included elsewhere in this Quarterly Report on Form 10-Q and (ii) the consolidated financial statements and accompanying notes included in our Annual Report on Form 10-K for the fiscal year ended January 31, 2019 that was filed with the SEC on April 10, 2019 (the “Annual Report”).

 

Cautionary Statement Regarding Forward Looking Statements

 

The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for certain forward-looking statements. We have made statements in this Item 2 and elsewhere in this Quarterly Report on Form 10-Q that may constitute “forward-looking statements.” The words “believe,” “expect,” “anticipate,” “plan,” “intend,” “foresee,” “should,” “would,” “could,” or other similar expressions are intended to identify forward-looking statements. These forward-looking statements are based on our current expectations and beliefs concerning future developments and their potential effects on us. There can be no assurance that future developments affecting us will be those that we anticipate. All comments concerning our expectations for future revenues and operating results are based on our forecasts for our existing operations and do not include the potential impact of any future acquisitions. Our forward-looking statements, by their nature, involve significant risks and uncertainties (some of which are beyond our control) and assumptions. They are subject to change based upon various factors including, but not limited to, the risks and uncertainties described in this Quarterly Report on Form 10-Q and our Annual Report. Should one or more of these risks or uncertainties materialize, or should any of our assumptions prove incorrect, actual results may vary in material respects from those projected in the forward-looking statements. We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise.

 

Business Description

 

Argan, Inc. is a holding company that conducts operations through its wholly-owned subsidiaries, GPS, APC, SMC and TRC. Through GPS and APC, we provide a full range of engineering, procurement, construction, commissioning, operations management, maintenance, development, technical and consulting services to the power generation and renewable energy markets for a wide range of customers including independent power project owners, public utilities, power plant equipment suppliers and global energy plant construction firms. GPS, including any consolidated joint ventures and VIEs, and APC represent our power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southern region of the United States and that are based on its expertise in producing, delivering and installing fabricated steel components such as pressure vessels, heat exchangers and piping systems. Through SMC, now conducting business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the United States. At the holding company level, we may make additional acquisitions of and/or investments in companies with potential for profitable growth. We may have more than one industrial focus. We expect that acquired companies will be held in separate subsidiaries that will be operated in a manner that best provides cash flows and value for our stockholders.

 

18


Table of Contents

 

Overview

 

In our Annual Report, we disclosed that APC has encountered significant operational and contractual challenges in completing a power-plant construction project in the United Kingdom, and that the consolidated operating results for the year ended January 31, 2019 reflected unfavorable gross profit adjustments related to this project, the Tees Renewable Energy Plant (“TeesREP”), which is a biomass-fired power plant under construction in Teesside. The disclosure explained that the project progress was behind the schedule originally established for the job and warned that the project may continue to impact the Company’s consolidated operating results negatively until it reaches completion.

 

Subsequent to the filing of our Annual Report, APC’s estimates of the unfavorable financial impacts of the unique and numerous difficulties on this project, including work stoppages due to labor strikes, escalated substantially. APC conducted a comprehensive review of the remaining contract work, prepared a new timeline for the completion of the project and assessed other factors. We currently estimate that the costs for APC to complete the work that remains for TeesREP will exceed projected revenues by $27.6 million. The amount of this loss was recognized in our operating results for the three-month period ended April 30, 2019. APC continues to investigate and consider courses of action, operationally and legally, that may provide mitigation to this loss. Reflecting the accounting for this loss, the combined amount of accounts receivable (which are current) and contract assets included in the condensed consolidated balance sheet as of April 30, 2019, less a provision for contract loss, was $10.1 million.

 

Nonetheless, we did have notable favorable accomplishments and other events related to the three-month period ended April 30, 2019 including the following:

 

·                        The addition of a new project after quarter-end boosted our project backlog amount to over $1.4 billion.

 

·                        TRC reported improvements in gross margins for the first quarter.

 

·                        We paid a regular quarterly cash dividend of $0.25 per share of common stock to our stockholders.

 

Our consolidated revenues for the three months ended April 30, 2019 were $49.5 million which represented a decline of $91.9 million from $141.4 million for the three months ended April 30, 2018. As GPS prepares to proceed fully with its new projects, its revenues remain at a low level. The revenues of its power industry services segment represented only 40.1% of consolidated revenues for the three months ended April 30, 2019. For the comparable period a year ago, the percentage share was 86.6%. The majority of consolidated revenues were contributed by the industrial services business of TRC which continued its strong top-line performance by reporting revenues of $27.1 million for the current quarter. This performance represented 54.6% of consolidated revenues for the current period and an increase of 64.6% from revenues of $16.4 million reported for the first quarter last year.

 

However, the significant loss incurred by APC caused a consolidated gross loss for the current quarter of $21.0 million. With the additional loss of $2.1 million recorded during current quarter which recognized the impairment of the goodwill of APC, we incurred a consolidated loss before income tax benefit of $30.4 million for the three months ended April 30, 2019. We did not record any income tax benefit for the operating loss of APC’s subsidiary in the United Kingdom for the current quarter. As a result, we have reported a net loss attributable to the stockholders of Argan in the amount of $29.8 million for the three months ended April 30, 2019, or $1.91 loss per share on a diluted basis. For the comparable period last year, we reported net income attributable to our stockholders in the amount of $4.8 million, or $0.31 earnings per share on a diluted basis.

 

As it takes time for us to ramp-up meaningful revenues associated with new construction projects due to the project life-cycles of gas-fired power plants, we expect current year results to improve slowly over the next few quarters with meaningful contributions from fully proceeding on new projects not occurring until the fourth quarter of the current year. We are optimistic that we will see a resumption of year-to-year growth as these new projects mature. New project opportunities still exist and negotiations continue with project owners for several other major projects.

 

Project Backlog

 

Recently, GPS entered into an engineering, procurement and construction (“EPC”) services contract with ESC Harrison County Power, LLC to construct a 625 MW natural gas-fired power plant in Harrison County, West Virginia. Caithness Energy, L.L.C. (“Caithness”) has partnered with Energy Solutions Consortium, LLC (“ESC”) to develop this project. Early in the first quarter, we announced that GPS had entered into an EPC services contract with Guernsey Power Station, LLC to build an 1,875 MW natural gas-fired power plant in Guernsey County, Ohio. The Guernsey Power Station is being jointly developed by Caithness and Apex Power Group, LLC. Last year, we successfully completed the construction of the Freedom Generating Station for Caithness, a 1040 MW combined cycle natural gas-fired power plant located in Pennsylvania.

 

19


Table of Contents

 

Both new facilities will be state-of-the-art combined cycle power plants, with power islands based on natural gas-fired turbines supplied by General Electric, providing electricity to the PJM interconnect (grid). Limited notices to proceed with preliminary design and site preparation activities have been received from the owners of both projects. Construction activities for the facilities are expected to begin this summer with completion scheduled in 2022.

 

Our project backlog amount was $1.1 billion as of April 30 and January 31, 2019. Including the value of the Harrison County Power Station project that was awarded subsequent to the end of the quarter, the amount of our project backlog now exceeds $1.4 billion. Our reported amount of project backlog at a point in time represents the total value of projects awarded to us that we consider to be firm as of that date less the amounts of revenues recognized to date on the corresponding projects. Cancellations or reductions may occur that may reduce project backlog and our expected future revenues. We include the value of an EPC services contract in project backlog when we believe that it is probable that the project will commence within a reasonable timeframe, among other factors.

 

The following table summarizes our large power plant projects:

 

 

 

 

 

Facility

 

FNTP (1)

 

Scheduled

Current Project

 

Location

 

Size

 

Received

 

Completion

TeesREP Biomass Power Station

 

Teesside (England)

 

299 MW

 

May 2017

 

2020

InterGen Spalding OCGT Expansion Project

 

Spalding (England)

 

298 MW

 

November 2017

 

2019

NTE Reidsville Energy Center

 

North Carolina

 

475 MW

 

(2)

 

(2)

Guernsey Power Station

 

Ohio

 

1,875 MW

 

(3)

 

(2)

Harrison County Power Station

 

West Virginia

 

625 MW

 

(3)

 

(2)

 


(1)         Full Notice-to-Proceed (“FNTP”) represents the formal notice provided by the customer instructing us to commence all of the activities covered by the corresponding contract.

(2)         FNTP has not been received and the scheduled completion date has not been established definitively.

(3)         Limited notices to proceed with certain preliminary design and site preparation activities have been issued to GPS.

 

We believe that new business awards to GPS are being delayed by a variety of factors especially in the northeast and mid-Atlantic regions of the United States. For example, there is some remaining uncertainty surrounding the level of regulatory support for coal as part of the energy mix, an increase in the amount of power generating capacity provided by renewable energy assets and improvements and decreasing prices in renewable energy storage solutions. Together with the difficulty in obtaining project financing, these factors may be impacting the planning and initial phases for the construction of new natural gas-fired power plants which continue to be deferred by project owners.

 

Although the downward trend was interrupted last year, our country has experienced a decline in carbon dioxide emissions from power plants as the growth in renewable energy and the supply of inexpensive natural gas have moved more energy producers away from coal. The coal-fired power plant fleet is getting old. It is expensive to keep the coal plants running, and they are not competitive in the market. Nevertheless, in some cases, new support may encourage the continued operation of old coal plants that might otherwise be retired without any government intervention. Other unfavorable factors include challenging energy capacity auctions for new power generating assets, the impacts of environmental activism and California’s resolve to move towards 100% renewable energy. The increase in the number of protests against fossil-fuel related energy projects continue to garner media attention and public skepticism about new pipelines resulting in project delays due to onsite protest demonstrations, indecision by local officials and lawsuits. Pipeline approval delays may jeopardize projects that are needed to bring supplies of natural gas to planned gas-fired power plant sites, thereby increasing the risk of power plant project delays or cancellations.

 

Market Outlook

 

The total annual amount of electricity generated by utility-scale facilities in the United States in calendar year 2018 was the highest amount generated since 2007. In its latest base-case outlook, the U.S. Energy Information Administration (the “EIA”) forecasts steady growth in net electricity generation through 2050 with average annual increases of approximately 1.0% per year. The growth rate is tempered by new electricity-efficient devices and production processes replacing older, less-efficient appliances, heating, cooling and ventilation systems and capital equipment. Nonetheless, the EIA forecasts continued growth for natural gas-fired electricity generation through 2050 with average annual increases of 1.2% per year. EIA expects the share of total utility-scale electricity generation from natural gas-fired power plants in the United States to rise from approximately 34% in 2018 to 37% in 2022 and to 39% by 2050. The generation share from coal is forecast to fall steadily during these periods, from 28% in 2018 to 23% in 2022 to 17% by 2050.

 

20


Table of Contents

 

As reported by EIA, net electricity generation at utility-scale facilities in our country rose by 3.6% during 2018 as net generation from natural gas, wind and solar sources increased by 13.2%, 8.1% and 25.0%, respectively. Moreover, the share of net electricity generation fueled by natural gas rose from approximately 31.7% in 2017 to 34.4% for 2018. The net electricity generation from coal declined by 4.9% for the year. In summary, the share of the electrical power generation mix fueled by natural gas continued its increase, while the share fueled by coal has continued its fall.

 

Over the next three years, EIA forecasts that new wind and photovoltaic solar capacity will continue to be added to the utility-scale power fleet in the United States at a brisk pace substantially attributable to declining equipment costs and the availability of valuable tax credits. As these credits decline and then expire early in the next decade, the wind capacity additions will slow. Although tax incentives related to solar power also expire, the continuing decline in the cost of solar power equipment is predicted to sustain the growth of photovoltaic solar power generation facilities. Persistent low natural gas prices, lower power plant operating costs and higher energy generating efficiencies should sustain the demand for modern combined cycle gas-fired power plants in the future. Natural gas is relatively clean burning, cost-effective and reliable; its benefits as a source of power are compelling.

 

We believe that the future prospects for natural gas-fired power plant construction are favorable as natural gas is the primary source for power generation in our country. Major advances in horizontal drilling and the practice of hydraulic fracturing led to the boom in natural gas supply which is available at consistently low prices now and in the foreseeable future. The abundant availability of cheap, less carbon-intense and higher efficiency natural gas should continue to be a significant factor in the economic assessment of future power generation capacity additions. As indicated above, the demand for electric power in this country is expected to grow slowly but steadily over the long term. Demands for electricity, the ample supply of natural gas, and the future retirement of coal, nuclear and inefficient gas-fired energy plants, should result in modern natural gas-fired energy plants representing a substantial portion of new power generation additions in the future and an increased share of the power generation mix.

 

Moreover, the competitive landscape in the EPC services market for natural gas-fired power plant construction has changed significantly. Last year, several significant competitors announced that they were exiting the market for a variety of reasons. While the competitive market remains dynamic, we expect that there will be fewer competitors for new gas-fired power plant EPC project opportunities.

 

We believe that the development of natural gas-fired power generation facilities in the United States should continue to provide new construction opportunities for us, although the pace of new opportunities emerging may be restrained in the near term as discussed above. We are committed to the rational pursuit of new construction projects and the future growth of our revenues. This may result in our decision to make investments in the development and/or ownership of new projects. Because we believe in the strength of our balance sheet, we are willing to consider certain opportunities that include reasonable and manageable risks in order to assure the award of the related EPC services contract to us. We believe that the Company has a growing reputation as an accomplished and cost-effective provider of EPC and other large project construction contracting services. With the proven ability to deliver completed power facilities, particularly combined cycle, natural gas-fired power plants, we are focused on expanding our position in the power markets where we expect investments to be made based on forecasts of electricity demand covering decades into the future. We believe that our expectations are valid and that our plans for the future continue to be based on reasonable assumptions.

 

Comparison of the Results of Operations for the Three Months Ended April 30, 2019 and 2018

 

We reported net loss attributable to our stockholders of $29.8 million, or $1.91 per diluted share, for the three months ended April 30, 2019. For the three months ended April 30, 2018, we reported a comparable net income amount of $4.8 million, or $0.31 per diluted share.

 

21


Table of Contents

 

The following schedule compares our operating results for the three months ended April 30, 2019 and 2018 (dollars in thousands):

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

$ Change

 

% Change

 

REVENUES

 

 

 

 

 

 

 

 

 

Power industry services

 

$

20,203

 

$

122,487

 

$

(102,284

)

(83.5

)%

Industrial fabrication and field services

 

27,069

 

16,449

 

10,620

 

64.6

 

Telecommunications infrastructure services

 

2,272

 

2,430

 

(158

)

(6.5

)

Revenues

 

49,544

 

141,366

 

(91,822

)

(65.0

)

COST OF REVENUES

 

 

 

 

 

 

 

 

 

Power industry services

 

44,526

 

108,296

 

(63,770

)

(58.9

)

Industrial fabrication and field services

 

24,271

 

15,649

 

8,622

 

55.1

 

Telecommunications infrastructure services

 

1,773

 

1,969

 

(196

)

(10.0

)

Cost of revenues

 

70,750

 

125,914

 

(55,164

)

(43.8

)

GROSS (LOSS) PROFIT

 

(21,026

)

15,452

 

(36,478

)

N/M

 

Selling, general and administrative expenses

 

9,588

 

9,637

 

(49

)

(0.5

)

Impairment loss

 

2,072

 

 

2,072

 

N/M

 

(LOSS) INCOME FROM OPERATIONS

 

(32,686

)

5,815

 

(38,501

)

N/M

 

Other income, net

 

2,252

 

764

 

1,488

 

194.8

 

(LOSS) INCOME BEFORE INCOME TAXES

 

(30,434

)

6,579

 

(37,013

)

N/M

 

Income tax benefit (expense)

 

521

 

(1,737

)

2,258

 

N/M

 

NET (LOSS) INCOME

 

(29,913

)

4,842

 

(34,755

)

N/M

 

Net (loss) income attributable to non-controlling interests

 

(113

)

5

 

(118

)

N/M

 

NET (LOSS) INCOME ATTRIBUTABLE TO

 

 

 

 

 

 

 

 

 

THE STOCKHOLDERS OF ARGAN, INC.

 

$

(29,800

)

$

4,837

 

$

(34,637

)

N/M

 

 

N/M — Not meaningful.

 

Revenues

 

Power Industry Services

 

The revenues of the power industry services business decreased by 84%, or $102.3 million, to $20.2 million for the three months ended April 30, 2019 compared with revenues of $122.5 million for the three months ended April 30, 2018. The revenues of this business represented approximately 41% of consolidated revenues for the current quarter, and approximately 87% of consolidated revenues for the prior year quarter. GPS reached substantial completion on four gas-fired power plant projects during the year ended January 31, 2019 and concluded activities on a fifth gas-fired power plant early in the current quarter. These five power plants provided revenues of $8.4 million and $103.0 million for the three months ended April 30, 2019 and 2018, respectively, representing a 92% decline. GPS revenue levels have been negatively impacted by the delay in new project startups. The revenues for this segment also were negatively impacted by unfavorable adjustments recorded in April 2019 related to the TeesREP project. As previously discussed above, a detailed review of this challenging project by management for the quarter ended April 30, 2019 revealed that we were likely to incur a significant loss on this project which was recognized in the results of operations for the quarter. For the three months ended April 30, 2019, the reversal of revenues recorded in prior periods related to the changes that the Company made to transaction prices and to estimates of the costs-to-complete active contracts, including those changes related to the loss contract of APC, was a net amount of approximately $1.4 million.

 

Industrial Fabrication and Field Services

 

The revenues of the industrial fabrication and field services business (representing the business of TRC) provided 55% of consolidated revenues for the three months ended April 30, 2019. Revenues increased by $10.6 million, or 65%, to $27.1 million for the three months ended April 30, 2019, compared to $16.4 million for the three months ended April 30, 2018. The largest portion of the revenues of TRC continue to be provided by industrial field services, which increased by $6.9 million between quarters. The major customers of TRC include some of North America’s largest forest products companies, large fertilizer producers as well as energy and mining companies with plants located in the southeast region of the United States. Over the last few quarters, TRC has been successful in obtaining business from several large new customers while expanding the volume of business from recurring industrial customers.

 

22


Table of Contents

 

Telecommunications Infrastructure Services

 

The revenues of this business segment (representing the business of SMC) were $2.3 million for the three months ended April 30, 2019 compared with revenues of $2.4 million for the three months ended April 30, 2018.

 

Cost of Revenues

 

Due primarily to the substantial decrease in consolidated revenues for the three months ended April 30, 2019 compared with last year’s first quarter, the corresponding consolidated cost of revenues also decreased. These costs were $70.8 million and $125.9 million for the three months ended April 30, 2019 and 2018, respectively; a reduction of approximately 44%.

 

The loss recognized by APC for the quarter ended April 30, 2019 in the amount of $27.6 million had a significant unfavorable effect on the Company’s gross profit, causing us to report a consolidated gross loss for the current quarter in the amount of $21.0 million. For the three months ended April 30, 2018, we reported a gross profit of approximately $15.5 million which represented a consolidated gross profit percentage of approximately 11% of corresponding consolidated revenues. For comparison, after removing the loss reported by APC, our overall gross profit percentage for the three months ended April 30, 2019 was 13.8% of corresponding consolidated revenues. For the three months ended April 30, 2019, the gross profit percentages of corresponding revenues for the industrial services and the telecommunications infrastructure segments were 10.3% and 22.0%, respectively. Both results were improvements from the gross profit percentages reported for the three months ended April 30, 2018, which were 4.9% and 19.0%, respectively

 

Impairment Loss

 

APC recorded a substantial loss on TeesREP during the three months ended April 30, 2019. We considered the recognition of a contract loss of this magnitude to be an event triggering a re-assessment of the goodwill which resulted in our conclusion that the remaining balance was impaired. Accordingly, an impairment loss was recorded in April 2019 in the amount of $2.1 million.

 

Other Income

 

For the three months ended April 30, 2019 and 2018, this line item included interest income earned on CDs in the amounts of $1.0 million and $1.1 million, respectively, and $0.5 million and $0.3 million of additional investment income earned on funds maintained in a money market account, respectively. The weighted average annual interest rates of the CDs owned during the comparable periods were 2.7% and 1.6%, respectively. For the three months ended April 30, 2019 and 2018, the weighted average initial terms-to-maturity of the CDs were 218 days and 283 days, respectively. For the three months ended April 30, 2019, other income also included interest accrued during the period in the amount of $0.6 million on income tax refunds that we expect to receive related to amended prior year income tax returns. For the three months ended April 30, 2018, the amount of this line item reflected interest expense in the amount of $0.5 million related to the resolution of a legal dispute.

 

Income Tax Benefit (Expense)

 

We recorded an income tax benefit for the three months ended April 30, 2019 in the amount of approximately $0.5 million which primarily reflected the tax benefit of the loss incurred for the current period by our domestic operations. We did not record any income tax benefit related to the net loss reported by the European operations of APC for the current quarter. After eliminating this loss from the forecast of net income for the year, we estimate that our annual effective income tax rate for the year ending January 31, 2020 before discrete items will approximate 24.8%. This tax rate differs from the statutory federal tax rate of 21% due primarily to state income taxes and the unfavorable effects of permanent differences relating to nondeductible travel and entertainment expenses and certain nondeductible executive compensation.

 

For the quarter ended April 30, 2018, we recorded income tax expense of $1.7 million reflecting an annual effective income tax rate of approximately 26% which was expected at the time. The estimated annual income tax rate was higher than the federal income tax rate of 21% due primarily to the estimated unfavorable effect of state income taxes, and the unfavorable effects of additional limitations on the deductibility of certain executive compensation and certain meals and entertainment expenses. Most of such expenses for which we are unable to take full tax deductions are living expenses incurred by employees assigned to out-of-town projects.

 

23


Table of Contents

 

Liquidity and Capital Resources as of April 30, 2019

 

At April 30, and January 31, 2019, our balances of cash and cash equivalents were $132.4 million and $164.3 million, respectively. During this same period, our working capital decreased by $32.0 million to $302.1 million as of April 30, 2019 from $334.1 million as of January 31, 2019.

 

The net amount of cash used by operating activities for the three months ended April 30, 2019 was $36.4 million. Our net loss for the period, offset partially by the favorable adjustments related to non-cash income and expense items, used cash in the total amount of $26.2 million. Due substantially to the increased activity at TRC, accounts receivable increased during the three months ended April 30, 2019, representing a use of cash in the amount of $12.0 million. The Company also used cash during the three months ended April 30, 2019 in the amount of $10.5 million to reduce the level of accounts payable and accrued liabilities. However, the net balance of contract assets and liabilities declined by $8.4 million during the current quarter due primarily to a reduction in the amount of costs incurred and estimated earnings recognized on certain active projects in excess of the amounts billed on those projects, which represented a source of cash. Due primarily to the receipt of expected income tax refunds, the balance of other assets decreased by $4.0 million during the three months ended April 30, 2019; a source of cash.

 

The primary source of cash required to fund operations during the three months ended April 30, 2019 was the net maturity of short-term investments, certificates of deposit issued by Bank of America (our “Bank”), in the amount of $9.0 million. Cash proceeds in the amount of $1.6 million were received from the exercise of stock options during the current quarter. Non-operating activities used cash during the three months ended April 30, 2019, including primarily the payment of a quarterly cash dividend in the total amount of $3.9 million. Our operating subsidiaries also used cash during the three-month period ended April 30, 2019 in the amount of $2.0 million to fund capital expenditures.

 

During the three months ended April 30, 2018, our balance of cash and cash equivalents increased by $29.4 million to $151.5 million while our working capital decreased by $1.5 million during the period to $300.3 million as of April 30, 2018.

 

The net amount of cash used by operating activities for the three months ended April 30, 2018 was $60.9 million. Even though net income for the period, including the favorable adjustments related to non-cash expense items, provided cash in the total amount of $6.2 million, cash used in operations exceeded this amount primarily due to the effects of four major EPC projects that were nearing completion. Because these projects were well past the peak of their respective milestone billing schedules, the amounts of billings in excess of the amounts of the corresponding costs and estimated earnings on these projects declined during the quarter ended April 30, 2018. At the same time, the total amount of billings retained by customers continued to increase as these four projects were not yet completed as of April 30, 2018. As a result, we experienced an increase of $36.7 million in the amount of contract assets and a decrease of $17.2 million in the amount of contract liabilities during the quarter ended April 30, 2018, which together represented a use of cash in the amount of $53.9 million. In addition, increased activity on a fifth major project caused accounts receivable to increase during the three months ended April 30, 2018, a use of cash in the amount of $9.5 million.

 

Our primary source of this cash during the three months ended April 30, 2018 was the net maturity of short-term investments in the amount of $98.0 million. Non-operating activity cash uses included primarily the payment of a cash dividend of $3.9 million. Our operating subsidiaries used cash during the three-month period ended April 30, 2018 in the amount of $3.7 million for capital expenditures.

 

Our credit agreement with the Bank (the “Credit Agreement”), which expires on May 31, 2021, includes the following features, among others:

 

·                  a lending commitment of $50.0 million including a revolving loan with interest at the 30-day LIBOR plus 2.0%; and

 

·                  an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions.

 

We have pledged the majority of our assets to secure the financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Credit Agreement requires that we comply with certain financial covenants at our fiscal year-end and at each fiscal quarter-end. The Credit Agreement includes other terms, covenants and events of default that are customary for a credit facility of its size and nature. We may use the borrowing ability to cover other credit issued by the Bank for our use in the ordinary course of business. At April 30, 2019, we had approximately $15.5 million of credit outstanding under the Credit Agreement primarily to support our APC activities. However, we had no outstanding borrowings. At April 30, and January 31, 2019, we were compliant with the financial covenants of the Credit Agreement. However, certain financial covenant requirements are based on the amount of earnings before interest, taxes, depreciation and amortization (“EBITDA”), as defined in the Credit Agreement, reported by us on a rolling twelve-month basis. The loss incurred by us for the current quarter has reduced the covenant compliance margins considerably.

 

24


Table of Contents

 

At April 30, 2019, most of our balance of cash and cash equivalents was invested in a high-quality money market fund with at least 99.5% of its total assets invested in cash, U.S. Treasury obligations and repurchase agreements secured by U.S. Treasury obligations. Most of our domestic operating bank accounts are maintained with the Bank. We do maintain certain Euro-based bank accounts in the Republic of Ireland and certain pound sterling-based bank accounts in the United Kingdom in support of the operations of APC.

 

We believe that cash on hand, cash that will be provided from the maturities of short-term investments and cash generated from our future operations, with or without funds available under our line of credit, will be adequate to meet our general business needs in the foreseeable future. In particular, we maintain significant liquid capital on our balance sheet to help ensure our ability to maintain and obtain bonding capacity for EPC and other construction projects. Any future acquisitions, or other significant unplanned cost or cash requirement, may require us to raise additional funds through the issuance of debt and/or equity securities. There can be no assurance that such financing will be available on terms acceptable to us, or at all.

 

EBITDA

 

We believe that EBITDA is a meaningful presentation that enables us to assess and compare our operating cash flow performance on a consistent basis by removing from our operating results the impacts of our capital structure, the effects of the accounting methods used to compute depreciation and amortization and the effects of operating in different income tax jurisdictions. Further, we believe that EBITDA is widely used by investors and analysts as a measure of performance. However, as EBITDA is not a measure of performance calculated in accordance with U.S. GAAP, we do not believe that this measure should be considered in isolation from, or as a substitute for, the results of our operations presented in accordance with U.S. GAAP that are included in our condensed consolidated financial statements. In addition, our EBITDA does not necessarily represent funds available for discretionary use and is not necessarily a measure of our ability to fund our cash needs.

 

The following table presents the determinations of EBITDA for the three months ended April 30, 2019 and 2018, respectively (amounts in thousands):

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

Net (loss) income, as reported

 

$

(29,913

)

$

4,842

 

Interest expense

 

 

549

 

Income tax (benefit) expense

 

(521

)

1,737

 

Depreciation

 

829

 

771

 

Amortization of purchased intangible assets

 

299

 

253

 

EBITDA

 

(29,306

)

8,152

 

EBITDA of non-controlling interests

 

(115

)

5

 

EBITDA attributable to the stockholders of Argan, Inc.

 

$

(29,191

)

$

8,147

 

 

As we believe that our net cash flow provided by operations is the most directly comparable performance measure determined in accordance with U.S. GAAP, the following table reconciles the amounts of EBITDA for the applicable periods, as presented above, to the corresponding amounts of net cash flows used in operating activities that are presented in our condensed consolidated statements of cash flows for the three months ended April 30, 2019 and 2018 (amounts in thousands).

 

 

 

Three Months Ended April 30,

 

 

 

2019

 

2018

 

EBITDA

 

$

(29,306

)

$

8,152

 

Current income tax benefit (expense)

 

780

 

(1,575

)

Interest expense

 

 

(549

)

Impairment loss

 

2,072

 

 

Other noncash items

 

284

 

156

 

Increase in accounts receivable

 

(12,049

)

(9,522

)

Decrease (increase) in other assets

 

3,962

 

(2,970

)

Decrease in accounts payable and accrued expenses

 

(10,497

)

(745

)

Change in contracts in progress, net

 

8,372

 

(53,882

)

Net cash used in operating activities

 

$

(36,382

)

$

(60,935

)

 

25


Table of Contents

 

Critical Accounting Policies

 

We consider the accounting policies related to the recognition of revenues from customer contracts; the accounting for business combinations; the subsequent valuation of goodwill, other indefinite-lived assets and long-lived assets; income tax reporting; the valuation of employee stock options and the financial reporting associated with any significant legal matters to be most critical to the understanding of our financial position and results of operations, as well as the accounting and reporting for special purpose entities including VIEs.

 

Critical accounting policies are those related to the areas where we have made what we consider to be particularly subjective or complex judgments in arriving at estimates and where these estimates can significantly impact our financial results under different assumptions and conditions. These estimates, judgments, and assumptions affect the reported amounts of assets, liabilities and equity, the disclosure of contingent assets and liabilities at the date of financial statements and the reported amounts of revenues and expenses during the reporting periods. We base our estimates on historical experience and various other assumptions that we believe are reasonable under the circumstances, the results of which form the basis for making judgments about the carrying value of assets, liabilities and equity that are not readily apparent from other sources. Actual results and outcomes could differ from these estimates and assumptions.

 

An expanded discussion of our critical accounting policies is included in Item 7 of Part II of our Annual Report. During the three-month period ended April 30, 2019, there have been no material changes in the way we apply the critical accounting policies described therein except that Note 7 to the accompanying condensed consolidated financial statements presents the revised accounting policy for leases that was adopted on February 1, 2019.

 

In addition, as disclosed in Note 5 to the accompanying condensed consolidated financial statements, we recorded an impairment loss during the three-month period ended April 30, 2019 in the amount of approximately $2.1 million, which effectively wrote-off the remaining balance of goodwill related to APC.

 

Recently Issued Accounting Pronouncements

 

In 2016, the FASB issued Accounting Standards Update 2016-13, Measurement of Credit Losses on Financial Instruments. The scope of this new standard covers, among other provisions, the methods that businesses shall use to estimate amounts of uncollectible accounts receivable. As subsequently amended, we do not expect that the requirements of this new guidance, which becomes effective for us on February 1, 2020, will materially affect our consolidated financial statements. There are no other recently issued accounting pronouncements that have not yet been adopted that we consider material to our consolidated financial statements.

 

ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

 

In the normal course of business, our results of operations may be subject to risks related to fluctuations in interest rates. As of April 30, 2019, we had no outstanding borrowings under our financing arrangements with the Bank (see Note 6 to the accompanying consolidated financial statements), which provide a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2021 with interest at 30-day LIBOR plus 2.0%.

 

As of April 30, 2019, the weighted average annual interest rate on our short-term investments of $123.4 million was 2.7%. During the three months ended April 30, 2019 and 2018, we did not enter into derivative financial instruments for trading, speculation or other purposes that would expose us to market risk. To illustrate the potential impact of changes in interest rates on our results of operations, we have performed the following hypothetical analysis, which assumes that our consolidated balance sheet as of April 30, 2019 remains constant, and no further actions are taken to alter our existing interest rate sensitivity (dollars in thousands). As the weighted average interest rate on our short-term investments was 2.7% at April 30, 2019, the largest decrease in the interest rates presented above is 270 basis points.

 

Basis Point Change

 

Increase (Decrease) in
Interest Income

 

Increase (Decrease) in
Interest Expense

 

Net Decrease (Increase) in
Loss (pre-tax)

 

Up 300 basis points

 

$

991

 

$

 

$

991

 

Up 200 basis points

 

661

 

 

661

 

Up 100 basis points

 

330

 

 

330

 

Down 100 basis points

 

(330

)

 

(330

)

Down 200 basis points

 

(661

)

 

(661

)

Down 270 basis points

 

(856

)

 

(856

)

 

26


Table of Contents

 

With the acquisition of APC, we are subject to the effects of translating the financial statements of APC from its functional currency (Euros) into our reporting currency (US dollars). Such effects are recognized in accumulated other comprehensive loss, which is net of tax when applicable.

 

In addition, we are subject to fluctuations in prices for commodities including copper, concrete, steel products and fuel. Although we attempt to secure firm quotes from our suppliers, we generally do not hedge against increases in prices for copper, concrete, steel or fuel. Commodity price risks may have an impact on our results of operations due to the fixed-price nature of many of our contracts. We attempt to include the anticipated amounts of price increases or decreases in the costs of our bids.

 

ITEM 4. CONTROLS AND PROCEDURES

 

Evaluation of disclosure controls and procedures. Our management, with the participation of our chief executive officer and chief financial officer, evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934 (the “Exchange Act”) as of April 30, 2019. Management recognizes that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving their objectives, and management necessarily applies its judgment in evaluating the cost-benefit relationship of possible controls and procedures. Based on the evaluation of our disclosure controls and procedures as of April 30, 2019, our chief executive officer and chief financial officer concluded that, as of such date, our disclosure controls and procedures were effective to provide reasonable assurance that information required to be disclosed in our Exchange Act reports is recorded, processed, summarized, and reported within the time periods specified by the SEC, and the material information related to the Company and its consolidated subsidiaries is made known to management, including the chief executive officer and chief financial officer, to allow timely decisions regarding required disclosure in the reports.

 

Changes in internal controls over financial reporting. There have been no significant changes in our internal control over financial reporting (as defined in Rules 13a-15 and 15d-15 under the Exchange Act) during the fiscal quarter ended April 30, 2019 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

 

PART II

 

ITEM 1.   LEGAL PROCEEDINGS

 

Included in Note 8 to the condensed consolidated financial statements that are included in Item 1 of Part I of this Quarterly Report on Form 10-Q is the discussion of the status of a specific legal proceeding as of April 30, 2019. In the normal course of business, we may have other pending claims and legal proceedings. It is our opinion, based on information available at this time, that any other current claim or proceeding will not have a material effect on our condensed consolidated financial statements.

 

ITEM 1A.   RISK FACTORS

 

There have been no material changes from our risk factors as disclosed in our Annual Report.

 

ITEM 2.   UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS

 

None

 

ITEM 3.   DEFAULTS UPON SENIOR SECURITIES

 

None

 

ITEM 4.   MINE SAFETY DISCLOSURES (not applicable to us)

 

ITEM 5.   OTHER INFORMATION

 

None

 

27


Table of Contents

 

ITEM 6.   EXHIBITS

 

Exhibit No.

 

Title

 

 

 

Exhibit 31.1

 

Certification of Chief Executive Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934

Exhibit 31.2

 

Certification of Chief Financial Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934

Exhibit 32.1

 

Certification of Chief Executive Officer, pursuant to 18 U.S.C. Section 1350 *

Exhibit 32.2

 

Certification of Chief Financial Officer, pursuant to 18 U.S.C. Section 1350 *

 

 

 

Exhibit 101.INS#

 

XBRL Instance Document

Exhibit 101.SCH#

 

XBRL Schema Document

Exhibit 101.CAL#

 

XBRL Calculation Linkbase Document

Exhibit 101.LAB#

 

XBRL Labels Linkbase Document

Exhibit 101.PRE#

 

XBRL Presentation Linkbase Document

Exhibit 101.DEF#

 

XBRL Definition Linkbase Document

 


* The certification is being furnished and shall not be considered filed as part of this report.

 

SIGNATURES

 

Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

 

 

ARGAN, INC.

 

 

 

 

June 10, 2019

By:

/s/ Rainer H. Bosselmann

 

 

Rainer H. Bosselmann

 

 

Chairman of the Board and Chief Executive Officer

 

 

June 10, 2019

By:

/s/ David H. Watson

 

 

David H. Watson

 

 

Senior Vice President, Chief Financial Officer,

 

 

Treasurer and Secretary

 

28