10-Q 1 tpc-20150930x10q.htm 10-Q 20150930 Q3

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

 

FORM 10-Q

 

QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the quarterly period ended September 30, 2015

 

OR

 

TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the transition period from             to             

 

Commission File Number:  1-6314

 

Tutor Perini Corporation

(Exact name of registrant as specified in its charter)

 

 

 

 

MASSACHUSETTS

 

04-1717070

(State or other jurisdiction of
incorporation or organization)

 

(I.R.S. Employer
Identification No.)

 

15901 OLDEN STREET, SYLMAR, CALIFORNIA 91342-1093

(Address of principal executive offices)

(Zip code)

 

(818) 362-8391

(Registrant’s telephone number, including area code)

 

 

(Former name, former address and former fiscal year, if changed since last report)

 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes   No

 

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes   No 

 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer”, “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):

 

 

 

 

Large accelerated filer 

 

Accelerated filer 

 

 

 

Non-Accelerated filer 

 

Smaller reporting company 

 

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes   No 

 

The number of shares of common stock, $1.00 par value per share, of the registrant outstanding at November 12, 2015 was 49,072,710.

 

 

 

 

 

 


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

 

INDEX

 

 

 

 

 

 

 

 

Page Number

Part I. 

Financial Information:

 

 

Item 1.

Financial Statements (unaudited)

 

 

 

Consolidated Condensed Balance Sheets —  September 30, 2015 and December 31, 2014

3 - 4

 

 

Consolidated Condensed Statements of Operations — Three and Nine months ended September 30, 2015 and 2014

 

 

Consolidated Condensed Statements of Comprehensive Income — Three and Nine months ended September 30, 2015 and 2014

 

 

Consolidated Condensed Statement of Stockholders’ Equity  Nine months ended September 30, 2015

 

 

Consolidated Condensed Statements of Cash Flows — Nine months ended September 30, 2015 and 2014

 

 

Notes to Consolidated Condensed Financial Statements

9 - 33

 

Item 2.

Management’s Discussion and Analysis of Financial Condition and Results of Operations

34 - 44

 

Item 3.

Quantitative and Qualitative Disclosures About Market Risk

44 

 

Item 4.

Controls and Procedures

44 

Part II. 

Other Information:

 

 

Item 1.

Legal Proceedings

44 

 

Item 1A.

Risk Factors

44 

 

Item 2.

Unregistered Sales of Equity Securities and Use of Proceeds

44 

 

Item 3.

Defaults Upon Senior Securities

44 

 

Item 4.

Mine Safety Disclosures

45 

 

Item 5.

Other Information

45 

 

Item 6.

Exhibits

45 

 

Signatures

 

46 

 

 

2


 

Part I.  - Financial Information

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED BALANCE SHEETS

SEPTEMBER 30, 2015 AND DECEMBER 31, 2014

(Unaudited-in thousands, except share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30, 2015

 

December 31, 2014

ASSETS

 

 

 

 

 

CURRENT ASSETS:

 

 

 

 

 

Cash and cash equivalents

$

96,894 

 

$

135,583 

Restricted cash

 

38,572 

 

 

44,370 

Accounts receivable, including retainage

 

1,550,865 

 

 

1,479,504 

Costs and estimated earnings in excess of billings

 

883,809 

 

 

726,402 

Deferred income taxes

 

18,873 

 

 

17,962 

Other current assets

 

86,734 

 

 

68,735 

Total current assets

 

2,675,747 

 

 

2,472,556 

 

 

 

 

 

 

PROPERTY AND EQUIPMENT (net of accumulated depreciation of $245,091 in 2015 and $220,028 in 2014)

 

531,438 

 

 

527,602 

 

 

 

 

 

 

OTHER ASSETS:

 

 

 

 

 

Goodwill

 

585,006 

 

 

585,006 

Intangible assets, net

 

97,425 

 

 

100,254 

Other

 

80,639 

 

 

87,897 

Total assets

$

3,970,255 

 

$

3,773,315 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

3


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED BALANCE SHEETS (continued)

SEPTEMBER 30, 2015 AND DECEMBER 31, 2014

(Unaudited-in thousands, except share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30, 2015

 

December 31, 2014

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

CURRENT LIABILITIES:

 

 

 

 

 

Current maturities of long-term debt

$

85,897 

 

$

81,292 

Accounts payable, including retainage

 

985,217 

 

 

798,174 

Billings in excess of costs and estimated earnings

 

286,565 

 

 

319,296 

Accrued expenses and other current liabilities

 

185,764 

 

 

159,814 

Total current liabilities

 

1,543,443 

 

 

1,358,576 

 

 

 

 

 

 

LONG-TERM DEBT, less current maturities

 

746,283 

 

 

784,067 

 

 

 

 

 

 

DEFERRED INCOME TAXES

 

149,021 

 

 

150,371 

 

 

 

 

 

 

OTHER LONG-TERM LIABILITIES

 

114,902 

 

 

114,796 

Total liabilities

 

2,553,649 

 

 

2,407,810 

 

 

 

 

 

 

CONTINGENCIES AND COMMITMENTS

 

 

 

 

 

 

 

 

 

 

 

STOCKHOLDERS' EQUITY:

 

 

 

 

 

Preferred stock, $1 par value:

 

 

 

 

 

Authorized – 1,000,000 shares

 

 

 

 

 

Issued and outstanding – none

 

 —

 

 

 —

Common stock - $1 par value: 75,000,000 shares authorized; Shares issued and outstanding: 49,072,710 shares and 48,671,492 shares

 

49,073 

 

 

48,671 

Additional paid-in capital

 

1,043,103 

 

 

1,025,941 

Retained earnings

 

369,091 

 

 

332,511 

Accumulated other comprehensive loss

 

(44,661)

 

 

(41,618)

Total stockholders' equity

 

1,416,606 

 

 

1,365,505 

 

 

 

 

 

 

Total liabilities and stockholders' equity

$

3,970,255 

 

$

3,773,315 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

4


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF OPERATIONS

 (Unaudited-in thousands, except per share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

Nine Months Ended

 

September 30,

 

September 30,

 

2015

 

2014

 

2015

 

2014

 

 

 

 

 

 

 

 

 

 

 

 

Revenues

$

1,340,739 

 

$

1,250,689 

 

$

3,719,642 

 

$

3,290,432 

 

 

 

 

 

 

 

 

 

 

 

 

Cost of operations

 

1,240,538 

 

 

1,109,848 

 

 

3,430,062 

 

 

2,914,713 

 

 

 

 

 

 

 

 

 

 

 

 

Gross profit

 

100,201 

 

 

140,841 

 

 

289,580 

 

 

375,719 

 

 

 

 

 

 

 

 

 

 

 

 

General and administrative expenses

 

61,227 

 

 

70,487 

 

 

199,641 

 

 

198,425 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

38,974 

 

 

70,354 

 

 

89,939 

 

 

177,294 

 

 

 

 

 

 

 

 

 

 

 

 

Other income (expense), net

 

5,916 

 

 

(441)

 

 

5,261 

 

 

(10,788)

Interest expense

 

(10,935)

 

 

(11,297)

 

 

(33,048)

 

 

(32,985)

 

 

 

 

 

 

 

 

 

 

 

 

Income before income taxes

 

33,955 

 

 

58,616 

 

 

62,152 

 

 

133,521 

 

 

 

 

 

 

 

 

 

 

 

 

Provision for income taxes

 

(14,278)

 

 

(22,886)

 

 

(25,572)

 

 

(53,307)

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME

$

19,677 

 

$

35,730 

 

$

36,580 

 

$

80,214 

 

 

 

 

 

 

 

 

 

 

 

 

BASIC EARNINGS PER COMMON SHARE

$

0.40 

 

$

0.74 

 

$

0.75 

 

$

1.65 

 

 

 

 

 

 

 

 

 

 

 

 

DILUTED EARNINGS PER COMMON SHARE

$

0.40 

 

$

0.73 

 

$

0.74 

 

$

1.64 

 

 

 

 

 

 

 

 

 

 

 

 

WEIGHTED AVERAGE COMMON SHARES OUTSTANDING:

 

 

 

 

 

 

 

 

 

 

 

BASIC

 

49,070 

 

 

48,588 

 

 

48,951 

 

 

48,525 

Effect of dilutive stock options and restricted stock units

 

705 

 

 

487 

 

 

767 

 

 

495 

DILUTED

 

49,775 

 

 

49,075 

 

 

49,718 

 

 

49,020 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

5


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF COMPREHENSIVE INCOME

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

Nine Months Ended

 

September 30,

 

September 30,

 

2015

 

2014

 

2015

 

2014

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME

$

19,677 

 

$

35,730 

 

$

36,580 

 

$

80,214 

 

 

 

 

 

 

 

 

 

 

 

 

OTHER COMPREHENSIVE INCOME (LOSS):

 

 

 

 

 

 

 

 

 

 

 

  Foreign currency translation

 

(1,792)

 

 

(828)

 

 

(4,633)

 

 

(728)

  Change in fair value of investments

 

(2)

 

 

75 

 

 

(140)

 

 

362 

  Change in fair value of interest rate swap

 

77 

 

 

215 

 

 

250 

 

 

473 

Other comprehensive income (loss) before taxes

 

(1,717)

 

 

(538)

 

 

(4,523)

 

 

107 

INCOME TAX EXPENSE (BENEFIT):

 

 

 

 

 

 

 

 

 

 

 

  Foreign currency translation

 

(417)

 

 

(327)

 

 

(1,524)

 

 

(288)

  Change in fair value of investments

 

 —

 

 

30 

 

 

(54)

 

 

143 

  Change in fair value of interest rate swap

 

30 

 

 

86 

 

 

98 

 

 

187 

Income tax expense (benefit)

 

(387)

 

 

(211)

 

 

(1,480)

 

 

42 

NET OTHER COMPREHENSIVE INCOME (LOSS)

 

(1,330)

 

 

(327)

 

 

(3,043)

 

 

65 

 

 

 

 

 

 

 

 

 

 

 

 

TOTAL COMPREHENSIVE INCOME

$

18,347 

 

$

35,403 

 

$

33,537 

 

$

80,279 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

6


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENT OF STOCKHOLDERS’ EQUITY

FOR THE NINE MONTHS ENDED SEPTEMBER 30, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Accumulated

 

 

 

 

 

 

 

Additional

 

 

 

 

Other

 

 

 

 

Common

 

Paid-in

 

Retained

 

Comprehensive

 

 

 

 

Stock

 

Capital

 

Earnings

 

(Loss) Income

 

Total

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balance - December 31, 2014

$

48,671 

 

$

1,025,941 

 

$

332,511 

 

$

(41,618)

 

$

1,365,505 

Net income

 

 —

 

 

 —

 

 

36,580 

 

 

 —

 

 

36,580 

Other comprehensive loss

 

 —

 

 

 —

 

 

 —

 

 

(3,043)

 

 

(3,043)

Total comprehensive income

 

 

 

 

 

 

 

 

 

 

 

 

 

33,537 

Tax effect of stock-based compensation

 

 —

 

 

(186)

 

 

 —

 

 

 —

 

 

(186)

Stock-based compensation expense

 

 —

 

 

17,064 

 

 

 —

 

 

 —

 

 

17,064 

Issuance of common stock, net

 

402 

 

 

284 

 

 

 —

 

 

 —

 

 

686 

Balance - September 30, 2015

$

49,073 

 

$

1,043,103 

 

$

369,091 

 

$

(44,661)

 

$

1,416,606 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

7


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF CASH FLOWS

(UNAUDITED)

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Nine Months Ended September 30,

 

2015

 

2014

Cash Flows from Operating Activities:

 

 

 

 

 

Net income

$

36,580 

 

$

80,214 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

Depreciation and amortization

 

32,528 

 

 

42,165 

Stock-based compensation expense

 

17,064 

 

 

14,376 

Excess income tax benefit from stock-based compensation

 

(186)

 

 

(656)

Deferred income taxes

 

6,366 

 

 

15,988 

Loss on sale of investments

 

 —

 

 

1,786 

(Gain) loss on sale of property and equipment

 

(821)

 

 

926 

Other long-term liabilities

 

(1,379)

 

 

1,256 

Other non-cash items

 

(5,692)

 

 

1,324 

Changes in other components of working capital 

 

(63,786)

 

 

(300,804)

NET CASH PROVIDED BY (USED IN) OPERATING ACTIVITIES

 

20,674 

 

 

(143,425)

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

Acquisition of property and equipment excluding financed purchases

 

(33,365)

 

 

(37,778)

Proceeds from sale of property and equipment

 

2,220 

 

 

5,153 

Proceeds from sale of available-for-sale securities

 

 —

 

 

44,497 

Change in restricted cash

 

5,798 

 

 

(4,394)

NET CASH (USED IN) PROVIDED BY INVESTING ACTIVITIES

 

(25,347)

 

 

7,478 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

Proceeds from debt

 

672,719 

 

 

993,010 

Repayment of debt

 

(706,113)

 

 

(808,611)

Business acquisition-related payments

 

 —

 

 

(26,430)

Excess income tax benefit from stock-based compensation

 

186 

 

 

656 

Issuance of common stock and effect of cashless exercise

 

(808)

 

 

(1,692)

Debt issuance costs

 

 —

 

 

(3,681)

NET CASH (USED IN) PROVIDED BY FINANCING ACTIVITIES

 

(34,016)

 

 

153,252 

 

 

 

 

 

 

Net (Decrease) Increase in Cash and Cash Equivalents

 

(38,689)

 

 

17,305 

Cash and Cash Equivalents at Beginning of Year

 

135,583 

 

 

119,923 

Cash and Cash Equivalents at End of Period

$

96,894 

 

$

137,228 

 

 

 

 

 

 

Supplemental Disclosure of Cash Paid For:

 

 

 

 

 

Interest

$

28,706 

 

$

27,447 

Income taxes

$

21,565 

 

$

47,736 

Supplemental Disclosure of Non-cash Transactions:

 

 

 

 

 

Property and equipment acquired through financing arrangements not included above

$

 —

 

$

27,045 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

8


 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED CONDENSED FINANCIAL STATEMENTS

 

(1)     Basis of Presentation

 

The unaudited consolidated condensed financial statements presented herein include the accounts of Tutor Perini Corporation and its wholly owned subsidiaries (“Tutor Perini” or the “Company”). The Company’s interests in construction joint ventures are accounted for using the proportionate consolidation method whereby the Company’s proportionate share of each joint venture’s assets, liabilities, revenues and cost of operations are included in the appropriate classifications in the consolidated financial statements. All intercompany transactions and balances have been eliminated in consolidation.

 

The unaudited consolidated condensed financial statements have been prepared in accordance with the instructions to Form 10-Q and do not include all of the information and note disclosures required by accounting principles generally accepted in the United States as codified in the Financial Accounting Standards Board’s (“FASB”) Accounting Standards Codification. These statements should be read in conjunction with the financial statements and notes thereto included in the Company’s Annual Report on Form 10-K for the year ended December 31, 2014.

 

In the opinion of management, the accompanying unaudited consolidated condensed financial statements include all adjustments, consisting only of normal recurring adjustments necessary to present fairly the Company’s financial position as of September 30, 2015 and December 31, 2014, results of operations and comprehensive income, for the three and nine months ended September 30, 2015 and 2014, and cash flows for the nine months ended September 30, 2015 and 2014. The results of operations for the three and nine months ended September 30, 2015 are not indicative of the results that may be expected for the year ending December 31, 2015 because, among other reasons, such results can vary depending on the timing of progress achieved and changes in estimated profitability of projects being reported.

 

The Company considers events or transactions that occur after the balance sheet date but before the financial statements are issued to provide additional evidence relative to certain estimates or to identify matters that require additional disclosures.

 

 

(2)     Significant Accounting Policies

 

The significant accounting policies followed by the Company and its subsidiaries in preparing its consolidated financial statements are set forth in Note 1. Description of Business and Summary of Significant Accounting Policies of the Notes to Consolidated Financial Statements in Part IV, Item 15. Exhibits and Financial Statement Schedules, included in the Company’s Annual Report on Form 10-K for the year ended December 31, 2014.

 

Recently Issued Accounting Pronouncements

 

In May 2014, the FASB issued Accounting Standards Update (“ASU”) ASU No. 2014-09, Revenue from Contracts with Customers (Topic 606), which supersedes the revenue recognition requirements in ASC 605, Revenue Recognition. This ASU addresses when an entity should recognize revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the entity expects to be entitled in exchange for those goods or services. In August 2015, the FASB issued ASU No. 2015-14, Revenue from Contracts with Customers: (Topic 606): Deferral of the Effective Date, which defers the effective date to annual reporting periods beginning after December 15, 2017, including interim periods within that reporting period. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

 

In June 2014, the FASB issued ASU No. 2014-12, Compensation — Stock Compensation (Topic 718): Accounting for Share-Based Payments When the Terms of an Award Provide That a Performance Target Could Be Achieved after the Requisite Service Period, clarifying the recognition timing of expense associated with certain performance-based stock awards when the performance target that affects vesting could be achieved after the requisite service period. This ASU is an update to FASB ASC Topic 718 and is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015 with earlier adoption permitted. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements.

 

In February 2015, the FASB issued ASU No. 2015-02, Consolidation (Topic 810). The goal of this ASU is to reduce the potentially distortive impact on reporting entities’ consolidated financial statements resulting from the consolidation of certain legal entities, including joint ventures and variable interest entities. This ASU is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

In April 2015, the FASB issued ASU 2015-03, Interest – Imputation of Interest (Subtopic 835-30). This ASU requires that debt issuance costs related to a recognized debt liability be presented in the balance sheet as a direct deduction from the carrying amount of

9


 

that debt liability, consistent with debt discounts. In August 2015, the FASB also issued ASU 2015-15, Interest—Imputation of Interest (Subtopic 835-30): Presentation and Subsequent Measurement of Debt Issuance Costs Associated With Line-of-Credit Arrangements — Amendments to SEC Paragraphs Pursuant to Staff Announcement at June 18, 2015, EITF Meeting. This update allows an entity to defer and present debt issuance costs related to line-of-credit arrangements as an asset and subsequently amortize the deferred debt issuance costs ratably over the term of the line-of-credit arrangement, regardless of whether there are any outstanding borrowings on the line-of-credit arrangement. These ASUs are effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The adoption of these ASUs is not expected to have a material impact on the Company’s financial statements.

Use of and Changes in Estimates

 

The Company’s construction business involves making significant estimates and assumptions in the normal course of business relating to its contracts and its joint venture contracts. Management focuses on evaluating the performance of contracts individually. These estimates can vary in the normal course of business as projects progress, when estimated productivity assumptions change based on experience to date and uncertainties are resolved. Change orders and claims, as well as changes in related estimates of costs to complete, are considered revisions in estimates. The Company uses the cumulative catch-up method applicable to construction contract accounting to account for revisions in estimates. The impact on operating margin in a reporting period and future periods from a change in estimate will depend on the stage of contract completion.

 

In the third quarter of 2015, the Company recorded a  charge for an adverse legal decision related to a long-standing litigation matter, for which the Company assumed liability as part of an acquisition in 2011. This charge resulted in a decrease of $23.9 million in income from construction operations, $14.0 million in net income and $0.28 in diluted earnings per share (for further information, refer to the Brightwater Matter discussion in Note 7. Contingencies and Commitments and Note 16. Subsequent Event). Additionally, in the third quarter of 2015, the Company recorded favorable adjustments for a Civil segment runway reconstruction project related to the estimated cost to complete and the achievement of certain performance-based milestones that resulted in an increase of $13.7 million in income from construction operations, $7.9 million in net income and $0.16 in diluted earnings per share. Previously, in the second quarter of 2015, the Company recorded a significant adverse change in the estimated cost to complete a Building segment project, which is substantially complete and resulted in a decrease of $14.7 million in income from construction operations, $8.7 million in net income and $0.17 in diluted earnings per share. There were other immaterial changes in estimates for these projects during the nine months ended September 30, 2015; these immaterial changes offset each other.

 

During the three and nine months ended September 30, 2014, the Company's income from construction operations was positively impacted by $15.8 million and $30.6 million, respectively, because of changes in the estimated recoveries on two Civil segment projects and a Building segment project. These changes in estimates were driven by changes in cost recovery assumptions based on legal rulings pertaining to the Civil segment projects that were issued during the second quarter of 2014, as well as agreements reached with a customer regarding the Building segment project in the third quarter of 2014. The Building project change in estimate resulted in a $14.1 million increase in income from construction operations in the third quarter of 2014. With respect to the two Civil segment projects, during the nine months ended September 30, 2014, there was a $25.9 million increase and a $9.4 million decrease in income from construction operations. The above changes in estimates also resulted in increases of $9.5 million and $18.3 million in net income, and $0.19 and $0.37 in diluted earnings per share during the three and nine months ended September 30, 2014, respectively.

 

The above were the only changes in estimates considered individually material to the Company’s results of operations during the periods presented herein.

 

 

(3)     Cash and Cash Equivalents and Restricted Cash

 

Cash and cash equivalents include short-term, highly liquid investments with original maturities of three months or less when acquired.

 

Cash and cash equivalents, as reported in the accompanying Consolidated Condensed Balance Sheets, consist of amounts held by the Company that are available for general corporate purposes and the Company’s proportionate share of amounts held by construction joint ventures that are available only for joint venture-related uses, including future distributions to joint venture partners. Restricted cash is primarily held to secure insurance-related contingent obligations, such as insurance claim deductibles, in lieu of letters of credit.

 

10


 

Cash and cash equivalents and restricted cash consisted of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30,

 

December 31,

 

2015

 

2014

 

(in thousands)

Corporate cash and cash equivalents (available for general corporate purposes)

$

24,102 

 

$

40,846 

Company's share of joint venture cash and cash equivalents (available only for joint venture purposes, including future distributions)

 

72,792 

 

 

94,737 

Total Cash and Cash Equivalents

$

96,894 

 

$

135,583 

 

 

 

 

 

 

Restricted Cash

$

38,572 

 

$

44,370 

 

 

 

(4)     Costs and estimated earnings in excess of billings

 

Costs and estimated earnings in excess of billings related to the Company’s contracts and joint venture contracts consisted of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30,

 

December 31,

 

2015

 

2014

 

(in thousands)

Unbilled costs and profits incurred to date (a)

$

275,079 

 

$

253,078 

Unapproved change orders

 

312,090 

 

 

161,375 

Claims

 

296,640 

 

 

311,949 

 

$

883,809 

 

$

726,402 

 


(a) Represents the excess of contract costs and profits recognized to date on the percentage of completion accounting method over the amount of contract billings to date on certain contracts. 

 

Of the balance of “Unapproved change orders” and “Claims” included above in costs and estimated earnings in excess of billings at September 30, 2015 and December 31, 2014,  approximately $41.5 million and $38.4 million, respectively, are the amounts subject to pending litigation or dispute resolution proceedings as described in Note 7. Contingencies and Commitments. These amounts are management’s estimate of the probable cost recovery from the disputed claims considering such factors as evaluation of legal entitlement, settlements reached to date and experience with the customer. In the event that future facts and circumstances, including the resolution of disputed claims, cause a reduction in the aggregate amount of the estimated probable cost recovery from the disputed claims, the amount of such reduction will be recorded against earnings in the relevant future period.

 

The prerequisite for billing “Unbilled costs and profits incurred to date” is provided in the defined billing terms of each of the applicable contracts. The prerequisite for billing “Unapproved change orders” or “Claims” is the final resolution and agreement between the parties.

 

 

(5)     Fair Value Measurements

 

The Company measures certain financial instruments, including cash and cash equivalents, such as money market funds, at fair value. The fair values were determined based on a three-tier valuation hierarchy for disclosure of significant inputs. These hierarchical tiers are defined as follows:

 

Level 1 — inputs are unadjusted quoted prices in active markets for identical assets or liabilities.

 

Level 2 — inputs are other than quoted prices in active markets that are either directly or indirectly observable through market corroboration.

 

Level 3 — inputs are unobservable inputs in which little or no market data exists, therefore requiring an entity to develop its own assumptions based on the best information available in the circumstances.

 

The carrying amount of cash and cash equivalents approximates fair value due to the short-term nature of these items. The carrying value of receivables, payables and other amounts arising out of normal contract activities, including retainage, which may be settled

11


 

beyond one year, is estimated to approximate fair value. Of the Company’s long-term debt, the fair values of the fixed rate senior unsecured notes as of September 30, 2015 and December 31, 2014 were $306.4 million and $310.3 million, respectively, compared to the carrying value of $299.0 million and $298.8 million as of September 30, 2015 and December 31, 2014, respectively. The fair value of the senior unsecured notes was estimated using Level 1 inputs based on market quotations including broker quotes or interest rates for the same financial instruments at September 30, 2015 and December 31, 2014. The carrying values of the remaining balance of the Company’s long-term debt of $533.2 million and $566.6 million at September 30, 2015 and December 31, 2014, respectively, were estimated to approximate their fair values.

 

The following is a summary of financial statement items carried at estimated fair values measured on a recurring basis as of the dates presented:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Fair Value Measurements Using

 

 

 

 

 

 

 

 

 

Significant

 

 

 

 

 

 

 

 

 

Quoted prices

 

 

other

 

 

Significant

 

 

 

Total

 

 

in active

 

 

observable

 

 

unobservable

 

 

 

Carrying

 

 

markets

 

 

inputs

 

 

inputs

As of September 30, 2015

 

 

Value

 

 

(Level 1)

 

 

(Level 2)

 

 

(Level 3)

 

 

(in thousands)

Assets:

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents (a)

 

$

96,894 

 

$

96,894 

 

$

 —

 

$

 —

Restricted cash (a)

 

 

38,572 

 

 

38,572 

 

 

 —

 

 

 —

Investments in lieu of retainage (b)

 

 

37,617 

 

 

30,973 

 

 

6,644 

 

 

 —

Total

 

$

173,083 

 

$

166,439 

 

$

6,644 

 

$

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

Liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

Interest rate swap contract (c)

 

$

130 

 

$

 —

 

$

130 

 

$

 —

Contingent consideration (d)

 

 

26,181 

 

 

 —

 

 

 —

 

 

26,181 

 

 

$

26,311 

 

$

 —

 

$

130 

 

$

26,181 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Fair Value Measurements Using

 

 

 

 

 

 

 

 

 

Significant

 

 

 

 

 

 

 

 

 

Quoted prices

 

 

other

 

 

Significant

 

 

 

Total

 

 

in active

 

 

observable

 

 

unobservable

 

 

 

Carrying

 

 

markets

 

 

inputs

 

 

inputs

As of December 31, 2014

 

 

Value

 

 

(Level 1)

 

 

(Level 2)

 

 

(Level 3)

 

 

(in thousands)

Assets:

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents (a)

 

$

135,583 

 

$

135,583 

 

$

 —

 

$

 —

Restricted cash (a)

 

 

44,370 

 

 

44,370 

 

 

 —

 

 

 —

Investments in lieu of retainage (b)

 

 

33,224 

 

 

25,761 

 

 

7,463 

 

 

 —

Total

 

$

213,177 

 

$

205,714 

 

$

7,463 

 

$

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

Liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

Interest rate swap contract (c)

 

$

381 

 

$

 —

 

$

381 

 

$

 —

Contingent consideration (d)

 

 

24,814 

 

 

 —

 

 

 —

 

 

24,814 

 

 

$

25,195 

 

$

 —

 

$

381 

 

$

24,814 

 


(a)

Cash, cash equivalents and restricted cash consist primarily of money market funds with original maturity dates of three months or less, for which fair value is determined through quoted market prices.

(b)

Investments in lieu of retainage are classified as account receivables, including retainage and are comprised primarily of money market funds for which fair value is determined through quoted market prices. Investment in lieu of retainage also includes U.S. Treasury Notes and other municipal bonds for which fair value is determined through quoted market prices and other similar high quality investments whose values are determined from readily-available pricing sources for comparable instruments.

(c)

As discussed in Note 10. Financial Commitments, the Company entered into a swap agreement with Bank of America, N.A. to establish a long-term interest rate for its former $200 million five-year term loan. The swap agreement became effective for the

12


 

term loan principal balance outstanding at January 31, 2012. This term loan was paid off and the then current amount refinanced on June 5, 2014, providing for a $250 million term loan maturing on June 5, 2019. The interest rate swap continues on its original basis for the initial term and amount and finalizes on June 30, 2016. Bank of America calculates the fair market value of the interest rate swap liability by utilizing a mark-to-market valuation model that is based on current observable interest rates, expected future interest rates and the Company’s credit risk. The Company reviews the mark-to-market valuation when determining the fair value of the interest rate swap liability to be recognized. This liability is classified as a component of other long-term liabilities.

(d)

The liabilities listed as of September 30, 2015 and December 31, 2014 above represent the contingent consideration for the Company’s acquisitions in 2011.

 

The Company did not have any transfers between Levels 1 and 2 of financial assets or liabilities that are fair valued on a recurring basis during the three and nine months ended September 30, 2015 and 2014.

 

The following is a summary of changes in Level 3 liabilities measured at fair value on a recurring basis during the three and nine months ended September 30, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingent

 

 

Consideration

 

 

(in thousands)

Balance at December 31, 2014

 

$

24,814 

Fair value adjustments included in other income (expense), net

 

 

746 

Contingent consideration settled

 

 

 —

Balance at March 31, 2015

 

$

25,560 

Fair value adjustments included in other income (expense), net

 

 

774 

Contingent consideration settled

 

 

 —

Balance at June 30, 2015

 

$

26,334 

Fair value adjustments included in other income (expense), net

 

 

(153)

Contingent consideration settled

 

 

 —

Balance at September 30, 2015

 

$

26,181 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingent

 

 

Consideration

 

 

(in thousands)

Balance at December 31, 2013

 

$

46,022 

Fair value adjustments included in other income (expense), net

 

 

3,404 

Contingent consideration settled

 

 

(1,031)

Balance at March 31, 2014

 

$

48,395 

Fair value adjustments included in other income (expense), net

 

 

2,162 

Contingent consideration settled

 

 

(229)

Balance at June 30, 2014

 

$

50,328 

Fair value adjustments included in other income (expense), net

 

 

26 

Contingent consideration settled

 

 

(25,170)

Balance at September 30, 2014

 

$

25,184 

 

 

The fair values of the contingent consideration were estimated by discounting estimated future payments to their present value using a weighted-average cost of capital at a discount rate, which ranged from 14% to 18%, depending on the entity acquired. This approach requires management to project revenues, operating expenses, working capital investment, capital spending and cash flows for the acquired entities over a multi-year period.

 

 

(6)     Goodwill and Intangible Assets

 

The Company tests goodwill and intangible assets with indefinite lives for impairment by applying a fair value test in the fourth quarter of each year and between annual tests if events occur or circumstances change that suggest a material adverse change to the most recently concluded valuation. The Company did not observe any changes in facts or circumstances during the three and nine months ended September 30, 2015 that would indicate a material adverse change to the fourth quarter 2014 concluded valuation.

13


 

 

The Company tests intangible assets with finite lives for impairment whenever events or circumstances indicate that the carrying value may not be recoverable. The Company did not observe any events or circumstances during the three and nine months ended September 30, 2015 that would indicate that the carrying value of its intangible assets may not be recoverable.

 

The following table presents the carrying amount of goodwill allocated to the Company’s reporting units as of September 30, 2015: 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

Civil

 

Building

 

Contractors

 

Total

 

(in thousands)

Gross Goodwill Balance

$

492,074 

 

$

424,724 

 

$

156,193 

 

$

1,072,991 

Accumulated Impairment

 

(76,716)

 

 

(411,269)

 

 

 —

 

 

(487,985)

Balance at December 31, 2014

$

415,358 

 

$

13,455 

 

$

156,193 

 

$

585,006 

Current year activity

 

 —

 

 

 —

 

 

 —

 

 

 —

Balance at September 30, 2015

$

415,358 

 

$

13,455 

 

$

156,193 

 

$

585,006 

 

Intangible assets consist of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30, 2015

 

Weighted

 

 

 

 

 

 

 

Accumulated

 

 

 

 

Average

 

 

 

 

Accumulated

 

Impairment

 

Carrying

 

Amortization

 

Cost

 

Amortization

 

Charge

 

Value

 

Period

 

(in thousands)

 

 

Trade names (non-amortizable)

$

117,600 

 

$

 —

 

$

(67,190)

 

$

50,410 

 

Indefinite

Trade names (amortizable)

 

74,350 

 

 

(10,695)

 

 

(23,232)

 

 

40,423 

 

20 years

Contractor license

 

6,000 

 

 

 —

 

 

(6,000)

 

 

 —

 

Indefinite

Customer relationships

 

39,800 

 

 

(16,563)

 

 

(16,645)

 

 

6,592 

 

11.4 years

Construction contract backlog

 

73,706 

 

 

(73,706)

 

 

 —

 

 

 —

 

N/A

Total

$

311,456 

 

$

(100,964)

 

$

(113,067)

 

$

97,425 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

December 31, 2014

 

Weighted

 

 

 

 

 

 

 

Accumulated

 

 

 

 

Average

 

 

 

 

Accumulated

 

Impairment

 

Carrying

 

Amortization

 

 

Cost

 

Amortization

 

Charge

 

Value

 

Period

 

(in thousands)

 

 

Trade names (non-amortizable)

$

117,600 

 

$

 —

 

$

(67,190)

 

$

50,410 

 

Indefinite

Trade names (amortizable)

 

74,350 

 

 

(8,829)

 

 

(23,232)

 

 

42,289 

 

20 years

Contractor license

 

6,000 

 

 

 —

 

 

(6,000)

 

 

 —

 

Indefinite

Customer relationships

 

39,800 

 

 

(15,600)

 

 

(16,645)

 

 

7,555 

 

11.4 years

Construction contract backlog

 

73,706 

 

 

(73,706)

 

 

 —

 

 

 —

 

3.6 years

Total

$

311,456 

 

$

(98,135)

 

$

(113,067)

 

$

100,254 

 

 

 

Amortization expense was $0.9 million and $2.8 million for the three and nine months ended September 30, 2015 compared to $3.1 million and $10.4 million during the same periods in 2014. The following table presents estimated amortization expense of intangible assets for the remainder of 2015 and for the succeeding years:

 

 

 

 

 

 

 

 

 

Fiscal Year

 

 

(in millions)

2015 (three months remaining)

 

$

0.9 

2016

 

 

3.5 

2017

 

 

3.5 

2018

 

 

3.5 

2019

 

 

3.5 

Thereafter

 

 

32.1 

Total

 

$

47.0 

 

14


 

 

(7) Contingencies and Commitments

 

The Company and certain of its subsidiaries are involved in litigation and are contingently liable for commitments and performance guarantees arising in the ordinary course of business. The Company and certain of its clients have made claims arising from the performance under their contracts. The Company recognizes certain significant claims for recovery of incurred cost when it is probable that the claim will result in additional contract revenue and when the amount of the claim can be reliably estimated. These assessments require judgments concerning matters such as litigation developments and outcomes, the anticipated outcome of negotiations, the number of future claims and the cost of both pending and future claims. In addition, because most contingencies are resolved over long periods of time, liabilities may change in the future due to various factors.

 

Several matters are in the litigation and dispute resolution process and represent contingent losses or gains to the Company. The following discussion provides a background and current status of the more significant matters.

 

Tutor-Saliba-Perini Joint Venture vs. Los Angeles MTA Matter

 

During 1995, Tutor-Saliba-Perini (“Joint Venture”) filed a complaint in the Superior Court of the State of California for the County of Los Angeles against the Los Angeles County Metropolitan Transportation Authority (“LAMTA”), seeking to recover costs for extra work required by LAMTA in connection with the construction of certain tunnel and station projects, all of which were completed by 1996. In 1999, LAMTA countered with civil claims under the California False Claims Act against the Joint Venture, Tutor-Saliba and the Company jointly and severally (together, “TSP”), and obtained a judgment that was reversed on appeal and remanded for retrial before a different judge.

 

Between 2005 and 2010, the court granted certain Joint Venture motions and LAMTA capitulated on others, which reduced the number of false claims LAMTA may seek and limited LAMTA’s claims for damages and penalties. In September 2010, LAMTA dismissed its remaining claims and agreed to pay the entire amount of the Joint Venture’s remaining claims plus interest. In the remanded proceedings, the Court subsequently entered judgment in favor of TSP and against LAMTA in the amount of $3.0 million after deducting $0.5 million, representing the tunnel handrail verdict plus accrued interest against TSP. The parties filed post-trial motions for costs and fees. The Court ruled that TSP’s sureties could recover costs, LAMTA could recover costs for the tunnel handrail trial, and no party could recover attorneys’ fees. TSP appealed the false claims jury verdict on the tunnel handrail claim and other issues, including the denial of TSP’s and its sureties’ request for attorneys’ fees. LAMTA subsequently filed its cross-appeal. In June 2014, the Court of Appeal issued its decision reversing judgment on the People’s Unfair Competition claim and reversing the denial of TSP’s Sureties’ request for attorney’s fees and affirming the remainder of the judgment. In January 2015, payment was made by LAMTA in the amount of $3.8 million in settlement of all outstanding issues except for the attorney’s fees for TSP’s Sureties.

 

On May 1, 2015, TSP’s Surety’s motions for attorney’s fees were heard, and the Court issued its written ruling on May 5, 2015 in favor of TSP’s Sureties for a total award of $2.1 million. The Court denied adding interest onto these amounts. On June 26, 2015, payment was made by LAMTA for these amounts, which was received by TSP. On June 23, 2015, TSP’s Sureties filed a Notice of Appeal challenging the amount awarded to seek an increase. The appeal remains pending while the Court prepares the trial record for the Court of Appeal.

 

The Company does not expect ultimate resolution of this matter to have any material effect on its consolidated financial statements.

 

Long Island Expressway/Cross Island Parkway Matter

 

The Company reconstructed the Long Island Expressway/Cross Island Parkway Interchange project for the New York State Department of Transportation (the “NYSDOT”). The $130 million project was substantially completed in January 2004 and was accepted by the NYSDOT as finally complete in February 2006. The Company incurred significant added costs in completing its work and suffered extended schedule costs due to numerous design errors, undisclosed utility conflicts, lack of coordination with local agencies and other interferences for which the Company believes that the NYSDOT is responsible.

 

In March 2011, the Company filed its claim and complaint with the New York State Court of Claims and served to the New York State Attorney General’s Office, seeking damages in the amount of $53.8 million. In May 2011, the NYSDOT filed a motion to dismiss the Company’s claim on the grounds that the Company had not provided required documentation for project closeout and filing of a claim. In September 2011, the Company reached agreement on final payment with the Comptroller’s Office on behalf of the NYSDOT which resulted in an amount of $0.5 million payable to the Company and formally closed out the project, which allowed the Company’s claim to be re-filed. The Company re-filed its claim in the amount of $53.8 million with the NYSDOT in February 2012 and with the Court of Claims in March 2012. In May 2012, the NYSDOT served its answer and counterclaims in the amount of $151 million alleging fraud in the inducement and punitive damages related to disadvantaged business enterprise (“DBE”) requirements for the project. The Court subsequently ruled that NYSDOT’s counterclaims may only be asserted as a defense and offset to the Company’s claims and not as affirmative claims. In November 2014, the Appellate Division First Department affirmed the dismissal

15


 

of the City’s affirmative defenses and counterclaims based on DBE fraud. The Company does not expect the counterclaims to have any material effect on its consolidated financial statements. Discovery is ongoing.

 

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Fontainebleau Matter

 

Desert Mechanical Inc. (“DMI”) and Fisk Electric Company (“Fisk”), wholly owned subsidiaries of the Company, were subcontractors on the Fontainebleau Project in Las Vegas (“Fontainebleau”), a hotel/casino complex with approximately 3,800 rooms. In June 2009, Fontainebleau filed for bankruptcy protection, under Chapter 11 of the U.S. Bankruptcy Code, in the Southern District of Florida. Fontainebleau is headquartered in Miami, Florida.

 

DMI and Fisk filed liens in Nevada for approximately $44 million, representing unreimbursed costs to date and lost profits, including anticipated profits. Other unaffiliated subcontractors have also filed liens. In June 2009, DMI filed suit against Turnberry West Construction, Inc. (“Turnberry”), the general contractor, in the 8th Judicial District Court, Clark County, Nevada, and in May 2010, the court entered an order in favor of DMI for approximately $45 million.

 

In January 2010, the Bankruptcy Court approved the sale of the property to Icahn Nevada Gaming Acquisition, LLC, and this transaction closed in February 2010. As a result of a July 2010 ruling relating to certain priming liens, there was approximately $125 million set aside from this sale, which is available for distribution to satisfy the creditor claims based on seniority. At that time, the total estimated sustainable lien amount was approximately $350 million. The project lender filed suit against the mechanic’s lien claimants, including DMI and Fisk, alleging that certain mechanic’s liens are invalid and that all mechanic’s liens are subordinate to the lender’s claims against the property. The Nevada Supreme Court ruled in October 2012 in an advisory opinion at the request of the Bankruptcy Court that lien priorities would be determined in favor of the mechanic lien holders under Nevada law.

 

In October 2013, a settlement was reached by and among the Statutory Lienholders and the other interested parties. The agreed upon settlement has not had an impact on the Company’s recorded accounting position as of the period ended September 30, 2015. The execution of that settlement agreement continues under the supervision of a mediator appointed by the Bankruptcy Court.

 

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Honeywell Street/Queens Boulevard Bridges Matter

 

In 1999, the Company was awarded a contract for reconstruction of the Honeywell Street/Queens Boulevard Bridges project for the City of New York (the “City”). In June 2003, after substantial completion of the project, the Company initiated an action to recover $8.8 million in claims against the City on behalf of itself and its subcontractors. In March 2010, the City filed counterclaims for $74.6 million and other relief, alleging fraud in connection with the DBE requirements for the project. In May 2010, the Company served the City with its response to the City’s counterclaims and affirmative defenses. In August 2013, the Court granted the Company’s motion to dismiss the City’s affirmative defenses and counterclaims relating to fraud. In September 2013, the City filed a Notice of Appeal to the Court’s decision; said appeal was dismissed by the Appellate Court in November 2014.  Discovery is ongoing.

 

The Company does not expect ultimate resolution of this matter to have any material effect on its consolidated financial statements.

 

Westgate Planet Hollywood Matter

 

Tutor-Saliba Corporation (“TSC”), a wholly owned subsidiary of the Company, contracted to construct a time share development project in Las Vegas which was substantially completed in December 2009. The Company’s claims against the owner, Westgate Planet Hollywood Las Vegas, LLC (“WPH”), relate to unresolved owner change orders and other claims. The Company filed a lien on the project in the amount of $23.2 million, and filed its complaint with the District Court, Clark County, Nevada. Several subcontractors have also recorded liens, some of which have been released by bonds and some of which have been released as a result of subsequent payment. WPH has posted a mechanic’s lien release bond for $22.3 million.

 

WPH filed a cross-complaint alleging non-conforming and defective work for approximately $51 million, primarily related to alleged defects, misallocated costs, and liquidated damages. WPH revised the amount of their counterclaims to approximately $45 million.

 

Following multiple post-trial motions, final judgment was entered in this matter on March 20, 2014. TSC was awarded total judgment in the amount of $19.7 million on its breach of contract claim, which includes an award of interest up through the date of judgment, plus attorney’s fees and costs. WPH has paid $0.6 million of that judgment. WPH was awarded total judgment in the amount of $3.1 

16


 

million on its construction defect claims, which includes interest up through the date of judgment. The awards are not offsetting. WPH and its Sureties have filed a notice of appeal. TSC has filed a notice of appeal on the defect award. In July 2014, the Court ordered WPH to post an additional supersedeas bond on appeal, in the amount of $1.7 million, in addition to the lien release bond of $22.3 million, which increases the security up to $24.0 million. The Nevada Supreme Court is anticipated to rule on this matter during the first quarter of 2016.

 

The Company does not expect ultimate resolution of this matter to have any material effect on its consolidated financial statements. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Brightwater Matter

 

In 2006, the Department of Natural Resources and Parks Wastewater Treatment Division of King County (“King County”), as Owner, and Vinci Construction Grands Projects/Parsons RCI/Frontier-Kemper, Joint Venture (“VPFK”), as Contractor, entered into a contract to construct the Brightwater Conveyance System and tunnel sections in Washington State. Frontier-Kemper, a 20% minority partner in the joint venture, is a wholly owned subsidiary of the Company that was acquired in June 2011.

 

In April 2010, King County filed a lawsuit alleging damages in the amount of $74 million, plus costs, for VPFK’s failure to complete specified components of the project in the King County Superior Court, State of Washington. Shortly thereafter, VPFK filed a counterclaim in the amount of approximately $75 million, seeking reimbursement for additional costs incurred as a result of differing site conditions, King County’s defective specifications, and for damages sustained on VPFK’s tunnel boring machines (“TBM”), and increased costs as a result of hyperbaric interventions. VPFK’s claims were presented to a Dispute Resolution Board (“DRB”) who generally found that King County was liable to VPFK for VPFK’s claims for encountering differing site conditions, including damages to the TBM, but not on claims related to defective design specifications. From June through August 2012, each party filed several motions for summary judgment on certain claims and requests in preparation for trial, which were heard and ruled upon by the Court. The Court granted and denied various requests of each party related to evidence and damages.

 

In December 2012, a jury verdict was received in favor of King County in the amount of $155.8 million and a verdict in favor of VPFK in the amount of $26.3 million. In late April 2013, the Court ruled on post-trial motions and ordered VPFK’s sureties to pay King County’s attorneys’ fees and costs in the amount of $14.7 million. All other motions were denied. On May 7, 2013, VPFK paid the full verdict amount and the associated fees, thus terminating any interest on the judgment. VPFK’s notice of appeal was filed on May 31, 2013. King County has appealed approximately $17.0 million of the verdict award in VPFK’s favor and VPFK’s sureties have appealed the Court’s order granting King County’s request for legal fees and costs. Oral argument was held on March 9, 2015.

 

The Company received notice on November 9, 2015, that the Court of Appeals of the State of Washington filed their decision that day, which affirmed the trial court’s judgment and denied the appeals brought forth by both VPFK and King County. Management booked the impact of this judgment during the third quarter of 2015, resulting in a non-cash, pre-tax charge of $23.9 million. The Court granted King County’s request for recovery of reasonable attorney fees and appellate costs but did not quantify an amount. The Company does not expect the award of attorney fees, while not specifically determinable, to have a material financial impact on its consolidated financial statements.

 

156 Stations Matter

 

In December 2003, Five Star Electric Corporation (“FSE”), a wholly owned subsidiary of the Company, entered into an agreement with the Prime Contractor Transit Technologies, L.L.C (“Transit”), a Consortium member of Siemens Transportation Transit Technologies, L.L.C (“Siemens”), to assist in the installation of new public address and customer information screens system for each of the 156 stations for the New York City Transit Authority (“NYCTA”) as the owner.

 

In June 2012, an arbitration panel awarded FSE a total of approximately $11.9 million. Subsequently, the Court affirmed FSE’s position, however, decided that only $8.5 million of the total arbitration award of $11.9 million can be recovered against the payment bond. In December 2014, FSE filed its reply for the motion for re-argument with regard to the reduction in recoverable costs against the payment bond.

 

This matter was fully settled in April 2015 and payment was received. The settlement amount was consistent with the Company’s recorded position and, accordingly, the settlement did not have a material impact on the Company’s consolidated financial statements.

 

U.S. Department of Commerce, National Oceanic and Atmospheric Administration Matter

 

Rudolph and Sletten, Inc. (“R&S”), a wholly owned subsidiary of the Company, entered into a contract with the United States Department of Commerce, National Oceanic and Atmospheric Administration (“NOAA” or “Owner”) for the construction of a 287,000 square-foot facility for NOAA’s Southwest Fisheries Science Center Replacement Headquarters and Laboratory in La Jolla,

17


 

California. The contract work began on May 24, 2010, and was substantially completed in September 2012. R&S incurred significant additional costs as a result of a design that contained errors and omissions, NOAA’s unwillingness to correct design flaws in a timely fashion and a refusal to negotiate the time and pricing associated with change order work.

 

R&S has filed three certified claims against NOAA for contract adjustments related to the unresolved Owner change orders, delays, design deficiencies and other claims. The First Certified Claim was submitted on August 20, 2013, in the amount of $26.8 million ("First Certified Claim") and the Second Certified Claim was submitted on October 30, 2013, in the amount of $2.6 million ("Second Certified Claim") and the Third Certified Claim was submitted on October 1, 2014 in the amount of $0.7 million (“Third Certified Claim”).  

 

NOAA requested an extension to issue a decision on the First Certified Claim and on the Third Certified Claim, but did not request an extension of time to review the Second Certified Claim. On January 6, 2014, R&S filed suit in the United States Federal Court of Claims on the Second Certified Claim plus interest and attorney's fees and costs. This was followed by a submission of a law suit on the First Certified Claim on July 31, 2014. In February 2015 the Court denied NOAA’s motion to dismiss the Second Certified Claim. In March 2015 the Contracting Officer issued decisions on all Claims accepting a total of approximately $1.0 million of claims and denying approximately $29.5 million of claims. On April 14, 2015, the Court consolidated the cases and has commenced discovery through July 2016. No trial date has been set.

 

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Five Star Electric Matter

 

In the third quarter of 2015 Five Star Electric Corp ("Five Star"), a subsidiary of the Company that was acquired in 2011, entered into a tolling agreement related to an ongoing investigation being conducted by the United States Attorney for the Eastern District of New York (“USAO EDNY”). The tolling agreement extends the statute of limitations to December 31, 2015 to avoid the expiration of any unexpired statute of limitations while the investigation is pending. Five Star has been cooperating with the USAO EDNY since late June 2014, when it was first made aware of the investigation, and has been providing information related to its use of certain minority-owned, women-owned, small and disadvantaged business enterprises and, in addition, most recently information regarding certain of Five Star’s employee compensation, benefit and tax practices.  The investigation covers the period of 2005-2014.

 

The Company cannot predict the ultimate outcome of the investigation and cannot accurately estimate any potential liability that Five Star or the Company may incur or the impact of the results of the investigation on Five Star or the Company.

 

Alaskan Way Viaduct Matter

 

In January 2011, Seattle Tunnel Partners (“STP”), a joint venture between Dragados USA, Inc. and the Company, entered into a design-build contract with the Washington State Department of Transportation ("WSDOT") for the construction of a large diameter bored tunnel in downtown Seattle, King County, Washington to replace the Alaskan Way Viaduct, also known as State Route 99. 

 

The construction of the large diameter bored tunnel requires the use of a tunnel boring machine (“TBM”). In December 2013, the TBM struck a steel pipe, installed by WSDOT as a well casing for an exploratory well. The TBM was damaged and was required to be shut down for repair. STP has asserted that the steel pipe casing was a differing site condition that WSDOT failed to properly disclose. The Disputes Review Board mandated by the Contract to hear disputes issued a decision finding the steel casing was a Type I differing site condition. WSDOT has not accepted that finding.

 

The TBM was insured under a Builder’s Risk Insurance Policy (“the Policy”) with Great Lakes Reinsurance (UK) PLC and a consortium of other insurers (the “Insurers”). STP submitted the claims to the insurer and requested interim payments under the Policy.  The insurers refused to pay and denied coverage. In June 2015, STP filed a lawsuit in the King County Superior Court, State of Washington seeking declaratory relief concerning contract interpretation as well as damages as a result of the Insurers’ breach of its obligations under the terms of the Policy, and added WSDOT as a defendant since WSDOT is an insured under the Policy and had filed its own claim for damages. In August 2015, the Insurers filed a complaint in the Supreme Court, State of New York County seeking declaratory relief concerning contract interpretation. The Court in New York has stayed the Insurers’ lawsuit pending a decision from the Washington State Court.

 

In October 2015, WSDOT filed a complaint against STP in the King County Superior Court, State of Washington for breach of contract and declaratory relief concerning contract interpretation.

 

As of September 2015, the Company has concluded that the potential for a material adverse financial impact due to the Insurer’s and WSDOT’s respective legal actions are neither probable nor remote. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final

18


 

recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

 

(8)     Income Taxes

 

The Company’s income tax provision was $14.3 million and $25.6 million for the three and nine months ended September 30, 2015 compared to $22.9 million and $53.3 million for the same periods in 2014. The effective income tax rate was 42.0% and 41.1% for the three and nine months ended September 30, 2015, compared to 39.0% and 39.9% for the same periods in 2014. The largest contributor to the increase for both periods was increased activity in higher state tax jurisdictions. Higher compensation expense also contributed to the increase, particularly for the three month comparison period.

 

As of September 30, 2015, the total amount of unrecognized tax benefits, including related interest and penalties was $7.6 million. If the total amount of unrecognized tax benefits was recognized, $6.7 million of unrecognized tax benefits and $0.9 million of interest would decrease the effective tax rate.

 

 

(9)     Stock-Based Compensation

 

The Company is authorized to grant up to 8,500,000 stock-based compensation awards to key executives, employees, other key persons, including consultants, and directors of the Company under the Amended and Restated Tutor Perini Corporation Long-Term Incentive Plan (the “Plan”). The Plan allows stock-based compensation awards to be granted in a variety of forms, including stock options, stock appreciation rights, restricted stock unit awards, unrestricted stock awards, deferred stock awards and dividend equivalent rights. The terms and conditions of the awards granted are established by the Compensation Committee of the Company’s Board of Directors who also administers the Plan.

 

The Company intends to settle stock awards in shares upon vesting to the extent that the Company has shares available under the Plan. A total of 389,022 shares of common stock remain available for future grant under the Plan at September 30, 2015.  As a result, awards of 400,000 stock options that were made in December 2014 and March 2015 under the Plan were not deducted from the shares of common stock remaining available for future grant and these option awards, which may at the Company’s election be settled in cash, were classified as liabilities, and compensation cost for these liability-classified awards will be remeasured at each balance sheet date until such time that the Plan has been amended to increase the number of shares available. Under FASB ASC Topic 718, “Stock Compensation” (ASC 718), options or similar instruments on shares are classified as liabilities when a cash settlement feature exists in the stock based award that can be exercised only upon the occurrence of an event that is outside the employee’s control.

 

Restricted Stock Unit Awards

 

Restricted stock unit awards generally vest subject to the satisfaction of service requirements or the satisfaction of both service requirements and achievement of certain performance targets. Upon vesting, each restricted stock unit award is exchanged for one share of the Company’s common stock. The grant date fair values of these awards are determined based on the closing price of the Company’s stock on either the award date (if subject only to service conditions), or the date that the Compensation Committee establishes the applicable performance target (if subject to performance conditions). The related compensation expense is amortized over the applicable requisite service period. As of September 30, 2015, the Compensation Committee has approved the grant of an aggregate of 6,321,430 restricted stock unit awards under the 2004 Stock Option and Incentive Plan (and amendments) to eligible participants.

 

During the nine months ended September 30, 2015, the Compensation Committee established the 2015 performance targets for 321,500 restricted stock units awarded in 2015, 2013, and 2012. The restricted stock unit awards granted during the nine months ended September 30, 2015 had a weighted-average grant date fair value of $23.07.  During the nine months ended September 30, 2014, the Compensation Committee established the 2014 performance targets for 866,500 restricted stock units awarded in 2014, 2013, and 2012. The restricted stock unit awards granted during the nine months ended September 30, 2014 had a weighted-average grant date fair value of $27.33. The grant date fair value is determined based on the closing price of the Company’s common stock on the date of the grant.

 

There were 31,560 restricted stock unit awards forfeited during the nine months ended September 30, 2015.

 

During the three and nine months ended September 30, 2015, the Company recognized $2.5 million and $11.1 million, respectively, of compensation expense related to restricted stock unit awards, as compared to $3.2 million and $10.2 million during the three and nine months ended September 30, 2014. Such expense is included in general and administrative expenses in the Consolidated Condensed Statements of Operations. As of September 30, 2015, there was $12.4 million of unrecognized compensation cost related to the unvested awards which, absent significant forfeitures in the future, is expected to be recognized over a weighted-average period of approximately 1.5 years.

19


 

 

A summary of restricted stock unit awards activity for the nine months ended September 30, 2015 is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Aggregate

 

 

 

Weighted-Average

 

Intrinsic

 

Number

 

Grant Date

 

Value

 

of Shares

 

Fair Value

 

(in thousands)

Granted and Unvested - January 1, 2015

1,056,597 

 

$

26.54 

 

$

25,432 

Activity during the nine months ended September 30, 2015:

 

 

 

 

 

 

 

Vested

(370,940)

 

$

27.07 

 

$

7,983 

Granted

321,500 

 

$

23.07 

 

$

5,292 

Forfeited

(31,560)

 

$

28.19 

 

$

 —

Total Granted and Unvested - September 30, 2015

975,597 

 

$

26.70 

 

$

16,058 

Approved for grant

754,500 

 

 

(a)

 

$

12,419 

Total Awarded and Unvested - September 30, 2015

1,730,097 

 

 

(a)

 

$

28,477 

(a)

Grant date fair value cannot be determined currently because the related performance targets for future years have not yet been established by the Compensation Committee for certain grants.

 

The outstanding unvested awards at September 30, 2015 are scheduled to vest as follows, subject where applicable to the achievement of performance targets. As described above, certain performance targets are not yet established.

 

 

 

 

 

 

 

 

 

Number

Vesting Date

 

of Awards

2015

 

 -

2016

 

302,500 

2017

 

942,597 

2018

 

311,000 

2019

 

174,000 

 

 

1,730,097 

There are 30,000 of the unvested restricted stock unit awards that will vest based on the satisfaction of service requirements and 1,700,097 of the unvested restricted stock unit awards will vest based on the satisfaction of both service requirements and the achievement of performance targets.

 

Stock Options

 

Stock option awards generally vest subject to the satisfaction of service requirements or the satisfaction of both service requirements and achievement of certain performance targets. The grant date fair values of these awards are determined based on the Black-Scholes option price model on either the award date (if subject only to service conditions) or the date that the Compensation Committee establishes the applicable performance target (if subject to performance conditions). The related compensation expense is amortized over the applicable requisite service period. The exercise price of the options is equal to the closing price of the Company’s common stock on the date the awards were approved by the Compensation Committee, and the awards expire ten years from the award date. As of September 30, 2015, the Compensation Committee has approved the award of an aggregate of 3,445,465 stock options to eligible participants.

 

During the nine months ended September 30, 2015, the Compensation Committee established certain performance targets for 259,000 stock options awarded in 2015, 2014, 2013, and 2012. The stock option awards granted during the nine months ended September 30, 2015 had a weighted-average grant date fair value of $12.48. During the nine months ended September 30, 2014, the Compensation Committee established certain performance targets for 714,000 stock options awarded in 2014, 2013 and 2012. The stock option awards granted during the nine months ended September 30, 2014 had a weighted-average grant date fair value of $17.69.  

 

For the three and nine months ended September 30, 2015, the Company recognized compensation expense related to stock option awards of $1.2 million and $6.0 million, respectively, as compared to $1.3 million and $4.1 million for the three and nine months ended September 30, 2014, respectively. Such expenses are included in general and administrative expenses in the Consolidated Statements of Operations. As of September 30, 2015, there was $3.9 million of unrecognized compensation expense related to the

20


 

outstanding options, which, absent significant forfeitures in the future, is expected to be recognized over a weighted-average period of approximately 1.1 years.

 

A summary of stock option activity for the nine months ended September 30, 2015 is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted-Average

 

Number

 

Grant Date

 

Exercise

 

of Shares

 

Fair Value

 

Price

Granted and Outstanding - January 1, 2015

1,989,000 

 

$

12.75 

 

$

19.63 

Activity during the nine months ended September 30, 2015:

 

 

 

 

 

 

 

Granted

259,000 

 

$

12.48 

 

$

16.07 

Exercised

 —

 

$

 —

 

$

 —

Forfeited

 —

 

$

 —

 

$

 —

Total Granted and Outstanding - September 30, 2015

2,248,000 

 

$

11.93 

 

$

19.22 

Approved for grant

722,000 

 

 

(a)

 

$

20.58 

Total Awarded and Outstanding - September 30, 2015

2,970,000 

 

 

(a)

 

$

19.55 

 

 


(a)

Grant date fair value cannot be determined currently because the related performance targets for future years have not yet been established by the Compensation Committee for certain grants.

 

There were 1,485,000 stock options that have vested and were exercisable at September 30, 2015 at a weighted-average exercise price of $19.57 per share.

 

Of the remaining stock options outstanding, approximately  15,000 stock options will vest based on the satisfaction of service requirements and 1,470,000 stock options will vest based on the satisfaction of both service requirements and the achievement of performance targets.

 

At September 30, 2015, the outstanding stock options of 2,248,000 had an intrinsic value of $3.6 million and a weighted-average remaining contractual life of 5.4 years.

 

No stock options were granted during the third quarter of 2015. The following table details the key assumptions used in estimating the grant date fair values of stock option awards granted during the first quarter of 2015 based on the Black Scholes option pricing model using the following key assumptions:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Award Year

 

 

2015

 

 

 

2013

 

 

 

2012

 

Number of options granted during 2015

 

100,000 

 

 

 

9,000 

 

 

 

150,000 

 

Risk-free interest rate

 

1.46 

%

 

 

1.77 

%

 

 

1.15 

%

Expected life of options (years)

 

5.50 

 

 

 

5.68 

 

 

 

4.06 

 

Expected volatility of underlying stock

 

45.11 

%

 

 

43.92 

%

 

 

45.92 

%

Expected quarterly dividends (per share)

$

 —

 

 

$

 —

 

 

$

 —

 

 

 

 

(10)     Financial Commitments

 

Amended Credit Agreement

 

On June 5, 2014, the Company entered into a Sixth Amended and Restated Credit Agreement, (the “Credit Agreement”) restructuring its former $300 million revolving credit facility and $200 million Term Loan. All outstanding amounts under the Fifth Amended and Restated Credit Agreement were repaid in full using proceeds of the Credit Agreement. The new agreement provides for a $300 million revolving credit facility (the “Revolving Credit Facility") and a $250 million term loan (the “Term Loan”) with Bank of America, N.A. as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The Term Loan principal

21


 

is to be repaid on a quarterly basis, with 6.0% of the original total outstanding principal repaid in year 1, 9.0% in year 2, 12.0% in year 3, 15.0% in year 4 and 13.5% in year 5 along with a balloon payment of the remaining 44.5% due at maturity. Borrowings under the Revolving Credit Facility bear interest based either on Bank of America’s prime lending rate or the London Interbank Offered Rate (“LIBOR”) plus an applicable margin. Borrowings under the Term Loan bear interest based on LIBOR plus an applicable margin. Included in the Credit Agreement is a special provision allowing an additional accordion provision, which the Company may opt to utilize at a future date to increase either the Revolving Credit Facility or establish one or more new term loan commitments, up to an aggregate amount not to exceed $300 million. The Credit Agreement provides a sublimit for the issuance of letters of credit up to the aggregate amount of $150 million. Both the Revolving Credit Facility and the Term Loan mature on June 5, 2019.

 

The Revolving Credit Facility and Term Loan include usual and customary covenants for credit facilities of this type, including covenants providing maximum allowable ranges of consolidated leverage ratios from 3.75:1.00 to 2.75:1.00 over a range of five years and maintaining a minimum consolidated fixed charge coverage ratio of 1.25:1.00. The Credit Agreement eliminated the other covenant requirements that were formerly held under the Fifth Amended and Restated Credit Agreement.

 

Substantially all of the Company’s subsidiaries unconditionally guarantee the obligations of the Company under the Credit Agreement. The obligations under the Credit Agreement are secured by a lien on all personal property of the Company and its subsidiaries party thereto.  The Term Loan balance was $229.4 million at September 30, 2015 and $242.5 million at December 31, 2014.

 

As discussed in Note 7. Commitments and Contingencies and Note 16. Subsequent Event, during the three months ended September 30, 2015 the Company recognized a non-cash, pre-tax charge of $23.9 million as a result of an adverse ruling on the Brightwater litigation matter. The financial impact of this charge caused the Company to breach its financial covenants under the Credit Agreement. On November 13, 2015, the Company received a waiver from the Credit Agreement lenders. Therefore, the Company is not in default under the Credit Agreement.

 

The Company had $140.0 million of outstanding borrowings under its Revolving Facility as of September 30, 2015 and $130.0 million as of December 31, 2014. The net change in borrowings under the Revolving Facility comprises all “Proceeds from debt” and a significant portion of all “Repayment of debt” as presented in the Consolidated Condensed Statements of Cash Flows. The Company utilized the Revolving Facility for letters of credit in the amount of $0.2 million as of September 30, 2015 and $1.0 million as of December 31, 2014. Accordingly, at September 30, 2015, the Company had $159.8 million available to borrow under the Revolving Facility.

 

 

(11)     Earnings per Common Share

 

Basic earnings per common share were computed by dividing net income by the weighted-average number of common shares outstanding. Diluted earnings per common share were similarly computed after giving consideration to the dilutive effect of stock options and restricted stock unit awards outstanding on the weighted-average number of common shares outstanding. The computation of diluted earnings per common share for the three and nine months ended September 30, 2015 excluded the antidilutive effect of 201,764 and 110,620 restricted stock units, respectively, compared to 10,000 and 3,333 antidilutive restricted stock units for the three and nine months ended September 30, 2014, respectively. The computation of diluted earnings per common share for the three and nine months ended September 30, 2015 excluded the antidilutive effect of 1,579,667 and 908,889 stock options, respectively, compared to 5,000 and 88,333 antidilutive stock options for the three and nine months ended September 30, 2014, respectively.

 

 

22


 

 

(12)     Business Segments

 

The following table sets forth certain reportable segment information relating to the Company’s operation for the three and nine months ended September 30, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

 

 

Consolidated

(in thousands)

Civil

 

 

Building

 

Contractors

 

Totals

 

Corporate

 

Total

Three Months Ended September 30, 2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

$

604,317 

 

$

506,259 

 

$

325,365 

 

$

1,435,941 

 

$

 —

 

$

1,435,941 

Elimination of intersegment revenues

 

(64,067)

 

 

(31,135)

 

 

 —

 

 

(95,202)

 

 

 —

 

 

(95,202)

Revenues from external customers

$

540,250 

 

$

475,124 

 

$

325,365 

 

$

1,340,739 

 

$

 —

 

$

1,340,739 

Income from construction operations

$

43,183 

 

$

6,763 

 

$

4,741 

 

$

54,687 

 

$

(15,713)

(a)

$

38,974 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended September 30, 2014

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

$

496,142 

 

$

420,404 

 

$

355,932 

 

$

1,272,478 

 

$

 —

 

$

1,272,478 

Elimination of intersegment revenues

 

(13,472)

 

 

(8,317)

 

 

 —

 

 

(21,789)

 

 

 —

 

 

(21,789)

Revenues from external customers

$

482,670 

 

$

412,087 

 

$

355,932 

 

$

1,250,689 

 

$

 —

 

$

1,250,689 

Income from construction operations

$

53,684 

 

$

19,159 

 

$

10,876 

 

$

83,719 

 

$

(13,365)

(a)

$

70,354 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

 

 

Consolidated

(in thousands)

Civil

 

 

Building

 

Contractors

 

Totals

 

Corporate

 

Total

Nine Months Ended September 30, 2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

$

1,570,553 

 

$

1,394,568 

 

$

945,181 

 

$

3,910,302 

 

$

 —

 

$

3,910,302 

Elimination of intersegment revenues

 

(121,449)

 

 

(69,211)

 

 

 —

 

 

(190,660)

 

 

 —

 

 

(190,660)

Revenues from external customers

$

1,449,104 

 

$

1,325,357 

 

$

945,181 

 

$

3,719,642 

 

$

 —

 

$

3,719,642 

Income from construction operations

$

120,106 

 

$

(8,107)

 

$

29,008 

 

$

141,007 

 

$

(51,068)

(a)

$

89,939 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Nine Months Ended September 30, 2014

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

$

1,270,657 

 

$

1,122,072 

 

$

970,036 

 

$

3,362,765 

 

$

 —

 

$

3,362,765 

Elimination of intersegment revenues

 

(32,292)

 

 

(40,041)

 

 

 —

 

 

(72,333)

 

 

 —

 

 

(72,333)

Revenues from external customers

$

1,238,365 

 

$

1,082,031 

 

$

970,036 

 

$

3,290,432 

 

$

 —

 

$

3,290,432 

Income from construction operations

$

156,031 

 

$

28,656 

 

$

31,326 

 

$

216,013 

 

$

(38,719)

(a)

$

177,294 

(a)

Consists primarily of corporate general and administrative expenses.

 

The following table sets forth certain reportable segment information relating to the Company’s total assets as of September 30, 2015 and December 31, 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

September 30, 2015

 

December 31, 2014

(in thousands)

 

 

 

 

 

Building

$

794,274 

 

$

680,933 

Civil

 

1,973,925 

 

 

1,814,170 

Specialty Contractors

 

863,750 

 

 

775,162 

  Totals

$

3,631,949 

 

$

3,270,265 

Corporate (a)

 

338,306 

 

 

503,050 

Consolidated Total

$

3,970,255 

 

$

3,773,315 

(a)

Consists principally of cash and cash equivalents and corporate transportation equipment.

 

 

23


 

(13)     Employee Pension Plans

 

The Company has a defined benefit pension plan and an unfunded supplemental retirement plan. Effective September 1, 2004, all benefit accruals under the Company’s pension plan were frozen; however, the current vested benefit was preserved. The pension disclosure presented below includes aggregated amounts for both of the Company’s plans.

 

The following table sets forth the net periodic benefit cost by component for the three and nine months ended September 30, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended September 30,

 

Nine Months Ended September 30,

 

2015

 

2014

 

2015

 

2014

 

(in thousands)

 

(in thousands)

Interest cost

$

1,008 

 

$

1,030 

 

$

3,030 

 

$

3,090 

Expected return on plan assets

 

(1,256)

 

 

(1,192)

 

 

(3,768)

 

 

(3,576)

Amortization of net loss

 

(1,417)

 

 

1,077 

 

 

1,503 

 

 

3,231 

Net periodic benefit cost

$

(1,665)

 

$

915 

 

$

765 

 

$

2,745 

 

The Company contributed $2.3 million and $4.1 million to its defined benefit pension plan during the nine months ended September 30, 2015 and 2014, respectively. The Company expects to contribute an additional $0.5 million to its defined benefit pension plan during the remainder of fiscal year 2015.

 

 

(14)     Related Party Transactions

 

The Company leases certain facilities from Ronald N. Tutor, the Company’s Chairman and Chief Executive Officer, and an affiliate owned by Mr. Tutor under non-cancelable operating lease agreements. On April 18, 2014, the Company and Ronald N. Tutor entered into two separate lease agreements, replacing the former leases which terminated on May 31, 2014. Each of the new leases is effective June 1, 2014 with new monthly payments of an aggregate of $0.2 million, and an increase at the rate of the greater of 3% per annum or the Consumer Price Index (“CPI”) for the Los Angeles metropolitan area beginning on June 1, 2015. Both new leases provide for purchase/sell options of the facilities at fair market value beginning on June 1, 2021 and June 1, 2025. Also under both leases, the fair market value is to be agreed upon by both parties, or determined by a consensus of independent qualified appraisers. Lease expense for these new leases and the former leases until date of termination, recorded on a straight-line basis, was $0.8 million and $2.4 million for three and nine months ended September 30, 2015, respectively. Lease expense for these new leases and the former leases until date of termination, recorded on a straight-line basis, was $0.7 million and $1.8 million for three and nine months ended September 30, 2014, respectively.

 

Raymond R. Oneglia, who is the Vice Chairman of O&G Industries, Inc. (“O&G”), is a director of the Company. Currently the Company has a 30% interest in a joint venture with O&G as the sponsor involving a highway construction project for the State of Connecticut, with an estimated total contract value of approximately $362 million, scheduled for completion in 2016. Under this arrangement, O&G provides project-related equipment and services directly to the customer (on customary trade terms). In accordance with the joint venture agreement, payments to O&G for equipment and services for the three and nine months ended September 30, 2015 were $3.3 million and $8.5 million, respectively. Payments to O&G for equipment and services for the three and nine months ended September 30, 2014 were $1.8 million and $5.1 million, respectively. O&G’s cumulative holdings of the Company’s stock were 500,000 shares at both September 30, 2015 and September 30, 2014, or 1.02% and 1.03%, respectively, of total common shares outstanding.

 

 

(15)     Separate Financial Information of Subsidiary Guarantors of Indebtedness

 

The Company’s obligation to pay principal and interest on its 7.625% senior unsecured notes due November 1, 2018, is guaranteed on a joint and several basis by substantially all of the Company’s existing and future subsidiaries that guarantee obligations under the Company’s Sixth Amended Credit Agreement (the “Guarantors”). The guarantees are full and unconditional and the Guarantors are 100%-owned by the Company.

 

The following supplemental condensed consolidating financial information reflects the summarized financial information of the Company as the issuer of the senior unsecured notes, the Guarantors and the Company’s non-guarantor subsidiaries on a combined basis.

 

24


 

CONDENSED CONSOLIDATING BALANCE SHEET - SEPTEMBER 30, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

ASSETS

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and Cash Equivalents

$

64,316 

 

$

31,558 

 

$

1,020 

 

$

 —

 

$

96,894 

Restricted Cash

 

3,369 

 

 

4,008 

 

 

31,195 

 

 

 —

 

 

38,572 

Accounts Receivable

 

427,119 

 

 

1,186,601 

 

 

58,326 

 

 

(121,181)

 

 

1,550,865 

Costs and Estimated Earnings in Excess of Billings

 

110,378 

 

 

849,774 

 

 

152 

 

 

(76,495)

 

 

883,809 

Deferred Income Taxes

 

4,787 

 

 

12,955 

 

 

1,131 

 

 

 —

 

 

18,873 

Other Current Assets

 

76,162 

 

 

51,422 

 

 

37,765 

 

 

(78,615)

 

 

86,734 

Total Current Assets

$

686,131 

 

$

2,136,318 

 

$

129,589 

 

$

(276,291)

 

$

2,675,747 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Investments

$

 —

 

$

 —

 

$

 —

 

$

 —

 

$

 —

Property and Equipment, net

 

107,030 

 

 

420,262 

 

 

4,146 

 

 

 —

 

 

531,438 

Intercompany Notes and Receivables

 

 —

 

 

186,736 

 

 

 —

 

 

(186,736)

 

 

 —

Other Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

   Goodwill

 

 —

 

 

585,006 

 

 

 —

 

 

 —

 

 

585,006 

   Intangible Assets, net

 

 —

 

 

97,425 

 

 

 —

 

 

 —

 

 

97,425 

   Investment in Subsidiaries

 

1,998,039 

 

 

 —

 

 

 —

 

 

(1,998,039)

 

 

 —

   Other

 

57,170 

 

 

27,363 

 

 

1,761 

 

 

(5,655)

 

 

80,639 

 

$

2,848,370 

 

$

3,453,110 

 

$

135,496 

 

$

(2,466,721)

 

$

3,970,255 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Current Maturities of Long-term Debt

$

81,825 

 

$

45,072 

 

$

 —

 

$

(41,000)

 

$

85,897 

Accounts Payable

 

250,379 

 

 

918,808 

 

 

3,344 

 

 

(187,314)

 

 

985,217 

Billings in Excess of Costs and Estimated Earnings

 

100,598 

 

 

188,172 

 

 

34 

 

 

(2,239)

 

 

286,565 

Accrued Expenses and Other Current Liabilities

 

50,226 

 

 

118,252 

 

 

63,024 

 

 

(45,738)

 

 

185,764 

Total Current Liabilities

$

483,028 

 

$

1,270,304 

 

$

66,402 

 

$

(276,291)

 

$

1,543,443 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Debt, less current maturities

 

664,931 

 

 

87,007 

 

 

 —

 

 

(5,655)

 

 

746,283 

Deferred Income Taxes

 

 —

 

 

149,021 

 

 

 —

 

 

 —

 

 

149,021 

Other Long-term Liabilities

 

112,909 

 

 

1,993 

 

 

 —

 

 

 —

 

 

114,902 

Intercompany Notes and Advances Payable

 

152,120 

 

 

 —

 

 

34,616 

 

 

(186,736)

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingencies and Commitments

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Stockholders’ Equity

 

1,435,382 

 

 

1,944,785 

 

 

34,478 

 

 

(1,998,039)

 

 

1,416,606 

 

$

2,848,370 

 

$

3,453,110 

 

$

135,496 

 

$

(2,466,721)

 

$

3,970,255 

 

 

25


 

CONDENSED CONSOLIDATING BALANCE SHEET - DECEMBER 31, 2014

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

ASSETS

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and Cash Equivalents

$

75,087 

 

$

36,764 

 

$

23,732 

 

$

 —

 

$

135,583 

Restricted Cash

 

3,369 

 

 

5,274 

 

 

35,727 

 

 

 —

 

 

44,370 

Accounts Receivable

 

299,427 

 

 

1,246,635 

 

 

37,064 

 

 

(103,622)

 

 

1,479,504 

Costs and Estimated Earnings in Excess of Billings

 

70,344 

 

 

700,362 

 

 

152 

 

 

(44,456)

 

 

726,402 

Deferred Income Taxes

 

 —

 

 

15,639 

 

 

 —

 

 

2,323 

 

 

17,962 

Other Current Assets

 

39,196 

 

 

42,750 

 

 

24,397 

 

 

(37,608)

 

 

68,735 

Total Current Assets

$

487,423 

 

$

2,047,424 

 

$

121,072 

 

$

(183,363)

 

$

2,472,556 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Investments

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

Property and Equipment, net

 

92,413 

 

 

430,876 

 

 

4,313 

 

 

 —

 

 

527,602 

Intercompany Notes and Receivables

 

 —

 

 

122,401 

 

 

 —

 

 

(122,401)

 

 

 —

Other Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

   Goodwill

 

 —

 

 

585,006 

 

 

 —

 

 

 —

 

 

585,006 

   Intangible Assets, net

 

 —

 

 

100,254 

 

 

 —

 

 

 —

 

 

100,254 

   Investment in Subsidiaries

 

2,154,562 

 

 

19,519 

 

 

50 

 

 

(2,174,131)

 

 

 —

   Other

 

83,503 

 

 

9,847 

 

 

 —

 

 

(5,453)

 

 

87,897 

 

$

2,817,901 

 

$

3,315,327 

 

$

125,435 

 

$

(2,485,348)

 

$

3,773,315 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Current Maturities of Long-term Debt

 

34,776 

 

 

46,516 

 

 

 —

 

 

 —

 

 

81,292 

Accounts Payable

 

186,958 

 

 

716,851 

 

 

3,749 

 

 

(109,384)

 

 

798,174 

Billings in Excess of Costs and Estimated Earnings

 

139,020 

 

 

185,807 

 

 

2,672 

 

 

(8,203)

 

 

319,296 

Accrued Expenses and Other Current Liabilities

 

33,018 

 

 

95,177 

 

 

58,571 

 

 

(26,952)

 

 

159,814 

Total Current Liabilities

$

393,772 

 

$

1,044,351 

 

$

64,992 

 

$

(144,539)

 

$

1,358,576 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Debt, less current maturities

 

712,460 

 

 

112,060 

 

 

 —

 

 

(40,453)

 

 

784,067 

Deferred Income Taxes

 

142,457 

 

 

7,914 

 

 

 —

 

 

 —

 

 

150,371 

Other Long-term Liabilities

 

112,899 

 

 

1,897 

 

 

 —

 

 

 —

 

 

114,796 

Intercompany Notes and Advances Payable

 

90,373 

 

 

 —

 

 

35,619 

 

 

(125,992)

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingencies and Commitments

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Stockholders’ Equity

 

1,365,939 

 

 

2,149,105 

 

 

24,824 

 

 

(2,174,363)

 

 

1,365,505 

 

$

2,817,900 

 

$

3,315,327 

 

$

125,435 

 

$

(2,485,347)

 

$

3,773,315 

 

 

26


 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED SEPTEMBER 30, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Revenues

 

$

309,777 

 

$

1,111,034 

 

$

5,240 

 

$

(85,312)

 

$

1,340,739 

Cost of Operations

 

 

258,061 

 

 

1,067,789 

 

 

 —

 

 

(85,312)

 

 

1,240,538 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

$

51,716 

 

$

43,245 

 

$

5,240 

 

$

 —

 

$

100,201 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

19,584 

 

 

41,171 

 

 

472 

 

 

 —

 

 

61,227 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

$

32,132 

 

$

2,074 

 

$

4,768 

 

$

 —

 

$

38,974 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

4,186 

 

 

 —

 

 

 —

 

 

(4,186)

 

 

 —

Other (Expense) Income, net

 

 

4,414 

 

 

1,375 

 

 

127 

 

 

 —

 

 

5,916 

Interest Expense

 

 

(10,273)

 

 

(662)

 

 

 —

 

 

 —

 

 

(10,935)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (Loss) before Income Taxes

 

 

30,459 

 

 

2,787 

 

 

4,895 

 

 

(4,186)

 

 

33,955 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Benefit (Provision) for Income Taxes

 

 

(10,782)

 

 

(1,413)

 

 

(2,083)

 

 

 —

 

 

(14,278)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME (LOSS)

 

$

19,677 

 

$

1,374 

 

$

2,812 

 

$

(4,186)

 

$

19,677 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 Other Comprehensive Income of Subsidiaries

 

 

(1,377)

 

 

 —

 

 

 —

 

 

1,377 

 

 

 —

 Foreign currency translation

 

 

 —

 

 

(1,375)

 

 

 —

 

 

 —

 

 

(1,375)

 Change in fair value of investments

 

 

 —

 

 

(2)

 

 

 —

 

 

 —

 

 

(2)

 Change in fair value of interest rate swap

 

 

47 

 

 

 —

 

 

 —

 

 

 —

 

 

47 

 Total Other Comprehensive (Loss) Income

 

$

(1,330)

 

$

(1,377)

 

$

 —

 

$

1,377 

 

$

(1,330)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

18,347 

 

$

(3)

 

$

2,812 

 

$

(2,809)

 

$

18,347 

 

 

27


 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED SEPTEMBER 30, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Revenues

 

$

272,657 

 

$

1,020,335 

 

$

 —

 

$

(42,303)

 

$

1,250,689 

Cost of Operations

 

 

242,717 

 

 

913,797 

 

 

(4,363)

 

 

(42,303)

 

 

1,109,848 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

$

29,940 

 

$

106,538 

 

$

4,363 

 

$

 —

 

$

140,841 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

22,128 

 

 

47,884 

 

 

475 

 

 

 —

 

 

70,487 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

$

7,812 

 

$

58,654 

 

$

3,888 

 

$

 —

 

$

70,354 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

38,044 

 

 

 —

 

 

 —

 

 

(38,044)

 

 

 —

Other (Expense) Income, net

 

 

(1,246)

 

 

677 

 

 

128 

 

 

 —

 

 

(441)

Interest Expense

 

 

(10,369)

 

 

(928)

 

 

 —

 

 

 —

 

 

(11,297)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (Loss) before Income Taxes

 

$

34,241 

 

$

58,403 

 

$

4,016 

 

$

(38,044)

 

$

58,616 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Benefit (Provision) for Income Taxes

 

 

1,489 

 

 

(22,870)

 

 

(1,505)

 

 

 —

 

 

(22,886)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME (LOSS)

 

$

35,730 

 

$

35,533 

 

$

2,511 

 

$

(38,044)

 

$

35,730 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income of Subsidiaries

 

 

(456)

 

 

 —

 

 

 —

 

 

456 

 

 

 —

Foreign currency translation

 

 

 —

 

 

(501)

 

 

 —

 

 

 —

 

 

(501)

Change in fair value of investments

 

 

 —

 

 

45 

 

 

 —

 

 

 —

 

 

45 

Change in fair value of interest rate swap

 

 

129 

 

 

 —

 

 

 —

 

 

 —

 

 

129 

Total Other Comprehensive (Loss) Income

 

$

(327)

 

$

(456)

 

$

 —

 

$

456 

 

$

(327)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

35,403 

 

$

35,077 

 

$

2,511 

 

$

(37,588)

 

$

35,403 

 

 

28


 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

NINE MONTHS ENDED SEPTEMBER 30, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Revenues

 

$

855,286 

 

$

3,061,903 

 

$

12,324 

 

$

(209,871)

 

$

3,719,642 

Cost of Operations

 

 

733,023 

 

 

2,906,910 

 

 

 —

 

 

(209,871)

 

 

3,430,062 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

$

122,263 

 

$

154,993 

 

$

12,324 

 

$

 —

 

$

289,580 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

69,908 

 

 

128,322 

 

 

1,411 

 

 

 —

 

 

199,641 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

$

52,355 

 

$

26,671 

 

$

10,913 

 

$

 —

 

$

89,939 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

22,712 

 

 

 —

 

 

 —

 

 

(22,712)

 

 

 —

Other (Expense) Income, net

 

 

1,879 

 

 

3,002 

 

 

380 

 

 

 —

 

 

5,261 

Interest Expense

 

 

(30,670)

 

 

(2,378)

 

 

 —

 

 

 —

 

 

(33,048)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (loss) before Income Taxes

 

 

46,276 

 

 

27,295 

 

 

11,293 

 

 

(22,712)

 

 

62,152 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Benefit (Provision) for Income Taxes

 

 

(9,696)

 

 

(11,230)

 

 

(4,646)

 

 

 —

 

 

(25,572)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME (LOSS)

 

$

36,580 

 

$

16,065 

 

$

6,647 

 

$

(22,712)

 

$

36,580 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 Other Comprehensive Income of Subsidiaries

 

 

(3,195)

 

 

 —

 

 

 —

 

 

3,195 

 

 

 —

 Foreign currency translation

 

 

 —

 

 

(3,109)

 

 

 —

 

 

 —

 

 

(3,109)

 Change in fair value of investments

 

 

 —

 

 

(86)

 

 

 —

 

 

 —

 

 

(86)

 Change in fair value of interest rate swap

 

 

152 

 

 

 —

 

 

 —

 

 

 —

 

 

152 

 Total Other Comprehensive (Loss) Income

 

 

(3,043)

 

 

(3,195)

 

 

 —

 

 

3,195 

 

 

(3,043)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

33,537 

 

$

12,870 

 

$

6,647 

 

$

(19,517)

 

$

33,537 

 

 

29


 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

NINE MONTHS ENDED SEPTEMBER 30, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Revenues

 

$

707,448 

 

$

2,702,117 

 

$

 —

 

$

(119,133)

 

$

3,290,432 

Cost of Operations

 

 

614,408 

 

 

2,438,802 

 

 

(19,364)

 

 

(119,133)

 

 

2,914,713 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

 

93,040 

 

 

263,315 

 

 

19,364 

 

 

 —

 

 

375,719 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

58,908 

 

 

138,129 

 

 

1,388 

 

 

 —

 

 

198,425 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

 

34,132 

 

 

125,186 

 

 

17,976 

 

 

 —

 

 

177,294 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

85,073 

 

 

 —

 

 

 —

 

 

(85,073)

 

 

 —

Other (Expense) Income, net

 

 

(12,025)

 

 

861 

 

 

376 

 

 

 —

 

 

(10,788)

Interest Expense

 

 

(30,195)

 

 

(2,790)

 

 

 —

 

 

 —

 

 

(32,985)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (Loss) before Income Taxes

 

 

76,985 

 

 

123,257 

 

 

18,352 

 

 

(85,073)

 

 

133,521 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Benefit (Provision) for Income Taxes

 

 

3,229 

 

 

(49,209)

 

 

(7,327)

 

 

 —

 

 

(53,307)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME  (LOSS)

 

$

80,214 

 

$

74,048 

 

$

11,025 

 

$

(85,073)

 

$

80,214 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income of Subsidiaries

 

 

(221)

 

 

 —

 

 

 —

 

 

221 

 

 

 —

Foreign currency translation

 

 

 —

 

 

(440)

 

 

 —

 

 

 —

 

 

(440)

Change in fair value of investments

 

 

 —

 

 

219 

 

 

 —

 

 

 —

 

 

219 

Change in fair value of interest rate swap

 

 

286 

 

 

 —

 

 

 —

 

 

 —

 

 

286 

Total Other Comprehensive (Loss) Income

 

 

65 

 

 

(221)

 

 

 —

 

 

221 

 

 

65 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

80,279 

 

$

73,827 

 

$

11,025 

 

$

(84,852)

 

$

80,279 

 

 

30


 

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

NINE MONTHS ENDED SEPTEMBER 30, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Cash Flows from Operating Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income (loss)

 

$

36,580 

 

$

16,065 

 

$

6,647 

 

$

(22,712)

 

$

36,580 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Depreciation and amortization

 

 

8,279 

 

 

24,042 

 

 

207 

 

 

 —

 

 

32,528 

Equity in earnings of subsidiaries

 

 

(22,712)

 

 

 —

 

 

 —

 

 

22,712 

 

 

 —

Stock-based compensation expense

 

 

17,064 

 

 

 —

 

 

 —

 

 

 —

 

 

17,064 

Excess income tax benefit from stock-based compensation

 

 

(186)

 

 

 —

 

 

 —

 

 

 —

 

 

(186)

Deferred income taxes

 

 

(2,323)

 

 

10,450 

 

 

(1,761)

 

 

 —

 

 

6,366 

(Gain) loss on sale of property and equipment

 

 

79 

 

 

(900)

 

 

 —

 

 

 —

 

 

(821)

Other long-term liabilities

 

 

(1,480)

 

 

101 

 

 

 —

 

 

 —

 

 

(1,379)

Other non-cash items

 

 

(4,856)

 

 

(836)

 

 

 —

 

 

 —

 

 

(5,692)

Changes in other components of working capital 

 

 

(144,093)

 

 

114,658 

 

 

(34,351)

 

 

 —

 

 

(63,786)

NET CASH (USED) PROVIDED BY OPERATING ACTIVITIES

 

$

(113,648)

 

$

163,580 

 

$

(29,258)

 

$

 —

 

$

20,674 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Acquisition of property and equipment excluding financed purchases

 

 

(21,406)

 

 

(11,919)

 

 

(40)

 

 

 —

 

 

(33,365)

Proceeds from sale of property and equipment

 

 

 —

 

 

2,220 

 

 

 —

 

 

 —

 

 

2,220 

(Increase) decrease in intercompany advances

 

 

 —

 

 

(127,690)

 

 

 —

 

 

127,690 

 

 

 —

Change in restricted cash

 

 

 —

 

 

1,266 

 

 

4,532 

 

 

 —

 

 

5,798 

NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES

 

$

(21,406)

 

$

(136,123)

 

$

4,492 

 

$

127,690 

 

$

(25,347)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Proceeds from debt

 

 

678,622 

 

 

(5,903)

 

 

 —

 

 

 —

 

 

672,719 

Repayment of debt

 

 

(679,353)

 

 

(26,760)

 

 

 —

 

 

 —

 

 

(706,113)

Excess income tax benefit from stock-based compensation

 

 

186 

 

 

 —

 

 

 —

 

 

 —

 

 

186 

Issuance of common stock and effect of cashless exercise

 

 

(808)

 

 

 —

 

 

 —

 

 

 —

 

 

(808)

Increase (decrease) in intercompany advances

 

 

125,636 

 

 

 —

 

 

2,054 

 

 

(127,690)

 

 

 —

NET CASH (USED) PROVIDED BY FINANCING ACTIVITIES

 

$

124,283 

 

$

(32,663)

 

$

2,054 

 

$

(127,690)

 

$

(34,016)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net (Decrease) Increase in Cash and Cash Equivalents

 

 

(10,771)

 

 

(5,206)

 

 

(22,712)

 

 

 —

 

 

(38,689)

Cash and Cash Equivalents at Beginning of Year

 

 

75,087 

 

 

36,764 

 

 

23,732 

 

 

 —

 

 

135,583 

Cash and Cash Equivalents at End of Period

 

$

64,316 

 

$

31,558 

 

$

1,020 

 

$

 —

 

$

96,894 

 

 

31


 

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

NINE MONTHS ENDED SEPTEMBER 30, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Cash Flows from Operating Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income (loss)

 

$

80,214 

 

$

74,048 

 

$

11,025 

 

$

(85,073)

 

$

80,214 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Depreciation and amortization

 

 

5,617 

 

 

36,345 

 

 

203 

 

 

 —

 

 

42,165 

Equity in earnings of subsidiaries

 

 

(85,073)

 

 

 —

 

 

 —

 

 

85,073 

 

 

 —

Stock-based compensation expense

 

 

14,127 

 

 

249 

 

 

 —

 

 

 —

 

 

14,376 

Excess income tax benefit from stock-based compensation

 

 

(656)

 

 

 —

 

 

 —

 

 

 

 

 

(656)

Deferred income taxes

 

 

4,140 

 

 

11,848 

 

 

 —

 

 

 —

 

 

15,988 

(Gain) loss on sale of investments

 

 

1,786 

 

 

 —

 

 

 —

 

 

 —

 

 

1,786 

(Gain) loss on sale of property and equipment

 

 

833 

 

 

93 

 

 

 —

 

 

 —

 

 

926 

Other long-term liabilities

 

 

2,376 

 

 

(1,120)

 

 

 —

 

 

 —

 

 

1,256 

Other non-cash items

 

 

1,324 

 

 

 —

 

 

 —

 

 

 —

 

 

1,324 

Changes in other components of working capital 

 

 

(17,700)

 

 

(286,654)

 

 

3,550 

 

 

 —

 

 

(300,804)

NET CASH PROVIDED (USED) BY OPERATING ACTIVITIES

 

$

6,988 

 

$

(165,191)

 

$

14,778 

 

$

 —

 

$

(143,425)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Acquisition of property and equipment

 

 

(18,743)

 

 

(19,035)

 

 

 —

 

 

 —

 

 

(37,778)

Proceeds from sale of property and equipment

 

 

136 

 

 

5,017 

 

 

 —

 

 

 —

 

 

5,153 

Proceeds from sale of available-for-sale securities

 

 

44,497 

 

 

 —

 

 

 —

 

 

 —

 

 

44,497 

Change in restricted cash

 

 

15,464 

 

 

142 

 

 

(20,000)

 

 

 —

 

 

(4,394)

NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES

 

$

41,354 

 

$

(13,876)

 

$

(20,000)

 

$

 —

 

$

7,478 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Proceeds from debt

 

 

952,568 

 

 

40,442 

 

 

 —

 

 

 —

 

 

993,010 

Repayment of debt

 

 

(752,030)

 

 

(56,581)

 

 

 —

 

 

 —

 

 

(808,611)

Business acquisition related payments

 

 

(26,430)

 

 

 —

 

 

 —

 

 

 —

 

 

(26,430)

Excess income tax benefit from stock-based compensation

 

 

656 

 

 

 —

 

 

 —

 

 

 —

 

 

656 

Issuance of common stock and effect of cashless exercise

 

 

(1,692)

 

 

 —

 

 

 —

 

 

 —

 

 

(1,692)

Debt issuance costs

 

 

(3,681)

 

 

 —

 

 

 —

 

 

 —

 

 

(3,681)

Increase (decrease) in intercompany advances

 

 

(236,283)

 

 

236,089 

 

 

194 

 

 

 —

 

 

 —

NET CASH (USED) PROVIDED BY FINANCING ACTIVITIES

 

$

(66,892)

 

$

219,950 

 

$

194 

 

$

 —

 

$

153,252 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net Increase (Decrease) in Cash and Cash Equivalents

 

 

(18,550)

 

 

40,883 

 

 

(5,028)

 

 

 —

 

 

17,305 

Cash and Cash Equivalents at Beginning of Year

 

 

88,995 

 

 

18,031 

 

 

12,897 

 

 

 —

 

 

119,923 

Cash and Cash Equivalents at End of Period

 

$

70,445 

 

$

58,914 

 

$

7,869 

 

$

 —

 

$

137,228 

  

  

32


 

  

(16)     Subsequent Event

 

As described more fully in the Brightwater Matter discussion in Note 7. Contingencies and Commitments, on November 9, 2015, the Company received notice of an adverse appellate court decision, filed that day, regarding a long-standing litigation matter involving a joint venture in which Frontier-Kemper, a wholly-owned subsidiary of the Company, was a 20% minority partner. The adverse decision upheld a trial court’s jury verdict from May 2013 and resulted in a non-cash, pre-tax charge of approximately $23.9 million, which was recorded as a subsequent event in the third quarter of 2015. As part of the appellate court’s decision, the joint venture must pay reasonable attorney fees and appellate costs, which were not known and were not estimable at the time of the filing of this Form 10-Q. Since Frontier-Kemper contributed its 20% minority share of funds to satisfy the trial court’s earlier verdict, the decision is not expected to have a significant impact on future cash flows.

 

Frontier-Kemper is a wholly owned subsidiary of the Company that was acquired in June 2011. The Brightwater joint venture project had been completed and the dispute was in litigation at the time of the acquisition. As a minority partner, Frontier-Kemper did not lead the litigation effort, nor did the Company.

 

As a result of receiving notice of the adverse appellate court decision on November 9, 2015, the Company filed a Notification of Late Filing on Form 12b-25 with the Securities and Exchange Commission on November 10, 2015, disclosing that the Company was unable to timely file this Form 10-Q for the quarter ended September 30, 2015.

 

  

  

33


 

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

 

The following discusses our financial position at September 30, 2015 and the results of our operations for the three and nine months ended September 30, 2015 and should be read in conjunction with: (1) the unaudited consolidated condensed financial statements and notes contained herein, and (2) the audited consolidated financial statements and accompanying notes to our Annual Report on Form 10-K for the fiscal year ended December 31, 2014.

 

Overview

 

We were incorporated in 1918 as a successor to businesses that had been engaged in providing construction services since 1894. We provide diversified general contracting, construction management and design-build services to private customers and public agencies throughout the world. Our construction business is conducted through three basic segments or operations: Civil, Building and Specialty Contractors. Our Civil segment specializes in public works construction and the repair, replacement and reconstruction of infrastructure, including highways, bridges, mass-transit systems and water and wastewater treatment facilities, primarily in the western, midwestern, northeastern and mid-Atlantic regions of the United States. Our Building segment has significant experience providing services to a number of specialized building markets, including the hospitality and gaming, transportation, healthcare, municipal and commercial offices, sports and entertainment, educational, correctional facilities, biotech, pharmaceutical and high-tech markets. Our Specialty Contractors segment specializes in plumbing, HVAC, electrical, mechanical and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming and transportation end markets, among others.

 

The contracting and management services that we provide consist of general contracting, pre-construction planning and comprehensive management services, including planning and scheduling the manpower, equipment, materials and subcontractors required for the timely completion of a project in accordance with the terms and specifications contained in a construction contract. We also offer self-performed construction services, including site work, concrete forming and placement, steel erection, electrical, mechanical, plumbing and HVAC. We provide these services by using traditional general contracting arrangements, such as fixed price, guaranteed maximum price and cost plus fee contracts and, to a lesser extent, construction management or design-build contracting arrangements. We  occasionally enter into joint venture arrangements with other contractors for certain construction projects. Each of the joint venture participants is usually committed to supply a predetermined percentage of capital, as required, and to share in a predetermined percentage of the income or loss of the project. Generally, each joint venture participant is fully liable for the obligations of the joint venture.

 

We believe our leadership position as the contractor of choice for large, complex civil and building projects will support our long-term backlog growth. We continue to strategically focus on growing our business by pursuing and obtaining higher-margin public works projects and building projects on an opportunistic basis. In addition, we continue to leverage our unique, substantial self-performance and schedule-control capabilities to obtain additional large-scale civil and building awards. We have capitalized on this leadership position and these synergies with various recent significant new awards and pending awards (see Backlog Analysis on page 37).

 

 

34


 

The following tables present the results of operations of the Company for the three and nine months ended September 30, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Consolidated Results of Operations

 

 

 

 

 

 

 

% Change

 

 

 

 

 

 

 

% Change

 

Three Months Ended

 

Favorable

 

Nine Months Ended

 

Favorable

 

September 30,

 

(Unfavorable)

 

September 30,

 

(Unfavorable)

 

2015

 

2014

 

2015 vs 2014

 

2015

 

2014

 

2015 vs 2014

 

(In thousands)

 

 

 

(In thousands)

 

 

Revenues

$

1,340,739 

 

$

1,250,689 

 

7.2% 

 

$

3,719,642 

 

$

3,290,432 

 

13.0% 

Cost of operations

 

1,240,538 

 

 

1,109,848 

 

(11.8)%

 

 

3,430,062 

 

 

2,914,713 

 

(17.7)%

Gross profit

 

100,201 

 

 

140,841 

 

(28.9)%

 

 

289,580 

 

 

375,719 

 

(22.9)%

General and administrative expenses

 

61,227 

 

 

70,487 

 

13.1% 

 

 

199,641 

 

 

198,425 

 

(0.6)%

Income from construction operations

 

38,974 

 

 

70,354 

 

(44.6)%

 

 

89,939 

 

 

177,294 

 

(49.3)%

Other income (expense), net

 

5,916 

 

 

(441)

 

1441.5% 

 

 

5,261 

 

 

(10,788)

 

148.8% 

Interest expense

 

(10,935)

 

 

(11,297)

 

3.2% 

 

 

(33,048)

 

 

(32,985)

 

(0.2)%

Income before income taxes

 

33,955 

 

 

58,616 

 

(42.1)%

 

 

62,152 

 

 

133,521 

 

(53.5)%

Provision for income taxes

 

(14,278)

 

 

(22,886)

 

37.6% 

 

 

(25,572)

 

 

(53,307)

 

52.0% 

Net income

$

19,677 

 

$

35,730 

 

(44.9)%

 

$

36,580 

 

$

80,214 

 

(54.4)%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Consolidated Results of Operations

 

Three Months Ended September 30,

 

Nine Months Ended September 30,

 

2015

 

2014

 

2015

 

2014

 

(As a percentage of Revenues)

 

(As a percentage of Revenues)

Revenues

100.0% 

 

100.0% 

 

100.0% 

 

100.0% 

Cost of operations

92.5% 

 

88.7% 

 

92.2% 

 

88.6% 

Gross profit

7.5% 

 

11.3% 

 

7.8% 

 

11.4% 

General and administrative expenses

4.6% 

 

5.7% 

 

5.4% 

 

6.0% 

Income from construction operations

2.9% 

 

5.6% 

 

2.4% 

 

5.4% 

Other income (expense), net

0.4% 

 

(0.0)%

 

0.1% 

 

(0.3)%

Interest expense

(0.8)%

 

(0.9)%

 

(0.9)%

 

(1.0)%

Income before income taxes

2.5% 

 

4.7% 

 

1.6% 

 

4.1% 

Provision for income taxes

(1.0)%

 

(1.8)%

 

(0.6)%

 

(1.7)%

Net income

1.5% 

 

2.9% 

 

1.0% 

 

2.4% 

 

Revenues increased $90.0 million, or 7.2%, and approximately $429.2 million, or 13.0%, during the three and nine months ended September 30, 2015 compared to the same periods in 2014. The increase for both periods was due primarily to increased activity on various building projects in California,  a runway reconstruction project in New York and electrical projects at Hudson Yards in New York.  For the nine-month period, the increase was also due to greater activity on various electrical, mechanical and concrete placement projects in New York. The increase for both periods was partially offset by decreased activity on electrical projects at the World Trade Center and mechanical projects at the United Nations in New York, as well as, various smaller electrical projects in the southern U.S.

 

The decrease in net income for the three and nine months ended September 30, 2015 compared to the same periods in 2014, was principally attributable to an unfavorable change in the third quarter of 2015 for an adverse legal decision related to a long-standing litigation matter, for which the Company assumed liability as part of an acquisition in 2011 (for further information, refer to the Brightwater Matter discussion in Note 7 and Note 16 of the Notes to the Consolidated Condensed Financial Statements). Also contributing to the decrease was the inclusion of a favorable adjustment in the prior year period for the estimated recovery on a large hospitality and gaming building project, unfavorable adjustments in the current year third quarter related to a number of electrical projects in New York and decreased current year activity on certain higher-margin civil projects. For the nine-month period, the decrease was also due to unfavorable adjustments in 2015 related to the estimate of costs to complete an office building project in New York, decreased current year activity on certain tunnel projects on the West Coast and net favorable adjustments to the estimated recoveries on two civil projects in the second quarter of 2014, based on legal rulings issued during that period. The decrease in net income for both 2015 periods was partially offset by increased project execution activity and favorable adjustments on the New York runway reconstruction project, as well as progress on numerous other projects across all of the Company’s segments. (The adjustments related to the Brightwater legacy litigation matter, the two building projects, the New York runway project and the two civil projects that settled in the second quarter of last year, were discussed in Use of and changes in estimates.)

 

Diluted earnings per share (“EPS”) was $0.40 for the three months ended September 30, 2015, compared to $0.73 for the same period in 2014. Diluted EPS was $0.74 for the nine months ended September 30, 2015, compared to $1.64 for the same period in 2014.

35


 

 

Non-GAAP Measures

 

Our consolidated financial statements are presented based on accounting principles generally accepted in the United States (“GAAP”). We sometimes use non-GAAP measures of income from operations, net income, EPS and other measures that we believe are appropriate to enhance an overall understanding of our historical financial performance and future prospects. We are providing the below non-GAAP measures to disclose additional information to facilitate the comparison of past and present operations, as they are among the indicators that management uses as a basis for evaluating the Company’s financial performance, as well as for forecasting future periods. As such, management believes that these non-GAAP measures can be useful in measuring operating performance and should be considered by investors, prospective investors and others. These non-GAAP measures are not intended to replace the presentation of our financial results in accordance with GAAP, and they should be considered in addition to, and not in lieu of, our GAAP results. The non-GAAP measures that we provide may not be comparable to other similarly titled measures of other companies.

 

The following table presents a reconciliation of reported income from construction operations under GAAP to adjusted income from construction operations for the three and nine months ended September 30, 2015.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

 

 

Consolidated

(in thousands)

Civil

 

 

Building

 

Contractors

 

Totals

 

Corporate

 

Total

Three Months Ended September 30, 2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income from construction operations, as reported

$

43,183 

 

$

6,763 

 

$

4,741 

 

$

54,687 

 

$

(15,713)

 

$

38,974 

Litigation-related charge (a)

 

23,860 

 

 

 —

 

 

 —

 

 

23,860 

 

 

 —

 

 

23,860 

Adjusted income from construction operations

$

67,043 

 

$

6,763 

 

$

4,741 

 

$

78,547 

 

$

(15,713)

 

$

62,834 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

 

 

Consolidated

(in thousands)

Civil

 

 

Building

 

Contractors

 

Totals

 

Corporate

 

Total

Nine Months Ended September 30, 2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income from construction operations, as reported

$

120,106 

 

$

(8,107)

 

$

29,008 

 

$

141,007 

 

$

(51,068)

 

$

89,939 

Litigation-related charge (a)

 

23,860 

 

 

 —

 

 

 —

 

 

23,860 

 

 

 —

 

 

23,860 

Adjusted income from construction operations

$

143,966 

 

$

(8,107)

 

$

29,008 

 

$

164,867 

 

$

(51,068)

 

$

113,799 

(a)The Company recorded a non-cash, pre-tax charge of $23.9 million ($14.0 million after tax) for an adverse legal decision related to a long-standing litigation matter, for which the Company assumed liability for a minority interest in a joint venture as part of an acquisition in 2011.  (For further information, refer to the Brightwater Matter discussion in Note 7 and Note 16 of the Notes to the Consolidated Condensed Financial Statements.)

 

The following table presents a reconciliation of reported net income and reported diluted EPS under GAAP to adjusted net income and adjusted diluted EPS for the three and nine months ended September 30, 2015.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

Nine Months Ended

 

September 30,

 

September 30,

(in thousands, except for per share data)

2015

 

2015

Net income, as reported

$

19,677 

 

$

36,580 

Litigation-related charge, as mentioned above

 

14,032 

 

 

14,032 

Adjusted net income

$

33,709 

 

$

50,612 

 

 

 

 

 

 

Diluted earnings per common share, as reported

$

0.40 

 

$

0.74 

Litigation-related charge, as mentioned above

 

0.28 

 

 

0.28 

Adjusted diluted earnings per common share

$

0.68 

 

$

1.02 

 

There were no adjustments for non-GAAP measurement purposes to income from construction operations, net income or diluted EPS for the three and nine months ended September 30, 2014.

  

  

36


 

Backlog Analysis

 

Our backlog of uncompleted construction work at September 30, 2015 was approximately $7.5 billion compared to $7.8 billion at December 31, 2014. During the first nine months of 2015, we booked various new awards and adjustments to existing contracts into backlog across each of our business segments. Significant new awards and adjustments included a technology research and development facility project valued at $800 million and $93 million of incremental funding for a biotechnology facility project, both in California, a hospitality building project worth $239 million, a mixed-use building project worth $117 million, and a highway project in Pennsylvania valued at $58 million, four electrical projects in New York totaling $170 million and a tunnel project also in New York worth $56 million,  three educational building projects in Mississippi totaling $120 million, $69 million of incremental funding for a multi-unit residential building project in Florida and a highway project in Maryland valued at $60 million.

 

In addition to our existing backlog, we have approximately $4.5 billion of pending contract awards, including up to $2.3 billion in various future phases of the Hudson Yards project, approximately $800 million for five building projects in California, more than $400 million for three building projects in Florida and approximately $1.0 billion in various other contracts. We anticipate booking many of these and other pending awards into backlog over the next several quarters. We continue to track several large-scale civil and building prospects for both public and private sector customers.

 

The following table presents the Company’s backlog by business segment, reflecting changes from December 31, 2014 to September 30, 2015:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Backlog at

 

New Business

 

Revenues

 

Backlog at

 

December 31, 2014

 

Awarded (a)

 

Recognized

 

September 30, 2015

 

(in millions)

Civil

$

3,563.2 

 

$

696.5 

 

$

(1,449.1)

 

$

2,810.6 

Building

 

2,187.8 

 

 

1,818.0 

 

 

(1,325.4)

 

 

2,680.4 

Specialty Contractors

 

2,080.7 

 

 

912.4 

 

 

(945.1)

 

 

2,048.0 

Total

$

7,831.7 

 

$

3,426.9 

 

$

(3,719.6)

 

$

7,539.0 

(a)

New business awarded consists of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

 

 

Critical Accounting Policies

 

Our significant accounting policies are described in Note 1. Description of Business and Summary of Significant Accounting Policies of the Notes to Consolidated Financial Statements in Part IV, Item 15. Exhibits and Financial Statement Schedules, included in our Annual Report on Form 10-K for the fiscal year ended December 31, 2014.  Our critical accounting policies are also identified and discussed in Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations of our Annual Report on Form 10-K for the fiscal year ended December 31, 2014.

 

Recently Issued Accounting Pronouncements

 

In May 2014, the FASB issued Accounting Standards Update (“ASU”) ASU No. 2014-09, Revenue from Contracts with Customers (Topic 606), which supersedes the revenue recognition requirements in ASC 605, Revenue Recognition. This ASU addresses when an entity should recognize revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the entity expects to be entitled in exchange for those goods or services. In August 2015, the FASB issued ASU No. 2015-14, Revenue from Contracts with Customers: (Topic 606): Deferral of the Effective Date, which defers the effective date to annual reporting periods beginning after December 15, 2017, including interim periods within that reporting period. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

 

In June 2014, the FASB issued ASU No. 2014-12, Compensation — Stock Compensation (Topic 718): Accounting for Share-Based Payments When the Terms of an Award Provide That a Performance Target Could Be Achieved after the Requisite Service Period, clarifying the recognition timing of expense associated with certain performance-based stock awards when the performance target that affects vesting could be achieved after the requisite service period. This ASU is an update to FASB ASC Topic 718 and is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015 with earlier adoption permitted. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements.

 

In February 2015, the FASB issued ASU No. 2015-02, Consolidation (Topic 810). The goal of this ASU is to reduce the potentially distortive impact on reporting entities’ consolidated financial statements resulting from the consolidation of certain legal entities, including joint ventures and variable interest entities. This ASU is effective for fiscal years, and interim periods within those years,

37


 

beginning after December 15, 2015. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

In April 2015, the FASB issued ASU 2015-03, Interest – Imputation of Interest (Subtopic 835-30). This ASU requires that debt issuance costs related to a recognized debt liability be presented in the balance sheet as a direct deduction from the carrying amount of that debt liability, consistent with debt discounts. In August 2015, the FASB also issued ASU 2015-15, Interest—Imputation of Interest (Subtopic 835-30): Presentation and Subsequent Measurement of Debt Issuance Costs Associated With Line-of-Credit Arrangements — Amendments to SEC Paragraphs Pursuant to Staff Announcement at June 18, 2015, EITF Meeting. This update allows an entity to defer and present debt issuance costs related to line-of-credit arrangements as an asset and subsequently amortize the deferred debt issuance costs ratably over the term of the line-of-credit arrangement, regardless of whether there are any outstanding borrowings on the line-of-credit arrangement. These ASUs are effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The adoption of these ASUs is not expected to have a material impact on the Company’s financial statements.

Use of and changes in estimates

 

The Company’s construction business involves making significant estimates and assumptions in the normal course of business relating to its contracts and its joint venture contracts. Management focuses on evaluating the performance of contracts individually. These estimates can vary in the normal course of business as projects progress, when estimated productivity assumptions change based on experience to date and uncertainties are resolved. Change orders and claims, as well as changes in related estimates of costs to complete, are considered revisions in estimates. The Company uses the cumulative catch-up method applicable to construction contract accounting to account for revisions in estimates. The impact on operating margin in a reporting period and future periods from a change in estimate will depend on the stage of contract completion.

 

In the third quarter of 2015, the Company recorded a charge for an adverse legal decision related to a long-standing litigation matter, for which the Company assumed liability as part of an acquisition in 2011. This charge resulted in a decrease of $23.9 million in income from construction operations, $14.0 million in net income and $0.28 in diluted EPS (for further information, refer to the Brightwater Matter discussion in Note 7 and Note 16 of the Notes to the Consolidated Condensed Financial Statements). Additionally, in the third quarter of 2015, the Company recorded favorable adjustments for a Civil segment runway reconstruction project related to the estimated cost to complete and the achievement of certain performance-based milestones that resulted in an increase of $13.7 million in income from construction operations, $7.9 million in net income and $0.16 in diluted EPS. Previously, in the second quarter of 2015, the Company recorded a significant adverse change in the estimated cost to complete a Building segment project, which is substantially complete and resulted in a decrease of $14.7 million in income from construction operations, $8.7 million in net income and $0.17 in diluted EPS. There were other immaterial changes in estimates for these projects during the nine months ended September 30, 2015; these immaterial changes offset each other.

 

During the three and nine months ended September 30, 2014, the Company's income from construction operations was positively impacted by $15.8 million and $30.6 million, respectively, because of changes in the estimated recoveries on two Civil segment projects and a Building segment project. These changes in estimates were driven by changes in cost recovery assumptions based on legal rulings pertaining to the Civil segment projects that were issued during the second quarter of 2014, as well as agreements reached with a customer regarding the Building segment project in the third quarter of 2014. The Building project change in estimate resulted in a $14.1 million increase in income from construction operations in the third quarter of 2014. With respect to the two Civil segment projects, during the nine months ended September 30, 2014, there was a $25.9 million increase and a $9.4 million decrease in income from construction operations. The above changes in estimates also resulted in increases of $9.5 million and $18.3 million in net income and $0.19 and $0.37 in diluted EPS during the three and nine months ended September 30, 2014, respectively.

 

The above were the only changes in estimates considered individually material to the Company’s results of operations during the periods presented herein.

  

  

38


 

Results of Operations

 

Comparison of the Three and Nine Months Ended September 30, 2015 with the Three and Nine Months Ended September 30, 2014

 

Revenues

 

The following summarizes our revenues by business segment:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues for the

 

 

 

 

 

 

 

Three Months Ended September 30,

 

 

 

 

 

 

(dollars in millions)

2015

 

2014

 

$ Change

 

% Change

Civil

$

540.2 

 

$

482.7 

 

$

57.5 

 

11.9 

%

Building

 

475.1 

 

 

412.1 

 

 

63.0 

 

15.3 

%

Specialty Contractors

 

325.4 

 

 

355.9 

 

 

(30.5)

 

(8.6)

%

Total

$

1,340.7 

 

$

1,250.7 

 

$

90.0 

 

7.2 

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues for the

 

 

 

 

 

 

 

Nine Months Ended September 30,

 

 

 

 

 

 

(dollars in millions)

2015

 

2014

 

$ Change

 

% Change

Civil

$

1,449.1 

 

$

1,238.4 

 

$

210.7 

 

17.0 

%

Building

 

1,325.4 

 

 

1,082.0 

 

 

243.4 

 

22.5 

%

Specialty Contractors

 

945.1 

 

 

970.0 

 

 

(24.9)

 

(2.6)

%

Total

$

3,719.6 

 

$

3,290.4 

 

$

429.2 

 

13.0 

%

 

Civil Segment

 

Civil segment revenues increased $57.5 million, or 11.9%, and 210.7 million, or 17.0%, for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  The increase for both periods was due principally to increased activity on a runway reconstruction project in New York that was completed months ahead of schedule. Continued progress on a number of bridge projects in the Midwest, as well as progress on many other projects in the New York area, including the CM006 and CS179 mass-transit projects, the Verrazano-Narrows Bridge project, the Amtrak tunnel extension and the Hudson Yards platform, also contributed to the revenue growth.

 

Building Segment

 

Building segment revenues increased $63.0 million, or 15.3%, and $243.4 million, or 22.5%, for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  The increase for both periods was due primarily to increased activity on various building projects in California.

 

Specialty Contractors Segment

 

Specialty Contractors segment revenues decreased $30.5 million, or 8.6%, and $24.9 million, or 2.6%, for the three and nine months ended September 30, 2015, respectively, compared to the same periods in 2014.  The decrease for both periods was due primarily to decreased activity on electrical projects at the World Trade Center and mechanical projects at the United Nations in New York, as well as various smaller electrical projects in the southern U.S. The decrease for both periods was partially offset by increased activity on various electrical projects at Hudson Yards in New York. For the nine-month period, the decrease was also partially offset by increased activity on various other electrical, mechanical and concrete placement projects in New York.

 

39


 

Income from Construction Operations

 

The following summarizes the Company’s income from construction operations by business segment:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income from Construction Operations

 

 

 

 

 

 

 

 

 

 

and Operating Margins

 

 

 

 

 

 

 

 

 

 

Three Months Ended September 30,

 

Change in

 

2015

 

2014

 

Amount

 

Margin

(dollars in millions)

Amount

 

Margin

 

Amount

 

Margin

 

$

 

%

 

%

Civil

$

43.2 

 

8.0 

%

 

$

53.7 

 

11.1 

%

 

$

(10.5)

 

(19.6)

%

 

(3.1)

%

Building

 

6.8 

 

1.4 

%

 

 

19.2 

 

4.7 

%

 

 

(12.4)

 

(64.6)

%

 

(3.3)

%

Specialty Contractors

 

4.7 

 

1.4 

%

 

 

10.9 

 

3.1 

%

 

 

(6.2)

 

(56.9)

%

 

(1.7)

%

 

 

54.7 

 

4.1 

%

 

 

83.8 

 

6.7 

%

 

 

(29.1)

 

(34.7)

%

 

(2.6)

%

Corporate

 

(15.7)

 

(1.2)

%

 

 

(13.4)

 

(1.1)

%

 

 

(2.3)

 

(17.2)

%

 

(0.1)

%

Income from construction operations

$

39.0 

 

2.9 

%

 

$

70.4 

 

5.6 

%

 

$

(31.4)

 

(44.6)

%

 

(2.7)

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income from Construction Operations

 

 

 

 

 

 

 

 

 

 

and Operating Margins

 

 

 

 

 

 

 

 

 

 

Nine Months Ended September 30,

 

Change in

 

2015

 

2014

 

Amount

 

Margin

(dollars in millions)

Amount

 

Margin

 

Amount

 

Margin

 

$

 

%

 

%

Civil

$

120.1 

 

8.3 

%

 

$

156.0 

 

12.6 

%

 

$

(35.9)

 

(23.0)

%

 

(4.3)

%

Building

 

(8.1)

 

(0.6)

%

 

 

28.7 

 

2.7 

%

 

 

(36.8)

 

(128.2)

%

 

(3.3)

%

Specialty Contractors

 

29.0 

 

3.1 

%

 

 

31.3 

 

3.2 

%

 

 

(2.3)

 

(7.3)

%

 

(0.1)

%

 

 

141.0 

 

3.8 

%

 

 

216.0 

 

6.6 

%

 

 

(75.0)

 

(34.7)

%

 

(2.8)

%

Corporate

 

(51.1)

 

(1.4)

%

 

 

(38.7)

 

(1.2)

%

 

 

(12.4)

 

(32.0)

%

 

(0.2)

%

Income from construction operations

$

89.9 

 

2.4 

%

 

$

177.3 

 

5.4 

%

 

$

(87.4)

 

(49.3)

%

 

(3.0)

%

 

Civil Segment

 

Civil segment income from construction operations decreased $10.5 million, or 19.6%, for the three months ended September 30, 2015 compared to the same period in 2014. The decrease was primarily due to the charge for the adverse legal decision on the Brightwater Matter (as discussed in Note 7 and Note 16 of the Notes to the Consolidated Condensed Financial Statements). To a lesser extent, the decrease was also the result of reduced activity on certain higher-margin projects in the segment. The decrease was partially offset by increased project execution activity on a runway reconstruction project in New York, as well as favorable adjustments related to the estimated cost to complete the project and the achievement of certain performance-based milestones for the project. Additionally, the decrease was partially offset by the continued progress on the other projects mentioned above that contributed to the revenue growth for the period. For the nine months ended September 30, 2015, Civil segment income from construction operations decreased $35.9 million, or 23.0%, compared to the corresponding period in 2014. The decrease was due primarily to the Brightwater charge discussed above, decreased activity on certain higher-margin projects and certain tunnel projects on the West Coast, and net favorable adjustments to the estimated recoveries on two projects in the second quarter of 2014, based on legal rulings issued during that period. The decrease was partially offset by the increased project execution activity and favorable adjustments on the New York runway project, as well as the progress on the other projects discussed above that drove revenue growth.  Excluding the charge related to the Brightwater Matter, Civil segment income from construction operations was $67.0 million and $144.0 million for the three and nine months ended September 30, 2015, respectively. (Certain projects above were discussed previously in Use of and changes in estimates.) 

 

Civil segment operating margin declined to 8.0% and 8.3% for the three and nine months ended September 30, 2015 compared to 11.1% and 12.6% for the same periods in 2014.  The changes in Civil segment operating margins  were due primarily to the factors that impacted revenues and income from construction operations. Excluding the charge related to the Brightwater Matter, Civil segment operating margin was 12.4% and 9.9% for the three and nine months ended September 30, 2015, respectively.

 

40


 

Building Segment

 

Building segment income from construction operations decreased $12.4 million and $36.8 million for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  The decrease for both current year periods was primarily because the third quarter results of 2014 included a favorable adjustment for a large hospitality and gaming project. For the nine-month period, the decrease was also due to unfavorable adjustments in 2015 to the estimated cost to complete an office building project in New York (both projects above were discussed previously under Use of and changes in estimates).

 

Building segment operating margin declined to 1.4% and (0.6)%  for the three and nine months ended September 30, 2015 compared to 4.7% and 2.7% for the same periods in 2014.  The reduction in Building segment operating margin was due primarily to the reasons discussed in the preceding paragraph.

 

Specialty Contractors Segment

 

Specialty Contractors income from construction operations decreased $6.2 million, or 56.9%, and $2.3 million, or 7.3%, for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  The decrease for both periods was primarily due to unfavorable adjustments totaling $13.9 million related to a number of electrical projects in New York, none of which were individually material. The decrease was partially offset by increased activity on electrical subcontracts at Hudson Yards and mass-transit projects in New York, and improved performance in our mechanical business unit in New York.

 

Specialty Contractors segment operating margin declined to 1.4% for the three months ended September 30, 2015, and 3.1% for the nine months ended September 30, 2015 compared to 3.1% and 3.2% for the same periods in 2014.  The reduction in Specialty Contractors segment operating margin in the third quarter of 2015 was due primarily to the unfavorable adjustments mentioned in the preceding paragraph.

 

Corporate

 

Corporate general and administrative expenses increased $2.3 million, or 17.2%, and $12.4 million, or 32.0%, for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  The increase for the third quarter was due principally to a reduction in corporate expense allocated to the business segments and increased depreciation expense. The increase for the nine months ended September 30, 2015 was due primarily to increased compensation and depreciation expenses, as well as a reduction in corporate expenses allocated to the business segments.

 

Consolidated Other Income, Interest Expense and Provision for Income Taxes

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(dollars in millions)

September 30, 2015

 

September 30, 2014

 

$ Change

 

% Change

Three Months Ended

 

 

 

 

 

 

 

 

 

 

 

Other income (expense), net

$

5.9 

 

$

(0.4)

 

$

6.3 

 

(1,575.0)

%

Interest expense

 

10.9 

 

 

11.3 

 

 

(0.4)

 

(3.5)

%

Provision for income taxes

 

14.3 

 

 

22.9 

 

 

(8.6)

 

(37.6)

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(dollars in millions)

September 30, 2015

 

September 30, 2014

 

$ Change

 

% Change

Nine Months Ended

 

 

 

 

 

 

 

 

 

 

 

Other income (expense), net

$

5.3 

 

$

(10.8)

 

$

16.1 

 

(149.1)

%

Interest expense

 

33.0 

 

 

33.0 

 

 

 —

 

 —

%

Provision for income taxes

 

25.6 

 

 

53.3 

 

 

(27.7)

 

(52.0)

%

 

 

Other income (expense), net improved by $6.3 million and $16.1 million for the three and nine months ended September 30, 2015 compared to the same periods in 2014.  This was due principally to a reduction in acquisition-related earn-out expense. Additionally, there were losses recognized on the sale of our auction rate securities and expenses related to the refinancing of our Credit Agreement in the second quarter of 2014.

 

Interest expense decreased $0.4 million for the three months ended September 30, 2015 compared to the same period in 2014.  

 

The provision for income taxes was $14.3 million and $25.6 million for three and nine months ended September 30, 2015 compared to $22.9 million and $53.3 million for the same periods in 2014.  The effective income tax rate was 42.0% and 41.1% for the three and nine months ended September 30, 2015 compared to 39.0% and 39.9% for the same periods in 2014. The largest contributor to the

41


 

increase for both periods was increased activity in higher state tax jurisdictions. Higher compensation expense also contributed to the increase, particularly for the three month comparison period.

 

 

Liquidity and Capital Resources

 

Cash and Working Capital

 

At September 30, 2015 and December 31, 2014, cash available for general corporate purposes was $24.1 million and $40.8 million, respectively. In addition, our proportionate share of cash held by joint ventures and available only for joint venture-related purposes, including distributions to joint venture partners, was $72.8 million and $94.7 million at September 30, 2015 and December 31, 2014, respectively. We believe that our cash flows and other available cash sources will be sufficient to satisfy our currently anticipated cash requirements through at least the next 12 months.

 

Our restricted cash was $38.6 million and $44.4 million at September 30, 2015 and December 31, 2014, respectively. Restricted cash is primarily held to secure insurance-related contingent obligations, such as insurance claim deductibles, in lieu of letters of credit, and is not available for general corporate purposes.

 

We do not believe that it is likely we will be called upon to contribute significant additional capital in the event of default by any of our partners. We require each partner in the joint ventures in which we participate to accept joint and several responsibility for all obligations of the joint venture. Prior to forming a joint venture, we conduct a thorough analysis of the prospective partner to determine its capabilities, specifically relating to construction expertise, track record for delivering a quality product on time, reputation in the industry, as well as financial strength and available liquidity. We utilize a number of resources to verify a potential joint venture partner’s financial condition, including credit rating reports and financial information contained in its audited financial statements. We specifically review a potential partner’s available liquidity and bonding capacity. In the event we are concerned with the financial viability of a potential partner, we will require substantial initial cash contributions upon inception of the joint venture to mitigate the risk that we would be required to cover a disproportionate share of the joint venture’s future cash needs.

 

Many of our joint venture contracts are for various government agencies that typically require the joint venture and/or our partners to complete a thorough pre-qualification process. This pre-qualification process typically includes the verification of each partner’s financial condition and capacity to perform the work, as well as the issuance of performance bonds by surety companies who also independently verify each partner’s financial condition.

 

A summary of cash flows for the nine months ended September 30, 2015 and 2014 is set forth below:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Nine Months Ended September 30,

(in millions)

 

 

2015

 

 

2014

Cash flows from:

 

 

 

 

 

 

Operating activities

 

$

20.7 

 

$

(143.4)

Investing activities

 

 

(25.3)

 

 

7.5 

Financing activities

 

 

(34.0)

 

 

153.2 

Net (decrease) increase in cash

 

 

(38.6)

 

 

17.3 

Cash at beginning of year

 

 

135.5 

 

 

119.9 

Cash at end of period

 

$

96.9 

 

$

137.2 

 

During the nine months ended September 30, 2015, we generated $20.7 million in cash from operating activities. Working capital changes decreased cash from operating activities by $63.8 million, due primarily to the funding of unapproved change orders and an increase in receivables associated with higher revenue, partially offset by an increase in accounts payable. In the first quarter of 2015, we received full and final payments related to settlements on a large hospitality and gaming project and on a healthcare building project. We used $25.3 million in cash from investing activities, due primarily to the acquisition of property and equipment of $33.4 million. We used $34.0 million in cash from financing activities which was primarily due to debt repayments, partially offset by increased borrowings under our Credit Agreement.

 

Cash from operating activities for the nine months ended September 30, 2015 showed significant improvement over the nine months ended September 30, 2014 due primarily to a $237 million improvement in the use of working capital.

 

At September 30, 2015, we had working capital of $1,132.3 million, and a ratio of current assets to current liabilities of 1.73,  compared to working capital of $1,114.0 million, and a ratio of current assets to current liabilities of 1.82 at December 31, 2014.

 

 

42


 

Long-term Debt

 

As disclosed in Note 10 of the Notes to the Consolidated Condensed Financial Statements, the Company has a $300 million Revolving Facility, under which, as of September 30, 2015, the Company had $140.0 million of outstanding borrowings, $0.2 million reserved for outstanding letters of credit and $159.8 million available for future borrowings. In addition, under the Credit Agreement the Company may borrow an additional $300 million by either increasing the Revolving Facility or entering into one or more new term loans. We believe that our financial position and credit arrangements are sufficient to support our current backlog and anticipated new work.

 

The Company’s total debt outstanding at September 30, 2015 was $832.2 million, a decrease of $33.2 million from $865.4 million at December 31, 2014. This decrease was principally due to net reductions of $43.2 million, related to payments on our Term Loan and other debt, offset by a net increase in borrowings of $10.0 million on the Revolving Facility. Our debt to equity ratio was 0.59 as of September 30, 2015 compared to 0.63 as of December 31, 2014.

 

As discussed in Note 7 and Note 16 of the Notes to the Consolidated Condensed Financial Statements, during the three months ended September 30, 2015 the Company recognized a non-cash, pre-tax charge of $23.9 million as a result of an adverse ruling on the Brightwater litigation matter. The financial impact of this charge caused the Company to breach its financial covenants under the Credit Agreement. On November 13, 2015, the Company received a waiver from its lenders for the Credit Agreement. Therefore, the Company is not in default under the Credit Agreement. As of the filing date of this Form 10-Q, the Company expects to be in compliance with the financial covenants under the Credit Agreement for future periods.

 

There were no other material changes in our contractual obligations during the nine months ended September 30, 2015.

 

Off-Balance Sheet Arrangements

 

We do not have financial partnerships with unconsolidated entities, such as entities often referred to as structured finance or special purpose entities which are often established for the purpose of facilitating off-balance sheet arrangements or other contractually narrow or limited purposes. Accordingly, we are not exposed to any financing, liquidity, market or credit risk that could arise from such relationships.

 

 

Forward-looking Statements

 

The statements contained in this Management’s Discussion and Analysis of the Consolidated Condensed Financial Statements on Form 10-Q that are not purely historical are forward-looking statements within the meaning of Section 27A of the Securities Act of 1933 and Section 21E of the Securities Exchange Act of 1934, including without limitation, statements regarding our management’s expectations, hopes, beliefs, intentions or strategies regarding the future. These forward-looking statements are based on our current expectations and beliefs concerning future developments and their potential effects on us. Our expectations, beliefs and projections are expressed in good faith and we believe there is a reasonable basis for them. There can be no assurance that future developments affecting us will be those that we have anticipated. These forward-looking statements involve a number of risks, uncertainties (some of which are beyond our control) or other assumptions that may cause actual results or performance to be materially different from those expressed or implied by such forward-looking statements. These risks and uncertainties include, but are not limited to:

 

·

our ability to win new contracts and convert backlog into revenue;

·

our ability to successfully and timely complete construction projects;

·

our ability to realize the anticipated economic and business benefits of our acquisitions and our strategy to assemble and operate a Specialty Contractors business segment;

·

the outcomes of pending or future litigation, arbitration or other dispute resolution proceedings and the timing of related collections;

·

the potential delay, suspension, termination or reduction in scope of a construction project;

·

the continuing validity of the underlying assumptions and estimates of total forecasted project revenues, costs and profits and project schedules;

·

the availability of borrowed funds on terms acceptable to us;

·

the ability to retain certain members of management;

·

the ability to obtain surety bonds to secure our performance under certain construction contracts;

·

possible labor disputes or work stoppages within the construction industry;

·

changes in federal and state appropriations for infrastructure projects and the impact of changing economic conditions on federal, state and local funding for infrastructure projects;

·

possible changes or developments in international or domestic political, social, economic, business, industry, market and regulatory conditions or circumstances;

·

actions taken or not taken by third parties, including our customers, suppliers, business partners, and competitors and legislative, regulatory, judicial and other governmental authorities and officials;

43


 

·

the impact of inclement weather conditions on projects; and

·

other risks and uncertainties discussed under the heading “Risk Factors” in our Annual Report on Form 10-K for the year ended December 31, 2014 filed with the Securities and Exchange Commission on February 26, 2015.

 

We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.

 

 

Item 3. Quantitative and Qualitative Disclosures About Market Risk

 

There has been no material change in our exposure to market risk from that described in Item 7A of our Annual Report on Form 10-K for the year ended December 31, 2014, filed with the Securities and Exchange Commission on February 26, 2015.

 

 

Item 4. Controls and Procedures

 

Disclosure Controls and Procedures

 

An evaluation of the effectiveness of the design and operation of our disclosure controls and procedures as defined by Rule 13a-15(e) under the Securities Exchange Act of 1934, as amended (“Exchange Act”), as of the end of the period covered by this Quarterly Report on Form 10-Q was made under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that the Company’s disclosure controls and procedures (a) were effective to ensure that information we are required to disclose in reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in Securities and Exchange Commission rules and forms and (b) include, without limitation, controls and procedures designed to ensure that information required to be disclosed by us in reports filed or submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.

 

Changes in Internal Controls Over Financial Reporting

 

There were no changes in our internal control over financial reporting during the period covered by this report that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

 

 

Part II. - Other Information

 

Item 1. Legal Proceedings

 

From time to time in the ordinary course of business, we are subject to claims, asserted or unasserted, or named as a party to lawsuits or investigations. Litigation can be expensive and disruptive to normal business operations. Moreover, the results of legal proceedings cannot be predicted with any certainty and, in the case of more complex legal proceedings, the results are difficult to predict at all. We disclosed information about certain of our legal proceedings in Part I, Item 3 of our Annual Report on Form 10-K for the year ended December 31, 2014. For an update to those disclosures, see Note 7 of the Notes to the Consolidated Condensed Financial Statements.

 

Item 1A. Risk Factors

 

Information regarding risk factors affecting our business is discussed in our Annual Report on Form 10-K for the year ended December 31, 2014. There have been no material changes from those risk factors during the nine months ended September 30, 2015.

 

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

 

None.

 

Item 3. Defaults Upon Senior Securities

 

None.

 

44


 

Item 4. Mine Safety Disclosures

 

Section 1503 of the Dodd-Frank Wall Street Reform and Consumer Protection Act (the “Dodd-Frank Act”) requires domestic mine operators to disclose violations and orders issued under the Federal Mine Safety and Health Act of 1977 (the “Mine Act”) by the federal Mine Safety and Health Administration. We do not act as the owner of any mines but we may act as a mining operator as defined under the Mine Act where we may be an independent contractor performing services or construction of such mine.

 

Information concerning mine safety violations or other regulatory matters required by Section 1503(a) of the Dodd-Frank Act and Item 104 Regulation S-K is included in Exhibit 95.

 

 

Item 5. Other Information

 

On November 9, 2015 the Company and Gary Smalley, the Company’s new Executive Vice President and Chief Financial Officer, entered into an amended and restated letter agreement, to be effective upon execution retroactive to July 20, 2015, and which supersedes and replaces the original letter agreement between the Company and Mr. Smalley, which was dated July 20, 2015. The amended and restated letter agreement revises certain relocation-related payments to Mr. Smalley related to his move from Texas to California by providing for a special bonus of $700,000 (the “Special Bonus”), to be paid to Mr. Smalley no later than January 7, 2016. It also provides that in determining the amount of future bonuses earned by Mr. Smalley, the Company may reduce the amount of such future bonuses (in each case to no less than $0) by an aggregate amount of up to the amount of the Special Bonus.

 

Item 6. Exhibits

 

 

 

 

 

 

 

Exhibit 3.     Articles of Incorporation and By-laws

 

3.1

Restated Articles of Organization (incorporated by reference to Exhibit 4 to Form S-2 (File No. 33-28401) filed on April 28, 1989).

 

3.2

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.2 to Form S-1 (File No. 333-111338) filed on December 19, 2003).

 

3.3

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on April 12, 2000).

 

3.4

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on September 11, 2008).

 

3.5

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.5 to Form 10-Q filed on August 10, 2009).

 

3.6

Second Amended and Restated By-laws of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on November 24, 2009).

 

 

 

Exhibit 10.     Material Contracts

 

10.1*

Letter Agreement, dated November 9, 2015, by and between Gary Smalley and Tutor Perini Corporation filed herewith.

 

 

 

Exhibit 31.1

Certification of Principal Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 31.2

Certification of Principal Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 32.1

Certification of Principal Executive Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 32.2

Certification of Principal Financial Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.

 

 

Exhibit 95

Mine Safety Disclosure — filed herewith.

 

 

Exhibit 101.INS

XBRL Instance Document.

Exhibit 101.SCH

XBRL Taxonomy Extension Schema Document.

Exhibit 101.CAL

XBRL Taxonomy Extension Calculation Linkbase Document.

Exhibit 101.LAB

XBRL Taxonomy Extension Label Linkbase Document.

Exhibit 101.PRE

XBRL Taxonomy Extension Presentation Linkbase Document.

Exhibit 101.DEF

XBRL Taxonomy Extension Definition Linkbase Document.


* Management contract or compensatory arrangement required to be filed as an exhibit pursuant to Item 6 of Form 10-Q.

 

45


 

SIGNATURES

 

Pursuant to the requirements of the Securities Exchange Act of 1934, as amended, the registrant has duly caused this report to be signed on its behalf by the undersigned hereunto duly authorized.

 

 

 

 

Tutor Perini Corporation

 

Registrant

 

 

 

 

Date: November 16, 2015

/s/ Gary G. Smalley

 

Gary G. Smalley,

 

Executive Vice President and Chief Financial Officer

 

Duly Authorized Officer and Principal Financial Officer

 

 

 

46