EX-10.7 9 ff12019ex10-7_power.htm UNOFFICIAL ENGLISH TRANSLATION OF TECHNICAL DEVELOPMENT (COMMISSION) CONTRACT BETWEEN ZHUHAI POWERBRIDGE TECHNOLOGY CO., LTD AND GUANGXI NANNING DANGDAI FENGYUN INVESTMENT MANAGEMENT CO., LTD DATED AS OF JULY 27, 2016.

Exhibit 10.7

  

Technical Development (Commission) Contract

  

Project Name: Construction Project for Information Platform in Phase I of Nanning Comprehensive Bonded Area

 

Commissioning Party (Party A): Guangxi Nanning DangdaiFengyun Investment Management Co., Ltd

 

Commissioned Party (Party B): Zhuhai PowerBridge Technology Co., Ltd

 

Signature Date: July, 2016

 

Signature Address: Zhuhai

 

Period of Validity: One Year

  

1

 

 

Commissioning Party (Party A): Guangxi Nanning Dangdai Fengyun Investment Management Co., Ltd

 

Address: Floor 12, Tower A, Industry Building, Nanning Advertisement Industrial Park, No. 28, Binhe Road, Nanning

 

Legal Representative: Huang Weiping

 

Project Contact Person: Lu Hengyu

 

Contact information: 0771-5816916

 

E-mail: /__________________________

 

Address: Floor 12, Tower A, Industry Building, Nanning Advertisement Industrial Park, No. 28, Binhe Road, Nanning

 

Telephone: 0771-5816916 Fax: 0771-5816916

 

Commissioned Party (Party B): Zhuhai PowerBridge Technology Co., Ltd

 

Address: Floor D-1, Southern Software Park, No. 1, Software Park Road, Tangjiawan, Zhuhai

 

Legal Representative: BAN LOR

 

Project Contact Person: Li Jin

 

Contact information: 13978825992

 

E-mail: Jinli@powerbridge.com

 

Correspondence Address: Floor D-1, Southern Software Park, No. 1, Software Park Road, Tangjiawan, Zhuhai

  

2

 

 

Telephone: 0756-3395666 Fax: 0756-3395667

 

Service Hotline: 400-885-4114

 

Bank Name: Bank of Communications Zhuhai Branch Xiangzhou Sub-branch

 

Account Name: Zhuhai PowerBridge Technology Co., Ltd

 

Bank Account: 444000091018000745538

 

Upon the procurement tender procedure of Guangxi Nanning Municipal Government, Party A accepts the bid of Party B for the Project, and determines Party B as the construction unit for the Construction Project for Information Platform in Phase I of Nanning Comprehensive Bonded Area. In accordance with the Contract Law of the People's Republic of China, the Copyright Law of the People's Republic of China and other relevant laws and rules, and on the basis of consensus reached through full consultations in the principle of mutual understanding and equal cooperation, Party A and Party B come to agreement for relevant affairs about the Project and hereby authorize their respective representatives to sign the Contract (hereinafter short for “the Contract) with below terms and conditions.

  

1Procurement Scope and Content

 

1.1Procurement Name: Party B shall supply deliverables in the Construction Project for Information Platform in Phase I of Nanning Comprehensive Bonded Area (refer to the Project Equipment List for detailed information) As for the detailed information about the final software and hardware list, Party B shall investigate and analyze the demands of Party A according to the actual requirements of the Project after the kick-off of the Project. Both parties shall work together to confirm the software functions, hardware facilities, hardware configuration and service items and perform supplements and improvement for relevant Schedules of the Contract like technical specification. Under the supervision and confirmation of the supervision authority, Party A and Party B shall then sign to confirm the final version of Project Equipment List and Software Function Confirmation Letter to guarantee that the platform could reach the requirements described in the bid documents.

 

1.2In the event that the procurement quantity determined in the Project Equipment List and Software Confirmation Letter is not consistent with the actual quantity used, Party A will negotiate with Party B to sign a supplementary contract without making any changes to other terms and conditions of the Contract. Party B shall supply goods according to the actual use quantity of the Project. Both parties shall calculate the final settlement amount according to the actual use quantity and actual engineering quantity of the Project.

  

3

 

 

2Contract Price

 

No.   Item Contents  Price (Yuan) 
 1   Equipment procurement   23,988,800 
 2.   Software development and technical service fee   3,600,000 
     Total Contract Amount: RMB Twenty-seven Million Five Hundred and Eighty-eight Thousand Eight Hundred Yuan in Total   27,588,800 

 

 

3Delivery Requirements

 

3.1       Delivery Date: complete the delivery, installation and commissioning before July 31, 2016

 

3.2       Place of Delivery: A place in Nanning City (place designated by the Purchaser)

 

3.3       Delivery Method: Site construction and training

  

4Quality Guarantee Deposit for the Project

 

4.1After the acceptance of the Project, the amount equivalent with 5% of the contract amount will be used as the quality guarantee deposit. Upon the maturity of the warranty period, Party A shall refund the corresponding amount to Party B according to terms and conditions of the Contract.

 

5Quality Assurance and After-sales Services

 

5.1Warranty Period:

 

Hardware: one year from the date of arrival of the hardware equipment;
Software: One year from the date of on-line operation of the software system.

 

5.2In the warranty period, Party B shall assume quality assurance liabilities for all software and hardware supplied by it, without any additional charge to Party A.

 

4

 

 

5.3In the event that any software and hardware supplied by Party B has any quality problems in the using process, Party B shall provide response to Party A within two hours upon the receiving of the fault notice. In case of necessity in the belief of Party A, Party B shall come to the site to resolve such quality issues.

 

5.4In the warranty period, Party B is responsible for repairing errors in the software system, through software patch.

 

5.5In purchasing any components, Party B shall require the supplier to provide and same warranty period and supply spare parts and professional repair services at favorable prices. In case of any fault of the system due to quality defects of system hardware, Party B shall take charge of the maintenance, repair and technical supports. If required, Party B shall contact the manufacturer to repair or replace the corresponding parts. Non-intentional damages and damage arising in the normal using scope should be repaired for free. No separate expense should be charged for such services.

 

5.6Within the scope of the bidding documents, if Party A believes that the hardware purchased by Party B does not meet the technical requirements of Party A, both parties shall negotiate with each other according to the actual situations and handle according to below methods:

 

(1)Replace: Party B shall bear all expenses incurred;

 

(2)Handle at depreciated value: both parties shall negotiate to determine the price;

 

(3)Reject the products: if the quality of the hardware still fails to reach the requirements of Party A after the efforts of Party B and its suppliers, Party A shall provide a written notice and describe the reasons if it would like to reject the product. Upon the agreement of Party B, Party A could require Party B to refund the corresponding amount. In such cases, Party A could also require Party B to undertake all relevant direct expenses (transportation expenses, insurance expense, inspection expenses, interest of the contract price, banking service charges and so forth).

 

5.7Party B’s failure in fulfilling the above obligations in the warranty period would be deemed as breach of contract. In such cases, Party A shall also have the right to investigate Party B's relevant responsibilities.

 

5.8After-sales maintenance period shall commence upon the completion of the platform construction. Both parties shall negotiate and sign a project maintenance service agreement one month before the maturity of the warranty period. The annual maintenance fee is subject to the accumulated service amount. To facilitate Party B in providing professional services, the specific service responsibilities and service scope shall be defined in the agreement reached through friendly negotiation.

  

5

 

 

6Payment Stages

 

No.  Payment Basis and Date  Amount (Yuan) 
1  Pay 30% of the total contract amount within 10 working days upon the signature of the Contract.;   8,276,640 
2.  Pay 40% of the total contract amount within 10 working days after the hardware equipment is delivered to Party A;   11,035,520 
3  Pay 25% of the total contract amount within 10 working days after the Project passes the national acceptance;   6,897,200 
4  The remaining 5% of the total contract amount will be used as quality guarantee deposit for the project. In the absence of any quality issues, Party A shall refund the quality guarantee deposit (without interest) to Party B within 10 working days upon the maturity of the warranty period.   1,379,440 
Total  In Capital: Total Contract Amount: RMB Twenty-seven Million Five Hundred and Eighty-eight Thousand Eight Hundred Yuan in Total   27,588,800 

 

7Responsibilities and Obligations of Party B

 

7.1       Work contents to be jointly undertaken by Party A and Party B:

 

(1)The Project shall be completed under the cooperation of both parties. Both parties shall constitute a project management team. Party A and Party B shall designate their respective project responsible person to participate in the whole process of the platform construction and assume the corresponding responsibilities associated with the Project.

 

(2)Complete the investigation and analysis for the project demands and the overall planning and design of the Project, and confirm the Project Equipment List and Software Function Confirmation Letter.

 

(3)All critical items of the Project should be communicated between both parties in written. All amendments and supplement about the Project should be confirmed by both parties in written.

 

(4)Complete the preparation of working plan and objectives for various stages, confirmation for the completed tasks, and the acceptance check and final confirmation of software and hardware.

  

6

 

 

7.2       Work contents to be undertaken by Party A:

 

(1)Party A shall designate responsible person for the Project to take charge of coordinating resources of party A and relevant third parties (including users of the platform) to cooperate with Party B in implementing relevant project work, providing the basic environment and required conditions for the implementation of the Project, and performing confirmation and making timely decisions for specific events of the Project on behalf of Party A. Party B will take the information and decision-making opinions provided by project manager of Party A as the basis for the implementation of the Platform. Party A shall be liable for the data, information materials and decision-making opinions of its project manager, and assume the relevant responsibilities and consequence of its decisions.

 

(2)Take charge of the management of the platform project, organize personnel of relevant departments in participating in the project, and maintain the relationship with the governmental authorities and relevant supervision departments.

 

(3)Take charge of checking, supervising and accepting the delivery of software and hardware in various stages, and completing the acceptance check of the platform.

 

7.3       Work contents to be undertaken by Party B:

 

(1)Perform Party B's duties and responsibilities in accordance with the project plan and project objectives.

 

(2)Conduct a detailed investigation for the platform demands of of Party A, provide implementation proposal for the construction of the platform, which shall be taken as the guiding document of the project construction after final confirmation of both parties.

 

(3)Provide hardware facilities and equipment required by the platform, set up the network system, construct the computer room and guarantee the application and sound operation of the platform.

 

(4)Take charge of the technological research and development of the platform and development of corresponding applications, arrange tests, provide startup services, on-line operation services, system initialization services and technical supports, and arrange training programs about software application to personnel of Party A, and provide professional implementation and services.

 

7

 

 

8Property Rights

 

8.1Party B guarantees that the software and hardware provided will not infringe the patent, trademark or copyright of any third party.

 

8.2The intellectual property rights in the final result of the customized software commissioned by Party A to Party B in this contract shall be jointly owned by Party A and Party B. Technical achievements and intellectual property rights already owned by Party B before undertaking the Project are exceptional to the above provisions. Party A shall have the permanent use right of the Project.

 

9Technical Materials

 

9.1       Within the scope of the Contract, Party A will provide Party B with the relevant technical requirements about the goods to be purchased.

 

9.2       Party B shall provide Party A with relevant technical materials for the use of the goods within the time specified in the procurement documents.

 

9.3Without the prior written consent of both parties, neither party may provide clauses, specification, plan, drawings, samples or materials of the Contract or in connection with the Contract provided by the other party to any person irrelevant with the performance of the Contract. In the event of disclosure made to personnel in connection the performance of the Contract, Party B shall still fulfill the confidentiality obligation and limit such disclosure within the necessity for the performance of the Contract.

  

10Collaboration Matters at Various Stages of the Project

 

10.1       Methods for Equipment Delivery, Installation and Commissioning, System Deployment and Project Acceptance Check

 

1)Equipment Delivery

 

²Party B shall, before shipment of the goods, request the supplier to provide packages that could meet the requirements about the transportation, moisture resistance, shock resistance, rust prevention and damage prevention in loading and unloading and so forth for the goods to ensure the goods could be delivered to the designated place of Party A in a intact and safe manner.

  

8

 

 

²Party B shall require its suppliers to deliver the user manual, quality certificate, warranty documents, accompanied parts and tools and list of the goods together with the goods. Party B shall submit equipment delivery list and relevant documents to Party A.

 

²Party B shall inform Party A 24 hours before the arrival of the goods at designated place of Party A to ensure Party A has sufficient time to arrange the acceptance of the equipment. Party B shall also inform the arrival of the goods to Party A. Party B shall be liable for the risks arising before the goods are delivered to Party A.

 

²Party A shall, within five working days, carry out arrival inspection, confirmation and receipt signature for the equipment delivered by Party B according to relevant regulations. In the event that the appearance and specification of the goods fails to conform to relevant requirements or Party A has any objections to quality of the goods, Party A shall issue a written notice to Party B within five working days upon the arrival of the goods. In such cases, Party B shall handle and feedback to Party A in time. No refusal and delay are permitted. The absence of written objection notice would be deemed as completion of the equipment delivery.

 

2)Installation and Commissioning of Equipment:

 

²Within the scope of the terms and conditions of this contract, Party B shall arrange installation and commissioning for the equipment according to designated requirements of Party A, and submit equipment delivery list and relevant documents to Party A.

 

²Party A shall make fundamental environment and required conditions for the installation of the equipment in time.

 

²Party A shall confirm the equipment deployed by Party B within five working days. In case of any objections to equipment deployed by Party A, Party A shall, within five working days,. Issue a written notice to Party B. In such cases, party B shall arrange amendment and improvement for the installation and deployment of the equipment. No delay or refusal of Party B would be accepted. The absence of written objection notice would be deemed as completion of the equipment installation and commissioning.

 

3)System Deployment:

 

²In accordance with the terms and conditions of this contract, Party B shall arrange installation and deployment of the system according to designated requirements of Party A, and submit equipment delivery list and relevant documents to Party A.

  

9

 

 

²Party A shall confirm the software functions deployed by Party B within five working days. In case Party A has any objections to the software system installed and deployed by Party B, Party A shall, within five working days, issue a written notice to Party B. In such cases, Party A could require Party B to arrange amendment and improvement for the software functions. No delay or refusal of Party B would be accepted. The absence of written objection notice from party A would be deemed as completion of the deployment for the system.

 

4)Acceptance Check of the Project

 

²As the final stage of project construction, project acceptance will be initiated after Party B completes equipment delivery, equipment installation and commissioning, software system deployment and trial operation. Party A organizes relevant personnel to perform acceptance check for the overall operation status of the Project.

 

²On the basis of the scope and commitments described in the tender and bid documents of the Project, and the specification documents, technical indicators, quality indicators and other Project information in the Project Equipment List and Software Function Confirmation Letter confirmed by both parties, Party B shall prepare relevant acceptance check documents for the Project according to technical requirements of Party A and regulations in applicable national standard or industry standard. These acceptance check documents should be submitted to Party A, who would take them as the basis for the acceptance check of the Project.

 

²At the time of acceptance check, both Party A and Party B should present at the site. Acceptance check result report should be issued upon the completion of the acceptance check, which shall be confirmed by signatures and seals of both parties.

 

²Party B shall arrange professional training for Party A. Party A shall arrange and organize its personnel to participate in professional training programs arranged by Party B. The training contents shall cover the application, maintenance and operation of the system.

 

²After the input of typical data of users, the software system shall run normally and the output data should be correct.

  

10

 

 

11Liabilities for Breach of Contract

 

11.1Within the scope of the Contract, Party B shall supply goods in accordance with the Project Equipment List and Software Function Confirmation Letter. Party A’s rejection of goods without any just cause and written rejection notice would be deemed as Party A’s breach of contract. In such cases, Party A shall pay liquidated damage at the amount of 5% of the value of the goods rejected.

 

11.2After completing any staged work specified in the Contract, Party B shall send an official notice to Party A. If Party A fails to pay any contract price to Party B without any reasonable cause, Party A shall pay the liquidated damage at the amount equivalent with 0.05% of the overdue amount for each day delayed. In case the overdue period is more than 20 working days, Party A would be deemed as breach of contract. In case of breach of contract of Party A, Party A shall pay Party B a liquidated damage at the amount of 5% of the total contract value. If Party B's loss exceeds the liquidated damages, Party A shall continue undertaking the compensation liability.

 

11.3In the event that Party A fails to provide the basic facilities and required conditions for the installation of the equipment and system, or fails to settle the contract payment in time and in full amount according to terms and conditions of the Contract, Party A shall be liable for relevant liabilities and consequences, including loss of Party B arising from delay in the project progress caused by such failure of Party A.

 

11.4In the event that Party B fails to deliver goods on time for reasons other than fault of Party A, Party B shall pay liquidated damage at the amount of 0.05% of the amount of the delayed goods. Party B would be deemed as breach of contract if it fails to deliver the goods for more than 20 working days after the due date specified in the Contract. In case Party B has such behaviors in breach of contract, Party B shall pay Party A a liquidated damage at the amount of 5% of the total contract amount.

 

11.5If the variety, model, specification, technical parameters and quality of goods delivered by Party B fail to conform to provisions of the Contract and standards specified in the Goods Demand List of the tender document, Party A has the right to reject the goods. If Party B agrees to replace the goods but delays in the delivery, Party A would handle according to provisions about delay in delivery. In case Party B refuses replacing goods, Party A has the right to terminate the Contract without the consent of Party A. Written notices should be used in such process as basis.

  

12Handling of Force Majeure Events

 

12.1In the term of the Contract, the performance period could be postponed if either party fails to perform the Contract due to the occurrence of any force majeure event. The period postponed should be same with the influencing period of the force majeure event.

  

11

 

 

12.2After the occurrence of such event, the affecting party shall inform the other party immediately, and send certificate issued by relevant authorities.

 

12.3If the force majeure event continues for more than 120 days, both parties shall make decision about whether to continue performing the Contract through friendly negotiation.

  

13Supplementary Rules

 

13.1Any dispute in connection with the Contract or relevant affairs should be first settled through friendly negotiation. In case no consensus could be reached through negotiation, the dispute should be submitted to the arbitration agency or People’s Court at the respective places of both parties for arbitration or judgment.

 

13.2       Without the consent of Party B, Party A shall transfer any rights and obligations under the Contract to any third party.

 

13.3       Modifications and changes to the Contract: Both parties can only amend the Contract through written document signed by both parties.

 

13.4       The Contract shall become effective after the signature of the legal representatives or authorized representatives and official seals of both parties.

 

13.5       Any unmentioned affairs of the Contract should be implemented according relevant clauses in the Contract Law of the People’s Republic of China.

 

13.6       The Contract should be made out in quadruplicate, each party shall keep two copies, all of which shall have same legal force.

 

142. Schedules of the Contract

 

Schedules: Project Equipment List, List of Software Development and Technical Service Fee

  

Party A: Guangxi Nanning Dangdai Fengyun Investment Management Co., Ltd

   

Signature: ________________________    

 

Signature Date: July 27, 2016

 

Party B: Zhuhai PowerBridge Technology Co., Ltd

 

(Seal)

 

Signature: ________________________    
   
Signature Date: July 27, 2016  

 

 

 

 

 

 

 

 

 

 

 

  

12