EX-10.22 5 exhibit10-22.htm EXHIBIT 10.22 Helius Medical Technologies, Inc.: Exhibit 15-C-0096-QASP - Filed by newsfilecorp.com

QUALITY ASSURANCE SURVEILLANCE PLAN

For the Development and U.S. Food and Drug Administration (FDA) Clearance of the
Portable Neuromodulation Stimulator (PoNSTM) Device
Contract Number: W81XWH-15-C-0096
Contractor Name: NeuroHabilitation Corporation

1. PURPOSE.

This Quality Assurance Surveillance Plan (QASP) provides a systematic method to evaluate performance for the stated contract. This QASP explains the following:

  What will be monitored?
  How monitoring will take place?
  Who will conduct the monitoring?
  How monitoring efforts and results will be documented?

This QASP does not detail how the contractor accomplishes the work. Rather, the QASP is created with the premise that the contractor is responsible for management and quality control actions to meet the terms of the contract. It is the Government’s responsibility to be objective, fair, and consistent in evaluating performance. In addition, the QASP should recognize that unforeseen and uncontrollable situations may occur.

This QASP is a “living document” and the Government may review and revise it on a regular basis. However, the Government shall coordinate changes with the contractor. Updates shall ensure that the QASP remains a valid, useful, and enforceable document. Copies of the original QASP and revisions shall be provided to the contractor and Government officials implementing surveillance activities.

2. GOVERNMENT ROLES AND RESPONSIBILITIES.

The following personnel shall oversee and coordinate surveillance activities.

a. Contracting Officer (KO) - The KO shall ensure performance of all necessary actions for effective contracting, ensure compliance with the contract terms, and shall safeguard the interests of the United States in the contractual relationship. The KO shall also assure that the contractor receives impartial, fair, and equitable treatment under this contract. The KO is ultimately responsible for the final determination of the adequacy of the contractor’s performance.

Assigned KO:
Organization or Agency: US Army Medical Research Acquisition Activity
Telephone: Phone:
Email:

b. Contracting Officer’s Representative (COR) – The COR is located at the U.S. Army Medical Materiel Agency (USAMMA) Office at. The COR will be responsible for technical administration of this contract, and shall assure proper Government surveillance of the contractor’s performance with the assistance of two (2) Contracting Officer’s Technical Representatives (COTRs). The COR shall keep a quality assurance file. At the conclusion of the contract or when requested by the KO, the COR shall provide documentation to the KO. A COR is not empowered to make any contractual commitments or to authorize any contractual changes on the Government’s behalf. The contractor shall refer any changes they deem may affect contract price, terms, or conditions to the KO for action.

Assigned COR:
Title: Assistant Project Manager, USAMMA
Telephone:
Email:


3. CONTRACTOR REPRESENTATIVES:

The following employees of the contractor serve as the contractor’s Program Managers for this contract.

Assigned Program Manager: Philippe Deschamps
Title: President, CEO, Helius Medical Technologies
Telephone:
Email:

4. PERFORMANCE STANDARDS.

Performance standards define desired services. The Government performs surveillance to determine if the contractor exceeds, meets or does not meet these standards.

The Performance Requirements Summary Matrix, shown in Table 1 below and contained in the Performance Work Statement (PWS) for this contract in Section C, includes performance standards. The Government shall use these standards to determine contractor performance and shall compare contractor performance to the Acceptable Quality Level (AQL).

Table 1. Performance Requirements

Number Deliverable Performance Standards Acceptable Quality Level Methods Used & Frequency Paragraph Number Compliance Level Data
1 Reports (CDRL A011 & A012) Contractor’s plans, updates, and reports that describe progress made within the period and inform the Government of existing or potential issues and problem areas and risk mitigation plans 100% of project issues identified COR reviews reports as provided and any subsequent modifications 3.1.1, 3.1.2,
3.1.3, 3.1.4,
3.2.1, 3.3.1,
3.3.3, 3.5.1,
3.5.2, 3.5.3,
3.5.4, and
3.5.5
Reports received as specified in PWS



Number Deliverable Performance Standards Acceptable Quality Level Methods Used & Frequency Paragraph Number Compliance Level Data
2 IRB Approved Clinical Protocols (CDRL A003) Contractor’s Clinical Study Protocol and informed consent form including Statistical Analysis Plan, Clinical Monitoring Plan, Data Management Plan, Proposed Clinical Data Management System, sample Case Report Form, End User Guidelines (training and technical support), and Recruitment and Retention Plan for each site. Suitable for submission to FDA in support of device clearance COR reviews documents as provided 3.1.3 Within 3 months of contract award
3 IRB Approvals (CDRL A004) Documentation of appropriate IRB approvals from each study site, institution, and the Army, as required Suitable for submission to FDA in support of device clearance COR reviews documents as provided 3.1.4 Within 3 months of contract award and prior to the start of the clinical study
4 Representati ve Test Articles (CDRL A005) Final development and manufacturing of representative test articles for use in the clinical trial; report completion and delivery to clinical test sites; contingency plan 120 (and/or a proportionate amount consistent with FDA guidance) representative test articles (PoNSTM, version 4.0) in support of the clinical trial COR reviews as provided 3.1.5 Prior to start of clinical trial



Number Deliverable Performance Standards Acceptable Quality Level Methods Used & Frequency Paragraph Number Compliance Level Data
5 Conduct Clinical Study (CDRL A006) Conduct clinical study in accordance with study protocol and governing regulations Study conducted to meet FDA submission and Army requirements at a minimum of 3 study sites and 120 subjects (and/or a proportionate amount consistent with FDA guidance) COR reviews documents as provided (monthly/quart erly/annual reports, IMF update, etc.) 3.2.1 Study is completed within period of performance
6 Interim Data Analysis (CDRL A007) Conduct an interim data analysis and provide Interim Clinical Study Report and Mitigation Plan Verification study is adequately powered and mitigation plan for issues identified during analysis COR reviews documents as provided 3.2.2 Within 30 days after completion of 60 subjects (and/or a proportionat e amount consistent with FDA guidance)
7 FDA de novo/510(k) Submission with Supporting Documentati on and Pre- Clinical Study Results Summary (CDRL A008, A009 & A013) Complete, final report all studies, papers, pre- clinical studies, and other documentation that will support the de novo/510(k) submission packet 100% complete to support all claims and data used for the submission to FDA in support of device clearance COR reviews documents as provided 3.3.1, 3.3.2 & 3.5.4 Concurrently with FDA submission
8 Technical Data Package (CDRL A010) Provide copies of TDP content, which includes the Design History File, Device Master Record, and Device History File. All necessary documentation and data required to continue the development or production of the product COR reviews documents as provided 3.3.4 Within seven (7) business days of the Government ’s request and/or at contract expiration.



Number Deliverable Performance Standards Acceptable Quality Level Methods Used & Frequency Paragraph Number Compliance Level Data
9 Delivery of 2 FDA cleared PoNSTM Devices Delivery of 2 FDA cleared PoNSTM devices with the indication as an aid to therapy for chronic balance deficits resulting from mild to moderate TBI and all accessories, product inserts, and supporting manuals/literature (e.g. including user, technical, and maintenance manuals) as applicable. 100% complete FDA cleared medical devices COR reviews as provided 3.4.1 Within 10 business days of FDA clearance
10 For Contract Requiring Performance or Delivery in a Foreign Country. IAW PWS Section 4.1.3.2. 100% COR Verification 2.5 Within 60 calendar days of foreign travel.

5. METHODS OF QA SURVEILLANCE.

Various methods exist to monitor performance. The COR shall use the surveillance methods listed below in the administration of this QASP.

  Feedback from Oversight Board
  Feedback from Government Users
  Feedback from Property Book Officers
  Direct Observation
  100% Inspection
  Review of Quarterly Reports (various)
  Review of Monthly Reports (various)

Regardless of the surveillance method, the COR shall always contact the contractor's task manager or on-site representative when a defect is identified and inform the manager of the specifics of the problem. The COR shall be responsible for monitoring the contractor’s performance in meeting a specific performance standard/AQL.

  DIRECT OBSERVATION. (Can be performed periodically or through 100% surveillance.)



MANAGEMENT INFORMATION SYSTEMS (MIS). (Evaluates outputs through the use of management information reports. Best used for general surveillance and may need to be supplemented by periodic inspections.)

 

PERIODIC INSPECTION. Uses a comprehensive evaluation of selected outputs. Inspections may be scheduled as required.


  o Analysis of contractor's progress reports. (Evaluate cost, schedule, etc.)
  o Performance reporting.

Surveillance results may be used as the basis for actions (to include payment deductions) against the contractor. In such cases, the Inspection of Services clause and the Inspection of Supplies clause in the Contract becomes the basis for the KO’s actions.

6. RATINGS.

Metrics and methods are designed to determine if performance exceeds, meets, or does not meet a given standard and acceptable quality level. A rating scale shall be used to determine a positive, neutral, or negative outcome. The following ratings shall be used:

Example 1:

EXCEPTIONAL: Performance significantly exceeds contract requirements to the Government’s benefit.
SATISFACTORY: Performance meets contractual requirements.
UNSATISFACTORY: Performance does not meet contractual requirements.

7. DOCUMENTING PERFORMANCE.

a. ACCEPTABLE PERFORMANCE.

The Government shall document positive performance. A report template is attached. Any report may become a part of the supporting documentation for fixed fee payments, award fee payments, or other actions.

b. UNACCEPTABLE PERFORMANCE.

When unacceptable performance occurs, the COR shall inform the contractor. This will normally be in writing unless circumstances necessitate verbal communication. In any case the COR shall document the discussion and place it in the COR file.

When the COR determines formal written communication is required, the COR shall prepare a Contract Discrepancy Report (CDR), and present it to the contractor's task manager or on-site representative. A CDR template is attached to this QASP.

The contractor shall acknowledge receipt of the CDR in writing. The CDR will specify if the contractor is required to prepare a corrective action plan to document how the contractor shall correct the unacceptable performance and avoid a recurrence. The CDR will also state how long after receipt the contractor has to present this corrective action plan to the COR. The Government shall review the contractor's corrective action plan to determine acceptability.

Any CDRs may become a part of the supporting documentation for contract payment deductions, fixed fee deductions, award fee nonpayment, or other actions deemed necessary by the KO.


8. FREQUENCY OF MEASUREMENT.

a. Frequency of Measurement.

During contract/order performance, the COR shall take periodic measurements, quarterly as specified in the AQL column of the Performance Standards Summary Matrix, and shall analyze whether the negotiated frequency of measurement is appropriate for the work being performed.

b. Frequency of Performance Assessment Meetings.

The COR shall meet with the contractor quarterly to assess performance and shall provide a written assessment.

PERFORMANCE REPORT

1. CONTRACT NUMBER: TBD

2. Prepared by: COR NAME ENTERED AT TIME OF AWARD

3. Date and time of observation:

4. Observation:

<Examples of items to include in a report are:
- Method of surveillance.
- How frequently you conducted surveillance.
- Surveillance results.
- Number of observations.>

Prepared by: COR

     
Signature – Contracting Officer’s Representative    Date

CONTRACT DISCREPANCY REPORT (CDR)

1. Contract Number: TBD

2. TO: (Contractor Task Manager or on-site representative) Philippe Deschamps

3. FROM: TBD

4. Date and time observed discrepancy:

5. DISCREPANCY OR PROBLEM:

<Describe in detail. Identify any attachments.>

6. Corrective action plan:

A written corrective action plan < is / is not > required.


< If a written corrective action plan is required include the following. > The written Corrective Action Plan will be provided to the undersigned not later than < # days after receipt of this CDR. >

Prepared by: COR

   
Signature – Contracting Officer’s Representative Date

Received by:

   
Signature - Contractor Task Manager or on-site representative Date

The COR may initiate a CDR at any time, including whenever the number of monthly recorded defects for a performance standard exceeds the allowable number of defects; anytime unacceptable performance is determined critical in nature and requires formal corrective action; and whenever an unfavorable trend is detected in contractor performance.




Page 2 of 41

Section A - Solicitation/Contract Form

ADDITIONAL INFORMATION
ADDITIONAL INFORMATION

PROJECT TITLE: Development and U.S. Food and Drug Administration (FDA) Clearance of the Portable Neuromodulation Stimulator (PoNS) Device.

The requirement is an R&D contract.

GOVERNMENT POINTS OF CONTACT

The Contract Specialist for this contract is

The Contracting Officer for this contract is

The Contracting Officer’s Representative for this contract is


Page 3 of 41

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT
0001   1 Job   $217,975.21
  Labor - Sponsor  
  COST  
  Labor - Sponsor, Development and FDA Clearance of the PoNS device.  
  FOB: Destination  
  PURCHASE REQUEST NUMBER: 0010553630-0003  
           
        ESTIMATED COST $217,975.21NTE
  ACRN AA $217,975.21
  CIN: GFEBS001055363000001  

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT
0002   1 Job   $2,763,289.24
  ODC - Subcontractor Expenses  
  COST  
  Other Direct Costs (ODCs) - Subcontractor expenses to include; Clinical  
  Research Organization, Regulatory, Contract Manufacturing, and Consultant.  
  FOB: Destination  
  PURCHASE REQUEST NUMBER: 0010553630-0002  
           
        ESTIMATED COST $2,763,289.24NTE
  ACRN AA $2,763,289.24
  CIN: GFEBS001055363000002  

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT
0003   1 Job   $14,979.55
  ODC - Travel  
  COST  
  Other Direct Costs (ODCs) - Travel  
  FOB: Destination  
  PURCHASE REQUEST NUMBER: 0010553630-0002  
           
        ESTIMATED COST $14,979.55NTE
  ACRN AA $14,979.55
  CIN: GFEBS001055363000003  


Page 4 of 41


Page 5 of 41

Section C - Descriptions and Specifications

PERFORMANCE WORK STATEMENT

PERFORMANCE WORK STATEMENT (PWS)

Development and U.S. Food and Drug Administration (FDA) Clearance of the Portable Neuromodulation
Stimulator (PoNS™) Device

1. Introduction:

The U.S. Amy Medical Materiel Agency (USAMMA) and its parent organization the U.S. Army Medical Research and Materiel Command (USAMRMC) are located at Fort Detrick, in Frederick, Maryland. USAMMA serves as the strategic level, medical logistics generating force, and medical lifecycle management command in support of Army Medicine, the Army Campaign Plan, Military Health System, and Combatant Commands. The agency provides optimal medical acquisition and logistics support and solutions across the full spectrum of military health care missions worldwide. USAMMA has operational oversight of medical materiel acquisition programs and serves as the Army Medical Department’s (AMEDD’s) command for fielding new medical materiel for the Army’s operational forces.

1.1. Background and Purpose:

The U.S. Army is supporting an effort to develop NeuroHabilitation Corporation’s (NHC) Portable Neuromodulation Stimulator (PoNS™) as an aid to therapy for chronic balance deficits resulting from a mild to moderate traumatic brain injury (TBI). On 1 February 2013, USAMMA, the U.S. Army Medical Materiel Development Activity (USAMMDA), and NHC established a collaborative relationship, via a Cooperative Research and Development Agreement (CRADA) under 15 USC §3710a, to develop an investigational medical device that employs non-invasive brain stimulation. The PoNS™ device, developed partially under the CRADA, works by applying principles of neuroplasticity that enables the brain to process information in new ways for rehabilitation after injury. The goal of this contract is to take the PoNS™ from an investigational medical device to an FDA-cleared device, obtaining clearance for the following indication: as an aid to therapy for chronic balance deficits resulting from mild to moderate traumatic brain injury (TBI).

The Contractor will be the regulatory sponsor and overall project coordinator for the PoNS™ version 4.0 device. The critical components of this PWS to obtain FDA regulatory clearance include the following steps: (1) write the clinical study protocols, (2) execute the clinical studies, (3) manage the clinical research sites, (4) submit the de novo/510(k) or other application to FDA, and (5) gain FDA clearance of the PoNSTM version 4.0 device for a mild-to-moderate TBI indication.

1.2. Scope:

This is a Research and Development (R&D) contract. The objective of this contract is to execute the clinical studies and regulatory responsibilities necessary to obtain FDA clearance for the PoNS™ 4.0 device and provide two FDA-cleared devices to the DoD (specifically USAMMA).

The Contractor shall complete the tasks noted in paragraph 3.1 to support the de novo/510(k) clearance application in accordance with (IAW) all noted applicable State, Federal, DoD, and U.S. Army regulations. The Contractor shall oversee and execute the clinical study. The Contractor shall support and perform services with DoD civilians, military and other Contractor personnel. The Contractor shall travel to Fort Detrick, Maryland at the Government’s request for an annual In Progress Review (IPR).

1.2.1. The Contractor shall perform the services set forth in this PWS, pursuant to the award of a R&D contract. The Contractor shall furnish all management, personnel, services, and other items necessary to successfully deliver the required services. The Contractor shall possess knowledge and skills in PoNSTM use/training/therapy, and regulatory requirements necessary to obtain 510(k) clearance.


Page 6 of 41

1.2.2. This contract supports the Project Management Office, Medical Devices, and USAMMA. The Government shall not exercise any supervision or control over the Contractor’s employees performing services under this contract. Contractor employees shall be accountable solely to the Contractor who, in turn is responsible to the Government.

1.2.3. The Contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items necessary to achieve the tasks as defined in this PWS.

1.2.4. Assumptions of the Parties:

1.2.4.1. A de novo/510 (k) petition shall be required for FDA to clear the PoNS™ 4.0 device.

1.2.4.2. The clinical trial using PoNS™ is considered to be of non-significant risk and, therefore, shall not require an Investigational Device Exemption submission.

1.2.4.3. QSR-produced PoNS™ 4.0 devices shall be available in/around April 2015 for use in the study. The devices shall be provided to the clinical trial sites by the Sponsor/Contractor.

1.2.4.4. The study shall take approximately 9-12 months to complete.

1.3. Period of Performance. The period of performance shall be for one (1) eighteen (18) month Base Period. The Period of Performance breakdown reads as follows:

Base Period 01 July 2015 – 31 December 2016

2. General Requirements:

2.1. Business Relations:

The Contractor shall successfully integrate and coordinate all activity needed to execute the requirement. The Contractor shall manage the timeliness, completeness, and quality of problem identification. The Contractor shall provide corrective action plans, proposal submittals, timely identification of issues, and effective management of subcontractors. The Contractor shall seek to ensure customer satisfaction and professional and ethical behavior of all Contractor personnel.

2.2. Contract Administration and Management:

This PWS provides distinct activities and functions. These activities are described in the following subsections, which specify requirements for contract management, contract administration, and personnel administration.

2.2.1. Contract Management:

The Contractor shall establish clear organizational lines of authority and responsibility to ensure effective management of the resources assigned to the requirement.

2.2.1.1. Management Activities. The Contractor shall identify a single point of contact as the Project Manager (PM). The Contractor PM shall ensure that the task is performed efficiently, accurately, timely, and in compliance with this PWS. The Contractor PM shall coordinate, as necessary with the Contracting Officer Representative (COR), to ensure the services are managed consistently with overall contract requirements. The Contractor PM shall submit all invoices within 30 days from completion of tasks at the end of each month.

2.2.2. Contract Administration. The Contractor shall establish processes and assign appropriate resources to effectively administer this contract. The Contractor shall respond to Government requests for contractual actions within one (1) day. The Contractor shall have a single point of contact between the Government and Contractor employee assigned to support the contract.


Page 7 of 41

2.3. Subcontract Management. The Contractor shall:

2.3.1. Manage any subcontract management necessary to integrate services to meet the overall requirements of this contract.

2.3.2. Be responsible and accountable for subcontractor performance on this requirement.

2.3.3. Manage work distribution to ensure there are no Organizational Conflict of Interest (OCI) considerations.

2.3.4. Add subcontractors to their team, as needed, after notification to the KO or COR. The Government may or may not permit cross-teaming (See paragraph 7.1.12 for definition).

2.4. Travel. The COR is designated, in writing, as the Contractor’s travel order approval authority by the contracting officer. Travel to government facilities or other locations that are requested by the Government for the annual IPR may be required. Only travel requirements specifically requested by the Government (including plans, agenda, itinerary, or dates) shall be pre-approved by the COR and is on a strictly cost-reimbursable basis. Costs for travel shall be billed IAW the regulatory implementation of Public Law 99-234 and FAR 31.205 -46 Travel Costs.

2.5. Anti-terrorism / Operation Security. For Contract Requiring Performance or Delivery in a Foreign Country. DFARS Clause 252.225 -7043, Antiterrorism/Force Protection for Defense Contractors Outside the United States. The clause shall be used in solicitations and contracts that require performance or delivery in a foreign country. This clause applies to both contingencies and non-contingency support. The key AT requirement is for nonlocal national contractor personnel to comply with theater clearance requirements and allows the combatant commander to exercise oversight to ensure the contractor’s compliance with combatant commander and subordinate task force commander policies and directives.

3. Specific Tasks and Performance Objectives

The Contractor shall complete development of the PoNSTM device from its current state as an investigational device to a FDA cleared/approved medical device for the following indication: an aid to therapy for chronic balance deficits resulting from mild to moderate TBI. The Contractor shall be the FDA regulatory sponsor, in accordance with Section 21, Code of Federal Regulations. The Contractor shall deliver two complete FDA cleared/approved devices to the government. The Contractor shall accomplish all required tasks and services IAW this PWS that include, but are not limited to the following Specific Tasks and Performance Objectives for the contract.

3.1. Contract Tasks and Performance Objectives Required Before Start of Clinical Trial

3.1.1. Project Management Plan. The Contractor shall provide a draft Project Management Plan, including an initial Integrated Master Schedule (IMS) and Risk Management Plan that encompasses the entire scope of the contract, with the Contractor’s proposal. The final Project Management Plan shall be submitted within 30 days of contract award. The IMS documents the critical path (including futility point), major milestones, tasks/activities, deliverables, duration, lead/lag/slack time and schedule relationships, and is directly traceable to the PWS. The IMS will contain all major project management tasks and associated milestones and/or deliverables to assist the Government in its monitoring of Contractor performance. The IMS shall be updated quarterly to track progress (CDRL A001 / QASP #1).

3.1.2. Quality Control Plan (QCP). The Contractor shall provide a draft QCP with the Contractor’s proposal. The Contractor shall prepare and implement a final QCP to ensure that all activities of the project are managed in a sound, reasonable way in conformance to the Government’s requirements within 30 days of contract award. The Contractor shall ensure that all deliverables produced are acceptable prior to delivery to the Government. Under this QCP, the Contractor shall provide for the Government or its designee to audit the Contractor and/or its Subcontractors for regulatory compliance and quality assurance purposes. At a minimum, the QCP shall include a self-inspection plan, an internal staffing plan, and an outline of the procedures that the Contractor shall use to maintain quality, timeliness, responsiveness and customer satisfaction. The QCP shall be updated as needed and reviewed at least quarterly (CDRL A002 / QASP #1).


Page 8 of 41

3.1.3. Institutional Review Board Approved Clinical Protocols. The Contractor shall provide a copy of the IRB-approved clinical study protocol and informed consent form for each study site within 3 months of contract award. The Contractor shall also provide the COR supporting documentation that shall include at minimum a Statistical Analysis Plan, Clinical Monitoring Plan, Data Management Plan, Proposed Clinical Data Management System, Sample Case Report Forms, End User Guidelines (Training and Technical Support), and a Recruitment and Retention Plan for each site (CDRL A003 / QASP #2).

3.1.4. Institutional Review Board Approvals. The Contractor shall provide the COR with documentation of appropriate IRB approvals from each study site, institute, and Army, as required within 3 months of contract award and prior to the start of the clinical study. The Contractor shall maintain and update files of all applicable regulatory documentation for all appropriate IRBs (CDRL A004 / QASP #3).

3.1.5. Representative Test Articles. The Contractor shall provide final development and manufacturing of sufficient representative test articles (PoNSTM version 4.0 device) for use in the clinical trial for a minimum of 120 subjects (and/or a proportionate amount consistent with FDA guidance), including a contingency plan for replacement of defective and/or test articles that may be lost or damaged during the clinical trial. The devices shall be manufactured in a Title 21 CFR §820 Quality Systems Regulation (QSR)-compliant manufacturing facility and process that has successfully completed design verification testing and human factors testing (CDRL A005 / QASP #4).

3.2. Contract Tasks and Performance Objectives Required During Clinical Trial:

3.2.1. Conduct Clinical Trial. The Contractor shall conduct a clinical study to evaluate the treatment effect on balance using the PoNSTM version 4.0 devices at a minimum of three (3) study sites for a total of 120 subjects (and/or a proportionate amount consistent with FDA guidance). The Contractor shall conduct the clinical study in accordance with the study protocol and governing FDA Regulations. The Contractor shall provide a copy of their agreement with each study site that shall be responsible for executing the clinical trial in a manner that successfully supports an FDA submission and provide the COR with monthly status reports (CDRL A011 / QASP Item #1 and #5).

3.2.2. Interim Data Analysis. The Contractor shall conduct interim data analysis after 60 subjects (and/or a proportionate amount consistent with FDA guidance) to evaluate the observed treatment effect in order to determine if the study is adequately powered. The Contractor shall provide an Interim Clinical Study Report that includes the raw data and statistical analysis on the results within 30 day after completion of the 60 (or proportionate amount) subject testing , the futility point, and a mitigation plan for issues identified during the analysis (CDRL A007 / QASP #6).

3.3. Contract Tasks and Performance Objectives Required After Conclusion of Clinical Trial:

3.3.1. Final Clinical Study Report. The Contractor shall provide a complete Final Clinical Study Report that includes raw data and statistical analysis 75 days after completion of the study (CDRL 008 / QASP #1).

3.3.2. FDA Submission Packet. The Contractor shall provide data as deemed necessary by the FDA to support a clinical trial, and a copy of the de novo/510(k) application submission packet with copies of all supporting documentation, including but not limited to, the Pre-clinical Study results summary. This documentation shall be provided concurrent with FDA submission (CDRL A009 / QASP #7).

3.3.3. Final Report. The Contractor shall provide a Final Report that is formatted using best practices and consolidate (summarize) all data, costs, results, final status on all deliverables, and work activities performed during the contract period within 30 days after the end of the contract (CDRL A011 / QASP #1).


Page 9 of 41

3.3.4. Technical Data Packet. The Contractor shall provide the COR with a complete technical data packet (TDP) upon request by the Government within seven (7) business days. The Contractor shall prepare and maintain currency of a TDP that includes all necessary documentation and technical data and reports collected and prepared during the development effort funded by the Government. The TDP shall include all necessary documentation and data for the Government, or its designee, to continue the development or production of the product, including but not limited to the Design History File, Device Master Record, and Device History File. The Contractor shall assist in the technical transfer as directed by the Government. The Contractor shall provide copies of TDP content as requested by Government and at contract expiration (CDRL A010 / QASP #8).

3.4. Contract Tasks and Performance Objectives Required After FDA Clearance/Approval:

3.4.1. FDA Cleared Devices. The Contractor shall provide two (2) FDA cleared the PoNSTM devices with an indication as an aid to therapy for chronic balance deficits resulting from mild to moderate TBI, and all accessories, product inserts, and supporting manuals/literature (e.g., including user, technical, and maintenance manuals), as applicable, to the COR within 10 business days of FDA clearance (QASP #9). Any minor deviation of the above indication required by FDA guidance, must be approved by the Government and will be considered in scope of this contract.

3.5. Contract Tasks and Performance Objectives Required During Duration of Contract:

3.5.1. Progress, Status, and Management Reports. The Contractor shall provide annual, quarterly, and monthly Progress, Status, and Management Reports that describe progress made within the period, status of milestones and deliverables, cost expenditures against proposed costs (resource utilization), and inform the Government of existing or potential issues and problem areas and risk mitigation plans. The Contractor shall periodically provide an oral or email status report as the task proceeds to support the integrated product team needs for presentations and other tasks as needed to support the product effort. The reports shall include an updated IMS that shows the percent complete of each scheduled task item. Percent complete is defined as the cumulative amount of work actually performed through the end of the reporting month expressed as a percentage of the total amount of work to be performed. Monthly reports shall be provided to the COR the 10th day of each month, quarterly reports shall be provided the 15th day of each quarter, and annual reports shall be provided the 15th day after the end of each year (CDRL A011 / QASP #1).

3.5.2. Production or Delivery Problem Reports. Any significant positive or negative deviation to the schedule or scope of a task shall be explained and documented by the Contractor in its annual, quarterly, and monthly progress, and Status and Management Report shall be reported to the Government within 2 weeks of identification as a Production or Delivery Problem Report (CDRL A011 / QASP #1).

3.5.3. Annual Program Reviews. The Contractor shall formally present the prior year’s progress as part of an annual program review (for example, the IPR). The content of the briefing shall include but not be limited to the following: completed tasks within the year, highlights of completed tasks, summary of results from in-process studies, schedule updates, summary of results from completed studies, risks/issues, and funding execution. The annual program reviews shall be held at Fort Detrick, MD and may be held in conjunction with the integrated product team (IPT) meetings with senior leadership. Additional requests for travel to Fort Detrick, MD may be requested by the Government as needed (CDRL A011 / QASP #1).

3.5.4. FDA Communication and Study Reports. The Contractor shall provide the COR with FDA Communication and Study Reports. Regulatory documents including informal emails sent to the FDA are sent concurrently to the Government. Meeting notes shall be sent to the Government if efforts to attend verbal meetings (such as phone calls or meetings at the FDA) are not possible. Copies of informal and formal regulatory communications received from the FDA shall be sent within three (3) business days of receipt. Copies of Clinical Monitoring Reports should be sent within 30 business days of receipt (CDRL A013 / QASP #7).


Page 10 of 41

3.5.5. Trip Reports. The Contractor shall provide Trip Reports within five (5) business days for trips that have been requested by the Government. The report should describe the purpose, results of the trip, and actual costs (CDRL A001 / QASP #1).

3.5.6. The Contractor shall assist in Kick-Off, coordination, progress update, and informational meetings.

3.5.7. The Contractor shall provide guidance and consult with Principal Investigator, senior staff, and clinical personnel during formal training and to review data from pilot trial. The Contractor shall provide recommendations for modifications to interventions when used with the PoNSTM device, measurement tools and procedures.

3.5.8. The Contractor shall consult on data interpretation and collaborate on publications and presentations.

4. Deliverables:

The Contractor shall provide deliverables as described in the below chart.

Deliverable Table

Item

PWS Ref

Title

Distribution

E

Initial & Subsequent

1

2.2.1.1.

Program Manager Point of Contact

COR

1

Upon award of contract

2

3.1.1.

Final Project Management Plan (A001)

COR

1

Within 30 Calendar days after contract award; update quarterly

3

3.1.1.

Final Integrated Master Schedule (CDRL A001)

COR

1

Within 30 Calendar days after contract award; update quarterly

4

3.1.1.

Risk Management Plan (CDRL A001)

COR

1

Within 30 Calendar days after contract award; updated quarterly

5

3.1.2.

Quality Control Plan (CDRL A002)

COR

1

Within 30 Calendar days after contract award; update as needed; review quarterly

6

3.1.3.

IRB-approved Clinical Protocol for each Study Site (CDRL A003)

COR

1

Within 3 months of award of contract

7

3.1.3.

Statistical Analysis Plan (CDRL A003)

COR

1

Within 3 months of award of contract

8

3.1.3.

Clinical Monitoring Plan (CDRL A003)

COR

1

Within 3 months of award of contract

9

3.1.3.

Data Management Plan (CDRL A003)

COR

1

Within 3 months of award of contract

10

3.1.3.

Proposed Clinical Data Management System (CDRL A003)

COR

1

Within 3 months of award of contract

11

3.1.3.

Sample Case Report Forms (CDRL A003)

COR

1

Within 3 months of award of contract

12

3.1.3.

End User Guidelines (CDRL A003)

COR

1

Within 3 months of award of contract

13

3.1.3.

Recruitment and Retention Plan for each Clinical Site(CDRL A003)

COR

1

Within 3 months of award of contract



Page 11 of 41

Item

PWS Ref

Title

Distribution

E

Initial & Subsequent

14

3.1.4.

IRB Approvals (CDRL A004)

COR

1

Within 3 months of award of contract and prior to start of clinical trial

15

3.1.5.

Representative Test Articles (sent to study sites) (CDRL A005)

COR

1

Prior to start of clinical trial

16

3.1.5.

Contingency Manufacturing Plan (CDRL A005)

COR

1

Prior to start of clinical trial

17

3.2.1.

Conduct Clinical Trial (CDRL A006)

COR

1

Copy of agreement with each study site prior to the start of the trial; monthly status report

18

3.2.2.

Interim Clinical Study Report & Mitigation Plan (CDRL A007)

COR

Within 30 days of completion of n = 60 subjects (and/or a proportionate amount consistent with FDA guidance)

19

3.3.1.

Final Clinical Study Report (CDRL A008)

COR

1

Within 75 days after completion of study

20

3.3.2.

FDA Submission Packet (CDRL A009)

COR

1

Concurrently with FDA submission

21

3.3.3.

Final Report

COR

1

Within 30 days after end of contract

22

3.3.4.

Technical Data Packet (CDRL A010)

COR

1

Seven (7) business days upon request and final TDP at end of contract

23

3.4.1.

FDA cleared PoNSTM Devices

COR

N A

Within 10 business days of FDA clearance (2 devices)

24

3.5.1.

Monthly Progress, Status, and Management Reports (CDRL A011)

COR

1

Monthly reports due the 10th day of each month.

25

3.5.1.

Quarterly Progress, Status, and Management Reports (CDRL A011)

COR

1

Quarterly reports due the 15th day after end of each quarter.

26

3.5.1.

Annual Progress, Status, and Management Reports (CDRL A011)

COR

Annual reports due the 15th day after end of each year

27

3.5.2.

Production or Delivery Problem Reports (CDRL A012)

COR

1

Within 2 weeks of identification of deviation to schedule or scope of any task as needed

28

3.5.3.

Annual Program Reviews

IPT

N A

Annually In Process Review at Fort Detrick, MD

29

3.5.4.

FDA Communication and Study Reports (CDRL A013)

COR

1

Concurrently and/or 3 business days as applicable (see PWS 3.1.18.)



Page 12 of 41

Item PWS Ref Title Distribution E Initial & Subsequent
30 3.5.5. Trip Reports COR 1 Within 5 business days for Government requested travel

5. List of Acronyms:

AMEDD Army Medical Department
CFR Code of Federal Regulations
CONUS Continental United States (excludes Alaska and Hawaii)
COR Contracting Officer Representative
CRO Clinical Research Organization
DD250 Department of Defense Form 250 (Receiving Report)
DD254 Department of Defense Contract Security Requirement List
DFARS Defense Federal Acquisition Regulation Supplement
DoD Department of Defense
FAR Federal Acquisition Regulation
FDA United States Food and Drug Administration
HIPAA Health Insurance Portability and Accountability Act of 1996
IAW In Accordance With
IMS Integrated Master Schedule
IRB Institutional Review Board
KO Contracting Officer
n Number of Research Subjects
NA Not Applicable
NDA Non-disclosure Agreement
NHC NeuroHabilitation Corporation
OCI Organizational Conflict of Interest
OCONUS Outside Continental United States (includes Alaska and Hawaii)
ODC Other Direct Costs
PM Project Manager
PoNSTM Portable Neuromodulation Stimulator
PWS Performance Work Statement
QA Quality Assurance
QAP Quality Assurance Program
QASP Quality QAP Assurance Surveillance Plan
QC Quality Control
QCP Quality Control Plan
QSR Quality Systems Regulations
TDP Technical Data Packet
TBI Traumatic Brain Injury
USAMMA United States Army Medical Materiel Agency
USAMRMC United States Medical Research and Materiel Command

CONTRACTOR MANPOWER REPORTING

Contractor Manpower Reporting (CMR) for the Base Period. Input for Contract Services information in the web site operated and maintained by the Assistant Secretary of the Army (Manpower & Reserve Affairs). See the "Contractor Manpower Reporting" clause for specific reporting information. Reporting period will be the period of performance not to exceed 12 months ending 30 September of each Government fiscal year and must be reported by 31 October of each calendar year. The Contract SHALL provide evidence of compliance with the CMR requirement to the Contracting Officer's Representative (COR), Contract Specialist, and Contracting Officer no later than 15 November of each calendar year.


Page 13 of 41

The contractor does not propose any additional costs related to Contractor Manpower Reporting.

CLAUSES INCORPORATED BY FULL TEXT

CONTRACTOR MANPOWER REPORTING (CMR) - (ACCOUNTING FOR CONTRACT SERVICES) (APR 2011) (USAMRAA)

The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including sub-contractor manpower) required for performance of this contract. The contractor is required to completely fill in all the information in the format using the following web address: https://cmra.army.mil. The required information includes: (l) Contract Number; (2) Delivery Order Number (If applicable); (3) Task Order Number (If applicable); (4) Requiring Activity Unit Identification Code (UIC); (5) Command; (6) Contractor Contact Information; (7) Federal Service Code (FSC); (8) Direct Labor Hours; (9) Direct Labor Dollars; and, (10) Location. In the event the Contracting Officer's Representative (COR)/Contracting Officer's Technical Representative (COTR) has not entered their data requirements first, the contractor must also enter the COR/COTR required data with the exception of fund cite, obligations, and disbursement data. The CMRA help desk can be reach at any technical questions. The help desk can also be contacted via email: As part of its quote or offer, the contractor will also provide the estimated total cost (if any) incurred to comply with this reporting requirement. The reporting period will be the period of performance not to exceed 12 months ending 30 September of each government fiscal year and must be reported by 31 October of each calendar year.


Page 14 of 41

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY
0001 Destination Government Destination Government
0002 Destination Government Destination Government
0003 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-5 Inspection Of Services Cost-Reimbursement APR 1984
52.246-8 Inspection Of Research And Development Cost Reimbursement MAY 2001


Page 15 of 41

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC
         
0001 POP 01-JUL-2015 TO N/A US ARMY MEDICAL MATERIEL AGENCY W25MWY
  31-DEC-2016   US ARMY MEDICAL MATERIEL AGENCY  
         
         
         
      FOB: Destination  
         
0002 POP 01-JUL-2015 TO N/A (SAME AS PREVIOUS LOCATION) W25MWY
  30-DEC-2016   FOB: Destination  
         
0003 POP 01-JUL-2015 TO N/A (SAME AS PREVIOUS LOCATION) W25MWY
  30-DEC-2016   FOB: Destination  

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989


Page 16 of 41

Section G - Contract Administration Data

ACCOUNTING AND APPROPRIATION DATA

AA: 09720142015013000018N10337374255 R.0011882.4.11 6100.9000021001
COST CODE: A7466    
AMOUNT: $2,996,244.00    
CIN GFEBS001055363000001: $217,975.21    
CIN GFEBS001055363000002: $2,763,289.24    
CIN GFEBS001055363000003: $14,979.55    

CLAUSES INCORPORATED BY REFERENCE

252.201-7000 Contracting Officer's Representative DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.004-4002 Contractor Performance Assessment Reporting System (CPARS) (USAMRAA) (September 2009)

The Contractor Performance Assessment Reporting System (CPARS) has been adopted electronically to capture assessment data and manage the evaluation process. CPARS is used to assess a contractor's performance and provide a record, both positive and negative, on a given contract during a specific period of time. The CPARS Automated Information System (AIS) collection tool and other CPARS information can be accessed at https://www.cpars.csd.disa.mil. CPARS collects contractor performance information and passes it to the Federal Past Performance Information Retrieval System (PPIRS) where it can be retrieved by Federal Government Agencies including the DoD Services. The CPARS process is designed with a series of checks and balances to facilitate the objective and consistent evaluation of contractor performance. Both government and contractor program management perspectives are captured on the CPAR form and together make a complete CPAR. The Contractor shall assign and provide to the Contracting Officer's Representative (COR), within 10 calendar days after award, the name, title, email address and phone number of the designated Contractor Representative (CR) within their firm who will be responsible for CPAR information and reviewing the Government's proposed assessment for the period of performance. A User ID and Password for the CPARS will be provided to the designated CR for this purpose of accessing the CPARS. The CR has the authority to: Receive the Government evaluation; Review/comment/return the evaluation to the Government within 30 calendar days after the Government's evaluation is completed; Request a meeting to discuss the CPAR. This meeting must be requested, in writing, no later than seven calendar days from the receipt of the CPAR and must be held during the contractor’s 30-day review period. The CR must either concur or nonconcur to each CPAR.


Page 17 of 41

CLAUSES INCORPORATED BY FULL TEXT

252.232 -7006     WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232 -7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Invoice 2-in-1 Services (Services Only)

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Not Applicable

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)


Page 18 of 41

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF
Pay Official DoDAAC HQ0490
Issue By DoDAAC W81XWH
Admin DoDAAC W81XWH
Inspect By DoDAAC W25MWY
Ship To Code W25MWY
Ship From Code ___
Mark For Code ___
Service Approver (DoDAAC) HAA391
Service Acceptor (DoDAAC) W25MWY
Accept at Other DoDAAC N/A
LPO DoDAAC N/A
DCAA Auditor DoDAAC HAA391
Other DoDAAC(s) N/A

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

 

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Not Applicable

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at

(End of clause)


Page 19 of 41

Section H - Special Contract Requirements

CLAUSES INCORPORATED BY FULL TEXT

ORGANIZATIONAL AND CONSULTANT CONFLICTS OF INTEREST (MAR 1999) (USAMRAA)

a. It is recognized by the parties hereto that the effort performed by the contractor under this contract is of a nature that it creates a potential organizational conflict of interest as is contemplated under the FAR Subpart 9.5.

b. In the performance of this contract, the contractor may have access to data which is procurement sensitive or is proprietary to other companies, Government consultants or advisors, or the Government. The contractor agrees that he will not utilize such procurement sensitive or proprietary data in performance of future competitive contracts, for studies in the same field, procured either through sealed bids or competitive negotiations. The contractor further agrees not to act as a subcontractor or consultant to any other prime contractor or subcontractor seeking to utilize such data.

c. The contractor will include the provisions of paragraphs a and b in every first tier subcontract for performance of any portion of this requirement.

d. This clause shall have effect from 01 July 2015 to 31 December 2016.

CLAUSES INCORPORATED BY FULL TEXT

GOOD LABORATORY PRACTICES (DEC 2006) (USAMRAA)

The conduct of studies on investigational new drugs or devices shall comply with the GOOD LABORATORY PRACTICE (GLP) FOR NONCLINICAL LABORATORY STUDIES regulations 21 CFR 58. The contractor shall notify the Administrative Contracting Officer by telephone immediately upon announcement by a representative of the Food and Drug Administration (FDA) of an inspection of studies performed under this contract. In addition to the FDA representative, the Contracting Officer's Representative (COR) shall have access to the contractor's records and specimens. With reference to paragraph 58.195(h) of the GLP regulations, the contractor shall notify the COR in writing in addition to the FDA, should the contractor go out of business and/or transfer the records during the periods prescribed in paragraph 58.195. On expiration or termination of the contract, the contractor shall notify the COR of any remaining unused test articles.

CLAUSES INCORPORATED BY FULL TEXT

INVESTIGATING AND REPORTING POSSIBLE SCIENTIFIC MISCONDUCT (MAR 1999) (USAMRAA)

a. "Misconduct" or "Misconduct in Science" is defined as fabrication, falsification, plagiarism, or other practices that seriously deviate from those that are commonly accepted within the scientific community for proposing, conducting or reporting research. It does not include honest error or honest differences in interpretations or judgments of data.

b. Contractors shall foster a research environment that prevents misconduct in all research and that deals forthrightly with possible misconduct associated with research for which U.S. Army Medical Research and Materiel Command funds have been provided or requested.


Page 20 of 41

c. The contractor agrees to:
(1) Establish and keep current an administrative process to review, investigate, and report allegations of misconduct in science in connection with research conducted by the contractor;
(2) Comply with its own administrative process;
(3) Inform its scientific and administrative staff of the policies and procedures and the importance of compliance with those policies and procedures;
(4) Take immediate and appropriate action as soon as misconduct on the part of employees or persons within the organization's control is suspected or alleged; and
(5) Report to the Administrative Contracting Officer (ACO) a decision to initiate an investigation into possible scientific misconduct.

d. The contractor is responsible for notifying the ACO of appropriate action taken if at any stage of an inquiry or investigation any of the following conditions exist:
(1) An immediate health hazard is involved;
(2) There is an immediate need to protect Federal funds or equipment;
(3) A probability exists that the alleged incident will be reported publicly; or
(4) There is a reasonable indication of possible criminal violation.

PROHIBITION OF HUMAN RESEARCH (JUN 2013 ) (USAMRAA)

** PROHIBITION – READ FURTHER FOR DETAILS **

Research under this award involving the use of human subjects, to include the use of human anatomical substances or identifiable private information (human data), shall not begin until the USAMRMC’s Office of Research Protections (ORP) provides authorization that the research may proceed. Written approval to begin research will be issued from the USAMRMC ORP, under separate notification to the contractor. Written approval from the USAMRMC ORP is also required for any subcontractor that will use funds from this award to conduct research involving human subjects.

Research involving human subjects shall be conducted in accordance with the protocol submitted to and approved by the USAMRMC ORP. Complete study records shall be maintained for each human research study and shall be made available for review by representatives of the USAMRMC. Research records shall be stored in a confidential manner so as to protect the confidentiality of subject information.

The contractor is required to adhere to the following reporting requirements:

Submission of major modifications to the protocol, continuing review documentation, and the final report are required as outlined in the USAMRMC ORP approval memorandum.

Unanticipated problems involving risks to subjects or others, subject deaths related to participation in the research, clinical holds (voluntary or involuntary), and suspension or termination of this research by the IRB, the institution, the Sponsor, or regulatory agencies, shall be promptly reported to the USAMRMC ORP and the USAMRAA Contracting Office.

The knowledge of any pending compliance inspection/visits by the FDA, ORP, or other government agency concerning this clinical investigation or research, the issuance of Inspection Reports, FDA Form 483, warning letters or actions taken by any Regulatory Agencies including legal or medical actions, and any instances of serious or continuing noncompliance with regulatory requirements that relate to this clinical investigation or research, shall be reported immediately to the USAMRMC ORP and the USAMRAA Contracting Office.

Non-compliance with these terms and conditions may result in withholding of funds and/or the termination of the award.


Page 21 of 41

52.035 -4035 PROHIBITION OF USE OF LABORATORY ANIMALS (JUN 2013) (USAMRAA)

** PROHIBITION – READ FURTHER FOR DETAILS **

Notwithstanding any other terms and conditions contained in this award or incorporated by reference herein, the contractor is expressly forbidden to use or subcontract for the use of laboratory animals in any manner whatsoever without the express written approval of the USAMRMC, Animal Care and Use Review Office (ACURO). Written authorization to begin research under the applicable protocol(s) proposed for this award will be issued in the form of an approval letter from the USAMRMC ACURO to the contractor with a copy to the USAMRAA Contracting Office. Furthermore, modifications to already approved protocols require approval by ACURO prior to implementation. Once approved, notification must be given immediately to USAMRAA contracting. For each fiscal year, the contractor shall maintain, and upon request from ACURO, submit animal usage information. Non-compliance with any of these terms and conditions may result in withholding of funds and/or ther terminations of the award.

52.035 -4036 PROHIBITION OF USE OF HUMAN CADAVERS (JUN 2013) (USAMRAA)

** PROHIBITION – READ FURTHER FOR DETAILS**

Research, development, testing and evaluation (RDT&E), education or training activities involving human cadavers under this award shall not begin until approval is granted in accordance with the Army Policy for Use of Human Cadavers for RDT&E, Education, or Training, 20 April 2012 (https://mrmc.amedd.army.mil/index.cfm?pageid=research_ protections.overview). The USAMRMC Office of Research Protections (ORP) is the Action Office for this policy. Approval must be obtained from the Head of the Army organization that is supporting/funding the activity involving cadavers as described in the Army Policy for Use of Human Cadavers. For certain activities involving cadavers, approval must also be obtained from ORP. Award contractors must coordinate with the supporting/funding Army organization to ensure that proper approvals are obtained. Written approvals to begin the activity will be issued under separate notification to the contractor. Non-compliance with these terms and conditions may result in withholding of funds and/or the termination of the award.

CONTRACTOR IDENTIFICATION (DEC 2005) (USAMRAA)

When contractor personnel perform the services required in this contract on a Government installation they are required to possess and wear an identification badge that displays his or her name and the name of the Company. The contractor shall ensure that contractor personnel identify themselves as contractors when attending meetings, answering Government telephones, providing any type of written correspondence, or working in situations where their actions could be construed as official Government acts.

While performing in a contractor capacity, contractor personnel shall refrain from using their retired or reserve component military rank or title in all written or verbal communications.


Page 22 of 41

REPORTS, MANUSCRIPTS AND PUBLIC RELEASES (DEC 2006) (USAMRAA)

a. Contractors are encouraged to publish results of research supported by the US Army Medical Research and Materiel Command (USAMRMC) in appropriate media forum. Any publication, report or public release, which may create a statutory bar to the issuance of a patent on any subject invention, shall be coordinated with appropriate patent counsel.

b. Manuscripts intended for publication in any media shall be submitted to the Contracting Officer and Contracting Officer's Representative (COR), simultaneously with submission for publication. Review of such manuscripts is for comment to the Principal Investigator, not for approval or disapproval. Courtesy copies of the reprint shall be forwarded to the Contracting Officer and COR, even though publication may be subsequent to the expiration of the contract.

c. The Contractor shall notify the Contracting Officer of planned news releases, planned publicity, advertising material concerning contract work, and planned presentations to scientific meetings, prior to public release. This is not intended to restrict dissemination of research information but to allow USAMRMC advance notice in order to adequately respond to inquiries.

d. Manuscripts, reports, public releases and abstracts, which appear in professional journals, media and programs, shall include the following statements:

(l) "This work is supported by the US Army Medical Research and Materiel Command under Contract No. W81XWH-15-C-0096"

(2) "The views, opinions and/or findings contained in this report are those of the author(s) and should not be construed as an official Department of the Army position, policy or decision unless so designated by other documentation."

(3) As applicable, if the research involves the use of animals, the Contractor must include the following statement: "In conducting research using animals, the investigator(s) adhered to the Animal Welfare Act Regulations and other Federal statutes relating to animals and experiments involving animals and the principles set forth in the current version of the Guide for Care and Use of Laboratory Animals, National Research Council."

(4) As applicable, if the research involves human use, the Contractor must include the following statement: "In the conduct of research where humans are the subjects, the investigator(s) adhered to the policies regarding the protection of human subjects as prescribed by Code of Federal Regulations (CFR) Title 45, Volume 1, Part 46; Title 32, Chapter 1, Part 219; and Title 21, Chapter 1, Part 50 (Protection of Human Subjects)."

(5) As applicable, if the research involves the use of recombinant DNA, the Contractor must include the following statement: "In conducting work involving the use of recombinant DNA the investigator(s) adhered to the current version of the National Institutes of Health (NIH) Guidelines for Research Involving Recombinant DNA Molecules."

TRAVEL (JULY 2007) (USAMRAA)

a. Approval of Foreign Travel. The cost of foreign travel is allowable only when the specific written approval of the Contracting Officer is obtained prior to commencing the trip. Approval shall be requested at least 90 calendar days before the scheduled departure date in order that all necessary clearances may be processed. Each individual trip must be approved separately, even though it may have been included in a previously approved budget. Foreign travel under this contract is defined as any travel outside of the United States and its territories and possessions.

b. Costs incurred by contractor personnel on official company business, whether foreign travel and/or domestic/local travel, are allowable, subject to the limitations contained in the Federal Acquisition Regulation (FAR) clause at 52.216 -7, Allowable Cost and Payment, incorporated into this contract.


Page 23 of 41

Section I - Contract Clauses

REGULATORY RIGHTS
REGULATORY RIGHTS IN EVENT OF PRODUCT DEVELOPMENT FAILURES

This contract includes research with an investigational drug, biologic or medical device that is regulated by the U.S. Food and Drug Administration (FDA) and requires FDA pre-market approval or clearance before commercial marketing may begin. It is expected that this contract will result in the FDA clearance and commercialization of the Portable Neuromodulation Stimulator (PoNS) device. The Contractor is the sponsor of the Regulatory Application (an investigational new drug application (IND), investigational device exemption (IDE), new drug application (NDA), biologics license application (BLA), premarket approval application (PMA), or 510(k) pre-market notification filing (510(k)) or another regulatory filing submitted to FDA) that controls the research under this contract. As the sponsor of the Regulatory Application to FDA (as the terms “sponsor” and “applicant” are defined or used in at 21 CFR §§3.2(c), 312.5, 600.3(t), 812.2(b), 812 Subpart C, or 814.20), the Contractor has certain standing before the FDA that entitles it to exclusive communications related to the Regulatory Application. This provision protects the return on research and development investment made by the U.S. Army Medical Research and Materiel Command (USAMRMC) in the event of certain regulatory product development failures related to the Technology.

The Contractor agrees to the following:

a. Contractor will, within three (3) business days of receipt, provide USAMRMC with all communications and summaries thereof, both formal and informal, to or from FDA regarding the Technology and ensure that USAMRMC representatives are given advance notice of and are invited to participate with at least two (2) representatives in any formal or informal sponsor meetings with FDA;

b. If contract is to be terminated or is about to expire prior to the time the Contractor obtains FDA approval or clearance ; or the Contractor fails to commercially market the regulated technology within three (3) years after the FDA issues approval or clearance, the Contractor, upon the request of the Government:

(i) shall transfer possession, ownership and sponsorship or holdership of any Regulatory Application (including any associated expedited review designation, priority review voucher, or marketing exclusivity eligibility or award), regulatory correspondence, and supporting regulatory information related to the Technology to USAMRMC or its designee;

(ii) shall inform FDA of the transfer of sponsorship or holdership of the Regulatory Application transferred under section (c)(i) above.

c. The terms of this provision and its derivative obligations:

(i) will be included in any license, sale or transfer by the Contractor to a third party of any intellectual property covered by section (b) above.

(ii) will survive the acquisition or merger of the Contractor by or with any third party.

(iii) will be included in any subcontracts relating to the development of the Technology.

(iv) will survive the expiration of this contract.

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013


Page 24 of 41

52.203-3

Gratuities

APR 1984

52.203-5

Covenant Against Contingent Fees

MAY 2014

52.203-6

Restrictions On Subcontractor Sales To The Government

SEP 2006

52.203-7

Anti-Kickback Procedures

MAY 2014

52.203-12

Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.203-17

Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4

Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9

Personal Identity Verification of Contractor Personnel

JAN 2011

52.204-10

Reporting Executive Compensation and First-Tier Subcontract Awards

JUL 2013

52.204-13

System for Award Management Maintenance

JUL 2013

52.209-6

Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

AUG 2013

52.209-9

Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10

Prohibition on Contracting With Inverted Domestic Corporations

DEC 2014

52.215-8

Order of Precedence--Uniform Contract Format

OCT 1997

52.215-23

Limitations on Pass-Through Charges

OCT 2009

52.217-2

Cancellation Under Multiyear Contracts

OCT 1997

52.219-8

Utilization of Small Business Concerns

OCT 2014

52.222-1

Notice To The Government Of Labor Disputes

FEB 1997

52.222-3

Convict Labor

JUN 2003

52.222-50

Combating Trafficking in Persons

MAR 2015

52.223-6

Drug-Free Workplace

MAY 2001

52.223-17

Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18

Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.224-1

Privacy Act Notification

APR 1984

52.224-2

Privacy Act

APR 1984

52.225-13

Restrictions on Certain Foreign Purchases

JUN 2008

52.227-1

Authorization and Consent

DEC 2007

52.227-1 Alt I

Authorization And Consent (Dec 2007) - Alternate I

APR 1984

52.227-2

Notice And Assistance Regarding Patent And Copyright Infringement

DEC 2007

52.228-7

Insurance--Liability To Third Persons

MAR 1996

52.232-23

Assignment Of Claims

MAY 2014

52.232-33

Payment by Electronic Funds Transfer--System for Award Management

JUL 2013

52.232-39

Unenforceability of Unauthorized Obligations

JUN 2013

52.232-40

Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.233-1

Disputes

MAY 2014

52.233-3 Alt I

Protest After Award (Aug 1996) - Alternate I

JUN 1985

52.233-4

Applicable Law for Breach of Contract Claim

OCT 2004

52.239-1

Privacy or Security Safeguards

AUG 1996

52.242-1

Notice of Intent to Disallow Costs

APR 1984

52.242-2

Production Progress Reports

APR 1991

52.242-3

Penalties for Unallowable Costs

MAY 2014

52.242-4

Certification of Final Indirect Costs

JAN 1997



Page 25 of 41

52.242-13

Bankruptcy

JUL 1995

52.242-13

Bankruptcy

JUL 1995

52.243-6

Change Order Accounting

APR 1984

52.244-5

Competition In Subcontracting

DEC 1996

52.244-6

Subcontracts for Commercial Items

OCT 2014

52.246-25

Limitation Of Liability--Services

FEB 1997

52.249-6

Termination (Cost Reimbursement)

MAY 2004

52.249-14

Excusable Delays

APR 1984

52.253-1

Computer Generated Forms

JAN 1991

252.203-7000

Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7001

Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.204-7000

Disclosure Of Information

AUG 2013

252.204-7003

Control Of Government Personnel Work Product

APR 1992

252.204-7012

Safeguarding of Unclassified Controlled Technical Information

NOV 2013

252.209-7004

Subcontracting With Firms That Are Owned or Controlled By The Government of a Terrorist Country

DEC 2014

252.223-7004

Drug Free Work Force

SEP 1988

252.225-7993 (Dev)

Prohibition on Contracting with the Enemy (Deviation)

SEP 2014

252.227-7001

Release Of Past Infringement

AUG 1984

252.227-7010

License to Other Government Agencies

AUG 1984

252.227-7013

Rights in Technical Data--Noncommercial Items

FEB 2014

252.227-7014

Rights in Noncommercial Computer Software and Noncommercial Computer Software Documentation

FEB 2014

252.227-7016

Rights in Bid or Proposal Information

JAN 2011

252.227-7030

Technical Data--Withholding Of Payment

MAR 2000

252.227-7037

Validation of Restrictive Markings on Technical Data

JUN 2013

252.227-7039

Patents--Reporting Of Subject Inventions

APR 1990

252.232-7003

Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.246-7001

Warranty Of Data

MAR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.216 -7     ALLOWABLE COST AND PAYMENT (JUN 2013)

(a) Invoicing.

(1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with Federal Acquisition Regulation (FAR) subpart 31.2 in effect on the date of this contract and the terms of this contract. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract.

(2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act. Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232 -25.

(3) The designated payment office will make interim payments for contract financing on the 30th day after the designated billing office receives a proper payment request.


Page 26 of 41

In the event that the Government requires an audit or other review of a specific payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date.

(b) Reimbursing costs. (1) For the purpose of reimbursing allowable costs (except as provided in subparagraph (b)(2) of the clause, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term "costs" includes only--

(i) Those recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract;

(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for--

(A) Supplies and services purchased directly for the contract and associated financing payments to subcontractors, provided payments determined due will be made--

(1) In accordance with the terms and conditions of a subcontract or invoice; and

(2) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government;

(B) Materials issued from the Contractor's inventory and placed in the production process for use on the contract;

(C) Direct labor;

(D) Direct travel;

(E) Other direct in-house costs; and

(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and

(iii) The amount of financing payments that have been paid by cash, check, or other forms of payment to subcontractors.

(2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid unless--

(i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's indirect costs for payment purposes).

(3) Notwithstanding the audit and adjustment of invoices or vouchers under paragraph (g) of this clause, allowable indirect costs under this contract shall be obtained by applying indirect cost rates established in accordance with paragraph (d) of this clause.

(4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of materials at the Contractor's expense or at no cost to the Government shall be disregarded for purposes of cost-reimbursement under this clause.

(c) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks.


Page 27 of 41

(d) Final indirect cost rates. (1) Final annual indirect cost rates and the appropriate bases shall be established in accordance with Subpart 42.7 of the Federal Acquisition Regulation (FAR) in effect for the period covered by the indirect cost rate proposal.

(2)(i) The Contractor shall submit an adequate final indirect cost rate proposal to the Contracting Officer (or cognizant Federal agency official) and auditor within the 6-month period following the expiration of each of its fiscal years. Reasonable extensions, for exceptional circumstances only, may be requested in writing by the Contractor and granted in writing by the Contracting Officer. The Contractor shall support its proposal with adequate supporting data.

(ii) The proposed rates shall be based on the Contractor's actual cost experience for that period. The appropriate Government representative and the Contractor shall establish the final indirect cost rates as promptly as practical after receipt of the Contractor's proposal.

(iii) An adequate indirect cost rate proposal shall include the following data unless otherwise specified by the cognizant Federal agency official:

(A) Summary of all claimed indirect expense rates, including pool, base, and calculated indirect rate.

(B) General and Administrative expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts).

(C) Overhead expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) for each final indirect cost pool.

(D) Occupancy expenses (intermediate indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) and expense reallocation to final indirect cost pools.

(E) Claimed allocation bases, by element of cost, used to distribute indirect costs.

(F) Facilities capital cost of money factors computation.

(G) Reconciliation of books of account (i.e., General Ledger) and claimed direct costs by major cost element.

(H) Schedule of direct costs by contract and subcontract and indirect expense applied at claimed rates, as well as a subsidiary schedule of Government participation percentages in each of the allocation base amounts.

(I) Schedule of cumulative direct and indirect costs claimed and billed by contract and subcontract.

(J) Subcontract information. Listing of subcontracts awarded to companies for which the contractor is the prime or upper-tier contractor (include prime and subcontract numbers; subcontract value and award type; amount claimed during the fiscal year; and the subcontractor name, address, and point of contact information).

(K) Summary of each time-and-materials and labor-hour contract information, including labor categories, labor rates, hours, and amounts; direct materials; other direct costs; and, indirect expense applied at claimed rates.

(L) Reconciliation of total payroll per IRS form 941 to total labor costs distribution.

(M) Listing of decisions/agreements/approvals and description of accounting/organizational changes.

(N) Certificate of final indirect costs (see 52.242 -4, Certification of Final Indirect Costs).


Page 28 of 41

(O) Contract closing information for contracts physically completed in this fiscal year (include contract number, period of performance, contract ceiling amounts, contract fee computations, level of effort, and indicate if the contract is ready to close).

(iv) The following supplemental information is not required to determine if a proposal is adequate, but may be required during the audit process:

(A) Comparative analysis of indirect expense pools detailed by account to prior fiscal year and budgetary data.

(B) General organizational information and limitation on allowability of compensation for certain contractor personnel. See 31.205 -6(p). Additional salary reference information is available at http://www.whitehouse.gov/omb/procurement_index_exec_comp/.

(C) Identification of prime contracts under which the contractor performs as a subcontractor.

(D) Description of accounting system (excludes contractors required to submit a CAS Disclosure Statement or contractors where the description of the accounting system has not changed from the previous year's submission).

(E) Procedures for identifying and excluding unallowable costs from the costs claimed and billed (excludes contractors where the procedures have not changed from the previous year's submission).

(F) Certified financial statements and other financial data (e.g., trial balance, compilation, review, etc.).

(G) Management letter from outside CPAs concerning any internal control weaknesses.

(H) Actions that have been and/or will be implemented to correct the weaknesses described in the management letter from subparagraph G) of this section.

(I) List of all internal audit reports issued since the last disclosure of internal audit reports to the Government.

(J) Annual internal audit plan of scheduled audits to be performed in the fiscal year when the final indirect cost rate submission is made.

(K) Federal and State income tax returns.

(L) Securities and Exchange Commission 10-K annual report.

(M) Minutes from board of directors meetings.

(N) Listing of delay claims and termination claims submitted which contain costs relating to the subject fiscal year.

(O) Contract briefings, which generally include a synopsis of all pertinent contract provisions, such as: Contract type, contract amount, product or service(s) to be provided, contract performance period, rate ceilings, advance approval requirements, pre-contract cost allowability limitations, and billing limitations.

(v) The Contractor shall update the billings on all contracts to reflect the final settled rates and update the schedule of cumulative direct and indirect costs claimed and billed, as required in paragraph (d)(2)(iii)(I) of this section, within 60 days after settlement of final indirect cost rates.

(3) The Contractor and the appropriate Government representative shall execute a written understanding setting forth the final indirect cost rates. The understanding shall specify (i) the agreed-upon final annual indirect cost rates, (ii) the bases to which the rates apply, (iii) the periods for which the rates apply, (iv) any specific indirect cost items treated as direct costs in the settlement, and (v) the affected contract and/or subcontract, identifying any with advance agreements or special terms and the applicable rates. The understanding shall not change any monetary ceiling, contract obligation, or specific cost allowance or disallowance provided for in this contract. The understanding is incorporated into this contract upon execution.


Page 29 of 41

(4) Failure by the parties to agree on a final annual indirect cost rate shall be a dispute within the meaning of the Disputes clause.

(5) Within 120 days (or longer period if approved in writing by the Contracting Officer) after settlement of the final annual indirect cost rates for all years of a physically complete contract, the Contractor shall submit a completion invoice or voucher to reflect the settled amounts and rates. The completion invoice or voucher shall include settled subcontract amounts and rates. The prime contractor is responsible for settling subcontractor amounts and rates included in the completion invoice or voucher and providing status of subcontractor audits to the contracting officer upon request.

(6)(i) If the Contractor fails to submit a completion invoice or voucher within the time specified in paragraph (d)(5) of this clause, the Contracting Officer may--

(A) Determine the amounts due to the Contractor under the contract; and

(B) Record this determination in a unilateral modification to the contract.

(ii) This determination constitutes the final decision of the Contracting Officer in accordance with the Disputes clause.

(e) Billing rates. Until final annual indirect cost rates are established for any period, the Government shall reimburse the Contractor at billing rates established by the Contracting Officer or by an authorized representative (the cognizant auditor), subject to adjustment when the final rates are established. These billing rates--

(1) Shall be the anticipated final rates; and

(2) May be prospectively or retroactively revised by mutual agreement, at either party's request, to prevent substantial overpayment or underpayment.

(f) Quick-closeout procedures. Quick-closeout procedures are applicable when the conditions in FAR 42.708(a) are satisfied.

(g) Audit. At any time or times before final payment, the Contracting Officer may have the Contractor's invoices or vouchers and statements of cost audited. Any payment may be (1) Reduced by amounts found by the Contracting Officer not to constitute allowable costs or (2) Adjusted for prior overpayments or underpayments.

(h) Final payment. (1) Upon approval of a completion invoice or voucher submitted by the Contractor in accordance with paragraph (d)(5) of this clause, and upon the Contractor's compliance with all terms of this contract, the Government shall promptly pay any balance of allowable costs and that part of the fee (if any) not previously paid.

(2) The Contractor shall pay to the Government any refunds, rebates, credits, or other amounts (including interest, if any) accruing to or received by the Contractor or any assignee under this contract, to the extent that those amounts are properly allocable to costs for which the Contractor has been reimbursed by the Government. Reasonable expenses incurred by the Contractor for securing refunds, rebates, credits, or other amounts shall be allowable costs if approved by the Contracting Officer. Before final payment under this contract, the Contractor and each assignee whose assignment is in effect at the time of final payment shall execute and deliver--

(i) An assignment to the Government, in form and substance satisfactory to the Contracting Officer, of refunds, rebates, credits, or other amounts (including interest, if any) properly allocable to costs for which the Contractor has been reimbursed by the Government under this contract; and


Page 30 of 41

(ii) A release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this contract, except--

(A) Specified claims stated in exact amounts, or in estimated amounts when the exact amounts are not known;

(B) Claims (including reasonable incidental expenses) based upon liabilities of the Contractor to third parties arising out of the performance of this contract; provided, that the claims are not known to the Contractor on the date of the execution of the release, and that the Contractor gives notice of the claims in writing to the Contracting Officer within 6 years following the release date or notice of final payment date, whichever is earlier; and

(C) Claims for reimbursement of costs, including reasonable incidental expenses, incurred by the Contractor under the patent clauses of this contract, excluding, however, any expenses arising from the Contractor's indemnification of the Government against patent liability.

(End of clause)

52.216 -12     COST-SHARING CONTRACT--NO FEE (APR 1984)

(a) The Government shall not pay to the Contractor a fee for performing this contract.

(b) After paying $100,000.00 of the Government's share of the total estimated cost of performance shown in the Schedule, the Contracting Officer may withhold further payment of allowable cost until a reserve is set aside in an amount that the Contracting Officer considers necessary to protect the Government's interest. This reserve shall not exceed one percent of the Government's share of the total estimated cost shown in the Schedule or $100,000.00, whichever is less.

(End of clause)

52.217 -8     OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 60 days.

(End of clause)

52.227 -11     PATENT RIGHTS--OWNERSHIP BY THE CONTRACTOR (MAY 2014)

(a) As used in this clause--

Invention means any invention or discovery that is or may be patentable or otherwise protectable under title 35 of the U.S. Code, or any variety of plant that is or may be protectable under the Plant Variety Protection Act (7 U.S.C. 2321, et seq.)

Made means--


Page 31 of 41

(1) When used in relation to any invention other than a plant variety, the conception or first actual reduction to practice of the invention; or

(2) When used in relation to a plant variety, that the Contractor has at least tentatively determined that the variety has been reproduced with recognized characteristics.

Nonprofit organization means a university or other institution of higher education or an organization of the type described in section 501(c)(3) of the Internal Revenue Code of 1954 (26 U.S.C. 501(c)) and exempt from taxation under section 501(a) of the Internal Revenue Code (26 U.S.C. 501(a)), or any nonprofit scientific or educational organization qualified under a State nonprofit organization statute.

Practical application means to manufacture, in the case of a composition of product; to practice, in the case of a process or method; or to operate, in the case of a machine or system; and, in each case, under such conditions as to establish that the invention is being utilized and that its benefits are, to the extent permitted by law or Government regulations, available to the public on reasonable terms.

Subject invention means any invention of the Contractor made in the performance of work under this contract.

(b) Contractor's rights. (1) Ownership. The Contractor may retain ownership of each subject invention throughout the world in accordance with the provisions of this clause.

(2) License. (i) The Contractor shall retain a nonexclusive royalty-free license throughout the world in each subject invention to which the Government obtains title, unless the Contractor fails to disclose the invention within the times specified in paragraph (c) of this clause. The Contractor's license extends to any domestic subsidiaries and affiliates within the corporate structure of which the Contractor is a part, and includes the right to grant sublicenses to the extent the Contractor was legally obligated to do so at contract award. The license is transferable only with the written approval of the agency, except when transferred to the successor of that part of the Contractor's business to which the invention pertains.

(ii) The Contractor's license may be revoked or modified by the agency to the extent necessary to achieve expeditious practical application of the subject invention in a particular country in accordance with the procedures in FAR 27.302(i)(2) and 27.304 -1(f).

(c) Contractor's obligations. (1) The Contractor shall disclose in writing each subject invention to the Contracting Officer within 2 months after the inventor discloses it in writing to Contractor personnel responsible for patent matters. The disclosure shall identify the inventor(s) and this contract under which the subject invention was made. It shall be sufficiently complete in technical detail to convey a clear understanding of the subject invention. The disclosure shall also identify any publication, on sale (i.e., sale or offer for sale), or public use of the subject invention, or whether a manuscript describing the subject invention has been submitted for publication and, if so, whether it has been accepted for publication. In addition, after disclosure to the agency, the Contractor shall promptly notify the Contracting Officer of the acceptance of any manuscript describing the subject invention for publication and any on sale or public use.

(2) The Contractor shall elect in writing whether or not to retain ownership of any subject invention by notifying the Contracting Officer within 2 years of disclosure to the agency. However, in any case where publication, on sale, or public use has initiated the 1-year statutory period during which valid patent protection can be obtained in the United States, the period for election of title may be shortened by the agency to a date that is no more than 60 days prior to the end of the statutory period.

(3) The Contractor shall file either a provisional or a nonprovisional patent application or a Plant Variety Protection Application on an elected subject invention within 1 year after election. However, in any case where a publication, on sale, or public use has initiated the 1-year statutory period during which valid patent protection can be obtained in the United States, the Contractor shall file the application prior to the end of that statutory period. If the Contractor files a provisional application, it shall file a nonprovisional application within 10 months of the filing of the provisional application. The Contractor shall file patent applications in additional countries or international patent offices within either 10 months of the first filed patent application (whether provisional or nonprovisional) or 6 months from the date permission is granted by the Commissioner of Patents to file foreign patent applications where such filing has been prohibited by a Secrecy Order.


Page 32 of 41

(4) The Contractor may request extensions of time for disclosure, election, or filing under paragraphs (c)(1), (c)(2), and (c)(3) of this clause.

(d) Government's rights--(1) Ownership. The Contractor shall assign to the agency, on written request, title to any subject invention--

(i) If the Contractor fails to disclose or elect ownership to the subject invention within the times specified in paragraph (c) of this clause, or elects not to retain ownership; provided, that the agency may request title only within 60 days after learning of the Contractor's failure to disclose or elect within the specified times.

(ii) In those countries in which the Contractor fails to file patent applications within the times specified in paragraph (c) of this clause; provided, however, that if the Contractor has filed a patent application in a country after the times specified in paragraph (c) of this clause, but prior to its receipt of the written request of the agency, the Contractor shall continue to retain ownership in that country.

(iii) In any country in which the Contractor decides not to continue the prosecution of any application for, to pay the maintenance fees on, or defend in reexamination or opposition proceeding on, a patent on a subject invention.

(2) License. If the Contractor retains ownership of any subject invention, the Government shall have a nonexclusive, nontransferable, irrevocable, paid-up license to practice, or have practiced for or on its behalf, the subject invention throughout the world.

(e) Contractor action to protect the Government's interest. (1) The Contractor shall execute or have executed and promptly deliver to the agency all instruments necessary to--

(i) Establish or confirm the rights the Government has throughout the world in those subject inventions in which the Contractor elects to retain ownership; and

(ii) Assign title to the agency when requested under paragraph (d) of this clause and to enable the Government to obtain patent protection and plant variety protection for that subject invention in any country.

(2) The Contractor shall require, by written agreement, its employees, other than clerical and nontechnical employees, to disclose promptly in writing to personnel identified as responsible for the administration of patent matters and in the Contractor's format, each subject invention in order that the Contractor can comply with the disclosure provisions of paragraph (c) of this clause, and to execute all papers necessary to file patent applications on subject inventions and to establish the Government's rights in the subject inventions. The disclosure format should require, as a minimum, the information required by paragraph (c)(1) of this clause. The Contractor shall instruct such employees, through employee agreements or other suitable educational programs, as to the importance of reporting inventions in sufficient time to permit the filing of patent applications prior to U.S. or foreign statutory bars.

(3) The Contractor shall notify the Contracting Officer of any decisions not to file a nonprovisional patent application, continue the prosecution of a patent application, pay maintenance fees, or defend in a reexamination or opposition proceeding on a patent, in any country, not less than 30 days before the expiration of the response or filing period required by the relevant patent office.

(4) The Contractor shall include, within the specification of any United States nonprovisional patent or plant variety protection application and any patent or plant variety protection certificate issuing thereon covering a subject invention, the following statement, “This invention was made with Government support under (identify the contract) awarded by (identify the agency). The Government has certain rights in the invention.”


Page 33 of 41

(f) Reporting on utilization of subject inventions. The Contractor shall submit, on request, periodic reports no more frequently than annually on the utilization of a subject invention or on efforts at obtaining utilization of the subject invention that are being made by the Contractor or its licensees or assignees. The reports shall include information regarding the status of development, date of first commercial sale or use, gross royalties received by the Contractor, and other data and information as the agency may reasonably specify. The Contractor also shall provide additional reports as may be requested by the agency in connection with any march-in proceeding undertaken by the agency in accordance with paragraph (h) of this clause. The Contractor also shall mark any utilization report as confidential/proprietary to help prevent inadvertent release outside the Government. As required by 35 U.S.C. 202(c)(5), the agency will not disclose that information to persons outside the Government without the Contractor's permission.

(g) Preference for United States industry. Notwithstanding any other provision of this clause, neither the Contractor nor any assignee shall grant to any person the exclusive right to use or sell any subject invention in the United States unless the person agrees that any products embodying the subject invention or produced through the use of the subject invention will be manufactured substantially in the United States. However, in individual cases, the requirement for an agreement may be waived by the agency upon a showing by the Contractor or its assignee that reasonable but unsuccessful efforts have been made to grant licenses on similar terms to potential licensees that would be likely to manufacture substantially in the United States, or that under the circumstances domestic manufacture is not commercially feasible.

(h) March-in rights. The Contractor acknowledges that, with respect to any subject invention in which it has retained ownership, the agency has the right to require licensing pursuant to 35 U.S.C. 203 and 210(c), and in accordance with the procedures in 37 CFR 401.6 and any supplemental regulations of the agency in effect on the date of contract award.

(i) Special provisions for contracts with nonprofit organizations. If the Contractor is a nonprofit organization, it shall--

(1) Not assign rights to a subject invention in the United States without the written approval of the agency, except where an assignment is made to an organization that has as one of its primary functions the management of inventions, provided, that the assignee shall be subject to the same provisions as the Contractor;

(2) Share royalties collected on a subject invention with the inventor, including Federal employee co-inventors (but through their agency if the agency deems it appropriate) when the subject invention is assigned in accordance with 35 U.S.C. 202(e) and 37 CFR 401.10;

(3) Use the balance of any royalties or income earned by the Contractor with respect to subject inventions, after payment of expenses (including payments to inventors) incidental to the administration of subject inventions for the support of scientific research or education; and

(4) Make efforts that are reasonable under the circumstances to attract licensees of subject inventions that are small business concerns, and give a preference to a small business concern when licensing a subject invention if the Contractor determines that the small business concern has a plan or proposal for marketing the invention which, if executed, is equally as likely to bring the invention to practical application as any plans or proposals from applicants that are not small business concerns; provided, that the Contractor is also satisfied that the small business concern has the capability and resources to carry out its plan or proposal. The decision whether to give a preference in any specific case will be at the discretion of the Contractor.

(5) Allow the Secretary of Commerce to review the Contractor's licensing program and decisions regarding small business applicants, and negotiate changes to its licensing policies, procedures, or practices with the Secretary of Commerce when the Secretary's review discloses that the Contractor could take reasonable steps to more effectively implement the requirements of paragraph (i)(4) of this clause.

(j) Communications.


Page 34 of 41

(k) Subcontracts. (1) The Contractor shall include the substance of this clause, including this paragraph (k), in all subcontracts for experimental, developmental, or research work to be performed by a small business concern or nonprofit organization.

(2) The Contractor shall include in all other subcontracts for experimental, developmental, or research work the substance of the patent rights clause required by FAR Subpart 27.3.

(3) At all tiers, the patent rights clause must be modified to identify the parties as follows: references to the Government are not changed, and the subcontractor has all rights and obligations of the Contractor in the clause. The Contractor shall not, as part of the consideration for awarding the subcontract, obtain rights in the subcontractor's subject inventions.

(4) In subcontracts, at any tier, the agency, the subcontractor, and the Contractor agree that the mutual obligations of the parties created by this clause constitute a contract between the subcontractor and the agency with respect to the matters covered by the clause; provided, however, that nothing in this paragraph is intended to confer any jurisdiction under the Contract Disputes statute in connection with proceedings under paragraph (h) of this clause.

(End of clause)

52.243 -2    CHANGES--COST-REIMBURSEMENT (AUG 1987) - ALTERNATE I (APR 1984)

(a) The Contracting Officer may at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract in any one or more of the following:

(1) Description of services to be performed.

(2) Time of performance (i.e., hours of the day, days of the week, etc.).

(3) Place of performance of the services.

(b) If any such change causes an increase or decrease in the estimated cost of, or the time required for, performance of any part of the work under this contract, whether or not changed by the order, or otherwise affects any other terms and conditions of this contract, the Contracting Officer shall make an equitable adjustment in the (1) estimated cost, delivery or completion schedule, or both; (2) amount of any fixed fee; and (3) other affected terms and shall modify the contract accordingly.

(c) The Contractor must assert its right to an adjustment under this clause within 30 days from the date of receipt of the written order. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract.

(d) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed.

(e) Notwithstanding the terms and conditions of paragraphs (a) and (b) above, the estimated cost of this contract and, if this contract is incrementally funded, the funds allotted for the performance of this contract, shall not be increased or considered to be increased except by specific written modification of the contract indicating the new contract estimated cost and, if this contract is incrementally funded, the new amount allotted to the contract. Until this modification is made, the Contractor shall not be obligated to continue performance or incur costs beyond the point established in the Limitation of Cost or Limitation of Funds clause of this contract.

(End of clause)


Page 35 of 41

52.243 -2     CHANGES--COST-REIMBURSEMENT (AUG 1987) - ALTERNATE V (APR 1984)

(a) The Contracting Officer may at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract in any one or more of the following:

(1) Drawings, designs, or specifications.

(2) Method of shipment or packing.

(3) Place of inspection, delivery, or acceptance.

(b) If any such change causes an increase or decrease in the estimated cost of, or the time required for, performance of any part of the work under this contract, whether or not changed by the order, or otherwise affects any other terms and conditions of this contract, the Contracting Officer shall make an equitable adjustment in the (1) estimated cost, delivery or completion schedule, or both; (2) amount of any fixed fee; and (3) other affected terms and shall modify the contract accordingly.

(c) The Contractor must assert its right to an adjustment under this clause within 30 days from the date of receipt of the written order. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract.

(d) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed.

(e) Notwithstanding the terms and conditions of paragraphs (a) and (b) above, the estimated cost of this contract and, if this contract is incrementally funded, the funds allotted for the performance of this contract, shall not be increased or considered to be increased except by specific written modification of the contract indicating the new contract estimated cost and, if this contract is incrementally funded, the new amount allotted to the contract. Until this modification is made, the Contractor shall not be obligated to continue performance or incur costs beyond the point established in the Limitation of Cost or Limitation of Funds clause of this contract.

(End of clause)

52.243 -7   NOTIFICATION OF CHANGES (APR 1984)

(a) Definitions.

"Contracting Officer," as used in this clause, does not include any representative of the Contracting Officer.

"Specifically authorized representative (SAR)," as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing, within 15 calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state--

(1) The date, nature, and circumstances of the conduct regarded as a change;


Page 36 of 41

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including--

(i) What contract line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Continued performance. Following submission of the notice required by (b) above, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in (b) above, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall countermand any action which exceeds the authority of the SAR.

(d) Government response. The Contracting Officer shall promptly, within 15 calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either--

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under (1), (2), or (3) above, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

(e) Equitable adjustments.

(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--


Page 37 of 41

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

Note: The phrases “contract price” and “cost” wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

(End of clause)

52.244 -2     SUBCONTRACTS (OCT 2010) - ALTERNATE I (JUN 2007)

(a) Definitions. As used in this clause--

Approved purchasing system means a Contractor's purchasing system that has been reviewed and approved in accordance with Part 44 of the Federal Acquisition Regulation (FAR).

Consent to subcontract means the Contracting Officer's written consent for the Contractor to enter into a particular subcontract.

Subcontract means any contract, as defined in FAR Subpart 2.1, entered into by a subcontractor to furnish supplies or services for performance of the prime contract or a subcontract. It includes, but is not limited to, purchase orders, and changes and modifications to purchase orders.

(b) When this clause is included in a fixed-price type contract, consent to subcontract is required only on unpriced contract actions (including unpriced modifications or unpriced delivery orders), and only if required in accordance with paragraph (c) or (d) of this clause.

(c) If the Contractor does not have an approved purchasing system, consent to subcontract is required for any subcontract that--

(1) Is of the cost-reimbursement, time-and-materials, or labor-hour type; or

(2) Is fixed-price and exceeds--

(i) For a contract awarded by the Department of Defense, the Coast Guard, or the National Aeronautics and Space Administration, the greater of the simplified acquisition threshold or 5 percent of the total estimated cost of the contract; or

(ii) For a contract awarded by a civilian agency other than the Coast Guard and the National Aeronautics and Space Administration, either the simplified acquisition threshold or 5 percent of the total estimated cost of the contract.

(d) If the Contractor has an approved purchasing system, the Contractor nevertheless shall obtain the Contracting Officer's written consent before placing the following subcontracts: N/A


Page 38 of 41

(e)(1) The Contractor shall notify the Contracting Officer reasonably in advance of placing any subcontract or modification thereof for which consent is required under paragraph (b), (c), or (d) of this clause, including the following information:

(i) A description of the supplies or services to be subcontracted.

(ii) Identification of the type of subcontract to be used.

(iii) Identification of the proposed subcontractor.

(iv) The proposed subcontract price.

(v) The subcontractor's current, complete, and accurate cost or pricing data and Certificate of Current Cost or Pricing Data, if required by other contract provisions.

(vi) The subcontractor's Disclosure Statement or Certificate relating to Cost Accounting Standards when such data are required by other provisions of this contract.

(vii) A negotiation memorandum reflecting--

(A) The principal elements of the subcontract price negotiations;

(B) The most significant considerations controlling establishment of initial or revised prices;

(C) The reason cost or pricing data were or were not required;

(D) The extent, if any, to which the Contractor did not rely on the subcontractor's cost or pricing data in determining the price objective and in negotiating the final price;

(E) The extent to which it was recognized in the negotiation that the subcontractor's cost or pricing data were not accurate, complete, or current; the action taken by the Contractor and the subcontractor; and the effect of any such defective data on the total price negotiated;

(F) The reasons for any significant difference between the Contractor's price objective and the price negotiated; and

(G) A complete explanation of the incentive fee or profit plan when incentives are used. The explanation shall identify each critical performance element, management decisions used to quantify each incentive element, reasons for the incentives, and a summary of all trade-off possibilities considered.

(2) If the Contractor has an approved purchasing system and consent is not required under paragraph (c), or (d) of this clause, the Contractor nevertheless shall notify the Contracting Officer reasonably in advance of entering into any (i) cost-plus-fixed-fee subcontract, or (ii) fixed-price subcontract that exceeds either the simplified acquisition threshold or 5 percent of the total estimated cost of this contract. The notification shall include the information required by paragraphs (e)(1)(i) through (e)(1)(iv) of this clause.

(f) Unless the consent or approval specifically provides otherwise, neither consent by the Contracting Officer to any subcontract nor approval of the Contractor's purchasing system shall constitute a determination--

(1) Of the acceptability of any subcontract terms or conditions;

(2) Of the allowability of any cost under this contract; or

(3) To relieve the Contractor of any responsibility for performing this contract.


Page 39 of 41

(g) No subcontract or modification thereof placed under this contract shall provide for payment on a cost-plus-a-percentage-of-cost basis, and any fee payable under cost-reimbursement type subcontracts shall not exceed the fee limitations in FAR 15.404 -4(c)(4)(i).

(h) The Contractor shall give the Contracting Officer immediate written notice of any action or suit filed and prompt notice of any claim made against the Contractor by any subcontractor or vendor that, in the opinion of the Contractor, may result in litigation related in any way to this contract, with respect to which the Contractor may be entitled to reimbursement from the Government.

(i) The Government reserves the right to review the Contractor's purchasing system as set forth in FAR Subpart 44.3.

(j) Paragraphs (c) and (e) of this clause do not apply to the following subcontracts, which were evaluated during negotiations: N/A

(End of clause)

52.252 -2     CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil
www/usamraa.army.mil

(End of clause)

52.252 -6     AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

252.225 -7043     ANTITERRORISM/FORCE PROTECTION POLICY FOR DEFENSE CONTRACTORS OUTSIDE THE UNITED STATES (MAR 2006)

(a) Definition. United States, as used in this clause, means, the 50 States, the District of Columbia, and outlying areas.

(b) Except as provided in paragraph (c) of this clause, the Contractor and its subcontractors, if performing or traveling outside the United States under this contract, shall--


Page 40 of 41

(1) Affiliate with the Overseas Security Advisory Council, if the Contractor or subcontractor is a U.S. entity;

(2) Ensure that Contractor and subcontractor personnel who are U.S. nationals and are in-country on a non-transitory basis, register with the U.S. Embassy, and that Contractor and subcontractor personnel who are third country nationals comply with any security related requirements of the Embassy of their nationality;

(3) Provide, to Contractor and subcontractor personnel, antiterrorism/force protection awareness information commensurate with that which the Department of Defense (DoD) provides to its military and civilian personnel and their families, to the extent such information can be made available prior to travel outside the United States; and

(4) Obtain and comply with the most current antiterrorism/force protection guidance for Contractor and subcontractor personnel.

(c) The requirements of this clause do not apply to any subcontractor that is-- (1) A foreign government; (2) A representative of a foreign government; or (3) A foreign corporation wholly owned by a foreign government.

(d) Information and guidance pertaining to DoD antiterrorism/force protection can be obtained from HQDA-AT;

(End of clause)


Page 41 of 41

Section J - List of Documents, Exhibits and Other Attachments

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1

Quality Assurance Surveillance Plan

8

22-JUN-2015

Attachment 10 CDRL A009 2 26-MAR-2015
Attachment 11 CDRL A010 2 26-MAR-2015
Attachment 12 CDRL A011 2 26-MAR-2015
Attachment 13 CDRL A012 2 26-MAR-2015
Attachment 14 CDRL A013 2 26-MAR-2015
Attachment 2 CDRL A001 2 26-MAR-2015
Attachment 3 CDRL A002 2 26-MAR-2015
Attachment 4 CDRL A003 2 26-MAR-2015
Attachment 5 CDRL A004 2 26-MAR-2015
Attachment 6 CDRL A005 2 26-MAR-2015
Attachment 7 CDRL A006 2 26-MAR-2015
Attachment 8 CDRL A007 2 26-MAR-2015
Attachment 9 CDRL A008 2 26-MAR-2015